STATE OF WEST VIRGINIA
Report of the Court of Claims 1981-1983
Volume 14
STATE OF WEST
VIRGINIA REPORT OF THE COURT OF CLAIMS
For the Period from July 1, 1981 to June 30, 1983
By
CHERYLE M. HALL
CLERK
VOLUME XIV
(Published by authority Code 14-2-25)
BJW PNTERS, BECKLEY, WV
CONTENTS III
TABLE
OF CONTENTS
Claims reported, table of LXX
Claims classified according to statute, list of XXX
Court of Claims Law VII
Letter of transmittal -
- V
Opinions of the Court LXIX
Personnel of the Court IV
References 515
Rules of Practice and Procedure XX
Terms of Court VI
IV PERSONNEL OF
THE STATE COURT OF CLAIMS
PERSONNEL
OF THE
STATE COURT OF CLAIMS
HONORABLE GEORGE S. WALLACE, JR.
Presiding Judge
HONORABLE JAMES C. LYONS Judge
HONORABLE WILLIAM W. GRACEY Judge
CHERYLE M. HALL Clerk
CHAUNCEY BROWNING, JR Attorney General
FORMER JUDGES
HONORABLE JULIUS W. SINGLETON, JR. July 1, 1967
?July 31, 1968
HONORABLE A. W. PETROPLUS -
- August 1, 1968
?June 30, 1974
HONORABLE HENRY LAKIN DUCKER July 1, 1967
?October 31, 1975
HONORABLE W. LYLE JONES -
- July 1, 1967
?June 30, 1976
HONORABLE JOHN B. GARDEN -
- July 1, 1974
?December 31, 1981
HONORABLE DANIEL A. RULEY, JR. July 1, 1976
?February 28, 1983
LETTER OF
TRANSMITTAL V
LETTER
OF TRANSMITTAL
To His Excellency
The Honorable John D. Rockefeller, IV
Governor of West Virginia
Sir:
In conformity with the requirements of section twenty-five of the Court of
Claims law, approved March eleventh, one thousand nine hundred sixty-seven, I
have the honor to transmit herewith the report of the State Court of Claims for
the period from July one, one thousand nine hundred eighty-one to June thirty,
one thousand nine hundred eightythree.
Respectfully submitted,
CHERYLE M. HALL,
Clerk
VI TERMS OF
COURT
TERMS OF COURT
Two regular terms of court are
provided for annually the second Monday of April and September.
STATE COURT OF
CLAIMS LAW VII
STATE COURT OF
CLAIMS LAW
CHAPTER 14 CODE
Article 2. Claims Against the State.
?14-2-1. Purpose.
? 14-2-2. Venue for certain suits and actions.
?14?2?3. Definitions.
?14-2-4. Creation of court of claims; appointment and terms of judges;
vacancies.
?14-2-5. Court clerk and other personnel.
?14-2-6. Terms of court.
? 14-2-7. Meeting place of the court.
? 14-2-8. Compensation of judges; expenses.
?14-2-9. Oath of office.
? 14-2-10. Qualifications of judges.
? 14-2-11. Attorney general to represent State.
?14-2-12. General powers of the court.
? 14?2?13. Jurisdiction of the court.
?14-2-14. Claims excluded.
? 14-2-15. Rules of practice and procedure.
? 14-2-16. Regular procedure.
?14-2-17. Shortened procedure.
? 14-2-18. Advisory determination procedure.
? 14-2-19. Claims under existing appropriations.
?14-2-20. Claims under special appropriations.
?14-2-21. Periods of limitation made applicable.
? 14-2-22. Compulsory process.
?14-2-23. Inclusion of awards in budget.
? 14-2-24. Records to be preserved.
? 14-2-25. Reports of the court.
? 14-2-26. Fraudulent claims.
? 14-2-27. Conclusiveness of determination.
? 14-2-28. Award as condition precedent to appropriation.
? 14-2-29. Severability.
?14-2-1. Purpose.
The purpose of this article is to
provide a simple and expeditious method for the consideration of claims against
the State that because of the provisions of section 35, article VI of the
Constitution of the State, and of statutory restrictions, inhibitions or
limitations, cannot be determined in the regular courts of the State; and to provide
for proceedings in which the State has a special interest.
VIII STATE
COURT OF CLAIMS LAW
?14-2.2. Venue for certain suits and actions.
(a) The following proceedings shall be
brought and prosecuted only in the circuit court of Kanawha county:
(1) Any suit in which the governor, any other state officer, or a state agency
is made a party defendant, except as garnishee or suggestee.
(2) Any suit attempting to enjoin or otherwise suspend or affect a judgment or
decree on behalf of the State obtained in any circuit court.
(b) Any proceeding for injunctive or mandamus relief involving the taking,
title, or collection for or prevention of damage to real property may be
brought and presented in the circuit court of the county in which the real
property affected is situate.
This section shall apply only to such proceedings as are not prohibited by the
constitutional immunity of the State from suit under section 35, article VI of
the Constitution of the State.
?14-2.3. Definitions.
For the purpose of this article:
?Court? means the state court of claims established by section four [l4-2-4] of
this article.
?Claim? means a claim authorized to be heard by the court in accordance with
this article.
?Approved claim? means a claim found by the court to be one that should be paid
under the provisions of this article.
?Award? means the amount recommended by the court to be paid in satisfaction of
an approved claim.
?Clerk? means the clerk of the court of claims.
?State agency? means a state department, board, commission, institution, or
other administrative agency of state government:
Provided, that a ?state agency? shall not be considered to include county
courts, county boards of education, municipalities, or any other political or
local subdivision of this State regardless of any state aid that might be
provided.
STATE COURT OF
CLAIMS LAW IX
?14-2-4. Creation of court of claims; appointment and terms of judges;
vacancies.
The ?court of claims? is hereby
created. It shall consist of three judges, to be appointed by the president of
the senate and the speaker of the house of delegates, by and with the advice
and consent of the senate, one of whom shall be appointed presiding judge. Each
appointment to the court shall be made from a list of three qualified nominees
furnished by the board of governors of the West Virginia State bar.
The terms of the judges of this court shall be six years, except that the first
members of the court shall be appointed as follows: One judge for two years,
one judge for four years and one judge for six years. As these appointments
expire, all appointments shall be for six year terms. Not more than two of the
judges shall be of the same political party. An appointment to fill a vacancy
shall be for the unexpired term.
?14-2-5. Court clerk and other
personnel.
The court shall have the authority to
appoint a clerk and a deputy clerk. The salary of the clerk and the deputy
clerk shall be fixed by the joint committee on government and finance, and
shall be paid out of the regular appropriation for the court. The clerk shall
have custody of all records and proceedings of the court, shall attend meetings
and hearings of the court, shall administer oaths and affirmations, and shall
issue all official summonses, subpoenas, orders, statements and awards. The
deputy clerk shall act in the place and stead of the clerk in the clerk?s
absence.
The joint committee on government and finance may employ other persons whose
services shall be necessary to the orderly transaction of the business of the
court, and fix their compensation.
?14-2-6. Terms of court.
The court shall hold at least two
regular terms each year, on the second Monday in April and September. So far as
possible, the court shall not adjourn a regular term until all claims then upon
its docket and ready for hearing or other consideration have been disposed of.
X STATE
COURT OF CLAIMS LAW
Special terms or meetings may be
called by the clerk at the request of the court whenever the number of claims
awaiting consideration, or any other pressing matter of official business, make
such a term advisable.
?14-2-7. Meeting place of the court.
The regular meeting place of the court
shall be at the state capitol, and the joint committee on government and
finance shall provide adequate quarters therefor. When deemed advisable, in
order to facilitate the full hearing of claims arising elsewhere in the State,
the court may convene at any county seat.
?14-2-8. Compensation of judges;
expenses.
Each judge of the court shall receive
one hundred fifteen dollars for each day actually served, and actual expenses
incurred in the performance of his duties. The number of days served by each
judge shall not exceed one hundred in any fiscal year, except by authority of
the joint committee on government and finance: Provided, that in computing the
number of days served, days utilized solely for the exercise of duties assigned
to judges and commissioners by the provisions of article two-A [ 14-2A-l et seq.] of this chapter shall be disregarded. Requisitions for
compensation and expenses shall be accompanied by sworn and itemized
statements, which shall be filed with the auditor and preserved as public
records. For the purpose of this section, time served shall include time spent
in the hearing of claims, in the consideration of the record, in the
preparation of opinions, and in necessary travel.
?14-2.9. Oath of office.
Each judge shall before entering upon
the duties of his office, take and subscribe to the oath prescribed by section
5, article IV of the Constitution of the State. The oath shall be filed with
the clerk.
?14-2-10. Qualifications of judges.
Each judge appointed to the court of
claims shall be an attorney at law, licensed to practice in this State and
shall have been so licensed to practice law for a period of not less than ten
years prior to his appointment as judge. A judge shall not be
STATE COURT OF
CLAIMS LAW XI
an officer or an employee of any
branch of state government, except in his capacity as a member of the court and
shall receive no other compensation from the State or any of its political
subdivisions. A judge shall not hear or participate in the consideration of any
claim in which he is interested personally, either directly or indirectly.
?14-2-11. Attorney general to
represent State.
The attorney general shall represent
the interests of the State in all claims coming before the court.
?14-2.12. General powers of the court.
The court shall, in accordance with
this article, consider claims which, but for the constitutional immunity of the
State from suit, or for some statutory restrictions, inhibitions or
limitations, could be maintained in the regular courts of the State. No
liability shall be imposed upon the State or any state agency by a
determination of the court of claims approving a claim and recommending an
award, unless the claim is (1) made under an existing appropriation, in
accordance with section nineteen [
14-2-19] of this article, or (2) a claim
under a special appropriation, as provided in section twenty [ 14- 2-20] of this article. The court shall consider claims in accordance
with the provisions of this article.
Except as is otherwise provided in this article, a claim shall be instituted by
the filing of notice with the clerk. In accordance with rules promulgated by
the court, each claim shall be considered by the court as a whole, or by a
judge sitting individually, and if, after consideration, the court finds that a
claim is just and proper, it shall so determine and shall file with the clerk a
brief statement of its reasons. A claim so filed shall be an approved claim.
The court shall also determine the amount that should be paid to the claimant,
and shall itemize this amount as an award, with the reasons therefor, in its
statement filed with the clerk. In determining the amount of a claim, interest
shall not be allowed unless the claim is based upon a contract which
specifically provides for the payment of interest.
?14-2-13. Jurisdiction of the court.
The jurisdiction of the court, except for
the claims excluded
XII STATE
COURT OF CLAIMS LAW
by section fourteen [ 14-2-14], shall extend to the following matters:
1. Claims and demands, liquidated and unliquidated, ex contractu and ex
delicto, against the State or any of its agencies, which the State as a
sovereign commonwealth should in equity and good conscience discharge and pay.
2. Claims and demands, liquidated and unliquidated, ex contractu and ex
delicto, which may be asserted in the nature of setoff or counterclaim on the
part of the State or any state agency.
3. The legal or equitable status, or both, of any claim referred to the court
by the head of a state agency for an advisory determination.
?14-2-14. Claims excluded.
The jurisdiction of the court shall
not extend to any claim:
1. For loss, damage, or destruction of property or for injury or death incurred
by a member of the militia or national guard when in the service of the State.
2. For a disability or death benefit under chapter twenty- three [ 23-1-1 et
seq.] of this Code.
3. For unemployment compensation under chapter twenty- one-A { 21A-1-1 et seq.] of this Code.
4. For relief or public assistance under chapter nine [ 9-1-1 et seq.] of this
Code.
5. With respect to which a proceeding may be maintained against the State, by
or on behalf of the claimant in the courts of the State.
?14-2-15. Rules of practice and
procedure.
The court shall adopt and may from
time to time amend rules of procedure, in accordance with the provisions of
this article, governing proceedings before the court. Rules shall be designed
to assure a simple, expeditious and inexpensive consideration of claims. Rules
shall permit a claimant to appear in his own behalf or be represented by
counsel.
STATE COURT OF
CLAIMS LAW XIII
Under its rules, the court shall not
be bound by the usual common law or statutory rules of evidence. The court may
accept and weigh, in accordance with its evidential value, any information that
will assist the court in determining the factual basis of a claim.
?14-2-16. Regular procedure.
The regular procedure for the
consideration of claims shall be substantially as follows:
1. The claimant shall give notice to the clerk that he desires to maintain a
claim. Notice shall be in writing and shall be in sufficient detail to identify
the claimant, the circumstances giving rise to the claim, and the state agency
concerned, if any. The claimant shall not otherwise be held to any formal
requirement of notice.
2. The clerk shall transmit a copy of the notice to the state agency concerned.
The state agency may deny the claim, or may request a postponement of
proceedings to permit negotiations with the claimant. If the court finds that a
claim is prima facie within its jurisdiction, it shall order the claim to be
placed upon its regular docket for hearing.
3. During the period of negotiations and pending hearing, the state agency,
represented by the attorney general, shall, if possible, reach an agreement
with the claimant regarding the facts upon which the claim is based so as to
avoid the necessity for the introduction of evidence at the hearing. If the
parties are unable to agree upon the facts an attempt shall be made to
stipulate the questions of fact in issue.
4. The court shall so conduct the hearing as to disclose all material facts and
issues of liability and may examine or cross- examine witnesses. The court may
call witnesses or require evidence not produced by the parties; may stipulate
the questions to be argued by the parties; and may continue the hearing until some
subsequent time to permit a more complete presentation of the claim.
5. After the close of the hearing the court shall consider the claim and shall
conclude its determination, if possible, within thirty days.
XIV STATE
COURT OF CLAIMS LAW
?14-2-17. Shortened procedure.
The shortened procedure authorized by
this section shall apply only to a claim possessing all of the following
characteristics:
1. The claim does not arise under an appropriation for the current fiscal year.
2. The state agency concerned concurs in the claim.
3. The amount claimed does not exceed one thousand dollars.
4. The claim has been approved by the attorney general as one that, in view of
the purposes of this article, should be paid.
The state agency concerned shall prepare the record of the claim consisting of
all papers, stipulations and evidential documents required by the rules of the
court and file the same with the clerk. The court shall consider the claim
informally upon the record submitted. If the court determines that the claim
should be entered as an approved claim and an award made, it shall so order and
shall file its statement with the clerk. Tithe court finds that the record is
inadequate, or that the claim should not be paid, it shall reject the claim.
The rejection of a claim under this section shall not bar its resubmission
under the regular procedure.
?14-2-18. Advisory determination
procedure.
The governor or the head of a state
agency may refer to the court for an advisory determination the question of the
legal or equitable status, or both, of a claim against the State or a state
agency. This procedure shall apply only to such claims as are within the
jurisdiction of the court. The procedure shall be substantially as follows:
1. There shall be filed with the clerk, the record of the claim including a
full statement of the facts, the contentions of the claimant, and such other
materials as the rules of the court may require. The record shall submit
specific questions for the court?s consideration.
2. The clerk shall examine the record submitted and if he
STATE COURT OF
CLAIMS LAW XV
finds that it is adequate under the
rules, he shall place the claim on a special docket. If he finds the record
inadequate, he shall refer it back to the officer submitting it with the
request that the necessary additions or changes be made.
3. When a claim is reached on the special docket, the court shall prepare a
brief opinion for the information and guidance of the officer. The claim shall
be considered informally and without hearing. A claimant shall not be entitled
to appear in connection with the consideration of the claim.
4. The opinion shall be filed with the clerk. A copy shall be transmitted to
the officer who referred the claim.
An advisory determination shall not bar the subsequent consideration of the
same claim if properly submitted by, or on behalf of, the claimant. Such
subsequent consideration, if undertaken, shall be de novo.
?14-2-19. Claims under existing
appropriations.
A claim arising under an appropriation
made by the legislature during the fiscal year to which the appropriation
applies, and falling within the jurisdiction of the court, may be submitted by:
1. A claimant whose claim has been rejected by the state agency concerned or by
the state auditor.
2. The head of the state agency concerned in order to obtain a determination of
the matters in issue.
3. The state auditor in order to obtain a full hearing and consideration of the
merits.
The regular procedure, so far as applicable, shall govern the consideration of
the claim by the court. If the court finds that the claimant should be paid, it
shall certify the approved claim and award to the head of the appropriate state
agency, the state auditor, and to the governor. The governor may thereupon
instruct the auditor to issue his warrant in payment of the award and to charge
the amount thereof to the proper appropriation. The auditor shall forthwith
notify the state agency that the claim has been paid. Such an expediture shall
not be subject to further review by the auditor upon any matter determined and
certified by the court.
XVI STATE
COURT OF CLAIMS LAW
?14-2-20. Claims under special appropriations.
Whenever the legislature makes an
appropriation for the payment of claims against the State, then accrued or
arising during the ensuing fiscal year, the determination of claims and the
payment thereof may be made in accordance with this section. However, this
section shall apply only if the legislature in making its appropriation
specifically so provides.
The claim shall be considered and determined by the regular or shortened
procedure, as the case may be, and the amount of the award shall be fixed by
the court. The clerk shall certify each approved claim and award, and
requistion relating thereto, to the auditor. The auditor thereupon shall issue
his warrant to the treasurer in favor of the claimant. The auditor shall issue
his warrant without further examination or review of the claim except for the
question of a sufficient unexpended balance in the appropriation.
?14-2-21. Periods of limitation made
applicable.
The court shall not take jurisdiction
of any claim, whether accruing before or after the effective date of this
article [July 1, 19671, unless notice of such claim be filed with the clerk
within such period of limitation as would be applicable under the pertinent
provisions of the Code of West Virginia, one thousand nine hundred thirty-one,
as amended, if the claim were against a private person, firm or corporation and
the constitutional immunity of the State from suit were not involved and such
period of limitation may not be waived or extended. The foregoing provision
shall not be held to limit or restrict the right of any person, firm or
corporation who or which had a claim against the State or any state agency,
pending before the attorney general on the effective date of this article [July
1, 1967J, from presenting such claim to the court of claims, nor shall it limit
or restrict the right to file such a claim which was, on the effective date of
this article [July 1, 1967], pending in any court of record as a legal claim
and which, after such date was or may be adjudicated in such court to be
invalid as a claim against the State because of the constitutional immunity of
the State from suit.
STATE COURT OF
CLAIMS LAW XVII
?14-2-22. Compulsory process.
In all hearings and proceedings before
the court, the evidence and testimony of witnesses and the production of
documentary evidence may be required. Subpoenas may be issued by the court for
appearance at any designated place of hearing. In case of disobedience to a
subpoena or other process, the court may invoke the aid of any circuit court in
requiring the evidence and testimony of witnesses, and the production of books,
papers and documents. Upon proper showing, the circuit court shall issue an
order requiring witnesses to appear before the court of claims; produce books,
papers and other evidence; and give testimony touching the matter in question.
A person failing to obey the order may be punished by the circuit court as for
contempt.
?14-2-23. Inclusion of awards in
budget.
The clerk shall certify to the
department of finance and administration, on or before the twentieth day of
November of each year, a list of all awards recommended by the court to the
legislature for appropriation. The clerk may certify supplementary lists to the
governor to include subsequent awards made by the court. The governor shall
include all awards so certified in his proposed budget bill transmitted to the
legislature.
?14-2-24. Records to be preserved.
The record of each claim considered by
the court, including all documents, papers, briefs, transcripts of testimony
and other materials, shall be preserved by the clerk and shall be made
available to the legislature or any committee thereof for the reexamination of
the claim.
?14-2-25. Reports of the court.
The clerk shall be the official
reporter of the court. He shall collect and edit the approved claims, awards
and statements, shall prepare them for submission to the legislature in the
form of an annual report and shall prepare them for publication.
Claims and awards shall be separately classified as follows:
1. Approved claims and awards not satisfied but referred to the legislature for
final consideration and appropriation.
XVIII STATE
COURT OF CLAIMS LAW
2. Approved claims and awards
satisfied by payments out of regular appropriations.
3. Approved claims and awards satisfied by payment out of a special
appropriation made by the legislature to pay claims arising during the fiscal
year.
4. Claims rejected by the court with the reasons therefor.
5. Advisory determinations made at the request of the governor or the head of a
state agency.
The court may include any other information or recommendations pertaining to
the performance of its duties.
The court shall transmit its annual report to the presiding officer of each
house of the legislature, and a copy shall be made available to any member of
the legislature upon request therefor. The reports of the court shall be
published biennially by the clerk as a public document. The biennial report
shall be filed with the clerk of each house of the legislature, the governor
and the attorney general.
?14-2-26. Fraudulent claims.
A person who knowingly and wilfully
presents or attempts to present a false or fraudulent claim, or a state officer or
employee who knowingly and wilfully participates or assists in the preparation
or presentation of a false or fraudulent claim, shall be guilty of a misdemeanor.
A person convicted, in a court of competent jurisdiction, of violation of this
section shall be fined not more than one thousand dollars or imprisoned for not
more than one year, or both, in the discretion of such court. If the convicted
person is a state officer or employee, he shall, in addition, forfeit his
office or position of employment, as the case may be.
?14-2-27. Conclusiveness of
determination.
Any final determination against the
claimant on any claim presented as provided in this article shall forever bar
any further claim in the court arising out of the rejected claim.
?14-2-28. Award as condition precedent
to appropriation.
It is the policy of the legislature to
make no appropriation to
STATE COURT OF
CLAIMS LAW XIX
pay any claims against the State, cognizable by the court, unless the claim has
first been passed upon by the court.
?14-2.29. Severability.
If any provision of this article or
the application thereof to any person or circumstance be held invalid, such invalidity
shall not affect other provisions or applications of the article which can be
given effect without the invalid provision or application, and to this end the
provisions of this article are declared to be severable.
XX RULES OF
PRACTICE AND PROCEDURE
Rules of Practice
and
Procedure
of the
STATE COURT OF CLAIMS
(Adopted by the Court
September 11, 1967.
Amended February 18, 1970
Amended February 23, 1972
Amended August 1, 1978
Amended May 3, 1982.)
RULES OF
PRACTICE AND PROCEDURE XXI
TABLE
OF RULES
Rules of Practice and Procedure
RULE
1. Clerk, Custodian of Papers, etc.
2. Filing Papers.
3. Records.
4. Form of Claims.
5. Copy of Notice of Claims to Attorney General and State Agency.
6. Preparation of Hearing Docket.
7. Proof and Rules Governing Procedure.
8. Appearances.
9. Briefs.
10. Continuances: Dismissal For Failure to Prosecute.
11. Original Papers Not To Be Withdrawn: Exceptions.
12. Withdrawal of Claim.
13. Witnesses.
14. Depositions and Interrogatories.
15. Re-Hearings.
16. Records of Shortened Procedure Claims Submitted by State Agencies.
17. Application of Rules of Civil Procedure.
XXII RULES OF
PRACTICE AND PROCEDURE
RULES
OF PRACTICE AND PROCEDURE
OF THE
COURT OF CLAIMS
STATE OF WEST VIRGINIA
RULE 1. CLERK, CUSTODIAN OF
PAPERS, ETC.
The Clerk shall be responsible for
all papers and claims filed in his office; and will be required to properly
file, in an index for that purpose, any paper, pleading, document, or other
writing filed in connection with any claim. The Clerk shall also properly
endorse all such papers and claims, showing the titlq of the claim, the number
of the same, and such other data as may be necessary to properly connect and
identify the document, writing, or claim.
RULE 2. FILING PAPERS.
(a) Communications addressed to the Court or Clerk and all notices,
petitions, answers and other pleadings, all reports, documents received or
filed in the office kept by the Clerk of this Court, shall be endorsed by him
showing the date of the receipt or filing thereof.
(b) The Clerk, upon receipt of a notice of a claim, shall enter of record in
the docket book indexed and kept for that purpose, the name of the claimant,
whose name shall be used as the title of the case, and a case number shall be
assigned accordingly.
(c) No paper, exclusive of exhibits, shall be filed in any action or proceeding
or be accepted by the Clerk for filing nor any brief, deposition, pleading,
order, decree, reporter?s transcript or other paper to be made a part of the
record in any claim be received except that the same be upon paper measuring 8
1/2 inches in width and 11 inches in length.
RULES OF
PRACTICE AND PROCEDURE XXIII
RULE 3. RECORDS.
The Clerk shall keep the following
record books, suitably indexed in the names of claimants and other subject
matter:
(a) Order Book, in which shall be recorded at large, on the day of their
filing, all orders made by the Court in each case or proceeding.
(b) Docket Book, in which shall be entered each case or claim made and filed,
with a file or case number corresponding to the number of the case, together
with brief chronological notations of the proceedings had in each case.
(c) Financial Ledger, in which shall be entered chronologically, all
administrative expenditures of the Court under suitable classifications.
RULE 4. FORM OF CLAIMS.
Verified notice in writing of each
claim must be filed with the Clerk of the Court. The notice shall be in
sufficient detail to identify the claimant, the circumstances giving rise to the
claim, and the State agency concerned, if any. The Court reserves the right to
require further information before hearing, when, in its judgment, justice and
equity may require. It is recommended that notice of claims be furnished in
triplicate. A suggested form of notice of claim may be obtained from the Clerk.
RULE 5. COPY OF NOTICE OF CLAIMS TO
ATTORNEY
GENERAL AND STATE AGENCY.
Upon receipt of a notice of claim to
be considered by the Court, the Clerk shall forthwith transmit a copy of the
notice to the State agency concerned, if any, and a copy thereof to the Office
of the Attorney General of the State, and the Clerk shall make a note of the
time of such delivery.
RULE 6. PREPARATION OF HEARING DOCKET.
On and after the date of adoption of
these rules by the Court, the Clerk shall prepare, fifteen days previous to the
regular terms of Court, a docket listing all claims that are
XXIV RULES OF
PRACTICE AND PROCEDURE
ready for hearing by the Court, and
showing the respective dates, as fixed by the Court, for the hearing thereof.
The Court reserves the right to add to, rearrange, or change said docket when
in its judgment such addition, rearrangement, or change would expedite the work
of the term. Each claimant or his counsel of record and the Attorney General
shall be notified as to the date, time, and place of the hearing.
RULE 7. PROOF AND
RULES GOVERNING PROCEDURE.
(a) Claims asserted against the State,
including all the allegations in a notice of claim, are treated as denied, and
must be established by the claimant with satisfactory proof, or proper
stipulation as hereinafter provided before an award can be made.
(b) The Court shall not be bound by the usual common law or statutory rules of
evidence. The Court may accept and weigh, in accordance with its evidential
value, any information that will assist the Court in determining the factual
basis of the claim.
(c) The Attorney General shall, within twenty days after a copy of the notice
has been furnished his office, file with the Clerk a notice in writing, either
denying the claim, requesting postponement of proceedings to permit
negotiations with the claimant, or otherwise setting forth reasons for further
investigation of the claim, and furnish the claimant or his counsel of record a
copy thereof. Otherwise, after said twenty- day period, the Court may order the
claim placed upon its regular docket for hearing.
(d) It shall be the duty of the claimant or his counsel in claims under the
regular procedure to negotiate with the Office of the Attorney General so that
the claimant and the State agency and the Attorney General may be ready at the
beginning of the hearing of a claim to read, if reduced to writing, or to
dictate orally, if not reduced to writing, into the record such stipulations, if
any, as the parties may have been able to agree upon.
(e) Where there is a controversy between a claimant and any State agency, the
Court may require each party to reduce
RULES OF PRACTICE
AND PROCEDURE XXV
the facts to writing, and, if the parties are not in agreement as to the facts,
the Court may stipulate the questions of fact in issue and require written
answers to the said stipulated questions.
(f) Claims not exceeding the sum of $10,000.00 may be heard and considered, as
provided by law, by one judge sitting individually.
RULE 8. APPEARANCES.
Any claimant may appear in his own
behalf or have his claim presented by counsel, duly admitted as such to
practice law in the State of West Virginia.
RULE 9. BRIEFS.
(a) Claimants or their counsel, and
the Attorney General, may file with the Court, for its consideration, a brief
on any question involved, provided a copy of said brief is also presented to
and furnished the opposing party or counsel. Reply briefs shall be filed within
fifteen days.
(b) All briefs filed with, and for the use of, the Court shall be in
quadruplicate -
original and three copies. As soon as any
brief is received by the Clerk, he shall file the original in the Court file
and deliver the three copies, one each, to the Judges of the Court.
RULE 10. CONTINUANCES: DISMISSAL FOR
FAILURE TO PROSECUTE.
(a) After claims have been set for
hearing, continuances are looked upon by the Court with disfavor, but may be
allowed when good cause is shown.
(b) A party desiring a continuance should file a motion showing good cause
therefor at the earliest possible date.
(c) Whenever any claim has been docketed for hearing for three regular terms of
Court at which the claim might have been prosecuted, and the State shall have
been ready to proceed with the trial thereof, the Court may, upon its own
motion or that of the State, dismiss the claim unless good cause appear or
XXVI RULES OF
PRACTICE AND PROCEDURE
be shown by the claimant why such claim has not been prosecuted.
(d) Whenever a claimant shall fail to appear and prosecute his claim on the day
set for hearing and shall not have communicated with the Clerk prior thereto,
advising of his inability to attend and the reason therefor, and, if it further
appear that the claimant or his counsel had sufficient notice of the docketing
of the claim for hearing, the Court may, upon its own motion or that of the
State, dismiss the claim.
(e) Within the discretion of the Court, no order dismissing a claim under
either of the two preceding sections of this rule shall be vacated nor the
hearing of such claim be reopened except by a notice in writing filed not later
than the end of the next regular term of Court, supported by affidavits showing
sufficient reason why the order dismissing such claim should be vacated, the
claim reinstated, and the trial thereof permitted.
RULE 11. ORIGINAL PAPERS NOT TO BE
WITHDRAWN:
EXCEPTIONS.
No original paper in any case shall be
withdrawn from the Court files except upon special order of the Court or one of
the Judges thereof in vacation. When an official of a State department is
testifying from an original record of his department, a certified copy of the
original record of such department may be filed in the place and stead of the
original.
RULE 12. WITHDRAWAL OF CLAIM.
(a) Any claimant may withdraw his
claim. Should the claimant later refile the claim, the Court shall consider its
former status, such as previous continuances and any other matter affecting its
standing, and may re-docket or refuse to re-docket the claim as, in its
judgment, justice and equity may require under the circumstances.
(b) Any department or State agency, having filed a claim for the Court?s
consideration, under either the advisory determination procedure or the
shortened procedure provision of the Court Act, may withdraw the claim without
prejudice to the right of the claimant involved to file the claim under the
regular procedure.
RULES OF
PRACTICE AND PROCEDURE XXVII
RULE 13. WITNESSES.
(a) For the purpose of convenience and
in order that proper records may be preserved, claimants and State departments
desiring to have subpoenas for witnesses shall file with the Clerk a memorandum
in writing giving the style and number of the claim and setting forth the names
of such witnesses, and thereupon such subpoenas shall be issued and delivered
to the person calling therefor or mailed to the person designated.
(b) Requests for subpoenas for witnesses should be furnished to the Clerk well
in advance of the hearing date so that such subpoenas may be issued in ample
time before the hearing.
(c) The payment of witness fees and mileage (where transportation is not
furnished to any witness subpoenaed by or at the instance of either the
claimant or the respondent State agency) shall be the responsibility of the
party by whom or at whose instance such witness is subpoenaed.
RULE 14. DEPOSITIONS AND
INTERROGATORIES.
(a) Depositions may be taken when a
party desires the testimony of any person, including a claimant. The deposition
shall be upon oral examination or upon written interrogatory. Depositions may
be taken without leave of the Court. The attendance of witnesses may be
compelled by the use of subpoenas as provided in Rule 13.
(b) To take the deposition of any designated witness, reasonable notice of time
and place shall be given the opposite party or counsel, and the party taking
such deposition shall pay the costs thereof and file an original and three
copies of such deposition with the Court. Extra copies of exhibits will not be
required; however, it is suggested that where exhibits are not too lengthy and
are of such nature as to permit it, they should be read into the deposition.
(c) Depositions shall be taken in accordance with the provision of Rule 17 of
this Court.
(d) Unless otherwise permitted by the Court for good
XXVIII RULES OF
PRACTICE AND PROCEDURE
cause, no party shall serve upon any other party, at one time or cumulatively,
more than 30 written interrogatories, including parts and subparts. Sufficient
space for insertion of the answer shall be provided after each interrogatory or
subpart thereof. The original shall be filed with the Clerk, and two copies
shall be served upon the answering party. After inserting answers on the copies
served him, the answering party shall file one copy with the Clerk and serve
one copy on the issuing party. If there is insufficient space on the original
for insertion of answers, the answering party may attach supplemental pages.
RULE 15. REHEARINGS.
A rehearing shall not be allowed
except where good cause is shown. A motion for rehearing may be entertained and
considered ex parte, unless the Court otherwise directs, upon the petition and
brief filed by the party seeking the rehearing. Such petition and brief shall
be filed within thirty days after notice of the Court?s determination of the
claim unless good cause be shown why the time should be extended.
RULE 16. RECORDS OF SHORTENED
PROCEDURE
CLAIMS SUBMITTED BY STATE AGENCIES.
When a claim is submitted under the
provisions of Chapter 14, Article 2, Paragraph 17 of the Code of West Virginia,
concurred in by the head of the department and approved for payment by the
Attorney General, the record thereof, in addition to copies of correspondence,
bills, invoices, photographs, sketches or other exhibits, should contain a
full, clear, and accurate statement, in narrative form, of the facts upon which
the claim is based. The facts in such record, among other things which may be
peculiar to the particular claim, should show as definitely as possible that:
(a) The claimant did not, through neglect, default, or lack of reasonable care,
cause the damage of which he complains. It should appear he was innocent and
without fault in the matter.
(b) The department, by or through neglect, default, or failure to use
reasonable care under the circumstances, caused
RULES OF PRACTICE
AND PROCEDURE XXIX
the damage to claimant, so that the State in justice and equity should be held
liable.
(c) The amount of the claim should be itemized and supported by a paid invoice
or other report itemizing the damages, and vouched for by the head of the
department as to correctness and reasonableness.
RULE 17. APPLICATION OF RULES OF CIVIL
PROCEDURE.
The Rules of Civil Procedure will
apply in the Court of Claims unless the Rules of Practice and Procedure of the
Court of Claims are to the contrary.
Adopted by Order of the Court
of Claims, September 11, 1967.
Amended February 18, 1970.
Amended February 23, 1972.
Amended August 1, 1978.
Amended May 3, 1982.
CHERYLE M. HALL, Clerk
REPORT OF THE COURT OF CLAIMS For the Period Ju?y 1, 1981 to June 30, 1983
CI)
-4
Cl
?-I
-4
C
C
Cl
-4
Ci)
Ci)
(1) Approved claims and awards not satisfied but to be referred to the 1984 Legislature |
for |
final consideration and |
|||
appropriation: |
|
|
|
|
|
|
|
|
Amount |
|
Amount Date of |
No. Name of Claimant |
Name of Respondent |
|
Claimed |
|
Awarded Determination |
CC-81-55 Appalachian Engineers, Inc. |
Board of Regents |
$ |
9,434.53 |
$ |
9,434.53 6-30-83 |
CC-83-l11 Appalachian Power Company |
Department of Public Safety |
|
29.36 |
|
29.36 5-25-83 |
CC-83-118 Appalachian Power Company |
Department of Public Safety |
|
106.80 |
|
106.80 5-25-83 |
CC-83-35 Bailey, Incorporated |
Board of Regents |
|
131.01 |
|
131.01 5-25-83 |
CC-80-405 Wayne K. Baker, d/b/a |
Department of Highways |
|
22,800.00 |
|
9,000.00 3-16-83 |
Baker Coal Company |
|
|
|
|
|
CC-83-30 Beckman Instruments, Inc. |
Department of Health |
|
198.50 |
|
198.50 4-22-83 |
CC-80-252 James Burcham and |
Department of Highways |
|
2,006.67 |
|
1,605.33 4-22-83 |
Patricia J. Burcham |
|
|
|
|
|
CC-81-204 Armeda Jean Bush |
Department of Highways |
|
50,000.00 |
|
1,050.00 6-30-83 |
CC-81-440 Butler Corporation |
Department of Highways |
|
752.00 |
|
752.00 4-22-83 |
CC-82-103 C. W. Lewis, Inc. |
Department of Corrections |
|
410.20 |
|
410.20 3-16-83 |
CC-79-527 Betty Cook |
Department of Highways |
|
25,000.00 |
|
18,910.00 6-29-l3 |
CC-83-153 Foster & Creighton |
Department of Highways |
|
2,499.74 |
|
2,499.74 6-13-83 |
Company and Vecellio |
|
|
|
|
|
& Grogan, Inc. |
|
|
|
|
|
CC-80-373 Millard A. Harmon |
Department of Highways |
|
200,000.00 |
|
14,805.79 5-19-83 |
CC-80-173 U. G. Harrison and Edna Harrison |
Department of Highways |
|
32,400.84 |
|
8,800.00 5-19-83 |
CC-80-415 Lois V. Haynes and |
Department of Highways |
|
250,000.00 |
|
50,000.00 5-19-83 |
E. Robert Haynes |
|
|
|
|
|
CC-83-28 Holzer Medical Center CC-80-334 Norman Lewis |
Department of Health Department of Highways |
|
99.00 |
|
99.00 4-22-83 |
CC-78-248 Robert Marcum and |
Department of Highways |
|
25,000.00 |
|
10,799.00 5-19-83 |
Loretta Marcum |
|
|
|
|
|
REPORT OF THE COURT OF CLAIMS (Continued)
No. Name of
Claimant
CC-81-90 Andrew S. McGalla
CC-78-222 Lillian Akers Meade,
Administratrix of the
Estate of Gary Wayne
Akers, deceased
CC-78-222 Lillian Akers Meade, as guardian for and
on behalf of Christopher Lewis Akers
CC?78-222 Lillian Akers Meade, as guardian for and on behalf of Steven Wayne
Akers
CC-81-396 Paul E. Miller and
Marguerite Miller
CC-83-43 Miller?s Implement, Inc.
CC-79-679 Francis L. Parker
CC-83-26 S.S. Logan Packing Company
CC-78-165 Shelly & Sands, Inc.
CC-8l-359 Donald F. TJdeU
CC-81-425 Vecellio & Grogan, Inc.
CC-82-92 Vecellio & Grogan, Inc.
CC-83-40 Edwin 0. Walker
Name of
Respondent
Board of Regents Department of
Highways
610.00 610,00
44,050.34 44,050.34
38,061.33 38,061.33
38,061.33 38,061.33
39,000.00 39,000.00
5-19-83
6-30-83
6-30-83
6-30-83
6-24-83
(1) Approved claims and awards not satisfied but to be referred to the appropriation:
1984 Legislature
for final consideration and
Amount Amount Date of Claimed Awarded Determination
C)
Ci)
CI)
C)
1-4
C
0
C.)
Cl)
e
CI)
Department of Highways |
|
||
Department of Highways |
|||
Department of Highways |
|||
Department of Health |
92.65 |
92.65 |
5-25-83 |
Department of Health |
12,000.00 |
8,000.00 |
6-29-83 |
Board of Regents |
819.86 |
819.86 |
5-25-83 |
Department of Highways |
39,300.00 |
50,665.56 |
6-1-83 |
Board of Regents |
102.00 |
102.00 |
4-22-83 |
Department of Highways |
12,930.32 |
12,930.32 |
5-19-83 |
Department of Highways |
1,911.88 |
1,911.88 |
5-19-83 |
Department of Health |
30.00 |
30.00 |
5-25-83 |
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1981 to June 30, 1983:
(1
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination cr2
(12
CC-78-145 Michael Conley Department of
Highways 1,500.00 1,500.00 12-1-82
CC-78-145 Robert Conley Department of Highways 2,995.00 2,995.00 12-1-82
CC-81-168 County Commission cf Office of the Supreme 3,020.00 3,020.00 11-25-81
Webster County Court of Appeals
CC?82-204 William E. Coy Department of Health 90.14 90.14 1-25-83 o
CC-81-10 Crosby Beverage Co., Inc.
Nonintoxicating Beer 688.42 688.42 8-24-81
Commission
CC-78-236 Michael Crouch Department of Highways 2,500.00 1,350.00 12-6-82 i
CC-82-323 Chad Cunningham Department of Health 7.34 7.34 1-28-83
CC-81-341 Clifford Cupp Department of Health 137.25 137.25 11-9-81 t-?
CC-81-355 Dairyland Insurance Department of Public Safety 423.00 423.00 2-1-82
Company, subrogee of
Wesley D. Myers cr2
CC-83-51 Harold E. Darlington Supreme Court of Appeals 4,500.00 4,500.00
2-18-83
CC-83-52 E. W. Day Supreme Court of Appeals 4,500.00 4,500.00 2-18-83 z
CC-81-114 Jacqueline E. Delazio Department
of Highways 169.72 169.72 11-9-81
CC-82-260a Department of Department of Corrections 14,760.02 11,588.42 2-14-83 . Employment Security
CC-82-260b Department of Department of Corrections 20,204.50 17,074.63 2-14-83 . Employment Security
CC-82-260c Department of Department of Corrections 16,055.64 12,559.57 2-14-83
Employment Security
CC-82-260d Department of Department of Corrections 37,436.16 37,335.36 2-14-83
Emoloyment Security
CC-82-260e Department of Department of Corrections 59,852.35 47,621.09 2-14-83
Employment Security
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period
July 1, 1981 to June 30, 1983:
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination t-
CC-82-329 Department of Department of Corrections 1,472.54 1,420.00 2-14-83
Employment Security
CC-82-330 Department of Department of Corrections 10,990.47 10,642.46 2-14-83
Employment Security
CC-82-331 Department of Department of Corrections 4,146.50 3,998.55 2-14-83
Employment Security ?
CC-82-334 Department of Department of
Corrections 16,134.76 14,026.92 2-14-83
Employment Security
CC-82-262 Department of Department of Culture 3,670.29 2,822.00 2-14-83 0
Employment Security n?id History
CC-82-263a Department of Department of Health 3,865.01 2,149.23 2-14-83 (1
Employment Security
CC-82-332 Department of Department of Health ,934.1l 6,686.70 2-14-83
Employment Security
CC-82-266 Department of Dprtment of Public Safety 1,781.69 1,341.64 2-14-83
Employment Security
CC-82-261 Department of Farm Management Commission 6,117.30 5,308.35 2-14-83
Employment Security
CC-82-264 Department of Human Rights Commission 17,099.74 13,577.00 2-14-83
Emnlovment Security
CC-82-265 Department of Insurance Commission 6,272.56 5,511.92 2-14-3 ?
Employment Security
CC-82-333 Department of Secretary of State 3,273.06 2,279.12 2-14-83
Employment Security
CC-81-93 Edward E. Dilling Department of Highways 100.00 75.00 7-1-82
and Jennifer Dilling
CC-83-53 C. P. Dingler Office of the Supreme 4,500.00 4,500.00 2-18-83
Court of Appeals
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1981 to June 30, 1983:
Name of
Claimant
James W. Dixon and
Doris A. Dixon
Ruth A. Donaldson
Peter H. Dougherty Eastman Kodak Company
Energy Technology
Consultants, Inc.
D & M Weather Service
Evans Lumber Company
No.
CC-80-365
CC-83-54
CC-83-55
CC-81-386
CC-81-443
CC-82-249
CC-81- 196
CC?81-402
CC-82-3 14
CC-80-121
CC-81-369
CC-81-172
CC-80-386
Amount Amount
Date of
Claimed Awarded Determination
14,500.00 14,500.00 12-16-81
Name of
Respondent
Department of Highways
Office of the Supreme
Court of Appeals
Office of the Supreme
Court of Appeals
Department of Finance
and Administration
Board of Regents
Division of Vocational
Rehabilitation
Department of Highways
Department of Natural
Resources
Office of the Supreme
Court of Appeals
Department of Natural Resources
Office of the State Auditor
Department of Education
Department of Highways
4,500.00
4,500.00
4,391.50
350.00
458.97
29,482.48
852.72
165.00
1,956.00
38.32
800.00
9,054.19
Fibair, Inc.
Firestone Tire &
Rubber Company
C. Elaine Friend
Victor Frisco and Janet Frisco
Richard D. Frum
Rabert Lee Fulks, Jr.
General Accident F/L
Assurance Corp., Ltd.
Subrogee of Innovative
Industries
CC-8l-80 General Communications
Company
4,500.00
4,500.00
4,391.50
350.00
458.97
29,482.48
852.72
165.00
500.00
38.32
684.95
9,054.19
CD
-w
I
IC
0
C)
rJ
2- 18-83
2-18-83
2-1?82
2?1-82
1-25-83
2- 14-83
2?1?82
1- 28-83
1?25?83
10-7 -8 1
11?9?81
8-24-81
Board of Regents 400.00
400.00 8-6-81
REPORT OF THE COURT OF CLAIMS (Cantnued)
Name of Claimant
General Motors
Acceptance Corporation
Alonzo Gibson
Silbern D. Goddard
and Metta Gcddard
David R. Gold and
Louis H. Khourey,
d/b/a Gold & Khourey
CC-82-192a David H. Gold and
Louis H. Khourey,
d/bf a Gold & Khourey
CC-82-192b David R. Gold and
Louis H. Khourey,
d/b/a Gold & Khourcy
CC-82-192b David R. Gold and
Louis H. Khourey,
d/b/a Gold & Khourey
Margaret Graff
Richard D. Graham, Jr.
larry Greathouse Green Tab Publishing Glen Greene
Paul Gyke and
Joe Ann Qyke
Name of
Respondent Department of Motor Vehicles
Department of Highways Department of Corrections
Office of the State Auditor (Mental Hygiene Fund)
Office of the State Auditor (Needy Persons Fund)
Public Legal Services (Needy Persons Fund)
Public Legal Services (Mental Hygiene Fund)
Board of Regents
Office of the Supreme
Court of Appeals
Department of Health
Department of Corrections
Office of the Supreme
Court of Appeals
Department of Highways
Amount Amount Date of Claimed Awarded Determination
4,245.98 12?1-82
(2) Approved claims and awards satisfied by payments out of appropriations July 1, 1981 to June 30, 1983:
No.
CC-82-46
CQ-81-7 CC-81-301
CC-82? 192a
made by the Legislature for the period
CC-82?2 16
CC-82- 190
CC-82-64
CC-82- 194
CC-83-56
CC-82-162
C)
(4,
(0
-4
Ii
a
-4
0
0
C)
(I,
IL?
z
4,259.64 |
|
|
500.00 |
480.00 |
11-9-81 |
42.50 |
42.50 |
10-26-82 |
1,140.50 |
1,140.50 |
10-26-82 |
422.50 |
422.50 |
10-26-82 |
65.00 |
65.00 |
10-26-82 |
1,096.50 |
1,096.50 |
12-16-82 |
204.00 |
204.00 |
5-21-82 |
452.97 |
83.97 |
12?6?82 |
CC-80-258
CC-80-397
CC-81-442
CC-81-381
CC-81-431
CC-78-234
CC-81-175
CC-82-96
CC?82- 137
CC-80-183
CC-82- 183
CC-80-375
CC-83-16
D-893
CC-81-367
CC-80-329
CC-81-450
CC-82-182
CC-82-229
CC-79-297
CC-79-297
Name of Claimant
H & A Coal & Hauling, Inc.
L. D. Hall
Patricia Ann Hall
and Lacy Hall
Donald A. Harman
Hawes Electric Co.
Christine E. Henderson and
Rodgers Paul Henderson
Henry F. Ortlieb
Brewing Co.
Benjamin C. Henry
The Hertz Corporation
Mr. & Mrs. Stephen Kent Hill
Glenn E. Hiller
Mark A. Hissam and
Julia A. Hissam
Donald R. Hogsett
Holly, Kenney, Schott, Inc.
Howard Uniform Company
Ricky S. Howerton
Hughes-Bechtol, Inc.
Industrial Gas & Supply
Company
Robert A. Isner
Patricia Ann Jarboe
Robert N. Jarboe
Nonintoxicating
Beer
Commission
Department of Highways
Department of Public Safety
Board of Regents
Department of Highways
Department of Highways
Office of the
Supreme
Court of Appeals
Department of Highways
Department of Highways
No.
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the July 1, 1981 to June
30, 1983:
Legislature for the period
Name of
Respondent
Department of Highways
Department of Highways
Department of Highways
Department of Corrections
Department of Health
Department of Highways
Amount Amount Date of Claimed Awarded Determination
1,000.00
800.00
1,846.78
497.45
1,126.00
1,305.00
8-24-81
11?9?81
7-1-82
1-25-83
2-1-82
8-24-8 1
3,004.87 2-1-82
cf cl
0
0
0
(j.
O
C12
1,000.00
2,000.00
1,846.78
994.90
1,126.00
100,000.00
3,004.87
8,434.82
600.00
93.35
155.76
3,395.37
60.00
13,755.00
244.30
40,000.00
1,275,570.70
2,389.42
4,923.00
18,000.00
18,000.00
Department of
Health
Department of Highways
Department of Public Safety
Department of Highways
Board of Regents
Department of Highways
4500.00
600.00
93.35
155.76
3 .395 .37
60.00
13,755.00
244.30
20,000.00
542,982.11
2,389.42
1-28-83
7-1?82
12-6-82
12?1?82
12 -6-82
2-16-83
2-9-83
12-6-81
12-6-82
7?26-82
12-6-82
4,500.00 10-12-82
1,040.00
3,676.00
8-7-81
8-7-8 1
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1981 to June 30, 1983:
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination e
U)
CC-79-297 Robert N. Jarboe, as next
Department of Highways 18,000.00 50.00 8-7-81
friend of Stephanie Jarboe
CC-78-17 Waitman D. Jett and Department of Highways 935.00 935.00 10-26-82 )
Marilyn Jett
CC-8l-316 Johnson Controls, Inc. Department of Finance 2,376.75 2,376.75 2-1-82
and Administration 0
CC-81-454 Johnson Controls, Inc. Department of Finance 4,160.00 4,160.00 2-1-82
Z
and Administration 0
CC-82-87 Johnson Controls, Inc. Department of Finance 2,856.20 2,856.20 7-1-82
and Administration
CC-81-35 Charles W. Jones Board of Regents 213.75 213.75 8-6-81 ?
CC-76-51 Chester Jones Deoartment of
Highways 24,200.00 9,000.00 9-23-82
CC-81-447 Kanawha County Commission DDpartment of Highways 2,362.08 2,362.08
2-14-83
CC-81-116 Kanawha Valley Regional Department of Highways 3,744.80 3,744.80
11-9-81 ?
Transportation Authority
CC-80-l46 Henry A. Kay and Department of Natural 3,800.00 3,800.00 12-1-82
Charles E. Kay Resources
CC-82-168 Teddy Keiffer Department of Highways 3,875.17 3,557.14 12-16-82 >
CC-80-396 Thcmas G. Kimble Department of Public Safety 230.03 230.03 8-24-81
CC-79-667 William P. Knight Office of the State Treasurer 152.94 152.94 2-1-82
CC-80-391 Barbara B. Krantz Department of Highways 130.49 104.39 2-16-82
CC-82-230 Ruth A. Krippene Department of Highways 3,152.65 3,152.65 1-25-83
CC-82_167 Lester A. Kubski Department of Health 126.05 88.07 12-6-82
CC-81-70 L. Robert Kimball & Associates Ste Tax Department 2,824.42
2.824.42 8-6-81
CC-82-147 Robert Howard Latta Department of Highways 150.00 150 00 12-6-82
CC-82-245 Thomas E. Layton, II Dpartment of Highways 235.36 2? 36 2-16-83
CC-82-285 Doris Leslie Department of Highways 146.47 146.47 1-25-83
REPORT OF THE COURT OF CLAIMS (Continued)
No. Name of
Claimant
CC-81-93 Liberty Mutual Ins.
Company, Subrogee of
Edward E. Dilling and
Jennifer Dilling
Ernest E. Lowe
Lucas Tire, Inc.
Lundia, Myers Industries, Inc.
Nat Marino
James C. Martin, Jr.
and Shirley B. Martin
Donald C. Master
John T. May
RayrpQnd L. Maynard
McAnallen Brothers, Inc.
Charles E. McCarty
Charles E. McCarty
M?Donnell Douglas
Corporation
Jeffrey 0. McGeary
William .
McGinley
Thomas E. MeNamee
The Mi?hie Company
The Michie Company
Name of
Respondent
Department of Highways
Department of Education
Department of Highways
Board of Regents
Office of the Supreme
Court of Appeals
Department of Highways
Department of Highways
Department of Highways
Board of Regents
Board of Regents
Office of the Supreme
Court Administrator
Office of the State Auditor
Department of Education
Human Rights Commission
Board of Regents
Department of Highways
Department of Health
Office of the Supreme
Court Administrator
Department of Highways
made by the
Legislature for the period
Amount Amount Date of Claimed Awarded
Determination
2,423.35 7?1-82
(2) Approved claims and awards satisfied by payments out of appropriations July 1, 1981 to June 30, 1983:
CC-81-186
CC-83-14
CC-.81-356
CC-83- 108
CC-78?231
CC?80-131
CC-81- 165
CC-81-206
D-1031
CC-81-400
CC-81-371
CC...81- 124
CC-82-12
CC-81-20
CC-81- 100
CC-82-35
CC-82-3
-4
-4
C
z
0
CD
0)
0)
CC-82-116 Monongahela Power Company
38.38 38.38 9-23-82
3,231.14 |
|
|
195.00 |
195.00 |
11-9-81 |
1,804.07 |
1,804.07 |
2-14-83 |
125.30 |
125.30 |
12?16-81 |
4,500.00 |
4,500.00 |
2-18-83 |
83,853.40 |
6,846.00 |
1-27-83 |
1,000.00 |
1,000.00 |
8-24-81 |
15,000.00 |
1,061.74 |
9-23-82 |
20,228.00 |
20,228.00 |
10-12-82 |
55.00 |
55.00 |
2-22-82 |
240.00 |
240.00 |
10-7-81 |
28,132.00k |
28,132.00 |
8-7-81 |
110.64 |
110.64 |
2-16-82 |
35,000.00 |
00.00 |
12?1-82 |
423.21 |
423.21 |
11-9?81 |
163.31 |
163.31 |
5?21?82 |
56.13 |
56.13 |
2?1-82 |
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1981 to June 30, 1983:
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-82-298 Moore Business Forms, Inc. Department of Education 201.11 60.97 2-14-83
CC-82-41 Moore Business Forms, Inc. Department of Public Safety 2,586.61
2,586.61 2-1-82
CC-82-179 Irlant E. Moore and Department of Highways 43.15 43.15 10-26-82
Robert L. Moore
CC-82-337 Mountaineer Office Secretary of State 1,860.00 1,860.00 2-9-83
Suoply, a division of o
F&M Supply Co., Inc.
CC-82-209 Howard R. Nordeck Office of the Supreme 4,500.00 4,500.00 10-12-82 o
Court of Appeals
CC-78-175 Novo Corporation Department of Highways 373,982.00 162,929.00 4-26-82
CC-82-lll John Orndoff Department of Highways 104.16 104.16 10-26-82
CC-83-57 Garry Osburn Office of the Supreme 4,500.00 4,500.00 2-18-83
Court of Appeals
CC?81-132 Jimmy Polk Department of Highways 392.67 392.67 11-9-81 u
CC-.81-163 Sidney Pozell and Department of Highways 144.00 144.00 9-23-82
Lillian Pozell
CC-82-79 Angela Preston Attorney General?s Office 110.00 110.00 5-21-82
CC_81-169 Frank E. Redd Department of Highways 51.00 51.00 9-23-8
CC-81-426 Region V?Regional Department of Employment 2,145.25 2,145.25 2-1-82
Education Service Agency Security
CC-82-28 Reynolds Memorial Department of Corrections 53,321.95 53,321.95
12-1-82
Hospital, Inc.
CC-81-166 Stanley T. Ruckman Dcpartment of Highways 78.75 78.75 9-23-82
CC-80-422 James Scott Sadler Department of Highways 744.30 595.44 8-7-81
CC-81-14 Savage Construction Department of Highways 6,788.75 4,488.75 12-1-82
Company, Inc.
CC-82-102 Ethea M. Scott Department of Highways 38.00 38.00 12-6-82
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved
claims and awards satisfied July 1, 1981 to June 30, 1983:
No. Name of Claimant
CC-80-175 Selected Risks Insurance
Company, as Subrogee
of Shell C. Brady
CC-82-83 Harry R. Sellards
and Francis A. Sellards
CC-81-138 Eugene J. Sellaro, Jr.
CC-81-95 Daniel Serge, Jr.
CC-81-202 Charles R. Shaffer
CC-82-86 Shane Meat Company
CC-82-189 Roy G. Shawver
CC-81-142 Sterl F. Shinaberry
CC-78-168 Ruby E. Shrader
CC-82-311 C. 0. Smith, Jr.
CC-81-129 Southern Chemical Co.
CC_81-271 St. Paul?s Protestant
Episcopal Church
CC-80?193 Stark Electric, Inc.
CC-81-385 State Distributing
Company
CC-81-65 Ronald P. Stewart
CC-83-58 Sharrell Stickler
CC?81-12
CC-83-59
CC?82?15
Department of
Highways
Nonintoxicating Beer
Commission
Department of Highways
Office of the Supreme
Court of Appeals
Department of Highways
Office of the Supreme
Court of Appeals
Office of the State Auditor
Amount Amount
Date of
Claimed Awarded Determination
33,650.00 33,650.00 10-9-81
by payments out of appropriations made by the Legislature for the period
Name of
Respondent
Department of Highways
Department of Highways
Office of the State Auditor
Department of Highways
Department of Highways
Board of Regents
Department of Highways
Office of the State Auditor
Department of Highways
Department of Highways
Adjutant General
Department of Highways
U,
U,
0
C
C
0
Charles W. W. Stultz and Mary N. Stultz Eugene C. Suder
Larry N. Sullivan
170.00
170.00 2-16?82
432.10 |
122.00 |
7-13-82 |
433.95 |
433.95 |
12?9?81 |
139.05 |
139.05 |
11-9-81 |
255.33 |
255.33 |
9-29-81 |
1,450.44 |
1,412.52 |
9?23?82 |
833.49 |
833.49 |
2?9?83 |
1,500.00 |
1,500.00 |
12-18?81 |
20,000.00 |
18,310.00 |
1-27-83 |
630.00 |
630.00 |
2-9-83 |
98.76 |
93.76 |
9-29-81 |
122.00 |
122.00 |
1-27?83 |
26,699.30 |
10,800.00 |
12?1-82 |
11,068.92 |
11,068.92 |
2-1-82 |
259.76 |
259.76 |
11-9-81 |
3,375.00 |
3,375.00 |
2-18-83 |
5,126.91 |
5,126.91 |
12-6?82 |
3,375.00 |
3,375.00 |
2-18?83 |
REPORT OF THE COURT OF CLAIMS (Continued)
CC-83-2
CC-82-280
CC-80-249
CC-82-301
CC-83 -109
CC-82-283
CC-82-44
CC-81-372
CC?81-192
CC?82-227
CC_82- 173
a&b
CC -80-2 5 8
CC-82- 109
CC?82-156
CC-81-24
Name of
Claimant
Janet T. Surface
Janet T. Surface
Velma Sutton
Swain Window Cleaning
Services
Norma Tarr
Wayne Concrete
Co.
Weslakin Corporation
West Virginia Automobile &
Truck Dealers Association
Name of
Respondent
Department of Health
Workmen?s Compensation Fund
Department of Highways
Department of Finance
and Administration
Office of the Supreme
Court of Appeals
Department of Highways
Office of the State Auditor
Office of the State Auditor
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Office of the Supreme
Court of Appeals
Office of the Supreme
Court of Appeals
Department of Highways
Department of Corrections
Department of Motor Vehicles
(2) Approved claims and awards satisfied July 1, 1981 to June 30, 1983:
No.
by payments out of appropriations made by the Legislature for the period
Amount Amount Date of Claimed Awarded Determination
132.00
6.82833
2,969.36
3,511.74
132.00
6,828.33
2,969.36
2,332 .00
Terra Aqua
Conservation
James D. Terry
Gerald M. Titus, Jr.
.Tohn F. Tomblyn
Thomas R. Treadway
Tn-City Weldng
Supply Companj
United States
Fidelity & Guaranty
Company, subrogee of
H & A Coal & Hauling, Inc.
CC-83-60 D. M. VandeLinde
4,500.00 4,500.00
854.78
345.00
940.85
721.82
140.28
1,831.00
CC-83-61 Lester Warner
854.78
345.00
940.85
649.64
140.28
1,831.00
(?1
1j)
cr2
-4
C)
-4
0
z
0
I-)
Cr2
C,)
1-28-83
12-6-82
12-16-82
2?9-83
2-18-83
12-6-82
9-23?82
10-7?81
2?1-82
12?6-82
10-26-82
8?24?81
2-18-83
2?18-83
10-26-82
12-6?82
8-6-81
191.35 191,35
3,375.00 3,375.00
3,375.00 3,375 00
2,642.84
95.67
1,174.37
7 64?:? .84
95 67
1,174.37
REPORT OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1981 to June 30, 1983:
C.)
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-81-133 Wheeling Multi-Service Division of Vocational 5,220.00 5,220.00
2-1-82
Center, Inc. Rehabilitation C)
CC-80-331 Harold E. Wiley Department of Motor Vehicles 20.00 14.00 12-6-82
CC-83-62 Wetzel K. Workman Office of the Supreme 4,500.00 4,500.00 2-18-83
Court of Appeals
CC-81-135 Zummach-Peerless Chemical Department of Natural 918.29 918.29 9-29-81
Coatings Corporation Resources
(?1
(3) Approved claims and awards satisfied by paymcnt out of a special
appropriation made by the Legislature to pay claims arising during the fiscal
year: (None).
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
CC-81-180
CC-81-54
CC-82-6 1
CC-81-389
CC-80- 145
CC-82-294
CC-81-203
CC-82-267
CC-81-457
CC-80-352
CC-82-84
Steven Bellman,
d/b/a Baskin-Rcbbins
Pearl Hughes Bolling
and Charles Hughes
Anna Lou Booten
Doris Jane Bowen,
Wanda Sue Hanley,
Larry Jenkins, and
Lana Jean Jenkins
Teresa Britt
Robert R. Brock
John Charles Bungard
Arlene Burgess and
Charles E. Burgess
Name of
Respondent
Department of Highways Department of
Welfare
Department of Highways Department of Highways
Department of Highways
Department of Highways
DDpartment of Highways
Department of Highways
Civil Service Commission
and Department of
Natural Resources
Department of Highways
Department of Highways
Department of Highways Department of Highways
291,401.00
Disallowed
30,520.00 Disallowed
18,000.00 Disallowed
383.95 Disallowed
4,500.00 Disallowed
13,140.00 Disallowed
25,000.00 Disallowed
1,000.00 Disallowed
10-9-81
2-9-83
4-22-83
10-9-81
2-1?82
2-17-82
4-22-83
8-6-81
No.
Name of Claimant
D-773 A. B.
Engineering Company CC-79-554 Thomas Harold
Anderson, Sr. and
Edith lolene Anderson
H. R. Arrowood
Leona Asbury and
Tom Asbury
Donald E. Ashley
Connie Lawrence Bailey
James E. Bailey, Jr.
David R. Bassett
Gary L. Batton
Amount Amount Date of Claimed Awarded Determination
CC_81-36 CC-79-16
CC-81-176 CC-80-342
cj
Cl)
Ij
227.43 |
Disallowed |
7?2-82 |
1,962.16 |
Disallowed |
3-11?83 |
616.20 |
Disallowed |
3-16-83 |
167.62 |
Disallowed |
3-16-83 |
3,500.00 |
Disallowed |
2-2-82 |
Department |
of |
Highways |
258.30 |
Disallowed |
2-9-83 |
Wcrkmen?s |
Compensation Fund 200,000.00 |
Disallowed |
4-26-82 |
||
Department |
of |
Welfare |
2,313.00 |
Dsal1owed |
10-9-81 |
Department |
of |
Highways |
169.22 |
Disallowed |
6-30-82 |
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
No. Name of Claimant Name of Respondent
(1
U)
U)
-4
-4
C)
-4
0
0
C)
U)
U)
|
Amount |
Amount |
Date of |
||
Claimed |
Awarded |
Determination |
|||
CC-80-318 CC-78-278 |
Robert W. Burke D. A. Burner |
Department of Highways Department of Public Safety |
9,000.00 |
Disallowed Disallowed |
6-30-83 |
CC-82-158 |
Albert G.
Capinprn |
Department of
Highways |
205.54 |
Disallowed |
12-7-82 |
CC-79-161 |
Chafin Coal Company |
Workmen?s Compensation Fund |
33,101.04 |
Disallowed |
2-1-82 |
CC-81-62 |
Pius B. Chumbow |
Department of Highways |
3,012.05 |
Disallowed |
1-27-83 |
CC-82-123 |
Roger K. Clay |
Board of Regents |
329.00 |
Disallowed |
12-7-82 |
CC-77-3b |
Mary Lou Cole |
Department of Highways |
25,000.00 |
Disallowed |
1-26-83 |
CC-77-3a |
Wilson R. Cole |
Department of Highways |
3,000.00 |
Disallowed |
1-26-83 |
CC-77-3d |
Wilson R. Cole,
|
Department of Highways |
11,760.78 |
Disallowed |
1-26-83 |
CC-77-3c |
Wilson R. Cole, Admin. of the Estate of Timothy Ray Cole |
Department of Highways |
11,760.78 |
Disallowed |
1-26-83 |
CC-80-292 |
Lillian West Collins and John Collins |
Department of Highways |
4,261.85 |
Disallowed |
4-1-82 |
CC-80-154 |
William Conner and Lois Conner |
Department of Highways |
31,000.00 |
Disallowed |
3-11-83 |
CC-82-21 |
Dreama Dawn
Cook |
Department of
Highways |
133.45 |
Disallowed |
9-23-82 |
CC?81-378 CC-82-196 |
Doy P. Crites Ronald E. Cyrus |
Department of Highways Department of Highways |
2,500.00 |
Dismissed Disallowed |
3-16-83 |
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
U)
U)
C)
C
C
C)
Cl)
Cl)
|
|
Amount |
Amount |
Date of |
No. Name of Claimant |
Name of Respondent |
Claimed |
Awarded |
Determination |
CC-82-10 Dairyland Insurance |
Department of Highways |
1,035.09 |
Disallowed |
12-7-82 |
Company, subrogee of |
|
|
|
|
Jesse W. Cobern, Jr. |
|
|
|
|
CC-81-170 Maurice V. Davis CC-79-632 Azile Dean, |
Department of Highways Department of Highways |
113.40 |
Disallowed Disallowed |
10-9-81 |
Individually, and as |
|
|
|
|
Executrix of the |
|
|
|
|
Estate of Virgil Dean, dec. |
|
|
|
|
CC-80-336 Charles Dennis |
Department of Public Safety |
3,000.00 |
Dsallowed |
12-7-82 |
CC-82-335 Department of |
Department of Finance |
6,457.34 |
Disallowed |
3-16-83 |
Employment Security |
and Administration |
|
|
|
CC-82-263b Department of |
Department of Health |
52,730.71 |
Disallowed |
3-16-83 |
Employment Security |
|
|
|
|
CC-82-263c Department of |
Department of Health |
21,213.07 |
Disallowed |
3-16-83 |
Employment Security |
|
|
|
|
CC-81-92 Norma Dornbos, d/b a |
Department of Welfare |
260.66 |
Disallowed |
3-11-83 |
The Party Beer Store |
|
|
|
|
CC-81-103 June Dorton |
Workmen?s Compensation Fund |
|
Disallowed |
4-26-82 |
CC-81-181 Charles N. Durbin |
Department of Highways |
420.15 |
Disallowed |
12-7-82 |
CC-80-4Ola-h James D. Eads, et al. |
Department of Highways |
2,857.24 |
Disallowed |
6-30-83 |
CC-82-193 Jerry M. Edwards |
Department of Highways |
96.92 |
Disallowed |
1-26-83 |
and Edgar E. Edwards |
|
|
|
|
CC.-82-274 Kenneth N. Ellison |
Department of Highways |
214.05 |
Disallowed |
2-9-83 |
CC-81-49 William P. Estep, Sr. |
Department of Highways |
140.00 |
Disallowed |
10-9-81 |
CC-S0-339 Nellie Evans |
Department of Highways |
462.11 |
Disallowed |
8-6-81 |
CC-81-43 Veda E. Evans |
Department of Highways |
892.69 |
Disallowed |
2-17-82 |
CC-81-153 Kathleen R. Fewell |
Department of Highways |
62.38 |
Disallowed |
11-25-81 |
CC-82-50 Cheryl M. Fidler |
Department of Highways |
24.25 |
Disallowed |
6-30-82 |
No.
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
Name of Claimant
CC-82-52 Dae Anne Fletcher and
Paul Norman Fletcher
D-10l0 Nelson Eddie Furner,
an Incompetent, sues
by and through Ava
Elizabeth Furner Young,
his next friend, and
Ava Elizabeth Furner
Young, individually
G. M. McCrossin, Inc.
Gates Engineering
Company, et al.
John J. Gaughan
Dorothy M. Gore
Henry W. Gould
Susan L. Green
Amount Amount Date of Claimed Awarded Determination
100.00 Disallowed
125,000.00 Disallowed 10-26-82
9-23-82
CC-79-682
CC-82-68
CC-80-353
CC-81-161
CC-79-357
CC-80-385
CC- 79-307
CC-81-151
CC-82- 125
CC-81- 139
CC-76-89
CC-82-40
CC-81-86
CC-80-134
Name of
Respondent
Department of Highways Department of
Health
Board of Regents
Board of Regents
Department of Highways
Department of Highways
Board of Regents
Office of the Supreme
Court of Appeals
Department of Highways
Board of Examiners for
Registered Nurses
Department of Highways
Department of Highways
Department of Corrections
Department of Highways
Department of Highways
Department of Highways
152,809.00
Disallowed
143,225.68 Disallowed
-4
-4
C-)
I-,
U)
U)
-4
-4
C)
-4
C
z
0
C)
U)
z
U)
156.42
700.00
317.50
22,935.00
Nelson Gregory
John Grey
Earl F. Guthrie
Diana Lynn Hackfley
Lester Rolli?igs Haines
Atholl W Fa]stead
John A. Hannigan and
Carolyn Ann Hannigan
Ronald H. Harper and
Sarah E. Harper
Disallowed
Disallowed
Disallowed
Disallowed
50,000.00
Disallowed
26,100.00 Disallowed
12- 1-82
6 -30-83
2?17 -82
7-2-82
12-7 -82
3-14-83
1-26-83
2- 14-83
12?7- 82
11?25-81
5-19-83
6-30 -82
8-6-8 1
11? 25?8 1
631.00
298.70
200,000.00
84.50
129.39
Disallowed
Disallowed
Dsallcwed
Disallowed
Disallowed
10,000.00 Disallowed
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
CC-78-241 Geneva
Hill
CC-80-150 Ida M. Hiner and
Norman F. Hiner,
d/b/a Hercules
Construction Company
CC-81-191 Bobbie E. Holmes and Neva I. Holmes
CC-80-337 Hooten Equipmeit Company CC-81-238 Joyce Hupp
CC-80-291
CC-81-324
CC-81-l40
James David
Hutchinson Claude W. Jarrell John D. Tonkovich and Sons, Inc.
CC-81-29 Keller Industries, Inc.
CC-78-219 Douclas Edward Keller
and Patty Keller
CC-80-164 Margo A. Keyser
CC-82-ll0 Tommy Kinder
Name of
Respondent
Department of Highways
Department of Highways Board of Regents Board of Regents Department of Health
and Department of Finance and Administration Department of Highways Department
of Natural Resources
Department of Highways
Board of Regents
Office of the Chief
lJledical Examiner
Department of Highways
Department of Highways Department of Highways
Department of Highways
Adjutant General and
Department of Highways
Department of Highways
Department of Highways
Amount Amount
Date of
Claimed Awarded Determination
40,000.00 Disallowed 4-22-83
200.00 Disallowed
10-26-82
2,000,000.00 Dismissed 3-16-83
No. Name of Claimant
CC-79-685
CC-78-227
CC-78-13
CC-80-340
CC-79-367
Robert Hart,
d/b/a
Bob?s Bake Shop
Forrest C. Hatfield
Barbara Haynes
Francis J. Hennessy
Henry Elden & Associates
2,495.21 Disallowed 1-26-83
31,051.00
Disallowed
392.96 Disallowed
C)
Cl)
02
C)
I-i
I 0 z
0
C)
Cl)
d
Cl)
-I
2,475.00
3,125.00
11,563.00
663.44
65,000.00
5,000.00
217.92
Disallcwed
Disallowed
Disallowed
Disallowed
Disallowed
Disallcwed
Disallowed
6-30-83
7-13 ?82
1-24?83
3-11?83
6-30-83
3-11-83
8-24-81
9-29-81
12?7?82
25,000.00 |
Disallowed |
9-23-82 |
25,000.00 |
Disallowed |
12-20-82 |
4,086.00 |
Disallowed |
2-1-82 |
63,000.00 |
Disallowed |
12-7-82 |
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
CC-80-42 1
CC-81-41
CC-79-58
CC-81-177
CC-79-578
CC-81-111
CC-81-19
CC-81-246
CC-81-31
CC-81-421
CC-78-50
CC?81-59
CC-77- 150
Virginia Lewis
Rchard J. Lindroth
Lucille Linville
Willard Lucas
Bernard C. Lyons and
Helen V. Lyons
Martha White Foods
Dayton 0. B. Matthews
and Alline L. Matthews
Juanita McClarn
Dores D. McDonnell, Sr.
Cynthia Catherine McGrath
Ronald G. McGraw
John McKendrck
The Melbourne Brothers
Construction Company
Name of
Respondent
Department of Highways Department of
Highways
Department of Highways
Department of Highways
Department of Highways
Department of Finance
& Administration and
Department of Welfare
Department of Highways
Workmen?s Compensation Fund
Department of Highways
Department of H;ghways
Department of Highways
Department of Highways Department of Highways
Amount Amount
Date of
Claimed Awarded Determination
240,000.00 Disallowed
10,000.00 Disallowed
101.64 Disallowed
178.07 Disallowed
No. Name of
Claimant
CC-81-61 L. P. King, Jr. and Evelyn
King
CC-79-696 Charles L. Kinney and Joyce I. Kinney, d/b/a
The Southwood Carryout
CC-79-122 David H. Kisor,
Admin. of the Estate
of Julia Kisor, dec.
CC-81-107 Eugene A. Knotts
CC-82-70 Sandra W. Philflps Larese
CC-82-235 L. R. Lewis and
B. L. Lewis
725.24 Disallowed 11-25-81
657.76
258.80
28,200.00
176.90
90.00
3,500.00
20,000.00
45,000.00
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
02
rj
I(1
C
C
O
02
z
ci,
7-2-82
6 -30?83
2-1-82
6 -30-82
1-24-83
8-6?8 1
11-9-81
3-11?83
4-22-83
1-26-83
2-17-82
2?17?82
4-22 -83
8-6-8 1
4-1-82
5-19-83
2- 17-82
9-23?82
Department of
Department of
Department of
Department of
Department of
Department of
Highways
Highways
Motor Vehicles
Corrections
Highways
Highways
207.81
131.78
35.00
45,000.00
1,000.00
5,796.23
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
CC-76-127
CC-80-97a
CC-80-240
CC-83-116
CC-82-69
CC-78- 157
CC-82-8
CC-80-355
CC-79- 125
CC-80-357
CC-81-162
CC-78-l86
CC-79--315
CC-82-3 10
Name of
Claimant
Laird Minor and
Nancy G. Minor
Monsanto Company
Carl R. Moore
Charles E. Moore
D. Albert Moore
Dolores Mcore
Robert B. Moran
Earl G. Muck
John Mullenax, Admin.
of the Estate of
Edith Mullenax, dec.
Eugene P. Mullins
Nelva Munson
James Pack and
Ella Mae Pack
Kenneth Page
Herbert O?Dell Parsons, III
Catherine Pasceri
Kenneth H. Patrick, Jr.
David E. Paul and
Dolores R. Paul
Name of Respondent
Department of Highways
Board of Regents
Governor?s Office of
Economic and Community
Development
Department of Public
rnstitutions
Department
Department
Department
Department
Dcpartment
Alcohol Beverage Control Commissioner
397.97 Disallowed
13,010.00 Disallowed
1,299.23 Disallowed
4,000,000.00 Dismissed
6-24-83
10-26-82
3- 14-83
3-16-83
No.
CC -82-327
CC-78-282 CC-80-l37
Amount Amount Date of Claimed Awarded Determination
of Highways of Highways of Motor Vehicles of Highways of Agriculture
Department
Department
Department
700.00
50,000.00
6.00
670.95
100,000.00
155.78
20.00000
12,467.52
of Highways of Highways of Highways
Disallowed
Disallowed
Dsal1owed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
(1
(1)
-4
-4
-4
0
0
(1
4-,
ci,
ci,
Department of
Highways
Department of Highways
Department of Highways
Department of Highways
33,600.00 Disallowed
3-11-83
7?2-82
6- 24-83
7?2?82
12-20-82
6 -30-82
4-1-82
1-24? 83
6 -29-83
11?25-81
12?7 -82
4-22-83
6-24-83
56.65
1,882.60
20,000.00
128.68
Disallowed
Disallowed
Disallowed
Disallowed
CC-79-719 Frank A. Payne
Department of Highways
3,475.00 Disallowed 12-20-82
REPORT
OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
No. Name of Claimant
CC-80-243 Dale R. Pennington and
Gloria Mae Pennington
CC-82-246 Mary E. Peterson
CC-82-47 Richard T. Philpot
CC-81-30 Michael A. Piazza
CC-76-148 The Pioneer Company and Mountain State Construction Company, Inc.
Donald E. Platt and Linda L. Platt
Donna F. Porterfield Tammy Lynn Priestley, an infant who sues by her mother,
Carolyn Priestley, and Carolyn Priestley Gary L. Pritt and
Jeanette Pritt
Rainbow Development Corporation
Glen L. Ramey
Doris Randolph, Frank Randolph her husband and Yvonette (Suzie) Randolph,
infant
CC-81-458 Roger Richmond and Sandra Richmond
CC.-82-288 Robert G. Riner
CC-80-82 Keith Ray Roberts
Amount Amount
Date of
Claimed Awarded Determination
60,000.00 Disallowed 6.30-83
CC-81-l0l
CC-81-91 D-732
184.11
259.56
41,498.99
Disallowed
Disallowed
Disallowed
Disallowed
CC-81-418
CC-81-350
CC-81-178 CC-76?12
2?9?83
7?2?82
11-9?81
10-26-82
Name of
Respondent
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
258.00 Disallowed 11-9-81
300.70 Disallowed
10,000.00 Disallowed
1-28-83
11?25?81
C.)
C-,
Cl)
cJ
C.)
0
0
C)
z
Cl)
114.00 Disallowed
4-22-83
26,000.00 Disallowed 9-23-82
250,000.00
Disallowed
50,000.00 Disallowed
4?22-83
9-23-82
67.44 Disallowed 4-22-83
244.25 Disallowed
500,000.00 Disallowed
3-16-83
8-24-81
Department of
Highways
Department of Highways
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
No. Name of Claimant Name of Respondent
Amount Amount Date of Claimed Awarded Determination
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
70,000.00 Disallowed
25,000.00
1,500.00
109.32
8,000.00
72.68
4,000.00
154.50
(1 1-?
-4
-4
-4
0
0
I.z
Cl)
7?2?82
6-30?82
3- 14-83
3- 16?83
12-7-82
12?7-82
3?11?83
1-24-83
6-30-83
3-11-83
1-28-83
8-6-81
2-17?82
8-7-81
11-9-81
11-9-81
4-26-82
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed Disallowed
Disallowed
Department of Highways
677.35 Disallcwed 3-14?83
CC-82-16 |
Randall E. Rowley |
Department of Highways |
201.62 |
CC-82-60 |
Eldean Russell |
Department of Highways |
98.00 |
CC-80-38l |
Ryder Truck Rental, Inc. |
Department of Highways |
9,261.63 |
CC-82-319 |
Calvin L. Sargent |
Department of Highways |
1,410.19 |
CC-82-9R |
Richard L. Sargent |
Department of Highways |
43.45 |
CC-82-55 |
Robert C. Schumacher |
Department of Highways |
221.02 |
CC-81-428 |
Martha C. Scruggs |
Department of Highways |
140.00 |
CC-82-131 |
Clarence Shiflet and Florence Shiflet |
Department of Highways |
697.36 |
CC-80-242 |
Harry W. Shoemaker and Winifred G. Shoemaker |
Department of Highways |
|
CC-79-194 |
Terry Skeen |
Board of Regents |
|
CC-82-177 |
Alfred W. Smith |
Department of Highways |
|
CC-8l-5 |
Oscar D. Smith |
Department of Highways |
|
CC-79-56 |
Southern Gas and Oil, Inc. |
State Fire Marshal |
|
CC-80-l85 |
Margaret Spataf?re and Joseph Robert Soatafore |
Department of Highways |
|
CC-80-223 |
Richard A. Spotloe |
Administrative Office of the Supreme Court of Appeals |
|
CC-80-349 |
State Farm
Mutual |
Department of Highways |
|
CC-79-35 |
Bessie M.
Stone, by |
Department of Highways |
|
CC-81-26l |
George A. Stover and Carma Stover |
|
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
(1 1
U)
C))
C
C
(1
U)
U)
|
|
|
Amount |
Amount |
Date of |
No. |
Name of Claimant |
Name of Respondent |
Claimed |
Awarded |
Determination |
CC-81-50 |
Larry Lee Stricker |
Department of Highways |
155.60 |
Disallowed |
8-6-81 |
CC-81-416 |
Billy Sutphin |
Department of Highways |
92699 |
Disallowed |
3-11-83 |
CC-82-243 |
Jack L. Taylor |
Department of Highways |
832.15 |
Disallowed |
2-9-83 |
CC-82-163 |
Bertie Gibbs Thomas and Carolyn Thomas |
Department of Highways |
300.38 |
Disallowed |
12-7-82 |
CC-79-48 |
Audrey P. Tittle, Admin. of the Estate of Steven B. Parcell |
Department of Highways |
250,000.00 |
Disallowed |
4-26-82 |
CC-83-113 |
Alex Toth |
Department of Highways |
491.95 |
Disallowed |
6-24-83 |
CC_81-376 |
William M. Truman |
Office of Emergency Services |
5,620.00 |
Disallowed |
9-23-8? |
CC-82-93 |
United Farm Bureau Mutual Insurance Comoany |
Department of Public Safety |
6,080.75 |
Disallowed |
3-14-83 |
CC-83-122 |
Carole E. Updyke and Lionel Joe Updyke |
Department of Highways |
86.97 |
Disallowed |
6-24-83 |
CC-82-115 |
David E. Utt |
Department of Highways |
142.00 |
Disallowed |
9-23-82 |
CC-82-304 |
Robert Varney |
Department of Highways |
208.97 |
Disallowed |
3-16-83 |
CC-81-343 |
Vecellio & Grogan, Inc., for Peraldo Construction Company |
Department of Highways |
11,585.20 |
Disallowed |
4-22-83 |
CC-78-113 |
Charles S. Ward, guardian of Charles F. Ward |
Department of Corrections |
125,000.00 |
Disallowed |
1-27-83 |
CC-81-145 |
Ranson Bailey Ward and Debra Dawn Ward |
Department of Highways |
255.42 |
Disallowed |
11-9-81 |
CC-81-122 |
John J. West |
Department of Highways |
209.21 |
Disallowed |
2-17-82 |
CC_81-219 |
Michael E. Whalen and Ann Whalen |
Department of Health |
43,000.00 |
Disallowed |
6-30-83 |
CC-82-39 |
Drema Faye Wheeler |
Department of Highways |
|
Disallowed |
7-2-82 |
CC-80-338 |
Cecil Whitt, Sr. |
Department of Highways |
602.00 |
Disallowed |
9-29-81 |
No. Name of
Claimant
Wayne F. Wiggins
Renna S. Wilcox
A. B. Williams
Roy Franklin Williams, Jr.
and Beverly Williams
CC-82-100 Bob E. Willis and
Ragene Willis
CC-77-l03 Clyde Wood
CC-80-241 James Woody and
Lottie L. Woody
Gary L. Workman and
Brenda Workman
Martha P. Yoak, by
her agent, Judson K. Yoak
CC-81-75 Andrew S. Young
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
CC-82-207
CC-82-63
CC-79-466
CC-83-l17
Amount Amount Date ef Claimed Awarded Determination
449.82
116.28
14,067.92
85.54
CC?82-l32
CC-80-380
Disallowed
Disallowed
Disallowed
Disallowed
Name of
Respondent
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways Department of Highways
Department of Highways
Department of Highways
Department of Highways
C,
2-9-83
6-30-82
6-24?83
6-24-83
12-7-82
10-12-82 0
6-30-83
C,
4-22-83
3-16-83
1-26-83
C,)
119.38 Disallowed
950.00 Disallowed
80,000.00 Disallowed
394.43 Disallowed
60000.00 Disallowed
3,995.55 Disallowed
REPORT OF THE COURT OF CLAIMS (Continued)
(5) Advisory determinations made at
the request of the Governor or the head of a State agency:
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-81-388 Department of Department of Corrections 26,599.96 Disallowed
12-16-81
Employment Security
CC-82-58 Department of Highways Farm Management Commission 8,379.91 Disallowed
7-13-82
CC-82-76 Welding, Inc. Department of Corrections 22,950.00 22,950.00 5-20-82
CC-81-413 West Virginia Department of Corrections 7,440.43 Disallowed 2-2-82
University Hospital
CC-82-145 West Virginia Department of Corrections 117.50 Disallowed 10-26-82
University Pharmacy
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
No. Name of Claimant Name of Respondent
CD
P2
Cl)
CD
0
0
CD
1-?
Cl)
Cl)
*This claim was omitted from the Claims Bill by the 1983 Legislature.
|
Amount |
Amount |
Date of |
||
Claimed |
Awarded Determination |
||||
CC-82-315 |
A. H. Robins Co. |
Department of Corrections |
259.54 |
Disallowed |
2-9-83 |
CC-82-78 |
Ace Adjustment |
Department of Corrections |
325.00 |
Disallowed |
6-30-82 |
CC-81-289 |
C. K. Agarwal |
Department of Corrections |
70.00 |
Disallowed |
11-5-81 |
CC-82-211 |
C. K. Agarwal |
Department of Corrections |
1,235.00 |
Disallowed |
10-26-82 |
CC-81-293 |
Agway, Inc. |
Farm Management Commission |
412.07 |
Disallowed |
11-4-81 |
CC-81-217 |
Hassan Amjad |
Department of Corrections |
295.00 |
Disallowed |
11-5-81 |
CC-82-208 |
Jett S. Andrick |
Department of Corrections |
843.00 |
Disallowed |
10-26-82 |
CC-81-245 |
Appalachian Mental Health Center |
Department of
Corrections |
4,400.00 |
Disallowed |
11-5-81 |
CC-81-299 |
Appalachian Regional Hospital |
Department of Corrections |
1,690.00 |
Disallowed |
11-5-81 |
CC-81-282 |
Ayerst Laboratories |
Department of Corrections |
411.57 |
Disallowed |
11-5-81 |
CC_82_259* |
B. & S. Air Taxi Service |
Office of the Secretary of State |
304.50 |
Disallowed |
12-1-82 |
CC-82-214 CC-81-254 |
Beckley Medical Arts, Inc. Beckley Radiology Associates |
Department of Corrections Department of Corrections |
60.00 |
Disallowed |
10-26-82 |
CC-81-314 |
Beckley Veterinary |
Farm Management Commission |
188.00 |
Disallowed |
11-4-81 |
CC-81-444 CC-81-250 |
Hospital, Inc. |
Department of Corrections Department of Corrections |
100.91 |
Disallowed |
1-28-82 |
CC-81-352 |
Bessire &
Company, Inc. |
Farm Management
Commission |
540.70 |
Disallowed |
11-4-81 |
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-81-239 Boso Agri-Center, Inc. Farm Management Commission 8,406.83 Disallowed
11-4-81
CC-82-318 Boso Agri-Center, Inc. Farm Management Commission 2,288.94 Disallowed
2-9-83
CC-81-315 Boury, Inc. Department of Corrections 1,984.28 Disallowed 11-5-81
CC-82-150 Bowlings, Inc. Department of Corrections 407.74 Disallowed 12-1-82
CC-81-423 Buckeye Gas Products Farm Management Commission 95.39 Disallowed
12-9-81
Company
CC-82-226 Butler?s Pharmacy Department of Corrections 2,466.18 Disallowed
12-1-82
CC-81-247 C. H. James & Co. Department of Corrections 1,149.18 Disallowed
11-5-81
CC-82-326 C. H. James & Co. Department of Corrections 2,332.18 Disallowed
2-9-83
CC-81-295 Frank J. Cary? Farm Management Commission 3,344.55 Disallowed 11-4-81
Mountainland Animal Hospital
CC-81-338 Cecil E. Jackson Farm Management Commission 65.06 Disallowed 11-4-81
Equipment, Inc.
CC-82-297 Chandra P. Sharma, Department of Corrections 250.00 Disallowed
12-16-82
M.D., Inc.
CC-81-462 Charleston Area Department of Corrections 299.50 Disallowed 1-28-82
Medical Center
CC-81-439 Clarksburg Drug Company Department of Corrections 714.83 Disallowed
1-28-82
CC-82-4 Copy Graphics, Inc. Insurance Department 522.13 Disallowed 2-1-82
CC-81-218 Corder Tractor & Farm Management Commission 210.52 Disallowed
11-4-81
Equipment Company
CC-81-393 Craig Motor Service Department of Corrections 256.35 Disallowed
12-9-81
Co., Inc.
CC-81-226 G. Jay Crissman Farm Management Commission 265.00 Disallowed 11-4-81
CC-82-186 J. P. Currence Office of the Secretary of State 143.00 Disallowed
1-25-83
CC-81-344 Saryu P. Dani Department of Corrections 40.00 Disallowed 11-5-81
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
Amount Amount Date of Claimed Awarded Determination
C)
Ci)
-I
C)
I-I
0
0
2I
C)
Ci)
Ci)
*The claim was omitted from the Claim Bill by the Legislature.
No. |
Name of Claimant |
Name of Respondent |
|
||
CC-81-279 |
Darwin 0. Fike, d/b/a |
Farm Management Commission |
208.30 |
Disallowed |
11-4-81 |
|
Surge Sales & Service |
|
|
|
|
CC-81-337 |
James L. Davison |
Farm Management Commission |
122.25 |
Disallowed |
11-4-81 |
CC-81-222 |
Dearing Brothers. Inc. |
Farm Management Commission |
591.34 |
Disallowed |
11-4-81 |
CC-81-311 |
Dentists Fee Office |
Department of Corrections |
300.00 |
Disallowed |
11-5-81 |
CC_81_117* |
Department of Finance & Administration |
Department of Corrections |
13,702.00 |
Disallowed |
8-6-81 |
CC-81-3835 |
Department of Highways |
Department of Corrections |
3,69873 |
Disallowed |
11-5-81 |
CC_82_57* |
Department of Highways |
Department of Corrections |
194.63 |
Dsallowed |
5-21-82 |
CC-81-317 |
Dorsey Laboratories |
Department of Corrections |
156.90 |
Disallowed |
11-5-81 |
CC-81-455 |
E. R. Squibb & Sons, Inc. |
Department of Corrections |
214.60 |
Disallowed |
1-28-82 |
CC-81-211 |
Eglon Farm Service |
Farm Management Commission |
16,709.35 |
Disallowed |
11-4-81 |
CC-81-394 |
Elkins Dental Lab |
Department of Corrections |
67.00 |
Disallowed |
12-9-81 |
CC-81-294 |
Elkins Machine & Electric Co. |
Farm Management Commission |
556.00 |
Disallowed |
11-4-81 |
CC-81-229 |
Elkins Tire Company |
Farm Management Commission |
140.76 |
Disallowed |
11-4-81 |
CC-81-395 |
Equitable Gas, Inc. |
Department of Corrections |
45,831.75 |
Disallowed |
12-9-81 |
CC-81-456 |
Exxon Company, USA |
Department of Corrections |
229.74 |
Disallowed |
1-28-82 |
CC-82-136 |
Exxon Co., U.S.A. |
Farm Management Commission |
219.71 |
Disallowed |
9-2,3-32 |
CC-82-244 |
F. M. Mingo |
Department of Corrections |
99.00 |
Disallowed |
12-1-82 |
CC-82-222 |
FMRS Mental Health Council, Inc. |
Department of Corrections |
96.00 |
Disallowed |
12-1-82 |
CC-81-354 |
Fairmont State College |
Department of Corrections |
1,819.99 |
Disallowed |
11-5-81 |
CC-81-336 |
Firestone Stores |
Farm Management Commission |
119.50 |
Disallowed |
11-4-81 |
CC-81-384a |
The Firestone Tire and Rubber Company |
Department of Corrections |
574.34 |
Disallowed |
11-5-81 |
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but payments made by special appropriations by the Legislature:
CD
I C) -4
0
0
ITJ
C)
(j
z
|
|
|
Amount |
Amount |
Date of |
No. |
Name of Claimant |
Name of Respondent |
Claimed |
Awarded |
Determination |
CC-81-384b |
The Firestone Tire and Rubber Company |
Farm Management Commission |
51.60 |
Disallowed |
11-4-81 |
CC-81-286 |
Robert M. Flesher? |
Farm Management Commission |
55.00 |
Disallowed |
11-4-81 |
CC-81-227 |
Upshur Veterinary Hospital Frank?s Service Center |
Farm Management Commission |
110.43 |
Disallowed |
11-4-81 |
CC-81-23l |
Fullen Fertiziler Company, Inc. |
Farm Management Commission |
453.65 |
Disallowed |
11-4-81 |
CC-81-3 18 |
Fulton-Thompson Tractor Sales, Inc. |
Farm Management Commission |
675.00 |
Disallowed |
11-4-81 |
CC-81-368 |
Gall?s, Inc. |
Department of Corrections |
2,296.94 |
Disallowed |
11-5-81 |
CC-81-327 |
Gibson?s Scale Service |
Farm Management Commission |
677.40 |
Disallowed |
11-4-81 |
CC-81-276 |
Grafton City Hospital |
Department of Corrections |
3,777.94 |
Disallowed |
11-5-81 |
CC-82-36 |
Grafton City Hospital |
Department of Corrections |
108.00 |
Disallowed |
5-21-82 |
CC-81-392 |
Greenbrier Physicians Inc. |
Department of Corrections |
50.00 |
Disallowed |
12-9-81 |
CC-81-438 |
Greenbrier Physicians Inc. |
Department of Corrections |
1,348.50 |
Disallowed |
1-28-82 |
CC-82-250 |
Greenbrier Physicians Inc. |
Department of Corrections |
550.00 |
Disallowed |
12-1-82 |
CC-81-234 |
Greenbrier Tractor Sales, Inc. |
Farm Management Commission |
4,717.67 |
Disallcwed |
11-4-81 |
CC-81-264 |
Greenbrier Valley Farm Center, Inc. |
Farm Management Commission |
3,212.90 |
Disallowed |
11-4-81 |
CC-81-277 |
Greenbrier Valley Hospital |
Department of Corrections |
4,644.52 |
Disallowed |
11-5?81 |
CC-81-347 |
Greenbrier Valley Hospital |
Department of Corrections |
898.18 |
Disallowed |
11-5-81 |
CC-82-5 |
Greenbrier Valley Hospital |
Department of Corrections |
700.17 |
Disallowed |
1-28-82 |
CC-82-210 |
Harold E. Harvey, M.D., Inc. |
Department of Corrections |
75.00 |
Disallowed |
10-26-82 |
CC-81-270 |
Hedlund Manufacturing Co., Inc. |
Farm Management Commission |
1,622.07 |
Disallowed |
11-4-81 |
CC-81-230 |
Henderson Implement Company |
Farm Management Commission |
618.14 |
Disallowed |
11-4-81 |
CC-81-305 |
Henry Schein, Inc. |
Department of Corrections |
397.25 |
Disallowed |
11-5-81 |
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
No. Name of Claimant
CC-81-221 Heritage Equipment Company
CC-81-335 Humberson Farm Equipment
CC-81-260 Eugene E. Hutton, Jr.
CC-81-364 Independent Dressed
Beef Company, Inc.
CC-81-333 J. D. Woodrum, M.D., Inc. 11-5-81
CC-81-273 J. H. Holt Plumbing 11-4-81
and Heating, Inc.
CC-81-382 Jefferds Corporation 11-4-81
CC-81-187 Jenkins Concrete 12-9-81
Products, Co.
CC-81-320 E. L. Jimenez
CC-81-232 Jcalde Sales & Service
CC-81-298 Johnson?s Boiler
Sales & Service, Inc.
CC-8l-274 Johnston Alternator
and Trailer Sales, Inc.
CC-8l--243 Keefer?s Service Center
CC-81-285 Lawson Products, Inc.
CC-81-263 Lewis & Burge, Inc.
CC-8l-242 Liggett?s Supply
CC-82-299 Lois McElwee Memorial
Clinic
CC-81-214 Marlinton Electric Co., Inc. 11?5?81
CC-81-255 Marshall County 11-4-81
Cooperative, Inc.
CC-81-360 Mason County D.H.I.A., Inc. 11-4-81
Amount Amount Date of Claimed Awarded Determination
268.12
595.67
5,038.00
3,738.90
Disallowed
Disallowed
Disallowed
Disallowed
11-4-81
11-4-81
11?5?81
11?5?81
95.00 Disallowed
1,000.40 Disallowed
747.24 Disallowed
940.50 Disallowed
Name of
Respondent
Farm Management Commission
Farm Management Commission
Department of Corrections
Department of Corrections
Department of Corrections Farm Management Commission
Farm Management Commission Farm Management Commission
Department of Corrections
Farm Management Commission
Department of Corrections
Farm Management Commission
Farm Management Commission
Farm Management Commission
Farm Management Commission
Farm Management Commission
Department of Corrections
Dep?rtment of Corrections Farm Management Commission
Farm Management Commission
860.00
35.87
13,883.22
Disallowed
Disallowed
Disallowed
C-)
425.54 Disallowed
3,219.64
922.28
170.96
638.48
140.00
12-9-81
11-4-81
11-5-81
11-4-81
11-4-81
11-4-81
11-4-81
11?4-81
12-16?82
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
80,609.40
Disallowed
78.00 Disallowed
527.46 Disallowed
REPORT
OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
No. Name of Claimant Name of Respondent
|
Amount Claimed |
Amount Awarded |
Date of Determination |
||
CC-81-398
CC-82-255 |
Matthew Bender
& Company Department of Corrections |
1,459.00 |
Disallowed
Disallowed |
1-28-82 |
|
CC-82-2l8 CC-81-297 |
William D.
McLean Department of Corrections |
64.00 |
Disallowed Disallowed |
12-1-82 |
|
CC-81-365 |
Memorial General Department of Corrections |
133,500.35 |
Disallowed |
11-5-81 |
|
CC-82-256 |
Hospital
Association |
165,695.32 |
Disallowed |
o |
|
CC-81-237 |
Association,
Inc. |
130.00 |
Disallowed |
11-5-81 |
|
CC-8l-346 CC-8l-233 |
Board and ABC Commissioner Motor Car Supply Company Farm Management Commission Mountain Mobile Milling Farm Management Commission |
67.46 |
Disallowed Disallowed |
1-28-82 |
. 4 |
CC-82-106 |
Mountaineer
Motor Sales, Inc. Farm Management Commission |
86.87 |
Disallowed |
7-13-82 |
. 4 |
CC-8l-303 |
Improvement
Association |
412.06 |
Disallowed |
11-5-81 |
|
CC-81-278 |
Nova Rubber Company, Inc. Department of Corrections |
540.00 |
Disallowed |
11-5-81 |
|
CC-81-89 |
Ohio Valley Medical Center Department of Corrections |
125.80 |
Disallowed |
8-6-81 |
|
CC-82-276 |
Ohio Valley Medical Department of Corrections |
22,614.68 |
Disallowed |
12-7-82 |
|
|
Center, Inc. |
|
|
|
|
REPORT
OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
Amount Amount Date of
Name of Claimant Claimed Awarded Determination
CC-81-272 Orthopedic Clinic, Inc.
CC-81-328 Overnite Transportation Co.
CC-81-262b B. Payman
CC-82-205 B. Payman
CC-81-287 Perrmont Chemical Company
CC-82-l85 Peters Fuel Corp.
CC-8l?366 Pfizer, Inc.
CC-81-257 Physicians Associates, Inc.
CC-81-312a Physicians Fee Office
CC-8l-312b Physicians Fee Office
CC-8l-448 Physicians Fee Office
CC-82-284 Physicians Fee Office
CC-8l-235 Pickens Hardware Co., Inc.
CC-81-256 Picker Corporation
CC-81-339 Pioneer Harvestore
Systems, Inc.
CC-83-37 Potomac Valley Hospital
CC-81-373 Princeton Community Hospital
CC-81-225 Princeton Internists
CC-82-206 Professional Laboratory
& X-Ray
CC-8l-267 Raleigh General Hospital, Inc.
CC-81-307 Raleigh Gcneral Hospital, Inc.
CC-81-296a Raleigh Orthopaedic
Assoc., Inc.
CC-81-296b Raleigh Orthopaedic
Assoc., Inc.
No.
Name of Respondent
Cl,
Cl, I
C) 0
0
C,
Cl,
Cl,
Department of
Corrections |
350.00 |
Disallowed |
11-5-81 |
Department of
Corrections |
56.10 |
Disallowed |
5-25-83 |
Department of
Corrections |
1,541.25 |
Disallowed |
11-5?81 |
Department of Corrections |
2,310.00 |
Disallowed |
11-5-81 |
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
No.
CC-82-286
CC-82-217
CC-81-283
CC-81-198
CC-81-212
CC-81-265
CC-82-2l2a
CC-82-212b
CC-81-287b
CC-81-387a
CC-82-165
CC-81-403
CC-82-22
CC-81-329
CC-82- 130
CC-81-236
CC-81-241
CC?81-194
CC-8l-244
Name of
Claimant
Mario C. Ramas
D. L. Rasmussen
Reed & Carnrick
Reynolds Memorial
Hospital, Inc.
Reynolds Memorial
Hospital, Inc.
Reynolds Memorial
Hospital, Inc.
Reynolds Memorial
Hospital, Inc.
Reynolds Memorial
Hospital, Inc.
SK&F Co.
SK&F Lab Co.
Scott Saw Sales & Service
Seneca Mental Health Mental
Retardation Council, Inc.
Chandra P. Sharma
Adnan N. Silk-Beckley
Neurosurgical Clinic
Charles H. Simmons,
d/b/a Simmons? Hauling
Rajendra P. Singh
Skyland Hospital Supply
Southern Chemical Co.
Southern Chemical Co.
Name of
Respondent
Department of Corrections
Department of Corrections
Department of Corrections
Department of Corrections
Department of Corrections
Department of Corrections
Department of Corrections
Farm Management Commission
Department of Corrections Department of Corrections Department of Corrections
Department of Corrections
Department of Corrections
Farm Management Commission
Department of Corrections
Department of Corrections
Amount Date of Awarded Determination
Department
Department
Department
of Corrections of Corrections of Corrections
0
0
Cl
Amount Claimed |
|
|
110.00 |
Disallowed |
12-16-82 |
4,535.90 |
Disallowed |
11-5-81 |
39,476.17 |
Disallowed |
11-5-81 |
79,281.45 |
Disallowed |
12?16-82 |
15,899.49 |
Disallowed |
12-16-82 |
20.82 |
Disallowed |
11-5-81 |
815.00 |
Disallowed |
2-16-82 |
1,926.80 |
Disallowed |
12-1-82 |
215.00 |
Disallowed |
11-5?81 |
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
No.
CC-81-453
CC-81-348
CC-81-269
CC-82-241
CC-81-262a
CC_82-232
CC-8l-263
CC-82-202
CC-82-2
CC-81-213
CC-81- 460
CC -8 1-40 1
CC-81-304
CC-81-331
CC-81-253
CC-81-321
CC-81-228
CC-81-340
CC-81-405
Name of
Claimant
Southern States Cooperative
Southern States Elkins
Coop., Inc.
Southern States
Marlinton, Coop.
Steven Richman, DO, Inc.
Summers Community Clinic
Summers Community
Clinic Pharmacy
Summers County Hospital
Summers County Hospital
Superior Parts Service, Inc.
Swisher?s Feed and Supply
T. H. Mirza, M.D., Inc.
Taylor County Commission
John R. Tomlinson?
Fairlea Animal Hospital
Town & Country
Veterinary Clinic
Tn-State Ambulance
and Rentals
Tygarts Valley D.H.I.A.
Tygarts Valley Sanitation, Inc.
Union Oil Company of
California
Union Oil Company of
California
Name of
Respondent
Farm Management Commission Farm
Management Commission Farm Management Commission
Department of Corrections
Department of Corrections
Department of Corrections
Department of Corrections
Department of Corrections
Farm Management Commission
Farm Management Commission
Department of Corrections
Department of Corrections
Farm Management Commission
Farm Management Commission Department of Corrections
Farm Management Commission
Farm Management Commission
Department of Corrections
Department of Corrections
Amount
Claimed
455.31
24,591.24
29.85
495.00
103.02
29.90
13,341.30
13,456.65
56.25
2,068.40
115.00
248.00
249.00
1,588.50
569.00
85.30
60.00
8,452.08
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed Disallowed
Disallowed
Disallowed
Disallowed
1,149.19 Disallowed
1- 28-82
11-4-81
11-4-81
12-1-82
11-5-8 1
10 -26-82
11-5?81
10-26-82
1-28-82
11-4-81
1-28-82
1- 28-82
11-4-81
11-4-8 1
11-5-81
11-4-81
11-4-81
11?5?81
12-9-81
Amount Date of Awarded Determination
Disallowed
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but payments made by special appropriations by the Legislature:
No. Name of
Claimant
Union Oil Company of
California
Union Oil Company of
California
Union Oil Company of
California
The Upjohn Company
Utah Valley Hospital
Alfredo C. Velasquez
Virginia Harvestore, Inc.
G. W. Wandling
Walter J. Klein
Company, Ltd.
Ward Auto Parts Co.
Wechsler Coffee Corporation
West Virginia Artificial
Breeders Cooperative, Inc.
West Virginia Paper, Inc.
West Virginia School of
Osteopathic Medicine
West Virginia School of
Osteopathic Medicine
Clinic, Inc.
CC-82-306 West Virginia School of Osteopathic Medicine
Clinic, Inc.
Amount Amount
Date of
Claimed Awarded Determination
2,554.93 Disallowed 12-9-81
7,958.58 Disallowed 11-4-81
44.40 Disallowed 11-4-81
CC -8 1-407
CC-81-252
CC-81-l95
CC-81-281
CC-82-300
CC-82-253
CC-81-258
CC-81-284
CC?81?20l
CC-81-330
CC-81-259
CC-8l-357
CC-81-290
CC-81-461
CC-81-464
0
Cl)
Cl)
-4
-4
0
-4
0
0
0
Cl)
z
Cl)
Name of Respondent |
|
||
Department of Corrections |
|||
Farm Management Commission |
|||
Farm Management Commission |
|||
Department of
Corrections |
791.07 |
Disallowed |
11-5-81 |
Farm Management
Commission |
667.16 |
Disallowed |
11-4-81 |
Department of Corrections Department of Corrections |
3,478.25 |
Disallowed |
11-5-81 |
Department of Corrections |
20,305.17 |
Disallowed |
1-28-82 |
Department of Corrections |
14,709.50 |
Disallowed |
1-25-83 |
REPORT OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature:
Name of Claimant
West Virginia
Turnpike Commission
Westinghouse Electric
Supply Company
Weston Veterinary Clinic
White Sulphur Pharmacy, Inc.
Whitman Exterminating
Company
Wilson Welding Supply
Company
Winchester Equipment Co.
Xerox Corporation
Young?s, Inc.
No.
CC-81-280
CC?82-221
CC-8l-300
CC-81-391
CC-81-3 13
CC-82-258
CC-8l-249
CC-81-420
CC-8l-240
Name of
Respondent
Farm Management Commission
Department of Corrections
Farm Management Commission
Department of Corrections
Farm Management Commission
Railroad Maintenance Authority
Farm Management Commission
Department of Corrections
Farm Management Commission
Amount
Claimed
28.00
732.76
273.00
399.30
68.00
340.00
155.34
2,801.94
211.00
Amount Date of
Awarded Determination
Disallowed 11-4-81
Disallowed 12-6-82
Disallowed 11-4-81
Disallowed 12-9-81
Disallowed 11-4-81
Disallowed 12-6-82
Disallowed 11-4-81
Disallowed 12-9-81
Disallowed 11-4-81
(I
J)
J2
I
0 0
I
C?,
Cl)
(7) Approved claims and awards satisfied by payment by the State agency through an opinion decided by the Court under the Shortened Procedure: None.
OPINIONS
LXX
TABLE OF CASES REPORTED
TABLE OF CASES
REPORTED
A. B. Dick
Company v. Workmen?s Compensation Fund--- 95
A. B. Engineering Company v. Department of Highways 42
A. H. Robins Co. v. Department of Corrections 375
Ace Adjustment Service, Inc., Agent for United Hospital
Center, Inc. v. Department of Corrections 158 Adams, Jimmie G. v. Department of
Highways 214 Adams, Shirley R. and Billie Adams v. Department
of Highways -
279
Agarwal, C. K. v. Department of Corrections (CC-81-289) 40
Agarwal, C. K. v. Department of Corrections (CC-82-211)_ 255
Agway, Inc. v. Farm Management Commission 38
Allstate Insurance Co., as subrogee of Jacqueline E.
Delazio v. Department of Highways 62
Allstate Insurance Co., as subrogee of Michael Hall v.
Department of Highways ?
280
American Hospital Supply v. Department of Health 244
Amjad, Hassan v. Department of Corrections 40
Anderson, Jesse C. v. Department of Highways 360
Anderson, Thomas Harold, Sr. and Edith Jolene
Anderson v. Department of Welfare 376
Andrick, Jett S. v. Department of Corrections 255
Appalachian Engineers, Inc. v. Board of Regents 493
Appalachian Engineers, Inc. v. Department of Finance
& Administration ?
159
Appalachian Mental Health Center v. Department of
Corrections ?
40
Appalachian Power Company v. Department of
Public Safety (CC-82-111) 469
Appalachian Power Company v. Department of
Public Safety (CC-83-118) 469
Appalachian Regional Hospital v. Department
of Corrections 41
Archer, Oncie E., Missouri Thompson, William Thompson,
Truman Thompson, Grover Thompson, Chloie Batten,
Nellie Summersville, Etta Ingram, Dora Life, and
Helen Lockhart v. Department of Highways 96
Arrowood, H. R. v. Department of Highways 439
Asbury, Leona and Tom Asbury v. Department
ofHighways 45
TABLE OF CASES
REPORTED LXXI
Ashley, Donald E. v. Department of
Highways 174
Auto Tech, Inc. v. Department of Highways 113
Ayerst Laboratories v. Department of Corrections 41
B. & S. Air Taxi Service v. Office of the Secretary
of State ?
261
Bailey, Connie Lawrence v. Department of Highways 405
Bailey, James E., Jr. v. Department of Highways 423
Bailey, Incorporated v. Board of Regents 470
Baker, Wayne K. d/b/a Baker Coal Company v.
Department of Highways 424
Ballard, W. H., II and G. David Brumfield v.
Department of Natural Resources 46
Bassett, David R. v. Department of Highways 426
Batton, Gary L. v. Civil Service Commission and
Department of Natural Resources 114
Beckley Medical Arts, Inc. v. Department of Corrections 255
Beckley Radiology Associates v. Department of Corrections 40
Beckley Veterinary Hospital, Inc. v.
Farm Management Commission 38
Beckman Instruments, Inc. v. Department of Health 438
Beegle, Gene Brady v. Department of Highways 361
Bellman, Steven, d/b/a Baskin-Robbins v. Department
of Highways -
97
Bennett Publishing Company v. Department of Corrections 92
Bennett, Larry L. v. Department of Highways 216
Benson, Norman E. v. Department of Highways 193
Bernhardt?s Clothing, Inc. v. Department of Corrections 40
Bessire & Company, Inc. v. Farm Management
Commission ?
38
Bill Henning, Inc. v. Farm Management Commission 94
Black Rock Contracting, Inc. v. Department of
Highways 340
Blankenship, Eli, Jr., Admin. of the Estate of Johnny
Blankenship, dec. v. Department of Highways 194
Blue Grass Equipment, Inc. v. Farm
Management Commission 38
Bobbitt, Gordon A. v. Department of Corrections 152
Boland, J. C. and Michael P. Boland v.
Department of Highways 196
LXXII TABLE OF
CASES REPORTED
Boiling, Pearl Hughes and Charles
Hughes v.
Department of Highways 119
Bonacci, Frank v. Department of Highways 135
Booten, Anna Lou v. Department of Highways 438
Bora, Narendra v. Department of Health 245
Boso Agri-Center, Inc. v. Farm Management
Commission (CC-81-239) ?
37
Boso Agri-Center, Inc. v. Farm Management
Commission (CC-82-318) 378
Boury, Inc. v. Department of Corrections 40
Bowen, Doris Jane, Wanda Sue Hanley, Larry Jenkins,
and Lana Jean Jenkins v. Department of Highways 1
Bowlings, Inc. v. Department of Corrections 261
Brady, Matta L., Admin. of the Estate of Shell C. Brady,
deceased v. Department of Highways 33
Britt, Teresa v. Department of Highways 378
Brock, Robert R. v. Workmen?s Compensation Fund 136
Brown, Carol Jo v. Department of Health 159
Brown, Jack E. v. Department of Highways 167
Browning, Arthur U. v. Supreme Court of Appeals 402
Browning-Ferris Industries, Chemical Service, Inc. v.
Department of Highways 399
Brumbaugh, Richard H. v. Office of the State Auditor 32
Buckeye Gas Products Company v. Farm
Management Commission 83
Bungard, John Charles v. Department of Welfare 48
Burcham, James and Patricia J. Burcham V.
Department of Highways 441
Burgess, Arlene and Charles E. Burgess v.
Department of Highways 160
Burke, Robert W. v. Department of Highways 495
Burner, D. A. v. Department of Public Safety 50
Bush, Armeda Jean v. Department of Highways 496
Butler Corporation v. Department of Highways 442
Butler?s Pharmacy v. Department of Corrections 262
C. H. James & Co. v. Department of Corrections
(CC-81-247) ?
40
C. H. James & Co. v. Department of Corrections
(CC-82-326) 379
TABLE OF CASES
REPORTED LXXIII
C. W. Lewis, Inc. v. Department of Corrections 427
Cale, Susan L. v. Board of Regents 262
Capinpin, Albert G. v. Department of Highways 299
Carl M. Geupel Construction Co., Inc. v.
Department of Highways 198
Carney, Bernard F. v. Department of Highways 51
Carter?s Safety Systems, Inc. v. Department of
Finance and Administration 52
Cary, Frank J., Mountainland Animal Hospital v.
Farm Management Commission 38
Casto, Haywood Jobe, Jr. v. Department of Corrections 497
Casto, Willard v. Office of the State Auditor 86
Cecil E. Jackson Equipment, Inc. v.
Farm Management Commission 38
Chafin Coal Company v. Workmen?s Compensation Fund 98
Chandra P. Sharma, M.D., Inc. v.
Department of Corrections 320
Charleston Area Medical Center v.
Department of Corrections 93
Charleston Business Machines v. State Tax Department. 161
Chesapeake & Potomac Telephone Company (The) v.
Department of Natural Resources 332
Chicago Embroidery Company v. Office of the
Secretary of State 168
Chumbow, Pius B. v. Department of Highways 363
City of Oak Hill v. Municipal Bond Commission 344
Clarksburg Drug Company v. Department of Corrections 93
Clay, Mason M. v. Department of Highways 115
Clay, Roger K. v. Board of Regents 300
Closson, David Lee v. Office of the Supreme
Court of Appeals 237
Cochran Electric Company v. Department of Highways 206
Coffman, John R. v. Department of Highways - 216
Cole, Mary Lou v. Department of Highways 350
Cole, Wilson R. v. Department of Highways 350
Cole, Wilson R. Admin. of the Estate of Mary
Jacqueline Cole v. Department of Highways 350
Cole, Wilson R. Admin. of the Estate of
Timothy Ray Cole v. Department of Highways 350
LXXW TABLE OF CASES REPORTED
Collins, Lillian West and John Collins v. Department
of Highways 131
Conley, Geneva v. Department of Highways 263
Conley, Michael v. Department of Highways 263
Conley, Robert v. Department of Highways 263
Conner, William and Lois Conner v.
Department of Highways 405
Cook, Betty v. Department of Highways 486
Cook, Dreama Dawn v. Department of Highways 217
Cook, Mary Lynn v. Department of Public Safety 331
Copy Graphics, Inc. v. Insurance Department 99
Corder Tractor & Equipment Company v. Farm
Management Commission ?
37
County Commission of Webster County v. Office of the
Supreme Court of Appeals 75
Coy, William E. v. Department of Health 344
Craig Motor Service Co., Inc. v.
Department of Corrections 85
Crank, Jesse J. v. Department of Highways 476
Crissman, G. Jay v. Farm Management Commission 37
Crites, Doy P. v. Department of Highways 428
Crosby Beverage Co., Inc. v. Nonintoxicating
Beer Commission ?
19
Crouch, Michael v. Department of Highways 280
Cunningham, Chad v. Department of Health 370
Cupp, Clifford v. Department of Health 53
Currence, J. P. v. Office of the Secretary of State 345
Cyrus, Ronald E. v. Department of Highways 334
Dairyland Insurance Company, subrogee of Jesse W.
Cobern, Jr. v. Department of Highways 300
Dairyland Insurance Company, subrogee of Wesley D.
Myers v. Department of Public Safety 100
Dani, Saryu P. v. Department of Corrections 40
Darlington, Harold E. v. Supreme Court of Appeals 402
Davis, Maurice V. v. Department of Highways 54
Davison, James L. v. Farm Management Commission 38
Day, E. W. v. Supreme Court of Appeals 402
Dean, Azile, Individually, and as Executrix of the Estate
of Virgil Dean, dec. v. Department of Highways 325
TABLE OF CASES
REPORTED LXXV
Dearing Borthers, Inc. v. Farm Management Commission - 37
Delazio, Jacqueline E. v. Department of Highways 62
Dennis, Charles v. Department of Public Safety 301
Dentists Fee Office v. Department of Corrections 41
Department of Employment Security v. Department
of Corrections (CC-81-388) 89
Department of Employment Security v. Department of
Corrections (CC-82-260a) 387
Department of Employment Security v. Department of
Corrections (CC-82-260b) ?
387
Department of Employment Security v. Department of
Corrections (CC-82-260c) 387
Department of Employment Security v. Department of
Corrections (CC-82-260d) 387
Department of Employment Security v. Department of
Corrections (CC-82-260e) 387
Department of Employment Security v. Department of
Corrections (CC-82-329) 387
Department of Employment Security v. Department of
Corrections (CC-82-330) 387
Department of Employment Security v. Department of
Corrections (CC-82-331) 387
Department of Employment Security v. Department of
Corrections (CC-82-334) 387
Department of Employment Security v. Department of
Culture and History (CC82-262) 389
Department of Employment Security v. Department of
Finance and Administration 428
Department of Employment Security v. Department of
Health (CC-82-263a) 390
Department of Employment Security v. Department of
Health (CC-82-263b) 429
Department of Employment Security v. Department of
Health (CC-82-263c) 429
Department of Employment Security v. Department of
Health (CC-82-332) 390
Department of Employment Security v. Department of
Public Safety (CC-82-266) 391
-7
LXXVI TABLE OF CASES REPORTED
Department of Employment Security v.
Farm Management Commission (CC-82-261) 391
Department of Employment ?Security v.
Human Rights Commission (CC-82-264) 392
Department of Employment Security v.
Insurance Commission 392
Department of Employment Security v.
Secretary of State (CC-82-333) 393
Department of Finance & Administration v.
Department of Corrections 3
Department of Highways v. Farm Management
Commission 186
Department of Highways v. Department of
Corrections (CC-81-383) 41
Department of Highways v. Department of
Corrections (CC-82-57) 152
Dilling, Edward E. and Jennifer Dilling v.
Department of Highways 171
Dingier, C. P. v. Office of the Supreme Court of Appea?s 402
Dixon, James W. and Doris A. Dixon v. Department
of Highways 90
Donaldson, Ruth A. v. Office of the Supreme
Court of Appeals 402
Dornbos, Norma, d/b/a The Party Beer Store v.
Department of Welfare 407
Dorsey Laboratories v. Department of Corrections 41
Dorton, June v. Workmen?s Compensation Fund 137
Dougherty, Peter H. v. Office of the Supreme
Court of Appeals 403
Durbin, Charles N. v. Department of Highways 302
E. R. Squibb & Sons, Inc. v. Department of Corrections 93
Eads, James D., et al. v. Department of Highways 498
Eastman Kodak Company v. Department of
Finance and Administration 101
Edwards, Jerry M. and Edgar E. Edwards v.
Department of Highways 354
Eglon Farm Service v. Farm Management Commission 37
Elkins Dental Lab v. Department of Corrections 84
TABLE OF CASES
REPORTED LXXVII
Elkins Machine & Elecertic Co. v.
Farm
Management Commission 38
Elkins Tire Company v. Farm Management Commission 37
Ellison, Kenneth N. v. Department of Highways 380
Energy Technology Consultants, Inc. D & M Weather
Service v. Board of Regents 101
Equitable Gas, Inc. v. Department of Corrections 84
Estep, William P., Sr. v. Department of Highways 55
Evans Lumber Company v. Division of Vocational
Rehabilitation ?
345
Evans, Nellie v. Department of Highways 3
Evans, Veda E. v. Department of Highways 121
Exxon Co., U.S.A. v. Farm Management Commission 218
Exxon Company, USA v. Department of Corrections 93
Fairmont State College v. Department of Corrections 41
Fewell, Kathleen R. v. Department of Highways 76
Fibair, Inc. v. Department of Highways 393
Fidler, Cheryl M. v. Department of Highways 162
Fike, Darwin 0., d/b/a Surge Sales & Service v.
Farm Management Commission 38
Firestone Stores v. Farm Management Commission 38
Firestone Tire and Rubber Company (The) v.
Department of Corrections 41
Firestone Tire & Rubber Company v. Department of
Natural Resources 102
Firestone Tire and Rubber Company (The) v. Farm
Management Commission 39
Flesher, Robert M., Upshur Veterinary Hospital v.
Farm Management Commission 38
Fletcher, Dae Anne and Paul Norman Fletcher V.
Department of Highways 219
FMRS Mental Health Council, Inc. v. Department
of Corrections 262
Foster & Creighton Company and Vecellio & Grogan,
Inc. v. Department of Highways 475
Frank?s Service Center v. Farm Management
Commission 37
Friend, C. Elaine v. Office of the Supreme Court
of Appeals 370
LXX VIII TABLE
OF CASES REPORTED
Frisco, Victor and Janet Frisco v.
Department of
Natural Resources 346
Frum, Richard D. v. Office of the State Auditor 32
Fuiks, Rabert Lee, Jr. v. Department of Education 56
Fullen Fertiziler Company, Inc. v. Farm
Management Commission 36
Fulton-Thompson Tractor Sales, Inc. v. Farm
Management Commission 38
Furner, Nelson Eddie, an Incompetent, sues by and
through Ava Elizabeth Furner Young, his next friend,
and Ava Elizabeth Furner Young, individually v.
Department of Health 245
G. M. McCrossin, Inc. v. Board of Regents 265
Gall?s, Inc. v. Department of Corrections 41
Gates Engineering Company, et al. v. Board of Regents - - 500
Gaughan, John J. v. Department of Highways 122
General Accident F/L Assurance Corp., Ltd. Subrogee
of Innovative Industries v. Department of Highways 20 General Communications
Company v. Board of Regents -- - 5 General
Motors Acceptance Corporation v.
Department of Mtor Vehicles 268
Gibson, Alonzo v. Department of Highways 57
Gibson?s Scale Service v. Farm Management Commission - 38
Goddard, Silbern D. and Metta Goddard v.
Department of Corrections 281
Gold, David R. and Louis H. Khourey, d/b/a Gold &
Khourey v. Office of the State Auditor (Mental
Hygiene Fund) (CC-82-192a) 247
Gold, David R. and Louis H. Khourey, d/b/a Gold &
Khourey v. Office of the State Auditor (Needy
Persons Fund) (CC-82-192a) 247
Gold, David R. and Louis H. Khourey, d/b/a Gold &
Khourey v. Public Legal Services
(Mental Hygiene Fund) (CC-82-192b) 248
Gold, David R. and Louis H. Khourey, d/b/a Gold &
Khourey v. Public Legal Services
(Needy Persons Fund) (CC-82-192b) 248
Gore, Dorothy M. v. Department of Highways 175
/ a
TABLE OF CASES REPORTED LXXIX
Gore, Dorothy M. v. Department of
Highways
(Petition for Rehearing) 502
Gould, Henry W. v. Board of Regents 304
Graff, Margaret v. Board of Regents 318
Grafton City Hospital v. Department of Corrections
(CC-81-276) 41
Grafton City Hospital v. Department of Corrections
(CC-82-36) 153
Graham, Richard D., Jr. v. Office of the Supreme Court
of Appeals ?
238
Greathouse, Larry v. Department of Health 154
Green Tab Publishing v. Department of Corrections 239
Green, Susan L. v. Office of the Supreme Court of Appeals 416
Greenbrier Physicians Inc. v. Department of
Corrections (CC-81-392) 85
Greenbrier Physicians Inc. v. Department of
Corrections (CC-81-438) 93
Greenbrier Physicians Inc. v. Department of
Corrections (CC-82-250) 276
Greenbrier Tractor Sales, Inc. v. Farm
Management Commission 37
Greenbrier Valley Farm Center, Inc. v. Farm
Management Commission 37
Greenbrier Valley Hospital v. Department
of
Corrections (CC-81-277) ?
40
Greenbrier Valley Hospital V. Department of
Corrections (CC-81-347) 39
Greenbrier Valley Hospital v. Department of
Corrections (CC-82-5) 93
Greene, Glen v. Office of the Supreme Court of Appeals 403
Gregory, Nelson v. Department of Highways 355
Grey, John v. Board of Examiners for Registered Nurses - 395
Guthrie, Earl F. v. Department of Highways 304
Gyke, Paul and Joe Ann Gyke v. Department of
Highways 282
H & A Coal & Hauling, Inc. v. Department of
Highways 26
Hackney, Diana Lynn v. Department of Highways 77
Haines, Lester Rollings v. Department of Corrections 453
I
LXXX
TABLE OF CASES REPORTED
Hall, L. D. v. Department of Highways
58
Hall, Patricia Ann and Lacy Hall v.
Department of
Highways 169
Hall, William Paul, Sr., Admin. of the Estate of William
Paul Hall, Jr., dec. v. Department of Health 305
Halstead, Atholl W. v. Department of Highways 163
Hannigan, John A. and Carolyn Ann Hannigan v.
Department of Highways 5
Harman, Donald A. v. Department of Corrections 347
Harmon, Millard A. v. Department of Highways 454
Harold E. Harvey, M.D., Inc. v. Department of
Corrections 255
Harper, Ronald H. and Sarah E. Harper v.
Department of Highways 78
Harrison, U. G. and Edna Harrison v. Department of
Highways 456
Hart, Robert, d/b/a Bob?s Bake Shop v. Department
of Highways 443
Hatfield, Forrest C. v. Department of Highways 220
Hawes Electric C. v. Department of Health 102
Haynes, Barbara v. Board of Regents 327
Haynes, Lois V. and E. Robert Haynes v.
Department of Highways 460
Hedlund Manufacturing Co., Inc. v. Farm Management
Commission ?
?- 38
Henderson, Christine E. and Rodgers Paul Henderson
v. Department of Highways 21
Henderson Implement Company v. Farm Management
Commission ?
37
Hennessy, Francis J. v. Board of Regents 103
Henry Elden & Associates v. Department of Health and
Department of Finance and Administration 307
Henry F. Ortlieb Brewing Co. v. Nonintoxicating Beer
Commission 104
Henry Schein, Inc. v. Department of Corrections 41
Henry, Benjamin C. v. Department of Highways 371
Heritage Equipment Company v. Farm Management
Commission 37
Hertz Corporation (The) v. Department of Public Safety 170
Hill, Geneva v. Department of Highways 249
TABLE OF CASES
REPORTED -
LXXXI
Hill, Stephen Kent (Mr. & Mrs.)
v. Board of Regents 283
Hiller, Glenn E. v. Department of
Highways 269
Hiner, Ida M. and Norman F. Hiner, d/b/a Hercules
Construction Company v. Department of Natural
Resources 430
Hissam, Mark A. and Julia A. Hissam v.
Department of Highways 284
Hogsett, Donald R. v. Department of Health 400
Holly, Kenney, Schott, Inc. v. Department of Highways 381
Holmes, Bobbie E. and Neva I. Holmes v.
Department of Highways 356
Holzer Medical Center v. Department of Health 444
Hooten Equipment Company v. Board of Regents 503
Howard Uniform Company v. Department of
Public Safety 91
Howerton, lUcky S. v. Department of Highways 286
Hughes-Bechtol, Inc. v. Board of Regents 189
Humberson Farm Equipment v. Farm Management
Commission 38
Hupp, Joyce v. Office of the Chief Medical Examiner 186
Hutchinson, James David v. Department of Highways 335
Hutton, Eugene E., Jr. v. Department of Corrections 41
Independent Dressed Beef Company, Inc. v.
Department of Corrections 41
Industrial Gas & Supply Company v. Department of
Highways 288
Isner, Robert A. v. Office of the Supreme Court
of Appeals 239
J. D. Woodrum, M.D., Inc. v. Department of Corrections 40
J. H. Holt Plumbing and Heating, Inc. v. Farm
Management Commission 38
Jarboe, Patricia Ann v. Department of Highways 13
Jarboe, Robert N. v. Department of Highways 13
Jarboe, Robert N., as next friend of Stephanie
Jarboe v. Department of Highways 13
Jarrell, Claude W. v. Department of Highways 407
Jefferds Corporation v. Farm Management Commission 39
Jenkins Concrete Products, Co. v. Farm Management
Commission 83
/
LXXXII TABLE OF CASES REPORTED
Jett, Waitman D. and Marilyn Jett v. Department of
Highways 250
Jimenez, E. L. v. Department of Corrections 84
Joalde Sales & Service v. Farm Management
Comrrdssion 37
John D. Tonkovich and Sons, Inc. v. Department
of Highways 505
Johnson Controls, Inc. v. Department of Finance and
Administration CC(-81-316) 105
Johnson Controls, Inc. v. Department of Finance and
Administration (CC-81-454) 106
Johnson Controls, Inc. v. Department of Finance and
Administration (CC-82-87) 171
Johnson?s Boiler Sales & Service, Inc. v. Department
of Corrections 40
Johnston Alternator and Trailer Sales, Inc. v.
Farm Management Commission 38
Jones, Charles W. v. Board of Regents 6
Jones, Chester v. Department of Highways 221
Kanawha County Commisison v. Department of
Highways 397
Kanawha Valley Regional Transportation Authority v.
Department of Highways 60
Kay, Henry A. and Charles E. Kay v. Department of
Natural Resources 270
Keefer?s Service Center v. Farm Management
Commission 37
Keiffer, Teddy v. Department of Highways 319
Keller Industries, Inc. v. Department of Highways 417
Keller, Douglas Edward and Patty Keller v. Adjutant
General and Department of Highways 22
Keyser, Margo A. v. Department of Highways 27
Kimble, Thomas G. v. Department of Public Safety 23
Kinder, Tommy v. Department of Highways 311
King, L. P., Jr. and Evelyn King v. Department
of Highways 79
Kinney, Charles L. and Joyce I. Kinney, d/b/a The
Southwood Carryout v. Department of Highways 177
TABLE OF CASES
REPORTED LXXXIII
Kisor, David H., Admin. of the Estate
of Julia Kisor, Dec.
v. Department of Highways 506
Knight, William P. v. Office of the State Treasurer 106
Knotts, Eugene A. v. Department of Highways 108
Krantz, Barbara B. v. Department of Highways 116
Krippene, Ruth A. v. Department of Highways 348
Kubski, Lester A. v. Department of Health 289
L. Robert Kimball & Associates v. State Tax Department - 7
Larese, Sandra W. Phillips v. Department of Highways 164
Latta, Robert Howard v. Department of Highways 289
Lawson Products, Inc. v. Farm Management Commission - 38
Layton, Thomas E., II v. Department of Highways 401
Leslie, Doris v. Department of Highways 349
Lewis & Burge, Inc. v Farm Management Commission 37
Lewis, L. R. and B. L. Lewis v. Department of Finance &
Administration and Department of Welfare 336
Lewis, Norman v. Department of Highways 507
Lewis, Virginia v. Department of Highways 8
Liberty Mutual Ins. Company, Subrogee of Edward E.
Dilling and Jennifer Dilling v. Department of
Highways 171
Liggett?s Supply v. Farm Management Commission 37
Lindroth, Richard J. v. Workmen?s Compensation Fund 60
Linville, Lucille v. Department of Highways 408
Lois McElwee Memorial Clinic v. Department of
Corrections 320
Lowe, Ernest E. v. Department of Education 56
Lucas Tire, Inc. v. Department of Highways 397
Lucas, Willard v. Department of Highways 438
Lundia, Myers Industries, Inc. v. Board of Regents 92
Lyons, Bernard C. and Helen V. Lyons v.
Department of Highways 358
Malcomb, Pauline G. v. Alcohol Beverage
Control Commissioner 155
Marcum, Robert and Loretta Marcum v. Department
of Highways 461
Marino, Nat v. Office of the Supreme Court of Appeals -- - 404
Marlinton Electric Co., Inc. v. Department of
Corrections 41
/5
LXXXIV TABLE OF CASES REPORTED
Marshall County Cooperative, Inc. v. Farm
Management Commission 37
Martha White Foods v. Department of Highways 123
Martin, James C., Jr. and Shirley B. Martin V.
Department of Highways 364
Mason County D.H.I.A., Inc. v. Farm
Management Commission 39
Master, Donald C. v. Department of Highways 24
Matthew Bender & Company v. Department of
Corrections (CC.81-398) 93
Matthew Bender & Company, Inc. v. Department
of Corrections (CC-82-255) 276
Matthews, Dayton 0. B. and Alline L. Matthews v.
Department of Highways 124
May, John T. v. Department of Highways 290
Maynard, Raymond L. v. Board of Regents 225
McAnallen Brothers, Inc. v. Board of Regents 240
McCarty, Charles E. v. Office of the Supreme
Court Administrator 130
McCarty, Charles E. v. Office of the State Auditor 32
McClarin, Juanita v. Department of Highways 445
McDonnell Douglas Corporation v. Department
of Education 16
McDonnell, Dores D., Sr. v. Department of Highways 9
McGalla, Andrew S. v. Board of Regents 463
McGeary, Jeffrey 0. v. Human Rights Commission 117
McGhee & Company v. Farm Management Commission - 37
McGinley, William B. v. Board of Regents 271
McGrath, Cynthia Catherine v. Department of
Motor Vehicles 132
McGraw, Ronald G. v. Department of Corrections 464
McIntyre, Thelma E., Admin. of the Estate of Wilma S.
McIntyre, dec. v. Department of Health 209
McKendrick, John v. Department of Highways 125
McLean, William D. v. Department of Corrections 262
McNamee, Thomas E. v. Department of Highways 62
McNeil Pharmaceutical v. Department of Corrections 41
Meade, Lillian Akers, Administratrix of the Estate of
Gary Wayne Akers, deceased v. Department
of Highways 491
TABLE OF CASES
REPORTED LXXXV
Meade, Lillian Akers, as guardian for and on behalf of Christopher Lewis Akers
v. Department of Highways -
-- 491
Meade, Lillian Akers, as guardian for and on behalf of
Steven Wayne Akers v. Department of Highways 491
Melbourne Brothers Construction Company (The)
v. Department of Highways 226
Memorial General Hospital Association v. Department of
Corrections (CC-81-365) 41
Memorial General Hospital Association, Inc. v.
Department of Corrections (CC-82-256) 291
Mercer Radiology, Inc. v. Department of Corrections 40
Michie Company (The) v. Department of Health 157
Michie Company (The) v. Office of the Supreme
Court Administrator 109
Miller, Paul E. and Marguerite Miller v.
Department of Highways 477
Miller?s Implement, Inc. v. Department of Health 470
Mingo, F. M. v. Department of Corrections 276
Minor, Laird and Nancy G. Minor v.
Department of Highways 478
Monongahela Power Company v. Department of
Corrections (CC-82-220) 255
Monongahela Power Company v. Department of
Corrections (CC-81-362) 41
Monongahela Power Company v. Department of
Highways (CC-82-116) 227
Monsanto Company v. Board of Regents 251
Moore Business Forms, Inc. v. Department of
Education (CC-82-298) -
-- - 398
Moore Business Forms, Inc. v. Department of
Public Safety (CC-82-41) 173
Moore, Carl R. v. Governor?s Office of Economic
and Community Development 419
Moore, Charles E. v. Department of Public Institutions 431
Moore, D. Albert v. Department of Highways 410
Moore, Delores v. Department of Highways 179
Moore, Robert L. and Irlant E. Moore v.
Department of Highways --
253
Moran, Robert B. v. Department of Motor Vehicles 479
Morgan, Ellery H. v. Public Employees Insurance
Board and ABC Commissioner 471
/1
LXXXVI TABLE OF CASES REPORTED
Motor Car Supply Company v. Farm
Management
Commission 94
Mountain Mobile Milling v. Farm Management
Commission 37
Mountaineer Motor Sales, Inc. v. Farm
Management Commission 187
Mountaineer Office Supply, a division of F & M
Supply Co., Inc. v. Secretary of State 382
Muck, Earl G. v. Department of Highways -- 180
Mullenax, John, Admin. of the Estate of Edith Mullenax,
Dec. v. Department of Agriculture 328
Mullins, Eugene P. v. Department of Highways 164
Munson, Nelva v. Department of Highways 133
Nasco v. Farm Management Commission 38
Nordeck, Howard R. v. Office of the Supreme Court
of Appeals ?
238
North Central Dairy Herd Improvement Association v.
Farm Management Commission 37
Norwich-Eaton Pharmaceuticals v. Department
of Corrections 41
Nova Rubber Company, Inc. v. Department of
Corrections 41
Novo Corporation v. Department of Highways - 140
Ohio Valley Medical Center v. Department
of Corrections (CC-81-89) 10
Ohio Valley Medical Center, Inc. v. Department of
Corrections (CC-82-276) 312
Orndoff, John v. Department of Highways 254
Orthopedic Clinic, Inc. v. Department of Corrections 41
Osburn, Gary v. Office of the Supreme
Court of Appeals 403
Overnite Transportation Co. v. Farm
Management Commission 38
Pack, James and Ella Mae Pack v. Department of
Highways 337
Page, Kenneth v. Alcohol Beverage Control
Commissioner 487
Parker, Francis L. v. Department of Health 489
Parsons, Herbert O?Dell, III v. Department of Highways 81
Pasceri, Catherine v. Department of Highways 313
TABLE OF CASES
REPORTED LXXXVII
Patrick, Kenneth H., Jr. v. Department
of Highways 446
Paul, David E. and Delores R. Paul v. Department
of Highways 479
Payman, B. v. Department of Corrections (CC-81-262b) -- - 40
Payman, B. v. Department of Corrections (CC-82-205) - 254
Payne, Frank A. v. Department of Highways 330
Pennington, Dale R. and Gloria Mae Pennington
v. Department of Highways 510
Perrmont Chemical Company v. Department
of Corrections 41
Peters Fuel Corp. v. Departments of Corrections 255
Peterson, Mary E. v. Department of Highways 383
Pfizer, Inc. v. Department of Corrections 41
Philpot, Richard T. v. Department of Highways 181
Physicians Associates, Inc. v. Department of Corrections 40
Physicians Fee Office v. Department of
Corrections (CC-81-312a) 40
Physicians Fee Office v. Department of
Corrections (CC-81-312b) 41
Physicians Fee Office v. Department of
Corrections (CC-81-448) 93
Physicians Fee Office v. Department of
Corrections (CC-82-284) 320
Piazza, Michael A. v. Department of Highways - 65
Pickens Hardware Co., Inc. v. Management Commission 37
Picker Corporation v. Department of Corrections -- 40
Pioneer Company (The) and Mountain State Construction
Company, Inc. v. Department of Highways 256
Pioneer Harvestore Systems, Inc. v. Farm
Management Commission 38
Platt, Donald E. and Linda L. Platt v.
Department of Highways 66
Polk, Jimmy v. Department of Highways 67
Porterfield, Donna F. v. Department of Highways 373
Potomac Valley Hospital v. Department of Corrections -- 471
Pozell, Sidney and Lillian Pozell v. Department
of Highways 227
Preston, Angela v. Attorney General?s Office 157
Preston Contractor?s, Inc. v. Department of Highways 465
LXXXVIII TABLE OF
CASES REPORTED
Priestley, Tammy Lynn, an infant who sues by her
mother, Carolyn Priestley, and Carolyn
Priestley v. Department of Highways 82
Princeton Community Hospital v. Department
of Corrections 40
Princeton Internists v. Department of Corrections 40
Pritt, Gary L. and Jeanette Pritt v. Department
of Highways 447
Professional Laboratory & X-Ray v. Department
of Corrections 255
Rainbow Development Corporation v. Department
of Highways 228
Raleigh General Hospital, Inc. v. Department
of Corrections (CC-81-267) 40
Raleigh General Hospital, Inc. v. Department
of Corrections (CC-81-307) 41
Raleigh Orthopaedic Assoc., Inc. v. Department of
Corrections (CC-81-296a) 40
Raleigh Orthopaedic Assoc., Inc. v. Department
of Corrections (CC-81-296b) - 41
Ramas, Mario C. v. Department of Corrections 320
Ramey, Glen L. v. Department of Highways 439
Randolph, Doris, Frank Randolph, her husband, and
Yvonette (Suzie) Randolph, infant v. Department
of Highways 230
Rasmussen, D. L. v. Department of Corrections 262
Redd, Frank E. v. Department of Highways 231
Reed & Carnick v. Department of Corrections 41
Region V ?
Regional Education Service Agency v.
Department of Employment Security 110
Reynolds Memorial Hospital, Inc. v. Department
of Corrections (CC-81-198) 40
Reynolds Memorial Hospital, Inc. v. Department
of Corrections (CC-81-212) 40
Reynolds Memorial Hospital, Inc. v. Department
of Corrections (CC-81-265) 40
Reynolds Memorial Hospital, Inc. v. Department
of Corrections (CC-82-212a) 321
TABLE OF CASES
REPORTED LXXXIX
Reynolds Memorial Hospital, Inc. v.
Department
of Corrections (CC-82-212b) 321
Reynolds Memorial Hospital, Inc. v. Department
of Corrections (CC-82-28) 273
Richmond, Roger and Sandra Richmond v.
Department of Highways 449
Riner, Robert G. v. Department of Highways 432
Roberts, Keith Ray v. Department of Highways 25
Rowley, Randall E. v. Department of Highways 183
Ruckman, Stanley T. v. Department of Highways 232
Russell, Eldean v. Department of Highways 165
Ryder Truck Rental, Inc. v. Department of Highways 417
S. S. Logan Packing Company v. Board of Regents 472
Sadler, James Scott v. Department of Highways 16
Sargent, Calvin L. v. Department of Highways 433
Sargent, Richard L. v. Department of Highways 315
Savage Construction Company, Inc. v. Department
of Highways ?
274
Schumacher, Robert C. v. Department of Highways 315
Scott, Ethea M. v. Department of Highways 292
Scott Saw Sales & Service
v. Farm Management Commission 218
Scruggs, Martha C. v. Department of Highways 411
Selected Risks Insurance Company, as Subrogee of
Shell C. Brady v. Department of Highways 33
Sellards, Harry R. and Francis A. Sellards v.
Department of Highways 188
Sellaro, Eugene J., Jr. v. Office of the State Auditor 85
Seneca Mental Health Mental Retardation Council,
Inc. v. Department of Corrections 85
Serge, Daniel, Jr. v. Department of Highways 68
Shaffer, Charles R. v. Department of Highways 28
Shane Meat Company v. Board of Regents 233
Sharma, Chandra P. v. Department of Corrections 118
Shawver, Roy G. v. Department of Highways 384
Shelly & Sands, Inc. v. Department of Highways 473
Shiflet, Clarence and Florence Shiflet v. Department
of Highways 339
XC TABLE OF CASES
REPORTED
Shinaberry, Sterl F. v. Office of the State Auditor 94
Shoemaker, Harry W. and Winifred G. Shoemaker
v. Department of Highways 510
Shrader, Ruby E. v. Department of Highways 364
Silk, Adnan N. ?
Beckley Neurosurgical Clinic v.
Department of Corrections 40
Simmons, Charles H., d/b/a Simmons? Hauling v.
Department of Corrections 276
Singh, Rajendra P. v. Department of Corrections 40
SK&F Co. v. Department of Corrections 41
SK&F Lab Co. v. Department of Corrections 41
Skeen, Terry v. Board of Regents 412
Skyland Hospital Supply v. Farm Management
Commission 37
Smith, Alfred W. v. Department of Highways 374
Smith, C. 0., Jr. v. Department of Highways 385
Smith, Oscar D. v. Department of Highways 11
Southern Chemical Co. v. Adjutant General 29
Southern Chemical Co. v. Department of
Corrections (CC-81-194) 40
Southern Chemical Co. v. Department of
Corrections (CC-81-244) 40
Southern Gas and Oil, Inc. v. State Fire Marshal 127
Southern States Cooperative v. Farm Management
Commission 94
Southern States Elkins Coop., Inc. v. Farm
Management Commission 38
Southern States Marlinton, Coop. v. Farm
Management Commission 37
Spatafore, Margaret and Joseph Robert Spatafore v.
Department of Highways 18
Spotloe, Richard A. v. Administrative Office of the
Supreme Court?s of Appeals 69
St. Paul?s Protestant Episcopal Church v.
Department of Highways 361
Stark Electric, Inc. v. Department of Highways 277
State Distributing Company v. Nonintoxicating
Beer Commission ?
110
TABLE OF CASES
REPORTED XC!
State Farm Mutual Automobile
Insurance Company as Subrogee of Barbara A. Howe v. Department
of Highways 71
Steven Richman, DO, Inc. v. Department of Corrections 276
Stewart, Ronald P. v. Department of Highways 72
Stickler, Sharrell v. Office of the Supreme
Court of Appeals 403
Stone, Bessie M., by Charles H. Stone, her Attorney in
Fact v. Department of Highways 143
Stover, George A. and Carma Stover v. Department
of Highways 420
Stricker, Larry Lee v. Department of Highways 12
Stultz, Charles W. W. and Mary N. Stultz v.
Department of Highways 292
Suder, Eugene C. V. Office of the Supreme
Court of Appeals 403
Sullivan, Larry N. v. Office of the State Auditor 119
Summers Community Clinic v. Department of Corrections 40
Summers Community Clinic Pharmacy v.
Department of Corrections 256
Summers County Hospital v. Department of
Corrections (CC-81-263) 40
Summers County Hospital v. Department of
Corrections (CC-82-202) 256
Superior Parts Service, Inc. v. Farm Management
Commission 94
Surface, Janet T. v. Department of Health 375
Surface, Janet T. v. Workmen?s Compensation Fund 294
Sutphin, Billy v. Department of Highways 415
Sutton, Velma v. Department of Highways 323
Swain Window Cleaning Services v. Department
of Finance and Administration 385
Swisher?s Feed and Supply v. Farm Management
Commission 37
T. H. Mirza, M.D., Inc. v. Department of Corrections 93
Tarr, Norma v. Office of the Supreme Court of Appeals 404
Taylor County Commisison v. Department of Corrections -- 93
Taylor, Jack L. v. Department of Highways 386
Terra Aqua Construction v. Department of Highways 295
XCII TABLE OF
CASES REPORTED
Terry, James D. v. Office of the
State Auditor 234
Thomas, Bertie Gibbs and Carolyn
Thomas v.
Department of Highways 316
Tittle, Audrey P., Admin. of the Estate of Steven B.
Parcell v. Department of Highways 146
Titus, Gerald M., Jr. v. Office of the State Auditor 32
Tomblyn, John F. v. Department of Highways 111
Tomlinson, John R. ?
Fairlea Animal Hospital
v. Farm Management Commission 38
Toth, Alex v. Department of Highways 480
Town & Country Veterinary Clinic v.
Farm Management Commission 38
Treadway, Thomas R. v. Department of Highways 296
Tn-City Welding Supply Company v. Department
of Highways 258
Tn-State Ambulance and Rentals v. Department
of Corrections 40
Truman, William M. v. Office of Emergency Services 235
Tygarts Valley D.H.I.A. v. Farm Management Commission 38
Tygarts Valley Canitation, Inc. v. Farm
Management Commission 37
Udell, Donald F. v. Board of Regents 450
Underwood, Paul J. and Betty 0. v.
Department of Highways 242
Union Oil Company of California v. Department
of Corrections (CC-81-340) 41
Union Oil Company of California v. Department
of Corrections (CC-81-405) 85
Union Oil Company of California v. Department
of Corrections (CC-81-407) 84
Union Oil Company of California v. Farm
Management Commission (CC-81-252) 37
Union Oil Company of California v. Farm
Management Commission (CC-81-195) 37
United Farm Bureau Mutual Insurance Company v.
Department of Public Safety 422
United States Fidelity & Guaranty Company, Subrogee of H & A Coal &
Hauling, Inc. v. Department of Highways 26
TABLE OF CASES
REPORTED XCIII
Updyke, Carole E. and Lionel Joe
Updyke v.
Department of Highways 481
Upjohn Company (The) v. Department of Corrections 41
Utah Valley Hospital v. Department of Corrections 324
Utt, David E. v. Department of Highways 236
VandeLinde, D. M. v. Office of the Supreme
Court of Appeals 403
Varney, Robert v. Department of Highways 434
Vecellio & Grogan, Inc. v. Department of
Highways (CC-81-425) 467
Vecellio & Grogan, Inc. v. Department of
Highways (CC-82-92) 467
Vecellio & Grogan, Inc., for Peraldo Construction
Company v. Department of Highways 451
Velasquez, Aifredo C. v. Department of Corrections 276
Virginia Harvestore, Inc. v. Farm Management
Commission 37
Walker, Edwin 0. v. Department of Health -- 472
Walter J. Klein Company, Ltd. v. Board of Regents 29
Wandling, G. W. v. Farm Management Commission 38
Ward Auto Parts Co. v. Farm Management
Commission 38
Ward, Charles S., guardian of Charles F. Ward
v. Department of Corrections 368
Ward, Ranson Bailey and Debra Dawn Ward v.
Department of Highways 74
Warner, Lester v. Office of the Supreme Court of Appeals 403
Wayne Concrete Co. v. Department of Highways 259
Wechsler Coffee Corporation v. Department
of Corrections 41
Welding, Inc. v. Department of Corrections 150
Weslakin Corporation v. Department of Corrections 296
West, John J. v. Department of Highways 129
West Virginia Artificial Breeders Cooperative, Inc.
v. Farm Management Commission - 39
West Virginia Automobile & Truck Dealers
Association v. Department of Motor Vehicles 13
West Virginia Paper, Inc. v. Department of Corrections -- 41
XCIV TABLE OF
CASES REPORTED
West Virginia School of Osteopathic
Medicine v.
Department of Corrections 93
West Virginia School of Osteopathic Medicine Clinic,
Inc. v. Department of Corrections (CC-81-464) 93
West Virginia School of Osteopathic Medicine Clinic,
Inc. v. Department of Corrections (CC-82-306) 349
West Virginia Turnpike Commission v.
Farm Management Commission 38
West Virginia University Hospital v.
Department of Corrections 116
West Virginia University Outpatient Pharmacy v.
Department of Corrections 260
Westinghouse Electric Supply Company v.
Department of Corrections 297
Weston Veterinary Clinic v. Farm
Management Commission 38
Whalen, Michael E. and Ann Whalen v.
Department of Health 509
Wheeler, Drema Faye v. Department of Highways 184
Wheeling Multi Service Center, Inc. v. Division
of Vocational Rehabilitation -- - -- 112
White, Alva Katherine v. Department of Highways - - 212
White, Paul and Wanda White v. Department
of Highways 212
White Sulphur Pharmacy, Inc. v. Department
of Corrections 85
Whitman Exterminating Company v. Farm
Management Commission 38
Whitt, Cecil, Sr. v. Department of Highways 30
Wiggins, Wayne F. v. Department of Highways - - 386
Wilcox, Renna J. v. Department of Highways 166
Wiley, Harold E. v. Department of Motor Vehicles 298
Williams, A. B. v. Department of Highways 482
Williams, Roy Franklin, Jr., and Beverly Williams
v. Department of Highways ----
485
Willis, Bob E. and Ragene Willis v. Department
of Highways 317
Wilson Welding Supply Company v. Railroad
Maintenance Authority 298
TABLE OF CASES
REPORTED XCV
Winchester Equipment Co. v. Farm
Management
Commission 37
Wood, Clyde v. Department of Highways 243
Woody, James and Lottie L. Woody v.
Department of Highways 510
Workman, Gary L. and Brenda Workman v.
Department of Highways 452
Workman, Wetzel K. v. Office of the Supreme Court
of Appeals 403
Xerox Corporation v. Department of Corrections - - 84 Xerox Corporation v. Department of Natural Resources 435
Yoak, Martha P., by her agent, Judson K. Yoak v.
Department of Highways 436
Young, Andrew S. v. Department of Highways 359
Young?s Inc. v. Farm Management Commission 37
Zummach-Peerless Chemical Coatings Corporation v.
Department of Natural Resources 31
Cases
Submitted and Determined
in the Court of Claims in the
State of West Virginia
Opinion issued August 6, 1981
DORIS JANE BOWEN
WANDA SUE HANLEY
LARRY JENKINS
LANA JEAN JENKINS
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-342)
Omega Perdue appeared in person.
Douglas Hamilton, Attorney at Law, for respondent.
WALLACE, JUDGE:
Omega Perdue, formerly Omega Jenkins, filed this claim against the respondent
for damages to her tobacco crop and loss of topsoil and fertilizer caused by
the flooding of her tobacco field.
She testified that she and her four children owned an eighty- four acre farm
located on the waters of Jenkins Creek near Milton, West Virginia. She was
asked by the Court to furnish the deed to the farm so that the Court could
determine the proper ownership and claimants in this matter. This she failed to
do. The Court made its own investigation, and found that Omega Perdue and her
former husband, Willie Jenkins, conveyed the farm in 1959 to their four children,
Doris Jane Jenkins, now Bowen; Wanda Sue Jenkins, now Hanley; Larry Jenkins,
and Lana Jean Jenkins. Accordingly, Omega Jenkins owns no interest in the
property, and the
[1J
2 REPORTS STATE
COURT OF CLAIMS [W. VA.
Court, on its own motion, amended the notice of claim to dismiss Omega Perdue
as a claimant and to substitute the four children as claimants.
Jenkins Creek flows past a tobacco field located on the farm, then turns at
right angles through two six-foot culverts under Local Service Road #9, also
known as Dudley Gap Road. A second creek flows easterly under the road through
a five-foot culvert located in the immediate area of the six-foot culverts,
On August 4, 1980, there occurred a heavy rainstorm overflowing the banks of
Jenkins Creek and flooding a portion of the tobacco field. None of the
claimants live on the farm and none were present during the storm. Omega Perdue
contends that the culverts were clogged with debris, causing the creek to back
up and flood the field. She testified that the culverts had been blocked on
previous occasions, and she had made complaints to the respondent.
Lonnie Clagg, an employee of the respondent, testified that he had occasion to
pass through the area of claimants? farm immediately after the storm; that Jenkins
Creek and Trace Creek had flooded above and below the culverts; that the water
was over Local Service Road #, and that he
had to proceed through the water.
Donald Turner, respondent?s Maintenance Supervisor for Cabell County, testified
that he had no knowledge or record of complaints made by Omega Perdue other
than a call received after the August 4, 1980 storm advising of the damage to
the tobacco crop.
The evidence in the record does not establish that the culverts were actually
clogged at the time of the August 4, 1980 storm. None of the claimants were
present during the storm, and there was not actual proof that the culverts
were, in fact, stopped up at the time of the storm. On the contrary, the
testimony of Lonnie Clagg established that the storm was of such magnitude that
the run-off went over the culverts and the road, flooding the entire area above
and below the cul
W. VA.]
REPORTS STATE COURT OF CLAIMS 3
verts. No negligence on the part of
the respondent was proved. Accordingly, the Court must deny the claim.
Claim disallowed.
Opinion issued August 6, 1981
DEPARTMENT OF FINANCE AND ADMINISTRATION
vs.
DEPARTMENT OF CORRECTIONS
(CC?81?117)
No appearance by claimant.
Joseph C. Cometti, Assistant Attorney General, for respondent.
PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $13,702.00 on unpaid invoices for supplies furnished to
the West Virginia Penitentiary. Respondent admits the validity of the claim,
but also states that there were no funds remaining in the respondent?s
appropriation for the fiscal year in question from which the obligation could
have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are also of the opinion that an award cannot be made, based on our
decision in Airkem Sales and Service, et al. v. Department of Mental Health,
8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued August 6, 1981
NELLIE EVANS
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-339)
Claimant appeared in person.
W. Douglas Hamilton, Attorney at Law, for respondent. WALLACE, JUDGE:
Sometime in mid-July of 1980, claimant Nellie Evans was
4 REPORTS
STATE COURT OF CLAIMS [W. VA.
operating her 1976 Cadillac Coupe
DeVille on W. Va. Route 10 north from Logan to Mitchell Heights when traffic
was stopped for 1? hours. During that time, the claimant ran her car?s engine
at certain intervals to operate the air conditioner because of the intense
heat. Finally, the vehicle overheated, and the antifreeze boiled out. Claimant
incurred an expense of $16.44 for the replacement of the radiator and
thermostat.
The following month, along the same stretch of highway, the claimant was again
stopped in traffic, that time, for 2? hours. Ms. Evans testified that a flagman
was present on both occasions, and that the temperature was 100? or more. The
car once again overheated, resulting in a transmission repair bill of $400.67.
Claimant seeks to recover a total of $462.11 for damage to her vehicle
allegedly resulting from respondent?s traffic control on West Virginia Route
10.
Testifying on behalf of the respondent was Ludrus Gore, a blacktop inspector
who was on the Route 10 project in Logan County during the months involved
here. Mr. Gore stated that an independent contractor, State Construction, was
laying the blacktop on that particular project, and that the flag- men posted
in the area were employed by State Construction The only employees of the Department
of Highways at the site were Mr. Gore and another inspector.
It is clear from the record in this case that negligence on the part of the
respondent has not been established. State Construction was an independent
contractor, and this Court has held that ?the respondent may not be held
accountable for the contractor?s negligent acts.? Safeco Insurance Company v. Department of Highways, 9 Ct.Cl. 28 (1971). In another decision by this Court,
involving a flagman employed by an independent contractor, the Court found that
the respondent could not be held liable for the negligence, if any, of the
flagman. R. H. Bowman Distributing Co., Inc. v.
Department of Highways, 12 Ct.Cl. 156
(1978). Accordingly, this claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 5
Opinion issued August 6, 1981
GENERAL COMMUNICATIONS COMPANY
vs.
BOARD OF REGENTS
(CC-81-80)
No appearance by claimant.
Ann V. Dornblazer, Assistant Attorney General, for respondent.
PER CURIAM:
Claimant seeks payment of the sum of $400.00 for radio equipment lost by the
West Virginia Network for Educational Telecomputing (WVNET).
As the respondent?s Answer admits the validity and amount of the claim, and
sufficient funds remained in the respondent?s appropriation for the fiscal year
in question from which the obligation could have been paid, the Court makes an
award of $400.00 to the claimant.
Award of $400.00.
Opinion issued August 6, 1981
JOHN A. HANNIGAN AND
CAROLYN ANN HANNIGAN
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-86)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respcrndent.
WALLACE, JUDGE:
Claimant filed this claim against the respondent for damage sustained by his
automobile after striking a pothole as he approached the Montgomery Bridge in
Montgomery, West Virginia.
On Friday, February 20, 1981, at approximately 6:15 p.m., the claimant was
driving his 1977 Ford Granada westerly on U.S. Route 60 at approximately 20 to
25 miles per hour. It
REPORTS STATE
COURT OF CLAIMS [W. VA.
was raining. He turned off U.S. Route
60 onto the approach to the bridge over the river to Montgomery, and his
automobile struck a large pothole in the pavement, bursting a tire and damaging
a rim and hubcap.
The claimant testified that he travelled this bridge three to four times a
week; that he knew the hole was there; that the hole had been patched by the
respondent on prior occasions; and that he had made no complaints to the
respondent. Claimant?s insurance company paid for the rim and the hubcap. His
remaining damage is for a tire, alignment, and balancing in the amount of
$129.39.
In the course of the hearing, it developed that the automobile was titled in
the name of the claimant and his wife, Carolyn Ann Hannigan. The Court, on its
own motion, amended the claim to include Carolyn Ann Hannigan as an additional
claimant.
The State neither insures nor guarantees the safety of motorists travelling on
its highways. Adkins vs. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). For the respondent
to be held liable for damages caused by road defects of this type, the claimant
must prove that the respondent had actual or constructive knowledge of the
existence of the defect and a reasonable amount of time to take suitable
corrective action. Davis vs.
Department of Highways, 11 Ct.Cl. 150
(1977). Since the claimant did not meet that burden of proof, this claim must
be denied.
Claim disallowed.
Opinion issued August 6, 1981
CHARLES W. JONES
vs.
BOARD OF REGENTS
(CC-81-35)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Claimant filed this claim against the respondent in the amount of $289.50 for
items damaged and destroyed as the
W. VA.]
REPORTS STATE COURT OF CLAIMS 7
result of the falling of a shelf in
claimant?s apartment. The amount of the claim was amended at the hearing to
$213.75.
The claimant and his wife had just completed moving into an apartment in the
University Heights Housing Complex owned and maintained by Marshall University
in Huntington, West Virginia. Certain household items were placed on a shelf in
the bedroom closet. On June 23, 1980, for no apparent reason, the shelf fell,
and certain items listed in Claimant?s Exhibit No. 1 were damaged beyond
repair. The claimant notified the maintenance personnel and the housing office,
and was informed that this was not an isolated incident and that it had
happened in other apartments in the complex. The claimant had not been advised
of this when he moved into the apartment.
The Court finds that the respondent was negligent in failing to remedy the
shelf defect, and therefore makes an award to the claimant in the amount of
$213.75.
Award of $213.75.
Opinion issued August 6, 1981
L. ROBERT KIMBALL & ASSOCIATES
vs.
TAX DEPARTMENT
(CC-81-70)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $2,824.42 for damages caused by respondent?s breach of a
contract with the claimant.
Respondent, having admitted the validity of the claim, states that there were
sufficient funds available in its appropriation for the fiscal year in question
from which the obligation could have been paid.
Based on the foregoing, the Court makes an award to the claimant in the amount
of $2,824.42.
Award of $2,824.42.
8 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued August 6, 1981
VIRGINIA LEWIS
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-421)
Claimant appeared in person.
W. Douglas Hamilton, Attorney at Law, for respondent. WALLACE, JUDGE:
Claimant seeks payment of the sum of $176.90 for damages sustained by her
automobile as the result of striking a pothole.
The claimant, a resident of South Charleston, West Virginia, is the owner of a
1976 Chevrolet Nova. On the morning of December 20, 1980, she was traveling on
Campbell?s Creek Road, a two-lane, State-maintained highway, when she struck a
hole in her lane of traffic approximately six inches from the berm. Two tires
were damaged. The claimant testified that she had traveled the road two weeks
before the accident, and knew that there were several holes in the highway
because coal trucks frequently traveled the area.
The State is neither an insurer nor guarantor of the safety of persons
traveling on its highways. Adkins v.
Sims, 130 W.Va. 645, 46 S.E.2d
81(1947). To be found liable, the respondent must have had either actual or
constructive notice of the particular hazard which caused the damage. Davis v. Dept.
of Highways, 11 Ct.Cl. 150 (1976). In this case, statements by the
claimant that holes in the highway existed two weeks before the accident tend
to show that the respondent had at least constructive notice of the road?s
condition. However, it is the opinion of the Court that the claimant, with her
prior knowledge of the hazardous condition of the highway, was also negligent.
She stated that ?They have to frequently pave and repatch holes in that area?
(Transcript, p. 10).
Following the doctrine of comparative negligence, this Court declares that the
claimant?s negligence was equal to or greater than that of the respondent.
Therefore, the claim must
W. VA.]
REPORTS STATE COURT OF CLAIMS 9
be denied. Hull v. Dept. of Highways, 13 Ct.C1. 408
(1981); Spataf ore v. Dept. of Highways, 14 Ct.Cl. 18 (1981); Bayer v. Dept. of Highways, 13
Ct.Cl. 388 (1981).
Claim disallowed.
Opinion issued August 6, 1981
DORES D. MCDONNELL, SR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-8 1-3 1)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant filed this claim against the respondent in the amount of $131.78 for
damage to his 1980 Toyota Corolla automobile.
On November 17, 1980, claimant was driving his son?s automobile westerly on
Interstate 64. His son was following him in claimant?s automobile. At 10:00
p.m., while crossing Rocky Step Bridge at approximately milepost 41, he noticed
in his rearview mirror his son blinking his lights. He pulled off the highway
and his son stopped behind him and stated that he had a flat tire. They changed
the tire and proceeded
on. The next morning, the claimant examined the tire and discovered that it had
been cut on the inside of the tire and the inside of the rim was bent as though
some metal object had struck it. Claimant testified that he did not know what
caused the damage, but surmised that there may have been a metal plate placed
on the bridge by the respondent during repair work. He further stated that when
he crossed the bridge in front of his son, he saw nothing unusual, nor did he
see anything the next evening when he travelled the same section of the
highway.
The law in West Virginia is well established that the State is not an insurer
of the safety of a traveller on its highways.
10 REPORTS
STATE COURT OF CLAIMS [W. VA.
Adkins vs. Sims, 130 W.Va. 645, 46 S.E.2nd 81 (1947), Parsons vs. State Road Commission, 8 Ct.Cl. 35 (1969). Anyone who sustains damage
must prove that the negligence of the State caused th damage, in order for the
State to be held liable. See Eller vs.
Department of Highways, 13 Ct.Cl. 402
(1980). The record does not establish any negligence on the part of the
respondent; in fact, the claimant testified that he did not know what caused
the damage. In order to reach a conclusion as to what caused the damage to the
claimant?s automobile, the Court would have to resort to speculation or
conjecture, which, of course, is prohibited. See Miller vs. Departient of Highways, 13 Ct.Cl. 414 (1981). Accordingly, the Court disallows
this claim.
Claim disallowed.
Opinion issued August 6, 1981
OHIO VALLEY MEDICAL CENTER
vs.
DEPARTMENT OF CORRECTIONS
(CC-81-89)
No appearance by claimant.
Joseph C. Cometti, Assistant Attorney General, for respondent.
PER CURIAM:
Claimant herein seeks payment of the sum of $125.80 for medical services
furnished to an inmate of the West Virginia Penitentiary. In its Answer, the
respondent admits the validity of the claim, but also states that there were no
funds remaining in the respondent?s appropriation for the fiscal year in
question from which the obligation could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are also of the opinion that an award cannot be made, based on our
decision in Airkem Sales and Service,
et al. v. Department of Mental Health, 8
Ct.Cl. 180 (1971).
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 11
Opinion issued August 6, 1981
OSCAR D. SMITH
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-5)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant filed this claim in the amount of $109.32 against the respondent for
damage sustained by his automobile. In the early part of June, 1981, claimant
was driving his 1980 Eagle automobile on West Virginia Route 10, a highway
maintained by the respondent. At approximately 12:30 p.m., near Baileysville,
West Virginia, claimant struck a pothole in the highway which was located about
two feet from the edge of the road. It had been snowing and the hole was full
of water. A tire and rim on the passenger side of the vehicle were damaged.
Claimant testified that he had not driven this road for approximately one year,
and the hole was not there at that time. He further stated that he did not know
how long the hole had been there, nor did he know if the respondent had been
notified of its existence.
The simple existence of a pothole in the road does not make the State negligent
per se. For the State to be found negligent, it must have had actual or
constructive notice of the particular road defect which allegedly caused the
accident, and must have unreasonably allowed that defect to continue to exist. Davis
v. Dept. of Highways, 12 Ct.Cl. 31 (1977). The record in this case contains
no evidence of any notice to the respondent or failure to act on respondent?s
part. Thus, the respondent cannot be found negligent. Recognizing that the
State is neither an insurer nor a guarantor of the safety of persons travelling
on its highways (Adkins vs. Sims, 130 W.Va. 645 [1947]), and that, no award can be made
without proof of negligence, the Court must disallow this claim. See Hanson vs. Dept. of Highways, 12 Ct.Cl. 198 (1978).
Claim disallowed.
12 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued August 6, 1981
LARRY LEE STRICKER
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-50)
Claimant appeared in person.
Douglas Hamilton, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant filed this claim against the respondent for damage to his automobile
as the result of striking a hole in the road.
In the latter part of January, 1981, the claimant was driving his 1980 Datsun
210 automobile easterly on Hunter Road, in Kanawha County, West Virginia.
Hunter Road is a one-lane, blacktop road maintained by the respondent. It was
approximately 9:00 p.m., and the claimant was proceeding at four to five miles
per hour with his lights on low beam. It was raining and there were patches of
fog. The claimant?s automobile struck a hole in the pavement, and a piece of
the pavement hit the side of the vehicle, damaging the door, quarter panel, and
running board. Two estimates of repair, Claimant?s Exhibits 3 and 4, show
amounts of $155.60 and $179.22, respectively. The claimant testified that he
was familiar with the road but had not traveled it for about a month, at which
time ?it was normal.? He further stated that he did not see the hole until a
moment before he struck it and that there were no other bad holes in the
roadway.
Every user of the highways travels thereon at his own risk. The State does not,
and cannot, assure him a safe journey. Adkins
v. Sims, 130 W.Va. 645, 46 S.E.2nd 81
(1947). For the respondent to be held liable for damages caused by road defects
of this type, the claimant must prove that the respondent had actual or
constructive knowledge of the existence of the defect and a reasonable amount
of time to take suitable corrective action. Davis vs. Dept. of Highways, 11
Ct.Cl. 150 (1976). Since the claimant did not meet that burden of proof this
claim is disallowed.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 13
Opinion Issued August 6, 1981
WEST VIRGINIA AUTOMOBILE AND
TRUCK DEALERS ASSOCIATION
vs.
DEPARTMENT OF MOTOR VEHICLES
(CC-81-24)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $1,174.37 for processing and postage costs incurred as
the result of respondent?s erroneous reporting of registered vehicles in West
Virginia.
As the respondent admits the validity and amount of the claim, and sufficient
funds remained in its appropriation for the fiscal year in question from which
the obligation could have been paid, the Court makes an award of $1,174.37 to
the claimant.
Award of $1,174.37.
Opinion issued August 7, 1981
ROBERT N. JARBOE, PATRICIA ANN
JARBOE, AND ROBERT N. JARBOE AS NEXT FRIEND
OF STEPHANIE JARBOE, AN INFANT
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-297)
Henry Haslebacher, Attorney at Law, for the claimants. Nancy J. Aliff, Attorney at Law, for the respondent.
RULEY, JUDGE:
On Saturday, February 17, 1979, at approximately 5:00 p.m., Robert Jarboe, his
wife Patricia, and their daughter Stephanie, the claimants, were travelling
south on a section of U.S. Route 119 near Hernshaw, in Kanawha County, in a
1978 model Ford pickup truck owned by Robert and being driven by Patricia.
14 REPORTS
STATE COURT OF CLAIMS [W. VA.
They were returning to their home in
Peytona from a shopping trip in Charleston when they encountered a large sheet
of ice covering the entire pavement. The truck was equipped with snow tires and
carried cement blocks in its bed for additional traction. Although Mrs. Jaboe,
the driver, saw the ice and slowed to a speed of 30 mph, she still lost control
of the truck and slid off the pavement, striking a parked car and a house. Mrs.
Jarboe sustained a concussion, temporary impairment of vision, and a broken
wisdom tooth in the accident. She suffered from dizziness for four months
thereafter and incurred medical expenses in the sum of $837.57. Mr. Jarboe was
uninjured, but his truck was a total loss, its fair market value being
$4,500.00. Stephanie?s injuries required only an emergency-room examination,
which amounted to an expense of $76.00.
For the Court to conclude that the accident was caused by the negligence of the
respondent, it must be shown that the respondent had actual or constructive
knowledge of the obviously dangerous condition of the highway and failed to
take suitable action to remedy it or warn motorists of it. Mr. Jarboe testified
that the same spot iced over every winter due to the fact that there was no
ditch line on the upper side of the road. Water ran off the neighboring hillside,
across the road, and into a creek. He also stated that he had telephoned a
complaint about that spot to the respondent during the preceding winter and
that there were rio signs posted to warn motorists of the potentially hazardous
condition.
Deborah Hanning, who resides in a trailer near the accident site, testified
that she had telephoned the respondent on the morning of the 17th and informed
it of the presence of ice on the road. In addition, she stated that she had
complained to the respondent by telephone about the same hazard many times
prior to the 17th, and that there had been eight or nine accidents at that
place prior to that date.
In its defense, the respondent claimed that the road had been treated with salt
and cinders the preceding night, and the temperature had dropped sharply from
36? F to 9? F in the 24 hours preceding the accident.
W. VA.]
REPORTS STATE COURT OF CLAIMS 15
It appears that the respondent did
have actual knowledge of the dangerous condition of the highway both before and
on the day of this accident, but failed to take suitable action to remedy it or
to warn motorists of it. Mrs. Jarboe, however, also knew of the propensity of
ice to freeze upon the highway at the place of the accident, and should have
exercised greater care when approaching and traversing it. The Court finds that
the negligence of the respondent was a proximate cause of the accident and the
claimants? resulting injuries and damages, but the negligence of Patricia
Jarboe contributed, to the extent of 20 per cent, to cause the accident. In 7A
Am. Jur.2d ?Automobiles and Highway
Traffic?, ?753, it is stated:
?In most cases it has been held that the presence of the owner in his motor
vehicle while it is being driven by a member of his family creates a rebuttable
presumption or inference that he has or retains control over its operation, by
virtue of which the negligence of the driver is imputable to him in an action
against a third person. The fact that the owner refrains from directing the
operation of the vehicle does not change his right of control, nor prevent the
driver?s negligence from being imputed to him.* * *
In view of that authority, and in view of
the circumstance that it appears that Mr. and Mrs. Jarboe were engaged in a
joint enterprise at the time and place of the accident, the contributory
negligence of Patricia should be imputed to Robert. Of course, it car not be
imputed to Stephanie inasmuch as she was a child of tender age at the time of
the accident. See 13B M.J. ?Negligence?,
?44.
In view of the relatively minor nature
of their injuries, the Court concludes that Patricia Jarboe should receive an
award of $1,300.00, diminished by 20 per cent attributable to contributory
negligence, and that Stephanie should receive an award of $50.00. The award to
Robert Jarboe will be $4,500.00, diminished by 20 per cent attributable to
contributory negligence, plus $76.00 for medical expense incurred as a result
of Stephanie?s injuries.
Award of $1,040.00 to Patricia Ann Jarboe.
16 REPORTS
STATE COURT OF CLAIMS [W. VA.
Award of $3,676.00 to Robert N.
Jarboe.
Award of $50.00 to Robert N. Jarboe, as next friend of Stephanie Jarboe.
Opinion issued August 7, 1981
McDONNELL DOUGLAS CORPORATION
vs.
DEPARTMENT OF EDUCATION
(CC-81-124)
C. Stephen Kriegh, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $28,132.00 for coal miner teaching programs purchased by
the respondent. No payment was made by the respondent due to the claimant?s
failure to submit an invoice for the merchandise during the fiscal year in
which it was ordered.
As the respondent?s Answer admits the validity and amount of the claim, and
sufficient funds remained in its appropriation for the fiscal year in question
from which the obligation could have been paid, the Court makes an award of
$28,132.00 to the claimant.
Award of $28,132.00.
Opinion issued August 7, 1981
JAMES SCOTT SADLER
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-422)
Claimant appeared in person.
W. Douglas Hamilton, Attorney at Law, for the respondent.
RULEY, JUDGE:
On October 16, 1980, at about 7:00 a.m., the claimant, James Scott Sadler, was
driving his 1978 Toyota automobile east on
W. VA.]
REPORTS STATE COURT OF CLAIMS 17
Route 25 near Institute in Kanawha
County. The weather was clear and dry. It was not yet daylight, and Mr. Sadler
had his headlights on low beam. His speed was approximately 40 mph.
Eastward toward Institute from Nitro, Route 25 changes from a two-lane to a
four-lane highway at a point just before it intersects Goff Mountain Road. A
concrete median approximately six inches high and twenty inches wide separates
the two eastbound and two westbound traffic lanes. As the claimant entered the
four-lane divided highway, he collided with the median, causing damages to his
car of $744.30. He claimed that negligence on the part of the respondent was
the cause of this accident, citing the following facts:
a) the section of two-lane highway leading into the four- lane, plus part of
the four-lane itself, had recently been repaved, and no dividing lines had been
painted on the new pavement;
b) there were no signs or other devices to warn motorists of the elevated
median;
c) the median itself was not painted and had no reflecting devices on it;
d) an eastbound vehicle maintaining a straight course from the two-lane section
would collide with the elevated median.
The respondent asserted that the claimant?s own negligence was the proximate
cause of the accident, and there does seem to be some justification for this
argument. Mr. Sadler testified that he had travelled that portion of the road
before, although not recently. He also stated that, when the accident happened,
traffic was proceeding in both directions on the road, and he had observed cars
ahead of him bear to the right upon entering the four-lane section. However, he
had maintained his position because he had intended to turn left at the
intersection of Goff Mountain Road.
In view of all of the evidence, the Court is constrained to conclude that the
respondent was guilty of negligence which
18 REPORTS STATE
COURT OF CLAIMS [W. VA.
was a proximate cause of the accident and the claimant?s resulting damages. In
addition, the claimant himself was guilty of negligence which was a proximate
contributing cause of the accident and his resulting damages; therefore, the
Court allocates the negligence 80% to the respondent and 20% to the claimant.
Accordingly, an award of $595.44 should be, and is hereby, made.
Award of $595.44.
Opinion issued August 7, 1981
MARGARET SPATAFORE AND
JOSEPH ROBERT SPATAFORE
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-185)
Claimant, Margaret Spataf ore, for claimants.
Nancy J. A 11ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Margaret Spatafore filed this claim against the Department of Highways in the
amount of $72.68 for damages to a 1975 Buick automobile. As the record
indicated that the automobile was jointly owned by Margaret Spatafore and
Joseph Robert Spatafore, the Court, on its own motion, amended the style of the
claim to reflect both parties in interest.
The claimants? automobile was damaged when Margaret Spatafore was proceeding
north on Kelly Hill in Clarksburg, West Virginia, at approximately 3:00 p.m. on
March 27, 1980. As she proceeded up the hill, the automobile struck a large
pothole in her lane of travel, damaging the left front tire. It was raining at
the time of the accident. The claimant testified that there were two holes ?. . and to keep from hitting one, you have to hit the
other. .
. .? She was unable to avoid the holes
because of oncoming traffic.
The claimant also testified that, a month before the accidEnt, she had called
the Clarksburg District Office of the Depart-
W. VA.]
REPORTS STATE COURT OF CLAIMS 19
ment of Highways to report the
existence of these two holes. Mrs. Spatafore further stated that she passed the
area of the accident every day and knew of the existence of the pothole in
question.
The State is neither an insurer nor a guarantor of the safety of motorists
travelling upon its highways. Adkins
v. Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947). To be found liable, the respondent must have had either actual or
constructive notice of the particular hazard which caused the damage. Davis v. Dept. of
Highways, 11 Ct.Cl. 150 (1976). From the evidence, it appears
that the respondent was negligent in failing to repair the road after being
notified of the potholes. However, the claimant, with her knowledge of the
road?s condition. was also negligent.
This Court is constrained to follow its prior application of the doctrine of
comparative negligence in the case of Hull
v. Dept. of Highways, 13 Ct.Cl. 408
(1981), in which the claimant?s negligence, as in the case at hand, was equal
to or greater than that of the respondent. The claim must therefore be denied.
Claim disallowed.
Op?nion issued August 24, 1981
CROSBY BEVERAGE CO., INC.
vs.
NONINTOXICATING BEER COMMISSION
(CC-81-1O)
George E. Crosby appeared on behalf of the claimant.
Henry C. Bws, Jr., Deputy Attorney General, for the respondent.
PER CURIAM:
Claimant herein seeks payment of the sum of $688.42 in taxes paid on 1,580
cases of beer rendered unfit as the result of severe storms and flooding.
Subsequent destruction of the
20 REPORTS
STATE COURT OF CLAIMS [W. VA.
beer was supervised by a federal agent
of the Bureau of Alcohol, Tobacco, and Firearms Division of the Un4ted States
Treasury Department.
In its Answer, the respondent admits the validity of the claim and joins the
claimant in requesting that an award be made in favor of the claimant in the
amount requested.
The question of beer tax refunds has been before this Court on several
occasions. Where the State has not been damaged, the Court has held that
retention of the taxes paid would amount to unjust enrichment on the part of
the State. Central Investment
Corporation vs. Nonintoxicating Beer Commission, 10 Ct.Cl. 182 (1975). See also Falls City Industries, Inc., Formerly Falls City
Brewing Co. vs. Nonintoxicating Beer Commission, 13 Ct.Cl. 186 (1980).
Based on the foregoing, the Court makes an award to the claimant in the amount
of $688.42.
Award of $688.42.
Opinion issued August 24, 1981
GENERAL ACCIDENT F/L
ASSURANCE CORP., LTD.,
SUBROGEE OF INNOVATIVE INDUSTRIES
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-386)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damages to claimant?s 1978
International Trans Star tractor-trailer truck, in the amount of $9,054.19,
were caused when the southbound lane of Interstate 79 near Jane Lew, West
Virginia, collapsed as the truck crossed over a portion of the roadway under
which
W. VA.]
REPORTS STATE COURT OF CLAIMS 21
a tunnel existed; and to the effect
that this occurred because of the negligence of the respondent in failing to
properly maintain said highway, proximately causing the damages sustained, the
Court finds the respondent liable, and awards the claimant the amount agreed
upon by the parties.
Award of $9,054.19.
Opinion issued August 24, 1981
CHRISTINE E. HENDERSON AND
RODGERS PAUL HENDERSON
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-234)
David A. Glance, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted for decision based upon a stipulation filed by the
parties which reveals the facts which follow.
On or about September 29, 1976, claimant Christine Henderson was a passenger in
a Jeep owned and operated by claimant Rodgers Paul Henderson. They were
proceeding north on Route 250 in Marion County near Fairmont, West Virginia.
Along this highway, owned and maintained by the respondent, construction work
was being performed by a Department of Highways crew.
In the course of this construction work, respondent?s f1aman acted negligently
in his flagging procedures, causing claimant?s vehicle to be struck by another
vehicle. As a result, claimant Christine Henderson sustained personal injuries,
and claimant Rodgers Paul Henderson suffered the loss of his wife?s services,
society, and companionship, for which they filed this claim against the
Department of Highways in the amount of
$100,000.00.
22 REPORTS
STATE COURT OF CLAIMS [W. VA.
As the accident and resultant injuries
were proximately caused by the respondent?s negligence, the Court finds the
respondent liable, and makes an award to the claimants of $1,305.00, the amount
agreed upon by the parties.
Award of $1,305.00.
Opinion issued August 24, 1981
DOUGLAS EDWARD KELLER
AND PATTY KELLER
vs.
ADJUTANT GENERAL AND
DEPARTMENT OF HIGHWAYS
(CC-78-2 19)
Randy R. Goodrich, Attorney at Law, for the claimants.
Henry C. Bias, Jr., Deputy Attorney General, for the respondents.
RULEY, JUDGE:
Joseph Keller, Jr., aged 22 years, was employed during the severe winter
weather in January, 1978, to plow snow with his bulldozer upon the Wetzel
County Road in Preston County. On January 24, 1978, his brother, Douglas, who
then was aged 17 years, pursuant to his request, followed him with a pickup
truck so that he might have a place to get warm. As the Keller bulldozer met
and passed a bulldozcr being operated by the West Virginia National Guard, the
Keller bulldozer slid off or partly off the roadway and was unable to get back
on it under its own power. There was a conflict in the testimony as to whether
there was any contact between the two bulldozers, but, since no damage to the
Keller bulldozer is claimed, that point is not significant.
In any event, the National Guard bulldozer, manned by an operator and an
assistant, was stopped so that its winch could be used to assist the Keller
bulldozer back upon the roadway. The operator?s assistant got off the vehicle
and moved to its rear to disengage the hook upon the winch cable. At that
W. VA.]
REPORTS STATE COURT OF CLAIMS 23
time, Douglas was nearby. Despite the
fact that the motor was running, Douglas, believing that he heard the operator
tell him to ?Pull it out? (although the operator disputed that testimony),
unfortunately took hold of the cable with his right hand. Douglas testified
that he was aware that winches and winch cables were dangerous but ?assumed it
was safe for the time being?. At that moment, the operator, being unaware of
the danger into which Douglas had placed his hand, ?kicked it in reverse just a
little bit? so that his assistant ?could get enough slack so he could unhook
it?. At virtually the same time, he saw that ?the boy had his hand in the
cable? and ?kicked, it back into forward and he got his hand out?.
Douglas sustained a compound fracture of the distal phalanx of his right middle
finger and soft tissue injuries resulting in 50% disability of his right middle
finger, those injuries being the basis of this claim. While the Court is
sympathetic to the claimants, it cannot conclude that the operator of the
bulldozer should be held to a standard of care which would require him to
anticipate or foresee that a person would place his hand in such a dangerous
position. Accordingly, this claim must be denied.
Claim dissallowed.
Opinion issued August 24, 1981
THOMAS G. KIMBLE
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-80-396)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $230.03 as reimbursement for property taxes he paid on
certain real estate purchased by the respondent. By the terms of the deed, the
Department of
24 REPORTS
STATE COURT OF CLAIMS [W. VA.
Public Safety was responsible for the
payment of the 1978 real property taxes, which were paid by the claimant and
for which he was only partially reimbursed. The $230.03 claimed herein
represents the remainder owed to the claimant.
As the respondent?s Answer acknowledges the validity and amount of the claim,
and sufficient funds were available in the proper fiscal year from which the
obligation could have been paid, the Court makes an award to the claimant in
the amount requested.
Award of $230.03.
Opinion issued August 24, 1981
DONALD C. MASTER
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-131)
Henry W. Morrow, Sr., Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
In this claim, submitted for decision upon a stipulation filed by the parties,
claimant seeks payment of the sum of $1,000.00 for damage to his property on
Bakerton Road in Charles Town, West Virginia.
It was stipulated that Department of Highways crews from Jefferson County
negligently altered the drainage on Bakerton Road, causing mud and debris to be
carried onto claimant?s property. As a result, claimant?s house sustained
structural damage, and new drainpipe had to be installed beneath the driveway.
In addition, bathroom tile was damaged, and a furnace combustion chamber, which
heats the water yearround, was cracked.
Respondent?s negligenee in altering the drainage was the proximate cause of the
damages sustained by the claimant;
W. VA.J
REPORTS STATE COURT OF CLAIMS 25
therefore, the Court makes an award to
the claimant in the amount stipulated.
Award of $1,000.00.
Opinion issued August 24, 1981
KEITH RAY ROBERTS
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-82)
James Young, Jr., Attorney at Law, for the claimant. Nancy J. A 11ff, Attorney at Law, for the respondent.
RULEY, JUDGE:
On December 21, 1978, at about 8:30 p.m., the claimant was driving his 1971
Chevrolet south on U.S. Route 52, the Big Sandy Road, in Wayne County. The
weather was clear and dry. At a point one mile north of Whites Creek Road
(milest 10.90), Mr. Roberts encountered a rock slide and collided with a large
rock approximately five feet in diameter. As a result of this collision, Mr.
Roberts suffered lacerations of the face, groin, and left thigh, plus a broken
left ankle and two broken toes on his left foot. He remained hospitalized for
thirteen days and missed nine weeks of work, and his car irreparably damaged.
The main issue in this case is the location of the large rock t the time of the
collision. Mr. Roberts testified that it was upon the west berm, that it had
been there for at least two months and that he was obliged by a rock slide to
veer off the pavement onto the berm where his car struck the rock. That
evidence was completely rebutted, however, by the testimony of the
investigating State Police officer and by photographs taken shortly after the
accident occurred which clearly demonstrate that the rock was located at about
the middle of the southbound lane at the time the collision occurred, and that
it remained there until it was removed to the berm later
26 REPORTS
STATE COURT OF CLAIMS [W. VA.
that night. It had fallen and rolled
into the southbound lane shortly before the accident happened. The accident
occurred in an area where rock slides were common, and the claimant testified
that he was aware of that fact.
It is well established that the State is neither an insurer nor a guarantor of
the safety of motorists travelling on its highways. Adkins v. Sims, 130 W.Va. 645 (1947); Lowe v.
Department of Highways, 8
Ct.Cl. 210 (1971). Thus, establishing negligence on the part of the respondent
requires proof that respondent failed to conform to a standard of ?reasonable
care and diligence *
* * under all circumstances.? Parsons v. State Road Commission, 8 Ct.Cl. 35 (1969). The evidence in this case fails to
meet that burden of proof, and, accordingly, this claim must be disallowed.
Claim disallowed.
Opinion issued August 24, 1981
UNITED STATES FIDELITY &
GUARANTY COMPANY, SUBROGEE OF
H & A COAL & HAULING, INC.
AND H & A COAL & HAULING, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-8O-58)
No appearance by claimant.
Nancy J. Alff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damages to claimant?s 1978 Mack
truck in the amount of $1,191.35 were caused when the roadway surface of
Interstate 79 near Jane Lew, West Virginia, collapsed as the truck crossed over
an area under which a tunnel existed; and to the effect that this occurred
because of the negligence of the respondent in failing to properly maintain
said highway, proximately causing the
W. VA.]
REPORTS STATE COURT OF CLAIMS 27
damages sustained, the Court finds the
respondent liable, and awards the claimant the amount agreed upon by the
parties.
Award of $191.35 to United States Fidelity & Guaranty Company.
Award of $1,000.00 to H & A Coal & Hauling, Inc.
Opinion issued September 29, 1981
MARGO A. KEYSER
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-164)
Claimant appeared in person.
W. Douglas Hamilton, Attorney at Law, for the respondent.
RULEY, JUDGE:
This claim for property damage in the sum of $5,000.00 grows out of a
single-vehicle accident which happened at about 7:30 p.m. on Monday, January
22, 1979, on Little Seven Mile Road near Barboursville, Cabell County, West
Virginia. The claimant, an employee of the Veteran?s Administration, was
travelling alone in her 1973 model Chevrolet automobile on her way from
Washington, D.C., to her home in Huntington. At the time and place of the
accident, it was dark and raining. The claimant was familiar with the road. As
she approached a bridge across the Guyandotte River, she didn?t see the water
which covered the highway, and drove into it a speed that ?couldn?t have been
more than 25.? She continued to a point where, when her car stalled and she
left it, she was in water that was ?hip deep.? The claimant saw no warning
signs as she approached the hazard caused by the water, but testified that the
highway at the place of the accident was subject to recurrent flooding. She
also testified that she could see as far as the illumination extended by the
automobile headlights, which were on low beam.
Records maintained by the respondent, which were admitted into evidence,
reflected that the Little Seven Mile Road had
28 REPORTS
STATE COURT OF CLAIMS [W. VA.
been closed at 4:30 p.m. on January
22, 1979, and reopened at 2:40 am. on January 24, 1979. The witness who
identified those records testified that normal procedure incident to such a
road closure would have entailed placement of large warning signs reading ?High
Water? at each end of the roadway closed, but the witness did not personally
know whether or not such signs were erected at the time of the accident.
West Virginia Code ?17C-15-20 (b) requires that motor vehicles be equipped with
head lamps providing ?a lowermost distribution of light, or composite beam, so
aimed and of sufficient intensity to reveal persons and vehicles at a distance
of at least one hundred feet ahead.? Such lighting should have enabled the
claimant to see the flood water before she drove into it and to avoid damage to
her automobile, had she been exercising ordinary care under all of the facts
and circum stances existing at the time and place of the accident. The Court
concludes that, even though the respondent may have been negligent in failing
to warn motorists of the flooded road, such negligence was equalled or exceeded
by the negligence of the claimant herself. Accordingly, this claim must be
denied.
Claim disallowed.
Opinion issued September 29, 1981
CHARLES R. SHAFFER
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-.202)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damage to the rear bumper of
claimant?s automobile in the amount of $255.33 was caused when said vehicle
struck an improperly secured metal sheet covering a road repair hole on Route
20 in Upshur County, West Virginia, a highway owned and maintained by the
respondent; that this occurred because of the negligence of the respondent in
failing to properly install the metal sheet,
W. VA.]
REPORTS STATE COURT OF CLAIMS 29
which negligence was the proximate
cause of the damage sustained, the Court finds the respondent liable, and makes
an award to the claimant in the amount stipulated.
Award of $255.33.
Opinion issued September 29, 1981
SOUTHERN CHEMICAL CO.
Vs.
ADJUTANT GENERAL
(CC-81-129)
No appearance by claimant.
Henry C. Bias, Jr., Deputy
Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $98.76 for merchandise purchased by the respondent for
which no payment was received.
The respondent admits that the claim is valid and that sufficient funds
remained in its appropriation for the proper fiscal year from which the
obligation could have been paid. Therefore, the Court makes an award to the
claimant in the amount requested.
Award of $98.76.
Opinion issued September 29, 1981
WALTER J. KLEIN COMPANY, LTD.
vs.
BOARD OF REGENTS
(CC-81-201)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $350.00 for a damaged
30 REPORTS
STATE COURT OF CLAIMS [W. VA.
16mm film mailed by the respondent to
the claimant. The film was sent uninsured, and arrived damaged. The respondent
admits the validity of the claim, but also states that there were no funds
remaining in the respondent?s appropriation for the fiscal year in question
from which the claim could have been paid.
Although this a claim which, in equity and good conscience, should be paid, we
believe that an award cannot be made, based on our decision in Airkem Sales and Service, et al. v. Dept. of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued September 29, 1981
CECIL WHITT, SR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-338)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for the respondent. WALLACE, JUDGE:
This claim is in the sum of $602.00 for property damage sustained by the
claimant?s Ford pickup truck in an accident which happened at approximately 4:
10 p.m. on September 12, 1980, at Glen Ferris, West Virginia. The claimant, who
had been travelling west on Route 60, pulled into a service station where he
refueled and checked the air in his tires. At that time, there was a storm
drain with a steel grate cover located upon the berm of Route 60 in proximity
to the point where the pavement of the highway was joined by an exit from the
service station. In order to prevent motorists from running over the grate, the
respondent had installed a vertical steel beam on each side of it. The steel
beams projected about two feet above the surface of the ground and were painted
white, and each had a reflector upon it. The claimant testified that, when he
left the station using that exit, he did not see the steel beams
W. VA.J
REPORTS STATE COURT OF CLAIMS 31
because his view of them was blocked
by the hood of his truck He collided with one of them, damaging his truck.
While the claimant?s view of the steel beams may have been blocked by the hood
of his truck when he was close to them, it is obvious that, whether or not his
view was blocked completely, or the extent to which it was blocked, depends
upon distance. At some time (and distance) as he approached the beams, they
must have been within his view, and he would have seen them had he been
maintaining a reasonable lookout. In addition, it appears that, if he had kept
his vehicle upon the pavement and not driven onto the berm there would have
been no collision. For those reasons, the Court concludes that, even if the respondent?s
conduct in erecting and maintaining the steel beams could be viewed as
negligence, the claimant himself was guilty of negligence which equalled or
exceeded it. Accordingly, this claim must be denied.
Claim disallowed.
Opinion issued September 29, 1981
ZUMMACH-PEERLESS
CHEMICAL COATINGS CORP.
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-81-135)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $918.29 for redwood stain purchased by the Department of
Natural Resources for which the claimant received no payment.
As the respondent admits the validity of the claim, and as sufficient funds
remained in its appropriation for the proper fiscal year from which the claim
could have been paid, the Court makes an award to the claimant in the amount
requested.
Award of $918.29.
32 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued October 7, 1981
RICHARD D. FRUM
vs.
OFFICE OF THE STATE AUDITOR
(CC-81-369)
RICHARD H. BRUMBAUGH
vs.
OFFICE OF THE STATE AUDITOR
(CC-81-370)
CHARLES E. McCARTY
vs.
OFFICE OF THE STATE AUDITOR
(CC-81-371)
GERALD M. TITUS, JR.
vs.
OFFICE OF THE STATE AUDITOR
(CC-81-372)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims have been consolidated by the Court on its own motion since all of
the claims are governed by the same principles of law.
The claimants are attorneys who served as counsel for criminal indigents in
juvenile, misdemeanor, or felony proceedings pursuant to the provisions of West
Virginia Code Chapter 51, Article 11. Claimants? fees were denied by the
respondent because the fund was exhausted.
The factual situations in these claims are identical to that in Richard K. Swartling, et al. v. Office of the State
Auditor. issued on November 5, 1979.
Accordingly, the Court hereby grants awards to the claimants as follows:
Richard D. Frum ?
$38.32
Richard H. Brumbaugh $124.00
Charles E. McCarty ?
$240.00
Gerald M. Titus, Jr. ?
$940.85
W. VA.1
REPORTS STATE COURT OF CLAIMS 33
Opinion issued October 29, 1981
MATTA L. BRADY, ADMINISTRATRIX
OF THE ESTATE OF SHELL C. BRADY, DECEASED,
AND SELECTED RISKS INSURANCE COMPANY,
AS SUBROGEE OF SHELL C. BRADY
vs.
DEPARTMENT OF HIGHWAYS
(CC..80-175)
G. David Brumfielci, Attorney at Law, for claimant.
Nancy J. A 11ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim was filed against the respondent by Matta L. Brady as the
administratrix of the estate of Shell C. Brady, deceased, for damages resulting
from the death of the deceased.
Shell C. Brady owned a 1977 International tandem-type truck with which he
operated his own business hauling gravel and other materials. On July 25, 1979,
he was hauling gravel from the James River Hydrate Company in Swords Creek,
Virginia to respondent?s garage in Williamson, West Virginia. Linus Holt, a
truck driver for C&R Trucking Company, was also delivering gravel between
those points on the same day, using the same routes. Both trucks proceeded to
Williamson over Mary Taylor Mountain on West Virginia Secondary Route 9 at
approximately 10:30 a.m. It was a cloudy day, and there was dry dirt on the
surface of the mountain highway. Mr. Holt made no complaint about the dirt when
he arrived at the garage. Both trucks, after unloading the gravel, were
returning to Virginia and had stopped for lunch at about 12:30 p.m. at a small
restaurant in Taylorsville, West Virginia, situated at- the foot of Mary Taylor
Mountain. After lunch, they left the restaurant and proceeded up the mountain
on West Virginia Secondary Route 9. The decedent was in the lead about 200 feet
in front of Mr. Holt, who followed in his truck. It was raining very hard. The
mountain road was steep and had many curves. There were no guardrails. Mr. Holt
testified that both trucks were proceeding at a speed of 20-25 miles per
34 REPORTS
STATE COURT OF CLAIMS [W. VA.
hour, and, as the decedent?s truck
?topped over the mountain,? it slid sideways down the highway and went over the
side of the mountain, front end first. The road was covered with mud one
quarter to one-half inch thick for about 200 feet. Mr. Holt?s truck slid down
the road, but he was able to stop and move his truck off the highway. An
automobile was forced back down the mountain to prevent a collision with the
Holt truck. Mr. Holt called for assistance on his CB radio, got out of his
truck, slipped and fell on the muddy road, then managed to go down the mountain
side with another motorist to the point where the truck had come to rest. The
decedent was pinned under the truck. Trooper Barry M. Henry and Trooper D. A.
Hamlin, of the West Virginia State Police, reached the scene of the accident
from Williamson 30 minutes after being notified. An ambulance arrived 30
minutes later. The police. ambulance crew, and others took the injured man by
stretcher farther down the mountain to where the highway curved around the
mountain below the accident scene. Mr. Brady died en route to the hospital.
Mr. Holt, Trooper Henry, Cecil Diamond, and Deputy Wallace Baisden, witnesses
for the claimant, testified that the road was covered with mud for about 150 to
200 feet, and all but Trooper Henry testified that there were no warning signs
or watchmen posted to warn of the dangerous condition.
Wallace Baisden, Chief Field Deputy Sheriff of Mingo County, was notified of
the accident while in his office in Williamson. He met the ambulance coming off
the mountain, and proceeded up the mountain to clear traffic. Deputy Baisden
testified, ?I couldn?t get my cruiser up the left side of the traffic. . so I got it as far as I could and then I had to walk,
but I got up to the scene where the truck went over and the mud was so slick
that I couldn?t stand on it.? He further testified that he returned to his
cruiser and radioed his office to notify the respondent to send trucks with
gravel. The driver of a truck filled with gravel that was on the mountain
agreed that his load could be spread on the highway. The deputy and others
spread the gravel on the road. Respondent?s truck arrived later with gravel or flyash.
W. VA.]
REPORTS STATE COURT OF CLAIMS 35
Jake T. Watts, Jr., testified that he
was respondent?s grader operator on the mountain on the day of the accident. He
stated that the work crew consisted of his boss, H. P. Maynard, two flagmen,
and himself as the grader operator. He stated that his job was to remove slate
and clay which slid off the mountain and filled the ditch line and covered the
berm. With the grader, he pulled the dirt from the ditch line and berm and
pushed it across the road and down the mountain. He further stated that there
was too much material to move with the grader and he had complained to his boss
that the equipment was insufficient. He started to work at about 8: 15
a.m. The dirt and clay piled up on the surface of the road. It began to rain,
and the material became slick. He removed as much of the material as he could.
The crew was then moved to another site near Red Jacket, West Virginia, where
they finished out the day. When the crew left, the warning signs were removed and
the flagmen went with the crew. Apparently, no provisions were made for
additional signs or flagmen.
James E. Webb, respondent?s assistant county supervisor at the time of the
accident, testified that it was the practice to remove all of the materials from
the hillside of the road to the other side to build up the berm. This was the
procedure at the scene of the accident.
The record establishes that the respondent was negligent, and its negligence
was the proximate cause of the decedent?s death. A written stipulation filed
with the Court stipulated that, as a result of the death of Shell C. Brady, the
following expenses were incurred: burial marker, $702.00; flowers, $78.00;
hospital charges, $148.00; and funeral bill, $2,319.94. Also stipulated and entered
into evidence were life expectancy tables, wages and tax statements from
previous employers, and income tax returns for 1976, 1977, and 1978. A
Pecuniary Loss Report prepared by Dr. Richard Raymond, Ph.D. of Economics,
showing net income loss to claimant?s estate in the amount of $188,361.00, was
received in the stipulation. The deceased, Mr. Brady, was 38 years old at the
time of his death. i-Ic had a life expectancy of 34.8 years and a work-life
expectancy of 24.8 years. He had no children and was survived by
36 REPORTS
STATE COURT OF CLAIMS [W. VA.
a wife, Matta Brady, age 39. Mrs.
Brady suffers from rheumatoid arthritis arid is unable to work. She receives no
social security or monthly income and must support herself from savings. West
Virginia Code ?55-7-6 provides that, in an action from wrongful death, a jury
may award such damages as it may deem fair and just, and determine what
portions shall be distributed to the surviving spouse and children. In this
case, there were no children.
The written stipulation filed also indicated that the 1977 model International
truck, which was destroyed in the accident, had a fair market value at the time
of loss of $35,380.00. The claimant received $33,650.00 from Selected Risks
Insurance Company for this loss, with a provision for a deductible of
$100.00.
The Court, having considered the relevant facts, the stipulation of the
parties, and the opinion of Dr. Richard Raymond in his Pecuniary Loss Report,
concludes that damages should be awarded to Matta L. Brady, Administratrix of
the Estate of Shell C. Brady, deceased, in the amount of $203,347.94, and to
Selected Risks Insurance Company, as subroge of Shell C. Brady, in the amount
of $33,650.00.
Award of $203,347.94 to Matta L. Brady, Admin. of the Estate of Shell C. Brady,
deceased.
Award of $33,650.00 to Selected Risks Insurance Company, as subrogee of Shell
C. Brady.
Opinion issued November 4, 1981
FULLEN FERTILIZER COMPANY, INC., ET
AL.
vs.
FARM MANAGEMENT COMMISSION
(CC-81-231)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent PER CURIAM:
These claims against the Farm Management Commission were submitted for decision
upon the pleadings. The claimants
W. VA.] REPORTS
STATE COURT OF CLAIMS 37
seek payment for various goods and services furnished to the
respondent as follows:
Claim No. Claimant Amount
CC-81-231 Fullen Fertilizer Company, Inc $ 453.65
CC-81-211 Eglon Farm Service $16,709.35
CC-81-213 Swisher?s Feed and Supply $ 2,068.40
CC-81-218 Corder Tractor & Equipment
Company $
210.52
CC-81-221 Heritage Equipment Company $ 268.12
CC-81-222 Dearing Brothers, Inc $ 591.34
CC-81-223 McGhee & Company - $ 13.25
CC-81-224 North Central Dairy Herd
Improvement Association $
270.07
CC-81-226 G. Jay Crissman, D.V.M. $ 265.00
CC-81-227 Frank?s Service Center $ 110.43
CC-81-228 Tygarts Valley Sanitation, Inc $ 60.00
CC-81-229 Elkins Tire Company -- $ 140.76
CC-81-230 Henderson Implement Company $ 618.14
CC-81-232 Joalde Sales & Service - - $ 35.87
CC-81-233 Mountain Mobile Milling $ 200.75
CC-81-234 Greenbrier Tractor Sales, Inc. -- - $ 4,717.67
CC-81-235 Pickens Hardware Co., Inc. $ 239.49
CC-81-239 *Boso Agri-Center, Inc. - $ 8,585.13
CC-81-240 Young?s Inc $
211.00
CC-81-241 Skyland Hospital Supply $ 77.00
CC-81-242 Liggett?s Supply $ 638.48
CC-81-243 Keefer?s Service Center $ 3,219.64
CC-81-249 Winchester Equipment Co $ 155.34
CC-81-195 &
CC-81-252 Union Oil Company of California $ 8,002.98
CC-81-255 Marshall County Cooperative, Inc $ 78.00
CC-81-258 **virginia Harvestore, Inc. $ 1,146.72
CC-81-264 Greenbrier Valley Farm
Center, Inc -
$ 3,212.90
CC-81-268 Lewis & Burge, Inc $ 170.96
CC-81-269 Southern States Marlinton,
Cooperative $
29.85
* Amended by Court Order to $8,406.83.
** Interest and/or finance charges denied.
38 REPORTS STATE
COURT OF CLAIMS [W. VA.
Claim No. Claimant Amount
CC-81-270 Hedlund Manufacturing Co., Inc. $ 1,622.07
CC-81-273 J. H. Holt Plumbing and
Heating, Inc $
1,000.40
CC-81-274 Johnston Alternator and
Trailer Sales, Inc. $
425.54
CC-81-279 Darwin 0. Fike, d/b/a Surge
Sales and Service $
208.30
CC-81-280 West Virginia Turnpike
Commission $
28.00
CC-81-284 G. W. Wandling --
$ 150.00
CC-81-285 *Lawson Products, Inc. $ 922.28
CC-81-286 Robert M. Flesher, D.V.M. Upshu
Veterinary Hospital -
$ 55.00
CC-81-293 Agway, Inc. -
$ 412.07
CC-81-294 Elkins Machine & Electric Co. -- $ 556.00
CC-81-295 Frank J. Cary, D.V.M. Mountainlan
Animal Hospital $
3,344.55
CC-81-300 Weston Veterinary Clinic $ 273.00
CC-81.-304 John R. Tomlinson, D.V.M. Fairle
Animal Hospital $
249.00
CC-81-306 Blue Grass Equipment, Inc $ 117.40
CC-81-310 Nasco $
48.65
CC-81-313 Whitman Exterminating Company $ 68.00
CC-81-314 Beckley Veterinary Hospital, Inc. $ 188.00
CC-81-318 Fulton-Thompson Tractor Sales, Inc. $ 675.00
CC-81-321 Tygarts Valley D.H.I.A $ 85.30
CC-81-327 Gibson?s Scale Service $ 677.40
CC-81-328 Overnite Transportation Co $ 28.20
CC-81-330 Ward Auto Parts Co. $ 667.16
CC-81-331 Town & Country Veterinary Clinic $ 1,588.50
CC-81-335 Humberson Farm Equipment $ 595.67
CC-81-336 Firestone Stores $ 119.50
CC-81-337 James L. Davison $ 122.25
CC-81-338 Cecil E. Jackson Equipment, Inc. - $ 65.06
CC-81-339 Pioneer Harvestore Systems, Inc. $ 205.34
CC-81-348 Southern States Elkins Coop., Inc. $ 24,591.24
CC-81-352 Bessire & Company, Inc $ 540.70
* Interest and/or finance charges denied.
W. VA.] REPORTS STATE COURT OF CLAIMS 39
Claim No. Claimant Amount
CC-81-357 West Virginia Artificial
Breeders $
2,748.00
CC-81-360 Mason County D.H.I.A., Inc. - $ 527.46
CC-81-382 Jefferds Corporation $ 747.24
CC-81-384b The Firestone Tire and
Rubber Company $
51.60
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
While we feel that these claims should, in gquity and good conscier2ce, be
paid, we further believe that awards cannot be made, based on our decision in Air/cern Sales and Service, et al. v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claims disallowed.
Opinion issued November 5, 1981
GREENBRIER VALLEY HOSPITAL, ET AL.
vs.
DEPARTMENT OF CORRECTIONS
(CC-81-347)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims against the Department of Corrections were submitted for decision
upon the pleadings. The claimants seek payment for various goods and services
furnished to the respondent as follows:
Claim No. Claim Against Anthony Center
Amount
CC-81-347 Greenbrier Valley Hospital $ 898.18
40
REPORTS STATE COURT OF CLAIMS
[W. VA.
Claims
Against West Virginia
Claim No. Penitentiary Amount
CC-81-198 &
CC-81-265 Reynolds Memorial Hospital, Inc. - $ 40,956.67
CC-81-298 Johnson?s Boiler Sales &
Service, Inc. $13,883.22
CC-81-315 Boury, Inc $
1,984.28
Claims Against West Virginia
Claim No. Prison for Women Amount
Reynolds Memorial Hospital, Inc.
Rajendra P. Singh, M.D. $
Mercer Radiology, Inc $
Tn-State Ambulance and Rentals $
Summers Community Clinic $
B. Payman, M.D - $
Summers County Hospital
Raleigh General Hospital, Inc
Greenbrier Valley Hospital $
C. K. Agarwal, M.D $
Raleigh Orthopaedic Assoc., Inc $
Physicians Fee Office $
J. D. Woodrum, M.D., Inc $
Saryu P. Dani, M.D $
Princeton Internists $
Adnan N. Silk, MD., P.C.
Beckley Neurosurgical Clinic $
CC-81-217 Hassan Amjad, M.D. $
CC-81-373 Princeton Community Hospital $
Claims Aginst Huttonsville
Claim No. Correctional Center Amount
CC-81-212
CC-81-236
CC-81-237
CC-81-253
CC-81-262a
CC -8 1-2 62b
CC-81-263
CC-81-267
CC-81-277
CC-81-289
CC-81-296a
CC-81-312a
CC-81-333
CC-81-344
CC-81-225
CC-81-329
$
4,535.90
215.00
130.00
569.00
103.02
110.00
$13,341.30
$ 1,541.25
4,644.52
70.00
100.00
2,001.14
95.00
40.00
87.00
80.00
295.00
90.00
CC-81-194 & |
|
|
|
CC-81-244 |
Southern Chemical Co |
$ |
1,688.50 |
CC-81-245 |
Appalachian Mental Health Center |
$ |
4,400.00 |
CC-81-247 |
C. H. James & Co |
$ |
1,149.18 |
CC-81-250 |
Bernhardt?s Clothing, Inc |
$ |
3,215.38 |
CC-81-254 |
Beckley Radiology Associates |
$ |
323.50 |
CC-81-256 |
Picker Corporation |
$ |
1,043.51 |
CC-81-257 |
Physicians Associates, Inc |
$ |
245.00 |
W. VA.]
REPORTS STATE COURT OF CLAIMS
41
Claims
Against Huttonsville Correctional Center
Wechsler Coffee Corporation
Eugene E. Hutton, Jr., M.D
Raleigh General Hospital
Orthopedic Clinic, Inc.
Grafton City Hospital
Nova Rubber Company, Inc.
The Upjohn Company -
-- -
Ayerst Laboratories
Reed & Carnrick -
-
Perrmont Chemical Company
West Virginia Paper, Inc
Raleigh Orthopaedic Assoc., Inc.
McNeil Pharmaceutical -
Appalachian Regional Hospital
Norwich-Eaton Pharmaceuticals
Henry Schein, Inc.
Dentists Fee Office
Physicians Fee Office -
Claim No.
CC-81-259
CC-81-260
CC-81-307
CC-81-272
CC-81-276
CC-81-278
CC-81-281
CC-81-282
CC-81-283
CC-81-287
CC-81-290
CC-81-296b
CC-81-297
CC-81-299
CC-81-303
CC-81-305
CC-81-311
CC-81-312b
CC-81-317
CC-81-340
CC-81-214
CC-81-354
CC-81-362
CC-81-364
Amount
$
3,669.12
$ 5,038.00
$ 150.95
- $ 350.00
$ 3,777.94
$
540.00
- $ 791.07
-
$ 411.57
$ 970.08
$ 3,400.00
$ 3,478.25
$ 2,310.00
$ 131.87
$ 1,690.00
$ 412.06
$ 397.25
$ 300.00
3,528.25
Dorsey
Laboratories -
Union Oil Company of California
Marlinton Electric Co., Inc
Fairmont State College
Monongahela Power Company
Independent Dressed Beef
Company, Inc
CC-81-365 Memorial General Hospital
$
- ---
$ 156.90
$ 8,452.08
- $ 80,609.40 $ 1,819.99
$17,192.85
$ 3,738.90
$133,500.35
$ 558.97
$ 2,296.94
CC-81-366
CC-81-368
CC-81-383
CC-81-387a
CC-81-387b
CC-81-384a
Association - -
Pfizer, Inc
Gall?s Inc
West Virginia Department
of Highways
SK&F Lab Co
SK&F Co
The Firestone Tire and
Rubber Company
$
3,698.73
- $ 399.60
- $ 20.82
$ 574.34
The respondent admits the validity and amounts of these claims, but further alleges that sufficient funds were not avail-
42 REPORTS
STATE COURT OF CLAIMS [W. VA.
able at the close of the fiscal years
in question from which the obligations could have been paid.
While we feel that these claims should, in equity and good conscience, be paid,
we further believe that awards cannot be made, based on our decision in Airkem Sales and Service, et al.
v. Department of Mental Health, 8
Ct.Cl. 180 (1971).
Claims disallowed.
Opinion issued November 9, 1981
A. B. ENGINEERING COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(D?773)
W. Dale Greene, Attorney at Law, for claimant.
Stuart Reed Waters, Jr., Attorney at Law, for respondent. WALLACE, JUDGE:
This claim arises from a contract dated October 5, 1966, be tween the State
Road Commission of West Virginia and two partnerships: James G. Angelaras,
Alvin R. Schwab, and Richard A. Haber, doing business as the A. B. Engineering
Company, and Vladimir V. Barstow and Robert D. Mulligan, doing business as
Barstow and Mulligan, Consulting Engineers. The two partnerships entered into
the contract as a joint venture.
The claim was filed by A. B. Engineering Company as the claimant. At the outset
of the hearing, the respondent raised the question of joining Barstow and
Mulligan, Consulting Engineers, as a necessary party. Counsel for the
respondent represented to the Court that a small amount was owing to Barstow
and Mulligan by the claimant, anl, if an award were made by this Court, the
claimant would pay Barstow and Mulligan whatever amount was still due.
Under the terms of the contract, the claimant agreed to design Project APD-282
(31), a section of the Appalachian
W. VA.]
REPORTS STATE COURT OF CLAIMS 43
Development Highway, U.S. Route 50, in
the location of the selected line, 3-A, 3-F, 3-B of Sverdrup and Parcel and
Associates? Reconnaissance Report (furnished by respondent) from west of
Secondary Route 11, Doddridge County, West Virginia, near Arnold Creek, to
Secondary Route 50/13, Doddridge County, at Sherwood, for a distance of
approximately 10.01 miles. The contract contemplated that the 10.01 miles of
the highway be divided into two projects:
1) From west of Secondary Route 11 near Arnold Creek to west of Secondary Route
18, 3.01 miles.
2) From west of secondary Route 18 to Secondary Route
50/13 at Sherwood, 7 miles.
The claimant was to be paid, for all services rendered under the contract for
the construction contract plans, a lump-sum fee of $376,500.00. In addition to
this lump-sum payment, the claimant would be paid for additional services as
set out in the contract, a total estimated fee of $505,930.00.
The contract further provided:
?In the event of a substantial change in the scope and character of the work,
such as the addition or deletion of interchanges or bridges, or any other
changes requiring an increase or decrease in the fee payments, when ordered by
the Commission in writing, the fees will be adjusted accordingly by a
supplemental agreement on the basis of a lump sum fee or the actual cost of
direct technical labor plus overhead and expenses and a fixed fee to cover profits
only.?
The claimants contends that, subsequent to the award of the contract, the
design criteria were upgraded by the respondent and the Bureau of Public Roads;
that the selected line upon which claimant?s fee was predicated envisaged the
use of the existing U.S. Route 50 for two lanes of a four-lane highway for five
miles; and that the new criteria ruled out such use in that the existing U.S.
Route 50 met neither the vertical nor the horizontal alignment requirements.
The claimant further contends that the change in design criteria resulted in
increased costs beyond those originally estimated, and con-
44 REPORTS
STATE COURT OF CLAIMS [W. VA.
stituted a substantial change in the
scope and character of the work, for which claimant would be entitled to
additional compensation in the amount of $253,337.00. In addition to this
amount, claimant is claiming $27,012.13 for monies withheld for payment of B
& 0 tax due the State of West Virginia and for work performed by survey
teams provided by the respondent.
After the pre-trial hearing on July 31, 1978, hearings were held on November 13
and 14, 1978, and January 3 and 4, 1979. At the hearing on November 14, 1978,
the claimant advised the Court that it was not going to pursue the claim
pertaining to the withholding of monies for B & 0 tax and survey matters,
but would pursue that portion of its claim pertaining to the change in the
scope of the work, for which it claims $253,337.00.
At the close of the hearing on January 4, 1979, claimant reserved the right to
cross-examine certain of respondent?s witnesses and indicated it would be
necessary to depose certain witnesses on its behalf. Nothing further transpired
until the claimant filed its motion in November of 1980 asking permission to
?proceed further .
. . . as relates to the proving of damages
. . .
. upon a quantum merit basis.? The
respondent then filed its motion in opposition and further moved the Court to
dismiss the claim for failure to prosecute. These motions were heard by the
Court on January 21, 1981, at which time they were taken under advisEment.
Counsel for the claimant and respondent then represented to the Court that all
the evidence had been presented as relates to liability and asked that the
claim be bifurcated and that the issue of liability be decided before the
question of damages, to which the Court agreed.
According to the S & P Report, a portion of claimant?s contract was to
design two new lanes of highway and to incorporate a part of existing Route 50
into the final design contract. The claimant contends that the subsequent
design change of two lanes to four lanes involved major changes in the design
work required in the earthwork, drainage, rights of way, intersections and the
necessity to take into account the steeper terrain.
W. VA.]
REPORTS STATE COURT OF CLAIMS 45
In contrast to the claimant?s
contentions, Mr. Thomas P. Kirk, a civil engineer and former employee of the
respondent, testified that there are numerous problems encountered in designing
two lanes next to an existing two lanes that are not encountered when designing
four new lanes. These problems include utilities running parallel with the
existing lanes, adacent houses and parcels of land and access thereto, survey
problems in existing traffic, and adequate drainage. He further stated that a
new location can have problems, but normally, the contractor would be dealing
with larger parce]s of land where the same problems do not exist.
The claimant made no request for additional compensation claimed as a result of
a change in the scope of work until December of 1968. This was after over 74%
of the work had been performed. The respondent denied the request, but did
recognize certain work which it considered a change in the scope of work for
which supplemental agreements were executed and the claimant paid.
From the record, the Court is of the opinion that the claimant designed the
highway within the intent and scope of the agreement for which it has been
properly compensated, and the claim of the claimant is disallowed. Consequently,
the claimant?s motion to proceed upon a quantum merit basis is dismissed as is
the respondent?s motion to dismiss for lack of prosecution.
Claim disallowed.
Opinion issued November 9, 1981
LEONA ASBURY AND TOM ASBURY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-54)
Claimant Leona Asbury appeared
in person.
W. Douglas Hamilton, Attorney at Law, for respondent. GARDEN, JUDGE:
At about 5:30 p.m. on September 8, 1980, the claimant, Leona Asbury, was
operating a 1974 Oldsmobile automobile
46 REPORTS
STATE COURT OF CLAIMS [W. VA.
owned by her husband, Tom Asbury, in a
southerly direction on Route 52. Route 52 is a two-lane, paved highway running
generally in a north-south direction between Kenova and Prichard, West
Virginia. According to the tcstimony of the claimant, Leona Asbury, a slip had
occurred during the spring of 1980, which had partially blocked the southbound
lane of Route 52. At the point of the slip, claimant Leona Asbury moved to the
left to avoid it, and met a northbound truck owned by the Guepel Construction
Co. The truck moved to its right, partially left the road, and, in passing the
car operated by Leona Asbury, threw rocks which damaged the windshield of the
southbound Oldsmobile, necessitating repairs in a total amount of $383.95.
Leona Asbury, while testifying that the condition in the southbound lane had
existed since the spring of 1980, candidly admitted that she had never
complained to the respondent about the condition of this particular area of
Route 52. Even if a showing of negligence had been demonstrated by claimants,
it would appear that an intervening act of negligence on the part of the
northbound truck was the proximate cause of the damage to the claimants?
vehicle.
Claim disallowed.
Opinion issued November 9, 1981
W. H. BALLARD, II, AND
G. DAVID BRUMFIELD
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-81-44)
G. David Brum field, Attorney at Law, appeared on behalf of himself and W.
H. Ballard, II.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
The admitted operative facts as set forth in the verified Notice of Claim
reflect that on June 12, 1977, one Ronald Lee
W. VA.]
REPORTS STATE COURT OF CLAIMS 47
Young was employed by the respondent
as Assistant Superintendent of the Panther State Park located at Panther,
McDowell County, West Virginia. On that date, Young, in the performance of his
official duties, became involved in an altercation with one Mack Lee
Birchfield. As a result, Birch- field was shot by Young, necessitating the amputation
of the middle finger of Birchfield?s left hand.
Thereafter, on July 26, 1978, Birchfield filed a civil action in the Circuit
Court of McDowell County against Young and the respondent herein, seeking
compensatory damages in the amount of $25,000.00, and punitive damages in the
amount of $5,000.00. Robert D. Pollitt, Assistant Attorney General, appeared on
behalf of the defendants, and, prior to trial, was successful in having the
respondent herein dismissed as a party defendant in the civil action. At that
point, Mr. Pollitt determined that it would be improper for him to continue his
representation of Young, in view of the dismissal of the State agency from the
civil action.
Mr. Pollitt thereupon contacted the claimants, who agreed to represent Young,
with the understanding that their fee and expenses would be paid by the
respondent. The claimants proceeded to take the necessary steps to prepare
their client?s defense, and the case was tried to a jury over a period of two
days in August of 1980. The jury returned a verdict in favor of the defendant
Young. Claimants then submitted a statement for services rendered and expenses
in a total amount of $3,593.00, but payment was not made, resulting in the
filing of the claim in this Court.
The respondent, in its Answer, admitted the allegations of the Notice of Claim,
but alleged that it was uninformed regarding the amount of time spent by the
claimants in representing Young, and the value of the legal services. The
Answer called upon the claimants to submit strict proof of said services.
Claimant Brumfield, at the hearing, offered as an exhibit a three-page
itemization of the services rendered, which reflected a total of 32 1/4 hours
of ?out-of-court time? at an hourly rate of $60.00, and 16 hours of ?in-court
time? at an hourly rate of $100.00, for a total fee of $3,535.00. The exhibit
48 REPORTS
STATE COURT OF CLAIMS [W. VA.
further indicated that expenses in an
amount of $58.00 were incurred. On cross-examination, claimant Brumfield
testified that, in his opinion, the hourly charges were reasonable and in
keeping with the charges of other attorneys in McDowell County.
Considering the amount of time devoted to the defense of the case, the
responsibility assumed, the intricacies of the work involved, and, most
importantly, the results attained, this Court is of the opinion that the fee
charged was more than reasonable, and an award is thus made in favor of the
claimants in the amount of $3,593.00.
Award of $3,593.00.
Opinion issued November 9, 1981
JOHN CHARLES BUNGARD
vs.
DEPARTMENT OF WELFARE
(CC-80-352)
Larry L. Rowe, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Claimant filed this claim against the respond?nt for damages sustained by
reason of a ward of the State wrecking his automobile.
The claimant was a welfare worker for Area 9 working out of respondent?s
Grafton, West Virginia, office. He was a Social Worker IV in charge of the
specialized foster care program. The Grafton area had received a Federal grant
establishing specialized foster care, setting up eight foster homes for
training foster parents to deal with problem children who had no success with
institutional care. As part of the program, the claimant carried a limited caseload
of eight in order to give intensive service in an attempt to bring about a
change where normal foster care had not.
W. VA.]
REPORTS STATE COURT OF CLAIMS 49
Since July of 1979, the claimant had
been working with a 17-year-old juvenile with a history of behavioral problems.
At the time he was referred to the specialized foster care program, the
juvenile was on probation as a result of an arson charge. Claimant saw him at
least twice a week and sometimes daily. On April 21, 1980, the claimant picked
up his ward at his foster home and took him to a motorcycle repair shop where
the boy had applied for a job. After the visit to the repair shop, they stopped
at the nearby welfare office. Claimant parked his automobile in the parking
lot. The ward wanted to listen to the car radio, so the claimant left him with
the keys and went into the office. After making several phone calls, the
claimant returned to the parking lot and found that his automobile and his ward
were gone. He later learned that the ward had taken the automobile and wrecked
it. No charges were placed against the juvenile. The automobile, a 1975 Datsun
B-210, was totalled. The book value at the time of the accident was $2,225.00,
and wrecker charges were $88.00. Claimant testified that the salvage value of
the automobile was $200.00. The claimant further testified that the respondent
did not furnish him an automobile; that he was required to use his automobile
in his work; and that he frequently counseled in it so that he could have more
privacy. The respondent reimbursed the claimant for the use of his automobile
at the rate of $.20 per mile and required the claimant to maintain liability
insurance. The claimant did not have collision insurance.
The claimant testified that he had entrusted his ward with the keys to his
automobile on previous occasions, but that this practice occurred late in his
relationship with him. He stated that he was trying to teach the child
responsibility and reliability, that he made the decision to trust him, and that
no one instructed him to do so.
No evidence was introduced in this case with regard to any negligent behavior
on the part of the respondent. The record indicates that the claimant was well
aware of the juvenile?s behavior problems. Nevertheless, he permitted the boy
to remain alone in his car with the keys in it. Claimant therefore assumed the
risk of any loss which resulted. Claudine
flinkle v. Department of Welfare, 13
Ct.Cl. 199 (1980).
50 REPORTS STATE
COURT OF CLAIMS [W. VA.
This negligent act on the part of the claimant himself, in leaving his vehicle
ready for anyone to convert to his own use, was the proximate cause of any
subsequent harm done to the vehicle. LePera
v. Department of Corrections, 13
Ct.Cl. 49 (1979. Accordingly, this claim must be denied.
Claim disallowed.
Opinion issued November 9, 1981
D. A. BURNER
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-78-278)
The claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for rsspondent. WALLACE,
JUDGE:
The claimant filed this claim against the respondent in the amount of $346.50
for a dental bill incurred as a result of injuries received while in the employ
of the respondent.
The claimant was formerly a member of the Department of Public Safety, West
Virginia State Police. On December 9, 1972, while so employed, claimant was
assisting members of the Webster Springs Volunteer Fire Department in the
removal of the body of a man who had drowned in the Desert Fork of the Holly
River near Skelt, West Virginia. A pike pole inserted in the belt of the victim
was being used to free his body from between rocks. The belt broke and the
metal hook on the end of the pole struck the claimant on the left side of his
face damaging his teeth and existing dental work.
The claimant testified that the respondent was to pay the bill for the dental
work which was done in 1973, 1974, and 1975 as a result of his injuries.
Claimant further testified that he turned the bill in and it was to have been
mailed through company headquarters in Elkins to Charleston for payment. The
bill was not paid, and a collection agency attempted to collect from the
claimant in 1978.
W. VA.]
REPORTS STATE COURT OF CLAIMS 51
The bill represents damages incurred
as a result of the injuries sustained in 1972. This claim, filed with the Court
on November 21, 1978, is obviously barred by the Statute of Limitations. This
Court specifically lacks jurisdiction of the claim under the provisions of
Chapter 14, Article 2, Section 21 of the Code of West Virginia, and the claim
is therefore disallowed.
Claim disallowed.
Opinion issued November 9, 1981
BERNARD F. CARNEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-38)
Claimant appeared in person.
Nancy J. Alff, Attorney at Law, for respondent.
GARDEN, JUDGE:
On February 4, 1981, at about 7:50 a.m., the claimant was proceeding in an
easterly direction on Interstate 64 from his home in Hurricane to his place of
employment at Nitro High School. He was operating his 1980 Chevette in the
outside lane, and there was another eastbound car about two lengths in front of
him in the inside lane. Claimant indicated that he was travelling at a speed
between 55 and 60 miles per hour. Suddenly, the car in the inside lane in front
of the claimant struck a rather large loose piece of concrete in the highway,
dislodging it. This large piece of concrete, which claimant estimajed to be the
size of a football or basketball, then rolled into claimant?s lane of travel,
and the claimant was unable to avoid striking it.
As a result, the claimant?s car sustained rather severe damage to its front
end, including the front bumper, radiator, and radiator fan. Temporary repairs
were effected at Dunlap?s Radiator Exxon in Nitro at an expense of $44.92.
Thereafter,
52 REPORTS
STATE COURT OF CLAIMS [W. VA.
complete repairs were effected at
Landers Chevrolet at an expense of $320.89. Claimant is thus seeking a total
award of
$365.81.
No evidence was introduced at the hearing to establish that the respondent was
aware of, or had any knowledge of, the existence of this loose concrete on the
subject section of 1-64. This Court has consistently held that the State is not
an insurer of the safety of motorists using its highways; thus, as there was no
showing of negligence on the part of the respondent, the Court denies the
claim.
Claim disallowed.
Opinion issued November 9, 1981
CARTER?S SAFETY SYSTEMS, INC.
vs.
DEPARTMENT OF FINANCE AND ADMINISTRATION
(CC-81-189)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $974.82 for four Monitrex speed and theft control units
which, after being tested by the State Automobile Motor Pool, were mailed back
to the claimant but never arrived.
A bailee is liable where he fails to exercise ordinary care for the safety of
property in his hands. 2B M.J. Bailments
?11. This is true even though an ?act
of God? is a factor involved; if the occurrence could reasonably have been
anticipated and precautions taken to avoid the injury or loss, liability will
be imposed upon him whose responsibility it was to have taken such precautions
and failed to do so. Iron City Sand
& Gravel Div. of McDonough Co. v. West Fork Towing Corp., 298 F. Supp. 1091 (N.D.W.Va. 1969).
W. VA.]
REPORTS STATE COURT OF CLAIMS 53
Although it may be a sad comment on
the times, it is the opinion of this Court that the loss of an item in the mail
is an occurrence that reasonably can be anticipated, and the respondent?s
failure to take precautions, such as insuring the items mailed, resulted
directly in the claimant?s loss. Inasmuch as the respondent admits the validity
of the claim and states that sufficient funds were available in the fiscal year
in question from which the obligation could have been paid, the Court makes an
award to the claimant in the amount requested.
Award of $974.92.
Opinion issued November 9, 1981
CLIFFORD CUPP
vs.
DEPARTMENT OF HEALTH
(CC-81-341)
No appearance by claimant.
Curtis G. Power, III, Assistant Attorney General, for respondent
PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks an
award of $137.25 for back wages improperly withheld by the Department of Health
while the claimant was a patient at Weston State Hospital.
As the respondent?s Answer admits the validity of the claim and states that
sufficient funds were available in its appropriation for the fiscal year in
question from which the claim could have been paid, the Court makes an award to
the claimant in the amount requested.
Award of $137.25.
54 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion, issued November 9, 1981
MAURICE V. DAVIS
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-170)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant filed this claim against the respondent in the amount of $113.40 for
damages to his 1979 Chevrolet Malibu station wagon.
At approximately 10:00 p.m. on May 22, 1981, the claimant was driving his
automobile southerly on W.Va. Route 119 proceeding from Kanawha City to Racine,
West Virginia. It was raining. He was traveling 35-40 miles per hour on the
two-lane highway. There was no traffic in front of or behind him. About 4?
miles from Marmet, the claimant?s automobile struck a hole in the pavement
about one foot from the berm on the right-hand side of the highway. The right
front tire and wheel were damaged. The claimant testified that he travelled the
road once or twice a month, and that he did not see the hole.
The simple existence of a pothole in the road does not make the State negligent
per Se. For the State to be found negligent, it must have had actual or
constructive notice of the particular road defect which allegedly caused the
accident, and must have unreasonably allowed that defect to continue to exist. Davis v. Dept. of Highways, 12 Ct.C1. 31 (1977). The record in this case contains
no evidence of any notice to the respondent or failure to act on respondent?s
part. Thus, the respondent cannot be found negligent. Recognizing that the
State is neither an insurer nor a guarantor of the safety of persons travelling
on its highways (Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 [19471), and that no award
can be made without proof of negligence, the Court must disallow this claim.
W. VA.]
REPORTS STATE COURT OF CLAIMS 55
See Hanson v. Dept. of Highways, 12 Ct.Cl. 198 (1978). Smith v. Dept. of Highways, 14 Ct.Cl. 11(1981).
Claim disallowed.
Opinion issued November 9, 1981
WILLIAM P. ESTEP, SR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-49)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant filed this claim against the respondent in the amount of $140.00 for
damages to his 1981 VW Rabbit automobile.
At 8:55 a.m. on February 6, 1981, the claimant was driving his automobile
westerly on 1-70 just outside Elm Grove, West Virginia, on his way to Wheeling.
The road was wet but not icy. He was driving 45 to 50 miles per hour, five or
six car lengths behind another automobile. There were cinders on the highway
which were thrown against claimant?s car windshield by the wheels of the
vehicle in front of him. The claimant had insurance, but stated that he made no
claim for the damages to his windshield. Claimant testified, ?I figured they
loaded that truck too heavy and hit them chuckholes and those heavy frozen
clumps fell out in the road and when that guy run over them, he throwed it back
in my windshield.?
The State neither insures nor guarantees the safety of motorists travelling on
its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2nd 81 (1947). There is nothing
in the record in the instant case to show that the respondent had notice of any
dangerous condition on the highway. For the respondent to be held liable, the
claimant must prove that the respondent had actual or constructive knowledge of
the situation and a rea
56 REPORTS
STATE COURT OF CLAIMS [W. VA.
sonable amount of time to take
corrective action. Davis vs. Dept. of
Highways, 11 Ct.Cl. 150 (1977). Since
the claimant did not meet that burden of proof, this claim is disallowed.
Claim disallowed.
Opinion issued November 9, 1981
RABERT LEE FULKS, JR.
vs.
DEPARTMENT OF EDUCATION
(CC-81-172)
ERNEST E. LOWE
vs.
DEPARTMENT OF EDUCATION
(CC-81-186)
Claimant Rabert Lee Fuiks, Jr., appeared in person.
Claimant Ernest F. Lowe appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The above-styled claims arose out of the same factual situation, and, upon
motion of the respondent, the Court consolidated them for hearing.
Both claimants were employed by the respondent ? Rabert Lee Fuiks, Jr., as graphic arts supervisor, and Ernest E. Lowe as
a graphic artist. Certain photographic equipment belonging to the claimants was
stolen from respondent?s darkroom located in Room 015 in the basement of ?B?
Building in the Capitol complex. The theft was discovered on May 29, 1981. To
enter the darkroom, it was necessary to proceed through two locked doors. There
was no forced entry. Mr. Fuiks, in his testimony, surmised that someone had
left the doors unlocked.
Among the items stolen, Mr. Fuiks lost a Myamia 645 camera, a light meter, and
thermometer, all valued at $1,184.95. His insurance covered $500.00 of this
loss. Mr. Lowe lost a
58 REPORTS STATE
COURT OF CLAIMS [W. VA.
accommodate the respective northbound and southbound motorists. Claimant
testified that he was travelling at a speed of 15 to 20 miles per hour, and was
following the vehicle ahead by about a car length. The claimant further stated
that he never saw the hole until after his automobile had struck it. The hole,
according to the claimant, was at least two feet in diameter and extended to a
depth where the steel reinforcing bars were clearly visible.
As a result of striking the hole, the front suspension system of the claimant?s
automobile was ruined, the exhaust system was damaged beyond repair, and the
gas tank was torn from the car. The testimony established that the cost of
repairing the damage would amount to $480.00.
Credible evidence was introduced at the hearing which established that
respondent was aware of the existence of this particular hole prior to
claimant?s accident. Even absent such testimony, the respondent should have
been aware of the existence of this serious defect. The Patrick Street Bridge
is part of U.S. Route 60, and, as such, is certainly one of the most
heavily-travelled highways in the City of Charleston. Being of the opinion that
the respondent was negligent and that such negligence was the proximate cause
of the damage to the claimant?s automobile, the Court hereby makes an award in
favor of the claimant in the amount of $480.00.
Award of $480.00.
Opinion issued November 9, 1981
L. D. HALL
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-397)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, an employee of the respondent at Havaco, West Virginia, filed
this claim against the respondent for the value of certain tools stolen from
respondent?s premises.
W. VA.]
REPORTS STATE COURT OF CLAIMS 57
Series 900 Polaroid camera valued at
$195.000, but had no insurance.
Claimant Fuiks did the photographic work for the respondent and its newspaper, State Ed. The
respondent did not furnish a camera for this purpose, and Mr. Fuiks? supervisor,
Elnora Pepper, the Director of the Office of Public Information and
Publications, requested that he keep his camera ?on hand? and use it in the
respondent?s work.
Claimant Lowe had entrusted his camera to the editor who wanted to use it to
see if that type of camera would be helpful in meeting deadlines and saving
time and expense.
Both claimants herein had furnished their cameras and other items to be used in
respondent?s work pursuant to requests from their superiors. The items were
stolen due to no fault of the claimants. Accordingly, the Court makes an award
to claimant Fulks in the amount of $684.95, and to claimant Lowe in the amount
of $195.00.
Award of $684.95 to Rabert Lee Fulks, Jr.
Award of $195.00 to Ernest E. Lowe.
Opinion issued November 9, 1981
ALONZO GIBSON
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-7)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
At about noon on December 29, 1980, the claimant was involved in an accident on
the Patrick Street Bridge in Charleston, West Virginia. At the time, he was
operating his 1970 Chevrolet Camaro automobile in a southerly direction on the
bridge. Apparently, construction work was being done in the center of the
bridge, and only one lane of traffic was open to
W. VA.J
REPORTS STATE COURT OF CLAIMS 59
The claimant had stored his tools in
respondent?s garage in Havaco, West Virginia. They were in a locked toolbox
inside a locker, which also was locked. On September 1, 1980, someone broke
into the garage, and, with chain cutters, removed both locks and stole
claimant?s tools. Claimant testified that an employee of the respondent, Gladys
Smith, was supposed to have been on duty as watchman but wasn?t able to work
that night, and the respondent did not furnish a replacement. He further
testified that the employees had been taking their tools home, but after a
watchman was put on duty, the tools were left in the garage. The claimant
introduced as his Exhibit No. 1 a list of the tools that were stolen. Some were
new and others, used. He stated that they were worth $800.00, and that it would
cost over $1,000.00 to replace them new.
Randall Buller, respondent?s Director of the Maintenance Division in Putnam
County, testified that the respondent did not provide general night watchmen
for all its facilities; that he was not familiar with a Gladys Smith but he was
not in a position to deny that she was an employee of the respondent; and that
the respondent, from time to time, provided watchmen ?to break the chain of
theft which sometimes develops in certain facilities. It is done periodically.
It is not done as a matter of routine course.?
In response to the question, ?In certain positions such as the position Mr.
Hall has, as a mechanic, are the mechanics required to keep, to own their own
tools at the Department of Highways??, Mr. Buller replied, ?Yes, they are.?
The claimant further testified that he could take his tools home, but, after
there was a watchman, he and other employees left their tools in the garage.
The claimant was required to furnish his own tools and he stored them in the
locker provided by the respondent. He relied on a watchman being present after
working hours and had no reason to suspect that his tools might be stolen. The
watchman failed to report for work and no replacement was furnished.
From the record, the Court makes an award to the claimant in the amount of
$800.00.
Award of $800.00.
60 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued November 9, 1981
KANAWHA VALLEY REGIONAL
TRANSPORTATION AUTHORITY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-116)
Sarah G. Sullivan, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation that damages to claimant?s 1980 GMC bus in the amount
of $3,744.80 were caused when the vehicle struck a steep plate covering a hole
on Route 61/119 in Charleston, West Virginia; and that negligence on the part
of the respondent in failing to properly anchor the plate proximately caused
the damage suffered by the claimant, the Court finds the respondent liable, and
makes an award to the claimant in the amount stipulated.
Award of $3,744.80.
Opinion issued November 9, 1981
RICHARD J. LINDROTH
vs.
WORKMEN?S COMPENSATION FUND
(CC-81-41)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
On April 1, 1980, claimant Richard J. Lindroth, an attorney,
W. VA.) REPORTS
STATE COURT OF CLAIMS 61
was employed as an Executive Secretary with the Workmen?s Compensation Fund.
When he reported for work, Mr. Lindroth discovered that there was no dictating
equipment available for his use. While equipment had been ordered, it appeared
that it could not be delivered for four to six weeks. Because the commissioner?s
office used cassette dictators, the claimant decided to use his own Panasonic
cassette dictator.
Several weeks later, the claimant discovered that his cassette had been stolen
from the unlocked desk where he stored it during the evenings and on weekends.
Claimant contends that the respondent was under a legal duty to keep the
offices locked and to provide locks for the desks of personnel employed in its
offices. Mr. Lindroth asserts that the Panasonic had a fair market value of
$70.00 to $90.00.
The record is not clear as to the exact legal basis that the claimant contends
would impose liability on the respondent agency for the value of the cassette.
Certainly the law of bailment would have no application, for the claimant never
actually or constructively delivered the cassette to the respondent. The legal
duty owed by the respondent to the claimant in situations such as this is
discussed in 53 Am,Jur.2d Master and
Servant ?131 (1970) as follows:
?The law does not impose upon the employer an obligation to rescue his
employee?s property from the consequences of a destructive agency for which the
employer is not in any way responsible. And
it has been held that a master is under no duty to take
reasonable care to prevent the theft of his servant?s effects.? (Emphasis supplied.)
The Court, being of the opinion that the respondent owed no legal duty to the
claimant in respect to the subject cassette, and, being of the opinion that the
claimant assumed the risk attendant upon leaving his cassette in an unlocked
desk, must refuse to make an award.
Claim disallowed.
62 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued November 9, 1981
THOMAS E. McNAMEE
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-100)
ALLSTATE INSURANCE COMPANY AS
SUBROGEE OF JACQUELINE E. DELAZIO AND
JACQUELINE E. DELAZIO, INDIVIDUALLY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81?1 14)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
The above-designated claims were consolidated for hearing. The accident in each
of the claims occurred on February 16, 1981, on the same bridge on Interstate
81 in Berkeley County. West Virginia, just north of the Route 9 exit. Claimant
Thomas E. McNamee?s accident occurred at approximately 5: 15 p.m., and the
accident of claimant Jacqueline E. Delazio happened at approximately 7:30 p.m.
It was raining and the road was wet but not freezing.
Claimant McNamee was driving his 1971 Volvo automobile northerly in the inside
or slow lane of 1-81. He was very familiar with this road as he travelled it
every Monday in his business. There was traffic to the front and rear, and in
the passing lane. He was travelling in excess of 50 miles per hour, it was
getting dark, and his headlights were on low beam. Upon entering the bridge, Mr.
McNamee saw a hole in the northerly portion of the bridge deck about 25 to 30
feet in front of him. Traffic conditions were such that he could not slow down
nor swerve into the left lane. His automobile struck the hole and sustained
damage in the amount of $423.21. He stated that, apparently, a part of the
concrete bridge deck ?had
W. VA.]
REPORTS STATE COURT OF CLAIMS 63
dropped out,? leaving a hole
approximately 4 feet square. Claimant further stated that he did not know how
long the hole had existed, and that he notified the State police and the
respondent the next day.
The facts surrounding the action of the claimant Jacqueline
E. Delazio were substantially the same as those of claimant McNamee. She was
driving her 1975 Mazda automobile northerly in the inside or slow lane of 1-81
at a speed of approximately fifty miles per hour. It was raining and the
traffic was heavy. The vehicles in front of her apparently straddled the hole
because Ms. Delazio did not see the hole until her automobile struck it. She
stated that she literally ?flew in the air? when the accident occurred. The
claimant Delazio left the scene of the accident with another motorist and
returned later when a wrecker removed her vehicle. She stated that, on her
return, the State police had closed the damaged section of the bridge. She
further testified that the people at the service station where she had gone
stated that people ?had been hitting it all day.? According to the claimant?s
testimony, her automobile sustained damage to a door, the muffler, tail pipe,
hubcaps, and tires in the amount of $618.51. Ms. Delazio indicated that
Allstate Insurance Company paid her $448.79 and is joined in this proceeding as
a subrogee of the claimant.
Gary R. Klavuhm, respondent?s district bridge maintenance engineer, testified
that he was notified of the damaged bridge at approximately 9:30 p.m., but the
respondent?s office had been notified at about 8: 00 p.m. by the State police,
after which the decision was made to close that particular lane of bridge
traffic. Mr. Klavuhm further testified that the respondent had received a
report (Respondent?s Exhibit 1) on December 4, 1980, made by the Materials
Testing and Control Division in Charleston regarding this specific bridge. He
stated, ?The report basically indicated that there were severe distress and
disintegration in the top, essentially in the top two inches of the six-inch
concrete deck down to about the top of reinforcement steel.? Mr. Klavuhm also
said, ?There was nothing to lead us to believe that there would be an imminent
full depth structural failure in this particular bridge.? There had been
64 REPORTS
STATE COURT OF CLAIMS [W. VA.
no such failure on any other bridges
on 1-81. The Court then asked Mr. Klavuhm the following question concerning the
report:
Q. ?Okay, well, we have this report. Now, you?ve indicated
that there were also regular inspections reports made ? reported to the Department of Highways. Did those
reports coupled with this report that was made or per tests that were conducted
in the summer of 1980, taking all those together, did they give the Department
of Highways any notice, however slight, of that possibility of a collapse of
that portion of the bridge deck such as occurred here on February 16, 1981?
A. Yes, sir, they did.?
The evidence is not clear as to the actual time that the dangerous condition
appeared. Ms. Delazio testified that individuals at the service station stated
that people ?had been hitting it all day?; however, no one testified to this.
Mr. Klavuhm testified that the Department of Highways was notified at 8:00
p.m., and he was notified at 9:30 p.m. The lane of traffic was closed as soon
as the State Police and the respondent knew of the condition.
It appears to the Court from the record in this claim that the respondent had
reason to believe that this concrete section of the bridge might fail. In view
of the fact that this bridge was part of a major interstate system, the
respondent had a duty to maintain the bridge in such a way as to prevent a major
deck failure, such as occurred in this instance. Therefore, this Court is of
the opinion that negligence on the part of the respondent caused the resultant
damages sustained by the vehicles belonging to the claimants herein, and makes
the following awards:
Award of $423.21 to Thomas E. McNamee.
Award of $169.72 to Jacqueline E. Delazio.
Award of $448.79 to Allstate Insurance Company as subrogee of Jacqueline E.
Delazio.
W. VA.J REPORTS
STATE COURT OF CLAIMS 65
Oprnion issued November 9, 1981
MICHAEL A. PIAZZA
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-30)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant is seeking an award of $259.56 from the respondent for damage
sustained by his 1979 Cadillac Eldorado automobile.
On December 10, 1980, the claimant?s wife, Katherine N. Piazza, was driving to
work in claimant?s automobile on Interstate 70 at approximately 5:40 am. It was
dark, and there were no adverse road conditions. She was proceeding westerly at
about 45 miles per hour in the center lane through the Mount de Chantal area of
Wheeling, West Virginia. Interstate 70 at this point has three westbound lanes.
Mrs. Piazza testified that she uses 1-70 every day when going to and from work;
that there were no vehicles in front of her, and that she suddenly came upon a
pothole and it was too late to avoid hitting it . The automobile struck the pothole, damaging the right front wheel and
rim. She stated that the hole was not very large, but that it was deep, and had
not been there the previous day.
The claimant testified that he drove his 1981 Ford Van through the same area at
9:00 a.m. on the same day and saw the hole. He stated that he drove this road
daily but hadn?t seen the hole before.
The law of West Virginia is well established that the State is neither an
insurer nor a guarantor of the safety of motorists travelling on its highways. Adkins vs. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). For the respondent to be guilty of
negligence, proof of actual or constructive notice of the defect in the road is
required. Davis Auto Parts vs. Dept.
of Highways, 12 Ct.Cl. 31 (1977).
There is no evidence in the record of any
66 REPORTS
STATE COURT OF CLAIMS [W. VA.
notice to the respondent, and the
simple existence of a defect in the road does not establish negligence per Se.
See Bobo vs. Dept. of Highways, 11 Ct.Cl. 179 (1977). Since negligence has not been
proven, this claim must be disallowed. Duskey
vs. Dept. of Highways, 13
Ct.Cl. 401 (1981).
Claim disallowed.
Opinion issued November 9, 1981
DONALD E. PLATT AND
LINDA L. PLATT
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-1O1)
Claimant Linda L. Platt appeared
in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
GARDEN, JUDGE:
In the early evening of March 23, 1981, the claimants were travelling down Van
Voorhis Road in Morgantown, West Virginia, a road maintained by the respondent,
in their 1975 Volkswagen Rabbit. They had lived in the area for about ten months
and both were thoroughly familiar with this section of Van Voorhis Road,
travelling it daily to and from work. The road at the point of the accident is
two-laned.
Mrs. Platt testified that she and her husband were aware of the existence of
three rather large potholes in a row on the right-hand side of their lane of
travel, the same having been in existence for two or three weeks prior to the
accident. As they approached these holes at a speed of 25 to 30 miles per hour,
they observed three vehicles approaching from the opposite direction. With a
very narrow berm to their right, they were prevented from taking any evasive
action, although Mrs. Platt stated that her husband was ?gearing down? in order
to rcduce his speed. The right rear wheel of their car struck the middle
pothole, ruining the tire and rim, and knocking the car
W. VA.]
REPORTS STATE COURT OF CLAIMS 67
out of alignment. In addition to the
cost of repairs, Mr. Platt, a salesman, missed two and a half days of work due
to lack of transportation. Mrs. Platt testified that neither she nor her
husband had ever called the respondent?s headquarters to complain about these
potholes.
Proof of actual or constructive notice is a prerequisite of establishing
negligence on the part of the respondent. Davis
v. Department of Highways, 12 Ct.Cl.
31 (1977); Cummings v. Department of
Highways, 12 Ct.Cl. 59 (1977). Such
proof cannot be found in the record in this claim. The case of Adkins v. Sims, 131 W.Va. 645, 46 S.E.2d 81 (1947), clearly holds that the State is
neither an insurer nor a guarantor of the safety of motorists using its
highways. For these reasons, this claim must be denied.
Claim disallowed.
Opinion issued November 9, 1981
JIMMY POLK
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-132)
No appearance by claimant.
Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damage to claimant?s automobile in
the amount of $392.67 was caused when a road sign belonging to the respondent
fell and struck the right front fender and windshield of the vehicle; that this
occurred on Prince Street in Beckley, Raleigh County, West Virginia, highway
owned and maintained by the respondent; that the respondent?s negligence in
failing to properly secure the sign
68 REPORTS
STATE COURT OF CLAIMS [W. VA.
was the proximate cause of the
accident and resultant damage, the Court finds the respondent liable, and makes
an award to the claimant in the amount stipulated.
Award of $392.67.
Opinion issued November 9, 1981
DANIEL SERGE, JR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-95)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
Shortly after midnight on March 20, 1981, the claimant was operating his new
Chevrolet Citation automobile in a southerly direction on Route 250 between
Farmington and Fairmont in Marion County, West Virginia. He was returning from
his place of employment at Consolidation Coal Company to his home in Fairmont.
The weather conditions were very bad in that the roads were icy and at least
one inch of snow had fallen. The claimant was following another car on this
two-lane road when he observed a northbound truck which appeared to be
spreading cinders or salt on the highway.
Upon observing the approaching truck, which was travelling, in the opinion of
the claimant, at a speed of 40 to 45 miles per hour, the claimant moved to the
right of his lane of travel and came to a complete stop with both of his right
wheels on the berm. As the truck, with activated flashing lights, passed
claimant?s car, salt and/or cinders were thrown against his car, damaging it to
the extent of $139.05. Claimant candidly admitted that he did not observe any
sign or logo on the truck identifying it as a vehicle belonging to the respondent,
but
W. VA.]
REPORTS STATE COURT OF CLAIMS 69
he was sure, by reason of the color of
the vehicle, that it was the respondent?s vehicle. The respondent, in its
Answer, while not admitting that the subject truck was one of its units, did
not deny ownership. Furthermore, the respondent offered no evidence at the
hearing to dispute the ownership of the vehicle.
The Court, being of the opinion that the claimant did establish by a
preponderance of the evidence that the offending truck was owned and operated
by the respondent, and that its operator was negligently operating it at an
excessive speed under the conditions then prevailing, makes an award to the
claimant in the amount of $139.05.
Award of $139.05.
Opinion issued November 9, 1981
RICHARD A. SPOTLOE
vs.
ADMINISTRATIVE OFFICE OF THE
SUPREME COURT OF APPEALS
(CC-80-223)
Mark D. Nigh, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
In 1976, claimant Richard A. Spotloe and William Dadisman were elected
magistrates in Barbour County, West Virginia. In 1975, Barbour County had a
population of 15,126, and in 1980, the population had increased to 16,400. The
election of two magistrates was proper, for W.Va. Code ?50-1-2 provides, inter
alia. that in each county which has less than thirty thousand in population,
there shall be elected two magistrates.
On June 1, 1978, Magistrate Dadisman resigned, and his successor, Magistrate
Joseph E. Moats, was not appointed until
70 REPORTS
STATE COURT OF CLAIMS [W. VA.
December 1, 1978. Magistrate Moats
resigned on February 11, 1980, and his successor, Linda Stafford, was not
appointed until July 1, 1980. As a result, the claimant was the only acting
magistrate in Barbour County from June 1, 1978 to December 1, 1978, and again
from February 11, 1980 to July 1, 1980, for a total of six months and 18 weeks.
Consequently, the claimant is requesting additional compensation for the period
of time that he was the only acting magistrate in Barbour County.
With respect to salaries to magistrates, W.Va. Code ?50-1-3, as it existed
prior to July of 1980, provided as follows:
?The salary of each magistrate shall be paid by the State. Magistrates who
serve less than ten thousand in population shall be paid annual salaries of ten
thousand dollars. Magistrates who serve ten thousand or more in population but
less than fifteen thousand in population shall be paid annual salaries of
fourteen thousand dollars. Magistrates who serve fifteen thousand or more in
population shall be paid annual salaries of eighteen thousand dollars. For the purpose of determining the population served
by each magistrate, the number of magistrates authorized for each
county shall be divided into the population of each county. Magistrates shall be paid once a month.? (Emphasis
supplied.)
As can be observed, magistrates who serve more than 5,000 in population but
less than 10,000 in population shall be paid annual salaries of $10,000.00.
However, the above-quoted statute sets forth the method of determining the
population served, and that is by dividing the number of authorized magistrates
into the population of the county. Two magistrates were authorized by statute
to serve in Barbour County. Dividing that figure into the total population, it is
obvious that the claimant received his proper salary, i.e., $10,000 per year.
For the reasons stated above, the claim is disallowed.
Claim disallowed.
W. VA.J REPORTS
STATE COURT OF CLAIMS 71
Opinion issued November 9, 1981
STATE FARM MUTUAL AUTOMOBILE
INSURANCE COMPANY, AS SUBROGEE
OF BARBARA A. HOWE
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-349)
James A. Smith, Assistant Claims Superintendent for State Farm,
appeared on behalf of claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
South York Street on Wheeling Island in Wheeling, West Virginia, generally runs
in a north-south direction. It passes beneath 1-70 which is elevated over
Wheeling Island and runs in an east-west direction. To keep trespassers away
from the piers and abutments of 1-70, the respondent erected a chain-link fence
on both sides of South York Street. On the west side of South York Street, the
fence stands eight feet west of and parallel to the westerly curb line of South
York Street. To provide ingress and egress to the fenced-off area, the
respondent installed a 12-foot gate in the chain-link fence. As a result, when
the gate is fully opened in the direction of South York Street, it extends
three feet into South York Street.
On July 8, 1980, the claimant?s insured, Barbara A. Howe, legally parked her
1980 Chevrolet pickup truck on the west side of South York Street. Sometime
later, Ms. Howe returned to her truck and found that the gate had been opened
and was resting against the right side of her truck. Ms. Howe was unable to
state who had opened the gate, which resulted in damage to the right side of
her truck in the amount of $154.50. Ms. Howe was paid the amount of the damage
under the comprehensive provision of her insurance policy with the claimant.
She also signed a subrogation receipt on March 5, 1981, authorizing the
claimant to file this claim against the respondent in order to recoup its loss.
72 REPORTS
STATE COURT OF CLAIMS [W. VA.
Lara Bishop, respondent?s supervisor of
interstate employees and facilities in Ohio County, testified on behalf of the
respondent. She testified that she was quite familiar with the gate in question
and that it was the respondent?s policy to keep the gate locked; however, due
to vandalism, sometimes the lock would be broken. Ms. Bishop recalled being
notified by a Mr. Graham, who apparently had been contracted by Ms. Howe, that
the gate was unlocked, and that she, Ms. Bishop, sent a man over and had a new
lock put on the gate. She further testified that she had no prior knowledge
that the gate was unlocked.
In order to sustain an award in this case, it is necessary for a claimant to
prove by a preponderance of the evidence that the respondent was guilty of
negligence which proximately caused the damage to the vehicle of claimant?s
insured. There was a complete failure on the part of the claimant to establish
such negligence; therefore, this claim must be disallowed.
Claim disallowed.
Opinion issued November 9, 1981
RONALD P. STEWART
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-65)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
After nightfall on February 9, 1981, the claimant was operating his automobile
in a westerly direction on Route 91 in the Village of Bethlehem in Ohio County,
West Virginia, when
W. VA.]
REPORTS STATE COURT OF CLAIMS 73
both of his right wheels struck a
large pothole on the right-hand side of the west lane of travel. According to
the testimony, the hole was almost unobservable because of the configuration of
the road at that particular point.
The claimant?s testimony indicated that the hole was at least two feet in
diameter and at least two feet deep. He stated that he was unaware of its
existence and did not see the hole until the impact. The claimant further
testified that he was travelling at a speed of 25 miles per hour in a
30-mile-per-hour speed zone. As a result of this incident, damages in a total
amount of $259.76 were inflicted upon claimant?s car.
William B. Leasure, a police officer employed by the Village of Bethlehem,
testified on behalf of the claimant. He indicated that he was on duty on the
evening of the accident and was following the claimant on Route 91. Officer
Leasure confirmed the fact that the claimant was not exceeding the speed limit.
He also confirmed the fact that it was almost impossible to detect the presence
of the hole before striking it. Officer Lea- sure testified that the hole had
been in existence for at least three weeks prior to February 9, 1981, and that
he and the Mayor of the Village of Bethlehem had struck the hole on several
occasions. He further testified that numerous complaints had been telephoned,
including one of his own, to the respondent, but to no avail.
This Court has consistently held that the respondent is not an insurer of the
safety of persons using the highways of this State. However, where it has been
demonstrated that the respondent had actual knowledge of a dangerous defect in
a highway and took no action to remedy the defect, an award has been made. The
evidence in this claim clearly demonstrates that the respondent had notice of
the defect and negligently failed to repair it. For that reason, an award of
$259.76 is made in favor of the claimant.
Award of $259.76.
74 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued November 9, 1981
RANSON BAILEY WARD AND
DEBRA DAWN WARD
vs.
DEPARTMENT OF HIGHWAYS
(CC-81- 145)
Claimant Ranson Bailey Ward appeared
in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Ranson Bailey Ward filed this claim against the respondent in the amount of
$255.42 for damages to the 1979 Chevrolet Chevelle automobile owned by the
claimant and his wife.
Testimony revealed that the automobile was titled in the names of Ranson Bailey
Ward and Debra Dawn Ward. The Court, on its own motion, amended the claim to
include Debra Dawn Ward as an additional claimant.
At approximately 11:00 a.m. on April 2, 1981, claimant Ranson Bailey Ward was
driving the automobile southerly on W.Va. Route 61 between Montgomery and Oak
Hill, West Virginia, at 40-45 miles per hour. He stated that the weather
conditions were ?beautiful, sunny and nice? and the road conditions were
?excellent.? A pickup truck was proceeding northerly in the opposite lane of
the highway. There were no vehicles in front of or behind Mr. Ward. As the two
vehicles passed, the Ward automobile struck a hole on the right-hand side of
the road about eight inches inside the white exterior line. The right front and
rear tires burst and the rims were damaged.
Every user of the highways travels thereon at his own risk. The State does not
and cannot assure him a safe journey. Adkins
v. Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947). For the respondent to be held liable for damages caused by road defects
of this type, the claimant must prove that the respondent
W. VAJ REPORTS
STATE COURT OF CLAIMS 75
had actual or constructive knowledge of the existence of the defect and a
reasonable amount of time to take suitable corrective action. Davis v. Dept. of Highways, 11 Ct.Cl. 150 (1976). Since the claimant did not meet that burden
of proof, this claim is disallowed.
Claim disallowed.
Opinion issued November 25, 1981
COUNTY COMMISSION OF WEBSTER COUNTY
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-81-168)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks an
award of $3,020.00 for the payment of jury commissioners and special jury
commissioners in accordance with West Virginia Code ?52-1-3, which states, in
part:
?Jury commissioners shall receive as compensation for their services, while
necessarily employed, an amount to be fixed by the judge of the circuit court,
or the chief judge thereof, in accordance with rules of the supreme court of
appeals, which shall be payable out of the state treasury upon orders of the
circuit court or the chief judge thereof.?
The respondent, in its Answer, admits the validity and amount of the claim. As
sufficient funds remained in respondE?nt?s appropriation for the fiscal year in
question from which
76 REPORTS
STATE COURT OF CLAIMS [W. VA.
the obligation could have been paid,
the Court hereby makes an award to the claimant in the amount of $3,020.00.
Award of $3,020.00.
Opinion issued November 25, 1981
KATHLEEN R. FEWELL
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-153)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant herein seeks an award of $62.38, which was the cost of replacing a
tire ruined as the result of striking a pothole on Route 60 in South
Charleston, West Virginia, at about 8:30 p.m. on May 3, 1981.
The claimant testified that she was travelling on this four- lane highway in
the right-hand lane of the two lanes reserved for westbound traffic; that she rarely
drove this particular highway; that she was proceeding at a speed of 40 to 45
miles per hour, but was slowing down as she approached the stoplight at the
Montrose intersection; and that she did not observe the pothole before striking
it with her right front tire. Claimant testified that the pothole extended from
the berm on the right into her lane of travel. There was no testimony regarding
the length of time this particular defect had existed in the highway, nor was
any evidence introduced indicating that the respondent had actual knowledge of
the existence of the defect. The claimant did not stop after striking the
pothole, and thus could not testify as to its size.
Under the facts as set forth above, and in accordance with myriad prior
decisions of this Court, this claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 77
Opinion issued November 25,
1981
DIANA LYNN HACKNEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-139)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant?s 1972 Porsche automobile was damaged on February 21, 1981, at about
5:30 p.m., when she struck a pothole on Campbell?s Creek Road, a two-lane,
blacktop road in Kanawha County, West Virginia. Her car was repaired by Bert
Wolfe Ford for the sum of $298.70, and she is seeking an award in this amount
on the theory that the respondent was negligent in failing to properly maintain
this road.
Ms. Hackney testified that she was returning to her home in Blount from her
place of employment in Charleston. She quite candidly admitted that she was
aware of the existence of this hole near the edge of her lane of travel, but
had been able to avoid it on prior occasions by steering to her left toward the
center line of the road. On the evening of the accident, however, the road was
covered by several inches of water, according to the claimant?s testimony. This
water prevented her from observing the exact location of the hole. To compound
the problem, she could not steer to her left because a vehicle was approaching
from the opposite direction. The claimant neither testified as to the
dimensions of the hole, nor stated whether she had ever notified the respondent
of the existence of the hole prior to the accident.
By reason of the foregoing, the Court is of the opinion that the claimant has
failed to establish actionable negligence on the part of the respondent. On the
contrary, the evidence establishes that the accident and resultant damages to
the claimant?s car was due to her own negligence. For these reasons, this claim
is disallowed.
Claim disallowed.
78 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued November 25,
1981
RONALD H. HARPER AND
SARAH E. HARPER
vs.
DEPARTMENT OF HIGHWAYS
(CC-80- 134)
Walter L. Wagner, Jr., Attorney at Law, for claimants.
W. Douglas Hamilton, Attorney at Law, for respondent. RULEY, JUDGE:
The claimants have asserted this claim in the sum of $10,000.00 for damages to
unimproved real property allegedly caused by the respondent. The lot or parcel
of real property to which the claim relates is a lot containing 0.46 acre which
the claimants had surveyed in October, 1978. It is part of a larger tract of
8.8 acres located upon the waters of Tuppers Creek in Kanawha County, which the
claimants bought in 1973 for $6,000.00. The lot lies between a horseshoe curve
in State Local Service Route 21/10 SO that both its west end and its east end abut upon that
route. It also lies on a hillside, its west end being approximately 70 feet
higher than its east end. It is 220 feet long on its south side and about 170
feet long on its north side. There is a 24-inch culvert under the roadway at
about the midpoint of each end of the 1st.
The burden of the claim is that, in the last four or five years, there has been
an increase in the volume of surface water draining onto the west end of the
lot, which has increased, in both depth and width, the size of a ditch which
runs through the lot. The undisputed evidence, however, is that the respondent
has made no change in the roadway or the culverts since the claimants bought
their property. In addition, it is undisputed that the ditch is a natural
drainage course. Although the volume of surface water flowing through the ditch
and the lot may have increased in recent years, there is no evidence from which
the Court could infer that such increase is attributable to any legal fault on
the part of the respondent. For those reasons, the claim must be denied.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 79
Opinion issued November 25, 1981
L. P. KING, JR. AND EVELYN KING
vs.
DEPARTMENT OF HIGHWAYS
(CC?8 1-6 1)
John S. Hrko, Attorney at Law, for claimant.
Nancy J. A 11ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
At about 10:00 a.m. on November 17, 1980, th claimant, L. P. King, Jr., was
operating a 1979 Thunderbird on Route 54 in Raleigh County, West Virginia. The
automobile was owned by his wife, Evelyn King, who is also a claimant. Mr.
King, a resident of Mullens, was taking his young son to the YMCA in Beckley.
In proceeding from Lester to Glen White, the automobile was severely damaged
when it struck a pothole near the edge of the road in Mr. King?s lane of
travel. A written stipulation was filed by counsel for the parties reflecting
that the cost of repairing the automobile amounted to $645.14. The claimant
spent a considerable length of time effecting emergency repairs to the car and
was unable to report for his shift work with the N & W Railway Co. The
stipulation further reflects that as a result he lost one day?s wages in the
amount of $80.10.
Mr. King testified that he was familiar with Route 54 between Mullens and
Beckley as a result of travelling that way a few times a week. As he proceeded
down a hill between Lester nd Glen White and into a turn to his right at a
speed of between 35 and 40 miles per hour, he encountered two or three potholes
within a distance of 20 to 25 feet of each other, located on the right-hand
side of his lane of travel. He indicated that he was unable to avoid the holes
by moving to his left because another vehicle was approaching from the opposite
direction. As a result, he struck one of the holes, which he estimated to be 14
to 18 inches in diameter and 8 to 9 inches in depth. According to Mr. King, the
hole covered the width of the white line on the right-hand side of his lane and
extended an addi
80 REPORTS STATE
COURT OF CLAIMS [W. VA.
tional 6 inches into his lane of travel. Mr. King further testified that he was
aware of the existence of these holes in that he had observed them for two
months prior to the accident. He stated that he had not reported the holes to
the respondent because he was a resident of Wyoming County, and he felt sure
that someone from Raleigh County would have reported them.
Jennings Martin, respondent?s Raleigh County supervisor, testified on behalf of
the respondent. He indicated that his office had not received any specific
complaints concerning potholes on Route 54 in the Glen White vicinity prior to
November 17, 1980. Mr. Martin also stated that, according to his records, his
crew had conducted routine maintenance on October 10, 1980, which included
patching on Route 54 in the Glen White area. On cross-examination, Mr. Martin
testified that a week after the maintenance work had been performed, he had
inspected the work and did not observe any potholes at any place on Route 54.
While he would not deny that the potholes might have been present on November
17, 1980, he stated that he was unaware of it.
The case of Adkins v. Sims, 130 W. Va. 645, 46 S.E.2d 81 (1947), has often been
cited by the Court as the leading case in West Virginia for establishing the
legal principle that the State is neither an insurer nor a guarantor of the
safety of motorists travelling upon its highways. We have further held, in the
many pothole claims that have been presented over the years, that in order to
predicate liability upon the respondent, the claimant must establish notice,
either actual or constructive, to the respondent of the existence of a defect
or pothole. Davis v. Dept. of
Highways, 11 Ct.Cl. 150 (1976); Spataf ore v. Dept. of Highways, 14 Ct.Cl. 18 (1981); Piazza v. Dept. of Highways, 14
Ct.Cl. 65 (1981).
Following these principles, the Court is of the opinion that the claimant has
failed to establish by a preponderance of the evidence a case of liability
against the respondent; accordingly, an award is hereby denied.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 81
Opinion issued November 25, 1981
HERBERT O?DELL PARSONS, III
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-162)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
On May 8, 1981, the claimant was operating his 1981 Subaru Brat truck on a
highway maintained by the respondent between Cass and Stony Bottom in
Pocahontas County, West Virginia. It was mid-afternoon in nice weather, and the
respondent?s crew was engaged in clearing brush and timber from its right of
way, using a mulching machine in the operation. As a result, a certain amount
of debris and cuttings were left on the highway. The respondent?s crew directed
the claimant to proceed through the debris-covered area, which was about 1/2 mile in length. The debris covered both lanes, and a
small piece of tree cutting punctured one of the tires on the claimant?s
vehicle. The piece of cutting was introduced into evidence, and it measured
about 2 1/2 inches in length and less than 1/4 inch in diameter.
During a project such as the clearing of brush and timber, it is inevitable
that a certain amount of debris will remain on the highway. The small particle
of wood that punctured claimant?s tire, which cost $56.65 to replace, should
have been equally observable to the claimant and the employees of the respondent.
The Court, being of the opinion that the claimant has failed to establish
negligence on the part of the respondent, disallows this claim.
Claim disallowed.
82 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued November 25, 1981
TAMMY LYNN PRIESTLEY, AN INFANT
WHO SUES BY HER MOTHER, CAROLYN PRIESTLEY,
AND CAROLYN PRIESTLEY
vs.
DEPARTMENT OF HIGHWAYS
(0-732)
Robert N. Bland, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
This claim grows out of an accident which happened at about 2:30 p.m. on
February 29, 1972, when Tammy Lynn Priestley, who then was ten years of age and
a fifth-grade student at Taft Elementary.. School, stepped into a hole in the
sidewalk along Aithea Street in Charleston. The hole apparently was related to
a water line or meter and had been covered by a circular steel frame with a
small lid or grating which fit inside
it. At the time of the accident, the surrounding sidewalk was broken in
numerous places, a part of the steel frame was missing, and the lid or grating
also was missing. Tammy?s only significant injury consisted of a laceration
about one inch long above her right knee which was closed with six sutures.
Medical expense incurred as of the time of the hearing was under $100.00, but
there was evidence that the cost of removing the residual scar would be about
$1,000.00. Damages in the sum of $10,000.00 are sought.
It was stipulated that, as of February 29, 1972, the respondent had acquired
the properties adjacent to Aithea Street for interstate highway construction,
and it was proven that buildings on those properties had been, and were being,
demolished by contractors to whom the respondent had awarded a contract for
that purpose.
There was evidence that this claim previously had been prosecuted in the
Circuit Court of Kanawha County against the West Virginia Water Company, the
Cleveland Wrecking Company, and the City of Charleston in Civil Action Number
24,894-C. It was proven that, in connection with that case, a
W. VA.] REPORTS
STATE COURT OF CLAIMS 83
general release was executed on February 26, 1979, for the sum of $1,000.00,
and that the action was dismissed with prejudice. Despite the fact that on that
date Tammy still was a minor, there apparently was no judicial approval of that
settlement.
While the hole in question certainly constituted a defect in the sidewalk,
there is no evidence before the Court from which it can infer that the
respondent had actual or constructive knowledge of it, and, in the exercise of
ordinary care, should have repaired it before February 29, 1972. For those
reasons, the Court cannot conclude that the respondent was guilty of negligence
which proximately caused the accident and the resulting injury, and must
disallow this claim. Other problems in the proof which may appear from the
foregoing discussion of the claim are not considered.
Claim disallowed.
Opinion issued December 9, 1981
BUCKEYE GAS PRODUCTS COMPANY
vs.
FARM MANAGEMENT COMMISSION
(CC-81-423)
JENKINS CONCRETE PRODUCTS CO.
vs.
FARM MANAGEMENT COMMISSION
(CC-81- 187)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims against the Farm Management Commission were submitted for decision
upon the pleadings. The claimants seek payment for various goods and services
furnished to the respondent as follows:
Claimant Amount
Buckeye Gas Products Company $ 95.39
Jenkins Concrete Products Co $ 940.50
84 REPORTS STATE
COURT OF CLAIMS [W. VA.
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
While we feel that these claims should, in equity and good conscience, be paid,
we further believe that awards cannot be made, based on our decision in Airkem
Sales and Service, et al. v. Department of Mental Health, 8 Ct.CL 180
(1971).
Claims disallowed.
Opinion issued December 9, 1981
E. L. JIMENEZ, M.D., ET AL.
vs.
DEPARTMENT OF CORRECTIONS
(CC-81-320)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims against the Department of Corrections were submitted for decision
upon the pleadings. The claimants seek payment for various goods and services
furnished to the respondent as follows:
Claim Against West Virginia
Claim No. Prison for Women Amount
CC-81-320 E. L. Jimenez, M.D $ 860.00
Claims Againsi Huttonsville
Claim No. Correctional Center Amount
CC-81-394 Elkins Dental Lab $ 67.00
CC-81-420 Xerox Corporation $ 2,801.94
Claims Against Industrial
Claim No. School for Boys Amount
CC-81-395 Equitable Gas, Inc. $ 45,831.75
CC-81-407 Union Oil Company of California $ 2,554.93
W. VA.] REPORTS
STATE COURT OF CLAIMS 85
Claim No. Claims Against Anthony
Center Amount
CC-81-391 White Sulphur Pharmacy, Inc.
- $ 399.30
CC-81-392 Greenbrier Physicians, Inc. $ 50.00
CC-81-393 Craig Motor Service Co., Inc. $ 256.35
CC-81-403 Seneca Mental Health-Mental
Retardation Council, Inc. $ 3,000.00
CC-81-405 Union Oil Company of California $ 1,149.19
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
While we feel that these claims should, in equity and good conscience, be paid,
we further believe that awards cannot be made, based on our decision in Airkem Sales and Service, et al. v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claims disallowed.
Opinion issued December 9, 1981
EUGENE J. SELLARO, JR.
vs.
OFFICE OF THE STATE AUDITOR
(CC-81- 138)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant is an attorney who served as counsel for criminal indigents in
juvenile, misdemeanor, or felony proceedings pursuant to the provisions of West
Virginia Code Chapter 15, Article 11. Claimant?s fees were denied by the
respondent because the fund was exhausted.
The factual situation in this claim is identical to that in Richard K. Swartling, et al. v. Office of the State
Auditor, issued on November 5, 1979.
Accordingly, an award is made in the amount indicated below to the claimant.
Award of $433.95.
86 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 16, 1981
WILLARD CASTO
vs.
STATE AUDITOR?S OFFICE
(CC-79-116)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
The claimant seeks to recover damages allegedly caused by respondent?s
negligence in certifying a certain parcel of real estate for sale to the
Commissioner of Delinquent and Forfeited Lands.
The alleged negligent certification led to litigation between claimant and
Marlea Corporation, the owner of the real property in question, which
culminated in the West Virginia Supreme Court of Appeals in Marlea Corp. v.
Casto, W.Va.
242 S.E.2d 923 (1978). The facts of the case were set forth in the Supreme
Court?s opinion, as follows:
?In 1951, W. D. Burrus and his wife bought 1.6 acres in Kanawha County. In 1952
they jointly conveyed .18 acres of the 1.6 acre tract to Ida Rupp. The entire
tract remained assessed to Burrus until 1966 when Burrus, his wife, and Ida
Rupp conveyed to Marlea Corporation what was intended to be the entire 1.6
acres originally purchased by the Burruses. An erroneous metes and bounds
description appears in the deed to Marlea which encompassed only the .18 acre
tract conveyed from Burrus to Rupp instead of the full 1.6 acres conveyed by
the general description.
After recordation of the deed to Marlea, the assessor, apparently relying upon
the incorrect metes and bounds description rather than the general description,
both contained in the deed to Marlea, assessed .18 acre in the name of Marlea
Corporation and assessed .88 acre in the name of Burrus. As a result of the two
land book entries, Marlea
W. VA.] REPORTS
STATE COURT OF CLAIMS 87
did not receive a tax ticket for the .88 acre portion of the parcel. Taxes were
not paid on this portion in 1966 and 1967, and the parcel was purchased for the
state by the sheriff at the auctions for each of these years.
The record shows that Marlea?s principal officer, Lee Lewis, and his lawyer, A.
T. Ciccarello, went to the auditor?s office in February of 1969 to attempt to
redeem the property. Carl Fisher, Assistant to the Director of the Land
Department in the auditor?s office, testified by deposition that he remembered
when the two came to his office to redeem the property and to pay all the
taxes, that there was some error, and that all the taxes were not paid. He
later, at a hearing held subsequent to this deposition, offered the incredible
testimony that the defendant ?wasn?t interested? in redeeming the land in
question.
Appellant?s [Marlea] most forceful exhibit is the Certificate of Redemption
acquired from the auditor. This certificate dated February 28, 1969, notes the
receipt of $408.09 ?in full payment of taxes, interest and costs due, for the
years shown, against the land described . . . This
certificate is a receipt for the money paid and a release of the State?s title
or claim to the land redeemed for the years shown.? The years shown are 1966 and
1968 for property assessed in the name of ?Burrus, W. D. and B. R.? and in the
name of ?Marlea Corporation, Inc.?
Lewis and Ciccarello later checked to make certain that the redemption was
recorded in the assessor?s records as well as in the auditor?s office at the
Capitol. Pages from the assessor?s land books show the notation ?redeemed from
auditor 1966 thru 1968 ext.? for both the Marlea and Burrus parcels.
Nevertheless, the auditor certified to the Commissioner of Delinquent and
Forfeited Lands the .88 acre for nonpayment of taxes and upon certification the
Commissioner sold for $1,275.00 the .88 acre to appellee Casto for nonpayment
of 1967 taxes.
On August 30, 1971, the parcel was conveyed to Casto by the Deputy Commissioner
of Forfeited and Delinquent
REPORTS STATE
COURT OF CLAIMS [W. VA.
Lands. Marlea filed suit to enjoin Casto from interfering with the property and
to set aside this deed. Casto filed a crosscomplaint for rents owed. The
circuit court referred the case to Riggs, a commissioner, who found that the
sale to Casto by the Deputy Commissioner of Forfeited and Delinquent Lands was
in compliance with the Code and served to convey unto Casto the .88 acre in
dispute. The Commissioner?s findings were ratified and adopted by the circuit
court.?
The Supreme Court held that Marlea had indeed redeemed its property and that
the Deputy Commissioner of Forfeited and Delinquent Lands had no jurisdiction
to sell land that has been redeemed. The case was remanded for an accounting.
Ultimately, it was settled by the parties and a release was executed. The
claimant seeks recovery of the purchase price paid, real property taxes and
business and occupation taxes paid, attorney fees incurred, the settlement
payment made by him to Marlea Corporation and other incidental expenses that
the claimant incurred while he possessed the subject property.
West Virginia Code, ?11A-4-25, provides a legal remedy by which the claimant
may recover the purchase money which he paid, as follows:
?1lA-4-25. Return of purchase money.
Whenever, after sale and before confirmation thereof, it is discovered that the
land sold was nonexistent, or that it had been the subject of a duplicate or
improper assessment, or was transferred to others under the provisions of
section 3, article XIII of the Constitution, the purchaser shall be entitled to
a return of the purchase money. Upon request of a purchaser so entitled, it
shall be the duty of the deputy commissioner to apply to the circuit court for
an order directing the sheriff to return the purchase money. If satisfied that
the application is proper, the court shall enter the order applied for, but no
costs shall be taxed in connection with such an application. If the ground for
entering the order was that the land was nonexistent or the subject of a
duplicate assessment, the
W. VA.] REPORTS
STATE COURT OF CLAIMS 89
order shall also direct the assessor to drop the erroneous entry of such lands
from the land books.?
West Virginia Code, ?11-1-2A, provides a legal remedy for the recovery of taxes
improperly required. For those reasons, those facets of the claim are expressly
excluded from this Court?s jurisdiction by West Virginia Code, ?14-2-14(5).
All of the remaining items of damage claimed relate either to costs of litigation
or to ownership and maintenance of the property. If this is viewed as a tort
claim, the Court could not conclude that such items of expense were proximately
caused by the respondent?s error. If this is viewed as a contract claim, those
items of expense could not be considered ?forseeable? and, for that reason,
their recovery would be precluded by the time honored doctrine enunciated in Hadley v. Baxendale, 89 Exch. 341. Accordingly, the claim must be denied.
Claim disallowed.
Advisory Opinion issued December 16, 1981
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF CORRECTIONS
(CC-81-388)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for an advisory determination pursuant to West
Virginia Code ?14-2-18. The facts indicate that Huttonsville Correctional
Center underpaid its statutory contribution to the claimant for fiscal year
1980-81 in the amount of $24,996.90. Claimant also seeks interest on this
amount at the rate of one percent per month pursuant to West Virginia Code
?21A-5-17. The accrued interest as of the date of an itemized statement from
the Department of Employ-
90 REPORTS STATE
COURT OF CLAIMS [W. VA.
ment Security to Huttonsville amounted to $1,603.06, for a total claim of
$26,599.96.
In its Answer, the respondent admits the validity of the principal obligation
set forth in the Notice of Claim, but also states that there were not
sufficient funds in its appropriation for the fiscal year in question from
which the obligation could have been paid. While such a claim should, in equity
and good conscience, be paid, an award cannot be made, based on the Court?s
decision in Airkem Sales and Service, et al. v.
Dept. of Mental Health, 8 Ct.Cl.
180 (1971).
With respect to the claim for accrued interest, the Court concludes that, as
the restrictions of Code ?14-2-12 prevent an award of interest unless a claim
arises under a contract specifically providing for the payment of interest, the
respondent is not liable therefor.
The Clerk of this Court is hereby directed to file this opinion and to forward
copies thereof to the respective department heads of claimant and respondent.
Opinion issued December 16, 1981
JAMES W. DIXON AND
DORIS A. DIXON
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-365)
Richard L. Vital, Attorney at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted for decision upon a written stipulation filed by the
parties which revealed the following facts. Claimants are the owners of a
residence and tract of land on Ousley Gap Road, a highway owned and maintained
by the respondent in the vicinity of Barboursville, Cabell County, West
Virginia.
W. VA.] REPORTS
STATE COURT OF CLAIMS 91
In November of 1978, the Department of Highways cut into a hillside on Ousley
Gap Road in the vicinity of claimants? property. In so doing, the respondent
broke a water line, causing a saturated soil condition in the area.
A slide occurred on the claimants? property, damaging it in the amount of
$14,500.00. Said damages were the direct and proximate result of respondent?s
negligent cutting of the hillside.
Based on the foregoing, an award is made to the claimants in the amount agreed
upon by the parties.
Award of $14,500.00.
Opinion issued December 16, 1981
HOWARD UNIFORM COMPANY
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-81-367)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim submitted on the pleadings, claimant seeks payment of the sum of
$244.30 for two officers? blouses purchased by the respondent.
Respondent?s Answer admits the validity and amount of the claim, and states
that sufficient funds were available in its appropriation for the fiscal year
in question from which the obligation could have been paid. The Court therefore
makes an award of $244.30 to the claimant.
Award of $244.30.
92 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 16, 1981
LUNDIA, MYERS INDUSTRIES, INC.
vs.
BOARD OF REGENTS
(CC-81-356)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim submitted on the pleadings, claimant seeks payment of the sum of
$125.30 for the installation of book shelves at West Virginia State College.
As the respondent?s Answer admits the validity and amount of the claim, and as
sufficient funds remained in its appropriation for the fiscal year in question
from which the obligation could have been paid, the Court makes an award of
$125.30 to the claimant.
Award of $125.30.
Opinion issued January 28, 1982
BENNETT PUBLISHING COMPANY, ET AL.
vs.
DEPARTMENT OF CORRECTIONS
(CC-81-444)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims against the Department of Corrections were submitted for decision
upon the pleadings. The claimants seek payment for various goods and services
furnished to the iespondent as follows:
W. VA.] REPORTS
STATE COURT OF CLAIMS 93
Claim against West Virginia
Claim No. State Penitentiary Amount
CC-81-444 Bennett Publishing Company $ 100.91
Claims against West Virginia
Claim No. Prison for Women Amount
CC-81-438 Greenbrier Physicians, Inc. $ 1,348.50
CC-81-460 T. H. Mirza, M.D., Inc -- $ 115.00
Claims against Huttonsville
Claim No. Correctional Center Amount
CC-81-439 Clarksburg Drug Company $ 714.83
CC-81-448 Physicians Fee Office $ 823.00
CC-81-455 E. R. Squibb & Sons, Inc. $ 214.60
CC-81-462 Charleston Area Medical Center $ 299.50
CC-81-398 Matthew Bender & Company $ 1,459.00
Claim No. Claims against Anthony Center Amount
CC-81-401 Taylor County Commission - $ 248.00
CC-81-456 Exxon Company, USA $ 229.74
CC-81-461 West Virginia School of
Osteopathic Medicine $
6,290.60
CC-81-464 West Virginia School of Osteopathic
Medicine Clinic, Inc $
20,305.17
CC-82-5 Greenbrier Valley Hospital $ 700.17
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
While we feel that these claims should, in equity and good conscience, be paid,
we further believe that awards cannot be made, based on our decision in Airlcem
Sales and Service, e at. v. Department of Mental Health, 8 Ct.Cl. 180
(1971).
Claims disallowed.
94
REPORTS STATE COURT OF CLAIMS
[W. VA.
Opinion issued
January 28, 1982
MOTOR CAR SUPPLY COMPANY, ET AL.
vs.
FARM MANAGEMENT COMMISSION
(CC-81-346)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims against the Farm Management Commission were submitted for decision
upon the pleadings. The claimants seek payment for various goods and services
furnished to the respondent as follows:
Claim No. Claim Amount
CC-81-346 Motor Car Supply Company $ 67.46
CC-81-453 Southern States Cooperative $ 455.31
CC-81-466 Bill Henning, Inc. $ 25.00
CC-82-2 Superior Parts Service, Inc. - $ 56.25
The respondent admits the validity and amounts of these
claims, but further alleges that sufficient funds were not available at the
close of the fiscal years in question from which the obligations could have
been paid.
While we feel that these claims should, in equity and good conscience, be paid,
we further believe that awards cannot be made, based on our decision in Airkem Sales and Service, et al. ??. Department of Mental Health, 8 Ct.Cl. 180 (1971).
Claims disallowed.
Opinion zssued December 18, 1981
STERL F. SHINABERRY
vs.
OFFICE OF THE STATE AUDITOR
(CC-81-142)
No appearance by claimant.
Henry C. Bias, Jr.. Deputy Attorney General, for respondent. PER CURIAM:
The claimant is an attorney who served as counsel for a
W. VA.]
REPORTS STATE COURT OF CLAIMS 95
criminal indigent in felony
proceedings pursuant to the provisions of West Virginia Code Chapter 51,
Article 11. For his services, claimant submitted a voucher for $1,571.10. The
respondent State agency has denied $71.10 of the claim based upon the fact that
this amount is in excess of the statutory limit imposed by West Virginia Code
?51-11-8. The amount of $1,500.00 was not paid by the respondent as the needy
persons fund from which this amount should have been paid was exhausted.
The Court has reviewed the facts here presented and denies the amount of $71.10
as the law governing this situation was enunciated by the Court in the case of George M, Cooper v. Administrative Office of the
Supreme Court of Appeals, 13
Ct.Cl, 394 (1981).
The remaining amount of this claim, $1,500.00, is hereby awarded to the
claimant in accordance with the decision rendered by the Court in Richard K. Swa.rtliing, et at. v. Office of 1,he State
Auditor, issued on November 5, 1979.
Award of $1,500.00.
Opinion issued February 1, 1982
A.B. DICK COMPANY
vs.
WORKMEN?S COMPENSATION FUND
(CC-81-323)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant seeks payment of the sum of $9,264.00 for merchandise delivered to the
respondent. The pleadings filed herein reveal that the respondent State agency
ordered 150 cartons of file film from the claimant. There was an overshipment
on the order of 48 cartons. Instead of returning the
96 REPORTS
STATE COURT OF CLAIMS [W. VA.
surplus cartons, the Workmen?s
Compensation Fund used the film in its operations.
Respondent?s Answer admits the claim?s validity, and states that sufficient
funds remained in its appropriation for the fiscal year involved from which the
obligation could have been paid. Accordingly, the Court makes an award to the
claimant in the amount requested.
Award of $9,264.00.
Opinion issued February 1, 1982
ONCIE E. ARCHER AND THE HEIRS OF
HOMER THOMPSON -
MISSOURI THOMPSON,
WILLIAM THOMPSON, TRUMAN THOMPSON,
GROVER THOMPSON, CHLOIE BATTEN,
NELLIE SUMMERVILLE, ETTA INGRAM,
ONCIE ARCHER, DORA LIFE, AND
HELEN LOCKHART
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-390)
Claimant Oncie E. Archer appeared in
person.
Nancy JAliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimants seek payment of the sum of $787.41 for damage to their property
resulting from negligent acts of the respondent. Originally filed by Oncie E.
Archer as sole claimant, the claim is hereby amended by the Court to reflect
the names of all those who have an interest in said property according to the
testimony produced at the hearing.
Claimants allege, and respondent does not deny, that in October of 1979,
employees of the Department of Highways were clearing space for a bus
turnaround on the property adjacent to claimants? farm on Route 1 in Wood
County, West Virginia. In the process of this excavation, respondent used heavy
equip-
W. VA.]
REPORTS STATE COURT OF CLAIMS 97
ment to tear down claimants? fence,
posts, and two hickory trees, and dug up and removed a certain amount of dirt
from the area.
No evidence was presented on behalf of the respondent to refute any of
claimants? testimony. It is therefore clear to the Court that claimants? losses
were a direct and proximate result of respondent?s negligent acts during the
period of construction involved. An award is made to the claimants in the
amount requested.
Award of $787.41.
Opinion issued February 1. 1982
STEVEN BELLMAN d/b/a
BASKIN-ROBBINS
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-36)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant filed this claim against the respondent for loss of business,
resulting from the construction of a highway.
The record indicates that the respondent had contracted with the Cameron
Construction Company to relocate and widen from two lanes to four lanes, West
Virginia Route 705 from the intersection of University Avenue and Patterson
Drive to Stewartstown Road in Morgantown, West Virginia. The construction work
included Chestnut Ridge Road parallel to the Suburban Lanes Shopping Center
where the claimant operated, under a franchise, a Baskin-Robbins store selling
ice cream, ice cream cakes, pies, and party items.
The claimant contends that the inability of customers to readily reach his
place of business during the construction caused a loss in his business of
$4,500.00.
98 REPORTS
STATE COURT OF CLAIMS [W. VA.
Witnesses for the respondent testified
that there was at least one access open to the shopping center at all times
during construction and most of the time there were two.
Highway construction involves considerable inconvenience to the public or to
businesses that are close to the construction project, but without proof of
negligence on the part of the respondent causing damage to the claimant, there
can be no recovery. The record discloses that an independent contractor was
performing the construction work and the only employees of the respondent on
the construction site were inspectors. The record further discloses that at
least one access and most of the time two accesses were maintained to the
shopping center.
?The inconvenience and damage which a property owner suffers from these
temporary obstructions are incident to city life and must be endured. The law
gives him no right to relief, recognizing that he recoups his damage in the
benefit which he shares with the general public in the ultimate improvement
which is being made.? Farrell v. Rose,
253 NY 73, 170 N.E. 498, 68ALR 1505
(1930).
For the reasons herein set out, the claim is disallowed.
Claim disallowed.
Opinion issued February 1, 1982
CHAFIN COAL COMPANY
vs.
WORKMEN?S COMPENSATION FUND
(CC-79- 16 1)
Stephen P. Goodwin, Attorney at Law,
for claimant. Donald L. Hall, Attorney at Law, for respondent.
RULEY, JUDGE:
This claim was submitted for decision following the filing of a written
stipulation by the parties and brief oral argument.
The stipulation states that, as a subscriber to the Coal-
W. VA.]
REPORTS STATE COURT OF CLAIMS 99
Worker?s Pneumoconiosis Fund, claimant
inadvertently paid excessive premiums in 1974, 1975, and 1976 which amounted to
$33,101.04. The respondent refused to refund this amount or to give claimant
credit on future premiums. The gist of respondent?s argument is that claimant
did not comply with Section 5.01 of the Rules
and Regulations of the Coal-Worker?s Pneumoconiosis Fund (effective December 2, 1973), under which Chafin Coal could have applied
for reclassification of its business.
Section 5.01 provides: ?A subscriber may, at anytime during the first six months of a subscription
year, make a written request for
partial or total reclassification of his business, or for the exclusion of
certain of his operations, or for specific employments.? (Emphasis supplied.)
Section 5.02 states that a subscriber shall be entitled to a refund of an
excess premium paid ?based upon an evaluation of the experience of the
subscriber during the subscription year.?
The general rule is that where an administrative remedy is provided by statute
or by rules and regulations having the force and effect of law, relief must be
sought from the administrative body, and such remedy must be exhausted before
the courts will act. 1A M.J., Administrative Law, ?17; Gates v. Woods, 169 F.2d 440 (4th Cir. 1948). It is apparent that claimant herein failed
to seek relief under the available regulations, and, for that reason, the Court
is obligated to deny this claim.
Claim disallowed.
Opinion issued February 1, 1982
COPY GRAPHICS, INC.
vs.
INSURANCE DEPARTMENT
(CC-82-4)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks
100 REPORTS
STATE COURT OF CLAIMS [W. VA.
payment of the sum of $522.13 on
unpaid rental invoices for a Savin Model 780 plain paper copier.
Respondent admits the validity and amount of the claim, but its Answer further
states that sufficient funds were not available at the end of the fiscal year
in question from which the obligation could have been paid.
While we feel that this claim should, in equity and good conscience, be paid,
we cannot make an award, based on our decision in Airkem Sales and Service, et al. v. Dept. of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued February 1, 1982
DAIRYLAND INSURANCE COMPANY,
SUBROGEE OF WESLEY D. MYERS
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-81-355)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted on the pleadings, claimant is seeking $423.00 as
reimbursement for storage charges incurred when claimant?s insured?s burned
automobile was held by the State Police pending an investigation of arson. The
car was released when arson could not be proved, and the claimant paid the cost
of the vehicle?s storage.
Respondent admits the validity and amount of the claim, stating that sufficient
funds were available in its appropriation for the fiscal year involved from
which the obligation could have been paid. Accordingly, the Court makes an
award to the claimant in the amount requested.
Award of $423.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 101
Opinion issued February 1, 1982
EASTMAN KODAK COMPANY
vs.
DEPARTMENT OF FINANCE AND ADMINISTRATION
(CC-81-386)
Thomas D. Cornell, Sales
Representative, appeared for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
On May 15, 1979, claimant and respondent entered into a rental agreement for
the use of a Kodak EKTAPRINT Copier/ Duplicator. Claimant seeks payment of the
sum of $4,391.50 in rent due on the equipment.
The respondent Department of Finance and Administration transferred the
machine, for a time, to the office of Legislative Services in an arrangement
worked out by a representative of the claimant. According to the testimony
presented, the equipment was utilized by the respondent, in both departments,
for the period of time alleged in the invoices for the rental fees, and the
claimant should therefore be reimbursed.
Based on the foregoing facts, the Court makes an award of $4,391.50 to the
claimant.
Award of $4,391.50.
Opinion issued February 1, 1982
ENERGY TECHNOLOGY CONSULTANTS, INC.,
D & M WEATHER SERVICE
vs.
BOARD OF REGENTS
(CC.-81-443)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claiment herein seeks payment of the sum of $350.00 for
102 REPORTS
STATE COURT OF CLAIMS [W. VA.
weather forecasting services provided
West Virginia University.
Respondent admits the validity and amount of the claim, and states in its
Answer that sufficient funds remained at the close of the proper fiscal year
from which the claim could have been paid.
Based on the foregoing, the Court makes an award to the claimant in the amount
requested.
Award of $350.00.
Opinion issued February 1, 1982
FIRESTONE TIRE & RUBBER COMPANY
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-81-402)
Robert K. Lewis, Jr., Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
According to the pleadings filed herein, claimant seeks payment of the sum of
$852.72 for twenty-four passenger tires purchased by the respondent. As the
respondent admits the validity and amount of the claim, and sufficient funds
remained in its appropriation for the fiscal year in question from which the
claim could have been paid, the Court makes an award of $852.72 to the
claimant.
Award of $852.72.
Opinion issued February 1, 1982
HAWES ELECTRIC CO.
vs.
DEPARTMENT OF HEALTH
(CC-81-431)
No appearance by claimant.
Curtis G. Power, III, Assistant Attorney General, for respondent.
PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks
W. VA.]
REPORTS STATE COURT OF CLAIMS 103
payment of the sum of $1,126.00 for
the installation of a new fire alarm system at Huntington State Hospital.
Respondent admits the validity and amount of the claim, and states that
sufficient funds were available in its appropriation for the fiscal year in
question from which the obligation could have been paid.
Accordingly, the Court makes an award of $1,126.00 to the claimant.
Award of $1,126.00.
Opinion issued February 1, 1982
FRANCIS J. HENNESSY
vs.
BOARD OF REGENTS
(CC-80-340)
Walton S. Shepherd, III, Attorney at Law, for claimant.
Ann V. Dornblazer, Assistant Attorney General, for respondent.
RULEY, JUDGE:
The claimant filed this claim against the Board of Regents for breach of
contract while he was employed as President of the West Virginia School of
Osteopathic Medicine. The claimant was appointed President on May 23, 1978, to
serve effective September 1, 1978. The letter informing the claimant of the
appointment also quoted the annual salary rate. In May, 1979, Dr. Hennessy
received a second letter advising the claimant, then serving as President, of
the annual salary effective July 1, 1979.
It is the claimant?s contention that these letters created a contract of
employment between the claimant and the Board of Regents.
During a meeting of the Board of Regents in April, 1980, the Board requested
the resignation of the claimant and informed him that his services would no
longer be needed as of
104 REPORTS
STATE COURT OF CLAIMS [W. VA.
May 31, 1980, with the month of June,
1980, to be taken as claimant?s annual leave. It is the position of the Board
that administrative officials serve at the will and pleasure of the Board, that
services of the claimant could be terminated at any time, and that the claimant
was not under contract during his term as President of the school.
The claimant asserted that the letter of May 9, 1979, created
a year?s contract from July 1, 1979 through June 30, 1980,
and, therefore, claimant is entitled to full salary for June,
1980, and annual leave for July, 1980.
The Court does not perceive the letter of appointment of May 26, 1978, or the
letter of May 9, 1979, informing claimant of the annual salary rate for fiscal
1979-1980, to be contract documents. These letters reflected only the rate of
salary of the claimant while in the employ of the Board.
As the Board determined to terminate the services of the claimant as of May 31,
1980, it accorded the claimant annual leave for June, 1980, and the claimant
has been paid for that annual leave.
It is therefore the opinion of the Court that the claimant is entitled to no
recovery in this action.
Claim disallowed.
Opinion issued February 1, 1982
HENRY F. ORTLIEB BREWING CO.
vs.
NONINTOXICATING BEER COMMISSION
(CC?81-175)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant herein seeks payment of the sum of $3,004.87 as a refund of prepaid
State excise taxes for the months of June,
W. VA.]
REPORTS STATE COURT OF CLAIMS 105
August, and September of 1980.
Claimant did not renew its contract for 1981. In accordance with West Virginia
Code ?11-166, claimant paid barrel taxes based upon estimated montlly sales,
and liability for those taxes, when based upon actual sales, fell below the
amount paid by the claimant.
The respondent admits the validity and amount of the claim, and joins the
claimant in requesting that an award be made.
Tax refund cases are not uncommon in cases that have come before this Court,
and, where the State has not been damaged, it has been held that the retention
of such taxes would result in the unjust enrichment of the State. Crosby Beverage Co., Inc. vs. Nonintoxicating Beer
Commission, 14 Ct.Cl. 20 (1981), Falls City Industries, Inc. vs. Nonintoxicating Beer
Commission, 13 Ct.Cl. 186 (1980), Central Investment Corporation vs. Nonintoxicating
Beer Commission, 10 Ct.Cl. 182 (1975).
Based on the foregoing, the Court makes an award to the claimant in the amount
requested.
Award of $3,004.87.
Opinion issued February 1, 1982
JOHNSON CONTROLS, INC.
vs.
DEPARTMENT OF FINANCE AND ADMINISTRATION
(CC-81-316)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted on the pleadings, claimant seeks payment of the sum of
$2,376.75 in labor and materials for the repair of a computerized central
control system serving five buildings in the State Capitol Complex.
Respondent?s Answer admits the validity and amount of the claim, and, as
sufficient
106 REPORTS STATE
COURT OF CLAIMS [W. VA.
funds remained in its appropriation for the proper fiscal year from which the
obligation could have been paid, the Court makes an award of $2,376.75 to the
claimant.
Award of $2,376.75.
Opinion issued February 1, 1982
JOHNSON CONTROLS, INC.
vs.
DEPARTMENT OF FINANCE AND ADMINISTRATION
(CC-81-454)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks payment of the sum
of $4,160.00 for maintenance services on the air-conditioning, temperature, and
humidity systems in seven State Capitol buildings.
Respondent admits the amount and validity of the claim, stating in its Answer
that sufficient funds remained in its appropriation for the fiscal year in
question from which the obligation could have been paid.
Based on the foregoing, the Court makes an award to the claimant in the amount
requested.
Award of $4,160.00.
Opinion issued February 1, 1982
WILLIAM P. KNIGHT
vs.
TREASURER?S OFFICE
(CC-79-667)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
This claim against the Treasurer?s Office was originally filed
W.VA.] REPORTS
STATE COURT OF CLAIMS 107
against the State Tax Department, but
has been amended by the Court for reasons which will be made apparent by the
facts which follow.
Claimant William P. Knight and his wife at the time, Marjorie A. Knight, filed
a joint West Virginia personal irLcome tax return for 1977 showing a refund
due. The Tax Department requested that the Treasurer?s Office and the Auditor
issue a warrant for $305.88, the amount of the refund. The warrant, issued
March 15, 1978, was made payable to William P. Knight and Marjorie A. Knight, who,
during this period, were in the process of obtaining a divorce. William
allegedly forged the endorsement of Marjorie and then cashed the check.
On the advice of counsel, William paid the $305.88 back to the Treasurer.
Marjorie then applied to the Treasurer for reissuance of another warrant. The
new warrant, in the sum of $305.88, issued April 11, 1979, was made payable to
Marjorie A. Knight only. Subsequently, she cashed the check and left the State.
William proceeded to file this claim against the State Tax Department in the
amount of $152.94, representing his share of the improperly issued refund.
At the hearing, it was admitted by the respondent that ?apparently there was an
error made by the State officials?. The evidence indicates that the error was
made by the Treasurer?s Office, and not by the State Tax Department; therefore,
the claim has been amended by the Court to name the Treasurer?s Office as
respondent.
Tax refunds are provided for by West Virginia Code ?11-21- 86, which states, in
part, that ?the tax commissioner shall refund the amount of the overpayment to
the taxpayer.? As for the actual payment, or disposition of revenue, ?11-21-93
provides: ?Of the revenue collected under this article the state treasurer
shall retain in his hands such amount as the tax commissioner may determine to
be necessary for refunds to which taxpayers shall be entitled. .
In the case at bar, taxpayer William P.
Knight was entitled to one-half of the refund, which, because of the
respondent?s
108 REPORTS
STATE COURT OF CLAIMS [W. VA.
error, he did not receive.
Accordingly, the claim should be allowed.
Award of $152.94.
Opinion issued February 1, 1982
EUGENE A. KNOTTS
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-107)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant filed this claim in the amount of $300.00 against the respondent
for damages sustained to his 1978 Thunderbird automobile. It developed at the
hearing that damages sustained to the automobile were $657.76, and the Court
amended the complaint to correspond with the evidence.
On February 10, 1981, the claimant was driving his automobile southerly on
W.Va. Route 14 from Vienna, West Virginia to Valley Road in Parkersburg. It was
cold and clear and the highway was dry. The claimant was proceeding at 30-35
miles per hour in the outside lane of Route 14, which is a fourlane highway. At
the intersection of 23rd Street in Vienna, claimant?s automobile struck a
pothole in the left-hand side of the traffic lane in which he was travelling.
The hole was in the berm adjacent to the median and extended a short distance
into the highway. The left front and rear wheels and tires were damaged.
The claimant testified that he travelled the road frequently but had never seen
the hole that he struck and that there were no southbound vehicles in front of
him.
This Court has, over the years, been presented with claims of a similar nature,
and with few exceptions, has declined to
W. VA.] REPORTS STATE COURT OF CLAIMS 109
make awards primarily on the basis
that respondent is not an insurer of motorists using the highways of this
State. See Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). There must be proof
that the respondent knew or should have known of the existence of the
particular pothole and that the respondent had sufficient time within which to
repair the same. The record is devoid of any such evidence and, accordingly,
the Court must deny this claim. Blackwell
v. Dept. of Highways, 13
Ct.C1. 121 (1980).
Claim disallowed.
Opinion issued February 1, 1982
THE MICHIE COMPANY
vs.
OFFICE OF THE SUPREME COURT ADMINISTRATOR
(CC-82-3)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant herein seeks payment of the sum of $56.13 for two Replacement Volumes
of the West Virginia Code purchased by the respondent.
As respondent?s Answer admits the validity and amount of the claim, and
sufficient funds remained in its appropriation for the proper fiscal year, the
Court makes an award of $56.13 to the claimant.
Award of $56.13.
110 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued February 1, 1982
REGION V ? REGIONAL EDUCATION SERVICE AGENCY
vs.
DEPARTMENT OF EMPLOYMENT SECURITY
(CC-81-426)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In October of 1980, the Regional Education Service Agency, claimant herein,
loaned the respondent certain video equipment which subsequently was lost or
stolen. The Notice of Claim reveals a replacement cost of $2,145.25.
The respondent?s Answer admits the validity and amount of the claim, and, as
sufficient funds remained in its appropriation for the fiscal year in question
from which the obligation could have been paid, the Court makes an award to the
claimant in the amount sought.
Award of $2,145.25.
Opinion issued February 1, 1982
STATE DISTRIBUTING COMPANY
vs.
NONINTOXICATING BEER COMMISSION
(CC-81-385)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant herein seeks payment of the sum of $11,068.92 in taxes paid on 26,180
cases of beer rendered unfit for human consumption as the result of flooding.
Destruction of the beer was carried out under the supervision and inspection of
the
W. VA.]
REPORTS STATE COURT OF CLAIMS 111
West Virginia Department of
Agriculture and the respondent Beer Commission.
The respondent admits the validity of the claim and joins the claiment in requesting
that an award be made to the claimant in the amount requested.
In numerous prior decisions of this Court, it has been held that the retention
of taxes paid in such situations would amount to unjust enrichment on the part
of the State. Crosby Beverage Co.,
Inc. vs. Nonintoxicating Beer Commission, 14 Ct.Cl. 20 (1981), Falls City
Industries, Inc. vs. Nonintoxicating Beer Commission, 13 Ct.Cl. 186 (1980), Central Investment Corporation vs. Nonintoxicating Beer Commission, 10 Ct.Cl. 182 (1975).
Based on the foregoing, the Court makes an award to the claimant of $11,068.92.
Award of $11,068.92.
Opinion issued February 1, 1982
JOHN F. TOMBLYN
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-192)
Claimant appeared in his own behalf.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
This claim in the sum of $721.82 for property damage to the claimant?s 1980
model Ford automobile arises out of an unusual accident which happened at about
1:00 p.m. on June 4, 1981, upon a public highway in Buckhannon, West Virginia.
At the time and place of the accident, the vehicle was parked and the accident
occurred when a tree limb broke in part with its smaller branches falling upon
the top of the vehicle. Two
112 REPORTS STATE
COURT OF CLAIMS [W. VA.
employees of the respondent came to that scene, responsive to the claimant?s
call, and attempted to solve the problem by pulling the limb to one side. When
they executed that maneuver, the limb?s remaining attachment to the tree broke
and the butt of the limb fell upon the trunk of the car, denting it deep ly The
claimant testified that the limb was not rotten and there was no explanation of
why the initial break occurred. Accordingly, there is no liability for damage
caused by the initial break. Hersom v.
Department of Natural Resources, 12
Ct.Cl. 312 (1979). It is equally clear, however, that the respondent?s
employees failed to exercise ordinary care in their effort to maneuver the limb
away from the claimant?s car, and, for that reason, the claimant is entitled to
recover damages resulting therefrom. Finding that 90% of the damage was caused
by the respondent?s negligence, the Court makes an award in the sum of $649.64.
Award of $649.64.
Opinion issued February 1, 1982
WHEELING MULTI-SERVICE CENTER, INC.
vs.
DIVISION OF VOCATIONAL REHABILITATION
(CC-81-133)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted on the pleadings, claimant seeks payment of the sum of
$5,220.00 for rent due under a lease agreement with the respondent for office
space in Wheeling, West Virginia. Respondent admits the validity and amount of
the claim, and states that sufficient funds remained in its appropriation for
the fiscal year in question from which the obligation could have been paid.
114 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued Februarp 2, 1982
GARY L. BATTON
vs.
CIVIL SERVICE COMMISSION
AND
DEPARTMENT OF NATURAL RESOURCES
(CC-81-203)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
On March 27, 1980, claimant was suspended from duty and from pay as a Building
Maintenance Mechanic in the Division of Wildlife Resources pending the outcome
of criminal proceedings against him. The indefinite period of suspension was to
last no longer than six months.
Eleven months later, on February 23, 1981, the Department of Natural Resources
returned the claimant to duty since there had been no court action in his case.
By letter dated April 9, 1981, claimant asked the Civil Service Commission for
back pay relating to his suspension time, if the suspension had not been
legally correct. The Commission subsequently conducted a review of the
suspension, and denied the request for back pay because the request had not
been made within the thirty- day period following the suspension, as required
by West Virginia Code ?29-6-15.
In essence, claimant is asking this Court to rule upon the decision rendered by
the Civil Service Commission. The Cornmission?s Order, denying the request for
back pay, relies entirely upon the statute cited above, which reads:
?Any employee in the classified service. . .who
is suspended for more than thirty days in any one year, may, within thirty days
after such dismissal. .
.appeal to the commission for review
thereof.? (W.Va. Code ?29-6-15)
W. VA.]
REPORTS STATE COURT OF CLAIMS 113
Based on the foregoing, the Court
makes an award of $5,220.00 to the claimant.
Award of $5,220.00.
Opinion issued February 2, 1982
AUTO TECH, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-436)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Originally filed indicating Ron Samples as claimant, this claim was amended by
the Court to reflect the actual ownership of the vehicle involved.
According to a written stipulation filed by the parties, on or about June 17,
1981, Ron Samples was operating a 1978 Cadillac Seville titled in the name of
claimant Auto Tech, Inc., on Interstate 64 in Cabell County, West Virginia, a
highway owned and maintained by the respondent.
Between the Twenty-Ninth Street Exit and the Sixteenth
Street Exit of 1-64 West into Huntington, Mr. Samples passed
a mower owned and operated by the respondent, and gravel was
thrown against claimant?s vehicle. As a result, damage to the
paint, body, and windshield occurred, which amounted to
$325.50 in repairs.
The damages suffered by the claimant were the direct and proximate result of
the respondent?s negligent operation of its mower. Therefore, the Court makes
an award to the claimant in the amount stipulated by the parties.
Award of $325.50.
W. VA.]
REPORTS STATE COURT OF CLAIMS 115
The crucial phrase appears to be
?within thirty days after such dismissal.? Claimant?s suspension was supposed to
end no later than six months from March 27, 1980, which would place his
thirty-day appeal period from
September 27, 1980, to October 27, 1980.
His suspension actuaily ended on February 23, 1981, which would place his
thirty-day appeal period from February
23, 1981, to March 23, 1981. At any
rate, claimant did not appeal to the Commission until April 9, 1981. The
decision of the Commission was, therefore, correct.
Claim disallowed.
Opinion issued February 2, 1982
MASON M. CLAY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-397)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a written stipulation to the effect that the
respondent is liable for damages in the sum of $150.00 as the result of an
accident which occurred on or about September 22, 1981. At approximately 12: 10
p.m. on that date, claimant was operating his 1980 Datsun pickup truck on West
Virginia Route 16, a highway owned and maintained by the respondent, in Crab
Orchard, West Virginia.
In the course of this travel, claimant?s vehicle passed over a drain culvert
cover which flipped up and damaged the truck?s frame and emergency brake cable.
This occurred because of the negligence of the respondent in not securing the
culvert cover, proximately causing the damages suffered by the claimant.
Based on the foregoing facts, an award is made to the claimant in the amount
stipulated by the parties.
Award of $150.00.
116 REPORTS
STATE COURT OF CLAIMS [W. VA.
Advisory opinion issued February
2, 1982
WEST VIRGINIA UNIVERSITY HOSPITAL
vs.
DEPARTMENT OF CORRECTIONS
(CC-81-413)
Bernard G. West fall, Associate Administrator, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for an advisory determination pursuant to West
Virginia Code ?14-2-18. Claimant seeks payment of the sum of $7,440.43 for
medical care rendered to patients who were detainees of respondent?s Anthony
Center.
In its Answer, the respondent admits the validity and amount ci the claim, but
does not concede that an award should be made against the respondent as the
claimant is a State- supported institution. Respondent further states that no
funds remained in its appropriation for the fiscal year in question from which
the obligation could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are also of the opinion that an award cannot be made, based on our
decision in Airkem Sales and Service,
et al. v. Department of Mental} Health, 8
Ct.Cl. 180 (1971). As this is an advisory determination, the Clerk of the Court
is hereby directed to file this Opinion and forward copies thereof to the
proper parties within West Virginia University Hospital and the Department of
Corrections.
Opinion issued February 16, 1982
BARBARA B. KRANTZ
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-391)
Claimant appeared in her own behalf.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
On October 11, 1980, at about 1:00 p.m., the claimant?s hus
W. VA.]
REPORTS STATE COURT OF CLAIMS 117
band, Daniel Krantz, was backing
claimant?s 1974 Chevrolet station wagon out of a paved parking area at the New
River Gorge observation point in Fayette County when the right rear wheel of
the vehicle dropped into an unmarked hole at the edge of the pavement. The hole
was at the end of a drainpipe, and resultant damages to the exhaust system
amounted to $130.49. According to Mr. Krantz?s testimony, the hole was two to
three feet deep. It was not marked in any manner, and was unobservable from his
position.
The Court believes that the testimony anti photographs presented clearly
establish the respondent?s negligence, and that such negligence was the
principal cause of the accident and the resulting damage to the claimant?s
vehicle. However, the Court also believes that negligence on the part of the
driver of the claimant?s vehicle, i.e., his failure to remain on the paved
portion of the parking area, also contributed to cause this accident and
resulting damage. The Court is disposed to allocate 80% of the negligence to
the respondent and 20 to the claimant?s husband, and makes an award of $104.39.
Award of $104.39.
Opinion issued February 16, 1982
JEFFREY 0. McGEARY
vs.
HUMAN RIGHTS COMMISSION
(CC-82-12)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks payment of the sum
of $110.64 in expenses incurred over and above the money advanced to him by the
State to attend a conference in San Diego. Claimant traveled to an EEOC Con-
118 REPORTS
STATE COURT OF CLAIMS [W. VA.
ference in San Diego as the chairman
of the West Virginia Human Rights Commission.
Respondent?s Answer admits the validity and amount of the claim, and states
that sufficient funds remained in its appropriation for the fiscal year in
question from which the obligation could have been paid.
Accordingly, the Court makes an award to the claimant in the amount of $110.64.
Award of $110.64.
Opinion issued February 16, 1982
CHANDRA P. SHARMA
vs.
DEPARTMENT OF CORRECTIONS
(CC-82?22)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim against the Department of Corrections was submitted for decision
upon the pleadings. The claimant seeks payment for medical services furnished
to the respondent, West Virginia Prison for Women, in the amount of $815.00.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
While we feel that this claim should, in equity and good conscience, be paid,
we further believe that an award cannot be made, based on our decision in Airkem Sales and Service, et al. v.
Department of Mental Health, 8
Ct.Cl. 180 (1971).
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 119
Opinion issued February 16, 1982
LARRY N. SULLIVAN
vs.
OFFICE OF THE STATE AUDITOR
(CC-82-15)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant is an attorney who served as counsel for criminal indigents in
juvenile, misdemeanor, or felony proceedings pursuant to the provisions of West
Virginia Code Chapter 51, Article 11. Claimant?s fee was denied by the
respondent because the fund was exhausted.
The factual situation in this claim is identical to that in Richard K. Swartling, et al. v. Office of the State
Auditor, issued on November 5, 1979.
Accordingly, an award is made to the claimant in the amount of $170.00.
Award of $170.00.
Opinion issued February 17, 1982
PEARL HUGHES BOLLING
AND CHARLES HUGHES
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-16)
Eugene D. Pecora, Attorney at Law, for the claimants. Nancy J. Aliff, Attorney at Law, for the respondent.
RULEY, JUDGE:
In their notice of claim, filed on January 9, 1979, the claimants allege that
the respondent destroyed a stone wall
120 REPORTS
STATE COURT OF CLAIMS [W. VA.
upon real property owned by Carol
Brown in Glen White, West Virginia, incident to improving and widening a public
road in 1973. Claimants seek damages in the sum of $13,140.00.
The respondent has filed a motion to dismiss based upon the two-year period of
limitations for which provision is made in West Virginia Code ?55-2-12, as
follows:
?55-2-12. Personal actions not otherwise provided for.
Every personal action for which no limitation is otherwise prescribed shall be
brought: (a) Within two years next after the right to bring the same shall have
accrued, if it be for damage to property; . ..
West Virginia Code ?14-2-21, which
provides:
?14-2-21. Periods of limitation made applicable.
The Court shall not take jurisdiction of any claim, whether accruing before or
after the effective date of this article [July 1, 19671, unless notice of such
claim be filed with the clerk within such period of limitation as would be
applicable under the pertinent provisions of the Code of West Virginia.?
precludes this Court from taking jurisdiction of any claim barred by any
applicable period of limitations. In Shered
v. Department of Highways, 9 Ct.Cl.
137 (1972), it was stated:
?This Court is bound by express statutory law to apply the statute of
limitations in all cases where the statute would be applicable if the claim
were against a private person, firm or corporation.?
It appears that the theory of this claim is that it is ex delicto, and, for
that reason, the quoted statute applies and the motion must b granted. However,
the Constitution of West Virginia, Article III, Section 9, provides that
private property shall not be taken or damaged for public use without just
compensation, and it may be that mandamus would lie in a proper forum to compel
the respondent to institute an eminent domain proceeding.
Motion to dismiss granted.
W. VA.]
REPORTS STATE COURT OF CLAIMS 121
Opinion issued February 17, 1982
VEDA E. EVANS
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-43)
Claimant appeared in her own behalf.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
At about 4: 15 a.m. on November 28, 1980, Carlene Evans, daughter of the
claimant, was driving claimant?s 1979 Chevrolet Chevette on Campbell?s Creek
Drive in Kanawha County when she encountered a trench three feet wide and eight
inches deep ?xtending across the roadway. Miss Evans entered the trench,
causing considerable damage to the car. Claimant contends that negligence on
the part of the State was the cause of this accident, and seeks to recover
$892.69.
According to her testimony, Miss Evans was travelling at approximately 12 miles
per hour with her headlights on low beam and her foot on the brake. The trench
was located in a straight section of the road, and Miss Evans knew of its
existence. She had been driving over that particular road for ten years prior
to the accident.
James M. Mills, a project supervisor for the respondent, testified that the
trench had been dug by State Construction Co., Inc., for drainage purposes. An
18? corrugated pipe had been placed in the trench and it had been backfilled
with compacted store to the level of the pavement. Mr. Mills inspected the
trench on November 26, 1980, less than two days before the accident, and found
it to be in satisfactory condition.
From the testimony of Mr. Mills, it was clear that the Department of Highways
had been inspecting the area regularly and had no prior knowledge of the
dangerous condition that existed on the morning of November 28, 1980. Thus, we
cannot find the State guilty of any negligence with regard to the maintenance
of the trench.
122 REPORTS
STATE COURT OF CLAIMS [W. VA.
Further, in view of Miss Evans?
testimony that she was quite familiar with the road and that she was aware of
the trench, the Court is of the opinion that her own negligence was, in large
part, the cause of the accident. While Miss Evans claimed that she was
exercising proper caution, the Court is compelled to believe that, if she were
travelling only 12 miles per hour and had been maintaining a reasonable
lookout, she would have perceived the dangerous depth of the trench and been
able to stop before entering it.
This Court consistently has followed the decisions of the West Virginia Supreme
Court of Appeals in holding that the State is not an insurer of the safety of
persons travelling upon its highways, and its duty to travellers is a qualified
one, namely, reasonable care and diligence in the maintenance of highways.
Accordingly, this claim must be denied.
Claim disallowed.
Opinion issued February 17, 1982
JOHN J. GAUGHAN
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-353)
Claimant appeared in his own behalf.
Nancy J. Aliff, Attorney at Law, for the respondent. GARDEN, JUDGE:
On September 16, 1980, the claimant was driving his 1978 Chrysler Newport
westward across the Market Street Bridge between West Virginia Route 2 in
Brooke County and Steubenville, Ohio. As he left the bridge, claimant noticed
that his car was pulling to the right, and, when he arrived at his home two
miles away, he discovered that both tires on the passenger side of the vehicle
were flat. The claimant seeks to recover damages of $156.42, the cost of
replacing those two tires.
Claimant alleges that the damage to his tires was caused by
W. VA.]
REPORTS STATE COURT OF CLAIMS 123
steel spurs protruding from the bridge
surface. According to his undisputed testimony, the bridge surface was
constructed of steel decking and was in generally poor condition at the time of
the accident. The claimant had driven over the bridge many times and was
familiar with it. The damaged tires were Goodyear steel-belted radials that had
been driven for approximate]y 10,000 miles. The damage occurred in the center
of the tread on each tire. The claimant also testified that accidents of this
type had happened to several other people, including the claimant?s son.
While it appears that the damage to the tires of the claimant?s vehicle
probably was sustained while it traveled over the bridge, there is no proof
respecting what defect, if any, in the bridge surface caused the damage. The
only evidence was that the bridge surface was in generally poor condition. In
the absence of such proof, the Court is obligated to deny this claim.
Claim disallowed.
Opinion issued February 17, 1982
MARTHA WHITE FOODS
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-111)
David C. Myers appeared on behalf of the claimant.
Nancy J. Aliff, Attorney at Law, for the respondent. GARDEN, JUDGE:
On February 17, 1981, the claimant?s agent, David C. Myers, was driving a 1980
Chevrolet Citation, leased by the claimant, eastward on U.S. Route 50 near
Salem when he struck a pothole, damaging the right front tire and rim of the
automobile. The claimant seeks to recover $101.64 for that damage.
The State neither insures nor guarantees the safety of motorists travelling on
its highways, Adkins v. Sims, 130 W.Va.
124 REPORTS
STATE COURT OF CLAIMS [W. VA.
645, 46 S.E.2d 81 (1947). For the
respondent to be held liable for road defects of this type, the claimant must
prove that the respondent had actual or constructive knowledge of the defect,
and a reasonable amount of time to take suitable corrective action. Davis v. Department of Highways, 11 Ct.Cl. 150 (1976). Since the claimant did not meet that
burden of proof, this claim must be denied.
Claim disallowed.
Opinion issued February 17, 1982
DAYTON 0. B. AND ALLINE L. MATTHEWS
vs.
DEPARTMENT OF HIGHWAYS
(CC-8 1-19)
Claimants appeared in their own
behalf.
Douglas Hamilton, Attorney at Law, for the respondent.
RULEY, JUDGE:
On November 27, 1980, at approximately 10:30 p.m., claimant Alline L. Matthews
and her two grandchildren were travelling east on State Route 60 in claimant?s
1980 Volkswagen Rabbit. At a point near the Montgomery Bridge, the two
eastbound lanes merged into one, and claimant?s vehicle collided with several
dome-shaped metal lane dividers approximately three inches high, causing damage
to the vehicle in the amount of
$178.07.
Mrs. Matthews testified that she had been travelling at 35- 45 miles per hour
and that, due to rain, visibility was limited to 35-40 feet, in her estimation.
Her testimony also revealed that she normally drove over that same route two or
three times per week, that she was aware that it was under construction, and
that she had seen a sign warning motorists that there was a single lane ahead
before she collided with the lane dividers.
W. VA.]
REPORTS STATE COURT OF CLAIMS 125
For the respondent, project supervisor
Carl Osborne testified that the decks on the Montgomery Bridge and its
approaches were being replaced, which necessitated the rerouting of eastbound
traffic into Montgomery and restriction of part of Route 60 to a single lane of
traffic. White pavement markers were used to indicate that single lane.
According to Mr. Osborne, the markers were eight inches wide, slightly less
than three inches high, and reflectorized. In addition to these markers, two
signs were placed to warn motorists approaching the single lane, and yellow
tape and traffic arrows were used to direct motorists into the single lane. Mr.
Osborne also testified that the metal markers had been in place for months
before the accident.
The preponderance of the evidence in this case indicates that, if there were
any negligence involved, it was on the part of Mrs. Matthews. She travelled the
road frequently, knew of the construction, and had observed a sign warning
motorists of the approaching single lane. Also, despite the fact that it was
raining and visibility was only 35-40 feet, Mrs. Matthews maintained a speed of
35-45 miles per hour. For those reasons, the claim must be denied.
Claim disallowed.
Opinion issued February 17, 1982
JOHN McKENDRICK
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-59)
Claimant appeared in his own behalf.
Douglas Hamilton, Attorney at Law, for the respondent.
RULEY, JUDGE:
On January 9, 1981, at about 4:00 p.m., the claimant was driving his 1970
Cadillac in a southerly direction on Raccoon
126 REPORTS
STATE COURT OF CLAIMS LW. VA.
Creek Road in Cabell County when he
collided with a 1972 Volkswagen driven by Phillip Chapman. The accident
occurred at a point about 1i/2 miles from the McComas School, where the
two-lane blacktop road was curved and banked. As Mr. McKendrick rounded this
curve at approximately 15 miles per hour, his vehicle slipped on a patch of
ice, slid across the center of the road, and collided with Mr. Chapman?s
vehicle, which was rounding the curve from the opposite direction. Damage in
the sum of $650.00 was sustained by the Chapman vehicle, and $350.00 by the
McKendrick vehicle. The claimant paid Mr. Chapman for the damage to his vehicle
and now seeks to recover the damage to both vehicles, namely, $1,000.00. Mr. McKendrick
claims that the Department of Highways was negligent in failing to divert the
water flow across the highway and in failing to salt the road surface after it
froze.
During cross-examination, Mr. McKendrick testified that the ice patch had just
formed on the day of the accident, as it was not there when he had driven over
the highway earlier in the day.
Testifying for the respondent was Donald Turner, the Department of Highways
maintenance supervisor for Cabell County, who stated that, for snow and ice
removal or treatment, Raccoon Creek Road was rated at a priority of 4 on a
scale of 6, with numbers 1-3 being interstates, primary roads, and feeder
roads; that, before any work could be done on a priority 4 road, all roads in
the county having higher priority numbers must have been judged safe for
passage: and that the maintenance men simply had not yet reached priority 4
roads at the time of the accident. If the flow of water across the road were
caused by a defect in its drainage, there could be no liability on the part of
the respondent in the absence of proof that it had actual or constructive
knowledge of the defect. See Davis
Auto Parts v. Dept. of Highways, 12
Ct.C1. 31 (1977) and Lowe v. Dept. of
Highways, 8 Ct.C1. 210 (1971). For
those reasons, this claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 127
Opinion issued February 17, 1982
SOUTHERN GAS & OIL, INC.
vs.
STATE FIRE MARSHAL
(CC-79-56)
Lawrence E. Morhous, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
The claimant asserts that on January 23, 1978, its retail gasoline service
station on West Virginia Route 20 in Athens, Mercer County, West Virginia, was
closed upon the oral order of the respondent acting through an Assistant State
Fire Marshal, Frank Ubeda, due to the presence of gasoline vapors or fumes in
the Mountain Lion Motel which is located upon adjacent property. It also is
asserted that, although the resuits of air tests upon claimant?s gasoline
tanks, which were negative, were given to the respondent later that same month,
the respondent negligently refused to permit the station to reopen until June
28, 1978. Claimant seeks recovery of $6,000.00 for loss of profit and $539.52
in expense incurred in draining and testing its tanks.
West Virginia Code ?29-3-14 refers to the state fire marshal, and provides in
part:
.whenever he may find in any building or upon any premises any combustible,
flammable or explosive substance or material, or other conditions dangerous to
the safety of persons occupying the building or premises and adjacent premises
or property, he may make reasonable orders in writing, directed to the
owner of such buildin, structure or premises, for the repair or demolition of
such building or structure, or the removal of the combustible, flammable or
explosive substance or material, as the case may be, and the remedying of any
conditions found to be in violation of a regulation promulgated as
128 REPORTS
STATE COURT OF CLAIMS [W. VA.
aforesaid or to be dangerous to the
safety of persons or property.
A true copy of every order of the state fire marshal as provided for in this
section shall be filed in the county where the premises are totally or
partially located, with the county clerk who shall index and record the order
in the general lien book. Upon filing, the order constitutes notice of such
proceedings to all persons or parties thereafter having dealings involving said
property.? (Emphasis supplied.)
According to the undisputed testimony, gasoline fumes or vapors were present in
the claimant?s service station and in the adjacent motel on January 23, 1978.
The service station had been closed for a few weeks as of that date. Mr. Ubeda,
who inspected both establishments on that date, testified, without
contradiction, that gasoline was seeping through a wall beside the station and
that there were pools of gasoline standing on the floor of the basement
underneath its office. He also testified unequivocally that he did not order
the station closed. James D. Evans, the claimant?s general manager, was present
during that inspection. Other persons also were present. Mr. Evans did not
testify that Mr. Ubeda ordered the closure of the station, but testified:
?Well, I felt like the impressions I got from everyone that we ought to keep
the station closed until the situation was corrected or until we found the
source of the problem.?
Although the motel was evacuated on January 23, 1978, Mr. Evans testified that
he was aware on January 24, 1978, that it resumed normal operation on that
date. Following that date, there was considerable correspondence between Mr.
Morhous, writing on behalf of the claimant, and the respondent. In a letter
dated March 1, 1978, and in a letter dated March 16, 1978, Mr. Morhous alluded
to ?verbal closure? of the station by Mr. Ubeda, an allusion which was not
rejected in responsive correspondence. But, even if the failure to reject that
assertion at that time is viewed as some species of acquiescence, there is no
way that it can be elevated to constitute com
W. VA.]
REPORTS STATE COURT OF CLAIMS 129
pliance with the quated satute. In
addition, after acknowledging that the claimed oral order did not comply with
the statute, Mr. Morhous, in his letter of March 16, 1978, a copy of which was
mailed to the claimant, stated:
?Accordingly, we are advising our client by copy of this letter that unless it
is in receipt of your written order closing the above establishment as provided
in the above referenced West Virginia Code provisions within ten (10) days of
your receipt of this letter, they should proceed with reopening this
establishment for normal business.?
That was excellent legal advice and the claimant would have been wise to follow
it. In fact, Mr. Evans explained that the reason the station was not opened
from March until July was because of difficulty in finding an operator. While
there may have been some misunderstanding or misapprehension about the matter,
the Court cannot conclude from the evidence that the respondent ordered the
closure of the station or negligently refused to permit it to reopen, and, for
that reason, this claim must be denied.
Claim disallowed.
Opinion issued February 17, 1982
JOHN J. WEST
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-122)
John S. Hrko, Attorney at Law, for the claimant.
Nancy J. Aliff, Attorney at Law, for the respondent. WALLACE, JUDGE:
On March 23, 1981, the claimant?s wife, Mary S. West, was driving a 1975
Pontiac owned by the claimant north on Route 19 in Wyoming County when she
struck a pothole and damaged
130 REPORTS
STATE COURT OF CLAIMS [W. VA.
the right rear tire and rim of the
automobile. The claimant seeks to recover $209.20 for that damage.
The State neither insures nor guarantees the safety of motorists travelling on
its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). For the respondent
to be found liable for road defects of this type, the claimant must prove that
the respondent had actual or constructive knowledge of the defect. Davis v. Department of Highways, 11 Ct.Cl. 150 (1976). The claimant did not meet that
burden of proof; therefore, this claim must be denied.
Claim disallowed.
Opinion issued February 22, 1982
CHARLES E. McCARTY
vs.
OFFICE OF THE SUPREME COURT ADMINISTRATOR
(CC-81-400)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant herein, an attorney at law, seeks to recover the sum of $55.00, the
amount of an order entered by the Circuit Court of Roane County, for services
rendered by the claimant in a mental hygiene proceeding as provided by West
Virginia Code, Chapter 27, Article 5.
As the respondent?s Answer admits the validity and amount of the claim, and
sufficient funds remained in respondent?s appropriation for the fiscal year in
question from which the obligation could have been paid, the Court makes an
award to the claimant in the amount of $55.00.
Award of $55.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 131
Opinion issued April 1, 1982
LILLIAN WEST COLLINS AND
JOHN COLLINS
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-292)
Thomas L. Butcher, Attorney at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimants filed this claim against the respondent in the amount of $4,261.85
for damage to their automobile and injuries sustained by claimant Lillian West
Collins in an accident which occurred at approximately 8:00 a.m. on December 4,
1979, on West Virginia Route 97 south of Prenter, West Virginia.
On the morning of the accident, the claimant, Lillian West Collins, had taken
her son to school in their 1975 Cadillac automobile and was proceeding to the
post office. She was driving at about 25-30 miles per hour when, at a point in
the highway known locally as Beverly Curve, the automobile skidded on ice on
the highway and struck an embankment. Mrs. Collins suffered broken ribs and a
fractured arm. The automobile was totalled. She testified that the respondent
had done quite a bit of work on the road in September and October, and that the
ditch line had been filled with large gravel, causing water to flow across the
highway. Mrs. Collins further testified that she travelled the road two to
three times a week, that she had not encountered ice before, and that she had
no reason to complain to the respondent about the highway?s condition.
Witnesses for the claimants stated that numerous accidents had occurred on the
highway before and after the Collins accident. There was no testimony that
there were ice formations on the highway prior to the accident. The
respondent?s witness, Bill Wilcox, testified that the berm of the road had been
repaired in September and October; that large-size rock was placed on the berm
and the ditch line was pulled; that coal
132 REPORTS
STATE COURT OF CLAIMS [W. VA.
trucks usually run onto the berm and
damage the ditch line; that, because of heavy traffic on the road, maintenance
is a continuous problem, and that, at the time of the accident, there was no
reason to expect ice or snow on the highway.
To establish negligence on the part of the respondent, there must be proof that
the respondent either knew, or, in the exercise of ordinary care, should have
known about the ice and had sufficient time to remedy the problem. Lavender v. Dept. of Highways, 12 Ct.Cl. 54 (1977). The law of West Virginia is well
established that the State is not a guarantor of the safety of travelers on its
roads. Parsons v. State Road
Commission, 8 Ct.Cl. 35 (1969). The
case of Adkins v. Sims, 130 W.Va. 645, 46 S.E.2nd 81(1947), held in part:
.every user of the highways travels thereon at his own risk. The State does
not, and cannot, assure him a safe journey.?
From the record in this case, the Court is of the opinion that the claimants
have not proved such negligence on the part of the respondent as to establish
liability. Accordingly, the Court is of the opinion to, and does, disallow this
claim.
Claim disallowed.
Opinion issued April 1, 1982
CYNTHIA CATHERINE McGRATH
vs.
DEPARTMENT OF MOTOR VEHICLES
(CC-8 1-42 1)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
On May 27, 1981, claimant was involved in an accident on MacCorkle Avenue in
South Charleston, West Virginia, in which claimant?s 1975 model Ford Mustang
struck a flatbed
W. VA.] REPORTS
STATE COURT OF CLAIMS 133
truck owned by The IV Seasons Builders and driven by LaRue Causey.
According to the testimony, the accident was investigated by a South Charleston
police officer who estimated the damage to the truck to be $400.00. Actual
damages to the vehicle amounted to $100.00, as indicated by a statement from
Mr. Causey releasing the claimant from further liability.
As a result of the police officer?s report and the fact that claimant?s car was
uninsured, the West Virginia Department of Motor Vehicles suspended claimant?s
license and registration pursuant to W.Va. Code ?17D-3-3. Claimant?s license
and registration were restored by the respondent after the release was obtained
from Mr. Causey.
Claimant filed this claim against the respondent in the amount of $47.00 for
reimbursement of reinstatement fees. At the hearing, it developed that the
actual amount paid was
$35.00.
The fees collected by the respondent in cases of this nature are a part of the
administrative process of operating the department. From the record, no
improper action by the respondent was proven, and there is no basis for the
Court to make an award to the claimant for a refund of her costs.
Claim disallowed.
Opinion issued April 1, 1982
NELVA MUNSON
vs.
DEPARTMENT OF HIGHWAYS
(CC-80?355)
Roger F. Redmond, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant sustained injuries and her automobile was a total loss as the
result of a single-vehicle accident which
134 REPORTS STATE
COURT OF CLAIMS [W. VA.
occurred on November 13, 1979. She filed this claim against the respondent in
the amount of $20,000.00 for her damages.
At approximately 1:00 p.m. on the day of the accident, the claimant,
accompanied by her sister and her sister?s infant daughter, was returning to
Marietta, Ohio, from the mall at Vienna, West Virginia. She was proceeding
northerly in her 1976 Dodge Aspen automobile on West Virginia Route 14 toward
the bridge over the Ohio River. The weather was clear and the visibility was
good. The road was twenty feet wide, rough, and bumpy. Claimant traveled it
once or twice a month, and had traveled it on the way to the mall on the day of
the accident. At a point opposite the 84 Lumber Yard, she reduced her speed to
35 miles per hour when she observed an oncoming vehicle proceeding close to the
center line. She testified:
?At no time did I see him come across the line. He was very close to the line. He
was to the extreme left of his lane, but he was still in his lane.?
In her concern with the oncoming vehicle, the claimant struck a pothole in the
berm of the road which extended slightly into the road surface. As the right
front wheel struck the hole, the claimant lost control of the vehicle, and the
right rear fender struck a utility pole. The vehicle went up an embankment and
rolled over.
Her automobile, which she valued at $2,000.00, was totalled. After her $100.00
deductible, claimant was paid $1,835.00 by her insurance carrier, and received
$200.00 for the salvage. She was hospitalized for four days for observation and
treatment, incurring costs at Marietta Memorial Hospital of $895.37, and a bill
from Dr. Plummer in the amount of $75.00. Ambulance charges were $45.00, and
claimant was absent from work for twelve days.
Witnesses for the claimant testified that the hole had been there for a period
ranging from six months to a year, but no one had notified the respondent of
the condition. The assistant superintendent of maintenance for Wood County,
West Virginia, George Davis, testified that he had no knowledge of any
complaints, and that if the respondent knew ?of something we
W. VA.]
REPORTS STATE COURT OF CLAIMS 135
assumed was a hazard, we get to it
when seen or get a call.? Ray Casto, as claims investigator for the respondent,
checked respondent?s records for October and November of 1979 and found no
evidence of any complaints of road conditions at the point of the accident.
In order to make awards in claims such as this, the Court must be convinced
that the respondent knew or should have known of the existence of the pothole
in question, and that the respondent had sufficient time to repair it. The
record is not sufficient in this regard. William
T. Blackwell, et al. v. Department of Highways, 13
Ct.Cl. 121 (1980). This Court consistently has held that the State is not a
guarantor of the safety of travelers on its highways and that its duty to
travelers is a qualified one, namely, reasonable care and diligence in the
maintenance of a highway under all circumstances. Parsons v. State Road Commission, 8 Ct.Cl. 35 (1969); Lowe v. Department of Highways, 8
Ct.Cl. 210 (1971). Accordingly, this claim is disallowed.
Claim disallowed.
Opinion issued April 26, 1982
FRANK BONACCI
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-25)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damages to claimant?s automobile in
the amount of $531.30 were caused when the vehicle was buried by snow and
debris while crossing under Ihterstate 70 at a time when respondent?s employees
were clearing snow from the structure; that this occurred on
136 REPORTS
STATE COURT OF CLAIMS [W. VA.
Route 40 at a point below Interstate
70, a highway owned and maintained by the respondent; and to the effect that
respondent?s negligent snow removal operation was the proximate cause of the
damages suffered by the claimant, the Court finds the respondent liable, and
hereby makes an award to the claimant of $531.30.
Award of $531.30.
Opinion issued April 26, 1982
ROBERT R. BROCK
vs.
WORKMEN?S COMPENSATION FUND
(CC-81-457)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant Robert Brock alleges that he did not receive a check for Workmen?s
Compensation benefits to which he was entitled. According to Mr. Brock?s
petition, he did attend a hearing before the Workmen?s Compensation Review
Board. By letter dated April 16, 1981, Mc. Brock was advised that his claim
could be reopened within five years of the last day he received benefits. The
claimant has chosen to pursue the matter before the Court of Claims.
The respondent has filed a Motion to Dismiss the claim for two primary reasons:
first, the claimant did not exhaust his administrative remedies under Chapter
23 of the West Virginia Code, and second, the claim does not come within the
jurisdiction of the Court of Claims. With both these contentions the Court
agrees.
It has been the policy of this Court in similar cases to rule that a claimant
who does not exhaust his administrative remedies cannot avail himself of the
jurisdiction of the Court of
W. VA.j REPORTS
STATE COURT OF CLAIMS 137
Claims. Nichols Engineering and
Research Corporation v. State Tax Commissioner, 9 Ct.C1. 4 (1971).
It is apparent, from respondent?s letter of April 16, 1981, that Mr. Brock?s
claim could be reopened within a five-year period; thus, he could still pursue
the matter through administrative channels.
With respect to the issue of jurisdiction, the law is quite clear regarding
claims which cannot be brought before this Court. West Virginia Code ?14-2-14
provides:
?The jurisdiction of the court shall not extend to any claim. . .2. For a disability or death benefit under chapter
twenty-three. .
.of this Code.?
For the reasons hereinabove stated, respondent?s Motion to Dismiss is hereby
granted, and the claim is disallowed.
Claim disallowed.
Opinion issued April 26, 1982
JUNE DORTON
vs.
WORKMEN?S COMPENSATION FUND
(CC-81-103)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant June Dorton alleges that she was injured as the result of heavy
lifting she performed while in the employ of Hoggsett Insulation Service in
Huntington, West Virginia, on October 4, 1977. At that time, Mrs. Dorton?s
employer was a subscriber in good standing of the Workmen?s Compensation Fund,
and she subsequently filed a claim for Compensation benefits. Her claim was
rejected by the Commissioner?s Order ol July 24, 1979, on the grounds that the
disability complained
138 REPORTS
STATE COURT OF CLAIMS [W. VA.
of was not due to an injury received
in the course of and resulting from the claimant?s employment. By letter of
July 27, 1979, claimant protested the Commissioner?s ruling, and, pursuant to
that protest, a hearing was held on November 8, 1979. Following that hearing,
Mrs. Dorton?s attorney requested that the claim be continued in order that
medical evidence from her physician could be obtained. The request for a
continuance was granted, and another hearing was held on February 21, 1980. The
claim was then submitted for decision, and, by order of June 27, 1980, the
Workmen?s Compensation Commissioner affirmed the order of July 24, 1979,
rejecting Mrs. Dorton?s claim for benefits. No appeal from that final order was
made by the claimant, and she now seeks redress in this Court.
The procedure to be followed in Workmen?s Compensation claims is set forth in
the West Virginia Code, Chapter 23, Article 5. A review of the claimant?s
actions in accordance with the Code is necessary.
The Commissioner?s initial rejection of Mrs. Dorton?s claim ?shall be final
unless the employer, employee, claimant or dependent shall, within thirty days
after the receipt of such notice, object, in writing, to such finding?
(23-5-1). Mrs. Dorton?s objection was filed within three days of the receipt of
the notice, and was therefore a valid objection.
Upon receipt of the objection, the commissioner ?shall .
set a time and place for the hearing of
evidence? (23-5-1). Mrs. Dorton had two such hearings on her claim.
The law further provides:
?After final hearing the commissioner shall . . . render
his decision .
. . which shall be final: Provided, that
the claimant or the employer may apply to the appeal board . . within thirty days of receipt of notice of the
commissioner?s final action, or in any event within sixty days of the date of
such final action, regardless of notice? (23-5-l).
Mrs. Dorton did not apply to the appeal board regarding the final action of the
Commissioner. Had she done so, a hearing would have been held before the appeal
board, and, if
W. VA.]
REPORTS STATE COURT OF CLAIMS 139
she wished to protest the board?s
decision, a further appeal would have been possible under ?23-5-4:
?From any final decision of the board, including any order of remand, an
application for review may be prosecuted by either party, or by the
commissioner, to the supreme court of appeals within thirty days from the date
thereof. ..
It is clear from the record of this claim
that ample administrative remedies were available to the claimant, the
exhaustion of which would have led to a review by the West Virginia Supreme
Court of Appeals. It has been this Court?s position in a number of previous
cases that a claimant who has not exhausted his administrative and judicial
remedies cannot avail himself of the jurisdiction of this Court. Nichols Engineermg and Research Corporation v. State
Tax Commissioner, 9 Ct.Cl. 4 (1971).
We have also ruled that the remedies provided by Workmen?s Compensation are
exclusive and final. Hodges
v Dept. of Mental Health, 9 Ct.Cl. 76
(1972).
In addition, ?14-2-13 of the West Virginia Code extends the jurisdiction of
this Court to claims and demands, liquidated and hnliquidated, ex contractu and
ex delicto, against the State or any of its agencies, which the State as a
sovereign commonwealth should in equity and good conscience discharge and pay,
except for those claims excluded by ?14-2-14, which provides:
?The jurisdiction of the court shall not extend to any claim . . . 2. For a disability or death benefit under chapter
twenty-three [23-1-1 et seq.] of this Code.?
Therefore, as claimant herein has failed to exhaust her admtraH remedies, and,
as this Court?s jurisdiction does not extend to Workmen?s Compensation cases,
the claim must be denied.
Claim disallowed.
140 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued April 26, 1982
NOVO CORPORATION
vs.
DEPARTMENT OF HIGHWAYS
(CC-78- 175)
Vincent V. Chaney and Michael T.
Chaney, Attorneys at Law, for the
claimant.
Stuart Reed Waters, Jr., Attorney at Law, for the respondent. WALLACE, JUDGE:
The claimant, Novo Corporation, in conjunction with the Danbourne Corporation,
entered into a contract with the respondent in July of 1973 for the
construction of Cheat Lake Bridge near Morgantown, West Virginia. The project,
ACAPD 481 (31), was a joint venture of the two corporations. In addition to the
construction of the bridge, the contract provided for the construction of land
pier #6 and abutment
#2 on the east end of the bridge, and land pier #1 and abutment #1 on the west
end. Novo Corporation was responsible for the fabrication and delivery of all
structural steel. The Danbourne Corporation was responsible for the erection of
the steel and all the field work involved in completing the bridge.
Piers 2, 3, 4, and 5 in Cheat Lake were to be constructed by Allied Structural
Steel Company.
The Mashuda Corporation had the contract with the respondent to do the site
preparation work in the areas of the land piers and abutments.
Both contracts were awarded at about the same time as was the contract to Novo,
that is, in July 1973.
The above corporations will be referred to herein as ?Novo,? ?Danbourne,?
?Allied,? and ?Mashuda.?
Respondent issued its notice to proceed to Novo on August 2, 1973. Land piers 1
and 6 and abutments 1 and 2 were to be completed late in 1974; however, the
Mashuda Corporation
W. VA.] REPORTS STATE COURT OF CLAIMS 141
did not have the site preparation work
complete until June 25, 1975. Allied was to have piers 2, 3, 4, and 5 available
for bridge construction on November 30, 1974, but they were not completed and
accepted by the respondent until April 23, 1975.
After the site preparation was completed by Mashuda and the lake piers were
completed by Allied, Novo and Danbourne were able to proceed under the terms of
Novo?s contract with the respondent. The erection of the structural steel then
proceeded very close to the original estimated required time after the piers
were available, but the workers were forced to work in the winter of 1975-76.
These delays were brought to the attention of the respondent by letter from the
claimant dated January 27, 1975. In that letter, claimant requested a time
extension of 287 calendar days and a change order covering cost escalation
caused by the delays. A meeting was held in respondent?s Charleston office on
March 10, 1975, with representatives of the respondent, Allied, Mashuda, and
claimant, Novo, concerning the availability of the piers in the lake and the
site preparations. Later, the claimant, by its letter of January 13, 1977,
submitted a claim for additional compensation in the amount of 409,033.00. A
meeting was held at respondent?s office a year later on January 8, 1978,
concerning the validity of the claim. The respondent?s March 28, 1978, letter
to the claimant refused the claim but granted an extension of 155 calendar
days, revised the completion date to October 4, 1976, and waived liquidated
damages. The respondent had originally assessed 188 days of liquidated damages.
Subsequent to the completion of the project, the claimant filed its claim
against the respondent in the amount of $424,234.39. At the hearing, the claim
was amended by reducing the amount to $373,982.00. The claim consisted of
increased costs allegedly incurred by reason of the delays. Thcse included
additional labor costs, material and subcontract costs, finance costs, field
overhead, and home office costs.
The record establishes that the availability of the piErs being constructed by
Allied was delayed 4.75 months before the erection of the structural steel
could commence. This resulted in
142 REPORTS
STATE COURT OF CLAIMS [W. VA.
additional delays in the work to be
performed subsequent to the completion of the structural steel work. After the
erection of the structural steel, the bolting-up process commences. Then comes
the placing of the deck known as ?stay in place? deck, or ?SIP.? This is
eventually followed by the placing of the reinforcing steel and pouring of the
deck, parapet, and walls. The bolting-up process was delayed .75 month and the
installation of the SIP deck was delayed 1.75 months. The bolting-up and the
SIP work are labor-intensive items, that is, they are performed by labor. The
delays caused the work to be performed in the winter months, which had a
tremendous impact on productivity. The total delayed time was 7.25 months.
The delays in the completion of the work to be performed by Allied and Mashuda
delayed the commencement by the claimant of the work under its contract with
the respondent. However, the claimant was able to complete its work in the same
amount of time required under its time schedule as approved by the respondent.
The extension of the completion time and the waiver of liquidated damages by
the respondent are evidence that the respondent recognized that the delays were
not the fault of the claimant. The contract was bid with the expectation that
it would be completed within the estimated time frame. When the project did not
commence as scheduled, the claimant incurred additional expenses for labor and
materials. The increases in labor costs between the original estimated
completion date and the actual date were $14,735.00 for iron workers, $4,775.00
for carpenters, $4,670.00 for laborers, $1,906.00 for cement finishers, and
$546.00 for operating engineers. The increase In material costs during this
period were concrete, $60,797.00, resteel, $8,117.00, and paint, $112,500.00
including $37,000.00 paid to the original paint subcontractor for work
performed.
The claimant also contends that it incurred additional costs of $67,500.00 for
field operating expenses and $82,963.00 for home office expenses. It further
claims 1% per month on monies retained by the respondent, in the amount of
$15,473.00.
The Court is of the opinion that the claimant is entitled to
W. VA.]
REPORTS STATE COURT OF CLAIMS 143
recover the established fixed labor
increases for the iron workers, carpenters, laborers, cement finishers and
operating engineers in the total amount of $26,632.00, and the fixed increases
in material costs for concrete, and paint, less the $37,000.00 previously paid
in the amount of $136,297.00.
The cost of the reinforced steel is denied as included in the contract price of
the caissons. The percentages estimated for field overhead and home office
costs are considered speculative and are denied. The one per cent retainage is,
in effect, an attempt to collect interest which the Court, by statute, cannot
award.
Accordingly, the Court makes an award to the claimant of
$162,929.00.
Award of $162,929.00.
Opinion issued April 26, 1982
BESSIE M. STONE, BY
CHARLES H. STONE, HER ATTORNEY IN FACT
vs.
DEPARTMENT OF HIGHWAYS
(CC?79-35)
Stephen C. Littlepage,
Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Bessie M. Stone filed this claim against the respondent by her son, Charles H.
Stone, as her attorney in fact, asking for removal of a ferry approach road
over the claimant?s property in Henderson, West Virginia.
After the Silver Bridge collapse at Point Pleasant, West Virginia, on December
15, 1967, it was necessary to establish ferry service between West Virginia and
Ohio. In early 1968, a ferry approach and access road were built by the
respondent in Henderson, West Virginia. The access road was constructed
144 REPORTS STATE
COURT OF CLAIMS [W. VA.
from Locust Street to the ferry approach on the Kanawha River over a parcel of
land owned by the claimant. This road was used for traffic until a new bridge
was built and opened in December of 1969.
The road was used again for ferry service when the new bridge was closed for
repairs from July to October 1977. The claimant and respondent are presently
litigating the amount of compensation for this temporary use in a condemnation
suit brought by the respondent.
The claimant contends that by virtue of a letter dated February 23, 1968, from
the respondent to John G. Anderson, the attorney for the Town of Henderson,
that the respondent was required to remove the access road from claimant?s
property after the ferry service was terminated; that the letter was a contract
between the respondent and the Town of Henderson; and that the claimant was a
third-party beneficiary of the contract. The pertinent part of the letter
relied upon by the claimant states:
?The access from Locust Street to the river edge will also be maintained by the
Commission, and, upon termination of the ferry service, the access road will be
removed and that section of sidewalks removed will be replaced.?
Claimant did not know of the existence of this letter until a copy was furnished
her counsel in the fall of 1978.
In its Answer, the respondent contends that the claim was not in the proper
form; that the claim was a proper matter for a condemnation proceeding; and
that the claimant was barred by the doctrine of laches. Respondent also filed a
motion to dismiss on the grounds that the claim is barred by the statute of
limitations.
By a post-hearing stipulation, the cliamant and the respondent submitted to the
Court two leases and a sublease to be considered as part of the record in this
claim. All of the insiruments are of record in the Office of the Clerk of the
County Commission of Mason County, West Virg?nia, where the leased premises are
situate. One of the leases, dated January 31, 1968, and recorded March 18,
1968, in Deed Book 208 at page
W. VA.J
REPORTS STATE COURT OF CLAIMS 145
531, which was executed by the
claimant and her late husband, leases to Ohio Valley Towing, Inc., two parcels
of land ?for use as roadways and approaches to ferry landing. . .for the incidental use in the ferry service.? One of
the parcels is in the City of Point Pleasant, being the river frontage between
?Lot 125 and the Kanawha River at the foot of Main Street,? the other being Lot
5 in the Town of Henderson over which the road in question runs. The lease
provided for an annual rental of $730.00, representing $365.00 for each parcel
for a term of five years, and for ?such further number of years as may be
desired by Ohio Valley until a bridge across the Ohio River near Point Pleasant
shall have been built and opened...? The lease further provided:
?Improvements made to said parcels by Ohio Valley or anyone for it, or on its
behalf, including the State Road Commission shall remain on said parcels after
the termination of this lease, including but not limited to any and all
roadways, streets, permanent ramps.
The other lease, recorded in Deed Book 200 at page 174, is an agreement dated
February 1, 1966, and recorded February 24, 1966, between the claimant and her
late husband to R. E. &
E. Towing, Inc., a corporation. According to that document, claimant?s river
front property on the Kanawha River was leased for a period of fifty years at a
rental of $350.00 per year.
R. E. & E. Towing, Inc., subleased to Ohio Valley Towing, Inc., by
instrument of record in Deed Book 208 at page 529, dated January 31, 1968, and
recorded March 18, 1968, the parcel that extended along the Kanawha River bank
in front of Lot 5 above Ferry Street to the mouth of the Kanawha River. This
sublease contained the same clause herein above quoted, which was not contained
in the original lease, that improvements made to the property, including
roadways, were to remain on the parcels leased.
The sublease provided for a rental of $365.00 per year, and the same term of
?five years and for such further years until a bridge across the Ohio River
near Point Pleasant shall have been built and opened.?
There is no provision in the statute creating this Court wherein it can order
or direct an agency to accomplish certain
146 REPORTS
STATE COURT OF CLAIMS [W. VA.
acts or perform certain work. This
Court has no authority or jurisdiction to order the respondent to remove the
road. Its authority extends only to an award of damages. If the Court finds for
the claimant, any such finding must sound in damages.
The claimant relies upon the letter of February 23, 1968, as a contract between
the respondent and the Town of Henderson, and believes the claimant to be a
third-party beneficiary of the contract. The lease agreements entered into by
the claimant and the towing company provide that any roadway constructed shall
not be removed. The leases provided that compensation be paid to the claimant.
The leasing of the premises in question by the claimant eliminates the aspect
of a taking by the respondent. If the respondent had taken the premises without
just compensation, the claimant would have the remedy of mandamus to compel the
respondent to condemn the premises.
From the record in this claim, the Court is of the opinion that the leasing of
the premises by the claimant, and the provision in the lease against removal of
the road, bars recovery by the claimant for damages to her property.
Accordingly, the claim is disallowed.
Claim disallowed.
Opinion issued April 26, 1982
AUDREY P. TITTLE, ADMINISTRATOR
OF THE ESTATE OF STEVEN B. PARCELL
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-48)
Andrew J. Goodwin and Edward
C. Goldberg, Attorneys at Law, for the
claimant.
Henry C. Bias, Jr., Deputy Attorney General, and Nancy J. Aliff, Attorney at Law, for the respondent.
WALLACE, JUDGE:
Audrey P. Tittle, Administrator of the Estate of Steven B. Parcell, filed this
claim against the respondent for $250,000.00
W. VA.]
REPORTS STATE COURT OF CLAIMS 147
as the result of an accident in which
Steven B. Parcell lost his life.
On the morning of February 22, 1978, Steven B. Parcell was driving his 1976
Mercury automobile westerly on an elevated portion of Interstate 64 in
Charleston, West Virginia. The weather was cold and snowy. At a point near the
Court Street ramp, the Parcell vehicle crossed the westbound lane, struck the
median barrier or parapet on the left-hand side, went over the side, and
crashed to the ground below. Mr. Parcell was killed. The decedent was a young
man of twenty- six years, unmarried, who lived alone. Formerly, he had made his
home with his mother, who had been separated from her husband for eight or nine
years. Mr. Parcell had been an employee of the post office at Belle, West
Virginia.
The claimant alleges that the respondent was negligent in its failure to remove
the accumulation of snow next to the parapet, which formed a ramp over which
the decedent?s vehicle left the highway.
A witness for the claimant, Robert Goddard, testified that he was proceeding in
the eastbound lane of the interstate at the time of the accident, that he saw
the decedent?s vehicle in the westbound lane about two blocks before it left
the highway, and that it was at an angle pointed toward the eastbound lane. He
stated:
?That?s what called it to my attention first because of him being in an angle
in the highway and he, evidently, was traveling on the right lane headed west
and, like I say, when noticed him, he was at an angle, with his nose pointed
towards the?it would be towards his left and seemed to be?there was a white
vehicle. I don?t know whether it was white or cream colored or what. It was a
light vehicle?was going?was stopped. I mean it was completely still. His bumper
was towards the retaining wall at the break of the Court Street entrance. It was
pointed out into the middle of the highway and, evidently, I mean it looked
like it may have aimed to miss this vehicle setting in this peculiar situation,
see, and his vehicle never recovered. . .
148 REPORTS STATE
COURT OF CLAIMS [W. VA.
He traveled across the left lane striking the retaining wall at the angle, I?d
say, his left front?left front part of his vehicle where he hit the retaining
wall first, you know, rode up this snow that was piled against the retaining
wall or something and then it got up on top of the retaining wall and it sort
of nosed down slightly, rolled up on its side and then that was the last I seen
of it.?
Mr. Goodard further testified that the vehicle struck the wall at an angle of
about 45 degrees, that he couldn?t estimate its speed, and that he did not know
the condition of the road in the westbound lane.
Sergeant David Mickel of the Accident Investigation Bureau of the Charleston
Police arrived at the accident scene at about 8:30 am. He took photographs of
the automobile tracks, made measurements of the markings made by the vehicle on
the parapet, and went below the interstate and measured the distances the
vehicle travelled after it fell from the wall. Sergeant Mickel testified that,
according to his estimate, the automobile struck the parapet at an angle of
65-75 degrees; that it rode along the top of the parapet 69 feet, 5 inches; and
that it struck the face of the outside wall of the eastbound lane and then fell
between the east and westbound elevated sections 0 the roadway. The vehicle continued its forward motion for
30 feet as it fell 29 feet to the ground, where it skidded 32 feet, 4 inches on
its top. The sergeant further testified that two westbound travel lanes were
being used, snow and ice were built up on the sides, and traffic was moderate.
He stated:
?The highway was in a hazardous condition to the point that you could not
maintain 50 miles per hour which is the speed limit.?
He further stated that he did not believe that the road could have been
negotiated safely at a speed in excess of 40 miles per hour under those
conditions.
Garland Steele, Chief Engineer of Operations for the respondent, testified that
it was the practice of the State, during the early stages of interstate-highway
snow removal, to clear the travel lanes first and to store snow on adjacent
shoulders prior to its removal.
W. VA.J
REPORTS STATE COURT OF CLAIMS 149
The record establishes that the
parapet was 32 inches high and 1?/2 feet wide at the top. Photographs introduced into evidence
show the accumulation of snow beside the parapet over which the decedent?s
vehicle travelled. Although no measurements were given at the hearing, the
height of the snow against the parapet appears, from the photographs, to be 15
to 20 inches below the top of the parapet, and does not seem to be a solid
mass.
Dr. Carl Rotter, Professor of Physics from West Virginia University, having
been given all of the photographic exhibits and the factual situation of the
accident, was asked to use principles of physics in giving his opinion of the
speed of the decedent?s automobile when it struck the median barrier. Dr.
Rotter testified that, using the factual situation as outlined to him, and
assuming that the vehicle struck the barrier at an angle of 45 degrees, the
velocity of the automobile toward the parapet would have been 73 feet per
second, which translates to a speed of 50 miles per hour. He further testified:
?. . if you change the angle to 75 degrees, (as testified to
by Sgt. Mickel), the speed would have been 140 miles per hour and I think that
is extravagant. So I don?t think 75 degrees is in any way correct in analysis
of the motion of the car.? (Parenthetical statement supplied.)
As sympathetic as the Court may be regarding the loss of life resulting from
the accident, the Court finds, from the record, that the claimant has failed to
establish actionable negligence on the part of the respor dent that caused the
accident. On the contrary, the physical facts of this claim create an
inescapable inference that the decedent was travelling at an excessive rate of
speed, taking into consideration the condition of the highway. To operate a
motor vehicle in disregard of the visible condition of the roadway constituted
assumption of a known risk. See Swartzmiller
v. Department of Highways, 10 Ct.Cl.
29 (1973). A person operating a vehicle on a public highway must consider all
existing conditions with regard to his own safety and the safety of others.
West Virginia Code, Chapter 17C, Article 6, Section 1(a), provides:
?No person shall drive a vehicle on a highway at a speed
150 REPORTS
STATE COURT OF CLAIMS [W. VA.
greater than is reasonable and prudent
under the conditions and having regard to the actual and potential hazards,
then existing.
(3) (c) The driver of every vehicle shall, consistent with the requirements of
subsection (a), drive at an appropriate reduced speed. . .when special hazard exists. . by reason of weather or highway conditions.?
This Court has many times held that the State is not a guarantor of the safety
of travelers on its highways, and that the user of the highways travels at his
own risk. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2nd 81(1947); Parsons v. State Road Commission, 8 Ct.Cl. 35 (1969). For the reasons herein set out, the
Court disallows this claim.
Claim disallowed.
Advisory Opinion issued May 20, 1982
WELDING, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82--76)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant Welding, Inc. seeks payment of the sum of $22,- 950.00 for furnishing
and installing a hot water boiler system at the West Virginia State Prison for
Women.
According to claimant?s petition, on or about December 13, 1981, the prison
warden telephoned Welding, Inc., informed the company that it was the low
bidder on the project, and advised the claimant to begin work as soon as
possible. As the old boiler had suffered a major explosion and was condemned by
an Insurance Commission inspector, the situation was deemed an emergency by the
respondent Department of Corrections under West Virginia Code ?5A-3-17,
?Emergency purchases in open market.? There was an urgent need for hot
W. VA.]
REPORTS STATE COURT OF CLAIMS 151
water at the Women?s Prison for inmate
showers, dishwashing, and laundry. An emergency requisition form was prepared
at Pence Springs and received in Charleston on December 23, 1981. No one was
available in the Central Office to process the requisition until December 29,
at which time it was forwarded to the Purchasing Division.
Mr. Cummings, of the Purchasing Division, disapproved the emergency request. At
that time, the boiler from Welding, Inc. was already on the grounds of the
prison, and workmen had dismantled the old boiler and were working on fittings
for the new or.e. There was no evidence of any intentional wrongdoing in the
handling of the situation; rather, it merely was a case of administrative
error.
The respondent has filed an Answer admitting the allegations of the Notice of
Claim and the fact that the claim arose under an existing appropriation. The
respor dent further states that the matter is one to be considered under the
provisions of West Virginia Code ?14-2-19, ?Claims under existing appropriations,?
which states:
?A claim arising under an appropriation made by the legislature during the
fiscal year to which the appropriation applies, and falling within the
jurisdiction of the court, may be submited by:
1. A claimant whose claim has been rejected by the state agency concerned or by
the state auditor.?
The Code section further provides:
?If the court finds that the claimant should be paid, it shall certify the
approved claim and award to the head of the appropriate state agency, the state
auditor, and to the governor. The governor may thereupon instruct the auditor
to issue his warrant in payment of the award and to charge the amount thereof
to the proper appropriation.?
In view of the foregoing, the Court hereby finds the respondent liable, and
grants an award to the claimant in the amount of $22,950.00. The Clerkof the
Court is hereby directed to forward copies of this Opinion to the Commissioner
of the
152 REPORTS
STATE COURT OF CLAIMS [W. VA.
Department of Corrections, the State
Auditor, and the Governor, as provided by law.
Opinion issued May 21, 1982
GORDON A. BOBBITT
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-62)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant herein seeks payment of the sum of $265.25 for the installation of new
carpet at respondent?s Anthony Center. Respondent admits the validity and
amount of the claim, but also states that there were not sufficient funds on
hand at the close of the fiscal year in question from which the claim could
have been paid.
While we feel that this claim should, in equity and good conscience, be paid,
we cannot make an award, based upon the principles established in the case of Airkem Sales and Service, et at. v. Department of
Mental Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opoiion issued May 21, 1982
DEPARTMENT OF HIGHWAYS
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-57)
Nancy J. Aliff, Attorney at Law, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks
W. VA.]
REPORTS STATE COURT OF CLAIMS 153
payment of the sum of $194.63 for
repairs performed on a Plymouth vehicle at the request of the respondent.
Invoices for the material and labor, sent to the Department of Corrections?
Work Release Program, remain unpaid.
Respondent, in its Answer, admits the validity and amount of the claim, but
states also that sufficient funds were not on hand at the close of the fiscal
year in question from which the obligation could have been paid.
While we feel that this is a claim which, in equity and good conscience, should
be paid, we also are of the opinion that an award cannot be made, based on our
decision in Airkem SaLs and Service,
et al. v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued May 21, 1982
GRAFTON CITY HOSPITAL
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-36)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks payment of the sum
of $108.00 in medical bills ir.curred by an inmate of respondent?s Grafton Work
Release Center. Respondent admits the allegations of the Notice of Claim, but
further alleges that no funds remained in its appropriation for the fiscal year
in question from which the obligation could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we also are of the opinion that an award cannot be made, based on our
decision in Airkem Sales
154 REPORTS
STATE COURT OF CLAIMS [W. VA.
and Service, et al. v. Department
of Mental Health, 8
Ct.C1. 180 (1971).
Claim disallowed.
Opinion issued May 21, 1982
LARRY GREATHOUSE
vs.
DEPARTMENT OF HEALTH
(CC-82-64)
No appearance by claimant.
Curtis G. Power, III, Assistant Attorney General, for respondent.
PER CURIAM:
Claimant seeks payment of the sum of $204.00 for clothing lost while he was a
patient at Huntington State Hospital in February, 1982. The issue in this case
is whether or not the respondent can be held liable for the loss of property
entrusted to its care.
The situation created clearly was a bailment. While it has been held that a
bailee is not liable to his bailor for loss of property caused by robbery, Tancil v. Seaton, 69 Va. 601 (1877), a bailee is liable where he fails to exercise
ordinary care for the safety of property in his hands. 2B M.J., Bailments, ?11.
Claimant?s clothing was delivered over to employees of the respondent when he
checked into the hospital, and, when he checked out, a leather coat and a pair
of blue jeans were missing.
Based on the foregoing facts, the respondent admitted liability in its Answer,
and, accordingly, the Court makes an award to the claimant of $204.00,
representing the value of the property at the time of loss.
Award of $204.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 155
Opinion issued May 21, 1982
PAULINE G. MALCOMB
vs.
ALCOHOL BEVERAGE CONTROL COMMISSIONER
(CC-80-275)
Robert P. Martin, Attorney at Law, for claimant.
Gene Hal Williams, Deputy Attorney General, for respondent.
WALLACE, JUDGE:
The claimant seeks to recover $73,5Ol.4 expended in remodeling her store and
barn for use as a liquor store for the sale of alcoholic beverages as an agency
of the respondent.
At a pre-trial conference held in this matter, it was determined that the claim
be bifurcated and only the question of liability be heard and determined at
this hearing.
The claimant had become acquainted with a person by the name of Jim Morgan who
was connected with the Snowshoe Ski Resort in Pocahontas County, West Virginia.
Mr. Morgan was interested in obtaining a permit for a liquor agency to serve
the resort, but, for reasons unrelated to this hearing, was denied a permit.
Claimant was advised by Morgan of the possibility of establishing an agency on
her premises in the unincorporated community of Slatyfork, West Virginia, in
Pocahontas County. In fact, he furnished her an application form and
accompanied Gary Hamrick, of the Alcohol Beverage Control Commissioner, on his
first visit to the claimant. Claimant was told that Slatyfork was a good
location because of its proximity to the Snowshoe resort. The claimant operated
a small restaurant and gas station in Slatyfork which she remodeled for the
purpose of installing a liquor store. Respondent?s representatives had
indicated that there was not sufficient storage space, and claimant remodeled
and converted an old barn on her premises to be used as the store. Although the
store and storage area were supposed to be in the same premises, claimant was
given permission to store liquor in her
156 REPORTS
STATE COURT OF CLAIMS [W. VA.
garage until remodeling was complete.
Claimant testified that no remodeling started until a permit was issued.
On June 12, 1979, claimant made application to the responc ent to become a
State alcohol beverage agency. An agency agreement dated July 25, 1979, was
executed by the claimant and respondent after proper bond was furnished by
claimant. The agency opened for business in Slatyfork on November 8, 1979. It
was later determined that Pocahontas County was a dry county as the result of a
local option election held on May 25, 1954. Claimant was notified to close the
agency effective January 17, 1980, and the agency agreement was terminated
February 16, 1980.
Mr. Hamrick, in his testimony, stated that the ABC Commissioner used a prepared
list of all counties in West Virginia, and that Pocahontas County was listed as
a wet county.
The claimant testified that she had no knowledge of the referendum in May of
1954 when the county voted dry. She was thirty years old in 1954 and a resident
of the county. Because of the referendum, the respondent contends that the contract
with the claimant was void and unenforceable, and there can be no liability on
the part of the respondent. The claimant knew that the respondent had
established liquor stores in the incorporated towns of Cass and Marlinton, both
in Pocahontas County, and that it had been negotiating with Mr. Morgan, who
wanted to establish an agency at the Snowshoe Ski Resort six miles from
Slatyfork. The claimant was not an attorney nor was she represented by one at
that time. She could not have been expected to be fully aware of the legal
requirements necessary to make a perfectly formal contract with the State.
Claimant was certainly justified in accepting the representations of the
respondent. In the case of Cook v.
Dept. of Finance and Administration, 11
Ct.Cl. 28 (1975), this Court held,
?The Court cannot absolve the State of liability from a contract which its
agent made without compliance with the letter of the law where a private
citizen has been injured by the agents? actions in behalf of the State, especially
when there has been no question, except technically, as to the agents?
authority.?
W. VA.J
REPORTS STATE COURT OF CLAIMS 157
The Court is of the opinion that the
respondent is liable to the claimant for damages sustained by the claimant,
fully realizing that consideration must be given to any benefits realized by
the claimant. This claim is therefore held open for further evidence with
regard to the damages sustained by the claimant.
Opinion issued May 21, 1982
THE MICHIE COMPANY
vs.
DEPARTMENT OF HEALTH
(CC-82-35)
No appearance by claimant.
Curtis G. Power, III, Assistant Attorney General, for respondent.
PER CURIAM:
Claimant seeks payment of the sum of $163.31 for update material to the West
Virginia Code. An invoice for the material remains unpaid.
As the respondent admits the validity of the claim, and avers that sufficient
funds were available in its appropriation for that particular fiscal year from
which the obligation could have been paid, the Court makes an award to the
claimant in the amount requested.
Award of $163.31.
Opinion issued May 21, 1982
ANGELA PRESTON
vs.
ATTORNEY GENERAL?S OFFICE
(CC-82-79)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
PER CURIAM:
Claimant herein seeks payment of the sum of $110.00 for
158 REPORTS
STATE COURT OF CLAIMS [W. VA.
court reporter services furnished to
the Attorney General?s Office. The respondent admits the validity and amount of
the claim, and, as sufficient funds remained in its appropriation for the
fiscal year in question from which the claim could have been paid, the Court
hereby makes an award to the claimant in the amount requested.
Award of $110.00.
Opinion issued June 30, 1982
ACE ADJUSTMENT SERVICE, INC.,
AGENT FOR UNITED HOSPITAL CENTER, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-78)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $325.00 in hospital expenses for an inmate of
respondent?s Huttonsville Correctional Center. The prisoner, while a patient at
Memorial General Hospital in Elkins, West Virginia, underwent a Computerized
Axial Tomography, or CAT-scan, by the United Hospital Center, Inc., through its
?CAT-scan van.? United Hospital sent the bill to Huttonsville. After receiving
no response, they turned the bill over to Ace Adjustment Service, Inc.
While we feel that this claim should, in equity and good conscience, be paid,
we must decline to make an award, based on our decision in Airicem Sales and Service, et al. v. Dept. of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 159
Opinion issued June 30, 1982
APPALACHIAN ENGINEERS, INC.
vs.
DEPARTMENT OF FINANCE & ADMINISTRATION
(CC-82-90)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $1,076.16 for engineering services performed for the
respondent on its main unit air conditioning. The invoice for such services was
not presented for payment in the fiscal year in which the work was done, but
sufficient funds remained in the respondent?s appropriation for that fiscal
year from which the obligation could have been paid.
Accordingly, the Court makes an award of $1,076.16 to the claimant.
Award of $1,076.16.
Opinion issued June 30, 1982
CAROL JO BROWN
vs.
DEPARTMENT OF HEALTH
(CC-82-81)
Claimant appeared in her own behalf.
Curtis G. Power, III, Assistant Attorney General, and Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
PER CURIAM:
Claimant herein seeks payment of the sum of $546.13 for 8? days of accumulated
annual leave in accordance with the Civil Service Rules and Regulations which
went into effect December 1, 1981. A new provision in those Rules allows cer
160 REPORTS
STATE COURT OF CLAIMS [W. VA.
lain employees with over ten years of
regular employment to carry forward more than 30 days from one calendar year to
another. The State Auditor refused payment to the claimant beyond the 30-day
period.
The authority to establish rules and regulations is granted to the Civil Service
Commission by West Virginia Code ?29-6- 10, which states, ?The commission shall
have the authority to promulgate, amend or repeal rules, in accordance with
chapter twenty-nine-A [29A-l-1 et seq.] of this Code, to implement the
provisions of this article.? Chapter 29A, referred to above, sets forth State
administrative procedures, including rule making.
There was no evidence in this claim that proper rulemaking procedures were not
followed by the Civil Service Commission in establishing the provision allowing
certain employees to carry forward over 30 days from one year to the next.
Furthermore, the respondent, in its Answer, admits the validity and amount of
the claim, and states that sufficient funds remained in its appropriation for
the fiscal year in question from which the obligation could have been paid.
Accordingly, the Court makes an award of $546.13 to the claimant.
Award of $546.13.
Opinion issued June 30, 1982
ARLENE BURGESS and
CHARLES E. BURGESS
vs.
DEPARMENT OF HIGHWAYS
(C-82-84)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
On February 28, 1982, an automobile owned by the claimants nd driven by Arlene
Burgess struck potholes in Route 119 near Marmet, West Virginia, damaging two
tires and their
W. VA.J
REPORTS STATE COURT OF CLAIMS 161
rims. The claimants assert that the
accident was caused by respondent?s negligence, and seek damages in the sum of
$169.22.
The State is neither an insurer nor a guarantor of the safety of motorists travelling
on its highways. Adkins v. Sims, 130 W.Va. 645 (1947); Lowe v. Department of
Highways, 8 Ct.Cl. 210 (1971). Therefore, a claimant must prove
that the respondent failed to conform to a standard of ?reasonable care and
diligence. .
.under all the circumstances.? Parsons v. State Road Commission, 8 Ct.Cl.
35 (1969). In the instant case, the potholes were located on the right-hand
edge of the pavement, and they were filled with water. There is no evidence
that the respondent had either actual or constructive notice of those potholes.
See Davis v. Department of Highways, 12 Ct.Cl. 31 (1977); Swift v. Department of Highways, 10
Ct.Cl. 56 (1974). Accordingly, the evidence is not sufficient to establish
negligence on the part of the respondent, and this claim must be denied.
Claim disallowed.
Opinion issued June 30, 1982
CHARLESTON BUSINESS MACHINES
vs.
STATE TAX DEPARTMENT
(CC-82-54)
Jerry Lewis appeared for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
PER CURIAM:
Claimant seeks payment of the sum of $139.95 for a missing Victor 100
calculator which had been loaned to the Procurement Office of the State Tax
Department.
At the hearing, Mr. Jerry Lewis, owner of Charleston Business Machines,
stated that the cost of the machine to his com
162 REPORTS
STATE COURT OF CLAIMS [W. VA.
pany was ?probably about $95.00 to
$98.00.? Counsel for the respondent offered no evidence to refute the claim.
It is obvious that a bailment situation existed between claimant and respondent.
While a bailee is not liable for loss of property caused by robbery, Tancil v. Seaton, 69 Va. 601 (1877), a bailee is liable where he fails to exercise
ordinary care for the safety of property in his hands. 2B M.J., Bailments, ?11.
The Court finds that the respondent did not meet that standard of ordinary care
in regard to the calculator which was on loan from the claimant, and, based on
the foregoing facts, the Court makes an award to the claimant in the amount of
$95.00.
Award of $95.00.
Opinion issued June 30, 1982
CHERYL M. FIDLER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-50)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
On February 15, 1982, an automobile owned and driven by the claimant struck a
pothole on Oakwood Road in Charleston, West Virginia, necessitating a
realignment of the vehicle. The claimant asserts that the accident was caused
by the respondent?s negligence, and seeks damages in the sum of $24.25.
The State is neither an insurer nor a guarantor of the safety of motorists
travelling on its highways. Acikins v.
Sims, 130 W.Va. 645 (1947); Lowe v. Department of Highways, 8 Ct.Cl 210 (1971). A claimant must prove that the
respondent failed to conform to a standard of ?reasonable care and diligecce.
under all the circumstances.? Parsons
v. State Road Commis
W. VA.]
REPORTS STATE COURT OF CLAIMS 163
sion, 8 Ct.Cl. 35
(1969). In the instant case, the pothole was located on the claimant?s
right-hand side of the pavement, and was filled with water. There is no
evidence that the respondent had either actual or constructive notice of the
pothole. See Davis v. Department of Highways, 12 Ct.Cl. 31 (1977); Swift v. Department of Highways, 10
Ct.Cl. 56 (1974). Accordingly, the evidence is not sufficient to establish
negligence on the part of the respondent, and this claim must be denied.
Claim disallowed.
Opinion issued June 30, 1982
ATHOLL W. HALSTEAD
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-40)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant filed this action to recover damages in the amount of $84.50 as the
result of an accident in which claimant?s 1977 Mercury Cougar struck a pothole
on West Virginia State Route 3 near Comfort, West Virginia.
The law of West Virginia is well established that the State is neither an
insurer nor a guarantor of the safety of travellers on its highways. Acikins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947), Parsons v. State Road Commission, 8
Ct.Cl. 35 (1969). There is no evidence in the record of any prior notice to the
respondent. The existence of road defects without notice to the respondent is
not sufficient to establish negligence. Proof that the respondent had notice of
the defect in the road is necessary. Lowe
v. Dept. of Highways, 8 Ct.Cl. 210
(1971).
Accordingly, the Court is of the opinion to and does hereby disallow the claim.
Claim disallowed.
164 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued June 30, 1982
SANDRA W. PHILLIPS LARESE
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-70)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
On December 25, 1981, Donald C. Phillips was operating claimant?s automobile on
U.S. Route 52 near Elkhorn, West Virginia. The automobile struck a pothole on
the right-hand side of the road damaging the rim and the valve, and resulting
in the loss of two wheel covers. The claimant asserts that the accident was
caused by the respondent?s negligence and seeks damages in the sum of $258.80.
The law of West Virginia is well established that the State is neither an
insurer nor a guarantor of the safety of travellers on its highways. Adhins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947), Parsons v. State Road Commission, 8
Ct.Cl. 35 (1969). There is no evidence in the record of any prior notice to the
respondent. The existence of road defects without notice to the respondent is
not sufficient to establish negligence. Proof that respondent had notice of the
defect in the road is necessary. Lowe
v. Department of Highways, 8
Ct.Cl. 210 (1971).
Accordingly, the Court is of the opinion to and does hereby disallow the claim.
Claim disallowed.
Opinion issued June 30, 1982
EUGENE P. MULLINS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-8)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant herein alleges damages to his 1974 Chevrolet
W. VA.]
REPORTS STATE COURT OF CLAIMS 165
Impala which resulted when the vehicle
struck a pothole on
West Virginia Route 41 on January 2, 1982, while the claimant
was proceeding from Beckley, West Virginia, to his home at
Terry, West Virginia.
The pothole struck by claimant?s vehicle was located on the right-hand side of
the road, partly in the berm and partly in the paved portion of the highway.
Claimant?s vehicle sustained damages in the amount of $155.78 as a result.
No evidence was introduced to prove knowledge, either actual or constructive,
of the existence of the pothole on the part of the respondent. The law is well
established in West Virginia that the State is neither an insurer nor a
guarantor of the safety of persons travelling on its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). Before the respondent can be held
liable, there must be some showing that the respondent knew or should have
known of the defect in the highway. Accordingly, the Court disallows the claim.
Claim disallowed.
Opinion issued June 30, 1982
ELDEAN RUSSELL
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-60)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
On February 17, 1982, claimant Eldean Russell was operating her 1976 Ford
Torino automobile on State Route 3 in Comfort, West Virginia, when the right
front and right rear tires struck a pothole causing damage to the right rear
tire. The claimant testified that the damage was in the amount of $98.00.
The law of West Virginia is well established that the State is neither an
insurer nor a guarantor of the safety of travellers on
166 REPORTS STATE
COURT OF CLAIMS 1W. VA.
its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947), Parsons v. State Road Commission, 8 Ct.Cl. 35 (1969). There is no evidence in the record
of any prior notice to the respondent. The existence of road defects without
notice to the respondent is not sufficient to establish negligence. Proof that
the respondent had notice of the defect in the road is necessary. Lowe v. Department of Highways, 8 Ct.Cl. 210 (1971).
As the claimant lived near the area where the pothole was located and was
familiar with the pothole, the claimant herself was guilty of negligence which
equalled or surpassed that of the respondent.
Accordingly, the Court must disallow this claim.
Claim disallowed.
Opinion issued June 30, 1982
RENNA J. WILCOX
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-63)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
On February 16, 1982, an automobile owned and operated by the claimant struck a
pothole on North Kanawha, a street located in Beckley, West Virginia, and
maintained by the respondent. As a result of striking the pothole, the
automobile sustained damage to the right front tire and was knocked out of
alignment. The claimant asserts that the accident was caused by the
respondent?s negligence, and seeks damages in the sum of $116.28.
The State is neither an insurer nor a guarantor of the safety of motorists
travelling on its highways. Adkins v.
Sims, 130
W. VA.]
REPORTS STATE COURT OF CLAIMS 167
W.Va. 645 (1947); Lowe v. Department of Highways, 8 Ct.Cl. 210
(1971). A claimant must prove that the respondent failed to conform to a
standard of ?reasonable care and diligence in the maintenance of a highway
under all the circumstances.? Parsons
v. State Road Commission, 8 Ct.Cl. 35
(1969). In the instant case, the pothole was located on the claimant?s right-
hand side of the pavement and was filled with water. There is no evidence that
the respondent had either actual or constructive notice of the pothole. See Davis v. Department of Highways, 12 Ct.C1. 31 (1977); Swift v. Department of Highways, 10 Ct.Cl. 56 (1974). Accordingly, the evidence is not sufficient to
establish negligence on the part of the respondent, and this claim must be
denied.
Claim disallowed.
Opinion issued July 1, 1982
JACK E. BROWN
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-6)
Paula G. Brown appeared for the claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
On November 11, 1981, Paula G. Brown was operating claimant?s 1976 Ford Pinto
wagon on W.Va. Route 60, a four-lane highway in Belle, West Virginia. She was
proceeding east towards Montgomery, West Virginia, when she approached a
bridge. While upon the bridge, she slowed down and attempted to avoid a small
pothole in the right-hand portion of the right lane of travel, but then hit a
larger pothole in the center of the two eastbound lanes. As a result of striking
the pothole, the claimant incurred a towing charge in the amount of $15.00,
replacement costs for the tire and rim in the amount of $105.06, and costs for
the repair of wiring in the vehicle in the amount of $32.03, for a total of
$152.09 in damages. At the hearing it
168 REPORTS
STATE COURT OF CLAIMS [W. VA.
was determined that the vehicle was titled in the name of
Jack E. Brown, the husband of Paula G. Brown. The Court thereupon amended the
style of the claim to reflect the name of the owner of the vehicle.
Photographs of the pothole struck by claimant?s vehicle revealed the pothole to
be of sufficient depth that the steel reinforcing rods on the bridge were
exposed. U.S. Route 60 is one of the most heavily travelled highways in the
State. The nature and extent of the pothole demonstrate that it must have been
in existence for some appreciable time before the accident happened.
While the respondent is not an insurer of those using its highways, it does owe
a duty of exercising reasonable care and diligence in the maintenance of the
highways. If the respondent knows or should know of such a defect in the
highway, as in this case, it must take the necessary steps within a reasonable
period of time to repair the defect. Lohan v. Dept. of Highways, 11
Ct.Cl. 39 (1975).
From the record, and for the reasons herein set out, the Court makes an award
of $152.09 to the claimant.
Award of $152.09.
Opinion issued July 1, 1982
CHICAGO EMBROIDERY COMPANY
vs.
OFFICE OF THE SECRETARY OF STATE
(CC-82-91)
Kevin Blackwell, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant herein seeks payment of the sum of $3,468.07 for cloth emblems of the
State seal purchased by the respondent. The claim is submitted for decision
upon the pleadings, which reveal that the claim is valid and that sufficient
funds remained
W. VA.]
REPORTS STATE COURT OF CLAIMS 169
in respondent?s appropriation for the
fiscal year in question from which the obligation could have been paid.
Based on the foregoing, the Court hereby makes an award to the claimant in the
amount requested.
Award of $3,468.07.
Opinion issued July 1, 1982
PATRICIA ANN HALL and LACY HALL
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-442)
Claimant Patricia Ann Hall appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
On September 10, 1981, Patricia Ann Hall was driving her 1975 Mercury Bobcat
automobile on W.Va. Route 49 between Matewan and Delorme, West Virginia. The
claimant was proceeding toward Matewan at approximately 1:00 to 1:30 p.m. It
was a clear day and the road surface was dry. As the claimant topped a small
knoll, she came upon a rock fall in the road which covered the entire lane of
claimant?s lane of travel and some of the opposite lane. The claimant was then
forced to ?cut over to miss it and almost went over the guardrail on the other
side. .
. .? The claimant?s vehicle sustained
damages in the amount of $1,846.78.
The testimony in this claim established that the rock slide had occurred
sometime the previous day and that the Department of Highways had been notified
of the slide, but no signs were placed to warn the traveling public of the
hazard, nor was the slide removed in a timely manner. As the slide covered the
major part of the road, it was forseeable that vehicles using the road might
have an accident. The respondent?s failure to remove the slide or erect warning
devices constituted negli
170 REPORTS
STATE COURT OF CLAIMS [W. VA.
gence and was the proximate cause of
the accident. Farley v. Dept. of Highways, 13 Ct.Cl. 63 (1979).
The State is neither an insurer nor a guarantor of the safety of persons
traveling on its highways. Adkins v.
Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947). However, the State can be found liable if the maintenance of its roads
falls short of a standard of ?reasonable care and diligence. . under all the circumstances.? Parsons v. State Road Comm?n., 8 Ct.Cl. 35 (1969). Accordingly, the Court makes an
award to the claimant in the amount of $1,846.78.
The record indicated that the title to the vehicle was in the names of Patricia
Ann Hall and Lacy Hall. Accordingly, the Court amended the style of the claim
to include both parties as claimants.
Award of $1,846.78.
Opinion issued July 1, 1982
THE HERTZ CORPORATION
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-82-137)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Damages in the amount of $600.00 were caused to a Hertz vehicle while being
driven by an employee of the Department of Public Safety on November 11, 1981,
in Clearwater, Florida.
As the respondent admits the validity and amount of the claim, the Court makes
an award to the claimant in the amount admitted.
Award of $600.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 171
Opinion issued July 1, 1982
JOHNSON CONTROLS, INC.
vs.
DEPARTMENT OF FINANCE & ADMINISTRATION
(CC-82-87)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $2,856.20 for maintenance and service on mechanical
equipment in the State Capitol Complex buildings, including work on chillers,
air-handling units, pumps, and temperature controls. The respondent answers and
says that there was a failure on the part of the claimant to bill the
Department of Finance & Administration in the same fiscal year in which the
work was performed. However, sufficient funds remained in the respondent?s
appropriation from which the obligation could have been paid.
In view of the foregoing, the Court hereby makes an award to the claimant in
the amount admitted.
Award of $2,856.20.
Opinion issued July 1, 1982
LIBERTY MUTUAL INSURANCE COMPANY,
SUBROGEE OF EDWARD E. and
JENNIFER DILLING, and EDWARD E.
and JENNIFER DILLING
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-93)
William E. Mohier, III, Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant Edward E. Dilling was involved in an accident on July 18, 1979, at
approximately 9:30 or 10:00 p.m. on Route
172 REPORTS
STATE COURT OF CLAIMS [W. VA.
39 near St. Marys, West Virginia.
Claimants contend that the accident was the result of negligence on the part of
respondent?s employee in failing to properly park an endloader on the edge of
Federal Ridge Road (State Route 39) such that the bucket of the endloader
jutted into the travelled portion of the roadway. Claimants further allege that
respondent?s employees were negligent in failing to place warning devices or
signs to inform the travelling public of the presence of the endloader. As a
result of the accident, the claimant Edward Dilling suffered personal injuries,
and his 1979 Chevrolet pickup truck sustained damages in the sum of $2,639.24.
At the time of the accident, the claimant was driving upgrade into a curve. He
testified that the head lights of a vehicle approaching from the opposite
direction blinded him and that the pickup truck then struck the bucket of the
endloader.
Sherwood Wince, an equipment operator for the respondent, testified that he had
been operating the endloader on a construction project to set piling. His usual
procedure was to park the endloacler between two stacks of piling, as far off
the roadway as possible, with the bucket dipped down. He had parked the
endloader in this manner on the evening of the accident described herein. No
flashing lights or warning signs were placed in the vicinity of the parked
endloader.
Thomas Aubrey, claims investigator for the respondent, testified that he
visited the accident site and took measurements of the width of Federal Ridge
Road approximately where the endloader was parked. The gravel portion of the
road measured 27 feet in width and the berm measured 11 feet in width.
From the record, the Court is of the opinion that the failure of the respondent
to place a warning light to indicate the presence of the endloader was
negligence. However, the Court finds that the claimant, in failing to
appreciably slow down his truck when blinded by the lights of the oncoming
vehicle, was himself guilty of negligence which proximately contributed, to the
extent of 25 per cent, to cause the accident and his resulting injuries and
damages. Adkins v. Department of
Highways, 13 Ct.Cl. 355 (1981).
The claimant sustained a concussion, bruises, and a lacera
W. VA.] REPORTS
STATE COURT OF CLAIMS 173
tion to his right leg for which he incurred medical expenses aggregating
$691.90 as follows: Marietta Memorial Hospital, $513.66; Radiology Services,
Inc., $110.40; Phillips Pharmacy, $12.84; and Larry B. Gale, M.D., $55.00.
Liberty Mutual Insurance Company paid all of the medical expenses and all but
the $100 deductible of the property damage. Claimant Edward Dilling?s injuries
were not permanent in nature. In view of all of the evidence, the Court
determines the damages to be $3,231.14 to Liberty Mutual Insurance Company, and
$100.00 to claimants Edward E. and Jennifer Dilling, which sums must
necessarily be reduced by 25 per cent to reflect the contributory negligence of
claimant Edward E. Dilling.
Award to Liberty Mutual Insurance Company of $2,423.35.
Award to Edward E. and Jennifer Dilling of $75.00.
Opinion issued July 1, 1982
MOORE BUSINESS FORMS, INC.
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-82-41)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based upon the Notice of Claim and an
Amended Answer. Claimant seeks payment of the sum of $2,586.61 for forms
printed for the Department of Public Safety.
As the respondent, in its Amended Answer, admits the amount and validity of the
claim, and as sufficient funds remained in its appropriation for the fiscal
year in question from which the claim could have been paid, the Court makes an
award to the claimant in the amount admitted.
Award of $2,586.61.
174 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued Ju?y 2, 1982
DONALD E. ASHLEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-61)
Imo gene Jean Ashley for the claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
On February 9, 1982, Imogene Jean Ashley was operating a 1976 Oldsmobile on
West Virginia Route 119 proceeding south toward Charleston, West Virginia. It
was approximately 5:30 fl.m. on a misty, dark morning. Mrs. Ashley had just
picked up her rider, and the two of them were on their way to work when she
came upon rocks in the road. She attempted to miss the rocks by straddling a
large one, but, in so doing, damaged the underside of the automobile. This
claim was filed by Imogene Jean Ashley but the Court amended the style of the
claim to correspond with the name of the registered owner. Damages to the
vehicle were in the amount of $227.43.
Mrs. Ashley testified that she had observed rock slides in this area of State
Route 119 on prior occasions. She further testified that two employees of the
respondent came upon the scene shortly after the accident. They informed her
that they had just received a call that the rock fall had occurred.
Thomas Aubrey, a claims investigator for the respondent, testified that his
investigation revealed that a call had been received in the office of the
Kanawha County Sheriff at about 5:30 a.m. informing the respondent of the rock
fall on State Route 119.
There is no evidence that the respondent knew or should have known of the
existence of an unusually dangerous condition, and it is apparent from the
evidence that the rocks had fallen just prior to the accident. From the record
there is no showing of negligence on the part of the respondent, and
accordingly, the Court disallows this claim. See Botyarcl v. Department of
Highways, 12 Ct.Cl. 344 (1979).
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 175
Opinion issued July 2, 1982
DOROTHY M. GORE
vs.
DEPARTMENT OF HIGHWAYS
(CC-81- 16 1)
Tom Zerbe, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant filed this claim against the respondent for the value of her 1970
Chevrolet Nova automobile as the result of n accident which occurred on West
Virginia Route 20 between Bluestone Dam and Bluestone Bridge on September 21,
1979. On the evening of the accident, the claimant had picked up her friend,
Ken G. Milliner, and, because she was tired, allowed him to drive. The claimant
and Milliner?s cousin, Billy Jones, were passengers. They were proceeding
northerly on West Virginia Route 20 to Hinton, West Virginia, at about
8:30-9:00 p.m. Blue- stone Lake was on the right side and a cliff was located
on the left side of the highway. It had been raining and was very foggy. The
claimant, who was familiar with the road, had warned the driver to watch for
falling rocks. The driver testified that he was travelling about 25-30 mph and
that the headlights were on low beam. As they approached the area of the
Bluestone Bridge, an oncoming vehicle flashed its lights, and, shortly
thereafter, claimant?s automobile struck a rock in the highway. The vehicle
went over the embankment and landed upside-down fifty feet from the lake. The
driver stated that because of the bright lights of the oncoming vehicle and the
fog, he was unable to see the rock.
The claimant testified that her automobile was a total loss; that she had
purchased it in June or July of 1979 for $550.00; that she had done
considerable repairs on it, and that she could have sold it for $700.00 at the
time of the accident. No other evidence of value was introduced, and no mention
was made cf the salvage value of the vehicle.
176 REPORTS
STATE COURT OF CLAIMS [W. VA.
In addition to the claimant and the
driver of the automobile, three witnesses testified on behalf of the claimant.
Dean Lowry, Sr., and Albert L. Ward, former employees of the respondent,
testified that they were familiar with the particular section of West Virginia
Route 20 where the accident occurred. Both witnesses testified that the road
was constructed in the late 1940?s; that rock falls were frequent, especially
in wet and freezing weather; that it was necessary to remove rocks on numerous
occasions; and that nothing had been done by the respondent to correct the
situation. Nancy Moles testified that she had been living four miles away in
Hinton for 46 years; that she works at Bluestone State Park and travels the
road to and from work; and that she was familiar with the road and with slides
which occur in wet weather.
Bill Hanshaw, District 9 Engineer, testified for the respondent:
?The route runs generally north and south from the Bluestone Dam to the
Bluestone Bridge. It?s generally rolling in nature. It?s bounded on the east
side by the Bluestone Lake and on the west side by varying heights of cut
slopes from approximately 20 feet high to nearly 200 feet high..
The cut slopes are composed of layers of shale and earth and the erosion action
from the weathering causes the cut slope to shear off at times with small to
large rocks, particularly in the wet freezing season. This is common with many
cuts throughout West Virginia. We have investigated these particular cut slopes
with the idea of trying to correct that situation; however, this is a major
undertaking. It?s placed on a priority list with many other projects. We just
haven?t proceeded to find funding to move ahead on this project.?
The respondent maintains ?Falling Rock? signs in the area beside the highway.
Of necessity there are thousands of cuts and fills upon West Virginia highways.
Many cuts are made through rock. If it were possible to prevent rocks from
falling from the resulting
W. VA.J REPORTS
STATE COURT OF CLAIMS 177
rock cliffs, there would be no need to warn the travelling public of that
danger by ?Falling Rock? signs. Having been warned, as in this case, it is the
duty of the travelling public to heed such warning and it would be unreasonable
to impose liability for damage resulting from fallen rocks unless it is proved
that the respondent knew, or in the exercise of ordinary care, should have known
of the particular slide involved. Since that was not proved in this case, the
Court cannot conclude that the respondent was guilty of negligence which caused
the claimant?s damage.
Claim disallowed.
Opinion issued July 2, 1982
CHARLES L. KINNEY and
JOYCE I. KINNEY d/b/a
THE SOUTHWOOD CARRYOUT
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-696)
George J. Cosenza, Attorney at Law, for the claimants. Nancy J. Aliff, Attorney at Law, for the respondent.
WALLACE, JUDGE:
Claimants seek damages of $240,000.00 from the respondent by reason of changes
in the traffic pattern on West Virginia Route 14 in Parkersburg, West Virginia.
Claimants operated a carry-out business known as The Southwood Carryout on
Twenty-first Avenue in Parkersburg. The business consisted of the sale of beer,
nonalcoholic beverages, and snack-type food items. Twenty-first Avenue
intersects the west side of West Virginia Route 14.
In April of 1978, the respondent undertook a change in the traffic pattern of
Route 14. A median strip separating the north and south lanes was constructed
and traffic-control de
178
REPORTS STATE COURT OF CLATMS [W. VA.
vices were installed. The work was
completed in June of 1979. The claimants contend that the changes made by the
respondent limited the access to Twenty-first Avenue from Route 14, destroying
their business.
The respondent filed its Motion to Dismiss the claim on the basis that the
claimants failed to state a cause of action upon which relief could be granted,
because the jurisdiction of this Court does not extend to any claim in which a
proceeding may be maintained against the State in the regular courts of the
State, namely, a condemnation suit. At the pretrial conference held in this
matter, the parties were asked to submit memoranda to substantiate their
respective positions.
The claimants? business was not located on West Virginia Route 14 where the
construction took place, but on Twenty- first Avenue, and there is no basis for
a proceeding in eminent domain. The Court is of the opinion, however, that the
claim presented does not establish a cause of action against the respondent.
Chapter 17, Article 2A, Section 12 of the West Virginia Code gives the West
Virginia Commissioner of Highways the right and the duty, in the interest of
safety and convenience and control of vehicular traffic, to establish regulat
ons relating to and controlling the location, construction, and maintenance of
traffic control factors. The Commissioner may not unduly interfere with any
abutting property owner?s entrance or access rights to a highway. In this
claim, the claimants? business did not abut on West Virginia Route 14 on which
the traffic pattern was changed. A non-abutting property owner is not entitled
to damages for impairment of access if reasonable and adequate access is
provided in another direction or by other means. Heavner et ai. v. State Road Commission, 118 W.Va. 630, 191 SE. 574 (1937); State ex rel. Wiley v. State Road Commission, 148 W.Va. 76, 133 S.E.2d 113 (1963).
Accordingly, respondent?s Motion to Dismiss is hereby sustained.
Claim dismissed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 179
Opinion issued July 2, 1982
DOLORES MOORE
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-240)
A. Dana Kahie, Attorney at Law, for the claimant.
Nancy J. A 11ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim in the amount of $50,000.00 was filed by the claimant against the
respondent for damages resulting from a fall on West Virginia Route 2. By
agreement of the parties, this claim was submitted to the Court for decision on
the pleadings, stipulation of damages, and the deposition of the claimant.
On June 12, 1978, the claimant had been driving southerly on Warwood Avenue in
Wheeling, West Virginia. Warwood Avenue is also West Virginia Route 2
maintained by the respondent. She parked her automobile beside the west curb in
order to go across the street to Beckett?s Flower Shop. She purchased. three
small plants and returned across the street to her vehicle where she intended
to place the plants in her automobile on the passenger side. As the claimant
proceeded around her automobile, she fell down and severely injured her foot.
It was later determined that there was a drop-off in the road surface of 1 to
l?/2 inches about 18 inches from the curb. In explaining what happened, the
claimant stated in her deposition:
?and when I came back ?
what I had purchased ? I was going to go around the car and put them in. But
when I got so far, something just, I just went down and it was this offset in
the street.?
In July of 1976, resurfacing of this particular section of Warwood Avenue, or
West Virginia Route 2, was completed by Tn-State Asphalt Co. pursuant to
respondent?s specifications. The road at the point of the accident is 38 feet
wide. To permit proper drainage, 18 inches of the existing pavement adjacent to
the curb on each side of the street was not resurfaced. This
180 REPORTS
STATE COURT OF CLAIMS [W. VA.
space of 18 inches was l-1? inches
lower than the resurfaced pavement.
The law of West Virginia is well established that the State does not guarantee
nor ensure the safety of travelers on its highways, and its duty to travelers
is a qualified one, namely, reasonable care and diligence in the maintenance of
a highway under all the circumstances. Adkins
v. Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947); Lowe v. Department of Highways, 8 Ct.Cl.
210 (1971). The roadway surface contained no defects and the respondent did not
breach its duty of reasonable care and diligence in the resurfacing of the
highway. For this Court to find for the claimant, actionable negligence on the
part of the xespondent must be established by the evidence. White v. Department of Highways, 11 Ct.Cl. 138 (1976). The lower elevation existed on
both sides of the street. The claimant traversed the curb portion on both
sides, once while crossing to the store, and again on her return to her
automobile. Had the claimant exercised reasonable care under the circumstances
and maintained a proper lookout, she would have avoided her fall and resultant
injury. Her failure to do so was the proximate cause of her injury. Welch v. Department of Highways, 12 Ct.Cl. 136 (1978); Hall v. Board of Regents, 12
Ct.Cl. 232 (1978); Winer v. Department
of Highways, 12 Ct.Cl. 353
(1979). Accordingly, the Court must disallow this claim.
Claim disallowed.
Opinion issued July 2, 1982
EARL G. MUCK
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-69)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant Earl G. Muck lives on State Road 15/6 in LibErty, Jackson County, West
Virginia. State Road 15/6 is a road
190 REPORTS STATE
COURT OF CLAIMS [W. VA.
?All claims, disputes and other matters in question between the Contractor and
the Owner arising out of, or relating to, the Contract Documents or the breach
thereof, *
* * shall be decided by arbitration in
accordance with the Construction Industry Arbitration Rules of the American
Arbitration Association then obtaining unless the parties mutually agree
otherwise. *
* * The award rendered by the arbitrators
shall be final, and judgment may be entered upon it in accordance with
applicable law in any court having jurisdiction thereof.?
Subsequently, a dispute arose between the parties based upon a claim by
Hughes-Bechtol that the respondent, on the one hand, had caused substantial
delay in performance of the contract and, on the other hand, had refused to
extend the time of performance. When amicable resolution of the dispute failed,
Hughes-Bechtol filed a demand for arbitration at the Cincinnati Regional Office
of the American Arbitration Association asserting a claim for damages in the
sum of $932,-
172.00. On December 12, 1980, it was served upon the respondent. An arbitrator
was duly appointed and, at a hearing on February 10, 1982, it was determined
that the dispute was arbitrable. A hearing upon the merits of the dispute began
on March 18 and continued on March 19, April 9 and May 29, 1981. On June 9,
1981, an award was made to Hughes-Bechtol in the sum of $521,326.48 to which fees
of $7,884.63 were added, making a total of $542,982.11. That item is included
in the present claim of $1,275,570.70 which also includes other disputes
between the parties.
The matter now is before this court upon the claimant?s motion for partial summary
judgment enforcing the arbitration award. The gist of the respondent?s position
in opposition to that motion is that the quoted arbitration provision of the
contract is void and unenforceable because this court has exclusive
jurisdiction of claims against state agencies such as the respondent and, for
that reason, the respondent had no authority to agree to arbitration. The
principal authority cited for that position is the case of J. L. Simmons Company, Inc., v. Capital Development
Board, 424 N.E.2d 821 (Ill. 1981), a
very similar case in which enforcement of an arbitration award was
W. VA.]
REPORTS STATE COURT OF CLAIMS 189
edge of the existence of this defect,
this Court is of the opinion that it did have constructive notice. Route 119 is
one of the main arteries for motorists travelling north in Kanawha County.
Furthermore, the size of the pothole, as reflected in the photographs,
graphically demonstrates its presence for a long period of time prior to the
date of the accident. See Stone v.
Department of Highways, 12 Ct.Cl. 259
(1979). BEing of the opinion that the record as a whole clearly establishes
negligence on the part of the respondent, this Court hereby makes an award in
favor of the claimants in the amount of $122.00.
Award of $122.00.
Opinion issued July 26, 1982
HUGHES-BECHTOL, INC.
vs.
BOARD OF REGENTS
(CC-81-450)
E. Glenn Robinson, Attorney at Law, and David L. Wyant, Attorney at
Law, for claimant.
Victor A. Barone, Deputy Attorney General, and Henry C. Bias, Jr., Deputy Attorney General, for respondent.
RULEY, JUDGE:
This claim grows out of a written contract upon a printed form designated AlA
Document AlOl, Owner-Contractor Agreement, incorporating AlA Document A201,
General Conditions of the Contract for Construction, dated March 14, 1979, and
duly executed by the claimant and respondent, respectively. The contract
provides for the construction of a MultiPurpose Physical Education Facility at
Marshall University, in Huntington, for a fixed sum of $3,162,173.00. The
contract was approved by: the Director of the Purchasing Division; the
Commissioner of the Department of Finance & Administration; and, finally,
by the Attorney General on April 9, 1979. Paragraph 7.9.1 of the General
Conditions, pertaining to Arbitration, provides:
188 REPORTS
STATE COURT OF CLAIMS [W. VA.
While we believe that this claim
should, in equity and good conscience, be paid, we further believe that an
award cannot be made, based on our decision in Airkem Sales and Service, et al. v.
Dept. of Mental Health, 8 Ct.Cl. 180
(1971).
Claim disallowed.
Opinion issued July 13, 1982
HARRY R. SELLARDS and FRANCIS A.
SELLARDS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-83)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimants filed this claim in the amount of $432.00 for damage to their 1981
Oldsmobile which occurred when the vehicle struck a pothole on U.S. Route 119
in Hernshaw, Kanawha County, West Virginia.
Mr. Sellards, the driver of the vehicle, testified that he was proceeding north
on Route 119 at approximately 9:00 p.m. on the evening of March 16, 1982. He
estimated his speed to be 40-50 mph. It had been raining, and the road was wet.
Suddenly, the car struck a pothole located on the right-hand side of the road.
Mr. Sellards stated that the last time he had driven that road was three or
four weeks prior to the date of the accident, at which time the hole did not
exist.
Damage to the wheels of claimants? automobile totalled $432.10. Of that amount,
claimants paid a $122.00 deductible; the rest was paid by their insurer.
Therefore, the actual amount of their claim is $122.00.
While the respondent is not an insurer of the safety of motorists using the
highways of this State, it does have the affirmative duty of using reasonable
care for their safety. While there was no direct evidence that the respondent
had actual knowl
W. VA.J
REPORTS STATE COURT OF CLAIMS 187
curred on May 21-23, 1979, incident to
testing by employees of the respondent was filed on July 29, 1981. The
applicable period of limitation prescribed by West Virginia Code, ?55-2-12, is
two years. West Virginia Code, ?14-2-21, relating to jurisdiction of the Court,
provides, in part:
?The court shall not take jurisdiction of any claim, whether accruing before or
after the effective date of this article [July 1, 1967], unless notice of such
claim be filed with the clerk within such period of limitation as would be
applicable under the pertinent provisions of the Code of West Virginia, one
thousand nine hundred thirty-one, as amended, if the claim were against a
private person, firm or corporation and the constitutional immunity of the
State from suit were not involved and such period of limitation may not be
waived or extended.***?
Accordingly, this Court has no jurisdiction of this claim and cannot consider
the same.
Claim disallowed.
Opinion issued July 13, 1982
MOUNTAINEER MOTOR SALES, INC.
vs.
FARM MANAGEMENT COMMISSION
(CC-82-106)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks payment of the sum
of $86.87 for a tachometer purchased by the respondent.
The respondent, in its Answer, admits the validity and amount of the claim, but
further states that there were insufficient funds remaining in its
appropriation for the fiscal year in question from which the claim could have
been paid.
186 REPORTS
STATE COURT OF CLAIMS [W. VA.
Advisory opinion issued July 13,
1982
DEPARTMENT OF HIGHWAYS
vs.
FARM MANAGEMENT COMMISSION
(CC-82-58)
Nancy J. Aliff, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $8,379.91 for aggregate and gas and lube purchases made
by the Farm Management Commission.
Respondent answers and says that the claim is valid and the amount is correct,
but that no funds remained in its appropriation for the fiscal year in question
from which the obligation could have been paid.
While we feel that this claim should, in equity and good conscience, be paid,
we further believe that an award cannot be made, based on our decision in Airkem
Sales and Service, et al, v. Dept. of Mental Health, 8 Ct.Cl. 180
(1971).
Claim disallowed.
Opinion issued July 13, 1982
JOYCE HUPP
vs.
OFFICE OF THE CHIEF MEDICAL EXAMINER
(CC-8 1-238)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent WALLACE,
JUDGE:
This claim in the sum of $392.96 for property damage to an air conditioning
unit in claimant?s dwelling house which oc
W. VA.]
REPORTS STATE COURT OF CLAIMS 185
Q.
And your car stalled?
A. Yes.
Q. Then I presume he struck you?
A. Yes, he backed on top of the hood of my car.?
Ray Pack, a foreman for the respondent, testified that at the time of the
accident the road grader was pulling shoulders. There were signs on both ends
of the operation indicating ?Shoulder Work? and ?Flagmen Ahead.? The flagman on
one end would pass a ring to the last vehicle in the line of traffic to give to
the flagman on the other end for the one-lane traffic pattern to proceed around
the shoulder work. Mr. Pack testified as follows:
.as the traffic was going through, Mrs. Wheeler got in the right-hand lane
behind the grader and our laborer that was between the flagman and the grader
directed her to the left-hand lane. As soon as she passed the laborer then, she
got back in the right-hand lane behind the grader and followed him to a stop.?
Mr. Pack did not observe the accident as it occurred in the curve out of his
view.
The road grader operator, Emery Plumley, testified that he was backing up in
the usual manner on a ditching project; that he bad observed traffic proceeding
around him in the other lane; and that he looked back and then proceeded to
back up, whereupon the grader struck claimant?s vehicle. He did not observe the
claimant?s vehicle prior to striking it.
The Court is constrained to hold that, under the factual situation presented
here, the claimant?s failure to remain in the line of traffic directed to
proceed around this ditching operation was negligence which was the proximate
cause of the damage to her vehicle. Accordingly, the Court must disallow the
claim.
Claim disallowed.
184 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued July 2, 1982
DREMA FAYE WHEELER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-39)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant Drema Faye Wheeler suffered damage to her 1974 Buick Impala in an
accident with a road grader operated by an employee of the respondent.
On September 1, 1981, claimant was proceeding on State Route 19/21 Bypass when
she approached a flagman with a ?Slow? flag who was directing vehicles around a
road grader. The road grader was in claimant?s lane of travel. Claimant
testified as follows:
A. ?Well, I was driving and I saw a flagman with a ?Slow? flag. So all the
traffic was going slow and there was a grader up ahead and as each vehicle got
behind the grader, it would go around it. When I got behind him, it was in a
curve and I couldn?t see to go around him and I was going to follow him so
around the curve until I could see, and he stopped and I stopped.
Q. This was the grader operator?
A. Yes, and he started backing up. When I seen that he wasn?t going to even
look back, then I started to put my reverse in to move the car and go back and
it stalled on me.
Q. You started to back up?
A. Yes, sir.
W. VA.]
REPORTS STATE COURT OF CLAIMS 183
way of the respondent, the Court is of
the opinion to and does hereby disallow this claim.
Claim disallowed.
Opinion issued July 2, 1982
RANDALL E. ROWLEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-16)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
On December 26, 1981, claimant Randall Rowley was operating his 1980 Buick
Regal on 1-77 southbound just north of the Kenna Exit when he approached a
bridge on the interstate. He noticed several holes in the right-lane of the
bridge, so he moved into the left-lane to avoid the holes; in so doing, the
claimant?s vehicle struck a hole at the end of the bridge in the left-lane. The
left front tire of claimant?s vehicle was damaged as well as the rim and wire
wheel cover. The damages sustained by claimant?s vehicle are in the amount of
$201.62.
This Court has often held that the State is not an insurer of the safety of
highway travelers. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). To be held liable,
the respondent must have had either actual or constructive notice of the
hazardous condition of the highway. As no such evidence of notice was presented
in the instant case, the respondent cannot be found negligent. Accordingly, the
Court hereby disallows the claim.
Claim disallowed.
182 REPORTS
STATE COURT OF CLAIMS [W. VA.
to his driveway caused by water
run-off in the drainage ditch which flows on both sides of the driveway. This
ditch line located on Dairy Road is owned and maintained by the respondent.
During 1977, Dairy Road was resurfaced. At that time, Mr. Philpot experienced
problems with water flowing over the driveway instead of through the culvert
under the driveway.
Claimant?s residence was constructed in 1976. During the construction, the
contractor placed a culvert under the driveway and a steel grate at the end of
the driveway over a concrete box culvert. Mr. Philpot experienced no water or
erosion problems until Dairy Road was resurfaced and rock placed in the ditch
lines in front of his residence. Claimant informed the respondent of these
problems, and the respondent removed some of the rocks from the ditch line.
Since that time, Mr. Philpot has experienced water and erosion problems with
his driveway during heavy rains. No estimate for the cost of repairing the
driveway or the steel grate over the box culvert were submitted by the
claimant.
Kenneth W. Rumbaugh, a District One Maintenance Assistant for the respondent,
testified that he had inspected the claimant?s property in response to a
complaint from him. Mr. Rumbaugh explained that the ditch of dump rock was
placed by the respondent to prevent erosion and to slow down the flow of water
in order to minimize any damage that the water itself might cause. He also
testified that a permit from the respondent is necessary for any construction
upon the right of way of the respondent. The permit requires ?that whatever
construction, whether it be a driveway or a drainage facility or anything
else?whatever is being constructed is required to be constructed and maintained
by the property owner.?
From the record, the Court cannot conclude that the damage to claimant?s
driveway was due to any negligence on the part of the respondent. In fact, the
respondent has maintained the ditch line in the usual and customary manner for
hillside residential areas. As it is the responsibility of the property owner
to maintain driveways constructed upon the rights of
W. VA.]
REPORPS STATE COURT OF CLAIMS 181
owned and maintained by the
respondent. The claimant filed for damages to his 1976 Plymouth station wagon
when the vehicle became stuck in mud on State Road 15/6. The cost of repairing
the vehicle was $670.95.
The claimant contends that this road has been poorly maintained by the
respondent since 1978. Photographs of the road taken subsequent to claimant?s
accident depict a muddy, rut- filled road.
The respondent?s County Superintendent, Everett Parrish,
testified that the maintenance performed on Route 15/6 from
1978 through 1982 was in excess of what would normally be
done to this particular class of road. He further testified that
15/6 ?is a stabilized road with aggregate and a gravel cover
on top of that? and that it is a class 4/5 priority road.
The record in this claim establishes that Route 15/6 is a road that has been
maintained as well as could be expected given its classification as a class 4/5
priority road. For this Court to substitute its judgment as to the amount of
maintenance to be afforded to roads of this type, for the judgment of the
respondent, would be an arrogant misuse of power and might place an impossible
economic burden upon the respondent. Accordingly, the Court cannot conclude
that there was negligence on the part of the respondent.
Claim disallowed.
Opinion issued July 2, 1982
RICHARD T. PHILPOT
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-47)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant Richard T. Philpot is a resident of Dairy Road in Poca, West Virginia.
Mr. Philpot filed this claim for damages
W. VA.]
REPORTS STATE COURT OF CLAIMS 191
denied because the Illinois Court of
Claims has exclusive jurisdiction of the matter arbitrated. An examination of
the Illinois Statute cited in that case, delineating the jurisdiction of its
Court of Claims, Ill. Rev. Stat. 1979, Ch. 37, ?439.8, and upon which the
decision turned, however, discloses that it provides:
?The court shall have exclusive jurisdiction to hear and determine the
following matters:
* * *
(b) All claims against the State founded
upon any contract entered into with the State of Illinois.
* *
*,?
In view of that statute, that decision
could not have been otherwise. West Virginia has no similar statute.
West Virginia does have substantial statutory and case law on the subject of
arbitration and, if nothing else is clear, it is certain that the policy of the
law of this state favors arbitration. In Board
of Education v. W. Harley Miller, Inc., W.Va.
236 S.E.2d 439 (1977), our Supreme Court of Appeals stated:
?* *
* Where parties to a contract agree to
arbitrate either all disputes or particular limited disputes arising under the
contract, and where the parties bargained for the arbitration provision, then,
arbitration is mandatory, and any causes of action under the contract which by
the contract terms are made arbitrable are merged, in the absence of fraud,
with the arbitration award and the arbitration award is enforceable upon a
complaint setting forth the contract, the arbitration provision, and the award
of the arbitrators upon motion for summary judgment made at the proper time.
[4] The important words in the new rule are that the agreement to arbitrate
must have been ?bargained for.?
* *
*,?
If the agreement to arbitrate in this case
was not ?bargained
192 REPORTS
STATE COURT OF CLAIMS [W. VA.
for,? in view of its various
approvals, it would be difficult to conceive one that was.
In addition, West Virginia Code, ?55-10-1, provides:
?Persons desiring to end any controversy, whether there be a suit pending
therefor or not, may submit the same to arbitration, and agree that such
submissions may be entered of record in any
court. Upon proof of such agreement
out of court, *
* * it shall be entered in the proceedings
of such court; and thereupon a rule shall be made that the parties shall submit
to the award which shall be made in pursuance of such agreement. * * *? (Emphasis supplied).
The emphasized language ?any court? plainly is broad enough to include this court
and it is equally plain that the legislature could have excluded this court
from the operation of that statute had it wished to do so.
Finally, the general law appears to be to the effect that a state or its
agencies may enter a valid contract with a private party providing for the
arbitration of disputes that may arise under the contract. See 5 Am. Jur. 2d ?Arbitration and Award? ?67 and also 81A C. J. S. ?Arbitration? ?168c, page 636,
where it is stated:
?The parties to a contract for state improvements may agree to select an umpire
or arbitrator to settle disputes as to the interpretation of the contract, and
the rights of the parties thereunder, and his decision is binding in the
absence of fraud or bad faith; * * *,?
Since there is no assertion of fraud or
bad faith in this case. this court is obligated to grant the pending motion and
allow the award of $542,982.11. In addition, it appears proper to stay
proceedings in this court as to the remaining matters in dispute pending their
arbitration. See Zando, Martin &
Milstead, Inc. v. State Building Commission, 13 Ct.Cl. 354 (1981).
Award of $542,982.11.
W. VA.1
REPORTS STATE COURT OF CLAIMS 193
Opinion issued September 20, 1982
NORMAN E. BENSON
vs.
DEPARTMENT OF HIGHWAYS
(CC?79-503)
Damon Morgan, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
Claimant Norman Benson was employed by Mason County, West Virginia, as a Deputy
Sheriff. On January 4, 1979, he responded to a call concerning an accident on
the Shadle Bridge located in Point Pleasant, West Virginia. Upon arriving at
the scene of the accident, the claimant began directing traffic around a
vehicle stalled on the bridge. As he was directing traffic, he stepped into a
hole approximately two feet in length between the steel members of the bridge
deck. As a result of falling into the hole on the bridge, the claimant
sustained a broken wrist and contusions and ligament damage to his left knee.
Claimant incurred medical expenses in the amount of $765.00 and loss of wages
in the amount of $3,500.00. He still experiences pain and inconvenience from
the knee injury.
The claimant alleges that failure of the respondent to maintain the Shadle
Bridge in adequate condition was negligence, and such negligence was the
proximate cause of the injuries and losses which he incurred.
The claimant testified that he had seen the particular hole into which he fell
on the morning of the day on which he fell, and that he saw the hole again upon
arriving at the accident scene prior to directing traffic. He stated that he
forgot the existence of the hole in the course of directing the traffic. The
hole was located approximately 20 feet from the stalled vehicle in the
southbound lane of the two-lane bridge and close to the center line of the two
lanes.
Frank C. Liss, the District I Crews Maintenance Engineer, testified on behalf
of the respondent. He stated that the Shadle
194 REPORTS
STATE COURT OF CLAIMS [W. VA.
Bridge has a steel grid deck with
evidence of deterioration as one could hear the rattling of the steel when
crossing the bridge. He further testified that when the first signs of
deterioration began in 1975, crews of the respondent welded sections of the
steel deck as they broke. The second type of repair performed by the respondent
was the placement of quarter-inch, flat-welded steel over breakage areas on the
bridge deck. Eventually, the respondent let a contract to repair the bridge
deck in June, 1979. From 1975 to mid-1979, temporary repairs were effected by
respondent?s employees.
After careful consideration of the evidence and review of the photographs of
the bridge deck, the Court finds that the respondent was negligent in its
maintenance of the bridge deck [See Davis
v. Dept. of Highways, 12 Ct.Cl. 31
(1977)], and further finds that the claimant was aware of the disrepair of the
bridge and the particular hole into which he stepped, and in accordance with
the doctrine of comparative negligence was negligent to the extent of 20%
causing his own injuries. Bradley v.
Appalachian Power Co., W.Va. , 256 S.E.2d 879 (1979). Accordingly, the Court makes an
award of $7,500.00 reduced by 20% or $6,000.00.
Award of $6,000.00.
Opinion issued September 20, 1982
ELI BLANKENSHIP, JR.,
ADMINISTRATOR OF THE ESTATE
OF JOHNNY BLANKENSHIP, DECEASED
vs.
DEPARTMENT OF HIGHWAYS
(CC-76-113)
Warren R. McGraw, Attorney at Law, for the claimant. Gregory W. Evers, Attorney
at Law, for the respondent.
GARDEN, JUDGE:
At approximately 4:00 p.m. on December 7, 1975, claimant?s
W. VA.J
REPORTS STATE COURT OF CLAIMS 195
decedent, Johnny Blankenship, was
walking along Secondary Route 7 near Clear Fork, West Virginia, a highway owned
and maintained by the respondent, when he was struck and killed by a pickup
truck driven by Robert John Edwards. Mr. Edwards testified at the hearing that,
as he was rounding a curve in Route 7, he saw a boy standing near the right
side of the road, and swerved onto the berm to avoid striking him. When cutting
back onto the surface of the highway, he lost control of his truck, which shot
across the road and struck hind killed the claimant?s decedent on the opposite
side.
Testimony at the hearing further revealed that the berm along Route 7 at the
scene of the accident was lower than the paved portion of the highway; that the
drop was three to six inches; that accidents had occurred in the area prior to
the Blankenship accident; and that numerous complaints regarding the condition
of the highway had been made to the Department of Highways.
The berm of a highway must be maintained in a reasonably safe condition for use
when the occasion requires. 39 Am. Jur. 2d ?Highways, Streets, and Bridges? ?488, Taylor v. Huntington, 126 W.Va. 732, 30 S.E.2d 14 (1944). The record
indicates that there was a drop of three to six inches from a highway to its
berm, and that complaints had been made to the respondent of the condition. The
driver testified that he went off the road onto the berm to avoid hitting a
boy. In such a situation, a driver?s use of the berm would be reasonably
necessary. Athinson v. Dept. of
Highways, 13 Ct.Cl. 18 (1979).
The Court finds that the respondent was negligent m its failure to properly
maintain the berm of the highway and awards the claimant $1,702.75 for hospital
expenses, $2,511.11 for funeral and burial costs, and $10,000.00 for the
wrongful death of Johnny Blankenship, for a total of $14,213.86.
Award of $14,213.86.
196 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued September 20, 1982
J. C. BOLAND and
MICHAEL J. BOLAND
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-15)
Michael F. Gibson, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimant, Michael J. Boland, filed this claim for personal injuries to
himself and property damages to a Datsun B-210 automobile owned by his father,
J. C. Boland, as the result of an accident which occurred on April 7, 1977, on West Virginia Route 3 in Summers County, West
Virginia, near Jumping Branch. During the hearing of the claim the style of the
claim was amended to include J. C. Boland as a claimant reflecting the true
owner of the vehicle involved in the accident which is the subject of this
claim.
The claimant was proceeding to Hinton, West Virginia, when the vehicle which he
was driving, a Datsun B-210, struck a hole in the berm approximately eight to
ten feet in length, eight to ten inches in width and three to six inches in
depth. Claimant was unable to avoid striking this hole as there was an oncoming
vehicle in the left lane and several holes in the center of the road on
claimant?s left side. The claimant attempted to drive his vehicle between the
holes in the center of the road and the hole in the berm, but his vehi&le
went into the hole in the berm which caused claimant?s vehic?tg turn over on
its side and the claimant was thrown from the v?hic1e. As a result of the
accident alleged to occur due to failure on the part of the respon dent to properly
maintain the road surface and berm of State Route 3, claimant sustained
physical injuries and the
W. VA.]
REPORTS STATE COURT OF CLAIMS 197
vehicle was rendered a total loss.
Claimants filed this action in the amount of $50,000.00.
David Johnson, a witness for the claimant, testified that he had struck this
same hole in the berm of Route 3 and had called the State road garage in
Summers County around April 1, 1977, to report the condition of the berm to the
respondent.
Testimony from witnesses of respondent revealed that the only maintenance
performed on Route 3 in the vicinity of the accident site was performed by
patching with cold mix, a form of temporary repair on holes in the highways of
the State.
This Court has followed the principle that the berm or shoulder of a highway
must be maintained in a reasonably safe condition for use when the occasion
requires, and liability may ensue when a motorist is forced onto the berm in an
emergency or otherwise necessarily uses the berm of the highway. 39 Am. Jur. 2d
?Highways, Streets, and Bridges? ?488, Taylor
v. Huntington, 126 W.Va. 732, 30
S.E.2d 14 (1944).
There were potholes in the center of the roadway which claimant was attempting
to avoid and an oncoming vehicle i?0 the opposite lane. The respondent was aware of the
condition of both the berm and the road surface of Route 3. It is the opinion
of this Court that the negligence of the respondent in failing to adequately
maintain the berm was the proximate cause of claimant?s accident and resulting
injuries.
A stipulation regarding hospital and physician charges to the claimant in the
amount of $1,614.17 was filed by the parties. It was also stipulated that the
Datsun B-210 had a value of $2,775.00 at the time of the accident.
The Court, therefore, makes an award to claimant, Michael
J. Boland, in the amount of $3,500.00 and to claimant J. C. Boland in the
amount of $2,775.00.
Award of $3,500.00 to Michael J. Boland.
Award of $2,775.00 to J. C. Boland.
198 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued September 20, 1982
CARL M. GEUPEL CONSTRUCTION
CO., INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC?79?172)
Wayne A. Sinclair, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. GARDEN, JUDGE:
Carl M. Geupel Construction Co., Inc., entered into a contract with the
respondent on July 23, 1973, for the construction of Project I-IG-77-3 (113)
95, C-2, in Kanawha County, West Virginia. A subcontractor for Geupel, Hi-Way
Paving, Inc., was to supply sand and gravel for the project. Geupel has filed
this claim requesting payment for increases in transportation charges for sand
and gravel in bulk under Section 110.1 of the Standard Specifications for Roads and Bridges (1972).
When the claimant and the respondent entered into this contract, the rates for
transportation of sand and gravel in bulk were regulated by the Interstate
Commerce Commission. Five months after the contract was entered into, the
applicable section of the Interstate Commerce Act was amended. This amendment,
in effect, deregulated the transportation of sand and gravel in bulk. As a
result of this deregulation, the rates charged increased on February 15, 1974,
by $.30 per ton to a total of $1.45 per ton; on February 15, 1975, another $.30
per ton to a total of $1.75 per ton; and on. April 1, 1976, an increase of $09
per ton to a total of $1.84 per ton. The contractor requested payment for these
increases which totalled $42,758.79, but the respondent has refused payment.
The only question to be decided by this Court is whether the additional costs
arising out of the change in the ICC rate should be borne by the contractor or
by the respondent.
The Standard Specifications under which this particular contract was controlled
provides as follows:
W. VA.J REPORTS
STATE COURT OF CLAIMS 199
?110.1 Common Carrier Rates:
?The common carrier rates and taxes thereon which are current on the date of
opening the bids shall be considered as applicable to all items subject to
transportation charges thereunder.
If such rates or taxes are thereafter increased by public authority on any
materials entering into and forming a part of the contract, an amount equal to
the sum of all such increases, when evidenced by receipted common carrier
bills, will be paid to the Contractor by the Department. All claims for such
payment shall be made within 60 days after final acceptance of the work.
If such rates or taxes are thereafter reduced by public authority on any
materials entering into and forming a part of the contract, an amount equal to
the sum of all such decreases, when evidenced by receipted common carrier
bills, will be deducted by the Department from the monies due the Contractor on
the work performed under the contract.
When deliveries of materials are performed by means other than common carriers,
an increase or decrease in price will not be allowed or charged for changes in
rates or methods of delivery.?
The respondent contends that the increases requested by the contractor were not
increased by a public authority as required by Section 110.1, but by the water
carrier to its customer as the result of deregulation by the authority.
The Court finds from the record that the deregulation of transportation rates
occurred as the direct result of an act of a public authority and that an award
be made to the claimant for these increased charges. The Court directs that the
parties determine from their respective records the amount of the increased
charges and report their finding for the Court for determination of the award.
200 REPORTS STATE
COURT OF CLAIMS [W. VA.
Filed with Court of Claims on March 5,
1981
IN THE COURT OF CLAIMS OF
THE STATE OF WEST VIRGINIA
CARL M. GEUPEL CONSTRUCTION
CO., INC.,
Claimant,
V. Claim No. CC-79-172
DEPARTMENT OF HIGHWAYS,
STATE OF WEST VIRGINIA,
Respondent.
ORDER AND RECOMMENDATION
This day came the claimant, Carl M. Geupel Construction Co., Inc., by counsel,
Wayne A. Sinclair, and the respondent, Department of Highways, State of West
Virginia, by counsel, Stuart Reed Waters, Jr., and jointly represented to the
Court that as directed by the Court in its opinion issued in the above styled
claim, the parties have agreed to an amount of recovery for approval by the
Court.
It is hereby jointly recommended by Carl M. Geupel Construction Co., Inc.,
claimant, and Department of Highways, State of West Virginia, respondent, that
the claimant is entitled to recover from the respondent, the following sums of
money on the following items:
I. COMMON CARRIER RATE INCREASE
PRIOR TO FEBRUARY 15, 1976 SEE
?EXHIBIT A? ATTACHED $16,846.54
II. COMMON CARRIER RATE INCREASE
AFTER FEBRUARY 15, 1976 SEE
?EXHIBIT B? ATTACHED $21,125.09
III. TAXES AND BOND
A. 2.2% STATE BUSINESS AND
OCCUPATION $
835.38
B. 1.5% CITY BUSINESS AND
OCCUPATION $
569.57
W. VA.]
REPORTS STATE COURT OF CLAIMS 201
C. .5% BOND $ 189.86
TOTAL RECOMMENDED AWARD $39,566.44
It is further agreed by and between the claimant and the respondent hereto that
any additional amounts claimed not agreed to be paid in this recommendation, as
st out and alleged in claimant?s Notice of Claim filed in this action, are to
be disallowed and not considered by the Court for any award and are to be
dismissed.
Upon consideration of the claimant?s and respondent?s representations, the
Opinion of the Court heretofore filed in deciding the subject claim and the
recommendations set out aforesaid, the Court is of the opinion to and does
sustain the same and the same are hereby received, filed and accepted; and it
is hereby further ordered that the claimant be and it is hereby granted an
award against the respondent in the amount of Thirty-Nine Thousand Five Hundred
Sixty-Six Dollars and Forty-Four Cents ($39,566.44).
It is hereby further ordered that any additional amounts claimed and alleged in
claimant?s Notice of Claim not allowed in the above award, are hereby
disallowed.
Entered this 5th day of March, 1981.
JOHN B. GARDEN/s
Judge
Approved by:
Carl M. Geupel Construction
Co., Inc., a corporation
By WAYNE A. SINCLAIR
Its Counsel
Department of Highways,
State of West Virginia
By STUART REED WATERS, JR.
Its Counsel
202 REPORTS STATE
COURT OF CLAIMS [W. VA.
?EXHIBIT A?
Computations of the aggregate quantities set forth below were based upon item
quantities paid through February 15, 1976, Project Materials Records and/or the
Job Mix Formula for the payment items as submitted by the Contractor.
1. Item 501-1(8?) Portland Cement Concrete Pavement, Non-Reinforced Estimate
ending February 15, 1976 2,141 SY Estimate ending September 30, 1975 0
2,141 SY
SF CF
2,141 SY x 9 SY x
.67 Ft. + 27 CY = 478.16 CY
#57 Gravel 478.16 CY 1.01 Ton/CY = 482.94
Tons x
0.60
$289.76
Sand 478.16 CY x
.585 Ton/CY = 279.72 Tons X 0.60 =
$167.83
2. Item 50 1-6 (8?) Continuously Reinforced Portland Cement Concrete
Pavement
Estimate ending February 15, 1976 49,890 SY
Estimate ending September 30, 1975 18,244 SY
31,646 SY
SF CF
31,646 SY y 9 SY x
.67 Ft. ? 27 CY ? 7,067.61 CY
#57 Gravel 7,067.61 CY x
1.01 Ton/CY ? 7,138.29 Tons x
0.60 = $4,282.97
Sand 7,067.61 CY x
.585 Ton/CY 4,134.55 Tons x 0.60 = $2,480.73
3. Item
501-1 (10?) Portland Cement Concrete Pavement, Reinforced Estimate ending
February 15, 1976 16,969 SY Estimate ending September 30, 1975 9,073 SY
7,896 SY
SF CF
7,896 SY x
9 SY x .83
Ft. : 27 CY =
2,184.56 CY #57 Gravel 2,184.56 CY x 1.01 Ton/CY ? 2,206.40
Tons x
0.60 ? $
1,323.84
Sand 2,184.56 CY x
.585 Ton/CY ? 1,277.97 Tons x
0.60 =
$776.78
W. VA.] REPORTS
STATE COURT OF CLAIMS 203
4. Item
501-1 (10?) Portland Cement Concrete Pavement, Non-Reinforced
Estimate ending February 15, 1976 7,470 SY
Estimate ending September 30, 1975 1.686 SY
5,784 SY
SF CF
5,784 SY x 9 SY x .83 Ft. 27 CY = 1,600.24 CY
#57 Gravel 1,600.24 CY x 1.01 Ton/CY = 1,616.24
Tons X 0.60 =
$969.74
Sand 1,600.24 CY x .585 Ton/CY = 936.14 Tons x
0.60 =
$561.68
5. Item
502- (12?) Portland Cement Concrete Approach Slab
Estimate ending February 15, 1976 329 CY
Estimate ending September 30, 1975 164 SY
165 SY
SF CF
165 SY x 9 SY x 1 Ft. ?
27 CY = 55
CY
#57 Gravel 55 CY >< 1.01 Ton/CY ? 55.55
Tons x 0.60 =
$33.33
Sand 55 CY x
.585 Ton/CY 32.18 Tons x 0.60 = $19.31
6. Item 50 1-7 Anchor Joints
Estimate ending February 15, 1976 8 each
Estimate ending September 30, 1975 0
8 each
#57 Gravel 76.76 Tons x 0.60 ? $46.06
Sand 44.46 Tons x 0.60 ?
$26.88
7. Item 610-3(2) Combination Concrete Curb and Gutter
Estimate ending February 15, 1976 3,376 LF
Estimate ending September 30, 1975 1,241 LF
2,135 LF
57 Gravel 28.02 Tons x
0.60 ? $16.81
Sand 16.22 Tons >< 0.60 ? $ 9.73
204 REPORTS STATE
COURT OF CLAIMS [W. VA.
8. Item 501-1 (9?) Portland Cement Concrete Pavement
Estimate ending February 15, 1976 6,878 SY Estimate ending September 30, 1975
6,835 SY
43 SY
SF CF
43 SY x 9 SY x .75 Ft. +
27 CY = 10.75
CY
#57 Gravel 10.75 CY x
1.01 Ton/CY = 10.86 Tons x
0.60 = $6.52
Sand 10.75 CY x
.585 Ton/CY = 6.29 Tons x
0.60 = $3.77
9. #57 Gravel Stockpile 5,768 Tons x 0.60 ? $
3,460.80
Sand Stockpile 3,967 Tons x 0.60 ? $ 2,380.20
TOTAL $16,846.54
?EXHIBIT B?
Computations of the aggregate quantities set forth below are based or final
quantities of the various items less amounts used and stockpiled prior to
February 15, 1976.
1. Item 50 1-1 (8?) Portland Cement Concrete Pavement, Non-Reinforced
SF CF
36,291.3 SY ?
2,141 SY >< 9 SY >< .67 Ft. 27
CY 7,626.9 CY
#57 Gravel 7,626.9 y 1.01 Ton/CY ? 7,703.17
Tons x
0.69 ? $5,315.19
Sand 7,626.9 x .585 Ton/CY = 4,461.74 Tons
>< 0.60
$3,078.60
2. Item 501-6 (8?) Continuous Reinforced Portland Cement Concrete Pavement
SF CF
70,620.7 SY ?
49,890 SY >< 9 SY x .67 Ft. 27 CY ? 4,629.86
CY
#57 Gravel 4,629.86 x 1.01 Ton/CY ? 4,676.16
Tons >< 0.69 $3,226 .55
Sand 4,629.86 x .585 Ton/CY = 2,708.47 Tons
x 0.69 ?
$1,868.84
W. VA.] REPORTS
STATE COURT OF CLAIMS 205
3. Item 501-1 (10?) Portland Cement Concrete Pavement, Reinforced
SF CF
39,239.1 SY ?
16,969 SY x 9 SY x
.83 Ft. + 27 CY =
7,161.39 CY
#57 Gravel 6,161.39 >< 1.01 Ton/CY = 6,223.00
Tons X 0.69 =
$4,293.87
Sand 6,161.39 x
.585 Ton/CY = 3,604.41 Tons x
0.69 =
$2,487.04
4. Item 501-1 (10?) Portland Cement Concrete Pavement,
Non-Reinforced
SF CF
22,327.5 SY ?
7,470.0 SY x 9 SY x
.83 Ft. + 27 CY =
4,110.58 CY
457 Gravel 4,110.58 y 1.01 Ton/CY = 4,151.69
Tons X 0.69
$2,864.67
Sand 4,110.58 x
.585 Ton/CY = 2,404.69 Tons x
0.69 =
$1,659.24
5, Item 502-1 (12?) Portland Cement Concrete Approach Slab
SF CF
2,146.8 SY ?
329.9 SY )< 9 SY x 1 Ft. + 27 CY = 605.93 CY #57 Gravel 605.93 x 1.01 Ton/CY = 611.99
Tons x
0.69 = $422.27
Sand 605.93 x
.585 Ton/CY = 354.47 Tons x
0.69 = $244.58
6. Item 501-7 Anchor Joints
18 each ?
8 each at 9.5 CY/ea = 95 CY
#57 Gravel 95 x
1.01 Ton/CY = 95.95 Tons x
0.69 = $66.21
Sand 95 x
.585 Ton/CY = 55.58 Tons x
0.69 = $38.35
7. Item 6 10-3 (2) Combination Concrete Curb and Gutter
29,069.3 LF ?
3,376 LF x .013 CY/LF =
334.91 CY
#57 Gravel 334.01 x
1.01 Ton/CY = 337.35 Tons x
0.69 = $232.77
Sand 334.01 x
.585 Ton/CY = 195.40 Tons )< 0.69 = $134.83
206 REPORTS STATE
COURT OF CLAIMS [W. VA.
8. Item 501-1 (9?) Portland Cement Concrete Pavement, Reinforce and
Non-Reinforced
SF CF
13,817.2 SY ?
6,878 SY x 9 SY x .75 Ft. ? 27 CY = 1,734.8 CY
#57 Gravel 1,734.8 x 1.01 Ton/CY = 1,752.15
Tons >< 0.69 =
$1,208.98
Sand 1,734.8 x .585 Ton/CY = 1,014.86 Tons
x 0.69 =
$ 700.25
9. Less # 57 Gravel Stockpile (5,768) Tons X 0.69 = ($ 3,979.92) Sand Stockpile (3,967) Tons x 0.69 = ($ 2,737.23)
TOTAL $21,125.09
Opinion issued September 20, 1982
COCHRAN ELECTRIC COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC?76?117)
Frank A. O?Brien, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. GARDEN, JUDGE:
Claimant Cochran Electric Company, hereinafter referred to as the contractor,
entered into a contract on April 3, 1972, with the respondent for the
installation of vehicular and pedestrian traffic lights in the downtown section
of Wheeling, West Virginia. There were approximately twelve intersections
involved in the contract which required the installation of new poles to
support overhead traffic signals. For the pedestrian lights, the contractor was
to use the existing concrete bases for the support poles. These poles had
anchor bolts
W. VA.]
REPORTS STATE COURT OF CLAIMS 207
over which the poles were to fit. The
contractor ordered all of the materials for completion of the contract except
for anchor bolts which generally may be purchased as off-the- shelf items.
However, the anchor bolts were not delivered until October 1972, which delayed
the contractor in beginning construction by 26 days. The traffic poles were
delivered to the job site in December 1972. The contractor contends that the
anchor bolts were a necessary item before it could begin the excavation and
construction of the concrete bases for the traffic poles. Construction began
when the anchor bolts were received in October. The project was not completed
until November 15, 1973. The respondent calculated the project time from June
19, 1972, and, after granting time for proper delays, established a completion
date of July 12, 1973. The respondent then assessed the contractor 104 days in
liquidated damage at $100.00 per day in the amount of $10,400.00 for failing to
complete the project until November 15, 1973. The contractor alleges that the
assessment of liquidated damages was unjustified and requests an award in that
amount. The contractor also alleges that the delay caused extra costs to be
incurred in the amount of $2,100.00.
The respondent contends that in accordance with the specifications of the
contract, the contractor is responsible for all materials on the project, and,
if the contractor is delayed by reason of its failure to receive the materials
necessary for the project, the respondent is entitled to liquidated damages
under the contract for the delay. The respondent also contends that the extra
labor or materials claimed are included in the contract, and are the
responsibility of the contractor, with which the Court agrees.
The contractor contemplated the delivery of the materials in July and so
informed the respondent at a pre-construction conference on May 18, 1972.
Construction was to commence in June 1972 for site preparation. The first delay
occurred when the anchor bolts for the traffic poles were not delivered until
October 4, 1972. The poles for the traffic signals were
208 REPORTS
STATE COURT OF CLAIMS [W. VA.
not delivered by the supplier until
December 1972. The contractor claims that the respondent contributed to the
delay in delivery as the items were not approved and green-tagged by the
respondent at the site of the supplier in a timely manner.
The question to be considered herein is the propriety of the assessment of 104
days of liquidated damages. The contract provided for a completion date of May
31, 1973. The respondent extended this date to July 12, 1973. The contractor
completed the contract on November 15, 1973, and was assessed liquidated
damages for the time from July 12 through November 15.
The Court has determined that an assessment of 26 days or $2,600.00 is a fair
and reasonable assessment by the respondent for the delay attributed to the
late start by the contractor. However, the imposition of the additional 78 days
is unreasonable. The general rule for assessment of liquidated damages is found
in 22 Am. Jur. 2d ?Damages?, ?233, p. 319 as follows:
?The plaintiff cannot recover liquidated damages for a breach for which he is
himself responsible or to which he has contributed, and as a rule there can be
no apportionment of liquidated damages where both parties are at fault. Hence,
if the parties are mutually responsible for the delays, because of which the
date fixed by the contract for completion is passed, the obligation under which
another date can be substituted, cannot be revived.?
The delay by the respondent in approving the materials through the ?green tag?
process contributed to the delay, and the record fails to establish that the
respondent sustained any damage by reason of the delay. See Whitmyer Bros., Inc. v. Dept. of Highways, 12 Ct.Cl. 9 (1977) and Vecellio & Grogan, Inc. v. Dept. of Highways, 12 Ct.Cl. 294 (1979).
The Court therefore makes an award to the contractor in the amount of
$7,800.00.
Award of $7,800.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 209
Opinion issued September 20, 1982
THELMA E. McINTYRE, ADMINISTRATRIX
OF THE ESTATE OF WILMA S. McINTYRE, DECEASED
vs.
DEPARTMENT OF HEALTH
(CC-76-70)
Frederick P. Grill, Attorney at Law, and J. T. Michael, Attorney at
Law, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
GARDEN, JUDGE:
Claimant Thelma E. McIntyre brought this claim as the administratrix of the
estate of Wilma S. McIntyre.
Claimant?s decedent, Wilma S. McIntyre, was admitted to Weston State Hospital
on July 10, 1974. She was taken to Weston State Hospital by Harrison County
deputy sheriffs in response to a request from the Veterans Hospital in
Clarksburg, West Virginia. The decedent exhibited symptoms of mental illness
which she had suffered in the past prior to previous commitments to
institutions for mental health treatment.
The first night at Weston, the decedent was placed in Ward 8, an area with
barred windows and locked doors. The next day, July 11, 1974, the claimant
spoke with the decedent?s psychiatrist at Weston, Dr. Castillo, advising him to
keep the decedent in a restricted area. Later that same day, the claimant, her
husband, and her niece (the daughter of the decedent) went to visit the
decedent. She had been transferred to a crisis intervention unit (CIU), where
there were no bars on the windows and no locks on the doors. The window in the
decedent?s room had a screen on it which latched with one hook and eye. The
decedent recognized the claimant, claimant?s husband, and her daughter. The
claimant was contacted at approximately 1:45 a.m. on July 12, 1974,
210 REPORTS
STATE COURT OF CLAIMS [W. VA.
by Dr. Castillo, who advised the
claimant that the decedent had fallen through the window in her room and was
being taken by ambulance to West Virginia University Hospital in Morgantown,
West Virginia.
The decedent was paralyzed from the neck down as a result of sustaining a
broken neck in the fall through the window at Weston and died from these
injuries on August 14, 1974.
Claimant alleged that the respondent was negligent in its failure to place the
decedent in an appropriate ward, considering her mental condition.
The evidence reveals that the decedent had suffered from mental illness for
many years, requiring commitment to mental health institutions at various times
for various periods. The claimant had, in fact, been a patient at Weston State
Hospital in 1943 for approximately 14 months. Her case history revealed the
mental problems from which she suffered. Before being taken to Weston on July
10, 1974, the decedent had been examined by Dr. Jaime E. Lazaro, who had stated
on the ?Certificate of Physician? form the following: ?Wanders off home.
Travels country. Very disorganized, delusional, irrational. Talks about the
dead and wants reunion with the dead. Incompetent, dangerous to self - psychotic.? According to a report compiled by Dennis
Bridgeman, Administrative Assistant II, and Peggy Aliman, Psychologist II,
employees of Weston, the decedent was interviewed by social worker Roger
Belknay on July 11, 1974. Mr. Belknay determined that she met the criteria for
admission to the Crisis Intervention Unit, and she was transferred to the CIU
at that time. Both teams of Unit II (Ward 8) and CIU approved of this transfer.
The report also contained the written statement of Kathleen Cottrill, Aide II
on CIU, who had been on duty the night of the decedent?s fall. Her statement
indicated that the decedent did not seem disturbed or upset; that she requested
that she not be given her H.S. Medication (a sleeping inducement medication);
and that she appeared to be sleeping well. She last checked the decedent at
11:15 p.m. The statement continues as follows:
W. VA.]
REPORTS STATE COURT OF CLAIMS 211
?I was getting ready to leave the ward
when I heard a noise, the aide (on midnight) and I rushed to Wilma, she was
lying on her back on the ground, I asked her what happened, and she said she
thought she was at a door, instead it was a window and she fell. In my honest
opinion, I do not think the woman jumped from the window. I believe she mistook
the window for a door, and was leaning out to see where she was, and lost her
balance.?
Whether the decedent fell from the window or jumped from the window is a matter
of speculation. The fact that the decedent was a patient in the care of the respondent
created a burden upon the respondent to take reasonable precautions to prevent
the decedent from doing harm to herself. Under the circumstances of the case,
that should have included placing the patient in wards with more adequate
safeguards. In the instant case, the decedent was placed in a ward without
adequate consideration being given to her past mental history. The respondent
failed to adequately protect the decedent when she was placed in a ward where
there were no bars on the windows.
The Court concludes that the respondent failed to fulfill its moral and legal
obligation to protect the claimant?s decedent; that the respondent?s acts
constituted negligence; and, that such negligence was the proximate cause of
the death of claimant?s decedent. House
v. Dept. of Mental Health., 10 Ct.Cl. 58 (1974).
The decendent?s estate was responsible for the hospital bill of $3,538.56
incurred while decedent was a patient at the West Virginia University Medical
Center; the funeral bill of $1,786.23; and the cost of a grave marker of
$302.51, for a total of $5,627.30.
The Court is of the opinion to and does hereby award to the claimant, Thelma E.
McIntyre as administratrix of the estate of Wilma S. McIntyre, decedent, the
sum of $10,000.00, with the additional sum of $5,627.30 for expenses incurred
by the estate, a total of $15,627.30.
Award of $15,627.30.
212 REPORTS
STATE COURT OF CLAIMS [W. VA,
Opinion issued September 20, 1982
ALVA KATHERINE WHITE
vs.
DEPARTMENT OF HIGHWAYS
(D-748a)
and
PAUL WHITE and WANDA WHITE
vs.
DEPARTMENT OF HIGHWAYS
(D-748b)
John Boettner, Jr., and Michael R. Crane, Attorneys at Law, for claimants.
Nancy J. Norman, Attorney at Law, for respondent. GARDEN, JUDGE:
These two claims were consolidated for hearing purposes and ultimate decision
because the same alleged acts of negligence on the part of the respondent
allegedly caused the damage to four homes located in proximity to each other in
the Cabin Creek Hill area of Kanawha County, West Virginia. Two of the homes
were owned by the claimant Alva Katherine White, and the other two were owned
by the claimants Paul White and Wanda White. The two homes owned by Alva
Katherine White were built on Lots 6 and 7 as
shown on J. D. Kittinger?s Map of Lots of Cabin Creek Junction, Kanawha County,
West Virginia, and the two homes of claimants Paul White and Wanda White were
built on Lot 21 of the same subdivision. To describe the terrain in the area of
these homes as hilly would certainly be an understatement. At the foot of the
hill is situated State Route 61, which runs generally in an east-west direction
between Cabin Creek Bridge and the towns of Coalburg and East Bank. To the
south of State Route 61 and also running in an east-west direction are railroad
tracks of the C & 0. Fronting on the C & 0 right of way are Lots 6 and
7 upon which Alva Katherine White?s homes are constructed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 213
Behind Lots 6 and 7 is State Route
61/9 above which is located Lot 21, There is a set of concrete steps situate on
the hillside of Lot 21 and a private road above the lot. During the years 1964
and 1965, the respondent installed three drainage pipes. One of the drainpipes
was located on the private road directly above the concrete steps and Lot 21.
Two drain- pipes were installed on State Route 61/9 above Lots 6 and 7. It is
the contention of the claimants that the installation of these drains resulted
in excess water being cast upon the properties of the claimants, causing
extensive damage thereto. The respondent contends that the water from both
roads is following its natural drainage path and would flow across the lots
belonging to the claimants regardless of the presence of the three drains.
The claimants testified that, prior to the installation of these drains and the
grading of the roads, they had not experienced the water problems which have
occurred since
1964-65.
H. Douglass Preble, a consulting geoiogist, testified on behalf of the
respondent. His investigation involved observations of the topography, drains,
running water, and subsurface water on the properties and the two roadways. He
testified that the water from both roads was following the natural drainage of
the hillside and would flow across claimants? lots in the same manner without
the presence of the drains installed by the respondent. However, on
cross-examination, the witness testified that the presence of the drainpipes
may have propelled and accelerated the flow of water.
It is well established law that land at lower levels is subject to the
servitude of receiving waters that flow naturally upon it from adjoining higher
land levels, and, unless a landowner collects surface water and precipitates it
with greatly increased or unnatural quantities upon his neighbor?s land, causing
damage, the law affords no redress. If no more water is collected on the
property than would naturally have flowed upon it in a diffused manner, the
dominant tenement cannot be held liable for damage to land subject to the
servitude of flowing waters. The evidence in these claims reveals that the
214 REPORTS
STATE COURT OF CLAIMS [W. VA.
installation of the three drains did,
in fact, result in excess water being cast upon the properties of the
claimants.
The common law rule that surface water is considered a common enemy, and that
each landowner may fight it off as best he can prevails in Virginia and West
Virginia, with the modification that an owner of higher ground may not inflict
injury on the owner of lower ground beyond what is necessary. Norfolk & W. R. Co. v. Carter, 91 Va. 587, 22 S.E. 517, Jordan v. Benwood, 42 W.Va. 312, 26 S.E. 266, and Lindamood
v. Board of Education, 92 W.Va. 387,
114 S.E. 800.
The Court concludes that the facts of the claims herein reveal that the actions
of the respondent in placing the drains caused the damages inflicted upon the
properties of the claimants.
The property appraisal report submitted to the Court indicates a difference in
before-and-after market value of $1,000.00 for the properties of the claimant
Alva Katherine White, and a difference in before-and-after market value of
$4,000.00 for the properties of Paul White and Wanda White. Accordingly, the
Court makes an award to the claimant Alva Katherine White in the amount of
$1,000.00, and an award to claimants Paul and Wanda White in the amount of
$4,000.00.
Award of $1,000.00 to Alva Katherine White.
Award of $4,000.00 to Paul and Wanda White.
Opinwn issued September 23, 1982
JIMMIE G. ADAMS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-139)
Claimant appeared in person.
Nanc?q J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
At approximately 7:00 am. on May 16, 1982, claimant was driving along Route
11/11 in Upshur County, West Virginia,
W. VA.1
REPORTS STATE COURT OF CLAIMS 215
a road owned and maintained by the
respondent, when his right front tire struck an object in the road and went
flat. Claimant got out to investigate and discovered a small cut in the side of
the tire. He then walked back to examine the road and recognized it as having
been recently graded. A photograph introduced into evidence shows a jagged
metal protrusion in the road, which the claimant described as a part of a
culvert yanked up during ditching operations.
Testifying on behalf of the respondent was Veril C. Powers, the Upshur County
Superintendent for the Department of Highways. Mr. Powers stated that, prior to
the date of the claimant?s accident, he had received no phone calls or
complaints that a culvert was damaged at that location on Route
11/11.
The law of West Virginia is well settled that the State is not a guarantor of
the safety of motorists upon its highways; its duty is one of reasonable care
and diligence in the maintenance of a highway under all circumstance. Parsons v. State Road Comm?n., 8 Ct.Cl. 35 (1969); Adkins v. Sims, 130 W.Va. 645,
46 S.E.2d81 (1947).
In the instant case, claimant?s testimony concerning the grading of Route 11/11
was unrefuted. While there was no evidence that the respondent had actual
notice of the fact that there was a defect in the road, the Court believes that
the respondent failed in its duty to use reasonable care in the maintenance
thereof. This failure was the proximate cause of the damages suffered by the
claimant.
Claimant?s Notice of Claim indicates the sum of $120.00 in damages. Submitted
into evidence was an invoice from Alker Tire & Supply of Buckhannon in the
amount of $402.91 for the purchase of four new tires, balancing, and the cost
of two valves. As the actual damage to claimant?s vehicle resulting from the
incident in question was to one tire only, the Court hereby awards the claimant
$89.54 for one new tire, $2.89 in excise tax, $3.00 for balancing, and $1.00
for the valve, for a total award of $96.43.
Award of $96.43.
216 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued September 23, 1982
LARRY L. BENNETT
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-434)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
At approximately 3:00 p.m. on Friday, November 13, 1981, claimant was operating
his 1980 Buick Skylark northerly on West Virginia Route 2 near Welisburg, West
Virginia, where employees of the respondent were patching the road with tar and
cinders. As claimant passed through the area, he heard something hit his
vehicle. After about five minutes, claimant stopped his car to inspect it and
discovered a crack in the windshield. Introduced into evidence was an invoice
in the amount of $192.42 for replacement of the windshield. No evidence was
produced by the respondent to refute the claim.
Accordingly, the Court finds the respondent negligent in its road repair
operations, which negligence proximately caused the damage to the claimants
vehicle, and hereby makes an award to the claimant in the amount of $192.42.
Award of $192.42.
Opinion issued September 23, 1982
JOHN R. COFFMAN
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-51)
No appearance by claimant.
Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damages to the muffler system of
claimant?s vehicle in the amount of $131.24
W. VA.]
REPORTS STATE COURT OF CLAIMS 217
were caused when the vehicle, while
crossing the Maple Lake Bridge in Bridgeport, West Virginia, struck a portion
of the deck which had settled; that said bridge is owned and maintained by the
respondent; that the accident occurred because of the negligence of the
respondent, and that this negligence was the proximate cause of the claimant?s
damages, the Court finds the respondent liable, and makes an award to the
claimant in the amount stipulated.
Award of $131.24.
Opinion issued September 23, 1982
DREAMA DAWN COOK
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-21)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
At approximately 11:30 am, on December 3, 1981, claimant
was operating her 1978 Dodge Colt automobile on Route 60
west of Belle in Kanawha County, West Virginia. Route 60
is a highway owned and maintained by the respondent.
According to the claimant?s testimony, she was travelling at a speed of 50 mph
when the right front tire struck a pothole measuring 2? feet by 1? feet,
resulting in damage to the vehicle in the amount of $133.45.
It is well-established law in West Virginia that the State cannot and does not
guarantee the safety of motorists upon its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). To be found liable, the respondent
must have had either actual or constructive notice of the particular hazard
which caused the damage. Davis v.
Dept. of Highways, 11 Ct.Cl. 150
(1976). No evidence of notice was presented in this case; therefore, no negligence
on the part of the respondent can be established. Accordingly, the claim must
be denied.
Claim disallowed.
218 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued September 23, 1982
EXXON CO., U.S.A.
vs.
FARM MANAGEMENT COMMISSION
(CC-82-136)
and
SCOTT SAW SALES & SERVICE
vs.
FARM MANAGEMENT COMMISSION
(CC-82-165)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims against the Farm Management Commission were submitted for decision
upon the pleadings. The claimants seek payment for various goods and services
furnished to the respondent as follows:
Exxon Co., U.S.A. $219.71
Scott Saw Sales & Service $ 42.44
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
While we feel that these claims should, in equity and good conscience, be paid,
we further believe that awards cannot be made, based on our decision in Airkem
Sales and Service, et at. v. Department of Mental Health, 8 Ct.Cl.
180 (1971).
Claims disallowed.
W. VA.J REPORTS STATE COURT OF CLAIMS 219
Opinion issued September 23, 1982
DAE ANNE FLETCHER and
PAUL NORMAN FLETCHER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-52)
Claimants appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
At 9:30 a.m. on Sunday, February 14, 1982, claimants were operating their 1980 Plymouth
Horizon in a southerly direction on Route 19 in Harrison County, West Virginia.
Route 19 is owned and maintained by the respondent.
Claimant Dae Anne Fletcher testified that she and her husband and son were on
their way to church that morning and the roads were clear. However, upon
turning left onto Clarksburg Country Club Road, they encountered ice. Mrs.
Fletcher stated that Clarksburg Country Club Road had a little rise to it, and
after coming up over the rise, they saw an automobile stopped in front of them.
Mr. Fletcher turned to the left to go around the car and glanced the rear
bumper of that vehicle. The Fletcher vehicle then skidded into a tree, went
back into the road, made a complete circle, and hit a tree on the other side.
Claimants suffered personal injuries and were treated and released by a
Clarksburg hospital. Damage to claimants? automobile was paid by their insurer,
Erie Insurance, with the exception of a $100.00 deductible.
The law of West Virginia is well established that the State cannot and does not
guarantee the safety of motorists travelling upon its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). To be held liable, the respondent
must have had either actual or constructive notice of the hazardous condition
of the highway. Since no such evidence of notice was brought forth in this
case, the respondent cannot be found negligent. Therefore, the Court hereby
disallows the claim.
Claim disallowed.
220 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued September 23, 1982
FORREST C. HATFIELD
vs.
DEPARTMENT OF HIGHWAYS
(CC?78-227)
Michael I. Spiker, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant seeks to recover $25,000.00 from the respondent
for personal injuries and damages to his 1977 Ford F-100 pickup
truck sustained in a single-vehicle accident on November 29,
1977.
At the time of the accident, the claimant resided in Staats Mill, West
Virginia, in Jackson County. To go to and from his residence he travelled West
Virginia Route 34/5 also known as Southall Ridge Road which is a secondary
blacktop road maintained by the respondent. The claimant had moved to Staats
Mill sometime in 1976. In his testimony he stated that there was a small slip in
the road near his house at the time and at the time of the accident two
automobiles could pass ?if one gets off on the berm?.
The claimant travelled the road daily. On the day of the accident he drove his
wife to work at the K-Mart in Charleston and then returned home. He returned to
Charleston in the evening to pick her up, returning home about 6 p.m. It had
rained the day before and on the day of the accident. Between 6:45 and 7:45
p.m. he left his house to drive to a neighbor?s home. It was dark, rainy, and
foggy. He stated, ?you couldn?t see ten feet ahead of you.? The claimant
testified, ?.
. .1 just started out from the house maybe
a couple or three hundred yards and the road had dropped more when I hit that
chuck hole or slip or whatever you call it.? ?. . .that one particular piece of road there had dropped in after we had
come back from Charleston.? The claimant further stated that his vehicle?s
right wheel went over the hill; that he lost control and jumped out of his
truck, the door struck him and knocked him under the back wheel crushing his
left foot. He crawled up to the road surface where he was picked up by a
neighbor and subsequently taken to the hospital.
W. VA.1 REPORTS
STATE COURT OF CLAIMS 221
The parties stipulated that the truck sustained damage of $77.20; that medical
expenses for doctors and hospital were
$4,396.95; and that the claimant had a 30% permanent partial disability
resulting from his injuries.
The claimant and John Cobb, a witness in his behalf, both testified that they
had complained to respondent?s Ripley and Charleston offices prior to the
accident and that there were no signs posted to warn of the slip condition, a
fact which is immaterial as far as this claimant is concerned because he knew
of the road condition. However, the respondent could not have been aware of the
slip which the claimant testified occurred from the time he returned from
Charleston and the time of the accident.
Although the record establishes that the respondent had notice of the condition
of the road prior to the day of the accident, it also establishes that the
claimant was very familiar with it and its condition. Under the doctrine of
comparative negligence, the negligence of the claimant in traveling a road, at
night in rain and fog, known to him to be in disrepair was equal to or greater
than the negligence of the respondent in its failure to repair the road. Bradley v. Appalachian Power Co., 256 S.E.2d 879 (1979). A traveller on the highway
travels at his own risk. The State is not a guarantor of his safety. Adhins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947); Parsons v. State Road Commission, 8 Ct.Cl. 35 (1969). The claim of the claimant is disallowed.
Claim disallowed.
Opinion issued September 23, 1982
CHESTER JONES
vs.
DEPARTMENT OF HIGHWAYS
(CC?76-51)
E. Joseph Buffa, Jr., Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent. GARDEN, JUDGE:
Chester Jones, also known as Chester Mynes, filed this
222 REPORTS
STATE COURT OF CLAIMS [W. VA.
claim to recover damages alleged to
have occurred when the respondent allegedly breached a contract with the
claimant for quarrying stone on claimant?s property.
Claimant is the owner of a 10-acre tract of land located on Green Creek Road in
Roane County, West Virginia. On April 3, 1971, the claimant and the respondent
entered into a written lease agreement, the purpose of which was to permit the
respondent to proceed onto claimant?s property ?to purchase and acquire certain
rock and stone for the purpose of using same upon said highways;? (Claimant?s
Exhibit No. 10). The agreement further provides for payment of the stone
quarried as follows:
?The agreed price to be paid by party of the second part to party of the first
part shall be $0.05 per ton for all stone removed and certified. It is mutually
agreed that volume shall be determined by truck load records. The back wall of
the quarry shall be left as a perpendicular wall and the quarry site left in a
tidy condition. This agreement shall be for a period of four (4) years from
drte.?
During the term of the contract, the claimant received one payment from the
respondent for the stone quarried. This payment, which was in the amount of
$1,989.40, was transmitted to the claimant by a letter stating that payment was
in full. Claimant, at that time, questioned the amount of the payment, but
accepted it with the understanding that further payments would be forthcoming.
The claimant then received nothing further.
To perform the stone quarrying operation, it was necessary for the respondent
to clear a portion of claimant?s property of trees and move dirt to obtain the
rock. Then, blasting was undertaken to obtain the rock for the stone crushing
operation. Respondent also constructed a haul road on the property for removal
of the stone from the quarry. This road was actuully part of an old road
already existing on the property and partially new road. The quarrying
operation on claimant?s property ceased at some point in 1973. The lease
agreement expired on April 3, 1975.
W.VA.l REPORTS
STATE COURT OF CLAIMS 223
The claimant subsequently filed this
claim in May 1976 alleging a breach of the lease agreement. Claimant contends
that he was not paid for all of the stone quarried on his property; that his
house sustained damages as the result of the blasting activities; that rocks
were left strewn over the property; that a garage was destroyed; that fruit
trees were destroyed; and that the road ramp which cuts across the meadow has
not been removed. Claimant alleges that his property has not been left in a
?tidy condition? in accordance with the provisions of the lease agreement.
Respondent, however, contends that claimant had been paid in full for the stone
quarried. According to records of the respondent, 39,788 tons of stone were quarried
and the claimant was paid at a rate of $.05 per ton, the rate agreed to in the
lease agreement. Respondent also contends that the claimant has released the
State from any and all claims for damages and compensation to the residue.
Previously, the Court made an award to the claimant in the amount of $3,760.60
for stone quarried by the respondent in accordance with the terms of the lease
agreement. The award was paid by an appropriation by the 1980 Legislature.
Subsequent to the award, the claimant filed a petition for rehearing and
thereafter the claimant and the respondent filed briefs on the question of
damages to the real property and buildings of the claimant. The Court, having
considered these briefs, reviewed the law of West Virginia with respect to
damages to real property.
The general rule has been that damages to real property were classified as
temporary or permanent. The measure of damages then depended upon the
classification. A temporary injury to property occurred when the cause of the injury
and its effects could be remedied, removed or abated. The measure of damages
was the cost of remedy, removal or abatement. Injury to real property was
permanent when the injury affected the property?s value permanently. The
measure of damages was then the difference in the market value of the property
immediately before and immediately after the injury. The West Virginia Supreme
Court reviewed these two methods
224 REPORTS
STATE COURT OF CLAIMS [W. VA.
of measuring damages to real property
in the case of Jarrett v. Harper &
Son, Inc., W.Va. , 235 S.E.2d 362 (1977), and determined that:
?. . .a more manageable and meaningful meshing of the
measures is possible simply by eliminating the temporary and permanent
classifications. The result would be similar to the rule about damage to
personal property. When realty is injured the owner may recover the cost of
repairing it plus his expenses stemming from the injury including loss of use
during the repair period. If the injury cannot be repaired or the cost of
repair would exceed the property?s market value, then the owner may recover the
money equivalent of its lost value plus his expenses resulting from the injury
including loss of use during the time he has been deprived of his property.?
The Court further stated that:
?. . .cases that differentiate between measures of damages
for injury to real property on the ?temporary? or ?permanent? bases are
overruled on that point.?
In this claim, the claimant?s property sustained damages to the residence and
other outbuildings and damages to the terrain. During the hearing of this
claim, testimony from the claimant and exhibits introduced with respect to
damages, indicated the following: the cost of cleaning up the real
property?$14,480.00; repairs to the residence?$623.00: clean-up of the quarry
site?$14,700.00; rebuilding of the garage?$1,200.00; and replacement of fruit
trees?$1,335.00, for a total amount of damages of $32,338.00.
Also submitted for the Court?s consideration were appraisals. The appraisal
report submitted by the claimant demonstrated a difference in before and after
market values of $24,000.00, while the difference in before and after market
values in the appraisal report submitted by the respondent was $1,700.00.
The Court has carefully considered all of the damage evidence submitted in this
claim and hereby makes an award of $12,760.60, less the award of $3,760.60
heretofore received.
Award of $9,000.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 225
Opinion issued September 23, 1982
RAYMOND L. MAYNARD
vs.
BOARD OF REGENTS
(CC-81-206)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant Raymond L. Maynard is seeking damages in the amount of $15,000.00
resulting from a loss of his veteran?s benefits allegedly due to counseling
errors at Southern West Virginia Community College.
The claimant obtained a two-year associate degree in Mining Technology from
Southern West Virginia Community College in May of 1980. In August of 1980, he
enrolled for the College?s fall semester in Drafting and Design. His
difficulties with the Veteran?s Administration arose in regard to two courses,
Mining 122 and Data Processing 101, which he had taken for his mining degree.
It was the position of the Veteran?s Administration that those elective courses
should have been transferred as credit toward his drafting degree. The VA
decided to stop payment of all benefits to the claimant until the VA was
reimbursed $1,061.74 it considered overpayment for the two courses in question.
This resulted in a loss of $370.00 per month for April and May 1981. The claimant
testified, ?Once the VA is reimbursed the $1,061.74, I?m assuming the VA will
forward my two checks for the last two months of the semester.? A letter to the
claimant dated April 28, 1981, from the Veteran?s Administration?s Huntington
office, states, ?We will withhold any future benefits due you until the debt
($1,061.74) is recovered.? (Parenthetical figure supplied.)
The evidence further reveals that claimant?s advisor at Southern West Virginia
Community College treated him as a ?new student? in his advisement because the
?transfer of credit evaluation form? had not been completed.
226 REPORTS
STATE COURT OF CLAIMS [W. VA.
The claimant relied upon his advisor
in selecting the course work necessary for the drafting degree, and this advice
resulted in the loss of benefits. The school received the benefit of the
overpayment to the detriment of the claimant. The Court makes an award to the
claimant in the amount of
$1,061.74.
Award of $1,061.74.
Opinion issued September 23, 1982
THE MELBOURNE BROTHERS
CONSTRUCTION COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC-77-150)
Michael T. Chaney, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. GARDEN, JUDGE:
The Melbourne Brothers Construction Company, hereinafter referred to as the
contractor, entered into a contract with the respondent for project BRF-0312
(019) which included the removal of an existing bridge and construction of the
Third Avenue Bridge in Huntington, West Virginia. The first part of this claim
involves a dispute in the painting of the steel on the Third Avenue Bridge, and
the second part of the claim involves a dispute as to which party to the
contract is responsible for the bond required to be posted by the U.S. Coast
Guard to insure the safe and adequate removal of an existing structure.
The contractor contends that it was required to place a wash coat not called
for in the contract which resulted in an additional expense to the contractor
of $5,296.00. The specifications provide for a wash coat if a zinc rich system
of paint is used and if the wash coat is, in fact, recommended by the
manufacturer. The contractor herein was to apply an inorgaric zinc shop primer
with a vinyl top coat. The wash coat is placed upon the primer if the primer is
incompatible with the vinyl top coat used by the contractor. Section 711.20.3
of the Stan-
228 REPORTS
STATE COURT OF CLAIMS [W. VA.
tion filed by the parties, claimants
seek payment of the sum of $144.00 for damages to their 1980 Eagle station
wagon resulting when the vehicle passed through tar which had been applied to
the highway by the respondent?s employees. This occurred on Fish Creek Road in
Marshall County, West Virginia, a highway owned and maintained by the
respondent. At that time and place, no warning signs had been posted, and the
respondent?s negligence in failing to warn motorists of the substance on the
highway was the proximate cause of the damages suffered by the claimants.
Accordingly, the Court makes an award to the claimants in the amount stipulated.
Award of $144.00.
Opinion issued September 23, 1982
RAINBOW DEVELOPMENT CORPORATION
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-350)
Ernest Pennington appeared for the claimant.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
Claimant herein seeks reimbursement in the amount of $26,000.00 for certain
work done on Russet Drive, a West Virginia secondary highway located in Cross
Lanes, Union District, Kanawha County.
The claimant, Rainbow Development Corporation, was engaged in land development,
the creation of subdivisions, and housing construction. The Kanawha County
Planning and Zoning Commission required it to widen and improve a section of
Russet Drive before the commission would grant it permission
to sell lots in the area.
Claimant thereupon drafted a set of plans and specifications and submitted them
to the respondent Department of High-
W. VA.]
REPORTS STATE COURT OF CLAIMS 227
dard Specifications of Roads and
Bridges requires a wash coat if
recommended by the manufacturer, and the contractor must necessarily apply the
wash coat. The cost of the wash coat is the responsibility of the contractor.
The provisions of the contract dictate that the cost of the bond required by
the U.S. Coast Guard in the amount of $500.00 is the responsibility of the
contractor. Therefore, the contractor must bear this expense.
The Court hereby disallows the claim in its entirety.
Claim disallowed.
Opinion issued September 23, 1982
MONONGAHELA POWER COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-116)
David L. Williams, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
Upon written stipulation to the effect that damages to claimant?s secondary
power line in the amount of $38.38 were caused when employees of the respondent
negligently tore down the line, located in the vicinity of Route 19 near Gore,
Harrison County, West Vir?inia, the Court finds the respondent liable, and
hereby makes an award of $38.38 to the claimant.
Award of $38.38.
Opinion issued September 23, 1982
SIDNEY POZELL and LILLIAN POZELL
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-163)
No appearance by claimants.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
In this claim, submitted for decision upon a written stipula
W. VA.]
REPORTS STATE COURT OF CLAIMS 229
ways. The Department of Highways
informed Rainbow that it would not be necessary for the corporation to bear the
expense of upgrading Russet Drive, and that if Rainbow proceeded with the
subdivision of the lots and got several families to live there, the Department
of Highways would improve the road. Rainbow then took this information back to
the Kanawha County Planning and Zoning Commission, which found the proposal
unacceptable. The Commission ruled that the work would have to be completed
before any families could be moved into the subdivision. Ernest Pernington,
claimants? president, testified, the Rainbow Development Corporation ?went back
to the Department of Highways and agreed in writing (via a permit) to widen and
improve the road at our expense.? There was a cost estimate of approximately $8,400.00
for the work.
The set of specifications for the project had originally called for asphalt
pavement, but approximately one month after the Department of Highways issued
the work permit, district Engineer L. S. Smith issued to Rainbow a verbal
directive to change the pavement from asphalt to concrete. Testimony at the
hearing indicated that there was never a written
agreement concerning reimbursement:
?Q. Did you ever enter into any kind of contract with the
Department of Highways, other than the permit which has been admitted into
evidence. .
.
A. No, there was never a contract on this
job, no.
Q. Now, that permit does not make any mention of payment
to you by the Department of Highways; isn?t that correct?
A. It does not.
Q. Did you ever receive anything in writing, any
agreement, from the Department of Highways that they would pay for any portion
of this, in writing?
A. The only thing we?ve ever received was a verbal commitment from the district
engineer, Mr. Smith.?
From the evidence, it is clear to this Court that no contract
230 REPORTS
STATE COURT OF CLAIMS [W. VA.
was ever entered into by the parties.
It follows that there can be no breach of contract on the part of the
respondent, and no basis for liability. Hence, the claim is hereby disallowed.
Claim disallowed.
Opinion issued September 23, 1982
DORIS RANDOLPH, FRANK RANDOLPH,
her husband, and YVONETTE
(SUZIE) RANDOLPH, infant
vs.
DEPARTMENT OF HIGHWAYS
(CC-76- 12)
Samuel D. Lopinsky, Attorney at Law, for claimants. Gregory W. Evers, Attorney
at Law, for respondent.
GARDEN, JUDGE:
The accident, which is the subject of this claim, occurred at approximately
8:30 p.m. on June 22, 1975, on W.Va. Route 35 near Pliny, West Virginia. The
claimants Doris Randolph and Yvonette Randolph were proceeding in a southerly
direction on this road en route from Pomeroy, Ohio, to their home in Cross
Lanes, West Virginia. W.Va. Route 35 at the accident scene is a two-lane
roadway, one lane for northbound travel and one lane for southbound travel. The
claimant Doris Randolph was operating a 1974 Chevrolet Corvette owned by her
husband, Frank Randolph. According to claimant Doris Randolph, she was
attempting to pass a vehicle in front of her by entering the northbound lane.
As she began to pass the vehicle, her vehicle struck a depressed area of the
roadway causing her to lose control of her vehicle, whereupon the vehicle
turned sideways and slid into a tree adjacent to the berm of the southbound
lane. Upon impact with the tree, the vehicle exploded.
As a result of the accident, the claimant Doris Randolph sustained fractured
ribs, a fractured right ankle, a broken left wrist, and internal injuries which
required surgery. In addition to personal injuries, the claimant also sustained
a loss of wages of approximately 13 months. Claimant Yvonette Ran-
W. VA.]
REPORTS STATE COURT OF CLAIMS 231
doiph sustained a fractured clavicle.
The vehicle was rendered a total loss.
The testimony established that there was a depressed area in the northbound
lane of Route 35. There were supposed to be signs posted which read ?Dip
Ahead?, but the record was unclear as to whether these signs were in place on
the date of this accident. Two of the eyewitnesses to this accident testified
that the vehicle being driven by the claimant appeared to be proceeding at a
high rate of speed when it was in the northbound lane.
The claimant had, earlier that same day, driven over this same stretch of Route
35. She testified that she had had no difficulty proceeding over Route 35 and,
in fact, did not remember having any difficulty in negotiating this part of the
highway earlier in the day.
This Court consistently has held that the State is not a guarantor of the
safety of travelers on its highways and that its duty to travelers is one of
reasonable care and diligence in the maintenance of a highway under all the
circumstances. Parsons v. Dept. of
Highways, 8 Ct.C1. 35 (1969). The
oft-cited case of Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81, holds that the user of the
highways travels at his own risk and that the State does not and cannot assure
him a safe journey.
While we are most sympathetic to the claimants who suffered painful injuries,
we do not feel that the record in this claim is sufficient to make this claim
an exception to the general rule as hereinabove set forth, and we, therefore,
disallow this claim.
Claim disallowed.
Opinion issued September 23, 1982
FRANK E. REDD
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-169)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
In this claim, submitted for decision upon a written stipula
232 REPORTS
STATE COURT OF CLAIMS [W. VA.
tion filed by the parties, claimant
seeks payment of the sum of $51.00 for damages to
his Chevrolet Blazer resulting when the vehicle passed through tar which had
been applied to the highway by the respondent?s employees. This occurred on
Fish Creek Road in Marshall County, West Virginia, a highway owned and
maintained by the respondent. At that time and place, no warning signs had been
posted, and the respondent?s negligence in failing to warn motorists of the substance
on the highway was the proximate cause of the claimant?s damages.
Accordingly, the Court makes an award to the claimant in the amount stipulated.
Award of $51.00.
Opinion issued September 23, 1982
STANLEY T. RUCKMAN
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-166)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
In this claim, submitted for decision upon a written stipulation filed by the
parties, claimant seeks payment of the sum of $78.75 for damages to his 1977
Chrysler Cordoba resulting when the vehicle passed through tar which had been
applied to the highway by the respondent?s employees. This occurred on Fish
Creek Road in Marshall County, West Virginia, a highway owned and maintained by
the respondent. At that time and place, no warning signs had been posted, and
the respondent?s negligence in failing to warn motorists of the substance on
the highway was the proximate cause of the claimant?s damages.
Accordingly, the Court makes an award to the claimant in the amount stipulated.
Award of $78.75.
W. VA.j
REPORTS STATE COURT OF CLAIMS 233
Opinion issued September 23, 1982
SHANE MEAT COMPANY
vs.
BOARD OF REGENTS
(CC-82-86)
H. Ronald Shane appeared in behalf of claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant Shane Meat Company entered into a contract with West Virginia University, a school under the supervision of the Board
of Regents. The terms of the contract provided that the claimant was to supply
unbreaded veal in chopped form with TVP added. The contract also provided that
the price was based upon price ?per piece.? It is that provision in the
contract which resulted in this claim.
It is the claimant?s contention that it should be paid in accordance with the
terms of the contract for each piece of unbreaded veal steak ordered by and
shipped to the University. The respondent, on the other hand, contends that
during the bidding process, a mechanical error occurred which resulted in the
?per piece? language rather than ?per pound? in the bid. The error was
discovered after the contract had been entered into by the parties. The
University paid the claimant for the veal ordered and shipped to the Uni?ersity
based upon a per pound rate rater than the ?per piece? price quoted in the
contract. The difference in the calculation based upon per pourd rather than
per piece is $1,450.44, which is the amount claimed herein. The
claimant delivered more pieces of the veal than that ordered by West Virginia
University.
The claimant entered into the contract based upon the language in the contract
which stated clearly that the unbreaded veal was to be priced ?per piece.? The
claimant based its invoice to the University upon the terms of the contract.
Where a contract is free from ambiguity or doubt, it is the duty of the court
to construe the contract according to its terms, and
234 REPORTS
STATE COURT OF CLAIMS [W. VA.
to give full force and effect to the
language used. 4B M.J., Contracts, ?40.
The Court, In accordance with the testimony adduced at the hearing, grants an
award to the claimant for the difference in the ?per pound? amount paid to the
claimant and the ?per piece? rate in the contract for the unbreaded veal steaks
originally ordered by West Virginia University, which award is in the sum of
$1,412.52.
Award of $1,412.52.
Opinion issued September 23, 1982
JAMES D. TERRY
vs.
OFFICE OF THE STATE AUDITOR
(CC-82-44)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant is an attorney who served as counsel for criminal indigents in
juvenile, misdemeanor, or felony proceedings pursuant to the provisions of West
Virginia Code Chapter 51, Article 11. This statute provides for the payment of
attorney fees out of the ?needy persons fund? by the State Auditor. Claimant?s
fee of $345.00 was denied by the respondent as the fund was exhausted.
The factual situation in this claim is identical to that in Richard K. Swartling, et al. v. Office of the State
Auditor, issued on November 5, 1979.
Accordingly, an award is hereby made to the claimant in the amount indicated
below.
Award of $345.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 235
Opinion issued September 23, 1982
WILLIAM M. TRUMAN
vs.
OFFICE OF EMERGENCY SERVICES
(CC-81-376)
Robert B. Stone, Attorney at Law, for claimant.
Henry C.
Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
During the month of September 1979, claimant William M. Truman applied for the
position of lead engineer of an emergency communications system which was, at
that time, being organized by the Office of Emergency Services, an agency of
the State of West Virginia. During the preliminary steps of the hiring process,
the claimant alleges that he was led to believe that he would be employed by
the respondent State agency. In reliance thereon, he resigned from the
employment he had at the time and entered into a purchase contract for a house
near Charleston, West Virginia. As a result of these actions, Mr. Truman sustained
losses in the amount of $5,620.00, for which he filed this claim.
On September 3, 1979, claimant was contacted via telephone by John Anderson,
the Director of the Office of Emergency Services, concerning the position of
engineer of the emergency communications system and was interviewed by Mr.
Anderson on September 8. It was necessary for the claimant to receive a rating
from Civil Service to determine the salary to be offered to him; and the
position had to be approved by the Commissioner of the Department of Finance
and Administration.
On September 26, 1979, the salary level which was approved through Civil
Service was communicated to the claimant, whereupon the claimant and Mr.
Anderson discussed the starting date for claimant?s employment, and designated
it to be November 1, 1979. The claimant then notified his employer of his
intention to assume a new position. He also visited
236 REPORTS
STATE COURT OF CLAIMS [W. VA.
Charleston, West Virginia, to locate a
house, and did, in fact, enter into a purchase contract, and approached a
lending institution for financing.
Thereafter, Mr. Anderson informed the claimant that approval of the claimant
for the position of communications engineer was not forthcoming from the
Commissioner of the Department of Finance and Administration. Subsequently, the
claimant sought and accepted a position elsewhere.
Mr. Anderson testified that from October 11, 1979, until the end of November
1979, the approval for the hiring of the claimant was in question as the Commissioner
of the Department of Finance and Administration would not approve the salary
level agreed upon by the claimant and Mr. Anderson. This approval was necessary
before the claimant could be employed by the Office of Emergency Services.
From the facts referenced above, the Court is constrained to conclude that the
claimant prematurely assumed that he would be employed by the Office of
Emergency Services. The record establishes that an agreement by the parties
concerning claimant?s employment was not effected. Any losses sustained by the
claimant in anticipation of employment by the respondent must be borne by the
claimant himself. Therefore, the Court must disallow this claim.
Claim disallowed.
Opinion issued September 23, 1982
DAVID E. UTT
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-H5)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
On the evening of April 4, 1982, claimant was operating his 1982 Oldsmobile
Toronado easterly on State Route 22 (also
W. VA.] REPORTS
STATE COURT OF CLAIMS 237
known as Cove Road) in Weirton, West
Virginia, a road owned and maintained by the respondent. As the claimant was
turning onto Harmon Creek Road, a two-lane secondary road, the right front
wheel of his automobile struck a pothole, damaging the hubcap and rim in the
amount of $142.00.
According to the claimant?s testimony, he had been travelling at a speed of 25
mph and was familiar with the road in question. On prior occasions, he had
observed the pothole, but made no complaints to the Department of Highways.
It is well established law in West Virginia that the State cannot and does not
guarantee the safety of motorists upon its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). To be held liable, the respondent
must have had either actual or constructive notice of the hazardous condition
of the highway. No such evidence of notice was presented in this case;
therefore, the respondent cannot be held negligent, and the Court must disallow
the claim.
Claim disallowed.
Opinion issued October 12, 1982
DAVID LEE CLOSSON
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC?82?176)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney Genera], for respondent. PER CURIAM:
A civil judgment against the claimant in Marion County Magistrate Court
resulted in the revocation of his driver?s license. The judgment was later set
aside, but, due to a clerical error, no notification was given to the
Department of Motor Vehicles. Claimant expended $30.00 in tcwing fees and
$20.00 in long distance phone calls to get his license reinstated, for a total
claim of $50.00.
238 REPORTS
STATE COURT OF CLAIMS [W. VA.
The respondent?s Answer admits the
amount and validity of the claim, and states that sufficient funds remained in
its appropriation for the fiscal year in question from which the claim could
have been paid. The Court therefore makes an award to the claimant in the
amount requested.
Award of $50.00.
Opinion issued October 12, 1982
RICHARD D. GRAHAM, JR.
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-82-190)
HOWARD R. NORDECK
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-82-209)
No appearance on behalf of the
claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Each of the claimants hereinabove is a magistrate who has petitioned the Court
for the payment of wages not paid in accordance with the results of the 1980
decennial census. In the case of Ruth
A. Donaldson, Magistrate, etc., et al. v. Gainer, Jr., Auditor et al. (June 30, 1982), the West Virginia Supreme Court of
Appeals held that the 1980 decennial census became effective July 1, 1981.
There were insufficient funds available to pay magistrates whose salaries were
based upon the 1980 decennial census for the 1981-82 fiscal year.
The Supreme Court Administrator?s Office has reviewed these claims and has
admitted that the amounts claimed are valid and correct.
This Court has previously determined that payment for back wages arises at the
time the wages are found to be due. Petts
and Preston v. Div. of Voc. Rehab., 12
Ct.Cl. 222 (1978).
W. VA.J
REPORTS STATE COURT OF CLAIMS 239
Therefore, the Court makes awards for
the wages which were not paid to the claimants during the 1981-82 fiscal year.
Award of $4,500.00 to Richard D. Graham, Jr.
Award of $4,500.00 to Howard R. Nordeck.
Opinion issued October 12, 1982
GREEN TAB PUBLISHING
vs.
DEPARTMENT OF CORRECTIONS
(CC-82- 194)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant herein seeks payment of the sum of $3,856.47 for typesetting the West
Virginia Tax Book for the respondent.
Respondent?s Answer admits the allegations of the Notice of Claim, and states
that payment was not made because statutory purchasing procedures were not
followed.
From the evidence, the Court believes that a misunderstanding regarding
purchasing procedures existed between the parties; that, nevertheless, the work
was performed satisfactorily; and that sufficient funds remained in the
respondent?s account for the proper fiscal year from which the obligation could
have been paid.
Accordingly, an award is hereby made to the claimant in the amount requested.
Award of $3,856.47.
Opinion issued October 12, 1982
ROBERT A. ISNER
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-82-229)
No appearance on behalf of the
claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant hereinabove is a magistrate who has petitioned
240 REPORTS
STATE COURT OF CLAIMS [W. VA.
the Court for the payment of wages not
paid in accordance with the results of the 1980 decennial census. In the case
of Ruth A. Donaldson, Magistrate,
etc., et al. v. Gainer, Jr., Auditor et al. (June 30, 1982), the West Virginia Supreme Court of Appeals held that
the 1980 decennial census became effective July 1, 1981. There were
insufficient funds available to pay magistrates whose salaries were based upon
the 1980 decennial census for the 1981-82 fiscal year.
The Supreme Court Administrator?s Office has reviewed this claim and has
admitted that the amount of $4,500.00 is the correct amount to be paid to the
claimant.
The claimant has added interest to the amount claimed which this Court must
deny in accordance with West Virginia Code Chapter 14, Article 2, Section 12.
This Court has previously determined that payment for back wages arises at the
time the wages are found to be due. Petts
and Preston v. Div. of Vov. Rehab., 12
Ct.Cl. 222 (1978). Therefore, the Court makes an award to the claimant for the
wages which were not paid to the claimant during the 1981-82 fiscal year.
Award of $4,500.00.
Opinion issued October 12, 1982
McANALLEN BROTHERS, INC.
vs.
BOARD OF REGENTS
(D-1031)
Edgar F. Heiskell, III, Attorney at Law, and Robert L. Shuman, Attorney at
Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
McAnallen Brothers, Inc., had a contract with the respondent, Board of Regents,
for construction of a natatorium at West Virginia University. A part of that
contract provided for the construction of a sanitary sewer. This claim is for
the cost incurred by the contractor for extra work performed in
W.VA.J REPORTS STATE COURT OF CLAIMS 241
the construction of this sanitary line
as the direct result of rock encountered on the project site. The contractor
contends that the test borings provided prior to bidding on the job provided no
indication of the type of rock on the project site as was encountered in the
area of the sanitary sewer. The respondent, on the other hand, contends that
the contractor should have performed its own test borings on the project to
determine the sub-surface conditions and, therefore, the respondent is not
responsible for the costs incurred by the contractor.
The record in this claim establishes that the contractor began construction on
the sanitary line and within a week?s time encountered sub-surface hard rock
similar to granite. The contractor attempted to use mechanical means to break
the rock but soon resorted to the use of dynamite with the permission of the
respondent?s field inspector. This method proved to be too time consuming to
the contractor so the architect was requested to assist the contractor by redesigning
the sanitary line. The architect complied with the contractor?s request by
redesigning the line so as to raise the elevation and alter the direction and
ultimate length of the line. The contractor then constructed the sanitary line
according to the redesign.
The architect for the respondent, William Hartlep, testified that the rock
encountered by this contractor ?is blue limestone which is nearly as hard as
granite and very, very rare.? He further testified that the borings did not
disclose this subsurface condition ?because it?s a very isolated small area and
I can?t explain it because it?s a freak occurrence of stone in that area. It?s
one in a hundred shot that it would be there.?
The record in this claim establishes that an unanticipated sub-surface
condition existed on the project and this condition caused the contractor to
incur extra expense in the amount of $20,228.00 for which the contractor is
entitled to be compensated. C. J. Lan
genf elder & Sons, Inc. v. State Road
Commission, 8 Ct.Cl. 193 (1971). The Court, therefore, makes an
award to the claimant in the amount of $20,228.00.
Award of $20,228.00.
242 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued October 12, 1982
PAUL J. and BETTY 0. UNDERWOOD
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-86)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. GARDEN, JUDGE:
Claimants are the owners of property located on State Route 12 at Ada in Mercer
County, West Virginia, which they purchased in 1974.
Across State Route 12, on the north side, is situated a drainpipe whose ends
became clogged with dirt during the summer of 1978. As a result, claimants?
property suffered damage from water which flowed across the highway during
heavy rains. On September 10, 1978, hard rain washed into the drainage ditch on
State Route 12, across the roadway, and onto the Underwood property. Claimants?
basement became flooded, cracking the basement wall and bowing the cinder block
foundation. The total amount of damages as indicated by the evidence was
$3,777.09.
Testifying on behalf of the respondent was Mr. Elwood Simons, Mercer County
Superintendent of the Department of Highways. According to Mr. Simons, the
ditch line along Route 12 was cleaned some time during the summer of 1978, but
he could not recall the exact date.
A registered professional engineer, Mr. Bruce Leedy, also offered testimony on
behalf of the respondent. Mr. Leedy stated that the cracks in the basement wall
of claimants? structure were due to foundation failure caused when the weight
imposed on the foundation on the footer became too much for the bearing
capacity of the soil beneath. However, he further stated that the damage may
have occurred as the result of excess water or a saturated condition in the
soil, which would have aggravated the footer condition to the point where
cracking occurred.
W. VA.]
REPORTS STATE COURT OF CLAIMS 243
From the evidence, the Court finds
that the drain was located in the ditch along the State highway and it was the
responsibility of the respondent to maintain. Respondent?s failure to maintain
the drain caused water to flow across the road and onto claimants? property,
damaging it extensively. See Stevens
v. Dept. of Highways, 12 Ct.Cl. 180
(1978), and Taylor v. Dept. of Highways, 12 Ct.Cl. 261 (1979). Therefore, the Court makes an
award to the claimants in the amount of $3,777.09.
Award of $3,777.09.
Opinion issued October 12, 1982
CLYDE WOOD
vs.
DEPARTMENT OF HIGHWAYS
(CC-77-103)
Arthur A King, Attorney at Law, for claimant.
Nancy J. A 11ff, Attorney at Law, for respondent.
GARDEN, JUDGE:
Claimant is the owner of a tract of land on Surveyor?s Branch Road in Summers
County, West Virginia. The claimant purchased the property in September 1975,
at which time he had a small summer home built on the property. In 1976, a slip
occurred, and by the spring of 1977, the slip had progressed up to the house. The
claimant was forced to purchase a second piece of property and move the house
and an outbuilding from the original tract of land. The claimant contends that
the slip which occurred was the result of action taken by employees of the
respondent when they stopped up a ditch line on Surveyor?s Branch Road causing
water to flow over the road and onto his property.
Bill Hanshew, Jr., Regional Construction Engineer for the Department of
Highways, testified that he was the District Engineer for District 9, which
includes Summers County, from 1975 to 1977, and was familiar with the property
damage in this claim. He explained that the claimant?s property was affected by
the movement of the ground, which was aggravated
244 REPORTS
STATE COURT OF CLAIMS [W. VA.
by underground water seeping beneath
Surveyor?s Branch Road and existing on the claimant?s property. There was also
a small dirt road below claimant?s property which removed some of the lateral
support for the property. Mr. Hanshew recommended that the respondent drill the
ditch line and install a perforated pipe to help stabilize Surveyor?s Branch
Road and claimant?s property. This work was performed, but claimant?s property
continued to slip to the point that claimant was no longer able to reside upon the
land.
The Court has determined from the preponderance of the evidence that the
respondent was not negligent in the maintenance of its road, and, in fact, had
attempted to correct the slip on claimant?s property while remedying the slip
problem occurring on Surveyor?s Branch Road. Therefore, the Court is of the
opinion to, and hereby does, disallow the claim.
Claim disallowed.
Opinion issued October 26, 1982
AMERICAN HOSPITAL SUPPLY
vs.
DEPARTMENT OF HEALTH
(CC-82- 197)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant seeks payment of the sum of $1,140.00 for two airfloat lapidus units
for patient care which, while being rented by Huntington State Hospital, were
damaged and rendered inoperable.
Respondent?s Answer admits the validity and amount of the claim, and states
that sufficient funds were available in its appropriation for the fiscal year
in question from which the obligation could have been paid.
Accordingly, the Court makes an award to the claimant in the amount requested.
Award of $1,140.00.
W. VA.J
REPORTS STATE COURT OF CLAIMS 245
Opinion issued October 26,
1982
NARENDRA BORA
vs.
DEPARTMENT OF HEALTH
(CC-82-97)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks payment of the sum
of $157.00 for damage to personal property at Huntington State Hospital.
Respondent acknowledges the validity and amount of the claim, and avers that
sufficient funds were available in its appropriation for the pertinent fiscal
year from which the claim could have been paid. Accordingly, the Court makes an
award of $157.00 to the claimant.
Award of $157.00.
Opinion issued October 26, 1982
NELSON EDDIE FURNER, AN INCOMPETENT,
SUES BY AND THROUGH AVA ELIZABETH FURNER
YOUNG, HIS NEXT FRIEND, AND
AVA ELIZABETH FURNER YOUNG, INDIVIDUALLY
vs.
DEPARTMENT OF MENTAL HEALTH
(D-1O1O)
James R. Watson, Attorney at Law, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General for the respondent.
GARDEN, JUDGE:
Ava Elizabeth Furner Young filed this action individually and on behalf of her
son, Nelson Eddie Furner, an incompetent. Mr. Furner was injured when he jumped
from the roof of Ward 0 at respondent?s Weston State Hospital where he was a
patient. The claimant contends that the respondent was negligent in failing to
prevent him from gaining access to the roof of the building.
246 REPORTS
STATE COURT OF CLAIMS [W. VA.
Nelson Eddie Furner, 24 years of age,
was a patient at Weston State Hospital for treatment of an epileptic condition
and for mental retardation. The ward on which he was located, Ward 0, Unit 3,
was a ?closed ward,? that is all doors leading to the outside of the ward were
kept locked at all times. The patients were not locked in their rooms but were
free to roam in the hallways or rooms of the ward as they desired. On the
evening of October 13, 1973, Mr. Furner was given his usual medication at
approximately 9:00 p.m. Normally, the patients receive medication and then
return to their rooms for the night, but are permitted to stay up if they
desire. Bernard Davis, a Psychiatric Aide II employed by Weston State Hospital,
was on duty the night of October 13, 1973. After having provided the usual
medication to Mr. Furner and the other ward patients at approximately 9:00
p.m., Mr. Davis was sweeping the TV room when he heard a ?fall sound? and
thought that a wheelchair patient may have fallen. The telephone then rang and the
supervisor told him that Nelson Furner was ?laying out back.? Mr. Davis
proceeded outside where he found him lying on the ground. He did not know why
he was outside the building, nor did he know how he had gotten there.
Nelson Eddie Furner testified that he entered the mop room on his floor through
an unlocked door, and then went up a ladder in the mop room, into the attic.
Then, he used a smaller ladder to go up onto the roof of the building. Another
patient, Gary George, was with him. When the two reached the roof, Nelson Eddie
Furner jumped off one end of the building and Gary George jumped off the other
end. Both patients were injured. Mr. Furner was taken to WVU Hospital for
treatment of abrasions to his body and a broken left leg. He remained in the
hospital until his release on December 24, 1973, when the claimant took him to
Ohio where he now resides. Since that time, it has been necessary for him to
have surgery on his right leg.
When the psychiatric aide, Bernard Davis, returned to Unit 3, he determined
that the mop room door was unlocked and that a ladder had been placed against
the trap door in the ceiling, which door was opened to the attic. Mr. Davis
then
W. VA.] REPORTS
STATE COURT OF CLAIMS 247
locked the mop room door and ?got away from it.? According to Davis, the mop
room door was kept locked at all times except during the evenings from 8:45 to
9:30 p.m. when the floors were being mopped. It was necessary at that time to
obtain water from the mop room for use in washing the floors. Apparently it was
at this time that the two patients, Furner and Young, gained entrance to the
mop room. One ladder was in the mop room because men were making repairs to the
roof during the day and were using the ladder to get to the attic and then onto
the roof.
For the respondent to be found liable for the injuries to Nelson Eddie Furner,
negligence on the part of the respondent must be established. Foreseeability of
injury to one to whom a duty is owed, is of the very essence of negligence. 13
M. J. Negligence ?22. This Court is of the opinion that the sequence of
events leading to the injury of the claimant was not forseeable.
Although the Court is sympathic to Nelson Eddie Furner, the Court is
constrained to hold that, for the foregoing reasons, the claim must be denied.
Claim disallowed.
Opinion issued October 26, 1982
DAVID R. GOLD and
LOUIS H. KHOUREY d/b/a
GOLD & KHOUREY
vs.
OFFICE OF THE STATE AUDITOR
(CC-82-192a)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent PER CURIAM:
The claimants are attorneys who served as counsel for criminal indigents in
juvenile, misdemeanor, or felony proceed-
248 REPORTS
STATE COURT OF CLAIMS [W. VA.
ings pursuant to the provisions of
West Virginia Code, Chapter 51, Article 11. Claimants? fees were denied by the
respondent because the fund was exhausted.
The claimants also served as counsel for indigents in Mental Hygiene hearings
by appointment of the Circuit Court of Marshall County, West Virginia, pursuant
to the provisions of West Virginia Code, Chapter 27, Article 5. This statute
provides for the payment of mental hygiene commissioner fees and attorney fees
out of the ?mental hygiene fund? by the State Auditor. West Virginia Code
?27-5-4(i). Claimants? fees were denied by the respondent as the fund was
exhausted.
The factual situations in this claim are identical to that in Richard K. Swartling, et al. v.
Office of the State Auditor, 13 Ct.Cl. 57 (1979). Accordingly, awards are made in the amounts
indicated below to the claimants.
Needy Persons Fund ?
award of $1,140.50.
Mental Hygiene Fund ?
award of $42.50.
Opinion issued October 26, 1982
DAVID R. GOLD and
LOUIS H. KHOUREY d/b/a
GOLD & KHOUREY
vs.
PUBLIC LEGAL SERVICES
(CC-82-192b)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimants are attorneys who served as counsel for criminal indigents in
juvenile, misdemeanor, or felony proceedings pursuant to the provisions of West
Virginia Code, Chapter 51, Article 11. Claimants fees were denied by the
respondent because the fund was exhausted.
The claimants also served as counsel for indigents in Mental
W. VA.J REPORTS
STATE COURT OF CLAIMS 249
Hygiene hearings by appointment of the Circuit Court of Marshall County, West
Virginia, pursuant to the provisions of West Virginia Code, Chapter 27, Article
5. This statute provides for the payment of mental hygiene commissioner fees
and attorney fees out of the ?mental hygiene fund? by the State Auditor. West
Virginia Code ?27-5-4(i). Claimants? fees were denied by the respondent as the
fund was exhausted.
The factual situations in this claim are identical to that in Richard K. Swartling, et al. v. Office of the State
Auditor, 13 Ct.Cl. 57 (1979). Accordingly,
awards are made in the amounts indicated below to the claimants.
Needy Persons Fund ?
award of $422.50.
Mental Hygiene Fund ?
award of $65.00.
Opinion issued October 26, 1982
GENEVA HILL
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-241)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
This claim seeks recovery of damages to personal property located in the
basement of claimant?s residence at 82A Rural Lane near Chester, West Virginia.
At some time during the period between May 30, 1978, and June 14, 1978, water
flooded the claimant?s basement. The claimant alleges that the water was
surface water cast onto her property from State Route 16/4 which entered the
basement through a window well.
The claimant testified that a low spot on the road created a large puddle which
splashed water onto claimant?s property when vehicles passed through the
puddle. There is also a culvert from the road which empties onto claimant?s
property from which she has attempted to maintain a ditch through
250 REPORTS
STATE COURT OF CLAIMS [W. VA.
her property for drainage. The
claimant had made many complaints to employees of the respondent about the
water problems which she experienced.
Donald M. Robinson, the Maintenance Superintendent for Hancock County,
testified that he had visited the claimant?s property after a complaint from
the claimant. He explained that water flowed onto claimant?s property because
it is the natural drainage course. The respondent maintains a ditchline on the
side of the road opposite from claimant?s property. There is no easement for a
drain through claimant?s property; therefore, it is the responsibility of the
claimant to maintain the ditch for the water draining naturally onto her property.
The Court finds that the preponderance of the evidence supports those
assertions of the respondent and, accordingly, is constrained to deny this
claim.
Claim disallowed.
Opinion issued October 26, 1982
WAITMAN D. JETT and
MARILYN JETT
vs.
DEPARTMENT OF HIGHWAYS
(CC?78?17)
Joseph C. Hash, Jr., Attorney at Law, for claimants. Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
Claimants are the owners of real estate and a residence located on West
Virginia Secondary Route 8 in Jackson County, West Virginia, adjacent to
Interstate 77.
On or about July 11, 1976, a heavy
rainfall occurred and water from Little Sandy Creek flooded claimants? property
and residence. A second flood occurred in July 1977. The claimants and the
respondent stipulated that damage to claimants? property mounted to $935.00 as
a result of the first flood.
The claimants allege that negligent maintenance of a channel
W. VA.] REPORTS
STATE COURT OF CLAIMS 251
and the construction of an inadequate culvert under 1-77 were the proximate
causes of the flooding.
The respondent contends that the culvert under 1-77, a 96-inch pipe, was
adequate; that the drain or channel flowing into this pipe was on private
property; and that the rainfall was of an extraordinary nature.
Two witnesses for the claimants, Mrs. Roland Haught and Mr. Kenneth 0. Gough,
testified to their familiarity with the property which is the subject of this
claim. Mr. Gough owned the property at one time. He testified that no floods
had occurred prior to the construction of 1-77. Mrs. Haught testified that she
taught school in a building on the site of claimants? home for many years and
she had never observed any floods on the property.
The evidence establishes that large rocks and other debris were blocking the
channel of the creek to the 96-inch culvert under 1-77. After the rocks and
debris were removed by the respondent and the claimants, the claimants did not
experience any further flooding on their property.
The Court is of the opinion that the respondent was negligent in its
maintenance of the creek bed at the mouth of the 96- inch culvert under 1-77,
and this negligence was the proximate cause of the flood on claimants?
property. See Haught v. Dept. of Highways, 13 Ct.Cl. 237 (1980). Therefore, the Court makes an
award to the claimants in the amount of $935.00.
Award of $935.00.
Opinion issued October 26, 1982
MONSANTO COMPANY
vs.
BOARD OF REGENTS
(CC-78-282)
Gary C. Markham, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
The respondent Board of Regents on behalf of Marshall Uni
252 REPORTS
STATE COURT OF CLAIMS [W. VA.
versity, one of the institutions under its supervision and control, arranged
fcir bids to be let for the replacement of the Astro-Turf on Marshall?s
football field on April 26, 1978. The claimant, Monsanto Company, hereinafter
referred to as Monsanto, submitted a bid in the amount of $390,000.00 to remove
the old turf and to put down new Astro-Turf. A bid from Super-Turf was also
submitted in the amount of $386,920.78. Thereafter, Monsanto received from the
respondent a letter of intent dated May 10, 1978, which specifically stated:
?This letter of intent does not authorize you to commence work on the referenced
project. Any work performed or any materials purchased or contracted for prior
to receipt of a written ?Notice to Proceed? and/or a purchase order shall be at
the contractor?s risk.? The letter requested certain documentation from
Monsanto required to be executed before the contract could be awarded to
Monsanto. Included with this letter was the standard Form of Agreement which
Monsanto signed and returned to the respondent.
Monsanto requested permission to remove the old turf prior to the time the
contract was approved by the respondent, and was informed by Larry Barnhill, an
employee of the respondent, that the contract had not been signed, and that if
Monsanto performed any work it would be at Monsanto?s own risk. On May 31,
1978, Monsanto sent employees to remove the old turf, which work was completed
on June 6, 1978.
The Department of Finance and Administration awarded the bid to the low bidder,
Super-Turf, and the respondent refused to pay claimant?s invoice in the amount
of $13,010.00 for the removal work. The claimant filed this claim to recover
the amount of the invoice.
The respondent admits the work was performed by Monsanto but takes the position
that the claimant proceeded at its own risk without a contract. Cost of
removing the old turf was included in the bid of the low bidder.
To support its position, the claimant contends its claim is similar to one
awarded by this Court in Russell
Transfer v.
W. VA.]
REPORTS STATE COURT OF CLAIMS 253
Alcohol Beverage Control
Commissioner, 10 Ct.Cl. 40 (1973) The
instant case is distinguishable from that claim as the claimant therein had an
executed contract. The Department of Finance and Administration refused to
issue a purchase order to permit performance of the contract. The Court held
that the issuance of a purchase order ?is a ministerial act, and the
destruction of it .
. . in no manner nullified a written and
legally enforceable contract between the parties.?
In this claim the evidence is undisputed and, accordingly, it must be denied.
Claim disallowed.
Opinion issued October 26, 1982
IRLANT E. MOORE and
ROBERT L. MOORE
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 179)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a stipulation to the effect that on or about June
8, 1982, while claimant Irlant E. Moore was operating a 1973 Chervolet Caprice
titled in the name of Robert L. Moore across a bridge on West Virginia Route 52
in McDowell County, a highway owned and maintained by the respondent, one of
the tires struck a piece of steel, protruding from the surface of the bridge,
resulting in damage in the amount of $43.15.
Following the precedent of Haliiburton Services vs. Dept. of Highways, 12
Ct.Cl. 281 (1979), an award in that sum should be made.
Award of $43.15.
254 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued October 26, 1982
JOHN ORNDOFF
vs
DEPARTMENT OF HIGHWAYS
(CC-82-111)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a stipulation to the effect that on or about
February 5, 1982, while claimant was operating his 1972 Chevrolet station wagon
across a bridge on West Virginia County Route 15, a highway owned and
maintained by the respondent, the vehicle struck loose timber decking
protruding from the bridge which damaged the car?s exhaust system in the amount
of $104.16.
Following the precedent of Halliburton Services vs. Dept. of Highways, 12
Ct.Cl. 281 (1979), an award in the above amount is made.
Award of $104.16.
Opinion issued October 26, 1982
B. PAYMAN, M.D., ET AL
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-205)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims were submitted for decision upon the pleadings. The claimants seek
reimbursement for medical and dental services rendered to persons incarcerated
at the West Virginia
W. VA.] REPORTS
STATE COURT OF CLAIMS 255
State Prison for Women at Pence Springs, West Virginia, as follows:
Claim No. Claimant Amount
CC-82-205 B. Payman,
M.D. $1,199.00
CC-82-206 Professional Laboratory & X-Ray $ 32.00
CC-82-208 Jett S. Andrick, D.D.S. $ 843.00
CC-82-210 Harold E. Harvey, M.D., Inc.
$ 75.00
CC-82-211 C. K. Agarwal, M.D. $1,235.00
CC-82-214 Beckley Medical Arts, Inc. $ 60.00
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
While we feel that these claims should in equity and good conscience be paid,
we further believe that awards cannot be made, based on our decision in Air/cern Sales and Service, et al. v.
Dept. of Mental Health, 8 Ct.Cl. 180
(1971).
Claims disallowed.
Opinion issued October 26, 1982
PETERS FUEL CORPORATION, ET AL.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-185)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims were submitted for decision upon the pleadings. The claimants seek
payment for various goods and services furnished to the respondent as follows:
Claims Against Huttonsville
Claim No. Correctional Center Amount
CC-82-185 Peters Fuel Corporation
$30,097.20
CC-82-220 Monongahela Power Company $66,033.70
256 REPORTS
STATE COURT OF CLAIMS [W. VA.
Claims Against West Virginia
Claim No. Prison for Women Amount
CC-82-202 Summers County Hospital
$13,456.65
CC-82-232 Summers Community Clinic
Pharmacy $
29.90
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
While we feel that these claims should in equity and good conscience be paid,
we further believe that awards cannot be made, based on our decision in Airkem Sales and Service, et al v. Dept.
of Mental Health, 8 Ct.Cl. 180
(1971).
Claims disallowed.
Opinion issued October 26, 1982
THE PIONEER COMPANY and
MOUNTAIN STATE CONSTRUCTION COMPANY, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-76-148)
Charles W. Yea ger, Attorney at Law, for claimants.
S. Reed Waters, Jr., Attorney at Law, for respondent. GARDEN, JUDGE:
The Pioneer Company and Mountain State Construction Company, Inc., had a
contract with the respondent for the construction of a storm sewer from the
Kanawh River crossing beneath Kanawha Boulevard and Greenbrier Street in
Charleston, West Virginia. At the point where Kanawha Boulevard and Greenbrier
Street intersect, the contractors encountered a sanitary sewer which the
contractors allege
W. VA.1
REPORTS STATE COURT OF CLAIMS 257
caused considerable extra work and
additional time on the project, for which they seek compensation from this
Court.
The claimants used a tunnel method of installing the storm sewer, starting from
a manhole at the edge of the Kanawha River. As the mechanical hydraulic shield
progressed beneath the Kanawha Boulevard, it struck an object and became lodged
underground. In order to dislodge the shield, it was necessary for employees of
the claimants to hand excavate from a manhole 20 feet from the shield. The
respondent redesigned the location of the storm sewer after it was determined that
a 15? sanitary sewer encased in concrete was the object struck by the shield of
the machine excavator. The contractors were paid for the work performed in
accordance with the redesign of the storm sewer and sanitary sewer which
crossed beneath the storm sewer. A portion of the Kanawha Boulevard caved in,
breaking other utility lines, and the contractors were paid for the work and
materials incident to this. A broken water main also caused problems in the
correction work, keeping the soil in a more liquid state. The contractors
allege that the extra labor, equipment, and materials for dislodging the shield
amounted to $41,498.99.
The original plans fcr this project showed the storm sewer passing over the
sanitary sewer with 1.6 foot clearance. The plans also provided that the
contractor was to use extreme care in the area of existing utilities and should
hand excavate.
The respondent contends that the claimants failed to comply with a specific
note in the construction plans which provided as follows: ?Location and depth
of existing utility lines shall be verified by the contractor in advance of
storm sewer construction. Extreme care shall be exercised in excavating
existing utilities and hand excavation only will be permitted in the vicinity
of existing pipes and/or conduits.? The respondent also contends that when the
contractors encountered the obstruction, they failed to ascertain that it was a
utility or to use the proper construction methods that would have prevented the
problem which occurred. The respondent further contends that the claimants have
been paid for all of the construction costs incident to the project in
accordance with the contract provisions
258 REPORTS
STATE COURT OF CLAIMS [W. VA.
From the evidence, it appears to the
Court that the contractors were paid for all costs incident to the redesign of
the storm sewer over the sanitary sewer which was actually adjacent to the
planned flow line of the storm sewer. The use of the mechanical hydraulic
machine in the proximity of the sanitary sewer, rather than hand excavation,
resulted in the extra costs incurred by the contractors in dislodging the
shield from the sanitary sewer.
The Court is of the opinion to and does disallow this claim. Claim disallowed.
Opinion issued October 26, 1982
TRI-CITY WELDING SUPPLY COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-173a)
A. J. Massinople for claimant.
Stuart Reed Waters, Jr., Attorney at Law, for respondent. WALLACE, JUDGE:
This claim was submitted for determination upon a written stipulation filed by
the parties indicating that the claimant supplied the respondent?s Equipment
Division with oxygen and acetylene in cylinders; that it is common custom and
practice in the welding industry that cylinders are loaned to customers; that
three cylinders of the claimant were darni.ged by fiie while in the possession
and control of the respondent, and that the sum of $437.00 is a fair and
reasonable amount for the damaged cylinders.
Accordingly, the Court makes an award to the claimant in the amount stipulated.
Award of $437.00.
W. VA.J
REPORTS STATE COURT OF CLAIMS 259
Opinion issued October 26, 1982
TRI-CITY WELDING SUPPLY COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-173b)
A. J. Massinople for claimant.
Stuart Reed Waters, Jr.,
Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim was submitted for determination upon a stipulation indicating that
the claimant supplied the respondent?s Equipment Division with oxygen and
acetylene in cylinders; that it is common custom and practice in the welding
industry that cylinders are loaned to customers; that eight cylinders belonging
to the claimant were lost due to the negligence of the respondent; that this
negligence was the proximate cause of the damages suffered by the claimant, and
that the sum of $1,394.00 is a fair and reasonable amount for the lost
cylinders.
Accordingly, the Court makes an award to the claimant in the amount stipulated.
Award of $1,394.00.
Opinion issued October 26, 1982
WAYNE CONCRETE CO.
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-109)
D. W. Daniel, Jr., for claimant.
Stuart Reed Waters, Jr., Attorney at Law, for respondent. WALLACE, JUDGE:
This claim was submitted for determination upon a stipulation filed by the
parties which revealed the following facts:
260 REPORTS STATE
COURT OF CLAIMS [W. VA.
Claimant supplied 34 cubic yards of concrete grout to the respondent for use in
certain highway projects. The purchase order for the grout was dated after the
delivery date of the material, and could not be processed by the respondent.
The respondent acknowledges that the concrete grout was received and utilized
in its work, and that the sum of $2,642.84 is a fair and reasonable amount for
the material supplied.
Based on the foregoing facts, the Court makes an award to the claimant in the
amount stipulated.
Award of $2,642.84.
Advisory opinion issued October 26, 1982
WEST VIRGINIA UNIVERSITY
OUTPATIENT PHARMACY
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-145)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim arose between two State agencies, and the Court will render an
advisory decision pursuant to West Virginia Code ?14-2-18.
Claimant seeks payment of the sum of $117.50 for prescriptions filled for an
inmate of the West Virginia Penitentiary at Moundsville. Respondent admits the
validity and amount of the claim, but states in its Answer that no funds
remained in its appropriation for the fiscal year in question from which the
obligation could have been paid.
No award can be made by the Court in this case since it is an advisory
determination. Even if an award were possible, we believe that the case is
governed by this Court?s decision in 4irkem
Sales and Service, et al. v. Dept. of Mental
Health, 8 Ct.Cl. 180 (1971), and the claim would be denied.
W. VA.] REPORTS
STATE COURT OF CLAIMS 261
The Clerk of the Court is hereby directed to forward copies of this opinion to
the respective heads of the State agencies involved in this claim.
Opinion issued December 1, 1982
B.
& S. AIR TAXI SERVICE
vs.
OFFICE
OF THE SECRETARY OF STATE
(CC-82-259)
No appearance by claimant.
Henry C. Bias, Jr., Deputy
Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings. The claimant seeks
payment for services furnished to the respondent in the amount of $304.50.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
The Court finds that an award cannot be made, based on the decision in Airicem Sales and Service, et al. v. Department of
Mental Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued December 1, 1982
BOWLINGS, INC., ET AL.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82- 150)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims were submitted for decision upon the pleadings.
262 REPORTS
STATE COURT OF CLAIMS [W. VA.
The claimants seek payment for various
goods and services furnished to the respondent as follows:
Claim No. Claim Against Anthony Center
Amount
CC-82-150 Bowlings, Inc. $ 407.74
Claims Against West Virginia
Claim No. Prison for Women Amount
CC-82-226 Butler?s Pharmacy $2,466.18
CC-82-222 FMRS Mental Health Council, Inc. $ 96.00
CC-82-218 William D. McLean, M.D. $ 64.00
CC-82-217 D. L. Rasmussen, M.D. $ 665.00
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
The Court finds that these claims should, in equity and good conscience, be
paid, but awards cannot be made, based on the decision in Airkem Sales and Service, et al. v. Department of
Mental Health, 8 Ct.C1. 180 (1971).
Claims disallowed.
Opin?on issued December 1, 1982
SUSAN L. CALE
vs.
BOARD OF REGENTS
(CC-82- 160)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted upon the pleadings, claimant seeks payment of the sum
of $530.00 representing a miscalculation in her rate of pay by West Virginia
University. While in the employ of the Department of Ophthalmology, claimant
changed position from Secretary II to full-time Secretary II,
W. VA.1
REPORTS STATE COURT OF CLAIMS 263
and finally, to Secretary III. Two
incorrect computations of her salary resulted in a $530.00 underpayment to her.
The respondent admits the amount and validity of the claim and that sufficient
funds remained in its appropriation for the fiscal year in question from which
the obligation could have been paid. The Court makes an award to the claimant
in the amount of $530.00.
Award of $530.00.
Opinion issued December 1, 1982
ROBERT CONLEY, GENEVA CONLEY
and MICHAEL CONLEY, by
his mother, GENEVA CONLEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-78- 145)
Charles T. Bailey and Tom Parks,
Attorneys at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
On June 8, 1976, claimant Geneva Conley was operating a 1973 Ford Bronco
belonging to her husband, claimant Robert Conley, on W.Va. Route 3 in Logan
County, West Virginia. Claimant Michael Conley, son of claimants Geneva Conley
and Robert Conley, was a passenger in the vehicle. As claimant proceeded on
State Route 3 towards her home in Shively, West Virginia, she had a single
vehicle accident in which she and her son received personal injuries, and the
vehicle was totalled. Claimants have alleged that failure of the respondent to
maintain the berm of State Route 3 caused the accident and resultant injuries
and losses sustained by the claimants.
W.Va. State Route 3, in the area of the accident, was described as a narrow
two-lane, blacktopped road with a slight curve. A hillside is on one side and a
narrow berm is on the other side. As claimant came into the curve, a truck was
approaching in the opposite lane of travel. When the two vehicles were
approximately five to ten feet apart, the claim-
264 REPORTS STATE
COURT OF CLAIMS [W. VA.
ant drove onto the berm of the road.
The vehicle thereupon struck a large rock located about six inches from the
pavement causing claimant to lose control, and the vehicle crossed the road,
hit the hillside and rolled over. Claimant testified that she was unable to see
the rock ?until I was right on it,? because weeds had grown up around it.
Walter Hager, a foreman for respondent during the period before claimant?s
accident, testified that he was aware of the rock on the berm. He was not aware
of how the rock came to be on the berm. He stated that the rock had not been
moved off of the bern because ?I didn?t have the equipment to move it with,
didn?t have a good end loader to pick it up.? He further testified that ?. . .If you met somebody coming around that curve pretty
fast, you would have to move off.? He also stated that he had received
complaints about the rock on the berm prior to claimant?s accident.
?The berm or shoulder of a highway must be maintained in a reasonably safe
condition for use when the occasion requires, and liability may ensue when a
motorist is forced onto the berm in an emergency, or otherwise necessarily uses the berm of the
highway.? (Emphasis supplied.) 39
Am.Jur. 2d Highways, Streets &
Bridges ?488, Taylor v. Huntington, 126 W.Va. 732, 30 S.E.2d 14 (1944). Failure to remove a
large rock from the berm and permitting weeds to obscure the rock from the view
of a motorist in a section of highway where use of the berm by motorists is
common, created an unsafe condition.
The record in this claim established that the respondent had knowledge of the
presence of the rock on the berm of the road. The failure of respondent to
remove this rock created a hazardous condition which constituted negligence.
This negligence was the proximate cause of the injuries and loss sustained by
the claimants.
Claimant Michael Conley suffered an injury to his back and two broken ribs. He
was required to stay in the hospital in traction for five days. He has now
fully recovered from his injuries. Claimant Geneva Conley suffered a
compressiontype fracture of the second and third lumbar vertebrae with
deformity. She remained in the hospital for three weeks following the accident.
It was necessary for her to wear a
W. VA.J
REPORTS STATE COURT OF CLAIMS 265
back brace following her release from
the hospital. She has suffered low back pain since the injury occurred,
requiring her to avoid lifting heavy objects and to sleep on a hard surface. As
a result of the injury to her back, claimant has a gibbous deformity or
humpback, which is permanent. The percentage of her disability is approximately
35 percent. Inasmuch as the accident occurred in June, 1976, after school was
out for the summer and claimant was able to return to her position as a
teacher?s aide in Logan County in September 1976, she did not sustain any loss
of wages.
The medical bills incurred by claimant Michael Conley were in the amount of
$516.00, and those incurred by claimant Geneva Conley were in the amount of
$1,863.05. The ambulance bills totalled $195.71.
The 1973 Bronco had a fair market value at the time of the accident of
$3,700.00, but the purchase price had been $2,995.00.
In view of the evidence, the Court makes awards as follows:
$2,995.00 to claimant Robert Conley; $1,500.00 to claimant Michael Conley; and
$10,000.00 to Geneva Conley.
Award of $2,995.00 to Robert Conley.
Award of $1,500.00 to Michael Conley.
Award of $10,000.00 to Geneva Conley.
Opinion issued December 1, 1982
G. M. McCROSSIN, INC.
vs.
BOARD OF REGENTS
(CC-79-682)
Patrick Thompson and Ronald G.
Robey, Attorneys at Law, for claimant.
Ann V. Dornblazer, Assistant Attorney General, and Henry C. Bias, Jr., Deputy Attorney General, for respondent.
GARDEN, JUDGE:
In April 1979, the Board of Regents issued an Advertisement for Bids for the
construction of an athletic shell facility for
266 REPORTS
STATE COURT OF CLAIMS 1W. VA.
West Virginia University in
Morgantown, West Virginia. The bid documents requested a base bid and alternates
numbered one through eight. Claimant G. M. McCrossin, Inc. (McCrossin)
submitted a bid for this project in accordance with the bid documents on July
26, 1979. At the bid opening, McCrossin was the apparent low bidder. When
employees of McCrossin compared its bid with the bids submitted by the other
bidders, they determined that an error had been made in alternates 2 and 5 on
the bid documents. On the day following the bid opening, McCrossin notified the
respondent, by letter dated July 27, 1979, of the errors in alternates 2 and 5.
After a review of the bid documents and supporting data from McGrossin, the
Division of Purchasing in the Department of Finance and Administration notified
McCrossin that there was insufficient justification for rejection of the bid.
McCrossin then proceeded with construction of the shell facility in accordance
with the contract, but filed this claim to recover the loss alleged as a result
of the errors in alternates 2 and 5.
McCrossin contends that an adjustment should have been permitted by the
respondent or that it should have been released from performance of the
contract.
The respondent contends that McCrossin failed to meet the mandatory
requirements of Purchasing Regulation 2.02 (6), which details the conditions
under which a bid may be rejected after a bid opening. Section 2.02 (6)
provides as follows:
?The Director, at his discretion, may reject an erroneous bid after the bid opening if all of the following conditions exist: 1) a clerical error was made; 2) the error materially
affected the bid; 3) rejection of the bid would not cause a hardship on the
State agency involved other than losing an opportunity to receive goods and/or
services at a reduced cost; 4) enforcement of the part of the bid in error
would be unconscionable.? (Emphasis supplied.)
In explaining the decision made by the Purchasing Division, Glenn R. Cummings,
Director of the Purchasing Division, testified that the data submitted by
McCrossin to explain the errors in alternates 2 and 5 on the bid did not
establish that a
W. VA.]
REPORTS STATE COURT OF CLAIMS 267
clerical error had occurred; that he
determined that a judge- mental error had occurred; that the portion of the
error was a small percentage of the whole contract; that rejection of the bid would
have caused a hardship upon the respondent in having to rebid the alternates or
the whole bid; and that enforcement of the part of the bid in error was not
unconscionable as it was only a three or four percent differential.
McCrossin introduced an abundance of evidence illustrating in detail the manner
in which the errors in the alternates occurred. The errors occurred during the
hour prior to the submission of the bid when McCrossin?s employees were
finalizing the figures to be relayed by telephone to an employee waiting in
Charleston. Needless to say, there was much confusion in putting the figures in
the proper places, computing the final figures, and then reporting the same to
the person in Charleston who submitted the final bid at the bid opening. ?. . .Construing the words literally, a ?clerical error?
means an error committed by a clerk or some subordinate agent in the
performance of clerical work. It usually denotes negligence or carelessness
which is not attributable to the exercise of judicial consideration or
discretion.? 21A M.J., Words & Phrases, Page 350. In the opinion of the
Court, McCrossin did satisfactorily prove that the errors were clerical.
However, Regulation 2.02 (6) of the Division of Purchasing. which applies to
the rejection of a bid, requires that three other conditions also be met before
the bid may be rejected.
The clerical error must also materially affect the bid. As the errors in
alternates 2 and 5 constituted approximately three to four percent, the Court
is reluctant to find that the bid was materially affected by the errors.
Rejection of the bid in this instance may have caused a hardship upon the
respondent Board of Regents inasmuch as this bid letting was the second one for
the construction of the Athletic Shell Facility. The delay involved in
re-bidding the contract probably would have resulted in increased cost of the
project to the detriment of the respondent.
In addition, it does nQt appear from the evidence that en-
268 REPORTS
STATE COURT OF CLAIMS [W. VA.
forcement of the bid in error by the
Division of Purchasing would be unconscionable.
In the opinion of the Court, the Director of the Purchasing Division did not
abuse the discretion granted to him under Section 2.02 (6) of the Purchasing
Regulations.
For the foregoing reasons, the Court is of the opinion to, and does, disallow
the claim.
Claim disallowed.
Opinion issued December 1, 1982
GENERAL MOTORS
ACCEPTANCE CORPORATION
vs.
DEPARTMENT OF MOTOR VEHICLES
(CC-82-46)
Sarah G. Sullivan, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant seeks to recover the sum of $4,259.64 for damages it has suffered due
to respondent?s failure to record claimant?s lien on a West Virginia Certificate
of Title.
On April 19, 1978, Lillian Vaught entered an installment sales contract payable
to Gary Fronrath Chevrolet, Inc. of Fort Lauderdale, Florida, for the purchase
of a 1978 Chevrolet Monte Carlo. The contract was transferred and assigned to
General Motors Acceptance Corporation (?GMAC?). A Florida Certificate of Title
was issued to Ms. Vaught on which GMAC was designated as first lien holder.
In January of 1980, Ms. Vaught applied for a W.Va. Certificate of Title. A
title was issued, omitting GMAC?s lien, which had been recorded on the Florida
title. Ms. Vaught defaulted on her sales contract, at which time GMAC
discovered that Ms. Vaught was holding clear title to the vehicle. GMAC also
discovered that Ms. Vaught had sold the automobile.
W. VA.]
REPORTS STATE COURT OF CLAIMS 269
On June 29, 1981, GMAC obtained a
default judgment in the Circuit Court of Kanawha County in the amount of
$4,235.98 with interest, and costs in the sum of $10.00. A Writ of Execution
was issued and returned no property found; claimant now seeks recovery from the
Department of Motor Vehicles.
The Court finds that the respondent was negligent in failing to record
claimant?s lien on the W.Va. Certificate of Title and makes an award to the
claimant in the amount of $4,245.98, an award of interest being precluded by
Code, ?14-2-12. See Wood Countj Bank
v. Dept. of Motor Vehicles, 12 Ct.Cl.
276 (1979).
Award of $4,245.98.
Opinion issued December 1, 1982
GLENN E. HILLER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 183)
No appearance by claimant.
Matthew H. Fair, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a written stipulation to the effect that
respondent is liable for damages in the amount of $155.76, based upon the
following facts.
On or about July 1, 1982, claimant was driving his automobile off the Patrick
Street Bridge in Kanawha County, West Virginia. The automobile ran over a drain
hole on the right side of the exit and was damaged because the metal cover over
the grill of the drain was broken and sharply edged. Respondent?s failure to
repair the metal grill cover was the proximate cause of the damages suffered by
the claimant. The Court makes an award to the claimant for the sum of $155.76,
which is a fair and equitable estimate of the damages sustained.
Award of $155.76.
270 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 1, 1982
HENRY A. KAY and
CHARLES E. KAY
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-80-146)
Robert H. C. Kay, Attorney
at Law, for claimants.
Robert D. Pollitt, Assistant Attorney General, for respondent.
GARDEN, JUDGE:
Claimants filed this claim to recover damages occasioned by actions of
employees of the respondent when they released certain Canada geese near
claimants? farm located in Mason County, West Virginia. The geese came upon
claimants? property and ate sorghum and corn plants resulting in damage of
$3,800.00.
The respondent obtained the Canada geese from the State of New York and
released them in an attempt to re-establish a native wildlife population of
Canada geese in West Virginia. The Canada geese were released at two points on
the Kanawha River on June 24, 1979. In early June, 1979, the claimants had
planted corn and sorghum on 19 acres of their farm in the area next to the Kanawha
River where it joics Pond Branch Creek. In early July, 1979, when the plants
were about knee high, claimants noticed numerous geese in the field, at which
time claimants contacted their uncle, who in turn notified the respondent of
the problem. Employees of the respondent attempted to scare the geese off
claimants? property by shooting over the heads of the geese, but to no avail.
The geese continued to be a problem to the claimants until fall 1979 when the
crops were harvested.
Respondent?s witness, Thomas Lee Dotson, a District Wildlife Biologist for the
respondent, testified that 91 Canada geese were released at one point on the
Kanawha River, and 104 more were released at another point to go ?wherever they
wanted to go.?
W. VA.]
REPORTS STATE COURT OF CLAIMS 271
The Court finds that the respondent
released the Canada geese without regard to the propensity of geese to feed
upon sorghum. It was foreseeable that the Canada geese would seek the nearest
food supply, which happened to be available in claimants? field. It is the
opinion of the Court that the responder t was negligent in releasing the Canada
geese in proximity to claimants? property, and the Court makes an award to the
claimants in the amount of $3,800.00.
Award of $3,800.00.
Opinion issued December 1, 1982
WILLIAM B. McGINLEY
vs.
BOARD OF REGENTS
(CC-81-20)
James Casey, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Claimant seeks damages and attorney fees from the respondent for breach of
contract.
The claimant, after graduation from the College of Law at West Virginia
University in May 1980, was interviewed for the position of Attorney for
Students at the University. Of those interviewed, he was ranked second. The first
choice accepted the position. The claimant then accepted a position with the
Legal Services Plan in Beckley, West Virginia. In September 1980, the position
of Attorney for Students became vacant, and Edmund Podeszwa of the Office of
Personnel at West Virginia University wrote the claimant advising him of the
vacancy and asked if he wanted to apply for the position. The claimant advised
that he was interested and was interviewed in Morgantown on September 25, 1980.
After all interviews were completed, the claimant, on October
272 REPORTS
STATE COURT OF CLAIMS [W. VA.
1, 1980, was offered the job at an annual salary of $16,776.00, which was
accepted by claimant, and by agreement, he was to start work on October 20,
1980. After accepting the employment, the claimant resigned from his position
with Legal Services Plan, cancelled his lease on his apartment in Beckley, and
made preparations to move to Morgantown.
On October 7, 1980, the claimant was notified by Mr. Podeszwa that the
employment offer was withdrawn because the University had made a mistake
concerning the affirmative action policy in their hiring policy.
The claimant was unable to return to his job with Legal Services, and since he
had no employment, he and his wife returned to Morgantown where he entered the
private practice of law.
The position as Attorney for Students was not filled, and the University again
sought applicants. The claimant was again offered the job on February 18, 1981,
but declined the employment because he had accepted the position as Assistant
Prosecuting Attorney of Mason County, West Virginia at a salary of
$14,300.00.
The claimant contends in his complaint that he had a valid contract with the
University which was breached; that the salary agreed upon was annual and,
therefore, he was employed at least for a year. He seeks, as a part of his
damages, attorney fees and travel expenses. Mr. Podeszwa testified that travel
expenses to Morgantown were not to be paid by the University, which was
confirmed in claimant?s testimony. Mr. Podeszwa also testified that the first
six months are considered as a probationary period of employment.
There is no dispute of the facts in this claim. While it appears that the
respondent did breach the contract which it made with the claimant, there is no
evidence that the claimant sustained damage for reason of the breach inasmuch
as his employment could have been terminated at any time during his
probationary period. Accordingly, the Court is disposed to make an award in the
sum of $500.00.
Award of $500.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 273
Opinion issued December 1, 1982
REYNOLDS MEMORIAL HOSPITAL, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-28)
John T. Madden, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was filed by Reynolds Memorial Hospital to recover costs expended in
rendering medical services to Vester McCoy, an inmate of the West Virginia
State Penitentiary at Moundsville, West Virginia. Mr. McCoy was admitted to
Reynolds Memorial on February 19, 1981, where he remained until his death on
June 21, 1981. Total hospital charges for this period were $58,950.70. The
respondent has paid $5,628.75, which is the amount of expenses incurred between
February 19 and March 10, 1981, leaving a balance of $53,321.95. The respondent
denies liability for expenses incurred after March 10, 1981. On that date, the
Governor of the State of West Virginia, in accordance with W.Va. Code ?5-1-16,
granted a Medical Respite to Vester McCoy. The State would not bear any
responsibility for Mr. McCoy?s medical bills.
The Medical Respite was an agreement entered into between the Governor of West
Virginia and the inmate, and its purpose was to allow the inmate to die with
dignity. Mary McCoy, wife of Vester McCoy, initiated the request for the
Respite. At the time the Respite was issued, Vester McCoy was in a coma, and
the agreement was signed by Mrs. McCoy for her husband.
In accordance with W.Va. Code ?2-2-10 (m), persons ?under disability? is
defined to include convicts while confined in the penitentiary. W.Va. Code
?28-5-33 provides for the appointment of a committee for a convict confined to
a penitentiary for one year or more. Mr. McCoy?s sentence was for a term of
life with mercy. W.Va. Code ?28-5-36 provides that the committee main-
274 REPORTS
STATE COURT OF CLAIMS [W. VA.
tam all actions for the convict. ?No
action or suit shall be instituted by or against such convict after he is
incarcerated, and all actions or suits to which he is a party at the time of
his incarceration shall abate, and continue so until revived by or against the
committee, whose duty it shall be to prosecute or defend, as the case may be.?
The record does not establish that Mrs. McCoy was committee for her husband.
Therefore, no contract was entered into which would obligate the McCoy family
to bear Vester McCoy?s medical expenses. A contractual relationship had been
established between the hospital and respondent in which respondent agreed to pay
Vester McCoy?s medical bills. This contract continued throughout his
hospitalization. It is the opinion of the Court that the claimant is entitled
to recover the medical expenses incurred by Vester McCoy; therefore, the Court
makes an award to the claimant in the amount of $53,321.95.
Award of $53,321.95,
Opinion issued December 1, 1982
SAVAGE CONSTRUCTION COMPANY, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-14)
T. Carroll McCarthy, Jr., Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. WALLACE, JUDGE:
The claimant seeks to recover $6,788.75 from the respondent, $4,488.75
representing the cost of the installation of hot laid bituminous concrete as
directed by respondent, the balance of $2,300.00 representing liquidated
damages charged to the claimant.
By contract dated September 6, 1978, the claimant contracted with the
respondent to build a bridge known as the Folsom Bridge in Wetzel County, West
Virginia. All work was to be
W. VA.1 REPORTS
STATE COURT OF CLAIMS 275
completed in 90 working days. Notice to proceed was given the claimant on
October 5, 1978.
During the course of the contract, there were numerous delays for which the
respondent did not charge the claimant for working days. Work on the contract
actually commenced on November 6, 1978, after being delayed by the power
cornpanys failure to remove its pole and lines. The stream over which the
bridge was to be constructed was very narrow. The claimant installed pipes and
pumps to control the water during construction. However, the project was washed
out twelve times because of heavy rains requiring the claimant to clean up and
start over. A steel hauler?s strike held up the delivery of reinforcing steel
required in the footers. The steel was delivered January 23, 1979. Time was not
charged for these delays.
In June or July, 1979, claimant reported to respondent serious errors in the
plans and specifications. The bridge was to have been built with one wing wall
excluded, which was to be constructed after the bridge was completed, open for
traffic, and the existing bridge removed. There was an 81/2 foot error in the
plans, making it necessary to shorten the width of the bridge, then to open it
for traffic, remove the old structure, and complete the new bridge. No time was
charged for completing an abutment and building the wing wall due to the error
in the plans. Originally, it was planned to use slag or traffic maintenance
aggregate to maintain traffic on the bridge, but because of the time of the
year, respondent directed the claimant to cover the aggregate with hot laid
bituminous base. Claimant was paid for the base, but the cost was deducted from
its final payment, because the bridge was not completed on time. The bridge
opened for traffic on November 26, 1979, after 96 working days. Guardrail
installation and finishing work was not completed until spring. A total of 23
days were charged as liquidated damage.
The contract required the traffic be maintained over the existing bridge during
construction, then reroute the traffic over the new bridge with a minimum of
interruption. Work was to have been completed in 90 working days The bridge
276 REPORTS
STATE COURT OF CLAIMS [W. VA.
opened for traffic in 96 days on
November 26, 1979, and additional time was required to complete guardrails and
finishing work for a total of 113 working days. The Court finds the charge for
liquidated damages to be proper.
However, the error in the plans and specifications caused delays which, in
addition to extensions granted claimant, extended the completion date into the
winter months. For these reasons, the Court awards the claimant the $4,488.75
charged against its proceeds for hot laid bituminous concrete and its
installation.
Award of $4,488.75.
Opinion issued December 1, 1982
CHARLES H. SIMMONS d/b/a
SIMMONS? HAULING, ET AL.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-130)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims were submitted for decision upon the pleadings.
The claimants seek payment for various goods and services
furnished to the respondent as follows:
Claim No. Claims Against Anthony Center Amount
CC-82-130 Charles H. Simmons d/b/a
$1,926.80
Simmons? Hauling
CC-82-250 Greenbrier Physicians, Inc. $ 550.00
CC-82-253 Alfredo C. Velasquez, M.D. $1,430.00
Claims Against West Virginia
Claim No. Prison for Women Amount
CC-82-241 Steven Richman, DO, Inc. $ 495.00
CC-82-244 F. M. Mingo, D.D.S. $ 99.00
CC-82-255 Matthew Bender & Company, Inc. $ 95.00
W. VA.]
REPORTS STATE COURT OF CLAIMS 277
The respondent admits the validity and
amounts of these claims, but further alleges that sufficient funds were not
available at the close of the fiscal years in question from which the
obligations could have been paid.
The Court finds that these claims should, in equity and good conscience, be
paid, but awards cannot be made, based on the decision in Airkem Sales and Service, et al. v. Department of
Mental Health, 8 Ct.Cl. 180 (1971).
Opinion issued December 1, 1982
STARK ELECTRIC, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-193)
James W. St Clair, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. GARDEN, JUDGE:
Claimant filed this claim to recover liquidated damages assessed against it by
the respondent for failure to complete the installation of a lighting system on
1-64 under the terms of its contract for that work.
The claimant and the respondent entered into the contract on March 10, 1977.
Claimant was notified to proceed with the work on or about April 6, 1977.
Actual work on the project did not begin until October 26, 1977. The contract
completion date was March 15, 1978, but the actual completion date was July 26,
1978. The respondent contends that claimant would have completed this project
in the time allotted under the terms of the contract, but for the fact that
claimant failed to keep in contact with its suppliers and failed to perform
timely the preparation work necessary for the project, thereby run- fling into
the winter season.
The claimant contends that the delay in the project was occasioned by the
respondent in ?green tagging? or approving lids for the conduit boxes at the
site of the supplier and then later rejecting these lids on the project site, thereby
making
278 REPORTS
STATE COURT OF CLAIMS [W. VA.
it necessary to reorder the lids,
which then were unavailable to the claimant until February, 1978.
The evidence showed that claimant?s supplier for the junction boxes, frames and
lids submitted drawings to the respondent for approval in May, 1977. These
drawings were approved by respondent?s inspector, Robert W. Kendall, on May 26,
1977. The claimant then submitted a purchase order to the supplier for the
materials on June 1, 1977. A partial delivery of the junction boxes was made in
August 1977, at which time respondent informed the claimant that the lids for
the junction boxes did not meet the specifications, and the ?green tags? were
removed. The claimant contends that the junction boxes could not be installed
without the lids as this would have posed a danger to vehicular traffic. The
claimant then reordered the lids specified by the respondent. The new lids were
not approved and delivered until February 1978, at which time claimant was able
to install the junction boxes and complete the project. The claimant requested
a 90-day time extension, but this request was denied. The respondent assessed
liquidated damages in the amount of $10,800.00.
From the record in this claim, it was established that the problem of the lids
was based upon the tensile strength. The plans provided for 18 x 18 inch
junction boxes with lid strength of 60,000 psi. The claimant requested a change
to 22 x 22 inch junction boxes which the respondent permitted. However, when
the boxes were manufactured, the lids had a tensile strength of 30,000 psi.
These were the lids which were green tagged by respondent?s inspector. That
approval was an inadvertent error which was not discovered until August 18,
1977, at which time the junction boxes had been shipped to the project site.
The error was discovered by the respondent?s consultant for the inspection of
the materials. The whole problem originated with the failure of the respondent
to indicate the tensile strength required on the shop drawings, so the
inspector was not aware of the requirement.
From the record in this claim, the Court concludes that respondent?s
inadvertent error of green tagging the junction boxes, at least, contributed to
cause the delay experienced by claimant in completing the project. In addition,
it does not ap
W. VA.]
REPORTS STATE COURT OF CLAIMS 279
pear from the evidence that the
respondent suffered any damages as a result of this delay. For those reasons,
it was inappropriate for the respondent to assess liquidated damages. See Whitmyer Brothers, Inc. v. Dept. of Highways, 12 Ct.Cl. 9 (1977).
Award of $10,800.00.
Opinion issued December 6, 1982
SHIRLEY R. ADAMS
and BILLIE ADAMS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 146)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent
PER CURIAM:
This claim was originally filed in the name of Shirley R. Adams. The testimony
disclosed that the damaged automobile, a 1979 Impala stationwagon, was titled
in the joint names of the claimant and her husband, Billie Adams, and the Court
on its own motion joined Billie Adams as an additional claimant.
Mrs. Adams testified that she was driving their stationwagon on houte i9 near
Marlinton, West Virginia, on May 1, 1982, when she observed a ?Rough Road?
sign. She slowed down and then struck a drainage ditch which had been dug by
respondent across the road. The ditch was estimated to be 18 inches wide and 8
to 10 inches deep. Both front tires had to be replaced at a cost of $91.68.
The evidence indicates that the ditch line was dug on April 29 and that the
gravel covering the ditch settled over the next two days. The Court finds that
the respondent was negligent in failing to properly maintain the construction
area. Hale and Wingate vs. Dept. of
Highways, 11 Ct.Cl. 93 (1976). An
award of $91.68 is accordingly made to claimant.
Award of $91.68.
280 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 6, 1982
ALLSTATE INSURANCE CO.,
as subrogee of MICHAEL HALL
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-149)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a written stipulation to the effect that the
respondent is liable for damages in the sum of $246.76, based upon the
following facts.
On or about the week of February 4, 1981, a 1980 Dodge Omni, owned by
claimant?s insured, Michael L. Hall, was parked in his driveway in Fairview,
Marion County, West Virginia. Respondent, then engaged in snow removal and
cindering operations, caused cinders to be blown onto the vehicle, damaging the
painted finish.
The Court finds that respondent?s negligence was the proximate cause of the damages
suffered by the claimant?s insured and makes an award to the claimant in the
amount of $246.76.
Award of $246.76.
Opinion issued December 6, 1982
MICHAEL CROUCH
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-236)
Paul R. Goode, Jr., Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent. GARDEN, JUDGE:
The claimant seeks to recover $2,500.00 for damage sustained to his home and
1977 Ford automobile caused by dust from
W. VA.J REPORTS STATE COURT OF CLAIMS 281
a section of W.Va. Route 7 in Wyoming
County, near Oceana, West Virginia. Claimant?s house is located 35-40 feet off
the highway. Heavy traffic and winter weather caused a section of the highway
of approximately 65-70 yards in front of claimant?s home to deteriorate. In the
early spring and summer of 1978, the respondent dug out the existing blacktop
pavement and replaced it with heavy rock and crusher run rock. This was covered
by a mixture of gravel and tar. After this process was completed, the entire
section was blacktopped. The application of crusher run rock to the road
surface created the heavy dust condition which caused damage to the claimant?s
house and automobile.
Although numerous complaints were made to the respondent, no action was taken
to alleviate the dust problem during construction.
The claimant?s frame house had to be repainted, and the paint finish was
damaged on his automobile, which he sold at a reduced price because of the
damage. Based upon estimates of the damage, the Court makes an award to the claimant
in the amount of $1,350.00.
Award of $1,350.00.
Opinion issued December 6, 1982
SILBERN D. and
METTA GODDARD
vs.
DEPARTMENT OF CORRECTIONS
(CC-81-301)
Claimants appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimants are the owners of property located on McConnell Drive in Moundsville,
West Virginia, behind the West Virginia State Penitentiary. They seek damages
in the amount of
282 REPORTS
STATE COURT OF CLAIMS 1W. VA.
$2,723.00 allegedly caused by the
negligence of the respondent when the penitentiary installed a new sewer
system. The old sewer and two catch basins were removed. Since the catch basins
were taken out, surface water has flowed through the field behind the
penitentiary and down onto claimants? property. On June 25, 1981, the water ran
below the foundation of claimants? house and through the basement, cracking the
rear wall. Also damaged were the water heater, furnace, and dryer. There had
been no problems with surface water before the installation of the new sewer.
After the June 1981 flooding, penitentiary personnel used a backhoe to dig a
ditch to drain the water from claimants? property.
The preponderance of the evidence presented herein shows that the sewer system
constructed by the respondent caused a substantial increase in the volume of
surface water flowing onto the claimants? land. It is a general rule of law
that one who, by means of artificial channels, collects surface water in a body
or mass and discharges it upon adjacent land is liable for any resulting
damage. WiUston Apartment, Section F,
Inc. v. Berger, 229 Fed. Supp. 338
(E.D. Va. 1964). Accordingly, the Court makes an award of $2,723.00 to the
claimants.
Award of $2,723.00.
Opinion issued December 6, 1982
PAUL GYKE and JOE ANN GYKE
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-162)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
On June 11, 1982, claimant Joe Ann Gyke was driving her husband?s 1982 Cavalier
on Interstate 64 across the Nitro Bridge from Nitro into Hurricane, West
Virginia. She was following a pickup truck that struck a pothole from which a
WVA.J REPORTS
STATE COURT OF CLAIMS 283
piece of concrete or a rock was thrown. The concrete or rock hit and cracked
the Cavalier?s windshield. Mrs. Gyke?s startled reaction resulted in pulled
back muscles which necessitated a doctor?s visit and medication. The car was
repaired at a cost of $419.00, of which all but $50.00 was paid by insurance.
Mrs. Gyke?s medical bills totalled $33.97.
Mrs. Gyke testified that she had called respondent approximately three weeks
before this incident to complain about the condition of the road.
The record reflects, by a preponderance of the evidence, that respondent had
notice of the condition of the road and its failure to remedy the defect
constitutes negligence. The Court makes an award to the claimant, for expenses
not covered by insurance, of $83.97.
Award of $83.97.
Opinion issued December 6, 1982
MR. and MRS. STEPHEN KENT HILL
vs.
BOARD OF REGENTS
(CC-80- 183)
David HILl, Attorney at Law, for claimant.
Ann Dornblazer, Attorney at Law, for respondent.
GARDEN, JUDGE:
In May 1978, claimants entered a lease with West Virginia University to rent an
apartment in the College Park Apartment complex. Coin-operated washers and
dryers were provided in the complex. On May 9, 1979, claimant was washing some
clothes which belonged to his wife. After washing and drying the clothes,
claimant found that they had oil stains on them. Claimant testified that he was
unable to determine whether the washer alone, or in combination with the dryer
caused the spots, but that there were ?greasy handprints? on the washer.
Dry-cleaning failed to remove the stains. The
284 REPORTS STATE
COURT OF CLAIMS [W. VA.
clothes, 2 blouses, a dress and a skirt, were valued at $93.35, including
dry-cleaning costs. The Court has determined that the personal property
involved in the claim is jointly owned by Stephen Kent Hill and his wife. The
Court therefore amends the style of the claim to include Mrs. Stephen Kent
Hill.
The relationship between the claimant and respondent was that of landlord and
tenant. See Delassio v. Board of
Regents, 12 Ct.Cl. 242 (1979). A
landlord may be found liable when negligence is shown in the maintenance of its
appliances provided for the use of tenants, even in the absence of a
contractual or statutory duty. Allen
v. Board of Regents, 13 Ct.Cl. 321
(1980). 49 Am. Jur. 2d Landlord &
Tenant, ?881 (1970).
From the evidence presented in this case the Court is of the opinion that
respondent?s failure to properly inspect and maintain the equipment in the
College Park Apartment laundramat constituted negligence and that such
negligence proximately caused the damage to claimants? personal property.
Award of $93.35.
Opinion issued December 6, 1982
MARK A. HISSAM and
JULIA A. HISSAM
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-375)
Claimants appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent. GARDEN, JUDGE:
Claimants are residents of the Oakbrook Drive subdivision in Mineral Wells,
West Virginia. Prior to July of 1980, Oakbrook Drive was an unpaved road which
was not a part of the State road system. The homeowners on Oakbrook Drive
petitioned respondent to bring the road into the State system.
W. VA.] REPORTS
STATE COURT OF CLAIMS 285
This was done in early 1980. Shortly after, the homeowners requested that
respondent pave the road, but were told there were insufficient funds to do
this work. By an informal agreement, however, the homeowners agreed to pay for
the paving, and respondent agreed to provide the necessary engineering and a
drainage system. The road was paved by a third party in July and August of
1980, but the drainage system was not installed. August 18, 1980 brought the
first significant rainstorm since the road was completed. Claimants? family
room and basement were flooded. They seek $3,395.37 for damages sustained by
respondent?s failure to provide adequate drainage.
Claimant Mark Hissam testified that the agreement provided that the drainage
system would be installed before the road. Respondent failed to put in the
drainage system before the road was completed. The only change made to the
existing system was to put a 15-inch pipe under the road. This pipe, however,
fed into an existing 8-inch drain line. When the August 18 rainstorm occurred,
water backed up in several homeowners? yards and flowed down claimants?
driveway into their house. Mr. Hissam stated that he had expressed fears that
flooding would occur to respondent?s employees. There had never been a flooding
problem before respondent?s work, and there has been no flooding since
respondent completed a new drainage system.
Respondent?s witness, Kenneth Webb, an engineer in respondent?s employ, testified
that respondent acquired right-of-ways for a drainage system, but did not
install drainage at the time of paving because it was felt the existing system
was sufficient. A gap was left between the 15-inch and 8-inch pipes to allow
any overflow of water to drain over the land as it had previously. Mr. Webb
stated that construction work then being done on Mr. Hissam?s driveway was the
cause of the flooding.
The Court finds that respondent failed to design and provide adequate drainage
for the road improvement and that this negligence was the proximate cause of
claimants? damages.
This Court has previously held that when respondent fails
286 REPORTS
STATE COURT OF CLAIMS [W. VA.
to design and provide adequate
drainage, and a reasonably prudent person would have foreseen that damage would
occur without proper drainage, an award for damages will be made. Osborne v. Dept. of Highways, 10 Ct.Cl. 83 (1974). Claimants? evidence indicated that
their damage amounted to $3,395.37.
Award of $3,395.37.
Opinion issued December 6, 1982
RICKY S. HOWERTON
vs.
DEPARTMENT OF HIGHWAYS
(CC-80?329)
W. Merton Prunty, Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
On the morning of August 21, 1980, a record flood hit the area of Goldtown,
Jackson County, West Virginia. Numerous homes in the area were damaged or
destroyed. The house owned by the claimant, Ricky Howerton, was lifted from its
foundation by the flood waters and was carried approximately 7/10 of a mile
downstream. It struck a bridge and came to rest sideways across W.Va. Route 21
completely blocking the road. Claimant alleges that negligence on the part of
respordent?s employees in attempting to remove the house from the road resulted
in the destruction of the house. The claimant had built the house between May
and November of 1978. His records indicate that he had spent approximately
$28,000.00 for materials and expended 750 hours or more in constructing the
house. Claimant seeks to recover $40,000.00.
Claimant was able to reach his house before noon on August
21. Respondent?s work crew was already present at the site. Claimant was
removing his possessions from his house when he was informed that the crew was
going to try to turn the house to clear one lane for traffic. The work crew
removed two windows on one end of the house and ran a chain through
W. VA.] REPORTS
STATE COURT OF CLAIMS 287
them. When the chain was pulled, it ripped through the house. Mr. Howerton
testified that no precautions were taken to prevent damage to the house. ?If
they had put a steel plate
it was suggested to them .
. . in front of that house where
or anything so that chain would have held onto it and got more of an area to
push, the house could have been turned right around enough to have opened up
that road there on the side.?
Claimant testified that his home then was destroyed by respondent. ?Well, after
that, the next thing I remember was somebody hollering, ?get out of the house.?
I got out the front and looked up in the air and there come that Grade-All
bucket over the top and just smashed it. After he got it down on the ground,
the endloader come up. Them guys was just grinning. They just loaded her up in
the pickups and buried it on another man?s property.? Claimant also testified
that he had suggested getting a house mover. Claimant said, ?On the house
movers, having them move it which I checked into, it would have been at the
tops four hours. That?s their travel time and all.? Claimant?s witness, Dickie
E. Fisher, who was present when the house was destroyed corroborated claimant?s
testimony.
Respondent?s witness, Corporal Harold Facemyer of the State Police, testified
that the house had to be removed in order to allow for passage of emergency
vehicles. While conceding that there were alternate routes to the houses along
Route 21, Corporal Facemyer stated that the detours were too lengthy for
emergency vehicles had there been any life-threatening situations. Under
cross-examination, he said no such emergency arose. Corporal Facemyer also
stated his belief that the house was unsalvageable.
Claimant?s witness, William F. Boggess, a residential home- builder testified
to the value of the house. He estimated the fair market value before the flood
was $68,000.00. He estimated that it would cost $19,450.00 to restore the house
to its original condition after it was damaged by the flood and that the fair
market value of the house immediately after the flood but before its
destruction was $48,550.00. These estimates were based on a study of
photographs of the house and on viewing a comparable house with similar damage.
288 REPORTS
STATE COURT OF CLAIMS [W. VA.
While the respondent had both a right
and a duty to remove the house from the highway and was obliged to perform it
expeditiously, it had a concomitant obligation to perform that duty in a
reasonable manner. The plain preponderance of the evidence impels the
conclusion that it did not do so and accordingly, the claimant is entitled to
an award of the damages which he sustained as a result of the respondent?s
actions.
On the issue of damages, the weight attributable to the testimony of the
witness Boggess must be reduced considerably by reason of the fact that it was
based upon photographs of the house. Aside from that evidence, however, there
is only the testimony of the claimant and the witness Facemyer which is in
irreconcilable conflict. In view of that conflict, the Court is disposed to
award damages in the sum of $20,000.00.
Award of $20,000.00.
Opinion issued December 6, 1982
INDUSTRIAL GAS & SUPPLY COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 182)
J. Peter Richardson, Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent
PER CURIAM:
This claim was submitted upon a written stipulation to the effect that the
respondent is liable for damages in the amount of $2,389.42, based upon the
following facts.
Between January 31, 1979 and February 28, 1982, respondent agreed to purchase
goods from claimant under written contract R-77-94. Respondent owes claimant
the sum of $2,389.42 for costs of oxygen and acetylene cylinders, the cost of
lost cylinders, and for service charges for goods sold. The Court makes an
award of $2,389.42, which is a fair and equitable estimate of damages sustained
by claimant.
Award of $2,389.42.
W. VA.J
REPORTS STATE COURT OF CLAIMS 289
Opinion issued December 6, 1982
LESTER A. KUBSKI, M.D.
vs.
DEPARTMENT OF HEALTH
(CC-82-167)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant is a psychiatrist employed by Huntington State Hospital. Dr. Kubski
was subpoenaed to testify at a criminal court hearing in Charles Town, West
Virginia. Claimant?s travel expenses for food, lodging, and gasoline amounted
to
$126.05.
Respondent has admitted it is indebted to claimant in the amount of $88.07.
West Virginia State Travel Regulations allow $15.00 per day for food allowance.
The $37.98 balance is in excess of the $15.00 per day allowance. The Court
makes an award in the amount admitted.
Award of $88.07.
Opinion issued December 6, 1982
ROBERT HOWARD LATTA
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-147)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
On or about May 29, 1982, claimant was driving his 1973 Cadillac across the
35th Street Bridge from Charleston into Kanawha City, West Virginia. A bolt
broke off from the bridge
290 REPORTS
STATE COURT OF CLAIMS [W. VA.
and fell, cracking claimant?s
windshield. The damage was repaired at a cost of $150.00.
While respondent is not an insurer of the safety of motorists using the
highways of this State, it does have the affirmative duty of using reasonable
care to keep the same in reasonably safe condition. This includes bridges which
are part of the State highway system. The Court is of the opinion that the
record establishes negligence on the part of the respondent, and makes an award
in favor of the claimant.
Award of $150.00.
Opinion issued December 6, 1982
JOHN T. MAY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-165)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. WALLACE, JUDGE:
On May 18, 1981, at about 6:30 in the evening, claimant was injured in a fall
from a bridge into a creek on Route 44 in Stirrat, West Virginia. The bridge
involved had been taken into the State highway system in the spring of 1981.
Department of Highways personnel inspected the bridge and found it defective.
It was barricaded and closed to vehicular traffic.
Claimant testified that by closing the bridge, access to his residence from the
highway was prevented. No walkway across the creek was built, so claimant was
forced to walk along a steel ?I? beam that had been left when the bridge was
torn down. He stated he had travelled this way for about 2 1/2 months and was
aware that the bridge was closed.
As a result of the accident, claimant injured his back, received facial
abrasions, and broke his glasses. Medical bills
W. VA.]
REPORTS STATE COURT OF CLAIMS 291
for emergency room treatment and
replacement of eyeglasses totalled $379.25.
Respondent was negligent in failing to provide an adequate walkway after
closing the bridge, but the Court believes that the claimant, with his prior
knowledge of the condition of the bridge, was also negligent. Under the
doctrine of comparative negligence, the Court allocates negligence as follows:
Claimant 20%, respondent 80%. Reducing the claimed damages by 20%, the Court
makes an award in favor of claimant in the amount of $303.40.
Award of $303.40.
Opinion issued December 6, 1982
MEMORIAL GENERAL HOSPITAL
ASSOCIATION, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-256)
Richard H. Talbot, Jr., Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings. The claimant seeks
payment for services furnished to respondent?s Huttonsville Correctional Center
in the amount of
$165,695.32.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
The Court finds that this claim should, in equity and good conscience, be paid,
but an award cannot be made, based on the decision in Airkem Sales and Service, et al. v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
292 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 6, 1982
ETHEA M. SCOTT
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-102)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant is a psychiatric aide at Huntington State Hospital. On March 25, 1982,
she was helping to transport patients from Huntington, using a State-owned car.
The car developed mechanical problems and was taken to the Department of
Highways garage at Crawley, West Virginia. The car was serviced and the parties
continued on their travel. When claimant left the car, the back of her nurse?s
uniform was covered with oil and grease. She testified that this had not been
present prior to stopping at the garage, and that two mechanics had test-driven
the car after making the repairs. Claimant?s witness, Kermit L. Sargent
testified that both mechanics were ?filthy dirty.? The cost of the uniform was
approximately $38.00. The Court believes that the negligence of respondent?s
employees in failing to adequately protect the car seats proximately caused the
claimant?s damage.
Award of $38.00.
Opinion issued December 6, 1982
CHARLES W. W. STULTZ and
MARY N. STULTZ
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-12)
Howard Krauskopf, Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
At approximately 1:00 a.m. on January 1, 1981, claimants were traveling on
Secondary Route 5 in Hampshire County,
W. VA.]
REPORTS STATE COURT OF CLAIMS 293
West Virginia, on their way home from
a New Year?s Eve party. It was snowing and the roads were slick. While
traveling at a speed of 30-35 miles per hour in their 1977 Blazer about a mile
from their home, claimants came upon a little rise or knoll in the road
followed by a 14-15 foot dip. Claimant Charles Stultz testified that, parked in
the middle of the roadway, in the dip, was a truck belonging to the respondent
with bright lights blazing. Mr. Stultz stated that he was one hundred feet from
the truck when he first observed it, and when he tried to stop his car, it began
to slide, and hit trees on the opposite side of the road.
As a result of the accident, the Blazer was totaled, and claimants seek $4,200
in damages for the vehicle. In addition, claimant Mary N. Stultz suffered
personal injuries, and both claimants? glasses were broken. The amount of those
bills was $926.91, for a total claim of $5,126.91.
Testifying on behalf of the respondent was the driver of the truck, Ersel A.
Hott. Mr. Hott indicated that he was cindering Route 5 when a piece of wood
became lodged in the fan. He then stopped the truck in his lane of travel and
got out to investigate. Mr. Hott stated that the four-way flashers and the
revolving light were on.
Liability in this claim is governed by West Virginia Code
?17C-13-1:
?(a) Upon any highway outside of a business or residence district no person
shall stop, park, or leave standing any vehicle, whether attended or
unattended, upon the paved or main-traveled part of the highway when it is
practicable to stop, park, or so leave such vehicle off such part of said
highway, but in every event an unobstructed width of the highway opposite a
standing vehicle shall be left for the free passage of other vehicles and a
clear view of such stopped vehicles shall be available from a distance of two
hundred feet in each direction upon such highway.
(b) This section shall not apply to the driver of any vehicle which is disabled
while on the paved or main-
294 REPORTS
STATE COURT OF CLAIMS [W. VA.
traveled portion of a highway in such
manner to such extent that it is impossible to avoid stopping and temporarily
leaving such disabled vehicle in such position.?
Respondent?s driver violated that statute and respondent thereby was guilty of
negligence which proximately caused the damages suffered by the claimants. See
also The Board of Education of the
County of Kanawha vs. Department of Highways, 13 Ct.Cl. 60 (1979).
Accordingly, an award of $5,126.91 is made to the claimants.
Award of $5,126.91.
Opinion issued December 6, 1982
JANET T. SURFACE
vs.
WORKMEN?S COMPENSATION FUND
(CC-82-280)
William H. Hazlett, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations in the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment in the amount of $6,828.33, for reporting services for
Workmen?s Compensation hearir gs under a contract with the Department of
Finance and Administration for fiscal year 1980-1981. Respondent in its Answer
admits the validity of the claim and that the amount is fair and reasonable for
the services rendered.
In view of the foregoing, the Court makes an award to the claimant in the
amount of $6,828.33.
Award of $6,828.33.
W. VA.]
REPORTS STATE COURT OF CLAIMS 295
Opinion issued December 6, 1982
TERRA AQUA CONSERVATION
Vs.
DEPARTMENT OF HIGHWAYS
(CC-82-283)
No appearance by claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a written stipulation to the c?ffect that the
respondent is liable for damages in the amount of $854.78, based on the
following facts.
On September 3, 1981, claimant received from respondent a purchase order for
wire gabions, which contained a ?ship to? and a ?delivery? address. Claimant
shipped the goods via Allegheny Freight Lines, Inc. to the Clarksburg, West
Virginia ?ship to? address. Respondent indicated to Allegheny that the goods
actually belonged in Fairmont, West Virginia, but would accept shipment in
Clarksburg and redeliver to Fairmont themselves. Respondent failed to provide
for redelivery until October 28, 1981, when claimant was requested to authorize
a reconsignment. Claimant incurred storage and redelivery costs of $854.78 as
the result of respondent?s failure to provide for the reconsignment and
redelivery, which sum the Court finds is a fair and reasonable amount of the
damages sustained.
Based on the foregoing facts, an award of $854.78 is made to the claimant.
Award of $854.78.
296 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 6, 1982
THOMAS R. TREADWAY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-227)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
This claim was submitted upon a written stipulation to the effect that
respondent is liable for damages in the amount of $140.28, based upon the
following facts.
On or about August 23, 1982, claimant Thomas Treadway was driving his 1976
Chevrolet on W.Va. Route 73 in the vicinity of Campbell?s Creek Drive, Kanawha
County, West Virginia. While crossing the Campbell?s Creek Bridge, claimant?s
vehicle struck a piece of metal protruding from the bridge, damaging a tire.
The Court finds that respondent?s negligence was the proximate cause of the
damages suffered by claimant in the amount of $140.28, which is a fair and
equitable estimate of the damages.
Based on the foregoing facts, an award of $140.28 is made to claimant.
Award of $140.28.
Opinion issued December 6, 1982
WESLAKIN CORPORATION
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-156)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant seeks payment of the sum of $95.67 for steel pipe sold to Anthony
Correctional Center.
W. VA.1
REPORTS STATE COURT OF CLAIMS 297
Respondent?s Answer admits the
validity and amount of the claim, and states that sufficient funds were
available in its appropriation for the fiscal year in question from which the
obligation could have been paid.
Accordingly, the Court makes an award to the claimant in the amount requested.
Award of $95.67.
Opinion issued December 6, 1982
WESTINGHOUSE ELECTRIC SUPPLY COMPANY
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-221)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings. The claimant seeks
payment for services furnished to the respondent in the amount of $732.76.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
The Court finds that an award cannot be made, based on the c3ecision in Airkem Sales and Service, et al, v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
298 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 6, 1982
HAROLD E. WILEY
vs.
DEPARTMENT OF MOTOR VEHICLES
(CC-80-33 1)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
In 1977, claimant licensed his 1977 GMC Truck with respondent. Respondent
erroneously titled the vehicle as a station wagon. Claimant annually paid a
license fee which was $6.00 higher than it would have been had the truck been
titled correctly. The error persisted for three years, and claimant spent $2.00
to have the vehicle properly titled. He sues respondent for $20.00.
The Court finds that respondent was negligent in erroneously titling claimant?s
vehicle. However, the statute of limitations has run on the first year of Mr.
Wiley?s claim. W.Va. Code ?14-2-21 provides that ?the court shall not take
jurisdiction of any claim .
. . unless notice of such claim be filed
with the clerk within such period of limitation as would be applicable under
the pertinent provisions of the Code of W.Va. . . . and such period of limitation may not be waived or
extended.? The Court makes an award in the amount of $14.00.
Award of $14.00.
Opinion issued December 6, 1982
WILSON WELDING SUPPLY COMPANY
vs.
RAILROAD MAINTENANCE AUTHORITY
(CC-82-258)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings. The claimant seeks
payment in the amount of $340.00 for one
W. VA.]
REPORTS STATE COURT OF CLAIMS 299
oxygen cylinder and one acetylene
cylinder which were lost by the respondent.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
While this claim should, in equity and good conscience, be paid, an award
cannot be made, based on the decision in Airkem
Sales and Service, et al. v. Department of Mental Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued December 7, 1982
ALBERT G. CAPINPIN
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-158)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
Claimant sues for $205.54 for damages to his 1980 Chevrolet when it struck a
low lying branch on Lucado Street in Charleston, West Virginia. The retractable
antenna was broken and had to be replaced. Respondent?s witness, Albert L.
Fleshman, Jr., an employee of the Department of Highways, testified that Lucado
Street has been owned and maintained by the City of Charleston since 1959.
The Court cannot conclude from the evidence that the accident was caused by
negligence on the part of the respondent and therefore, denies the claim.
Claim disallowed.
300 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 7, 1982
ROGER K. CLAY
vs.
BOARD OF REGENTS
(CC-82- 123)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
On Monday, April 23, 1982, claimant returned to his dormitory room at Marshall
University after a weekend in Tennessee. He discovered that his cassette deck
was missing. The loss was reported to campus security. Upon investigation, no
evidence of breaking and entering could be found. Claimant seeks $329.00, the
purchase price of the cassette deck.
Under cross-examination, claimant testified that whoever entered his room did
so with a pass key. He also said that ?there was nothing they [the State] could
have done? to prevent his loss. There is no evidence of negligence on the part
of the University officials in maintaining proper security for the dormitory.
Claim disallowed.
Opinion issued December 7, 1982
DAIRYLAND INSURANCE COMPANY,
SUBROGEE OF JESSE W. COBERN, JR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-10)
Robert J. Louderback, Attorney
at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
On September 11, 1981, Jesse W. Cobern, Jr. was driving his 1975 Chevrolet on
Campbell?s Creek Drive in Charleston, Kanawha County. He encountered an area of
construction, and because there was gravel on the road, he switched from the
right-hand to the left-hand lane where the road was clear.
W. VA.]
REPORTS STATE COURT OF CLAIMS 301
When Mr. Cobern saw traffic
approaching, he returned to his lane. Shortly afterward, he struck a manhole
which was in the middle of his lane. The car stopped on impact. The front
frame, fly wheel cover, oil pan, and windshield had to be replaced at a cost of
$1,035.09, the amount of this claim. The amount includes $250.00 deductible,
paid by Mr. Cobern.
Mr. Cobern testified that there were no flagmen or signs warning of
construction or of the manhole. He also testified that he had travelled the
road without incident previously, although in a different vehicle. He was aware
of the construction, but not the manhole.
Respondent?s witness, Albert L. Fleshman, Jr., an employee of Department of
Highways, stated that the construction involved the installation of sanitary,
sewer, and force mains. This work was being performed by the Maiden Public
Service District, under contract with Department of Highways. According to the
contract, responsibility for all work done, and any necessary repairs to the
roadway rested with the Public Service District. There is no evidence in the
record to establish that the respondent had notice of the condition. Even if
there was notice, the Court is of the opinion that claimant?s negligence was
equal to or greater than respondent?s, because of his knowledge of the
construction area. For those reasons, the Court must deny the claim.
Claim disallowed.
Opinion issued December 7, 1982
CHARLES DENNIS
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-80-336)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
In 1978, claimant converted a Voikswagon automobile into a dune buggie.
Concerned about inspection requirements,
302 REPORTS
STATE COURT OF CLAIMS [W. VA.
claimant first contacted the
Department of Public Safety to find out what would be required to make the
vehicle ?street legal.? These requirements were met and in August 1978, the
dune buggie passed State inspection. In 1979, respondent adopted new safety
regulations for dune buggies. Claimant?s vehicle failed to meet these new
regulations and was rot issued another inspection sticker. Claimant contends
that the old regulations should continue to apply to his vehicle. He sues for
$3,000.00. the amount he spent converting the car into a dune buggie.
The Commissioner of Motor Vehicles is charged with making rules and regulations
concerning the administration and enforcement of motor vehicle inspections.
West Virginia Code ?17C-16-4. There was no evidence to the effect that he
abused his discretion in changing those regulations and, accordingly, this
claim must be denied.
Claim disallowed.
Opinion issued December 7, 1982
CHARLES N. DURBIN
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-181)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant seeks payment for damage to his barn wall allegedly caused by the improper
construction of a highway berm which allowed water to flow onto his land. Bills
totalling $420.15 were submitted as proof of the damage.
Claimant?s property, consisting of 27 acres, is located on both sides of Route
891 in Cameron, Marshall County, West Virginia.
W. VA.]
REPORTS STATE COURT OF CLAIMS 303
Mr. Durbin?s barn, a two-story
structure, is situate 15-20 feet from the edge of the road. The top floor is
almost level with the roadway, and the basement is below the elevation of the
roadway.
On about the first day of June, 1981, rainwater flowed from the surface of the
roadway down to claimant?s barn and pushed cut the cement block wall. Claimant
testified that the respondent, over his objections, kept lowering the berm of
the road, prior to the date of the incident in question, in an effort to divert
water from claimant?s property.
James P. Reid, Marshall County Maintenance Superintendent, testified that they
had indeed made ?various attempts to divert the water from the area of the
barn.? Cold mix asphalt was applied to the berm in the area of the barn in May
of 1981, one month before the incident complained of by claimant.
When questioned about the work, the claimant stated:
? They went ahead and they put the blacktop in there along the edge and the
water goes right on down and spread out all over the place . . . That solved the problem, and, of course, here the other
night it come a hard rain and sort of broke over and I had to build it up a
little bit again.?
The law of West Virginia is well settled that surface water is a common enemy
which each landowner must fight off as best he can, provided that an owner of
higher ground may not inflict injury to the owner of lower ground beyond what
is reasonably necessary. Hoidren v.
Dept. of Highways, 11 Ct.Cl. 75
(1975). In the instant case, the evidence indicates that the respondent
conducted its highway repairs to the satisfaction of the claimant prior to the
flooding and damage complained of; that the flooding occurred as the result of
a single, heavy rainstorm; and that the respondent did nothing to increase the
flow of water onto the claimant?s land. Accordingly, the claim is disallowed.
Claim disallowed.
304 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 7, 1982
HENRY W. GOULD
vs.
BOARD OF REGENTS
(CC-79-357)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant, a West Virginia University professor, resides on College Avenue in
Morgantown. During a snow storm on January 16, 1978, a large tree on University
High School property fell, cutting the power lines to claimant?s residence.
Electric service was not restored for 24 hours. Claimant?s tropical fish,
valued at $317.50, froze because the heaters in the fish tanks could not
operate.
Claimant testified that the tree, estimated to be 150 feet high, was living and
that high winds accompanied approximately 18? of snow. Claimant?s wife stated
that she had, on a number of occasions, complained to University officials
about the trees facing their property. She explained that the size and angle of
the trees made her feel that they were unsafe. Grounds crews responded to the
complaints by inspecting the trees and declaring them safe.
It is not demonstrated by a preponderance of the evidence that the accident was
caused by negligence on the part of the respondent. For that reason, the claim
must be denied.
Claim disallowed.
Opinion issued December 7, 1982
EARL F. GUTHRIE
vs.
DEPARTMENT OF HIGHWAYS
(CC?82-125)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant seeks compensation in the amount of $631.00 for
W. VA.]
REPORTS STATE COURT OF CLAIMS 305
damage to a 1981 Plymouth sustained
when the car struck a pothole. The pothole was located on Route 60 in Belle,
West Virginia. Claimant testified that the pothole was located just past a
bridge ramp, and because of a dip in the road the pothole was not visible. The
hole was located about half way across the right-hand lane and measured about
two feet long by nine inches wide. When claimant called respondent after the
accident, he was told that there had been another call concerning the pothole.
In order to make an award, it must be established that respondent knew or
should have known of the existence of the pothole and respondent must have had
sufficient time in which to repair the pothole. The Court, accordingly,
disallows this claim.
Claim disallowed.
Opinion issued December 7, 1982
WILLIAM PAUL HALL, SR.,
ADMINISTRATOR OF THE ESTATE OF
WILLIAM PAUL HALL, JR.
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(CC-76-134)
William C. Garrett and Thomas N.
Whittier, Attorneys at Law, for
claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
This is a claim for damages for the alleged wrongful death of William Paul
?Sonny? Hall, Jr., a 25-year-old patient at Weston State Hospital. In 1968, at
the age of 19, Sonny was committed to Weston by his parents on the advice of a
psychiatrist. On August 20, 1975, while a patient in Ward 14, Unit 5 of the
hospital, Sonny Hall was burned by another patient, Arnold Lee Shinaberry. The
incident occurred at ap
306 REPORTS
STATE COURT OF CLAIMS [W. VA.
proximately 8:00 p.m. in a locked,
enclosed sun porch. Sonny Hall was clad in a long tee shirt, and Arnold
Shinaberry, who had received matches from another patient earlier in the day,
set fire to Sonny?s shirt. One of the two aides on duty that night, Mickey
Scarff, heard shouting on the sun porch and ran to unlock the door. Scarff
called the other aide and they escorted Sonny Hall to his room. A registered
nurse was summoned and emergency treatment was administered to the victim by
the nurse and the only physician on duty at that time, Dr. Zabat. The doctor
ordered Sonny Hall?s transfer to the West Virginia University Medical Center in
Morgan- town. He was transported there by ambulance, where he was examined and
immediately sent to the burn center at West Penn Hospital in Pittsburgh,
Pennsylvania. Two days later, he died as the result of his injuries.
Claimant alleges that the respondent was negligent in failing to properly
supervise the patients in the ward and in failing to have proper treatment available
to the victim. Claimant seeks damages under West Virginia Code ? 55-7-6 in the amount of $10,000 for bereavement suffered by the parents
and the sum of $1,783.19 for funeral expenses.
Testimony at the hearing revealed that Sonny Hall was a severely retarded
individual who was unable to speak well or feed and clothe himself. He was
small of stature, hirsute, and needed constant care. Sonny was placed in Ward
14, which housed approximately 59 patients.
On the day of the incident in question, the two aides on duty locked Sonny Hall
and three other patients in a sun porch next to the ward. The three other
patients were described as ?troublemakers,? and Sonny Hall required ?a lot of
care,? so the four of them were isolated while the two aides shaved the other
patients. There was no supervision of Sonny and his companions during their
41/2-hour seclusion on the sun porch.
It is a fundamental principle of law that negligence cannot create a cause of
action unless it is the proximate cause of the injury complained of. 13 M.J., Negligence, ?21.
The injury must have been the natural and probable consequence of the
W. VA.] REPORTS
STATE COURT OF CLAIMS 307
negligence, and it ought to have been foreseen in the light of the attending
circumstances. 13 M.J., Negligence, ?22. In the case, the evidence indicates a high degree
of foreseeability, especially the testimony regarding Arnold Shinaberry, the
perpetrator of the crime. A hospital aide described Shinaberry as oftentimes
causing disturbances. When such a person is left locked up with others for a
long period of time with absolutely no supervision, it is reasonably
foreseeable that some harm could occur to a patient such as Sonny Hall, who was
unable to take care of himself.
The Court finds from the record that the respondent failed to exercise
reasonable care for the safety of the decedent, and that its failure
proximately caused his injury and subsequent death.
Accordingly, the Court makes an award in the sum of $10,000.00 plus $1,783.19
for funeral expenses, for a total award of $11,783.19.
Award of $11,783.19.
Opinion issued December 7, 1982
HENRY ELDEN & ASSOCIATES
vs.
DEPARTMENT OF HEALTH and
DEPARTMENT OF FINANCE AND ADMINISTRATION
(CC-79-367)
Michael T. Chaney, Attorney at Law, Kay, Casto & Chaney, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant seeks $63,000.00 from the respondent for architectural work
performed for the Fairmont Emergency Hospital in Fairmont, West Virginia.
By contract with the Department of Public Institutions, dated October 16, 1972,
the claimant was to furnish archi
308 REPORTS
STATE COURT OF CLAIMS [W. VA.
tectural services for the construction
and renovation of the Fairmont Emergency Hospital. A decision was made later
not to renovate the existing facilities, but to build a new facility. The first
and second appropriations of funds by the Legislature were not sufficient, and
the building was completed as far as possible in April 1976. The claimant was
paid all compensation due him under his contract and the subsequent change
orders.
In January 1977, the Legislature appropriated $1,500,000.00 to complete the
work on the hospital. These funds became available on July 1, 1977. Also on
July 1, 1977, the State Department of Health came into being, consolidating
certain other departments, including the Department of Public Institutions. A
search committee was formed to find and recommend someone to be the director of
the new department. Dr. Charles Andrews of the Medical School of West Virginia
University was named Acting Director.
The record indicates that the claimant actively pursued his employment to
complete the project. He testified that he was in constant contact with Blake
Boggess, the administrator of the hospital; that he had met with Dr. Andrews
and told him what was necessary to complete the building; and that Blake
Boggess had contacted his organization and told them ?to proceed to complete
the drawings for the finalization of the building.? The claimant further stated
that he then submitted plans and specifications to Blake Boggess.
Claimant stated that he received an agreement from Blake Boggess covering the
work to be done, which he signed and returned. However, claimant never received
an approved and executed copy.
Blake Boggess testified that he met with Dr. Andrews in late July of 1977; that
Jane Stout, Acting Director of the Division of Hospitals, and Keith Swarny,
assistant to Mr. Boggess, were present; and that the reason for the meeting was
to make Dr. Andrews aware of the status of the hospital. Mr. Boggess stated
that Dr. Andrews instructed him ?to proceed to draw up the initiating documents
to get the project under way.? He talked with the claimant and his son and
W. VA.]
REPORTS STATE COURT OF CLAIMS 309
instructed them to proceed with the
project. Mr. Swarny, using an old purchase order as a guide, prepared the
purchase order signed by the claimant. After being initialed by Boggess, it was
forwarded to Charleston. Mr. Boggess stated that his authority ended when he
sent the requisition to the central office, that ?the final authority would
have been with the Director of the Health Department,? and that ?we wanted to
be ready to go with the project when the final approval came through.?
Jane Stout testified that she met often with Dr. Andrews, and that she had
attended the meeting with Blake Boggess and had the impression that Dr. Andrews
gave Blake Boggess permission ?to give Henry Elden the go-ahead to write the
plans.? In the course of her testimony, she was asked:
Q ?I take it from that that you mean you had the general
impression that Dr. Andrews may have authorized Blake Boggess to go ahead??
A ?Well, mainly, because Henry Elden did go ahead after that meeting and we had
the plans that he wrote.?
Dr. Andrews testified that he had met with the claimant on three occasions;
that he was aware that the hospital was not completed; and that claimant had
been the architect. He testified that he probably met with Blake Boggess, but
doubted that he told him to proceed. He stated, ?. . .1 may have discussed it but I don?t think I would have told anybody to
proceed on the building without contracts and procedures and things you go
through to do it.? He did not authorize the claimant to proceed, but decided it
could wait for the director to determine what he was going to do with the
building.
Dr. George Pickett was appointed Director of the State Health Department and
commenced his duties in September 1977. Upon assuming his duties, he visited
all of the State institutions. Dr. Pickett testified that, during the interim
prior to his appointment, Dr. Andrews made the decisions that had to be made;
decisions involving policy, or the issues were postponed. When Dr. Pickett
visited Fairmont Emergency
310 REPORTS
STATE COURT OF CLAIMS [W. VA.
Hospital, he found that the building
was in place but not finished. There was no heat and no floor coverings. One
elevator was working, and not all rooms had toilet facilities. Doors were not
hung. It was not a functional building. He stated, ?. . .There were no visible programs that indicated that
there was any kind of planning that I could find anywhere in the files that
told me what the facility was to be.? A determination was made to establish a
primary general hospital. Proposals were solicited from architects for making
necessary corrections, design changes, and construction changes to bring it
into compliance with this purpose. The claimant was among those invited to
submit proposals.
Dr. Pickett further stated that, as a result of his investigation, he was not
able to find any type of directive that could be construed as a direction from
Dr. Andrews or the Health Department to proceed with any kind of obligation
with the claimant.
W.Y.K. Associates of Clarksburg received the contract for the exterior work,
and L. D. Schmidt and Son of Fairmont completed the interior plans.
The claimant contends that there was no substantial difference between his
plans and the plans used by the architects selected in the completion of the
hospital, and that he is entitled to be compensated for his plans. The
respondent contends that there were substantial changes made which were
necessary to complete the building for its designated use.
Daniel R. Smithson, Staff Engineer for the Department of Health, stated, ?The
things we did may not significantly change a building to someone that?s not
familiar with construction .
basically, the building looked the same . . . the building was designed . . . for a program that did not fit our need . . . we reviewed these drawings and reviewed the . . . specifications
? ? set forth by Medicare and Medicaid and we attempted to
bring the building as close as possible in conformity with these codes.?
Certain areas were eliminated, walls were changed, room sizes varied, and
omitted fireproofing was completed. The
W. VA.]
REPORTS STATE COURT OF CLAIMS 311
respondent relied on the parties as
designated to complete the building, and, if the successful architects did, in
fact, use the work of the claimant, it would be a matter between the
architects.
The record establishes that the claimant had performed services for many of the
various State departments as well as federal agencies. Claimant was familiar
with the contract procedures necessary before employment is insured. He knew
that it was necessary for the spending agency to initiate the contract which
then had to be approved by the Department of Finance and Administration,
followed by approval of the Attorney General as to its form. This was not done.
Miles Dean, who at the time was Director of Finance and Administration,
testified that no contract was submitted to his Department employing the
claimant to complete the hospital work. Daniel R. Smithson, the Staff Engineer
for the Department of Health, testified that he had no instructions from Dr.
Andrews or Dr. Pickett to work with the claimant on the project.
Since the claimant had no contract with the respondent, the Court denies the
claim.
Claim disallowed.
Opinion issued December 7, 1982
TOMMY KINDER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-11O)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was originally filed in the name of Eva Kinder, but when the
testimony revealed that the automobile, a 1981 Chevrolet Chevette, was titled
in the name of claimant?s hus
312 REPORTS
STATE COURT OF CLAIMS [W. VA.
band, Tommy Kinder, the Court on its
own motion amended the claim to reflect the proper party.
On April 2, 1982, Mrs. Kinder was driving her husband?s automobile on a
secondary road off Route 119 in Boone County, West Virginia. At about 7:30 that
evening, the car struck a pothole. The estimate for repairs to the car was
$217.92. Mrs. Kinder testified that she had previously observed potholes in
this road. She said that there were so many potholes ?it?s like driving on an
obstacle course.? She had not made any complaints to respondent concerning the
condition of the road. Claimant testified that he had on several occasions
mentioned the road condition to people in the Department of Highways garage at
Madison, West Virginia, but no action was taken.
The State is neither an insurer nor guarantor of the safety of persons
travelling on its roadways. Adkins v.
Sims, 130 W.Va. 645 (1947). For
negligence of the respondent to be shown, proof of notice of the defect is
required. Davis Auto Parts v. Dept. of Highways, 12 Ct.Cl. 31 (1977). In this case, claimant testified
that he had reported the road condition. The Court believes, however, that the
prior knowledge of claimant and his wife concerning the road condition, makes
them likewise negligent. Under the doctrine of comparative negligence, the
Court is of the opinion that the claimant?s negligence was equal to or greater
than the respondent?s and disallows the claim.
Claim disallowed.
Opinion issued December 7, 1982
OHIO VALLEY MEDICAL CENTER, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-276)
John L. Bremer, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings.
W. VA.]
REPORTS STATE COURT OF CLAIMS 313
The claimant seeks payment for
services furnished to respondent?s West Virginia Penitentiary in the amount of
$22,614.68.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
The Court finds that this claim should, in equity and good conscience, be paid,
but an award cannot be made, based on the decision in Airkem Sales and Service, et al. v. Department of
Mental Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued December 7, 1982
CATHERINE PASCERI
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-186)
Christine Hedges, Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
During the year 1976, the respondent engaged Lang Brothers Construction Company
to construct the South Clarksburg By-Pass, W. Va. Route 97. Incident to that
project, the contractor conducted blasting operations. Claimant, alleges that
the blasting performed by the respondent?s contractor caused the brick walls
adjacent to her driveway to collapse and the front steps to separate from her
house necessitating repairs in the amount of $1,882.60.
Claimant?s witness Delores Terango testified that she observed damage claimed
after the blasting.
314 REPORTS
STATE COURT OF CLAIMS [W. VA.
Ronald Smith, Jr., District
Maintenance Engineer for respondent, testified that blasting operations were
performed at approximately 500 feet from claimant?s property at the closest
point. Blasting operations also were performed at distances of approximately
1500 feet from claimant?s property.
Glenn R. Sherman, a geologist with respondent?s Materials Control, Soils and
Testing Division, testified that he had examined the blasting data and seismic
records maintained by Vibra-tec, a consulting firm hired by contractors to
analyze and recommend blasting limits. From his observations of claimant?s
property, he concluded that the damage to claimant?s property was the result of
movement in the soil rather than a result of the blasting operations. He
contended that the drainage of water behind the walls adjacent to the driveway
was the cause of the movement of the soil which occurred.
From the record in this claim it is undisputed that an independent contractor
performed the blasting alleged to be the proximate cause of the damages to claimant?s
property. The general rule is that an employer of an independent contractor is
not liable for torts committed by an independent contractor. However, an
exception to the general rule of non-liability is generally recognized in the
case of inherently or intrinsically dangerous work. Moore v. Department of Highways, 13 Ct.Cl. 148 (1980). It is held that blasting
operations are not so intrinscally dangerous as to render an employer liable
for the negligent acts of an independent contractor where the blasting is done in a barren, rural section,
ar in a mountainous area far removed from human habitation. (Emphasis supplied.) See 31 Am. Jur. 2d Explosions and Explosives ?43. Whether the work which produces the vibrations
sufficient to cause damage or injury is or is not so intrinsically dangerous as
to render an employer liable for the tort of an independent contractor depends
upon the circumstances. The Court is of the opinion that the exception to the
general rule of non-liability is not applicable to the facts of this claim.
Accordingly, the Court hereby disallows the claim.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 315
Opinion issued December 7, 1982
RICHARD L. SARGENT
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-98)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
Claimant seeks compensation in the amount of $43.45 for damage to a 1978 Datsun
automobile sustained when the car struck a pothole on the northbound lane of
U.S. Route 119 in Kanawha County, West Virginia, on March 11, 1982. There was
rain at the time of the incident, and claimant testified he did not see the
pothole because it was filled with water. He also stated that he travelled the
road about twice a week, and did not remember seeing the pothole.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
State to be found liable, it must first have had either actual or constructive
notice of the defect in the roadway. Since there was no proof in this case that
the State had notice of the defect, the claim must be denied.
Claim disallowed.
Opinion issued December 7, 1982
ROBERT C. SCHUMACHER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-55)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim is for damage to claimant?s automobile in the amount of $221.02.
Claimant?s son was driving the car on January 5, 1982, He was making a
right-hand turn from Hickory Road onto State Route 214 in Charleston, when the
316 REPORTS
STATE COURT OF CLAIMS [W. VA.
vehicle struck a pothole. The right
front and rear tires were ruined, both rims bent, one beyond repair, and the
front end went out of alignment.
Claimant?s son testified that he travelled this route about once a week, but
had not noticed the hole before. There was no oncoming traffic as he made the
turn. The hole was located on the berm next to the road. It was not visible
looking over the hood of the car, and, according to claimant?s son, he thought
he was on the road.
The berm or shoulder of a highway must be maintained in a reasonably safe
condition for use when the occasion requires, and liability may ensue when a
motorist is forced onto the berm in an emergency or otherwise necessarily uses
the berm of the highway. 39 Am. Jur. 2d Highways,
Streets, and Bridges ?488. A pothole
approximately eight inches deep existed along the berm. The Court cannot
conclude however, that claimant?s son was forced onto the berm or necessarily
used it. It appears that claimant?s son was guilty of negligence which equalled
or exceeded any negligence of which respondent may be guilty. The claim must be
denied. Sweda v. Dept. of Highways, 13 Ct.Cl. 249 (1980).
Claim disallowed.
Opinion issued December 7, 1982
BERTIE GIBBS THOMAS
and CAROLYN THOMAS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-163)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimants seek compensation in the amount of $300.38 for damages to a 1981
Ford. Bertie Gibbs Thomas testified that she was driving on Route 60 in Belle,
West Virginia, on June
W. VA.]
REPORTS STATE COURT OF CLAIMS 317
16, 1982, at about 11:20 p.m., when
she apparently struck a pothole and an exposed piece of metal reinforcement.
The right front and rear wheels were bent and the tires were ruined. She also
stated that she had driven the road at least twice a day for a number of years
and was aware of the bumpy condition of the road. She had never made a
complaint about the road?s condition prior to the accident.
The State is neither an insurer nor grantor of the safety of persons travelling
on its highways. Adkins v. Sims, 130 W.Va. 645 (1947). For the negligence of the
respondent to be shown, proof of notice of the defect is required. Davis Auto Parts v. Dept. of Highways, 12 Ct.Cl. 31(1977). The Court believes that claimant,
with her prior knowledge of the road?s condition, was negligent and that this
negligence was equal to or greater than that of respondent. Under the doctrine
of comparative negligence, the Court disallows the claim.
Claim disallowed.
Opinion issued December 7, 1982
BOB E. WILLIS
and RAGENE WILLIS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-100)
Claimants appeared in person.
Nancy J. Miff, Attorney at Law, for respondent.
PER CURIAM:
This claim was originally filed in the name of Bob E. Willis.
When testimony revealed that the damaged automobile, a
1981 Ford was titled in the joint names of the claimant and
his wife, Ragene Willis, the Court on its own motion joined
Ragene Willis as an additional claimant.
On March 21, 1982, at approximately 10:30 p.m., claimants?
318 REPORTS
STATE COURT OF CLAIMS [W. VA.
automobile struck a pothole on Route
119 at Hernshaw, West Virginia. Damage to the automobile amounted to $119.38.
Mr. Willis testified that he travelled the road about once a month and had
never seen the pothole.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). In order
for the State to be liable, it must first have had either actual or
constructive notice of the defect in the roadway. Since there was no proof in
this case that the State had notice of the defect, the claim must be denied.
Claim disallowed.
Opinion issued December 16, 1982
MARGARET GRAFF
vs.
BOARD OF REGENTS
(CC?82-2 16)
Russell M. Claw yes, Jr., Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This case was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer and Amended Answer.
Claimant received a promotion to the position of Senior Staff Nurse at West
Virginia University Hospital in November of 1980. The promotion entitled her to
a pay increase. Due to clerical error, she did not receive that increase from
November 1981 through May 1982. In its Amended Answer, the respondent admits
the validity of the claim and that respondent is liable to the claimant for the
sum of $1,096.50.
The Court makes an award to the claimant in the amount of $1,096.50.
Award of $1,096.50.
W. VA.1
REPORTS STATE COURT OF CLAIMS 319
Opinion issued December 16, 1982
TEDDY KEIFFER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 168)
Steven L. Miller, Attorney at Law, for claimant.
Nancy J. Aliff and Matthew H.
Fair, Attorneys at Law, for
respondent.
PER CURIAM:
On or about September 10, 1980, claimant was riding his 1977 Honda motorcycle
on West Virginia Route 16 between Dixie and Smithers, West Virginia. Claimant
alleges that respondent?s negligent maintenance of the road caused claimant to
lose control of his motorcycle. He claims $3,072.67 in damages to the
motorcycle, medical bills, lost wages and consequential damages of $802.50.
Claimant testified that he crested a hill, then entered an S-shaped turn. He
was going into a left-hand turn when he encountered gravel on the road.
Claimant stated that he reported his accident to the supervisor of respondent?s
road crew which was working in the area. He was told that the road crew lacked
the proper machine to remove the gravel from the road. The gravel had been used
to build up the berm alongside the road. Claimant stated that there were no
signs warning of the condition.
From the record in this case, the Court is of the opinion that a hazardous
condition existed on the roadway and that the failure of the respondent to
place any devices warning the travelling public was negligence. The Court has
previously held that a failure to warn the public of a hazardous condition
constitutes negligence. See Pullen v.
Dept. of Highways, 13 Ct.Cl. 278
(1980); Porter field v. Dept. of Highways,
13 Ct.Cl. 297 (1980). The Court finds that such negligence
was the proximate cause of the claimant?s injuries and damages and,
accordingly, makes an award to the claimant in the amount
320 REPORTS
STATE COURT OF CLAIMS [W. VA.
of $3,557.14. This award is based on
$3,113.14 in repair bills, $103.00 in medical bills, and personal property
damage and lost wages in the amount of $341.00.
Award of $3,557.14.
Opinion issued December 16, 1982
LOIS McELWEE MEMORIAL CLINIC, ET AL.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-299)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These claims were submitted for decision upon the pleadings. The claimants seek
payment for various goods and services
furnished by the respondent as follows:
Claim No. Claims Against Anthony
Center Amount
CC-82-299 Lois McElwee Memorial Clinic
$ 140.00 CC-82-284 Physicians Fee Office $2,773.00
Claims Against West Virginia
Claim No. Prison for Women Amount
CC-82-297 Chandra P. Sharma, M.D.,
Inc. $
250.00 CC-82-286 Mario C. Ramas, M.D. $ 110.00
The respondent admits the validity and amounts of these claims, but further
alleges that sufficient funds were not available at the close of the fiscal
years in question from which the obligations could have been paid.
The Court finds that these claims should, in equity and good conscience, be paid,
but awards cannot be made, based on the decision in Airkem Sales and
Service, et al. v. Department of Mental Health, 8 Ct.Cl. 180 (1971).
Claims disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 321
Opinion issued December 16, 1982
REYNOLDS MEMORIAL HOSPITAL, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-2 12a)
REYNOLDS MEMORIAL HOSPITAL, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-212b)
John T. Madden and B. Michael
Whorton, Attorneys at Law, for
claimant.
Henry C. Bias, Jr., Deputy Attorney General for respondent. PER CURIAM:
The above claims against the Department of Corrections, submitted upon the
pleadings by agreement of the parties, have been consolidated by the Court for
determination.
Claimant provided services to ill inmates of the West Virginia State
Penitentiary for a period of one fiscal year divided into quarters for payment
purposes. These claims arose because of an agreement made by the hospital and
Warden Bordenkircher regarding a discount to the State of 10 per cent, to be applied
to the last three quarters of the fiscal year. This agreement was made without
following mandatory purchasing procedures, but was entered into in good faith.
A letter from J. Matthew Foreman, Assistant Commissioner of the -Department of
Corrections, reveals that during the first quarter covered by the agreement,
the respondent paid for all invoiced services rendered by Reynolds, a total of
$31,564.81 (reflecting a $3,507.27 discount). During the second quarter, the
respondent paid all invoices for medical services in the sum of $32,247.13
(reflecting a $3,583.17 discount). In the third and final quarter of the
agreement, the respondent
322 REPORTS
STATE COURT OF CLAIMS [W. VA.
lacked funds to pay for any services
provided by claimant, and was not, therefore, entitled to a discount. The total
of services provided during this period was $63,873.86.
In addition to the medical services, the claimant provided 4,256 meals at a
cost of $24,216.64. The respondent made no payment for the meals.
The respondent accepts as a valid obligation to the claimant the amount of
$88,090.50, which represents the unpaid medical services ($63,873.86) and the
unpaid meal services ($24,216.64). Because no payment was made during the final
quarter, no discount is involved. The respondent contends, however, that
because the agreement was followed for the first two quarters, the respondent
does not owe the $7,090.44 discounted during that period.
The total amount claimed by claimant in these two cases is $95,180.94. The
respondent accepts as valid all but the $7,090.44 discount. By individual
claim, the respondent admits as true and valid all of Claim CC-82-212a
($79,281.45) and part of Claim CC-82-212b ($8,809.05), for a total of
$88,090.50, stating also that sufficient funds were not available in its
appropriation for that fiscal year from which the obligation could have been
paid.
From the evidence, the Court determines that the agreement is not a valid
contract inasmuch as the respondent?s representative signed the document
without authority to do so. Therefore, the claimant is entitled to the full
reasonable value of its services, viz.,
the sum of $95,180.94, and the
respondent is not entitled to the benefit of the discount which it would have
received had it made timely payment of the obligations.
While these claims are ones which in equity and good conscience should be paid,
awards cannot be made, based on our decision in Airkem Sales and Service, et
al. v. Dept. of Mental
Health, 8 Ct.Cl. 180 (1971).
Claims disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 323
Opinion issued December 16, 1982
VELMA SUTTON
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-249)
Harold S. Yost, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimant seeks an award in the sum of $2,969.36 for damages to personal
property stored in a garage on property located near the Meadowbrook Exit of
1-79 in Harrison County, West Virginia. Claimant alleges that flooding, which
occurred from May 31 through June 1, 1980, resulted from water backed up from a
culvert which was constructed for Barnetts Run to flow beneath 1-79 into
Simpson Creek.
Claimant alleges respondent constructed an inadequate culvert beneath the
interstate resulting in the flooding of the garage and damage to her personal
property. Respondent contends that the flooding occurred as the result of a
heavy rainfall and that construction on the hillside above the property where
vegetation was removed contributed to the flooding. Respondent also contends
that the culvert under 1-79 was adequate.
Claimant?s son, John T. Sutton, testified that he observed the flooding on the
night of May 31, 1980, at approximately 10:00 p.m. By 12:30 am. of June 1,
1980, the garage had six to seven feet of water inside. He also testified that
Barnetts Run was overflowing and the water was above the top of the culvert.
The claimant testified that she had not experienced any water problems from the
time of the construction of 1-79 until this flood.
Randolph Epperly, Jr., a design engineer for the respondent, testified that he
made a study of the drainage area affecting Barnetts Run. His calculations for
the culvert under the interstate and the Simpson Creek channel indicated that
the 96-inch culvert was sufficient to carry the water in the area.
324 REPORTS
STATE COURT OF CLAIMS [W. VA.
The computations were based upon a
ten-year flood frequency, a 25-year flood frequency, a 50-year flood frequency
and a 200-year flood frequency. The culvert was designed to carry a 25-year
storm without any problems. In answer to a question from Judge Ruley as to the
effect of the culvert acting as a dam, Mr. Epperly testified that ?the fact
that the highway field was there would not have decreased or lowered the amount
or depth of flooding back in the highway fill. It would just slow down the
amount of time it would take for the water to flow out of the 96-inch pipe. . . . It?s my opinion there was a very large amount of
rainfall in the area, plus the fact that the mall had disturbed some of the
area which would have naturally increased the amount of flow and that these
conditions combined and caused an enormous amount of water to flow into this
area.?
From the record in this claim the Court finds that an unusually heavy storm
occurred; that Barnett?s Run overflowed its banks; that the 96-inch culvert
constructed beneath 1-79 did, in fact, prevent the flow of water from Barnetts
Run into Simpson Creek; and that the area flooded as a result of a combination
of these circumstances. The evidence established that the value of personal
property lost was $2,969.36 and the Court makes an award to the claimant in the
amount of
$2,969.36.
Award of $2,969.36.
Opinion issued December 16, 1982
UTAH VALLEY HOSPITAL
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-300)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for
respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings. The claimant seeks
payment for medical services provided to George R. Keller who was being
extradicted to West Virginia.
W. VA.]
REPORTS STATE COURT OF CLAIMS 325
A bill for medical services in the
amount of $1,825.16 was included with the extradition papers.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
The Court finds that this claim should, in equity and good conscience, be paid,
but an award cannot be made, based on the decision in Airkem Sales and Service, et al. v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued December 20, 1982
AZILE DEAN, INDIVIDUALLY,
AND AS EXECUTRIX OF THE ESTATE OF
VIRGIL DEAN, DECEASED
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-632)
Hazel A. Straub, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent. GARDEN, JUDGE:
On January 31, 1979, at approximately 1:30 p.m., Virgil Dean was driving on
Route 119, between Danville and Rock Creek, in Boone County, West Virginia. A
portion of shale rock broke off of the side of the mountain and struck Mr.
Dean?s 1971 Chevrolet truck. Mr. Dean sustained a cerebral concussion, neck
strain and multiple contusions of the chest. He was hospitalized until February
6, 1979. Mr. Dean died on September 5, 1979, during heart surgery. Azile Dean,
widow of Virgil Dean, maintains this action on her behalf and as executrix of
her husband?s estate. She seeks an award of $50,000.00, based on respondent?s
allegedly negligent maintenance of Route 119.
326 REPORTS
STATE COURT OF CLAIMS [W. VA.
Claimant testified that her husband
had observed loose rock at the accident site, and told her if it fell, it would
kill someone. This occurred four to six weeks before the accident. Claimant
further stated that her husband left the house one day to notify the respondent
of this danger, but could not say whether, or to whom, he talked. She said that
Mr. Dean told their nephew, Ricky Daniel Dean, about the loose rock. Ricky Dean
was then employed by the respondent.
Ricky Dean testified that he informed James Anderson and Gary Keys, both
employees of the respondent, about the condition of the rock. These reports
were made as part of Mr. Dean?s daily inspector?s report, which was required by
his job. This was approximately five weeks before the accident, and according
to Mr. Dean, no action was taken as a result of his report.
James Anderson stated that he did not remember Ricky Dean reporting a hazardous
rock condition to him. Gary Keys said that he checked the daily inspector?s
reports for November and December of 1978 and found no information about the
rock area in question. Frank Ball, who was the Boone County Road Maintenance
Supervisor in 1979, testified for respondent. He stated that the portion of
Route 119 where the accident occurred had not been subject to rockfalls, just
shale debris falling into the ditch line. Mr. Ball said that it was ?very
unusual? for a large piece of shale rock to break off, and that this had never
happened in this area. He also said that he travelled that portion of Route 119
every day that he worked and had never seen anything unusual with the hillside
at the accident site.
A careful review of the facts as established by the record indicates to the
Court that the respondent was not negligent in its maintenance of Route 119.
This particular section of the road was not known to be one where falling
rocks, of the size which was encountered by Virgil Dean, usually fell. Manning v. Dept. of Highways, 13 Ct.Cl. 275 (1980). The Court is of the opinion that
the claimant has failed to establish by a preponderance of the evidence that
the respondent knew or should have known that a dangerous condition existed on
Route 119.
W. VA.]
REPORTS STATE COURT OF CLAIMS 327
The law of West Virginia is well
established that the State is neither an insurer nor a guarantor of the safety
of persons travelling on its highways. Adkins
v. Sims, 130 W.Va. 645, 46 S.E.2d81
(1947).
As the evidence does not establish negligence on the part of the respondent,
the claim must be denied.
Claim disallowed.
Opinion issued December 20, 1982
BARBARA HAYNES
vs.
BOARD OF REGENTS
(CC-78-13)
Thomas D. Ireland, Attorney at Law, for claimant.
Frank Ellison, Deputy Attorney General, for respondent.
GARDEN, JUDGE:
Claimant seeks $25,000.00, alleging that the negligence of respondent?s
employee resulted in claimant sustaining a broken finger, which has impaired
her work as a pianist and writer. Claimant was a patient at the West Virginia
Medical Center in Morgantown on February 4, 1976, when the injury occurred. She
was being transported in a wheelchair to the shower by a staff nurse. Her gown
became disarrayed, and in an effort to cover herself, claimant?s left middle
finger was caught in the spokes of the wheel chair, causing the fracture.
Claimant alleges that she had a permanent loss of flexion in the finger, due to
the fracture.
Claimant testified that she was feeling dizzy and was being pushed at a ?high
rate of speed.? There was conflicting testimony as to whether claimant wore a
hospital gown or her own clothing. When she reached to cover herself, her
finger was caught in the wheelchair. As a result of the injury, claimant lost
the ability to play the piano well, and was also unable to speed type, which
slowed her progress on a novel she was writing.
Nurse Pixier testified that she was pushing the wheelchair
328 REPORTS STATE
COURT OF CLAIMS [W. VA.
at a normal rate of speed, when she noticed Mrs. Haynes? robe slipping. She had
begun to stop the wheelchair when claimant?s finger became entangled in the
spokes.
The Court, in order to allow a recovery in this claim, must be satisfied by a
preponderance of the evidence that respondent?s negligence proximately caused
claimant?s injury. The evidence does not indicate negligence. There is no
evidence, other than claimant?s testimony, that she was being pushed at an
unreasonably high rate of speed. Claimant stated, ?I was dizzy. I felt heavy, I
didn?t feel like myself, .
. . and she pushed me very fast. . .
From the record, the Court finds that the
claimant has failed to prove by a preponderance of the evidence that the
negligence of the respondent caused her injury and disallows her claim.
Claim disallowed.
Ruley, J., did not participate in the hearing or decision of this claim.
Opinion issued December 20, 1982
JOHN MULLENAX, ADMINISTRATOR
OF THE ESTATE OF EDITH MULLENAX
vs.
DEPARTMENT OF AGRICULTURE
(CC?78- 157)
George I. Sponaugle, II, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
On July 29, 1976, the claimant and his wife, Edith Mullenax, attended the 34th
Annual West Virginia Poultry Convention and Festival in Moorefield, Hardy
County, West Virginia. At the conclusion of the festivities, Mrs. Mullanax
decided to find the ladies room. Mrs. Mullenax proceeded approximately 75 feet
down a dimly lit corridor of the school building where the festival was held.
She opened a door, thinking it the entrance to the ladies room, but it was
actually the stairway to the base-
W. VA.] REPORTS
STATE COURT OF CLAIMS 329
ment. Mrs. Mullenax fell 12 to 15 feet down the stairs to the floor below, sustaining
severe injuries, including two broken ankles, broken ribs, and a broken wrist
and a fractured cheekbone. There is nothing in the record to indicate that
these injuries were the cause of her death. The claimant contends that the
respondent is liable for damages arising out of Mrs. Mullen ax?s fall under an
agency theory, because the respondent contributes funds to the West Virginia
Poultry Association, which sponsored the event. Claimant seeks $100,000.00.
The testimony established that the respondent contributed $400.00 to the West
Virginia Poultry Association. According to Robert E. Ludwig, President of the
Hardy County Poultry Association in 1976, the money was ?just a grant to assist
us in our general program of furthering the poultry industry in Hardy County,
West Virginia.? He further stated that the West Virginia Poultry Association is
?in no way whatever? under respondent?s supervision. Claimant?s witness, Ralph
Hitt, an employee of respondent, stated that respondent neither controls nor
supervises the Poultry Association. Earl K. Kelley, also an employee of
respondent, stated that the respondent has given funds to the Poultry
Association in varying amounts since 1970, but that there is no requirement
that the money be expended in any particular manner. The sums have ranged from
$50.00 to $1,000.00.
The Court is of the opinion that these limited financial contributions are
insufficient to establish an agency relationship between the respondent and the
Poultry Association. Claimant in his brief argues that all that is necessary to
establish an agency relationship is the right or potential right of the
principal to control the agent. Claimant alleges that respondent?s financial
contributions coupled with respondent?s sponsorship of the Poultry Convention
is sufficient to establish a potential right to control. The Court cannot agree
with this contention. We do not find any evidence that the respondent held
itself out as being a sponsor of the Poultry Convention. The contributions made
by the respondent were simply that ? contributions.
There was no actual or potential control inolved. Cross-examination of Mr.
Ludwig elicited the following exchange:
330 REPORTS STATE
COURT OF CLAIMS [W. VA.
?Q. Mr. Ludwig, did the West Virginia Department of Agriculture
ever give you instructions as to how the activities of the Poultry Association
were to be carried out?
A. No way whatever. Even if they would have, we wouldn?t have considered them
in any way because it was not their function.?
The Court must therefore disallow the claim.
Claim disallowed.
Opinion issued December 20,
1982
FRANK A. PAYNE
vs.
DEPARTMENT OF HIGHWAYS
(CC?79-719)
John L. Boettner, Jr., Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
Claimant was driving his 1975 Chevrolet van on Route 119, at Elkview, Kanawha
County, West Virginia, on October 7, 1979. At approximately 1:00 a.m., claimant lost control
of the vehicle and slid into a ditch line. The van, valued at $3,475.00, was a
complete loss. Claimant alleges that respondent, in cleaning the ditch line
earlier that day, had negligently left mud on the road, which caused claimant?s
vehicle to skid, resulting in the accident.
Respondent?s witness, Trooper M. J. Smith, an employee of the West Virginia
Department of Public Safety, testified that he investigated the accident. He
stated that he did not see mud on the road, and that the claimant had been
drinking. Billy D. Ray, the foreman of the workcrew which had worked on the
ditch line on October 6, 1979, stated that to his knowledge there was not a
great deal of dirt left in the road. Mr. Ray stated that the road was cleaned
after pulling the ditch line
W. VA.]
REPORTS STATE COURT OF CLAIMS 331
and then fly ash was put on the road
to minimize danger to motorists.
Without a positive showing of negligence on the part of the respondent, this
case is governed by the well settled principle of Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947), cited in Parsons v. State Road Comm?n., 8 Ct.Cl. 35 (1969), that the State is not a guarantor
of the safety of travelers and the user of the highway travels at his own risk.
The duty of the State in the maintenance of highways is one of reasonable care
and diligence under all circumstances. The evidence in this case fails to
establish a lack of reasonable care and diligence. See McCarthy v. Dept. of Highways, 12 Ct.Cl. 139 (1978). Accordingly, the Court denies the
claim.
Claim disallowed.
Opinion issued January 21, 1983
MARY LYNN COOK
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-82-157)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
At a pre-trial conference and a hearing on respondent?s motion to dismiss, the
claimant outlined the basis of her claim. Claimant resided in apartment 2 on
the first floor of 1522 East Lee Street, Charleston, West Virginia, and was employed
by the West Virginia State Welfare Department at a salary of $525.00 per month.
Prior to October 1977, claimant contends certain activities commenced such as
loud noises, music playing late at night and people ?stomping in and out of the
house at all hours of the night up and down the stairs.? Her loss of sleep
caused her to quit her job. She complained to her landlady, Mrs. Angie Ehle,
and later sued her for damages. She didn?t pursue the suit because she stated
the respondent should have stopped the ?activities.? Claimant also contends
that people in the neighboring property at 1520 East Lee Street caused
disturbances and spied on her which in addition to the
332 REPORTS
STATE COURT OF CLAIMS [W. VA.
activities where she resided finally
caused her to move in March of 1980. Claimant alleges that she complained to
?all police departments? including respondent.
Damages claimed include $25,074.40 as salary lost after she quit work,
$5,000.00 claimed for things done to her personal belongings, some of which she
was forced to sell, and $3,000.00 for a foot and leg injury received from a
fall while residing at 1307? Quarrier Street. She was injured when she caught
her foot in a hole in the back lawn and fell on the gravelled street. This fall
was apparently prior to the activities at 1522 East Lee Street. An additional
$20,000.00 is claimed for the death of her husband who died on June 13, 1979,
as a result of a fall from a window at the Union Mission.
The Court has carefully considered the statements made by the claimant and has
examined the numerous papers filed with the claim and finds that the damages
claimed by the claimant were not caused by any breach of duty by the respondent
which could be the basis of an award by the Court. Additionally, the Court
notes that the activities complained of occurred more than two years prior to
the filing of this claim and are barred by the statute of limitations. West
Virginia Code ?55-2-12. By statute, West Virginia Code ?14-2-21, this Court is
prohibited from hearing matters which are barred by law. Accordingly, the
respondent?s motion to dismiss is sustained and the claim is dismissed.
Claim dismissed.
Opinion issued January 24, 1983
THE CHESAPEAKE & POTOMAC
TELEPHONE COMPANY
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-81-302)
David Ogborn, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks payment of $7,591.93 in back charges for
W. VA.]
REPORTS STATE COURT OF CLAIMS 333
phone service at the Pipestem State
Park. These charges were incurred between August 2, 1975 and June 7, 1979. An inventory of the phone system at Pipestem
resulted in billing errors being discovered, and this claim resulted from the
adjusted bill which was presented to the respondent for the period in question.
During the construction of the Pipestem facility, the respondent entered into
negotiation with the claimant for installation of a telephone system.
Eventually, a dial 701 B PBX system was agreed upon. This equipment contains
P-33 selectors, which are a part of the dialing chain within the system, and
44-M power and common equipment, which drives the system. The telephone
equipment became operational in 1970.
On May 2 and 3, 1979, the claimant performed an inventory of the telephone
equipment at Pipestem. This was part of a periodic routine verification of
customer accounts, made to insure accurate billing. The inventory, which
consisted of physically identifying the equipment which was listed on an
account information record, resulted in the discovery of 23 billing errors. Of
these errors, three were billed or credited to the respondent?s account. Two
items were billed, the P-33 selectors and the 44-M common equipment, at a total
cost of $7,591.93. A credit of $221.95 was given for equipment which had been
billed, but was not present at Pipestem.
The Court is of the opinion that the evidence establishes that a contract for
telephone service existed between the claimant and respondent. The equipment
for which the claimant seeks compensation is an integral part of the 701 B PBX
system. James Humphreys, the engineer of the Pipestem telephone system,
testified that the system would not operate without the P-33 selectors and the
44-M common equipment. The respondent has received the use of this equipment;
to deny the claimant relief would unjustly enrich the State. The Court,
therefore, makes an award of $7,591.93.
Award of $7,591.93.
334 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued January 24, 1983
RONALD E. CYRUS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 196)
Claimant appeared in person.
Matthew H. Fair, Attorney at Law, for respondent. PER CURIAM:
The claimant?s vehicle, a 1975 Chevrolet Van, was damaged in an accident on
Route 3, Boone County, West Virginia, on October 17, 1980. The vehicle was a
total loss. The accident occurred when the vehicle went through water on the
road. The water extended across the pavement and was three or four inches deep.
James Smith, who was driving at the time, lost control of the vehicle and hit
an overhanging rock cliff. Claimant seeks an award of $4,500.00, $3,000.00 for
the van, $500.00 for injuries received, and $1,000.00 for lost wages.
The claimant testified that he had driven that road on many occasions and knew
that the road had flooded before, although never as much as on the night of the
accident. He indicated that the water came from a stopped up culvert alongside
the road.
The State is neither an insurer nor a guarantor of the safety of persors
travelling on its highways. Adkins v.
Sim.s, 130 W.Va. 645 (1947). For
negligence of the respondent to be shown, proof of notice of the defect in the
road is required. Davis Auto Parts v.
Dept. of Highways, 12 Ct.Cl. 31
(1977). In this case, there was no evidence that respondent knew or should have
known of the condition of the road. The Court must therefore disallow the
claim.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 335
Opinion issued January 24, 1983
JAMES DAVID HUTCHINSON
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-291)
James C. Lyons, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent. GARDEN, JUDGE:
Claimant lives on Route 97 between Pineville and Maysville in Wyoming County,
West Virginia. On May 1 and July 10, 1980, there were heavy rainstorms. On both
occasions claimant?s property received flood damage. Claimant contends that
respondent was negligent in maintaining Route 97; that respondent, in trying to
widen arid stabilize the road, filled in the ditch line and blocked the culvert
which drains the rain from the area of claimant?s property. Claimant seeks an
award of $2,475.00, the cost of restoring his property. Respondent contends
that severe weather conditions were, in part, responsible for claimant?s
damages. The other contributing factor was the existence of two private roads
across from claimant?s property from which dirt and rock washed down onto
claimant?s property.
Claimant?s father, Lonnie Hutchinson, testified that prior to May 1, 1980,
respondent?s employees had worked on Route 97. This work consisted of widening
the road so that it would be safer for truck usage. Mr. Hutchinson said that
red dog was used to widen the road and that in widening the road, the ditch
line was stopped. Mr. Hutchinson stated that he asked respondent to open a new
ditch, but this request was not complied with until after July 10, 1980.
Respondent?s witness, Bill Wilcox, who was the Wyoming County Road Supervisor
in respondent?s employ, testified that he visited claimant?s property on July
11, 1980. He stated that there was ?quite a bit of stone washed over on Mr.
Hutchinson?s property.? This stone was a crusher type stone which respon
336 REPORTS
STATE COURT OF CLAIMS [W. VA.
dent had not used in its work on Route
97. Mr. Wilcox stated that the heavy rains that had occurred the previous day
swept the stone off two private roads located above claimant?s property. Mr.
Wilcox also testified that his records showed that red dog was not hauled to
Route 97 until September 1980.
In order for the Court to make an award in this case, it must be satisfied that
the actions taken by respondent resulted in the damages alleged. The evidence
is in conflict as to the cause of the claimant?s damages. The Court cannot base
an award on speculation, and to make an award on the evidence presented would
be to speculate. There is no doubt that the claimant?s property was damaged,
but it cannot be said that this damage iesulted from negligence on the part of
the respondent. The Court must therefore deny the claim.
Claim disallowed.
Opinion issued January 24, 1983
L. R. LEWIS & B. L. LEWIS
vs.
DEPARTMENT OF FINANCE & ADMINISTRATION
AND DEPARTMENT OF WELFARE
(CC-82-235)
Louis H. Khourey, Attorney at Law, for claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondents. WALLACE,
JUDGE:
The claimants, who are husband and wife, own two real estate lots on Diamond
Street, Moundsville, West Virginia. By a June 24, 1975 letter, the claimants
were informed that the Department of Finance and Administration intended to
lease a building to be constructed on these lots from the claimants. The letter
stated that the lease would be for a term of ?approximately ten years.? At
$600.00 per month, the claimants obtained a loan for $42,000.00, with interest
at 9% per annum payable for ten years, to construct the building. The
Department of Welfare occupied the building from February 1,
W. VA.]
REPORTS STATE COURT OF CLAIMS 337
1976 to February 28, 1982. The
Department of Welfare, by letter dated January 27, 1982, exercised its option
to cancel the lease on 30 days? notice. The claimants allege that the doctrine
of equitable estoppel should be applied to prevent the respondents from
cancelling the lease. Claimants allege that they have sustained damages of
$28,200.00 because of the cancellation.
Mr. Lewis testified that he had been told by some State employee not to be
concerned about the cancellation provision, because ??the State of West
Virginia has never cancelled a lease.?? This statement and the statement in the
June 24, 1975 letter were taken in good faith by Mr. Lewis to mean that the
lease would not be cancelled before the end of the ten-year period. He was,
however, aware of the terms of the cancellation provision contained in the
lease agreement.
The evidence indicates that a contract to lease a building was entered into
between the claimant and the respondent Department of Finance and
Administration. The lease contained a cancellation provision which was clear on
its face. The parties to the agreement were aware of the terms of this
provision. The respondent Department of Finance and Administration cancelled
the lease with the required 30 days? notice. The Court must therefore find that
the terms of the contract were controlling and deny the claim.
Claim disallowed.
Opinion issued January 24, 1983
JAMES PACK & ELLA MAE PACK
vs.
DEPARTMENT OF HIGHWAYS
(CC?79-125)
Abishi C. Cunningham, Attorney at Law, for claimants. Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
Claimants are co-owners of a tract of land which fronts county route 83/2 at
Atwell Hollow, Bartley, McDowell County,
338 REPORTS
STATE COURT OF CLAIMS [W. VA.
West Virginia. The land was purchased
in July 1974, and claimants moved onto the property in 1975. Claimants allege
that the house and real estate have suffered water damage which resulted from
respondent?s negligent maintenance of the roadway and drainage system.
Claimants seek damages in the amount of $12,467.52.
County route 83/2, also called the Atwell Branch Road, is a gravel-based dirt
road, designated as a local service road, which is situated about 50 feet above
claimants? property. The claimants testified that when there was heavy rain,
the ditch line drainage system which runs alongside the road, became blocked by
rocks and other debris. The water then overflowed onto their property and
damaged their house. Mr. Pack testified that he had made numerous complaints to
respondent concerning this condition. He stated that respondent brought gravel
to lay on the road, but that the slope of the road caused the gravel to wash
down onto his property. Photos admitted into evidence show gullies, rock slides
and other evidence of erosion.
Mr. Pack testified that on at least nine occasions he has hired a bulldozer to
try to correct the damage to his driveway and yard. The driveway was not in
existence when claimants moved onto the property. Mr. Pack testified that he
had the driveway bulldozed to connect to county route 83/2. He stated that the
driveway crosses over a small portion of an adjoining landowner?s property
before exiting into county route 83/2.
Jesse H. Gravely, a District Engineer for Construction, employed by respondent,
testified that he had examined the Pack property. On the basis of his
examination, he believed the problem resulted from the construction of the
driveway. He stated:
?Well, if the bulldozer took out too much material at the foot of the slope
between the driveway and the State road, then that would tend to weaken the
support of the State road and, of course, it would slide down into the
driveway. That apparently is what has happened. The slope here is very, very
steep. The material is of a talus or rocky
W. VA.}
REPORTS STATE COURT OF CLAIMS 339
nature and when it gets, if you
undercut it, it will slide away and in at least two places this has brought
slides from the road down into the driveway where the driveway was too close to
the road itself.?
Mr. Gravely stated that a permit is required to connect a driveway to a State
road. The permit will be issued after the property owner submits a plan showing
that the driveway will be properly constructed, meeting drainage standards. No
such permit was issued to the claimants. Mr. Gravely disputed Mr. Pack?s
testimony that the driveway crossed over another landowner?s property.
From the record, the Court is of the opinion that the drainage problem was
caused in part by the respondent?s failure to keep the ditch line clear.
However, the Court feels that the claimant was also negligent in the
construction of the driveway and that this was the significant contributing
factor to the drainage problems. Applying the doctrine of comparative negligence,
the Court is of the opinion that the negligence of the claimant was equal to or
greater than that of the respondent and denies the claim.
Claim disallowed.
Opinion issued January 24, 1983
CLARENCE SHIFLET & FLORENCE
SHIFLET
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 13 1)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
The claimants seek an award of $697.36 to repair damage to their 1980 Plymouth
Volare automobile. The damage allegedly occurred driving on Gluck Run in Gilmer
County, West Vir
340 REPORTS STATE
COURT OF CLAIMS [W. VA.
ginia, which is where the claimants reside. They testified that respondent left
large rocks in the road, which is a dirt road, after a scraping operation. The
damage occurred sometime in March or April, 1982, and there was no specific
incident which caused it,
Ralph Marks, Gilmer County maintenance supervisor, testified that three-inch
and one and one-half-inch stone was used to fill holes in the road. He also
said that he viewed Gluck Run after receiving a call from claimants and saw no
rocks which were large enought\o damage a car.
Without a positive showing of negligence on the part of the respondent, this
case is governed by the well settled principle of Adkins v. Sims, 130 W.Va. 645 (1947) that the State is not a guarantor of the safety of
travelers, and the user of the highway travels at his own risk. The existence
of a defect in the roadway does not establish negligence per Se. The claimants
lived on Gluck Run and were aware of its condition.
The evidence in the record is not sufficient to establish such negligence on
the part of the respondent as to create liability for the claimants? damage.
Accordingly, the Court is of the opinion to and does disallow the claim.
Claim disallowed.
Opinion issued January 25, 1983
BLACK ROCK CONTRACTING, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-222)
Frederick L. Thomas, Jr., Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. GARDEN, JUDGE:
During 1971 Marble Cliff Quarries Company (Marble Cliff) contracted with the
respondent for construction of Project I-
W. VA.]
REPORTS STATE COURT OF CLAIMS 341
470-1 (8) (0), Ohio County, West
Virginia. The work on the project commenced on January 17, 1972. In the course
of construction, Black Rock Contracting, Inc., (Black Rock) acquired all of the
assets of Marble Cliff and agreed to perform the subject contract.
On or about May 11, 1974, a major slide occurred on the project through no
fault of Black Rock. As a result of the slide, the respondent shut down the
earthwork operation. During a meeting on June 13, 1974, respondent?s
representatives indicated to representatives of Black Rock that the contract
would be rescinded as the respondent did not have access to the funds needed to
correct the slide and complete the project. The respondent then notified Black
Rock by letter dated June 25, 1974, that the contract was ?mutually rescinded.?
As a direct and proximate result of the cancellation of the contract, Black
Rock incurred substantial costs and damages including loss of income on six
subcontracts in the amount of $294,354.04. Black Rock also incurred costs in
the settlement of litigation and payment of attorneys? fees in the amount of
$18,387.42 in a related legal action brought against Black Rock by the Village
of Bethlehem.
The first issue to be considered is whether or not Black Rock is entitled to
recover the loss of income on the six subcontracts. To determine this issue the
facts in the claim must be examined to first clarify whether the contract was
?mutually rescinded? or was unilaterally cancelled by the respondent. At the
first meeting which was held on June 13, 1974, Black Rock provided an estimate
for the slide correction in the amount of $10 million. Representatives of the
respondent indicated that funds were not available and that a study of the
method of slide correction would be necessary on the part of the respondent;
therefore, the respondent requested Black Rock to prepare to ?clean up? the
construction site and remove all of its equipment. Leo A. Vecellio, Sr.,
President of Vecellio and Grogan, Inc., of which Black Rock is a wholly owned
subsidiary, testified that at this meeting he understood the contract was
cancelled and that Black Rock would be compensated by supplemental agreements
for preparing the job site for
342 REPORTS
STATE COURT OF CLAIMS [W. VA.
studies by the respondent and for
moving out all of its equipment.
Supplemental agreements were thereafter entered into by Black Rock and the
respondent for such items as idle equipment, site preparations necessary for a
delay of the project, moving and storing materials already at the site, and
various and sundry other items. Some of those agreements refer to the ?mutual
rescission? of the project or the ?termination? of the project. Black Rock was
well aware at the time the agreements were made that the project was stopped.
These agreements were the only method whereby Black Rock could be paid for work
it performed on the project site. The respondent contends that the signing of
these agreements by Black Rock was a waiver of Black Rock?s right to recover
for losses sustained as a result of the termination of the contract.
Joseph S. Jones, the State Highway Engineer for the respondent during the
period in which this claim arose, testified that the project was stopped due to
the costs involved in correcting the slide and the delay necessary for the
respondent to perform design work to correct the slide. As to his comments made
at the June 13, 1974, meeting he stated, ?Then we . . . the last part of it, I said, ?Then we?ll get together.?
We did not terminate the contract, but stopped it right then. We said, ?there
are things we?d like to meet in the field with you to go over to get this in a
shape so that it will be in as good a condition as we can to leave it until
such time as a new contract was let.? ?It was after this meeting that the
respondent sent the letter using the phrase ?mutually rescinded? with reference
to the contract. Black Rock contends that the contract was unilaterally
cancelled while the respondent contends the contract was mutually rescinded.
It is clear under the evidence in this case that the project was stopped and
Black Rock?s contract was terminated or rescinded but the Court cannot conclude
that the recission was ?mutual.? Mutual connotes a meeting of the minds and it
does not appear that there was a meeting of the minds between the parties
respecting the termination of this contract. Al-
W. VA.]
REPORTS STATE COURT OF CLAIMS 343
though, as a practical matter the
respondent may have had no choice in the premises, it unilaterally terminated
the contract without fault on the part of Black Rock and Black Rock was damaged
as a result of the termination. The argument that Black Rock waived its rights
incident to the termination by executing supplemental agreements related to
closing the project is regarded as unmeritorious.
It is well established that a party to a contract who is prevented from
performing it through no fault of his own may recover as damages that profit
which he would have made upon full performance. 12 Am. Jur. Contracts ?386.
The parties have entered into a written stipulation to the effect that that sum
in this instance was $294,354.04.
The second item of damage claimed presents a more unusual question. It relates
to another Marble Cliff contract which was assigned to Black Rock. Under the
terms of the contract, Black Rock was to dispose of waste material from the
project in an area which the Town of Bethlehem intended to develop into a
municipal park. The fill material was not available to Black Rock when the
project was stopped. As a result, Black Rock was obliged to cancel its contract
with the Town of Bethlehem and later negotiated a settlement of its claim at a
cost of $18,387.42. The general rule is that attorneys? fees and expenses
incurred in litigation are not recoverable as an item of damages in an action ex contractu but
an exception to the rule exists where a breach of contract has forced a party
to maintain or defend a suit with a third person. Among the losses recoverable
in that instance may be the expenses of counsel fees, court costs and the
amount of a judgment. 5B M.J. Damages ?44. The agreement by and between Black Rock and the
Town of Bethlehem resulted in litigation as a direct result of the rescission
of Black Rock?s contract with the respondent. The Court, therefore, makes an
award to Black Rock in the amount of $18,387.42 for this portion of the claim.
Award of $312,741.46.
344 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued January 25, 1983
CITY OF OAK HILL
vs.
MUNICIPAL BOND COMMISSION
(CC-82-268)
Pat R. Hamilton, Attorney at Law, for respondent.
Michael G. Claqett, Deputy Attorney General, for respondent.
PER CURIAM:
This claim was submitted upon a written stipulation acknowledging liability on
the part of the respondent in the amount of $531.49 based on the following
facts.
The respondent acted as the agent of the claimant in the matter of issuing call
notices for the period covered by the claim. The respondent failed to issue
call notices for the years 1977, 1978, 1979, and 1980 and is therefore liable
to the claimant for the losses suffered as a result of the failure. The
claimant was required to pay $1,071.94 in additional interest to holders of
bonds that should have been retired, but saved $540.45 in total expenses by not
calling the bonds. The Court finds that the respondent is liable, and makes an
award to the claimant in the amount of $531.49.
Award of $531.49.
Opinion issued January 25, 1983
WILLIAM E. COY
vs.
DEPARTMENT OF HEALTH
(CC-82-204)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of $90.14 for repairs to the armature shaft of his
wheelchair which was broken by a rapidly closing elevator door in Pinecrest
Hospital, Beckley, West Virginia.
W. VA.J
REPORTS STATE COURT OF CLAIMS 345
In its Answer, the respondent admits
the validity and amount of the claim. The Court therefore makes an award to the
claimant of $90.14.
Award of $90.14.
Opinion issued January 25, 1983
J. P. CURRENCE
vs.
OFFICE OF THE SECRETARY OF STATE
(CC-82-186)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings. The claimant seeks
payment for investigating services furnished to respondent in the amount of
$143.00.
The respondent admits the validity and amount of the claim, but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
The Court finds that this claim should, in equity and good conscience, be paid,
but an award cannot be made, based on our decision in Airkem Sales and Service5 et at. v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued January 25, 1983
EVANS LUMBER COMPANY
vs.
DIVISION OF VOCATIONAL REHABILITATION
(CC-82-249)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations
346 REPORTS
STATE COURT OF CLAIMS [W. VA.
of the Notice of Claim and the
respondent?s Answer. Claimant seeks payment of the sum of $458.97 for an unpaid
bill for lumber supplies.
In its Answer, the respondent admits the validity and amount of the claim. The
Court therefore makes an award to the claimant in the amount of $458.97.
Award of $458.97.
Opinion issued January 25, 1983
VICTOR FRISCO and
JANET FRISCO
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-80-121)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The Court in its opinion issued on November 10, 1980, denied this claim on the
grounds it was barred by the Statute of Limitations. The claim is now before
the Court for rehearing on the issue of whether the claim is time barred.
On or about May 20, 1977, hydacid uranine (flourscein) dye was placed in a
water well located upon property in Mineral County, West Virginia. The dye was
put in the well by respondent, in an effort to trace underground water to a
surface mine site. The dye damaged the well. Respondent drilled a new well, but
the dye migrated to ard contaminated the new well.
The claimants purchased the property in the fall of 1977, with the assurance
that the dye was temporary and not detrimental. On February 25, 1980, the
claimants filed this claim for $1,956.00 for the cost of installing a third
well. The respondent on June 11, 1980, filed its Answer admitting the damage to
claimants? well. On June 23, 1980, respondent filed its Amended Answer, with
the defense that the claim was barred by the applicable two-year period of
limitations.
W. VA.] REPORTS
STATE COURT OF CLAIMS 347
At the rehearing, it was established that the claimants were advised for the
first time not to use the well for domestic purposes on March 3, 1978, in a
letter from the West Virginia Department of Health. The claimants? right of
action accrued on March 3, 1978, and this claim is not barred by the statute of
limitations. However, the testimony at the rehearing established that the
claimants started to receive city drinking water ?a couple of months? prior to
the July 21, 1982, rehearing date. It was also established that the third well,
for which the claimants seek $1,956.00 to drill was never drilled. Accordingly,
there can be no award for special damages but, the claimants certainly have
been inconvenienced by action of the respondent before obtaining a public water
supply and, accordingly, the Court makes an award to the claimants in the
amount of
$500.00.
Award of $500.00.
Opinion issued January 25, 1983
DONALD A. HARMAN
vs.
DEPARTMENT OF CORRECTIONS
(CC-8 1-38 1)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Claimant seeks recovery of $994.90 for sundry articles of personal property
which he owned and which were removed from his possession by officers or
employees of the respondent at the West Virginia Penitentiary, in Moundsvilie,
while the claimant was imprisor.ed there. The property was taken during a
?shake down? on November 29, 1979. Subsequently, it supposedly was shipped to
claimant?s home and was received by his wife. The claimant testified that some
of the articles were destroyed in his presence, some never reached his home and
others were damaged beyond repair when they reached his home. That evidence was
not disputed. It would appear that,
348 REPORTS
STATE COURT OF CLAIMS [W. VA.
when the respondent took possession of
the property, it became
a bailee. In Chesapeake & Ohio
Railway Co. v. S.R.C., 8
Ct.Cl.
140 (1970), the Court stated:
?A bailee must return to the bailor the bailment property in the condition it
was in at the time of the bailment, usual wear and tear excepted.?
Following that gereral rule, liability of the respondent is clearly
established.
As to the amount of damage, however, it appears that the evidence was of
replacement cost rather than fair market value at the time of the loss. For that
reason, the Court is inclined to allow only half of the sum claimed on the
theory that this approach will be at least roughly consistent with experience.
Award of $497.45.
Opinion issued January 25, 1983
RUTH A. KR1PPENE
DEPARTMENT OF HIGHWAYS
(CC?82-230)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
This claim was submitted upon a written stipulation to the effect that the
respondent is liable for damages in the sum of $3,152.65 based upon the
following facts: On June 9, 1982, and on August 16, 1982 claimant?s property
flooded due to water from the adjacent roadway. The flood damage was the resuit
of respondent?s negligent maintenance of the drair age system in the vicinity
of claimant?s property. The claimant missed three days of work as a result of
the flooding. Damages for lost work amount to $213.00. Claimant?s property was
damaged in the amount of $2,939.65.
The Court finds that the respondent?s negligence was the proximate cause of the
claimant?s damages, and hereby makes an award in the amount stipulated.
Award of $3,152.65.
W. VA.]
REPORTS STATE COURT OF CLAIMS 349
Opinion issued January 25, 1983
DORIS LESLIE
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-285)
No appearance by claimant.
Nancy J. A 11ff, Attorney at Law, for respondent. PER CURIAM:
This claim was submitted upon a written stipulation to the effect that the
respondent is liable for damages in the sum of $146.47. On or about July 14,
1982, the claimant was operating a 1980 Ford Mustang on Route 52, in the
vicinity of Coaldale, Mercer County, West Virginia. In the course of this
travel, the vehicle crossed a section of roadway which had been ditched across
the roadway by respondent and filled with gravel. While crossing the ditch,
claimant?s vehicle sustained damage to its tire, wheel and alignment. This
occurred because of the negligence of the respondent and this negligence was
the proximate cause of the claimant?s damages.
In view of the foregoing facts, the Court finds the respondent liable, and
makes an award to the claimant in the amount stipulated.
Award of $146.47.
Opinion issued January 25, 1983
WEST VIRGINIA SCHOOL OF
OSTEOPATHIC MEDICINE CLINIC, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-306)
Paul S. Detch, Attorney at Law, for claiman,t.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings.
350 REPORTS STATE
COURT OF CLAIMS [W. VA.
The claimant seeks payment for medical services furnished to respondent?s
Anthony Center in the amount of $14,709.50.
The respondent admits the validity and amount of the claim. but further alleges
that sufficient funds were not available at the close of the fiscal year in
question from which the obligation could have been paid.
The Court finds that this claim should, in equity and good conscience, be paid,
but an award cannot be made, based on the decision in Airkem Sales and Service, et al. v. Department of Mental
Health, 8 Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued January 26, 1983
WILSON R. COLE
vs.
DEPARTMENT OF HIGHWAYS
(CC-77-3a)
MARY LOU COLE
vs.
DEPARTMENT OF HIGHWAYS
(CC-77-3b)
WILSON R. COLE, ADMINISTRATOR
OF THE ESTATE OF TIMOTHY RAY COLE
vs.
DEPARTMENT OF HIGHWAYS
(CC-77-3c)
WILSON R. COLE, ADMINISTRATOR
OF THE ESTATE OF MARY JACQUELINE COLE
vs.
DEPARTMENT OF HIGHWAYS
(CC-77-3d)
Randy D. Hoover, Attorney at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
On January 7, 1975, claimant Mary Lou Cole, wife of claim-
W. VA.J
REPORTS STATE COURT OF CLAIMS 351
ant Wilson R. Cole, was operating a
1973 Plymouth Road Runner owned by him on West Virginia Route 21 near Beckley,
Raleigh County, West Virginia. A single vehicle accident occurred in which she
suffered severe injuries, two children of the claimants were killed, and the
vehicle was destroyed. The claimants contend that the respondent was negligent
in permitting a layer of ice to accumulate on the highway at the place of the
accident. When Mrs. Cole drove onto the ice, she lost control of the vehicle,
crossed the center line into the opposite lane of travel, ran up and then down
an embankment and then crossed both lanes of travel and proceeded over a hill
into a pond where the vehicle turned over in the water.
Trooper Bradford Vaughan investigated the accident. He testified that the
surface of this particular section of State Route 21 is shaded by a high
embankment on the west side of the highway adjacent to the southbound lane for
a distance of ?at least a hundred feet? and, if there is any ice on that
portion of the highway, it does not thaw until mid-afternoon.
Trooper A. W. Maddy testified that he had passed the accident scene twice on
the day of the accident. On his way to his office be had noticed that all of
the road were covered with a thin layer of frost or ice and this spot was no
different from the surface of the roads elsewhere. However, on his way through
the accident scene later at about 11:00 am., he noticed that the ice was still
present there, whereas the surface of the other roads was clear of the ice. He
pulled off the highway immediately after he struck the ice and radioed the
Beckley dispatcher to call the Department of Highways to send a cinder truck to
that spot. He testified that he had not called earlier in the morning because
?As I previously testified, when there is a hazard in a general area, people
have to live with it and they ? everyone knows
to be careful when it?s cold and when they know that the road is slick and
everyone is careful. But I was especially concerned about it at 11 o?clock,
because at that time the road was dry everywhere else. People were just zooming
along there at the posted speed limit * and
352 REPORTS
STATE COURT OF CLAIMS [W. VA.
possibly beyond, but I knew that an
accident was going to happen. One had already happened and I was highly
suspicious that another one was going to happen because the roadway was dry
from Beckley all the way to there and it was dry from the other end of the icy
spot south. That was the only slick spot and it was just over the crest of the
hill as you?re going north and I was concerned that there was going to be an
accident because no one suspected it at that time of day with the sun out
shining.?
Mrs. Cole testified that she was driving at approximately 35 miles per hour.
She did not see the ice. She could not remember doing anything mechanically to
the automobile. She stated that she had driven through this area on previous
occasions and had noticed slick spots there.
Other witnesses for the claimants and for the respondent corroborated the fact
that ice existed on the surface of the road where the accident occurred.
Corporal A. C. Bartlect, a member of the Department of Public Safety, testified
about the scene where this accident occurred as follows:
Q ?Was that a known bad spot along the highway in Raleigh
County?
A Yes, it was.
Q And had you ever notified the Department of Highways
yourself, personally, about that bad spot?
A No. I had been there for years and the spot had always been there.
Q Are you saying it was common knowledge?
A Yes.
Q And what was common knowledge about it?
A Well, whenever the weather ? when it got cold, it usual-
W. VA.]
REPORTS STATE COURT OF CLAIMS 353
ly froze there, and it was always even
in a little dry weather, there was still some water or something coming out
through there, through the blacktop.
Q You don?t know ?
do you know where the water was coming
from?
A No, I don?t. There?s a pond on one side and, of course, the hill on the other
side, and I don?t have any idea.?
Following the decision in the case of Adkins
v. Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947), this Court has repeatedly held that the State is not a guarantor of the
safety of the travelers on its roads. ?The State is not an insurer and its duty
to travelers is a qualified one, namely, reasonable care and diligence in the
maintenance of a highway under all circumstances.? Parsons v. State
Road Comm?n., 8 Ct.Cl. 35 (1969). The State can neither be required
nor expected to keep its highways absolutely free of ice and snow at all times,
and the presence of an isolated ice patch on a highway during winter months s
generally insufficient to charge the State with negligence. See 39 Am. Jur.2d Highways, Streets, and Bridges ?506. See also Woof ter v. State Road Comm?n., 2
Ct.Cl. 393 (1944); Christo v. Dotson, 151 W.Va. 696, 155 S.E.2d 571 (1967).
The facts of this claim reveal a common occurrence which exists throughout the
mountainous terrain of West Virginia. Roads accumulate frost during cold winter
nights. The frost remains on the surface of roads until it thaws. In areas
shaded from the sun the surface of the roads naturally remain slick longer than
unshaded areas. This condition is common on many of this State?s highways.
Accordingly, the Court is of the opinion that the respondent was not negligent
in the maintenance of Route 21. Although the Court is very sympathetic to the
claimants, the Court is constrained to hold that, as there was lack of
negligence on the part of the respondent in the maintenance of the highway, the
claims must be denied.
Claims disallowed.
354 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued January 26, 1983
JERRY M. EDWARDS and EDGAR E. EDWARDS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82- 198)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
This claim was originally filed in the name of Jerry M. Edwards, but when the
testimony disclosed that the damaged vehicle, a 1982 98 Oldsmobile, was titled
in the joint names of the claimant and her husband, Edgar E. Ewards, the Court
on its own motion joined Edgar E. Edwards as an additional claimant.
On May 28, 1982, at 2:30 p.m., Mrs. Edwards struck a pothole near milepost 48 in
the westbound lane of 1-64 near Cross Lanes, West Virginia. Mrs. Edwards
testified that she was aware of holes in the road because she travels that
route twice a day. She added that she could avoid the holes by driving near the
edge of the road, but a truck, belonging to respondent, was on the berm and she
could not move over far enough to avoid the hole. Damage to the car amounted to
$96.92. Mrs. Edwards made no complaints to respondent prior to the accident.
The State neither insures nor guarantees the safety of motorists traveling on
its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). For the respondent
to be held liable for damages caused by the pothole, proof of notice of the
defect is required. Davis Auto Parts
v. Dept. of Highways, 12 Ct.Cl. 31
(1977). In this case, the claimant testified that respondent?s employees were
working near the site of her accident. However, the Court believes that the
claimant, with her prior knowledge of the road?s condition, was likewise
negligent. Under the doctrine of comparative negligence, the Court is of the
opinion that the claimant?s negligence was equal to or greater than the
respondent?s and disallows the claim. Hull
v. Dept. of Highways, 13 Ct.Cl. 408
(1981).
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 355
Opinion issued January 26, 1983
NELSON GREGORY
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-307)
William C. Garrett, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
On May 19, 1979, claimant was walking on State Route 22, in Webster County,
West Virginia, near Big Grassy Creek. At approximately 10:00 p.m., the claimant
reached the bridge over Big Grassy Creek. The guardrails were missing, and
claimant fell off the bridge, sustaining multiple personal injuries. Claimant
alleged that the failure of the respondent to replace the guardrails
constituted negligence and seeks $50,000.00.
Claimant?s testimony indicated that he was familiar with the condition of the
bridge. A coal company was working in the area, and its trucks, which travelled
across the bridge, were responsible for knocking off the guardrails on a
previous occasion. Respondent had replaced the rail at that time. According to
the claimant, the guardrail ?had been off a good while, maybe three weeks or a
month? this second time, before his accident. Respondent?s employee, Maxine K.
Alsop, was the Head Clerk of the Webster County Maintenance Detail at the time
of claimant?s accident. She testified that part of her job included taking
complaints and that there had been no complaints, prior to Mr. Gregory?s
accident, that the guardrails were down again.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its roadways. Adkins v.
Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947). For negligence of the respondent to be shown, proof of notice of the
defect is required. Davis Auto Parts
v. Department of Highways, 12 Ct.Cl.
31 (1977). Even if the Court should find that the respondent was negligent
under the facts of this case it appears from the
356 REPORTS STATE
COURT OF CLAIMS [W. VA.
evidence that the negligence of the claimant himself, having knowledge of the
bridge?s condition, would equal or exceed it. See Davis v. Dept. of
Highways, 9 Ct.Cl. 49 (1972).
Claim disallowed.
Opinion issued January 26, 1983
BOBBIE E. HOLMES and
NEVA I. HOLMES
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-191)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
Claimants are the owners of residential property located on Route 73, known as
Ridge Road, in Monongalia County, West Virginia. The land slopes downhill from
the road to the claimants? property. In 1979 and 1980, surface water flowed
down into their garden and destroyed it. Claimants seek recovery in the amount
of $2,495.21 for the damages caused by the flooding.
At the hearing, Mr. Holmes testified that the water which flooded his land came
from two of his neighbors? driveways:
?Q. It it your testimony that it?s flowing down the driveways
and then down into the lower area where your property is?
A. Uh-huh; comes right out their driveway, right down through their yard and
right on down through into the other driveway and then right down on me.
Q. Now, your property where your garden is located, is it
an area that is at a lower elevation than the roadway; is that correct?
W. VA.J
REPORTS STATE COURT OF CLAIMS 357
A. Well, yes, it?s sloped, it?s
graded.?
Mr. Holmes further testified that for the previous two years he had dug a small
ditch across his neighbors? driveways along the respondent?s right-of-way in an
attempt to correct the situation. Claimants had been living at that location
for twelve years.
Claimant Mrs. Holmes stated that a round, four-inch culvert existed in the
area, but that it had been installed by a neighbor, and not by the Department
of Highways.
Testifying on behalf of the respondent was Edward E. Goodwin, claims
investigator, who explained the procedure for the installation of driveway
culverts. According to Mr. Goodwin, a property owner must get a permit from the
district office to connect to the State road, Then, at least a 15-inch culvert
must be purchased by the property owner. The Department of Highways will then
come by with a grader to dig a ditch for the culvert, drop it in, and cover it.
No evidence was presented in this case to the effect that the respondent had
notice of a drainage problem along Route 73 in the area of claimants? property.
Edgar Malone, an employee of the respondent, testified that the road was
ditched in 1981, but it was unclear just how far the ditching was performed.
From the record in this case, the Court cannot conclude that any action, or
lack thereof, on the part of the respondent was the sole cause of the flooding
of claimants? property. Water simply followed its natural course downhill to
the lower-lying area of claimant?s garden. To hold that a diversion of the
water from a clogged ditch line was the sole, direct cause of the damage to the
garden, is not warranted from the evidence.
Accordingly, the Court is of the opinion that the claimants have not shown by a
preponderance of the evidence that their damages were the result of negligence
on the part of the Department of Highways, and hereby disallows the claim.
Claim disallowed.
358 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued January 26, 1983
BERNARD C. LYONS and
HELEN V. LYONS
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-578)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimants allege that respondent negligently failed to maintain drainage
lines along Route 39 in Richwood, Nicholas County, West Virginia, and that such
negligence resulted in damages to their home in the amount of $45,000.00. The
house, a two-story structure, which is concrete block on the lower level, and
wood on the top, has developed numerous cracks in the concrete floor and has
settled, cracking a number of windows. Claimants allege that respondent
promised to correct the drainage problems before resurfacing Route 39 in 1977
but failed to do so. As a result, the drain became clogged and water damage
occurred.
Respondent?s witness, Eugene Tuckwiller, an engineer, testified that the
hillside behind the claimants? property contains subsurface water which flows
continuously which has caused the ground to become unstable around the
claimants? home, and caused movement of the land. This movement is unrelated to
any action respondent has taken, and respondent has no responsibility for water
until it reaches its right-of-way.
The Court is of the opinion that the claimants have failed to establish by a
preponderance of the evidence that the acts or omissions of the respondent
resulted in the damage to their home. The evidence indicates that the
saturation of the hillside beyond claimants property was the direct cause of
the movement of the land. Caldwell, et
at. v. Dept. of Highways, D-690
et al. (1975). The Court must disallow the claim.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 359
Opinion issued January 26, 1983
ANDREW S. YOUNG
vs.
DEPARTMENT OF HIGHWAYS
(CC?81?75)
Claimant appeared in person.
Nancy J. Alff, Attorney at Law, for respondent.
PER CURIAM:
On February 11, 1981, claimant was driving his 1972 Datsun 240-Z on U.S. Route
52 about three-tenths of a mile south of the junction of U.S. Route 52 and West
Virginia Route 44 in Logan County, West Virginia. Claimant was traveling north
at about dawn, and entered the southbound lane in order to pass a truck. His
automobile struck a rock in the road, sustaining damages of $3,995.55.
The claimant testified that when he first saw the object, he was about 100 to
150 yards away and that he was parallel to the truck when he hit the rock.
There was nowhere for him to go to avoid the rock. Claude Blake, a claims
investigator, stated that at the scene of the accident the berms are
exceptionally wide, from 10 to 17 feet, and that the area is not prone to rock
falls. The claimant stated that he had travelled that road the day before the
accident and the rock was not present.
The State is neither an insurer nor a guarantor of the safety of persor?s
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
State to be found liable, it must first have had either actual or constructive
notice of the defect in the roadway. Since there was no proof in this case that
the State had notice of the defect, the claim must be denied.
Claim disallowed.
360 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued January 27, 1983
JESSE C. ANDERSON
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-110)
Claimant appeared in person.
Nancy J. Aiff, Attorney at Law, for respondent. PER CURIAM:
On August 18, 1980, the basement wall of the claimant?s home, which is located
on State Route 14 at Butcher Hill, Wood County, West Virginia, collapsed.
Claimant alleges that the damage was caused by land slippage from State
property. The vall was repaired at a cost of $1,132.95.
The claimant?s son, Harry Anderson, testified that his father?s house sits
below the road on the north side of Route 14 and that there is a hill on the
south side. The house was built in 1938, but there had been no damage to it
until 1980. Since
1938, there has been ?natural movement of the hillside? and respondent has
relocated Route 14 ?numerous? times and made a pile driving correction in order
to try to stablize the hillside. At the time of the damage, there was no ditch
line along Route 14 because of the slippage. There had been rain for a day or
two before August 18, and the water ran over the road onto claimant?s property,
resulting in the collapse of the basement wall according to claimant?s son.
Ralph Adams, a geologist, testified that a subsurface investigation was
performed in 1979 by Atec Associates in cooperatioii. with respondent, and this
investigation showed that a large slide area existed above and below Route 14.
The claimant?s property is in the middle of the slide. The soils in the area
are unstable and the ground water level is high. The investigation indicated
that there was ?a record of moving approximately 50 years with more recent
movement.? The work that respondent has done on Route 14 served to siow down
the land movement by cutting down the slope and
W. VA.]
REPORTS STATE COURT OF CLAIMS 361
removing weight from the hillside. A
slide correction has been proposed for the area, which would involve moving the
roadway into the hillside and removing the slide material from the cut slope
area.
The evidence indicates that the claimant?s home is situated in a slide prone
area. The respondent has made some effort to slow down the slippage. In making
its corrections, however, the respondent is under a legal duty to use
reasonable care to maintain the ditch line in such condition that it will carry
off surface water and not discharge it onto the property of others. Stevens v. Dept. of Highways, 12 Ct.Cl. 180 (1978). The Court finds that there is
sufficient evidence to show that water was discharged onto the claimant?s
property, and that the respondent?s failure to maintain the ditch line caused
the discharge and resultant damage sustained by the claimant. The Court
therefore makes an award in the amount of $1,132.95.
Award of $1,132.95.
Opinion issued January 27, 1983
GENE BRADY BEEGLE
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-248)
AND
ST. PAUL?S PROTESTANT EPISCOPAL CHURCH
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-271)
Robert E. Wright, Attorney
at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimants, Gene Brady Beegle and St. Paul?s Protestant Episcopal Church,
own adjacent properties on W.Va. Route 2, commonly called Cemetary Hill Road,
in Sistersville, Tyler
362 REPORTS
STATE COURT OF CLAIMS [W. VA.
County, West Virginia. These cases
were consolidated because the damages alleged arose out of the same incident.
In July 1981, during a heavy rainstorm, a portion of the curb on Cemetary Hill
Road broke. Water ran down the hillside and into the Beegle home and the
church. Claimant Beegle sustained damages of $1,778.00 for replacement of
carpeting and a furnace. The church sustained damages of $122.00. Claimants
allege that respondent was negligent in failing to maintain the curb.
Mr. Beegle testified that sometime in February 19B1, a school bus slid into the
curb. This caused the curb to crack. He said that he notified both the City of
Sistersville and the respondent prior to July 1981 to fix the curb, but no
action was taken until after the damage occurred.
Ray H. Maxwell, a county maintenance superintendent employed by respondent,
testified that Cemetary Hill Road was taken into the State system in May of
1972. By agreement between the respondent and the council of the City of
Sistersville, responsibility for the maintenance of the paved vehicular roadway
rested with respondent. All other portions of the roadway were to be maintained
by the city.
The evidence indicates that the normal run-off of rain down Cemetary Hill Road
was disrupted by the break in the curb. The respondent had actual notice of the
damage to the curb. It was foreseeable that the surface water run-off would be
diverted by the broken curb. West Virginia adheres to the common law rule that
a landowner may fight surface water in whatever manner he chooses, but the rule
is modified by the principle that one must use his property so as not to injure
the rights of another. 20 M.J., Waters
and Watercourses, ?5, p. 27. See also Miller v. Dept. of Highways, 13 Ct.Cl. 414 (1981). The Court finds that the
respondent was negligent in failing to maintain the curb, and the surface water
run-off from respondent?s roadway was the proximate cause of claimants?
damages.
Award of $1,778.00 to Gene Brady Beegle.
Award of $122.00 to St. Paul?s Protestant Episcopal Church.
W. VA.J
REPORTS STATE COURT OF CLAIMS 363
Opinion issued January 27, 1983
PIUS B. CHUMBOW
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-62)
William D. Highland, Attorney at Law, for claimant. Nancy J. A 11ff, Attorney at Law, for respondent.
RULEY, JUDGE:
On November 5, 1980, at approximately 4:30 p.m., claimant was driving his 1971
Mercury west on 7th Avenue, W.Va. Route 25, in Charleston, Kanawha County, at a
speed of 30-35 mph. Seventh Avenue is a four-lane highway with a concrete
median, and on that date, both inside lanes, eastbound and westbound, were
blocked off with Type 2 barricades because sewer modification work was being
carried out along that route. As claimant approached the intersection of 7th
Avenue and 29th Street, a 1966 Oldsmobile driven by Marian Helms made a left
turn from the eastbound lane of 7th Avenue and pulled. across the westbound
lane into the path of claimant. Claimant struck the Helms car which then struck
two other vehicles. As a result of that accident, claimant lost $3,012.05 in
automobile repairs, wages, towing fees and transportation expenses. He alleged
that the accident occurred because the Type 2 barricades in the inside lanes
obstructed the vision of both drivers.
Testimony failed to establish negligence on the part of the respondent. An
independent contractor was responsible for placing the barricades, and the
barricades themselves were placed in accordance with Department of Highways
regulations. According to Dennis King, traffic engineer for the respor dent,
the barricades were 36 inches tall, well below the 45 inches considered
standard eye level in traffic engineering design. Mr. King further testified
that the contractor was required ft prohibit left turns onto and off of 29th
Street only during working hours, which ended at 4: 00 p.m. The exact placement
of the barricades on November 5, 1980 could not be determined.
364 REPORTS
STATE COURT OF CLAIMS [W. VA.
It thus appears that any negligence in
this accident would have to be attributed to the drivers of the vehicles
involved. Since the claimant failed to establish negligence on the part of the
respondent, the claim must be disallowed.
Claim disallowed.
Opinion issued January 27, 1983
RUBY E. SHRADER
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-168)
AND
JAMES C. MARTIN, JR. AND
SHIRLEY B. MARTIN
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-231)
Fred 0. Blue and James C.
Cain, Attorneys at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
These claims were consolidated for hearing and decision. Claimant Ruby E.
Shrader was the owner of a house and not designated as 3511 Cumberland Road,
located at the intersection of Cumberland Road and Edgemont Drive in Blue-
field, West Virginia, and also was the owner of a garage apartment located on
Edgemont Drive to the rear of the house on Cumberland Road. Claimants James C.
Martin, Jr. and Shirley B. Martin rented the Cumberland Road house from
claimant Shrader. The claimants allege that due to improper design and construction
of the drainage system of the Bluefield Bypass of U.S. Route 460, they
sustained damage from
W. VA.]
REPORTS STATE COURT OF CLAIMS 365
water flowing out of overflow pipes
from under the highway across Cumberland Road.
The Bluefield Bypass at U.S. Route 460, a four-lane highway, was constructed as
a portion of Appalachian Corridor Q.
Cumberland Road is parallel to and on
the north side of the U.S. Route 460 Bypass. The segment of the bypass relevant
to this claim was designed by Gates Engineering Company and constructed by S.
J. Groves & Sons, both under contract with respondent. The respondent
accepted and approved the plans of Gates Engineering Company. The design of the
highway provided for water drainage to be disposed of through underground limestone
caves or caverns. Previous to the con struction in the vicinity of the Shrader
property, there had existed a depression or low area in which water from East
River Mountain would collect and be dispersed through an underground limestone
cave. It appeared as a small farm pond, 50 by 100 feet in size, and
approximately five to six feet in depth. This pond or cave was utilized in the
drainage system designed for the highway. One witness described the area as
?essentially a huge sink hole.? The actual cave opening was not located, and a
manifold was designed to carry water run-off which the sink hole had formerly
handled for East River Mountain and the general vicinity. The manifold was a
large horizontal corrugated metal pipe into which water entered from 60-inch
and 54-inch pipes running under th road from the south side of the highway.
Five pipes extended from the bottom of the manifold from which water percolated
into the caves below. If the manifold was unable to handle the water for any
reason and it rose two feet or more, it would be able to flow through two
overflow pipes; one, 54 inches and the other. 48 inches, located to the west
and east of the manifold respectively. The outlet of the 54-inch pipe was
located approximately in front of the Shrader property. The 48-inch pipe was
located to the east. The south ends or inlets of the overflow pipe were almost
at highway level, and the north end on the Cumberland Road side of the highway
emerged out of the bottom of the toe of the fill. There were no baffles or
weirs at the inlet ends of the pipes. There were energy dissipating type
baffles at the outlet ends designed to slow the flow of water out of the pipes
and
366 REPORTS
STATE COURT OF CLAIMS [W. VA.
riprap was in place to slow any
erosion that might occur. The Cumberland Road area on the north side of U.S.
Route 460, where the pipes emerged, slopes downward from east to west. Mr.
Robert L. Long, a civil engineer for the Gates Engineering Company, testified
in his deposition that it was anticipated that there would be water coming
through the overflow pipes at some periodic intervals over the life of the
highway, and such water would be deposited on the north side. He further stated
that Gates was not asked to provide any method to dispose of the water other
than the baffles and the riprap.
Frank Hamrick, a civil engineer employed by the respondent, testified that if
water came through the overflow pipes,
?Hopefully, it would have stayed in the road (Cumberland Road) and gone down
the road, which was close to where the lowest point is.?
He further testified that,
?There was no provision made beyond the right of way limits of that area
because really there was not a natural drain there at the time.?
He further stated that,
?From an economic standpoint, it wasn?t justified.?
Continuous flowing occurred on October 6, 7, and 8, 1976, and again on June 17,
1977, caused by unusually heavy rainstorms. On these occasions, the manifold
did not carry off the water and the excess water emptied through the overflow
pipes. When the water exited the overflow pipes, it struck the baffles with
such force as to shoot up into the air over them and proceed across Cumberland
Road into portions of the first floor and basement garage of the Shrader house
and into the basement of the garage apartment. The basement walls and floors
were cracked, the walk into the house and driveways were damaged. The lawn and
shrubs were washed out. Clothing and personal belongings of the Martins were
damaged and destroyed. Mrs. Martin, during her high school days, nearly drowned
in a swimming incident, memories of which caused her to become hysterical on
each occasion at the sight of the water gushing
W. VA.]
REPORTS STATE COURT OF CLAIMS 367
out of the pipe across the road from the
house. Mr. Martin suffers from hemophilia and arthritis and is unable to go up
and down stairs. After the floodings, the house remained damp, aggravating Mr.
Martin?s condition. His condition and Mrs. Martin?s fear of a repetition of the
rushing water entering the house were such as to necessitate the Martins to
find another place to live. They had rented from Mrs. Shrader for $95.00 per
month for many years and were unable to find comparable accommodations they
could afford. Later, the Martins built a home on a lot given to them by Mrs.
Martin?s parents.
Mrs. Shrader seeks $20,000.00 for damages sustained to her property. The
Martins seek recovery of $83,853.40 for the loss of their clothing and personal
property, for inconvenience and anguish, and for interest on the loan obtained
for the construction of their new home, which will amount to $60,932.40 over
the twenty-two-year life of the loan.
On the occasions of the floodings, the respondent was notified by the
claimants. Employees of the respondent went to the property and observed the
damages sustained. One employee testified that he saw the water gushing 30 to
40 feet into the air. After the flooding of June 1977, the respondent created a
ponding or storage area on the south side of the U.S. Route 460 Bypass and
installed baffles or weirs on the inlets of the overflow pipes. On the north
side of the highway, respondent dug a ditch line between the toe of the
embankment and Cumberland Road to carry off any water coming through the pipes.
Severe storms have occurred since these changes and there has been no
subsequent flooding.
In addition to the claim filed before this Court, the claimants brought suit in
the Circuit Court of Mercer County against Gates Engineering Company and S. J.
Groves & Sons. Mrs. Shrader?s suit was settled for $1,500.00, and the
Martins accepted $5,000.00 to settle their litigation.
The Court finds that the respondent approved and accepted the plans and
specifications for the drainage system designed for the section of the U.S. 460
Bypass in the vicinity of claimants? property without consideration being given
to the inability of the overflow system to properly carry off water. If
368 REPORTS STATE
COURT OF CLAIMS [W. VA.
the overflow pipes had been supplied with the necessary baffles, ponding areas
and a method provided to dispose of water as it leaves the outlets, there would
have been no damage.
The Court finds that claimant Shrader is entitled to recover the sum of $19,810.00,
less the $1,500.00 settlement already received. No recovery will be allowed the
Martins for labor or interest on their loan. Accordingly, the Court makes the
following awards.
Award of $18,310.00 to Ruby E. Shrader.
Award of $6,846.00 to James C. Martin, Jr. and Shirley B. Martin.
Opinion issued January 27, 1983
CHARLES S. WARD,
guardian of CHARLES F. WARD
vs.
DEPARTMENT OF CORRECTIONS
(CC-78-113)
Robert V. ertholc1, Jr., and Eugene R.
Hoyer, Attorneys at Law, for
claimants.
Henry C. Bias, Jr., Deputy Attorney General, and Gray Silver, III, Assistant Attorney General, for respondent.
GARDEN, JUDGE:
Because of the age of the claimant, this claim was filed by Charles S. Ward as
guardian of Charles F. Ward, seeking $125,000.00 for damages sustained while
assigned to the Anthony Forestry Center in Neola, West Virginia. For the
purposes of this opinion, the ward, Charles F. Ward, will be referred to as
?claimant.?
The claimant and two others, Ronald Deitz and John Preston, had been found guilty
of breaking and entering in Kanawha County, West Virginia. His two companions
thought
W. VA.)
REPORTS STATE COURT OF CLAIMS 369
that the claimant had cooperated with
the police, and, because of this, the presiding judge, in passing sentence,
recommended that they be placed in separate facilities. Claimant and Preston
were sent to the Leckie Center at Leckie, West Virginia, where claimant was
harassed as a ?snitch.? Claimant, fearing for his safety, wrote his probation
officer, which resulted in his transfer to the Anthony Center, where Ronald
Deitz was confined. Ronald Deitz told other inmates that claimant was a
?snitch.? On February 16, 1977, claimant, Jeff Webb, and Darrell King were
assigned to work in the cafeteria at the center. They left the cafeteria to
empty the garbage. Claimant?s companions pushed him about, threw him down, and
called him a ?snitch.? His hand was severely cut when he fell. The boys are not
supposed to leave the cafeteria without permission, and when they do leave,
they are supposed to be watched by center personnel.
At the time of the accident, claimant, to avoid further harassment, told the
cook at the cafeteria and others that he slipped on the ice and cut his hand.
The Court is not unmindful of the serious nature of claimant?s injury. Dr.
Jacques Charbonniez, an expert in plastic surgery and surgery of the hand,
testified eloquently concerning the surgery claimant has already undergone, and
will require in the future, as well as the extent of his disability. In order
for the Court to make an award in this case, however, it must be shown by a
preponderance of the evidence that the respondent was guilty of negligence
which proximately caused claimant?s injury. He testified that he had never
informed any staff member at the Anthony Center of his concerns for his safety.
It is well recognized that there can be no liability for injuries inflicted by
one inmate upon another without knowledge of some unusual danger, or reason to
anticipate such danger. 41 ALR 3d 1021. The evidence presented indicates that
claimant was provided with the usual amount of security; Anthony Center
officials had no reason to do otherwise. The Court must therefore deny the
claim.
Claim disallowed.
370 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued January 28, 1983
CHAD CUNNINGHAM
vs.
DEPARTMENT OF HEALTH
(CC-82-323)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the a1lega tions of the Notice
of Claim and the respondent?s Answer.
The claimant seeks payment of the sum of $7.34 for damage to a shirt. The
claimant was required to physically restrain a patient at Spencer State
Hospital. The patient grabbed the shirt and tore it.
In its Answer, the respondent admits the validity of the claim. As there were
sufficient funds on hand from which the claim could have been paid during the
fiscal year, the Court hereby makes an award to the claimant in the amount
requested.
Award of $7.34.
Opinion issued January 28, 1983
C. ELAINE FRIEND
vs.
SUPREME COURT OF APPEALS
(CC-82-314)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
W. VA.]
REPORTS STATE COURT OF CLAIMS 371
The claimant seeks payment of the sum
of $165.00 for services rendered as Jury Commissioner for Jefferson County,
West Virginia.
In its Answer, the respondent admits the validity of the claim, and the Court
hereby makes an award to the claimant in the amount requested.
Award of $165.00.
Opinion issued January 28, 1983
BENJAMIN C. HENRY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-96)
David S. Skeen, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
On June 13, 1981, the claimant?s home, which is located between Hillside Drive
and Route 25 in Nitro, Kanawha County, West Virginia, sustained flood damage.
The claimant alleges that this damage was the result of respondent?s failure to
maintain a culvert situated on Route 25. This clogged culvert caused water to
back up and flood the claimant?s property.
The claimant?s house faces Hillside Drive and backs on Route 25. Both roads run
east-west. A 15-inch drainpipe runs from Hillside Drive along the west side of
the claimant?s house. This drain empties into an 18-inch drain which is
maintained by respondent and runs from the north to the south under Route 25.
This drain empties into a 30-inch culvert, which runs parallel to Route 25 on
its south side. The water runs east in the 30-inch drain.
The claimant testified that shortly after moving into his
372 REPORTS
STATE COURT OF CLAIMS [W. VA.
house in 1977, he became aware of the
drainage problem. Water would go through the 18-inch drain, but because the
culvert was clogged the water would back up through the drain. The claimant?s
property is below the level of Route 25 and the water flowed from the drainpipe
across his yard and into his basement. The claimant made numerous phone calls
to respondent beginning in 1977. On three occasions before June 13, 1981, water
entered the home. One of respondent?s engineers visited the property in late
1977 and suggested that the level of the yard be raised. The claimant had about
two feet of dirt put in his back yard to try to prevent further water damage,
but this effort was unsuccessful. The claimant testified that not until after
the June 1981 damage did he witness any of respondent?s employees cleaning the
ditches and drains. He stated:
?Well, they had ?
I don?t know what you call the shovel
that?s on a truck ?
to come in that would go over into the
ditch line, the culverts and clean them out and they had at least two trucks.
One was loading while the other one was taking away and there was 8, 10, maybe
12 truck loads of debris that was taken out of there.?
Since the removal of the debris, the claimant has had water back up into his
yard, about 2/3 of the way from the 18-inch pipe to his back door. On June 13,
1981, the water was approximately five feet high in his house.
The Court is of the opinion that the flooding to claimant?s property occurred
as the direct result of the lack of maintenance of the 30-inch culvert located
on the south side of W.Va. Route 25.
After careful consideration of all of the estimates of damages, the Court has
determined that $4,500.00 is a just and equitable amount to compensate the
claimant for his losses. Accordingly, the Court makes an award in the amount of
$4,500.00.
Award of $4,500.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 373
Opinion issued January 28, 1983
DONNA F. PORTERFIELD
vs.
DEPARTMENT OF HIGHWAYS
(CC-8 1-9 1)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
RULEY, JUDGE:
On December 29, 1980, at approximately 7:00 p.m., claimant was driving her 1980
Pontiac south on U. S. Route 19 near Star City, in Monongalia County. Snow had
been falling and the pavement was wet, but there was no snow on the road surface.
At a point near the Star City Bridge, claimant encountered a large number of
rocks in her traffic lane and collided with several of them causing damage to
her automobile in the sum of $300.70, for which she filed this claim.
Testimony by James Tomay, the Department of Highways night watchman at the
Saberton station on the night of the accident, and John Gillespie, Department
of Highways equipment operator on duty that night, revealed that the respondent
was first notified of the rockslide at about 7:00 p.m., on December 29, 1980
(most probably after the accident happened), and had cleared the roadway by
7:30 p.m. that evening.
The State neither insures nor guarantees the safety of motorists travelling on
its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). For an award to be
made in cases such as this, it must be proven that the respondent had actual or
constructive knowledge of the existence of the defect plus a reasonable amount
of time to take corrective action. Davis
v. Department of Highways, 11 Ct.Cl.
150 (1976). The respondent acted competently and quickly to correct the defect
in question and thus cannot be held negligent. This claim must be disallowed.
Claim disallowed.
374 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued January 28, 1983
ALFRED W. SMITH
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-177)
William W. Pepper, Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Sometime in July 1982, the claimant was driving his 1976 Toyota Corolla on
Fisher Ridge in Putnam County, West Virginia, when he encountered a ditch in
the road. The chassis of the car broke in two places, and subsequent welding of
the frame proved unsuccessful. The car remains undrivable. Claimant seeks
$1,500.00 as replacement value of the car.
The claimant testified that when he went to work between 7:30 and 8:00 that
morning he saw four or five Department of Highways employees apparently
cleaning the ditch along Fisher Ridge. When he returned at 5:00 p.m., the ditch
was in the road, which claimant stated was the result of the installation of a
24-inch drainpipe across the road. A 12 to 14-inch drop existed between the
road and the ditch. The claimant saw no signs warning of danger. He did not see
any equipment capable of digging the ditch, nor could he say who dug the ditch.
From the evidence presented in this claim, the Court cannot find that
respondent dug the ditch which caused the damage to claimant?s automobile. The
State is neither an insurer nor a guarantor of the safety of persons travelling
on its highways. Adkins v. Sims, 130 W.Va. 645 (1947). For the State to
be found liable, it must first have had either actual or constructive
notice of the defect. Since there was no proof in this case that the State had
notice, the claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 375
Opinion issued January 28, 1983
JANET T. SURFACE
vs.
DEPARTMENT OF HEALTH
(CC-83-2)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
The claimant seeks payment of $132.00 for services rendered as a court
reporter.
In its Answer the respondent admits the validity of the claim. As there were
sufficient funds on hand from which the claim could have been paid during the
fiscal year, the Court hereby makes an award to the claimant in the amount
requested.
Award of $132.00.
Opinion issued February 9, 1983
A. H. ROBINS CO.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-315)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $259.54, representing unpaid bills for merchandise
purchased by respondent?s Huttonsville Correctional Center.
376 REPORTS STATE
COURT OF CLAIMS [W. VA.
Respondent?s Answer, although admitting the validity of the claim, states that
there were no funds remaining in respondent?s appropriation for the fiscal year
in question from which the obligation could have been paid.
While the Court feels that this is a claim which in equity and good conscience
should be paid, it is of the opinion that an award cannot be made, based on the
decision in Airkem Sales and Service,
et al. vs. Dept. of Mental Health, 8
Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued February 9, 1983
THOMAS HAROLD ANDERSON, SR.
and
EDITH IOLENE ANDERSON
vs.
DEPARTMENT OF WELFARE
(CC-79-554)
Anthony J. Julian and Charles E.
Anderson, Attorneys at Law, for
claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
Claimants seek payment of the sum of $30,520.00 as reimbursement for expenses
incurred while they served as foster parents for three children over an
eight-year period, from March 26, 1964, to October 23, 1972.
The evidence disclosed that on or about June 1, 1961, three children were
placed in the Andersons? home under the respondent?s foster care program. In
September of 1963, the children were moved from the claimants? home in the hope
that they would be adopted and given a permanent home. The Andersons received
monthly payments of $120.00 from the Department of Welfare during the time that
the children were in their care (June 1, 1961, to September 18, 1963).
W. VA.]
REPORTS STATE COURT OF CLAIMS 377
In February of 1964, the children were
placed in yet another home. Finally, after these two unsuccessful attempts at
securing adoption for the children, the Department of Welfare returned them to
the custody of the claimants on March 26, 1964. At that time, it was the
intention of Mr. and Mrs. Anderson to adopt the children, and they communicated
that intention to the Department of Welfare. They also contacted a lawyer in an
effort to institute adoption proceedings. Due to the Andersons? request to
adopt the children, the Department of Welfare closed its file in August of
1964, and no further monthly payments were made to the claimants. Frances R.
Vincent, a Social Services Worker for the respondent stated, ?Payment wasn?t
made because the children were placed in trial adoption and we don?t pay people
when children are placed in trial adoption unless there are extenuating
circumstances such as if the children are older and have physical problems . .
Eight years later, on October 23, 1972,
Mrs. Anderson telephoned the Department of Welfare, asking for financial
assistance for the care of the children. For some unknown reason, the adoption
had never materialized. The Department of Welfare immediately began (effective
October 23, 1972) making payments to the Andersons as foster parents and
continued such payments until each child reached eighteen years of age. On
October 11, 1979, this claim was filed seeking payments for the period from
March 26, 1964, to October 23, 1972.
The claimants? assertion of liability is based on the theory that the
Department of Welfare was negligent in not checking on the status or progress
of the children. Even if that be viewed as correct, however, it is clear that,
by the same token, the Andersons were equally negligent in failing to contact
the respondent or their own attorney to determine the status of the adoption.
And, irrespective of whether the claim be viewed as one based upon negligence
or one based upon an oral contract (there having been no evidence whatever of
any written contract), it would be barred by the applicable statute of
limitations. Accordingly, this claim must be denied.
Claim disallowed.
378 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued February 9, 1983
BOSO AGRI-CENTER, INC.
vs.
FARM MANAGEMENT COMMISSION
(CC-82-3 18)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $2,288.94, representing unpaid bills for merchandise
purchased by respondent.
Respondent?s Answer, although admitting the validity of the claim, states that
there were no funds remaining in respondent?s appropriation for the fiscal year
in question from which the obligation could have been paid.
While the Court feels that this is a claim which in equity and good conscience
should be paid, it is of the opinion that an award cannot be made based on the
decision in Airkem Sales and Service, et al. vs. Dept. of Mental Health, 8
Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued February 9, 1983
TERESA BRITT
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-267)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant?s 1973 Ford Mustang was damaged when the
W. VA.] REPORTS
STATE COURT OF CLAIMS 379
vehicle struck a tree which had fallen across Pemberton Road in Raleigh County,
West Virginia. The incident occurred on September 5, 1982, at about 10:30 p.m.
Estimates of the damage to the vehicle ranged from $258.30 to $474.55. The
claimant testified that the tree was live, and that the road had been clear at
10: 15 p.m.
The State is neither an insurer nor a guarantor of the safety of persons
traveling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). To be
liable, the State must have had either actual or constructive notice of the
particular hazard which caused the accident. Davis v. Dept. of Highways, 11
Ct.Cl. 150 (1976). There was no evidence of notice to the respondent or of the
prolonged existence of the hazard. The claimant?s testimony leads to the
conclusion that the tree had fallen only a short time before the accident.
Without notice of the hazard and a reasonable opportunity to remove it, the
respondent cannot be held liable. The claim must therefore be denied.
Claim disallowed.
Opinion issued February 9, 1983
C. H. JAMES & CO.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-326)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $2,332.18, representing unpaid bills for merchandise
purchased by respondent?s Beckley Work Release Center.
380 REPORTS
STATE COURT OF CLAIMS [W. VA.
Respondent?s Answer, although
admitting the validity of the claim, states that there were no funds remaining
in respondent?s appropriation for the fiscal year in question from which the
obligation could have been paid.
While the Court feels that this is a claim which in equity and good conscience
should be paid, it is of the opinion that an award cannot be made, based on the
decision in Airlcem Sales and Service,
et al. vs. Dept. of Mental Health, 8
Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued February 9, 1983
KENNETH N. ELLISON
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-274)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim arises out of damages to a 1978 Ford automobile which struck a
pothole on West Virginia Route 119 near Hernshaw, West Virginia. The accident
occurred in late March or early April, 1982. The vehicle?s right front wheel
rim was replaced at a cost of $214.05. The claimant testified that he did not
see the pothole until after the vehicle struck it.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v. Sims, 130 W.Va. 645 (1947). For the State to be found
liable, it must first have had either actual or constructive notice of the
defect in the roadway. Since there was no proof that the State had notice of
the defect, the claim must be denied.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 381
Opinion issued February 9, 1983
HOLLY, KENNEY, SCHOTT, INC.
Vs.
DEPARTMENT OF HIGHWAYS
(0-893)
Thomas L. Linkous, Attorney at Law, for the claimant.
Stuart Reed Waters, Jr., Attorney at Law, for the respondent. RULEY, JUDGE:
Claimant was employed by the town of Chapmanville, in Logan County, to design
water and sewer facilities which were to be advertised for bids in December,
1968. In early November, 1968, claimant obtained a copy of the plans for
Corridor G of the Appalachian Highway, from which it was readily apparent that
it would be necessary to redesign the water and sewer facilities for
Chapmanville. Rather than waiting for authorization of that work by the federal
Bureau of Public Roads which finally, on January 24, 1969, was given, the
claimant proceeded with the redesign work for which it seeks an award of
$13,755.00. The defense is based upon Bureau of Public Roads Policy and
Procedure Memorandum 30-4, par. 3d, which provides, in part:
***
?d. Where the advance installation of new
utility facilities, crossing or otherwise occupying the proposed right- of-way
of a future planned highway project, is either underway, or scheduled to be
underway, prior to the time such right-of-way is purchased by or under control
of the State, arrangements should be made for such facilities to be installed
in a manner that will meet the requirements of the future planned highway
project. Federal funds are eligible to participate in the additional costs incurred
by the utility that are attributable to and in accomodation of the planned
highway project, provided such costs are incurred subsequent to
authorization of the work by the division engineer.***? (emphasis supplied)
382 REPORTS
STATE COURT OF CLAIMS [W. VA.
In sum, the respondent asserts that,
since the claimant performed the work prior rather than subsequent to
authorization by the division engineer, it is not entitled to payment from the
respondent. However, in a letter dated June 19, 1969, from W. S. Ritchie, Jr.,
then the State Road Commissioner, to the division engineer of the Bureau of
Public Roads, Commissioner Ritchie stated:
?Since authorization to proceed was finally received and the work was
performed, completely documented and is satisfactory, the time limitation
should be waived. A definite period of time was required to complete the
redesign work regardless of a specific starting date and the cost is under the
estimate provided.?
The facts quoted from that letter bring into stark relief the technical nature
of the defense. ?Let Chapmanville pay? is suggested but why should Chapmanville
pay for work which was occasioned solely by action of the respondent? It is
undisputed that the claimant performed the work in good conscience and, if the
standard of equity and good conscience delineated in West Virginia Code ? 14-2-13, is applied, the award which is sought in this
claim must be granted.
Award of $13,755.00.
Opinion issued February 9, 1983
MOUNTAINEER OFFICE SUPPLY,
a division of F & M SUPPLY CO., INC.
vs.
SECRETARY OF STATE
(CC-82-337)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based upon the allegations of the Notice
of Claim and the respondent?s Answer.
W. VA.1
REPORTS STATE COURT OF CLAIMS 383
Claimant seeks payment of the sum of
$1,860.00 for certificate covers ordered by the respondent. In its Answer, the
respondent admits the allegations set forth in the Notice of Claim, but states
that the claim was not paid because respondent inadvertently failed to comply
with the technical regulations of the State purchasing procedures. There were
sufficient funds in respondent?s appropriation for the fiscal year in question
from which the claim could have been paid. Based on the foregoing, the Court
hereby makes an award to the claimant in the amount of $1,860.00.
Award of $1,860.00.
Opinion issued February 9, 1983
MARY E. PETERSON
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-246)
Claimant appeared in person.
Nancy J. A1ff, Attorney at Law, for respondent.
PER CURIAM:
The claimant seeks the sum of $184.11 for damages to her 1980 Subaru which
struck a pothole on West Virginia Route
3 in Beckley, Raleigh County, West Virginia. The incident occurred on March 16,
1982, at about noon. The pothole was covered with water, so the claimant did
not see it before she struck it. The right front and rear tires and rims had to
be replaced.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
State to be found liable, it must first have had either actual or constructive
notice of the defect in the roadway. Since there was no proof in this case that
the State had notice of the defect, the claim must be denied.
Claim disallowed.
384 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued February 9, 1983
ROY G. SHAWVER
vs.
DEPARTMENT OF HIGHWAYS
(CC?82?189)
John E. Dorsey, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant seeks compensation for damages sustained to his 1975 Ford truck on
July 12, 1982, on W.Va. Route 7, also known as Kelly?s Creek Road, in Kanawha
County, West Virginia. Two estimates of the damage were obtained. One was for
$833.49 and the other for $923.42. According to the claimant?s testimony, he
was coming out of a sharp curve and another vehicle was approaching. There was
mud in the middle of the road which the claimant?s vehicle struck, causing it
to slide into a rock cliff adjacent to the roadway. The claimant testified that
a grader, belonging to the respondent, was parked near the accident scene.
William J. Meade, testifying for the claimant, stated that the grader had
broken down apparently while performing a ditch cleaning operation along
Kelly?s Creek Road. While he did not see the work being done, he surmised that
the grader had broken down prior to the completion of the ditching, resulting
in dirt being left in the road.
Lloyd Myers, Kanawha County Maintenance Supervisor, testified that work was
done of Kelly?s Creek Road at the end of June or beginning of July. The work
corsisted of patching potholes and perhaps some ditch cleaning. Mr. Myers said
that he had received a complaint about Kelly?s Creek Road, but did not remember
from whom. As a result, he drove down Kelly?s Creek Road sometime between July
10 and 12, and at that time, the roadway and ditch lines were clear of dirt and
debris.
From the record, the Court is of the opinion that the failure of the respondent
to clear Kelly?s Creek Road of dirt following its ditch cleaning operation
caused the damages sustained
W. VA.]
REPORTS STATE COURT OF CLAIMS 385
by the claimant. The Court, therefore,
makes an award to the claimant of $833.49.
Award of $833.49.
Opinion issued February 9, 1983
C. 0. SMITH, JR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-31 1)
No appearance by claimant.
Nancy J. Aiiff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a written stipulation based on the following
facts. The claimant is the owner of real property located in Beckley, Raleigh
County, West Virginia. On August 4, 1982, employees of respondent, who were in
the process of surveying between 1-64 and 1-77, trespassed on claimant?s
property and destroyed two Norway Spruce trees, valued at $630.00. Based on the
foregoing, the Court makes an award to the claimant in the amount of $630.00.
Award of $630.00.
Opinion issued February 9, 1983
SWAIN WINDOW CLEANING SERVICES
vs.
DEPARTMENT OF FINANCE AND ADMINISTRATION
(CC-82-301)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant maintained a contract with the respondent to provide window
cleaning services at the State Capitol Complex in Charleston, West Virginia.
There is no dispute that services were rendered, however a dispute did arise on
the amount still due on warrants endorsed by the respondent. The Court has
determined, based on the evidence presented, that $2,332.00 is owed to the
claimant by the respondent. The
386 REPORTS
STATE COURT OF CLAIMS [W. VA.
Court, therefore, makes an award to
the claimant in that amount.
Award of $2,332.00.
Opinion issued February 9, 1983
JACK L. TAYLOR
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-243)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
At approximately 7:30 p.m. on September 6, 1982, the claimant was driving his
1973 Buick Electra on West Virginia Route 60 towards South Charleston, West
Virginia. He turned off West Virginia Route 60 onto Faulkner Street. Four or
five feet from the corner of West Virginia Route 60 the claimant?s car struck a
manhole which was protruding above the level of Faulkner Street, which is a
gravel road. The vehicle sustained damages in the amount of $832.15.
The testimony revealed that the manhole in question is not maintained by
respondent, but is probably maintained by the Sanitary Board of St. Albans. It
was not established whether the manhole was within respondent?s right-of-way.
As it was not established that the respondent was responsible for the
maintenance of either the manhole or the roadway around the manhole, the Court
is of the opinion, and does, deny the claim.
Claim disallowed.
Opinion issued February 9, 1983
WAYNE F. WIGGINS
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-207)
Claimant appeared in person.
Nancy J. Aiiff, Attorney at Law, for respondent. PER CURIAM:
On June 4, 1982, at approximately 11:10 p.m., the claimant?s
W. VA.] REPORTS
STATE COURT OF CLAIMS 387
1978 MGB was damaged when it struck a pothole on West Virginia Route 68 near
Sherman, West Virginia. The vehicle sustained damages of $449.82. The claimant
testified that the pothole was approximately 12 to 14 inches wide, two feet
long and 10 inches deep. He did not see the hole prior to the accident because
it was raining and the pothole had filled with water. The claimant stated that
he travelled the road about once a week and knew that there were a number of potholes
in the road. He had never noticed this particular pothole before.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 ?vV.Va. 645
(1947). For the State to be found liable, it must first have had either actual
or constructive notice of the defect in the roadway. Since there was no proof
in this case that the State had notice of the defect, the claim must be denied.
Claim disallowed.
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF CORRECTIONS
(CC-82-260a ?
Administration)
(CC-82-260b ?
Anthony Center)
(CC-82-260c ?
Industrial School for Boys)
(CC-82-260d ?
Leckie Center)
(CC-82-260e ?
W.Va. Penitentiary)
(CC-82-329 ?
Anthony Center)
(CC-82-330 ?
Parole Services)
(CC-82-33l ?
Industrial School for Boys)
(CC-82-334 ?
W.Va. Prison for Women)
Jack 0. Friedman, Attorney at Law, for claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
In this consolidated claim, the claimant seeks to recover $181,052.93, of which
sum $156,267.00 is the amount of unem
388 REPORTS
STATE COURT OF CLAIMS [W. VA.
ployment compensation tax owed by
respondent and $24,785.93 is accumulated statutory interest of 1% per month.
The following is a breakdown by tax and interest:
Institution Tax Interest
Administration $11,588.42 $ 3,171.60
Anthony Center 17,074.63 3,129.87
Industrial School for Boys 12,559.57 3,496.07
Leckie Center 37,335.36 100.80
W.Va. Penitentiary 47,621.09 12,231.26
Anthony Center 1,420.00 52.54
Parole Services 10,642.46 348.01
Industrial School for Boys 3,998.55 147.95
W. Va. Prison for Women 14,026.92 2,107.83
The purpose of the Unemployment Compensation Law is to provide a reasonable and
effective means of promoting social and economic security by reducing so far as
practicable the hazards of unemployment. In compliance with the Congressional
Mandate of Public Law 94-566, Unemployment Compensation Amendments of 1976, the
West Virginia Legislature amended the W.Va. Unemployment Compensation Law,
effective January 1, 1978. Under W.Va. Code ?21A-1-3 (7) and ?21A-1-3 (9) (a),
services rendered by employees of the State are covered by the Unemployment
Compensation Law.
The respondent in its Answers admits the validity of the claims, but states
that the claims must be denied under the doctrine announced by the Court in Airkern Sales and Servicr., et al. vs. Dept. of Mental
Health, 8 Ct.Cl. 180 (1971). The
consolidated claims in Air kern represented various supplies, commodities and services
furnished to the respondent for which an appropriation was made by the
Legislature during the preceding fiscal year. The claims were disallowed,
despite the respondent?s opinion that the claims were moral obligations of the
State, because the respondent lacked sufficient funds from its appropriation
with which to pay the claims.
The Court, however, looks to its decision in Swartling, et al. vs. Office of the State Auditor, 13 Ct.Cl. 57 (1979). In Swartling, the
Court made awards to the claimants for services rendered to the State pursuant
to statutes promulgated by
W. VA.]
REPORTS STATE COURT OF CLAIMS 389
the Legislature. Payment for these
services was provided from funds designated for this purpose and subject to appropriation
by the Legislature. The Court held in Swartling
that for the Legislature to provide
for the types of services performed by the claimants and then to fail to
appropriate sufficient funds to pay them would be contrary to public policy.
In this claim, the Legislature has adopted statutes based on Congressional
directives. The statutes provide for the collection and disbursement of funds
to compensate the unemployed. The cost of providing this service cannot be
predicted for any given fiscal year in advance. Only at the close of the fiscal
year is this total known. For the Court to deny these claims would be contrary
to public policy and the mandate of Congress.
W.Va. Code ?21A-5-17 provides interest payments on past due monies at a rate of
1% per month until payment. The Court is restricted by W.Va. Code ?14-2-12 from
awarding irterest unless the claim arises on a contract specifically providing
for the payment of interest. Based on this section, the Court concludes that
the respondent is not legally liable for the payment of accrued interest. The
Court, therefore, makes an award in the above listed claims in the amount of
$156,267.00.
Award of $156,267.00.
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF CULTURE AND HISTORY
(CC-82-262)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $2,822.00 for unemployment compensation tax owned by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections,
14
390 REPORTS
STATE COURT OF CLAIMS [W. VA.
Ct.Cl.
387 (1983), and, accordingly, the Court
makes an award to the claimant in the amount of $2,822.00.
Award of $2,822.00.
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF HEALTH
(CC?82-263a)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $2,149.23 for unemployment compensation tax owed by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections,
14 Ct.Cl. 387 (1983), and,
accordingly, the Court makes an award to the claimant in the amount of
$2,149.23.
Award of $2,149.23.
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF HEALTH
(CC-82-332)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $6,686.70 for unemployment compensation tax owed by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections,
14 Ct.Cl. 387 (1983), and,
accordingly, the Court makes an award to the claimant in the amount of
$6,686.70.
Award of $6,686.70.
W. VA.]
REPORTS STATE COURT OF CLAIMS 391
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-82-266)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $1,341.64 for unemployment compensation tax owed by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections,
14 Ct.Cl. 387 (1983), and,
accordingly, the Court makes an award to the claimant in the amount of
$1,341.64.
Award of $1,341.64.
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
FARM MANAGEMENT COMMISSION
(CC-82?261)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $5,308.35 for unemployment compensation tax owed by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections,
14 Ct.Cl. 387 (1983), and, accordingly,
the Court makes an award to the claimant in the amount of $5,308.35.
Award of $5,308.35.
392 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
HUMAN RIGHTS COMMISSION
(CC-82-264)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $13,577.00 for unemployment compensation tax owed by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections,
14 Ct.Cl. 387 (1983), and,
accordingly, the Court makes an award to the claimant in the amount of
$13,577.00.
Award of $13,577.00.
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
INSURANCE COMMISSION
(CC-82-265)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $5,511.92 for unemployment compensation tax owed by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections, 14 Ct.Cl. 387 (1983), and, accordingly,
the Court makes an award to the claimant in the amount of $5,511.92.
Award of $5,511.92.
W. VA.]
REPORTS STATE COURT OF CLAIMS 393
Opinion issued February 14, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
SECRETARY OF STATE
(CC-82-333)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The claimant seeks $2,279.12 for unemployment compensation tax owed by the
respondent.
The factual situation in this claim is identical to that in Dept. of Employment Security vs. Dept. of Corrections,
14 Ct.Cl. 387 (1983), and,
accordingly, the Court makes an award to the claimant in the amount of
$2,279.12.
Award of $2,279.12.
Opinion issued February 14, 1983
FIBAIR, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-196)
Neil A. Reed, Attorney at Law, for claimant.
Stuart Reed Waters, Jr., Attorney at Law, for respondent. RULEY, JUDGE:
Claimant owns property located near Reedsville, in Preston County, upon which
it manufactures fiberglass filter media. On the south or lower side of the
property there is a roadway running generally east and west which provides
access to an industrial park. All surface water accumulating on the north side
of the road, where claimant?s manufacturing plant is located, and at elevations
above it naturally flows toward the
394 REPORTS
STATE COURT OF CLAIMS [W. VA.
road and thence into Kanes Creek which
lies about one hundred yards south of the road. Two twelve-inch storm sewers
satisfactorily provided drainage from claimant?s property to Kanes Creek until
July, 1980.
In June and July, 1980, the respondent improved the access road and redesigned
the storm drainage so as to replace that portion of one of the twelve-inch
storm sewers which ran under the road and which connected catch basins on each
side of the road, directly south of claimant?s warehouse, with an eighteen-inch
storm sewer. This eighteen-inch storm sewer connected with the twelve-inch line
between the road and the creek. Respondent contends that it did not increase
the volume of surface water at that point but that contention is rebutted
persuasively by the undisputed evidence that, when rains subsequently occurred
on July 5, 6 and 7, 1980, water backed up from the twelve-inch line through the
eighteen-inch line and thence through a connecting line, into and through the
floor drains in claimant?s warehouse, causing it to be flooded. Thereafter the
respondent extended the eighteen-inch line to Kanes Creek and that apparently
solved the problem. Because of the flood, and principally as the result of
damage to its products in the warehouse, claimant sustained damage in the sum
of $29,482.48.
Although various imaginative defenses were asserted by the respondent, it
appears that principal reliance is upon the release contained in a deed dated
January 25, 1980, from the claimant to the respondent which reads:
?And for the consideration hereinbefore set forth, the said party of the first
part do (sic.) hereby release the party of the second part from any and all
claims for damages that may be occasioned to the residue of the lands of the
party of the first part by reason of the construction and maintenance of a
state road over, upon and under the tracts or parcels of real estate herein
conveyed.?
In rejecting the defense based upon that release, the Court notes that by its
own terms it is limited to ?damages * * * to
the residue of the lands?, none of which are claimed. In
W. VA.]
REPORTS STATE COURT OF CLAIMS 395
addition, it is clear that damages
such as those which are claimed never were contemplated by either party when
the release was executed. In sum, the damages claimed consisted of the fair
market value of manufactured products which were rendered useless and costs
related to cleaning, all of which were a result of the flood. Accordingly, the
Court is disposed to make an award of $29,482.48.
Award of $29,482.48.
Opinion issued February 14, 1983
JOHN GREY
vs.
BOARD OF EXAMINERS FOR
REGISTERED NURSES
(CC-81- 151)
Claimant appeared in person.
Curtis Power, Assistant Attorney General, and Henry C. Bias, Jr., Deputy Attorney General, for respondent.
RULEY, JUDGE:
Claimant, a registered nurse, seeks $26,100.00 for loss of wages and mental
anguish allegedly resulting from the respondent?s delay in granting him a
license to practice registered professional nursing in West Virginia. Claimant
testified that he was educated at Saddleback Community College, Mission Viejo,
California, where he received a certificate of achievement when he graduated.
Subsequently, he was licensed as a registered nurse in California and then, in
September, 1980, shortly before moving from California to West Virginia,
applied for a license in West Virginia. Claimant testified that, at some
unspecified later time while his application in this State was pending, he
received his A.A. degree. Between September, 1980, and February 2, 1981, the
date on which his West Virginia license was issued, there were various letters
and calls between the claimant, the respondent, Saddleback Community College
and the California Board of Nursing. It does not appear that the claimant ever
forwarded a copy of
396 REPORTS
STATE COURT OF CLAIMS [W. VA.
his A.A. degree to the respondent but,
finally, the respondent did obtain a copy of his college transcript on February
2, 1981, and it issued his license that same day.
West Virginia Code ?30-7-6, provides in part:
?30-7-6. Qualifications and examinations of persons seeking licensure;
applications; practitioners licensed in another state; present practitioners;
fees; temporary permits.
To obtain a license to practice registered professional nursing, an applicant
for such license shall submit to the board written evidence, verified by oath,
that he or she (a) is of good moral character; (b) has completed an approved
four-year high school course of study or the equivalent thereof, as determined
by the appropriate educational agency; and (c) has completed an accredited
program of registered professional nursing education and holds a diploma of a
school accredited by the board.
* * *
The board may, upon application, issue a
license to practice registered professional nursing by endorsement to an
applicant who has been duly licensed as a registered professional nurse under
the laws of another state, territory or foreign country if in the opinion of
the board the applicant meets the qualifications required of registered
professional nurses at the time of graduation.
* *
*,,
The respondent construes the statute to
require documentary evidence of compliance with the qualifications listed in
it. We believe that is reasonable. And, without summarizing the involved
evidence as to who said or wrote what to whom when, we conclude that, while the
claimant may have been distressed by the delay in his license, that delay was
not the result of any unlawful conduct on the part of the respondent and a
large part of it was attributable to his own inaction. Accordingly, this claim
must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 397
Opinion issued February 14, 1983
KANAWHA COUNTY COMMISSION
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-447)
Raymond G. Dodson, Attorney at Law, for claimant. Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations in the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $2,362.08 for waste disposal at Kanawha
County Landfill, a division of the Kanawha County Commission, as per a July 29,
1980 agreement. In April 1981, claimant was advised that because of the wording
of the agreement the State Auditor?s Office lacked the authority to pay certain
invoices. The respondent admits that the charges are valid and reasonable.
Based on the foregoing, the Court hereby makes an award to the claimant in the
amount of $2,362.08.
Award of $2,362.08.
Opinion issued February 14, 1983
LUCAS TIRE, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-83-14)
Robert J. Ashworth, Attorney at Law, for claimant. Nancy J. AlIff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a written stipulation to the effect that the
respondent is liable for damages in the sum
398 REPORTS
STATE COURT OF CLAIMS [W. VA.
of $1,804.07, based upon the following
facts. The claimant is the owner of real property located at 810 Neville
Street, in Beckley, Raleigh County, West Virginia. On January 25, 1981, the
road adjacent to claimant?s property was widened after a portion of the
property was condemned. In the process of excavation, the claimant?s sewer line
was crushed, damaging claimant?s property and necessitating re-excavation and
re-concreting of the pavement. The damage sustained by the claimant was the
result of the negligence of the respondent, and the Court therefore makes an
award to the claimant in the amount stipulated.
Award of $1,804.07.
Opinion issued February 14, 1983
MOORE BUSINESS FORMS, INC.
vs.
DEPARTMENT OF EDUCATION
(CC-82-298)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy
Attorney General, for respondent. PER CURIAM:
The claimant seeks payment of $201.11 for changes made to a classroom
designation form which was ordered by the respondent. Of this amount, $60.97 is
a freight charge, and the remainder, $140.14, is an alteration charge. The
respondent, in its Answer, admits the amount and validity of the freight charge.
James Ruziska, the claimant?s sales representative, testified that a proof
correction form was sent to respondent and returned by the claimant with
several minor corrections. These changes required that the claimant redo the
form. The respondent, however, was not informed of the cost of the alteration
prior to receiving the forms and was not made aware of the fact that a charge
would be made for the alterations.
W. VA.J
REPORTS STATE COURT OF CLAIMS 399
After reviewing the evidence, the
Court cannot find that the respondent is liable for the alteration cost. Even
if, as Mr. Ruziska testified, the charge could not be estimated with certainty
prior to making the changes, it was still incumbent on the claimant to inform
the respondent that a charge would be made. The Court therefore denies the
claim for the alteration charge, and makes an award for the freight charge in
the amount of $60.97.
Award of $60.97.
Opinion issued February 16, 1983
BROWNING-FERRIS INDUSTRIES,
CHEMICAL SERVICE, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-247)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant alleges damages in the amount of $601.71 for repairs made to a
high pressure water truck which struck a piece of concrete on Interstate 64
near Cross Lanes, Kanawha County, West Virginia. The incident occurred August
5, 1982, between 3:00 and 4:00 p.m. Mike Milam, an employee of the claimant,
was driving the truck at the time of the accident. He testified that he was traveling
between 45 and 50 mph, when the car in front of him swerved. Mr. Milam then saw
a triangular piece of concrete pavement which had broken loose and was standing
about a foot above the road?s surface. A portion of the highway had broken
loose which Mr. Milam was unable to avoid. The two left iear wheels struck the
concrete and had to be replaced.
M. W. Hughart, also employed by claimant, testified that he had been aware of
the broken piece of concrete for a week prior to the accident, although the
concrete was lying flat in
400 REPORTS
STATE COURT OF CLAIMS [W. VA.
the road when he saw it. He estimated
its size to be 8 inches thick, 18 inches wide, and 20 inches long. Mr. Hughart
had not contacted respondent about the broken concrete.
Herbert C. Boggs, interstate maintenance superintendent, testified that the
area where the accident occurred is a slide prone area. ?Bump? signs are in
place along this section of 1-64 to indicate that it is slide prone. He stated
that he was unaware of this broken piece of concrete and said that there are
work crews continually patching 1-64, which is in need of repair.
The evidence in this case indicates that a dangerous condition existed on 1-64
for a week prior to this accident. While this Court has repeatedly held that
the State is neither an insurer nor a guarantor of the safety of travellers on
its roads, the unusual circumstances of this case lead us to find that the
respondent was negligent in failing to discover the broken concrete and repair
it. The Court therefore makes an award to the claimant in the amount of
$601.71.
Award of $601.71.
Opinion issued February 16, 1983
DONALD R. HOGSETT
vs.
DEPARTMENT OF HEALTH
(CC-83-16)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted upon the allegations of the Notice of Claim and the
respondent?s Answer.
The claimant was admitted to Huntington State Hospital on December 19, 1982 at
3: 00 a.m. He had in his possession a new jacket, which was on his bed when he
went to sleep. When the claimant woke up, the jacket, valued at $60.00, was
missing.
W. VA.]
REPORTS STATE COURT OF CLAIMS 401
An investigation failed to locate the
jacket. The respondent in its Answer admits the validity of the claim and
requests the claim be honored. In view of the foregoing, the Court makes an
award to the claimant in the amount of $60.00.
Award of $60.00.
Opinion issued February 16, 1983
THOMAS E. LAYTON, II
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-24)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. PER CURIAM:
On September 9, 1982, at approximately 8:00 p.m., the claimant was driving his
1975 Chevrolet Vega on West Virginia Route 2 near Pt. Pleasant, Mason County,
West Virginia. The vehicle struck a bolt, which holds down a metal plate which
is part of a flood gate system installed by the Corps of Engineers and
maintained by the City of Pt. Pleasant. The bolt damaged the exhaust system and
transmission oil pan. The vehicle was repaired at a cost of $235.36. The
claimant testified that the bolt was about 21/2 to 3 inches above the
surface of the pavement, and that the concrete around the bolt had
deteriorated, allowing his automobile to drop even further. He said that he was
aware of the metal plate, but could not say how long the deterioration had been
present.
James L. Metheney, assistant supervisor for Mason County, testified that prior
to the accident, there had been no complaints about the bolts or the pavement
around the bolts. He further stated that the respondent does not maintain the
bolts or plates and presumed that the City of Pt. Pleasant or the Corps of
Engineers would maintain the concrete around the bolt.
402 REPORTS
STATE COURT OF CLAIMS [W. VA.
The Court is of the opinion that the
accident resulted when the bolt worked itself loose from the deteriorating
concrete. Under W.Va. Code ?17-2A-8(i) the State Road Commission has the
responsibility for the general supervision of the State road program and for
the construction, repair and maintenance of State roads and highways. The
deterioration of the concrete could not have occurred overnight, and the
respondent should have been aware of and repaired this dangerous condition
which existed on the surface of its road. The Court therefore makes an award to
the claimant in the amount of $235.36.
Award of $235.36.
Opinion issued February 18, 1983
ARTHUR U. BROWNING
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-50)
HAROLD E. DARLINGTON
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-51)
E. W. DAY
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-52)
C. P. DINGLER
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-53)
RUTH A. DONALDSON
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-54)
W. VA.]
REPORTS STATE COURT OF CLAIMS 403
PETER H. DOUGHERTY
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC?&3-55)
GLEN GREENE
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-56)
GARRY OSBURN
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-57)
SHARRELL STICKLER
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-58)
EUGENE C. SUDER
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-59)
D. M. VANDELINDE
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-60)
LESTER WARNER
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-61)
WETZEL K. WORKMAN
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-62)
404 REPORTS
STATE COURT OF CLAIMS [W. VA.
NAT MARINO
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-108)
NORMA TARR
vs.
OFFICE OF THE SUPREME COURT OF APPEALS
(CC-83-109)
LaVerne Sweeney, Attorney at Law, for the claimants.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
PER CURIAM:
Each of the claimants hereinabove is a magistrate who has petitioned the Court
for the payment of wages not paid in accordance with the results of the 1980
decennial census. Based on our opinion in Graham, et al. v. Office of the Supreme Court of Appeals, 14 Ct.Ci. - (1983),
the Court makes awards for wages which were not paid to the claimants during
the 1981-82 fiscal year.
Award of $4,500.00 to Arthur U. Browning.
Award of $4,500.00 to Harold E. Darlington.
Award of $4,500.00 to E. W. Day.
Award of $4,500.00 to C. P. Dingier.
Award of $4,500.00 to Ruth A. Donaldson.
Award of $4,500.00 to Peter H. Dougherty.
Award of $4,500.00 to Glen Greene.
Award of $4,500.00 to Garry Osburn.
Award of $3,375.00 to Sharreii Stickler.
Award of $3,375.00 to Eugene C. Suder.
Award of $3,375.00 to D. M. VandeLinde.
Award of $3,375.00 to Lester Warner.
Award of $4,500.00 to Wetzei K. Workman.
Award of $4,500.00 to Nat Marino.
Award of $4,500.00 to Norma Tarr.
W. VA.]
REPORTS STATE COURT OF CLAIMS 405
Opinion issued Marcft 11, 1983
CONNIE LAWRENCE BAILEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-389)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. RULEY, JUDGE:
On September 9, 1981, at about 12:30 am., the claimant was driving his 1974
Datsun pickup truck on West Virginia Route 99 near Kopperston, Wyoming County,
West Virginia. Falling rocks struck the truck, which sustained damage of
$1,962.16, rendering it a total loss. West Virginia Route 99 is a blacktopped
highway and is cut through a mountain side at the accident site. High rock
cliffs stand on either side of the highway and ?Falling Rock? signs are located
on both sides of the road. William W. Wood, a maintenance assistant employed by
respondent, testified that respondent had received no notice or forewarning of
this particular rock fall.
This Court has consistently held that the State is neither an insurer nor a
guarantor of the safety of persons travelling its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). The claimant testified that he
travelled the road daily, and knew that the area was prone to falling rocks.
Following Lowe v. Dept. of Highways, 8 Ct.Cl. 210 (1971), this claim must be denied.
Claim disallowed.
Opinion issued Marcft 11, 1983
WILLIAM CONNER AND LOIS CONNER
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-154)
James Allan Colburn, Attorney at Law, for claimants. Douglas Hamilton, Attorney at Law, for respondent.
RULEY, JUDGE:
The claimants own a parcel of property on Hubbard?s Branch
406 REPORTS
STATE COURT OF CLAIMS [W. VA.
Road in Huntington, West Virginia.
Hubbard?s Branch Creek runs through their property and access across it to
their home was provided by a private road. On June 21, 1979, during a heavy
rainstorm, the private road was washed out. The claimants allege that the cause
of the washout was a clogged culvert on the Interstate 64 right-of-way, which
caused the water to back up along Hubbard?s Branch Creek. The culvert became
clogged by refuse which a contractor or subcontractor, working under a contract
with respondent, had dumped near the culvert. Claimants seek an award of
$31,000.00 to rebuild their private road.
Mrs. Conner testified that on several occasions prior to June 21, 1979, she had
seen men dump truckloads of dirt, tree stumps and other debris near the
culvert. Mr. Conner stated that he had followed a truck from a nearby
construction area in Spring Valley which dumped debris near the culvert. The
truck was described as a black truck with an unpainted homemade bed on it. Mr.
Conner said that this dumping occurred, not in the spring of 1979, but in May
through July of 1978. He did not state that he had seen respondent?s trucks
dumping material near the culvert, although Mrs. Conner did. Carol Conner,
daughter-in-law of the claimants, said the dumping occurred in the spring of
1979.
Respondent?s witness, Kevin Reichard, who was superintendent of the Spring
Valley job, testified that the work on the project was performed by a general
contractor, Barboursville Bridge Co., and a subcontractor, Allen Stone Co. He
stated that the dumping on Hubbard?s Branch Creek was done by the contractor.
Furthermore, the material that was dumped came from the contractor?s property,
which was outside the respondent?s right-of-way. Mr. Reichard?s function was to
oversee performance of the contract, which did not include the dumping. From
the foregoing evidence, it is clear that the misconduct, if any, causing
claimants? injury, was committed by an independent contractor. Numerous
decisions of the Court have held that the respondent may not be held liable for
acts of an independent contractor. Safeco Ins. Co. v. Dept. of Highways, 9
Ct.Cl. 28 (1971). Therefore this claim is denied.
Claim disallowed.
W. VA.j
REPORTS STATE COURT OF CLAIMS 407
Opinion issued March 11, 1983
NORMA DORNBOS, d/b/a
THE PARTY BEER STORE
vs.
DEPARTMENT OF WELFARE
(CC-81-92)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
On January 10, 1981, the front window of the Party Beer Store, which is located
in St. Albans, West Virginia, was broken. According to the claimant?s
testimony, Dean Murphy, who is a foster child and a ward of the State, admitted
breaking the window when he fell off his bicycle. Claimant seeks $260.66 to
replace the window.
In order for the Court to make an award in this case, there must be a showing
of negligence on the part of the respondent. The record is devoid of any
evidence of such negligence. The Court therefore denies the claim.
Claim disallowed.
Opinion issued March 11, 1983
CLAUDE W. JARRELL
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-324)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. RULEY, JUDGE:
The claimant was employed by the respondent from 1962 until February 27, 1981.
On January 2, 1979, he was injured in a fall while at work. He visited a doctor
in April 1979, and discovered that he had suffered a broken back in the fall.
The claimant continued to work but was forced to take sick
408 REPORTS
STATE COURT OF CLAIMS [W. VA.
leave periodically until he was
terminated during a general reduction in force. The claimant had 430 hours of
sick leave remaining and claims he should have been allowed to exhaust those
hours before being terminated. He seeks $3,125.00 in compensation for those
hours.
Renee Seefried, respondent?s personnel administrator, testified that there was
no policy that pertained to terminating employees while on sick leave in a
reduction in force situation. The fact that an employee was on sick leave did
not influence the termination. Ms. Seefried stated that ?it was necessary
because of budgetary constraints to fairly quickly and substantially reduce the
number of employees and as I say, with the hundreds of hours of sick leave that
most of our employees have accumulated, this would be, you know, quite a
detriment in removing people from State service quickly.?
The evidence in the record indicates that there was no provision made to
compensate employees for sick leave when terminated as part of a general
reduction in force. There was no policy in existence which required that an
employee, who was on sick leave at the time of the reduction in force, be
allowed to exhaust the balance of his or her sick leave hours before being
terminated. For those reasons, the Court is constrained to deny this claim.
Judge Wallace disqualified himself and did not participate in the consideration
of this claim.
Claim disallowed.
Opinion issued March 11, 1983
LUCILLE LINVILLE
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-58)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. RULEY, JUDGE:
During 1978 and 1979, the claimant?s property on Buffalo
W. VA.J
REPORTS STATE COURT OF CLAIMS 409
Creek at Amherstdale in Logan County
was flooded several times. These floods caused erosion of topsoil and damage to
claimant?s fence and concrete walkway. Claimant presented no written estimate
of the cost of these damages, but estimated herself that repairs would cost
$3,500.00. She alleges that the flooding of her property was in some way related
to Highway Project ER 277, which involved altering the channel of Buffalo Creek
and constructing a new bridge near her property. However, the claimant also
testified that her home was in a low area where water often backed up after a
heavy rain.
Dallas Cary, Project Supervisor for Project ER 277, testified that the project
increased the flow capacity of Buffalo Creek in the area of the claimant?s
property, and that he believed claimant?s flooding problems might be due to
surface run-off from the area behind her property. He further testified that
the water table was very high in that area.
Joe Scarbury, an inspector on Project ER 277, testified that he inspected the
area several times in response to claimant?s complaints of flooding, but found
no water overflowing the creek banks. However, he did observe water percolating
up through claimant?s yard, which he said was the lowest spot in the area.
Testimony failed to establish negligence on the part of the respondent. In
fact, it was never established that the floodwaters on claimant?s property came
from Buffalo Creek, and it seems likely that other factors, such as a high
water table and a low elevation, were the cause of claimant?s flooding
problems. Therefore, the Court is of the opinion that the claimant has not
shown that the damages claimed were the result of actionable negligence on the
part of the respondent, and hereby disallows the claim.
Claim disallowed.
410 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued March 11, 1983
D. ALBERT MOORE
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-97a)
Claimant appeared in person.
Douglas Hamilton, Attorney at Law, for the respondent.
RULEY, JUDGE:
Claimant filed this claim in the amount of $700.00 for the cost of installing
two blacktop aprons at the intersection of Sun Valley Drive and Big Tyler Road,
a state-maintained road, in Cross Lanes. According to the claimant, the apron
installed by the Department of Highways at that intersection was damaged during
snow and ice removal operations, necessitating replacement on two separate
occasions in 1980 at a total cost of $700.00. Claimant presented no receipts
for this work, and could not recall the name of the paving company. In
addition, claimant had no permit for this work. Finally, claimant presented no
evidence that he, or any other party, had at any time contacted the Department
of Highways about this problem.
In sum, the claimant seeks reimbursement for monies allegedly expended in
repairing a public road. While it may be commendable for private citizens to
assist the respondent in the discharge of its duty to maintain the public
roads, it should be virtually needless to say that a private citizen, in the
absence of a contract, is not entitled to be reimbursed for such expense.
Claim disallowed.
W. VA.}
REPORTS STATE COURT OF CLAIMS 411
Opinion issued March 11, 1983
MARTHA C. SCRUGGS
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-428)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
On November 7, 1981, claimant was driving her 1976 Ford on 1-64 near the St.
Albans exit when it struck a ?hunk of steel or iron,? damaging the
undercarriage of the car in the sum of $442.32 (of which all but $140.00 was
paid by the claimant?s insurance).
Claimant testified that she did not know how long the piece of metal, which she
thought might have come off a tractor trailer or endloader, had been in the
highway. There is nothing in the record to indicate to the Court that the
respondent knew of the presence of this piece of metal. This Court has
consistently held that the respondent is neither an insurer nor a guarantor of
the safety of motorists using its highways and that, before an award can be
made in a case such as this, proof, either actual or constructive, that the
respondent was aware of the condition complained of must be presented. Davis Auto Parts v. Dept. of Highways, 12 Ct.Cl. 31 (1977). The Court therefore denies the
claim.
Claim disallowed.
412 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued March 11, 1983
TERRY SKEEN
vs.
BOARD OF REGENTS
(CC-79-194)
Jennifer Bailey and Larry Ellis, Attorneys at Law, for claimant.
Ann V. Dornblazer, Assistant Attorney General, for respondent.
RULEY, JUDGE:
Claimant alleges damages in the amount of $25,000.00 clue to changes in the
requirements for obtaining a Master?s Degree in Correctional Counseling from
the West Virginia College of Graduate Studies at Institute, West Virginia.
These changes allegedly delayed her receipt of the degree for two years and she
claims that, as a result, she was prevented from entering the job market for
two years and suffered anxiety which has required medical treatment.
Claimant was admitted into the master?s degree program in the Summer Term of
1975. She received, following payment of tuition, a catalog of courses for
1974-75, which claimant used to familiarize herself with the master?s degree
requirements to plan her courses. After a year of study, claimant enrolled in a
Practicum Course. This was one of two degree requirements then remaining. The
Practicum was listed as a three- hour course which claimant began in the first
Summer School Term in 1976. Towards the end of that term, the class was
informed that the course would extend through the Second Summer Term. There was
no written notification of that change and a three-hour course usually lasts
for one term. Respondent introduced into evidence the syllabus for the
Practicum which states the amount of counseling hours required to pass the
course and says, ?it is likely that two practicums would be needed to
approximate this recommendation.? Dr. Michael Burton and Dr. John Zarski, the
instructors for the Practicum, both testified that due to the shortened
W. VA.]
REPORTS STATE COURT OF CLAIMS 413
nature of the summer terms, the Practicum
extended over both.
Claimant alleges that she was inadequately supervised during the Practicum. The
testimony established that one of the original instructors for the course
resigned during the summer and Dr. Burton took over. Considerable confusion seems
to have resulted; neither professor seemed sure who had primary responsibility
for evaluating claimant?s work. They agreed, however, that her performance was
not satisfactory at the end of the summer, and that she would need additional
work.
Claimant also alleges difficulties in the administration of the Master?s
Comprehensive Examination (MCE). She took the examination in June 1976, while
working on the Practicum course. This was contrary to the school?s policy
requiring completion of the MCE before taking the Practicum. Claimant was
informed that she had failed one section of the MCE and would have to wait
until the next examination date, October 9, 1976, to take that section again.
She introduced other students who took the same examination, who testified that
they were allowed to do additional research to successfully complete the
examination, without having to wait until October. The examination was also
graded on a plus-minus system, instead of the letter grade provided for in the
course catalog. Claimant alleges that she was treated in an arbitrary manner by
the school officials.
As a result, claimant filed a grievance against the college and was granted a
hearing before the grievance committee on September 12, 1977. The committee
chairman, Dr. William Crockett, testified that the department failed to follow
the letter of the catalog with regard to the Practicum course and the MCE but
that the claimant was not treated differently than other students. The
committee recommended that the claimant be given a ?C? in the Practicum course
and be allowed to retake the failed portion of the MCE. These recommendations
were followed and claimant completed her degree requirements in December 1977,
receiving her diploma in May
1978.
414 REPORTS
STATE COURT OF CLAIMS [W. VA.
As a result of the delay between
claimant?s anticipated graduation date of December 1977, and actual graduation
date of May 1978, claimant alleges that she contracted a manic depressive
illness which has resulted in hospitalization on two occasions. Claimant
remains under medical treatment with therapy and medications; her prognosis is
guarded. At the time of the hearing, claimant was unemployed as a result of her
illness. Dr. Robert Ovington, the psychiatrist treating the claimant, testified
that the claimant was vulnerable to the kind of psychotic breakdown she
experienced when subjected to certain intense pressures. He suggested that
there may be an hereditary predisposition to a manic-depressive condition.
Furthermore, he testified that the home environment in which the claimant was
reared contributed to her condition. Dr. Ovington stated that the troubles with
West Virginia College of Graduate Studies were contributing factors to
claimant?s mental problems.
Dr. Charles C. Weise examined claimant at respondent?s request. In his report,
he stated that claimant?s illness appeared to be produced by a combination of
biological, genetic, psychological, and sociological factors. An individual who
is predisposed to the illness, in about 85% of cases, will have a depressed
episode within six months of a negative life event, but in about 15V of cases
depressed episodes do not have a negative event preceding them. Dr. Weise
stated that it is conceivable that the conflict with the school could have
precipitated an episode of illness but added, ?I do not, however, feel that a
negative event could produce a manic depressive illness in a person otherwise
not vulnerable to it.?
The general rules of law applicable to this case are delineated in 15A Am. Jur.2d
?Colleges and Universities? ?31, where it is stated:
* * Where a student matriculates at a college or
university, a contractual relationship is established under which, upon
compliance with all the requirements for graduation, he is entitled to a degree
or diploma. However, the faculty or other governing board of a college or
university, which is authorized to examine the students
W. VA.]
REPORTS STATE COURT OF CLAIMS 415
and to determine whether they have
performed all the conditions prescribed to entitle them to a degree or diploma,
exercises quasijudicial functions, in which capacity its decisions are
conclusive, except that a degree or diploma may not be refused arbitrarily.?
Although the listing of the Practicum in the Bulletin for 1974- 75 as a
three-hour course may have been misleading and although various other items
among the claimant?s litany of complaints may involve something less than
excellence on the part of faculty or administration, the Court cannot conclude
from all of the evidence that the delay in the award of claimant?s master?s
degree was arbitrary. For that reason, the claim must be denied.
Claim disallowed.
Opinion issued March 11, 1983
BILLY SUTPHIN
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-416)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant is the owner of a 1975 Cadillac which was damaged when it collided
with a manhole located in W. Va. Route 16, in Beckley, on November 6, 1981. The
manhole cover struck the undercarriage of the car and one wheel fell into the
manhole. The claimant incurred $170.15 in towing charges and damage to the
automobile of $756.84.
Charles Bragg, Assistant County Supervisor in Raleigh County, testified that
the manhole cover in question had been in place about six months. During that
time, there had been no complaints about it. The evidence indicates that the
top of the manhole was level with the paved surface of the high-
416 REPORTS
STATE COURT OF CLAIMS [W. VA.
way and offers no clue as to how or
why the accident happened. Since the Court cannot speculate as to that matter,
the claim must be denied.
Claim disallowed.
Opinion issued Marcft 14, 1983
SUSAN L. GREEN
VS.
SUPREME COURT OF APPEALS
(CC-80-385)
Lee H. Adler, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
Claimant was hired in May 1975 as secretary to the Judge of the Circuit Court
of Raleigh County. When she began in this position, her duties were those of a
general secretary. Starting in October 1975 claimant was required to report and
transcribe uncontested divorce cases. She continued to transcribe these cases
until August 1979. Claimant seeks compensation in the amount of $15.00 per
case, which is the fee that had been paid to the previous court reporter.
Claimant?s records indicate that she transcribed 1,529 cases, representing a
claim of $22,935.00.
Claimant testified that the court reporter, prior to October 1975, received a
$15.00 fee, in addition to her regular salary as an employee of the State of
West Virginia, for each uncontested divorce case. In October 1975 there was a
change in court reporters. The new court reporter refused to take uncontested
divorce cases because this $15.00 fee was not going to be paid. Instead, the
fee would be paid to the Circuit Court Clerk?s Office, and then forwarded to
the Treasury of the State of West Virginia. Ms. Green was then assigned the job
of transcribing uncontested divorce cases. Claimant testified that she received
repeated promises of compensation from the Circuit Court Judge. The $15.00 fee
was reinstated
W. VA.J
REPORTS STATE COURT OF CLAIMS 417
September 1, 1979. Claimant sues on a
theory of implied contract, in that she performed work which was beyond her job
description and had been promised compensation for this work. She also advances
a theory of unjust enrichment of the State of West Virginia, in that the State
received both the benefit of her work, as well as the $15.00 fee which was sent
to the State Treasury.
While the Court is sympathetic to the claim presented, we can find no basis
from which to make an award. The transcription of uncontested divorce cases
became a part of claimant?s job which her employer required her to perform. A
change in policy occurred during the 1975-1979 time period, and this policy was
uniformly applied. The $15.00 fee was paid into the clerk?s office even when
someone else performed the transcriptions. After 1979, there was a reversion to
the former policy. The Court must therefore deny the claim.
Claim disallowed.
Opinion issued March 14, 1983
KELLER INDUSTRIES, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC?81?29)
and
RYDER TRUCK RENTAL, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC?80 381)
GaryW. Hart, Attorney at Law, for claimants.
Nancy J. A [1ff, Attorney at Law, for respondent.
WALLACE, JUDGE:
These claims, which were consolidated for hearing, arise out of an accident
which occurred on March 23, 1980, on State Route 50, in Taylor County, West
Virginia. Russell Heatherly,
418 REPORTS
STATE COURT OF CLAIMS [W. VA.
an employee of Keller Industries,
Inc., was driving a truck rented by Keller and owned by Ryder Truck Rental,
Inc. Mr. Heatherly encountered a dropoff in the road, which caused the steering
gear to break. Mr. Heatherly lost control of the truck and an oncoming vehicle
was forced off the road, resulting in damage to both vehicles. An out-of-court
settlement was reached between the driver of the other vehicle and claimant
Keller Industries. Keller seeks $663.44 as the costs incurred in settling that
suit. Claimant Ryder Truck seeks $9,261.63 for towing and repairs on the truck.
The claimants allege that the respondent failed to adequately maintain the road
and to warn travelers of the defective condition of the road. The respondent
contends that a slide area exists in the vicinity of the accident which was not
caused by any action or inaction on its part.
Mr. Heatherly testified that as he drove down Route 50, he encountered a ?hump
in the road? and then hit a rough spot which was six inches to a foot deep. He
said that the only sign he could remember seeing was a curve sign. Mr.
Heatherly stated that he drove back over this stretch of road two or three days
later and observed new rough road signs.
John William Bishop, supervisor of the sign and paint shop in District 4, which
includes Taylor County, testified that the signs on Route 50, in the area of
the accident, were checked on January 3, 1980. At that time, hazard boards,
rough road signs, and curve signs were in place. He said that while he had no
personal knowledge that the signs were in place on March 23, 1980, there were
no records of work being done on the signs after that date. Had a sign been
removed or knocked down, his office would be aware of that fact within a day. A
photograph taken on the day of the accident shows what appears to be a hazard
paddle located near the site where the truck went off the road.
Barney Stinnett, a soils engineer employed by respondent, stated that the
hillside above Route 50 is a deep slide area which was caused by strip mining.
The magnitude of the slide involved is greater than any for which a slide
correction has been attempted. Paul Curry, road maintenance supervisor
W. VA.]
REPORTS STATE COURT OF CLAIMS 419
for Taylor County, testified that the
area of Route 50 at the accident site is a trouble area. He estimated that the
road could sag up to a foot within an hour. A maintenance log introduced into
evidence showed numerous patching jobs on this stretch of road.
There can be no doubt that the stretch of Route 50 in question is a potential
hazard due to its unstable condition. There is also no doubt that the
respondent has monitored the road and placed signs warning of the danger. There
is little else the respondent could do short of closing down the road or
undertaking a massive correction project. The State is neither an insurer nor a
guarantor of the safety of persons traveling on its highways. Adkins v. Sims, 130 W.Va. 645 (1947). For negligence of the respondent to be shown,
proof of notice of the defect in the road is required. Davis Auto Parts v. Dept. of Highways, 12 Ct.Cl. 31 (1977). While the road is a potential
danger, Mr. Heatherly testified that he had driven the road a ?hundred? times
before and knew the road was rough. Under the doctrine of comparative
negligence, the Court is of the opinion that the negligence of the driver was
equal to or greater than the respondent?s and disallows the claims.
Claims disallowed.
Opinion issued March 14, 1983
CARL R. MOORE
vs.
GOVERNOR?S OFFICE OF ECONOMIC AND
COMMUNITY DEVELOPMENT
(CC-80- 137)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
This claim, in the amount of $1,299.23, is for overtime pay which claimant
alleged he is owed for work performed for the Governor?s Disaster Recovery
Office, which is now an office of the respondent agency. Prior to December of
1978,
420 REPORTS
STATE COURT OF CLAIMS [W. VA.
claimant was working within the Office
of Economic and Community Development (OECD), under an assignment contract from
the Farmers Home Administration (FmHA), an agency of the federal government.
The FmHA paid the claimant?s salary. In December of 1978, claimant was
transferred to the Disaster Recovery Office to manage a disaster center.
Claimant?s salary was to be paid by the FmHA, and the State of West Virginia
would reimburse the FmHA for 55% of the basic salary.
During claimant?s tenure with the Disaster Recovery Office, from December 1978
to January 1979, he worked 85 overtime hours. There was no provision in the
contract between the respondent and the FmHA to provide overtime payments.
However, the claimant testified that there was an understanding between the
agencies that overtime at the rate of time and a half would be paid. Claimant
has made numerous attempts to secure payment, but his requests have been
denied.
It is obvious to the Court that it lacks the jurisdiction over this claim. The
respondent is not the claimant?s employer. His contract was with a federal
agency and that agency paid his salary. Any claim for overtime must be made to
that agency. The court must therefore deny the claim.
Claim disallowed.
Opinion issued March 14, 1983
GEORGE A. STOVER AND
CARMA STOVER
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-261)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
At 6:30 p.m., Sunday, July 19, 1981, claimant Carma Stover was driving a 1975
Chevrolet north on Route 62 near Buffalo in Putnam County at a speed of
approximately 30 m.p.h.
W. VA.] REPORTS STATE
COURT OF CLAIMS 421
when she encountered mud in the northbound lane, causing her vehicle to slide
off the road and into a ditch. Route 62 is a paved, two-lane roadway, straight
and level at the accident site. Claimants contend that the mud was left on the
road by Department of Highway personnel, who had been ditching along Route 62
during the week of July 13-17, 1981. The claim is for damage to the vehicle in
the amount of
$677.35.
Mrs. Stover testified that she had driven over the accident site every day
during the week preceding the accident, and that on Saturday, July 18, she had
noticed dirt on the road surface. As she approached the accident site on
Sunday, July 19, she observed an area of mud approximately one inch thick
covering her entire lane before she actually drove into it, but did not reduce
her speed between the time that she noticed the mud and the time that she drove
into it.
John Johnson, Putnam County Road Supervisor for the Department of Highways,
testified that DOH personnel had been ditching along Route 62 during the week
of July 13-17, and that the road surface had been scraped and cleaned when the
ditching was completed. He observed a small amount of dirt on the road surface
when work stopped on Friday, July
17. On Monday, July 20, he visited the accident site and found no mud or debris
of any type on the road surface.
Donald Atkins, Road Foreman for the Department of Highways, testified that he
observed personnel of the respondent cleaning the road surface with a grader at
the completion of the job on Friday, July 17.
The duty of the State to a traveller is a qualified one, namely, that of
reasonable care and diligence in the maintenance of a highway under all
circumstances. Parsons v. State Road
Commission, 8 Ct.Cl. 35 (1969).
Testimony given by Mr. Johnson and Mr. Atkins established that the Department
of Highways carried out this responsibility. The State neither insures nor
guarantees the safety of motorists travelling its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). For the respondent to be found
liable for damages caused by a road defect of this type, the claimant must
prove that the respondent had actual or constructive knowledge of the defect
plus a
422 REPORTS STATE
COURT OF CLAIMS [W. VA.
reasonable amount of time to take corrective action. Since the claimant
presented no evidence to that effect and did not meet the burden of proof, the
claim must be disallowed.
Claim disallowed.
Opinion issued March 14, 1983
UNITED FARM BUREAU
MUTUAL INSURANCE COMPANY
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-82-93)
Ralph C. Dusic, Jr., Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
A 1978 Pontiac Sunbird was stolen from its owner, Gay Burrows, on or about
January 11, 1979. Ms. Burrows, who had insured the vehicle with the claimant,
received the full cash value for the vehicle from the claimant, in exchange for
the title to the vehicle. At some time prior to June 25, 1979, the respondent,
Department of Public Safety, came into possession of the vehicle. On or about
June 26, 1979, the claimant was informed by respondent?s employee, Officer
Pennington, that the vehicle was located at respondent?s headquarters in
Princeton, West Virginia. The investigation into the theft of the automobile
was incomplete at that time. Officer Pennington informed the claimant that the
vehicle could not be released, and any charges against the vehicle would be
less than $40.00. Between June 1979 and June 1980, claimant contacted
respondent on several occasions and was informed that the vehicle could not yet
be released, and that the vehicle was being stored on the respondent?s impound
lot in Princeton with no storage charges being levied against claimant.
On June 30, 1980, claimant contacted the National Automobile Theft Bureau
(NATB) to try to regain possession of the automobile. In June 1981, claimant
learned that the vehicle had been removed from respondent?s impounding lot by
Danieley, Inc., of Princeton, West Virginia, and had been
W. VA.]
REPORTS STATE COURT OF CLAIMS 423
stored by Danieley, Inc., since May 5,
1980. Towing and storage charges were assessed against claimant from May 5,
1980. On or about July 14, 1981, claimant was informed that a lien had been
filed against the vehicle by Danieley, Inc., and that the vehicle would be sold
at public auction. Claimant then filed suit in the Circuit Court of Mercer
County to obtain possession of the automobile. Claimant paid $2,136.50 to
Danieley, Inc. for towing and storage charges; $507.50 for attorney?s fees;
$120.00 in court costs; and $1,816.75 for services rendered by Crawford and
Company to obtain possession of the automobile. Claimant also alleges that as a
result of the arbitrary, careless and negligent conduct of respondent, claimant
has incurred total losses of $6,080.75, and further requests interest of 10%
per annum from May 5, 1980.
The respondent, in its Answer, alleges that at the time the claim was filed,
April 5, 1982, the automobile was being held by the Prosecuting Attorney of
Mercer County. The vehicle was turned over to the Prosecuting Attorney in 1980,
to be used as evidence in the trial of the individual accused of stealing the
automobile, and had been under the control of the Prosecuting Attorney since
that time. The evidence indicates that the charges against the vehicle were
assessed after the vehicle left the possession of the respondent. The
respondent had no control over the vehicle, and canrot, therefore, be found
liable for the charges assessed after turning the vehicle over to the
Prosecuting Attorney. The Court must deny the claim.
Claim disallowed.
O?pinion issued March 16, 1983
JAMES E. BAILEY, JR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-80- 145)
Claimant appeared in person.
Douglas Hamilton, Attorney at Law, for respondent.
RULEY, JUDGE:
Claimant filed this claim against the Department of High-
424 REPORTS STATE
COURT OF CLAIMS [W. VA.
ways seeking to recover $616.20 which he expended for repairs to a broken water
line near his home in Bluefield on December 17, 1979, and January 8, 1980. The
water line in question runs underneath W.Va. Route 290 and U.S. Route 460; the
two breaks occurred at the same spot, in an area between the two roads,
slightly north of W.Va. 290, on the State right- of-way.
The claimant testified that the pipeline was installed in 1976 by West Virginia
Pipe Line, Inc., an independent contractor, and that the same company repaired
the two breaks in the line. Claimant testified twice that he did not know the
cause of the breaks, but later stated that he thought they were caused by
settling of the ground between the two roadways.
In sum, the evidence disclosed that: a water line installed on a State
right-of-way by a private contractor had broken on two separate occasions, each
time in the same spot; that on each occasion, the same private contractor
repaired the breaks; and that the cause of the breaks was unknown.
The Court fails to see how the Department of Highways can be held liable for
these damages. For an award to be made, it must be proved that some negligent
act or omission of the respondent proximately caused the damage sustained by
the claimant. The evidence presented did not meet this burden of proof, and
thus the claim must be denied.
Claim disallowed.
Opinion issued March 16, 1983
WAYNE K. BAKER, d/b/a
BAKER COAL COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC?80-405)
Andrew Fusco, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, and Henry C. Bias, Jr., Deputy
Attorney General, for respondent.
WALLACE, JUDGE:
In August 1980, severe rains caused flooding in Monongalia
W. VA.] REPORTS
STATE COURT OF CLAIMS 425
County, West Virginia, washing out a number of roads. The respondent used rocks
to stabilize stream banks along many of these roads. On August 20, 1980, the
claimant was requested to furnish rocks, which were a by-product of claimant?s
strip mining operation. Rocks were loaded on respondent?s trucks between August
20 and October 6, 1980. The respondent has refused to pay for the rock supplied
by the claimant and the claimant now seeks an award of $22,800.00 for the rock.
The evidence elicited at the hearing was in conflict on the question of whether
the respondent was informed that payment would be requested for the rock. It
was uncontroverted that the respondent took a quantity of rock, which the
claimant estimated at 475 truckloads, of 16 tons each, at $3.00 a ton. No
records were kept for the entire period. One of claimant?s employees kept an
informal record for part of the time, but the record was lost.
It is clear from the evidence that the failure of the parties to make their
intentions known has left the parties in an ironic position. The respondent
could have received rock from another mine site for free, but went to Baker
because it was closer. The claimant had a client to buy its rock for $3.00 a
ton, but instead furnished the rock to the respondent. The respondent has
received a commodity and for this, there is liability. As there was not
adequate evidence produced to show that 475 loads of material was taken, the
Court makes an award based on a figure of 187.5 loads. The Court has determined
from the evidence that an average of one to five trucks hauling an average of
one to five loads per day for a 30-day period, with 16 tons per load would
total approximately
3000 tons of rock. Based upon the $3.00 a ton figure at which the claimant
normally sold the rock, the Court hereby makes an award of $9,000.00.
Award of $9,000.00.
426 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued Mardi 16, 1983
DAVID R. BASSETT
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-294)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim for $167.62 arises out of damages sustained by the claimant?s 1978
Chevrolet Monza. The accident occurred between 11:00 p.m. and 12:00 midnight on
October 16, 1982, on 1-79 at the bridge in Elkview, West Virginia. The approach
to the bridge was being paved, and, when the claimant entered the bridge
approach, he struck a hole where excavation had been done. The right ball joint
of the automobile snapped, causing a loss of steering. The claimant testified
that he saw a sign, which said either ?Slow? or ?Bump?, which was placed about
100 feet from the bridge. He stated that he saw tne light on the sign when he
was a quarter of a mile from
it. The claimant said, however, that the sign was inadequate warning and he
therefore had not slowed down enough to avoid the accident.
Herbert C. Boggs, interstate supervisor, testified that there were construction
signs on both sides of the road at Elkview, as well as the lit ?Bump? sign. He
said that a ?Bump? sign is normally placed about 100 feet in front of the bump.
The law of West Virginia is well established that the State neither insures nor
guarantees the safety of motorists upon its highways. Adkins v. Sims, 130 W.Va. 645 (1947). However, the respondent does owe a duty of
exercising reasonable care and diligence in the maintenance of the highways.
It is the opinion of the Court that the respondent has met its duty of
reasonable care under the circumstances of this case. The Court must therefore
deny the claim.
Claim disallowed.
W. VA.J REPORTS
STATE COURT OF CLAIMS 427
Opinion issued March 16, 1983
C. W. LEWIS, INC.
vs.
DEPARTMENT OF CORRECTIONS
(CC-82- 103)
Ralph Hanna, Jr., appearing as representative of C. W. Lewis, Inc.,
claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim, for $410.20, is for work allegedly performed on the brakes of a
1966 Chevrolet bus, used at respondent?s Anthony Correctional Center, at Neola,
West Virginia. According to Ralph Hanna, Jr., President of C. W. Lewis, Inc.,
of White Sulphur Springs, West Virginia, the work was performed on December 5,
1980. Two bills, one for $326.15 and the other for $84.05, were introduced into
evidence. Mr. Hanna explained that Everett Norton, the purchasing officer at
the Anthony Center, requested two bills because he could not authorize a bill
of over $400.00. There was no written authorization for the work, only oral
from Mr. Norton. While this authorization was not received until after the work
had been performed, Mr. Hanna stated that unless there is a question concerning
the owner?s credit, his company does not consult the owner prior to making the
repairs.
In view of the evidence presented, the Court has concluded that to deny the
claim would result in unjust enrichment of the respondent. Previous decisions
of the Court have made awards for goods or services furnished by a claimant in
the absence of proper authorization. Respondent?s witness, Steven Farren, an
instructor at Anthony Center, testified that the brakes were not improved by
the repair work; however, the brakes were repaired in December 1980, and the
witness did not drive the bus until sometime in February 1981. There was no
evidence presented which would indicate that the claimant was made aware of
this fact, and Mr. Hanna testified that the work was guaranteed. The Court
therefore makes an award in the amount of $410.20.
Award of $410.20.
428 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued March 16, 1983
DOY P. CRITES
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-378)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant in this case seeks compensation for property taken by the
respondent in widening and moving Route 36 in Sutton, Braxton County, West
Virginia. Approximately one half of an acre of claimant?s land was taken in the
process of moving the roadbed. The respondent filed a Motion to Dismiss, as the
claim is the proper subject for condemnation. It appears to the Court that the
claimant has an adequate remedy at law; therefore, the motion should be
sustained based on the provisions of West Virginia Code ?14-2-14(5). The Court
therefore orders that the claim be dismissed.
Claim dismissed.
Opinion issued March 16, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF FINANCE & ADMINISTRATION
(CC-82-335)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim for $6,457.34 arises out of the payment of unemployment security
benefits to two former employees of the respondent. The claimant seeks
$5,403.08 as the amount of the benefits and $1,054.26 as accumulated interest.
W. VA.]
REPORTS STATE COURT OF CLAIMS 429
The first employee received benefits
totalling $3,640.00 following his dismissal from respondent?s employ. He was
reinstated, with full back pay after appealing his dismissal through the Civil
Service Commission and the West Virginia Supreme Court. Under West Virginia
Code ?21A-6-1 (4), he was not eligible for the benefits received because he was
not totally or partially unemployed for the period in question.
The second employee was dismissed from his position for misconduct. He received
$1,763.08 in benefits before a Board of Review Decision held him ineligible for
those benefits.
West Virginia Code ?21A-7-11 governs the payment of benefits pending appeal.
This section states in part:
?If the final decision in any case determines that a claimant was not lawfully
entitled to benefits paid to him pursuant to a prior decision, such amount of
benefits so paid shall be deemed overpaid. The commissioner shall recover such
amount by civil action or any manner provided in this Code for the collection
of past-due payment and shall withhold, in whole or in part, as determir!ed by
the commissioner, any future benefits payable to the individual and credit such
amount against the overpayment until it is repaid in full.?
As this section indicates that overpayments to an individual are to be
collected from that individual and not from the agency which employed him, the
Court denies the claim.
Claim disallowed.
Opinion issued Marth 16, 1983
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF HEALTH
(CC-82-263b&c)
Jack 0. Friedman, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
These two claims are for unemployment compensation tax
430 REPORTS
STATE COURT OF CLAIMS [W. VA.
arising for the quarters ending March
31, 1972, June 30, 1972, and June 30, 1977. Claim No. CC-82-263b is for
$52,730.71, of which $28,296.17 is the amount of the tax and $24,434.54 is
accumulated interest. Claim No. CC-82-263c is for $21,213.07, of which
$9,490.64 is the amount of the tax and $11,722.43 is accumulated interest. The
respondent, in its Answer, denies any liability for the tax based on the
statute of limitations. The Court finds that under W.Va. Code ?55-2-6, the
five-year statute of limitations applies. As no action was taken on these
claims until October 5, 1982, the claims are barred by this statutory
provision.
Any claim for accumulated interest is denied based on our opinion in Dept. of EmpLoyment Security vs. Dept. of Corrections, 14 Ct.C1 (1983).
Claims disallowed.
Opinion issued March 16, 1983
IDA M. HINER AND NORMAN F. HINER,
d/b/a HERCULES CONSTRUCTION COMPANY
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-80-150)
Fred A. Jesser, III, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, and Leonard Knee, Assistant
Attorney General, for respondent.
PER CURIAM:
In an opinion dated December 3, 1980, the Court dismissed the claimants?
complaint for failure to state a claim upon which relief could be granted. The
Court, however, granted the claimants leave to file an amended notice of claim,
and the matter is now before the Court upon the respondent?s motion to dismiss
the amended notice.
The basis of the claim is that the Director, Department heads and other
employees of the respondent formed a conspiracy as a result of which the
claimants were required to forfeit a
W. VA.] REPORTS
STATE COURT OF CLAIMS 431
bond which had been posted as security for a strip mining permit, and deprived
of the privilege to mine coal on property owned by them.
In our earlier decision, we cited 16 Am. Jur. 2d ?Conspiracy,? ?67,
in which it is stated:
?The rules governing pleadings in conspiracy actions are not materially
different from those applicable to other actions. The complaint must state
facts that constitute a cause of action, that is, the complaint must allege the
formation and operation of the conspiracy, the wrongful act or acts done
pursuant thereto, and the damage resulting from such act or acts. Facts, not
legal conclusions, must be pleaded, including facts showing damages.?
The amended notice also fails to allege such facts. The legal conclusion that a
conspiracy existed is insufficient to state a cause of action. The Court
therefore sustains the respondent?s motion to dismiss the amended notice of
claim.
Claim dismissed.
Opinion issued Mardi 16, 1983
CHARLES E. MOORE
vs.
DEPARTMENT OF PUBLIC INSTITUTIONS
(CC?76?127)
I-I. John Rogers, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
The claimant entered a plea of guilty to an indictment charging incest, and on
May 15, 1961, he was sentenced to a definite term of five years. The applicable
statute, West Virginia Code ?61-11-16, provides for a mandatory indefinite
sentence of five to ten years. The Prosecuting Attorney and claimant?s
court-appointed counsel mistakenly informed him that he could be sentenced to
the definite five-year term.
432 REPORTS
STATE COURT OF CLAIMS [W. VA.
Upon claimant?s arrival at the West
Virginia Penitentiary, his sentence was administratively changed to a
five-to-ten- year sentence. By Federal Court Order entered on September 4,
1964, the claimant?s conviction was declared null and void and he was released
from confinement. Claimant seeks $4,000,000.00 in damages as a result of his
alleged illegal incarceration.
The respondent, in its Answer, moves to dismiss, or, in the alternative, moves
for summary judgment based upon the Notice of Claim. The grounds for the Motion
to Dismiss is that the claim is barred by the applicable statute of
limitations. This claim was filed with the Court on October 27, 1976. As this
is more than ten years from the time of the alleged wrong, the Court sustains
the respondent?s Motion to Dismiss.
Claim dismissed.
Opinion issued March 16, 1983
ROBERT G. RINER
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-288)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant?s automobile, a 1973 Cadillac, was damaged in the sum of $244.25
at about 10:00 a.m. on Monday, October 18, 1982, at the intersection of Center
Street and Second Avenue in Prosperity, Raleigh County, West Virginia. Center
Street was in the process of being repaved at the time of the accident. As the
claimant turned off of Center Street and onto Second Avenue, he encountered a
drop-off where the pavement had not been levelled with Second Avenue. The
claimant testified that the drop-off was about a foot high but Bobby Daniels,
an employee of the respondent, testified that the drop-off was about six
inches. Respondent?s employees had begun the
W. VA.]
REPORTS STATE COURT OF CLAIMS 433
paving operation the previous Friday,
but stopped when the paving machine broke down. The asphalt was raked down to
try to even out the road, and the work crew returned on the day of the accident
to finish the project.
The evidence clearly established that the respondent created a hazardous
condition in the roadway. However, it was also established with equal clarity
that the claimant was aware of that condition.
He testified that he had driven another vehicle over the same drop-off the
night before. At the time of the accident, the claimant testified that he drove
over the drop-off slowly, believing his car would not drag, but, unfortunately,
it di?l with the resulting damage to the exhaust system. In view of the
circumstances, it appears that the claimant was guilty of negligence which
equalled or exceeded that of the respondent; therefore, the claim must be
denied.
Claim disallowed.
Opinion issued March 16, 1983
CALVIN L. SARGENT
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-319)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant?s vehicle, a 1973 Volkswagen Beetle, was damaged on November 22,
1982, when he struck a rock on U.S. Route 60 west of Montgomery, West Virginia.
The accident occurred at approximately 6:40 am. on a foggy morning. The
claimant testified that he did not see the rock, which was three to four feet
long and two feet high, until he was almost upon it. The vehicle sustained
damages in the amount of $1,410.19.
434 REPORTS
STATE COURT OF CLAIMS [W. VA.
Carl E. King, maintenance foreman for
Kanawha County, stated that time sheets indicated a rock slide had occurred in
the area that day. There was a complaint received, but he did not know at what
time it was received. The slide was removed that clay.
The State is neither an insurer nor a guarantor of the safety of motorists on
its highways. Adkins v. Sims, 130 W.Va. 645 (1947). For the respondent to be liable
for damages in this case, the claimant must prove that the respondent had
actual or constructive notice of the defect and a reasonable amount of time to
take suitable corrective action. Davis
v. Department of Highways, 11 Ct.C1.
150 (1976). The Court is of the opinion that the claimant failed to meet this
burden of proof and therefore denies the claim.
Claim disallowed.
Opinion issued March 16, 1983
ROBERT VARNEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-304)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
The claimant is the owner of a 1981 Chevrolet Monte Carlo. On November 7, 1982,
at approximately 9:30 p.m., the claimant was a passenger in his automobile
which was being driven by his nephew on Route 52 near Crum, Wayne County, West
Virginia. The automobile struck a pothole measuring approximately sixteen
inches by twenty inches. The right front tire, rim, and wheel cover had to be
replaced at a cost of
$208.97.
The State neither insures nor guarantees the safety of motorists travelling on
its highways. Acikins v. Sims, 130 W.Va. 645 (1947). In order for negligence to be
shown, proof of
W. VA.]
REPORTS STATE COURT OF CLAIMS 435
notice, either actual or constructive,
must be shown. As there was no positive showing of notice to respondent, the
claim must be denied.
Claim disallowed.
Opinion issued Marc ft 16, 1983
XEROX CORPORATION
vs.
DEPARTMENT OF NATURAL RESOURCES
(CC-82-236)
R. Edison Hill, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy .Attorney General, for respondent. WALLACE,
JUDGE:
In September 1981, claimant entered into an agreement with the Water Resources
Division of respondent agency for the rental of a Xerox Model 8200 copying
machine. The machine was installed on a limited trial basis, and on September
25, 1981, Lendin Conway, the property officer of the Division of Water
Resources, signed a contract with claimant. Under the contract, respondent
would pay a basic monthly charge of $1220.00, plus a usage fee for copies in
excess of 30,000. The machine was removed eight months later because of
nonpayment. Rental and removal charges amount to $12,065.88. The respondent
alleges that no contract was made because of the failure of the Department of
Finance and Administration to approve the contract. At the hearing, respondent
suggested that any award be limited to a quantum meruit recovery.
The Court is of the opinion that the claimant is entitled to some recovery?the
respondent benefited from the use of claimant?s copier for eight months. The
difficulty lies in deciding the amount of recovery. In order for the contract
signed by Mr. Conway to be valid, approval, in the form of a purchase order
from the Department of Finance and Administration, had to be issued. This
approval was not obtained. Mr. Conway testified that his ?understanding at the
signing of the agree-
436 REPORTS STATE
COURT OF CLAIMS [W. VA.
ment was that the approval was just a formality and there would be no problem
with it.? He was unaware of the necessity of a purchase order. Linda J0
Thompson, a senior marketing representative with Xerox, testified that she was
unaware of any requirement of a purchase order for the lease of a copier.
While the Court recognizes that the claimant is entitled to a monetary award on
a quantum meruit basis, the Court is also unable to determine the damages as
the claimant has not provided the Court with the data necessary to make this
determination. Therefore, the Court directs the claimant and the respondent to
agree upon an amount fair to both parties based upon the reasonable value of
the use of the equipment rented by the respondent. The claim will be held open
for 60 days for such agreement to be filed with the Court.
Opinion issued March 16, 1983
MARTHA P. YOAK, BY HER AGENT,
JUDSON K. YOAK
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-380)
Judson K. Yoalc appeared for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
The claimant is the owner of a parcel of real property located on Route 16 near
Grantsville, Calhoun County, West Virginia. In March or April 1977, a portion
of the land along Route 16 began to slip. According to the testimony of the
claimant?s son, the respondent would repair the slip and shortly thereafter, it
would begin again. In December 1978, the respondent performed a slide
correction which involved moving the road eastward, away from the slip and the
claimant?s property. The claimant?s son stated that the respondent dumped dirt
from the construction area onto his mother?s
W.VA.] REPORTS
STATE COURT OF CLAIMS 437
property, and that the slide has
continued to damage the property. The slip was estimated at 54 feet wide and
300 feet long. The claimant seeks damages in the amount of $60,000.00.
The claimant?s son testified that the repeated slips caused dirt and debris to
come onto his mother?s property, but that no damage occurred to any structure
on the land. An appraisal of the property made by the claimant?s son did not
reflect a decrease in the monetary value of the land due to the slip. An
appraisal report submitted by respondent established a decreased value of
$1,000.00.
Samuel H. Beverage, assistant district engineer in charge of maintenance,
described the area and the relocation of the road. He stated that the area was
slide prone, and that the soils have a safety factor of about one ?which means
that they are just on the balance of being stable or unstable so anything that
would upset that balance to make that factor of safety drop below one would
cause or create possibly a slip.? Saturation of the soils with water is the
usual reason for a slide to begin. The correction project, which involved
relocating the road and putting predrilled piling into the slip area, benefited
the claimant by preventing more material from coming onto the property. Mr.
Beverage stated that he did not recall seeing any prior construction or any
evidence of a drainage system installed by respondent which would have
contributed to the slide.
Alton Smith, district supervisor involved in the relocation project, testified
that a site was obtained to dump the waste material from the project. He stated
that as far as he was aware, all the waste was deposited on this site.
From the evidence presented in the claim, the Court is of the opinion that
there was insufficient proof of any acts or omissions by the respondent which
were the proximate cause of the claimant?s damages. The slide appears to be
caused by the natural movement of unstable soils. This being the case, the
Court must deny the claim.
Claim disallowed.
438 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued April 22, 1983
BECKMAN INSTRUMENTS, INC.
vs.
DEPARTMENT OF HEALTH
(CC-83-30)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of $198.50 representing an unpaid invoice for a monthly
charge on answer pak agreement 679131. The unpaid invoice was billed in May
1982, for invoice date May 7, 1979. In its Answer, the respondent admits the
validity of the claim and states that sufficient funds were on hand from which
to pay the claim.
The Court therefore makes an award to the claimant in the amount of $198.50.
Award of $198.50.
Opinion issued April 22, 1983
ANNA LOU BOOTEN
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-176)
WILLARD LUCAS
vs.
DEPARTMENT OF HIGHWAYS
(CC?81-177)
W. VA.]
REPORTS STATE COURT OF CLAIMS 439
GLEN L. RAMEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-178)
H. R. ARROWOOD
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-180)
William L. Redd, Attorney at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
These four claims were consolidated for hearing as all arise from the same
factual situation. The claimants are landowners on Beech Fork Road, Lavalette,
Wayne County, West Virginia. Situated from west to east on the south side of
Beech Fork Road is a mobile home owned by Mr. Lucas, a mobile home owned by
Mrs. Booten, the Ramey house, and the Arrowood house. Mrs. Booten also owns a
house located on the north side of Beech Fork Road, almost across from the
Lucas mobile home. She resides in this house. The claimants allege damage to
their properties due to the respondent?s failure to provide adequate drainage
for the area.
Claimant Ramey has made two prior claims for damage to his land. The first claim
was disallowed. The claimant then obtained legal counsel, and the Court granted
a Motion for Rehearing. In the second proceeding, the claimant was awarded
$4,933.13 for damages resulting from the respondent?s failure to maintain two
culverts and ditch lines. This failure allowed water to drain onto the Ramey
property. The claimants presently allege that subsequent repair work performed
by the respondent has caused further damage to all four properties.
The repair work involved deepening a ditch line between
440 REPORTS
STATE COURT OF CLAIMS [W. VA.
the Arrowood and Ramey properties. Mr.
Arrowood testified that his yard has settled since the work and cracks have
developed in one corner of his house. He had no estimates of the amount of
damage to the house.
According to Mr. Ramey, his property has been flooded when it rains. There has
also been a problem with raw sewage rising to the surface when it rains.
Similar complaints were voiced by Mr. Lucas and Mrs. Booten, but none presented
any evidence of damages.
Mary Sue Malik, a sanitarian for the Wayne County Health Department testified
that there is a septic system located behind the Booten mobile home. This
system was malfunctioning. She stated that this malfunction was ?probably?
caused by surface water, although the adjacent septic system on the Lucas
property was functioning properly.
An appraiser employed by the respondent, Joel Nunes, visited the Ramey property
in July 1980, and April 1982, and in his opinion the land was in better
condition on the latter date. Two engineers also testified for the respondent.
David Bevins, assistant maintenance engineer, stated that the ditch line in
question was an improvement to the existing drainage system. There has been no
other changes to the natural drainage in the area by the respondent. Frank
Hamrick, roadway design engineer, studied the drainage system at the claimants?
properties, and found it adequately designed for the age of Beech Fork Road. He
stated that the land slopes downward from the Booten house to the other
properties, with the Ramey land being the lowest point. The drainage problems,
in his opinion, are due to water running through the septic tank field and not
from drainage from the roadway.
From the evidence adduced at the hearing, the Court cannot find that the
problems were caused by the actions of the respondent. It appears that two
other factors are involved. The first is the natural drainage of the area. The
second is the inadequate septic system on the Booten property. If the surface water
were the sole source of the malfunction in the septic system, it would seem
likely that the adjacent system
W. VA.]
REPORTS STATE COURT OF CLAIMS 441
would be similarly affected. The
Court, therefore, disallows the claims.
Claims disallowed.
Opinion issued April 22, 1983
JAMES BURCHAM and
PATRICIA J. BURCHAM
vs.
DEPARTMENT OF HIGHWAYS
(CC-80?252)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
Claimants reside on Locust Hill Road in Chester, Hancock County, West Virginia.
Their home is a four-room structure which is located on the south side of
Locust Hill Road. There is a hillside to the north. On May 20, 1980, at
approximately 2:00 a.m., two trees fell across the house. These trees had been
situated five or six feet from the road, and were caught in a slide in which a
portion of Locust Hill Road gave way. A ditch line along the north side of the
road was clogged, and the claimants allege that this condition caused the
slide. The claimants incurred $2,006.67 in damages.
Elmer Shepherd, then general foreman in respondent?s Hancock County Office,
testified that the clogged ditch line caused water to run down the hill onto
the Burcham property, and, in his opinion, this water ?helped create the
slide.? The ditch line is required to be pulled, i.e., cleaned and cleared,
every two years, and in Mr. Shepherd?s inspection of respondent?s records, the
ditch line was last pulled January 2, 1980. However, this pulling was performed
on only a portion of Locust Hill Road, and did not include the area where the
slide occurred. Mr. Shepherd reviewed the records back through February 1979,
and found no evidence that this portion of the ditch line had been pulled.
442 REPORTS
STATE COURT OF CLAIMS [W. VA.
The respondent is charged with the
legal duty to use reasonable care to maintain a ditch line in such condition
that it will carry off surface water and prevent its passage upon adjacent
properties. Stevens v. Dept. of
Highways, 12 Ct.Cl. 180 (1978). The
respondent apparently failed to discharge that duty, and, as a result, the
claimants? damage occurred.
In making an award, however, the Court must also look to the action or inaction
of the claimants. Although the claimants were aware of the clogged condition of
the ditch line, they never made any complaint to the respondent. For that
reason, the Court finds that the claimants also were negligent, and, under the
doctrine of comparative negligence, the Court reduces the claimants? damages by
20?%.
Award of $1,605.33.
Opinion issued April 22, 1983
BUTLER CORPORATION
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-440)
James Butler appeared on behalf of claimant.
Nancy J. AUff, Attorney at Law, for respondent.
RULEY, JUDGE:
Claimant entered into a contract to build a fence around the respondent?s Tyler
County Office in Sistersville, West Virginia. The claimant?s bid of $5,200.00
was based on a diagram furnished by the respondent which showed only half of
the property involved. As a result, the claimant had to use eight more terminal
posts than were contemplated for which it claims
$752.00.
The failure of the claimant to include the terminal posts in its bid was based
on the incomplete information provided by the respondent. When it became
apparent that additional terminal posts were necessary, the claimant informed
the
W. VA.]
REPORTS STATE COURT OF CLAIMS 443
respondent of this fact. There was no
action on respondent?s part, so the claimant bought and installed the posts at
its own expense to complete the project. To deny the claim would unjustly
enrich the respondent for its own mistake. The Court therefore grants an award
in the amount sought.
Award of $752.00.
Opinion issued April 22, 1983
ROBERT HART, d/b/a
BOB?S BAKE SHOP
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-685)
Claimant appeared in person.
Nancy J. Miff, Attorney at Law, for respondent.
RULEY, JUDGE:
Claimant was the owner and operator of Bob?s Bake Shop, located at 930 Maple
Drive, Morgantown, West Virginia. The shop occupied approximately half of a
building, owned by William Marsh, which was located at that address. All the
equipment inside the bakery was owned by the claimant. The respondent acquired
the property by eminent domain in July 1979, as part of a four-lane highway
improvement project. The claimant closed his business on June 7, 1979, even
though he had received no written notification from the respondent to vacate,
Claimant alleged that he had received oral notice that he might possibly have
to leave by June 1 and definitely by July 1. He stated the June date came from
Kathleen Berry, the respondent?s right-of-way agent for District. 4. The July
date came from Elwood Penn, chief of relocation operations. Claimant seeks an
award of $40,000.00 as compensation for propertly allegedly taken by
respondent. The claimant has already received a $10,000.00 ?in lieu of? payment
instead of actual reimbursement for moving costs.
The testimony of respondent?s witnesses contradicted much
444 REPORTS
STATE COURT OF CLAIMS [W. VA.
of the claimant?s testimony. Ms. Berry
and Mr. Penn both deny telling the claimant to leave by a certain date. Contact
sheets maintained by Ms. Berry indicated that she told the claimant to ?plan on
continuing his business thru June.? The 30-day notice to vacate was sent July
30, 1979, advising the claimant to vacate on or before September 1, 1979.
Relocation assistance was offered to the claimant by Paul McMahan, a
right-of-way agent. His records indicate ?about 10? relocation sites which were
recommended. The claimant states that only four or five were mentioned and none
was acceptable.
The respondent?s evidence indicates that it attempted to aid the claimant by
suggesting relocation sites and offering to pay for moving expenses. There is
no evidence that the respondent acquired any of claimant?s property. Claimant?s
equipment apparently was transferred to William Marsh as payment for rent due
him from the claimant. The $10,000.00 in lieu of payment was the maximum amount
allowable. The Court can find no basis for an award to the claimant.
Claim disallowed.
Opinion issued April 22, 1983
HOLZER MEDICAL CENTER
vs.
DEPARTMENT OF HEALTH
(CC-83-28)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations in the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of $99.00 for medical services rendered for a patient at
Lakin State Hospital. In its Answer,
W. VA. REPORTS
STATE COURT OF CLAIMS 445
the respondent admits the validity of
the claim and states that sufficient funds were available from which the claim
could have been paid.
In view of the foregoing, the Court makes an award to the claimant in the
amount requested.
Award of $99.00.
Opinion issued April 22, 1983
MRS. JUANITA McCLARIN
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-246)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for respondent.
RULEY, JUDGE:
On June 14, 1981, the claimant was driving her 1978 98 Oldsmobile on U.S. Route
60 heading west towards Charleston, West Virginia. She observed gravel in the
road ahead of her, and changed lanes, going from the right lane to the left
lane where there was less gravel. Claimant struck a pothole just after changing
lanes. The left rear wheel was damaged. The wheel cover was replaced at a cost
of $95.81. The tire was also damaged and both rear tires were replaced at a
cost of $112.00.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
State to be found liable, it must first have had either actual or constructive
notice of the defect in the roadway. Since there was no proof in this case that
the State had notice of the defect, the claim must be denied.
Claim disallowed.
446 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued April 22, 1983
KENNETH H. PATRICK, JR.
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-315)
Larry Ford, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
The claimant is the owner of a tract of land in Booth Creek, Taylor County,
West Virginia. There is a house and a tool shed located on the land. The land
is bordered by two county roads maintained by the respondent and two streams.
The property lies below the level of the roads. Sometime in 1972, a culvert
which passes under one of the roads was replaced. The claimant alleges that
since that time, his property has been repeatedly flooded, because the new
culvert was placed in a different position, causing the water to be diverted
onto his land. The respondent denies that the new culvert was misaligned and
that respondent in no way contributed to the water damages suffered by the
claimant.
The claimant moved onto the property in 1965. He testified that between 1965
and 1972, he had never had any water damage. After the culvert was replaced, he
has had water on his land two or three times a year. The water has flooded his
tool shed, which is located several feet from the creek, as well as damaging
the cement porch behind claimant?s home. Claimant seeks $20,000.00 in damages
to the land and for loss of personal property.
John Jeffries, a heavy equipment operator employed by respondent, testified
that he replaced the culvert in question. According to his testimony, the old
culvert was replaced because it was rusted and caving in, making the road
unsafe for vehicular traffic.
James M. Beer, II, an area maintenance engineer, made a study of the culvert.
He stated that the new culvert had to be
W. VA.]
REPORTS STATE COURT OF CLAIMS 447
in approximately the same place as the
old culvert, because of the existence of two bridge abutments under the road.
The abutments limit the area where the culvert can be placed. He further
testified that from an engineering standpoint, the culvert is adequate to
handle a 10-year storm. The problem is the natural drainage in the area and the
fact that the stream above the culvert is unstable. Mr. Beer stated: ?A 10-year
storm, anything bigger, would really have no way of channeling itself to the
culvert. It could go over the road just as easy as it could go through the
culvert but you would have the problem no matter where you put the culvert
because of the way the stream is.?
The respondent has a duty to maintain State roads and the culverts under State
roads. In replacing the culvert in question, the respondent was performing the
kind of routine maintenance with which it is charged. The Court cannot say, as
a matter of law, that the respondent acted in a negligent manner when the
culvert was replaced in 1972. The evidence indicates that the new culvert?s
position was substantially the same as that of the old one. Other factors
appear to be the source of the flooding. As we cannot find that the respondent
acted negligently, the claim must be denied.
Claim disallowed.
Opinion issued April 22, 1983
GARY L. PRITT and JEANETTE PRITT
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-418)
Claimant, Gary L. Pritt, appeared
in person.
Nancy J. Aliff, Attorney at Law, for the respondent. WALLACE, JUDGE:
This claim was filed by Gary L. Pritt against the respondent
448 REPORTS STATE
COURT OF CLAIMS [W. VA.
for damages sustained to a 1980 Phoenix automobile titled in his name and that
of his wife, Jeanette. The Court on its own motion amended the complaint to
include Jeanette Pritt as a claimant.
On October 19, 1981, at approximately 7:45 p.m., claimant Gary Pritt was
driving the automobile northerly on Interstate 77 near Sissonville, West
Virginia, at about 55 miles per hour. The weather was clear. It was dark and
the automobile lights were on low beam. There was no traffic immediately in
front of him. As he crossed the Hayne?s Branch Bridge, the vehicle struck a
piece of loose concrete in the road. He proceeded to the Kenna Exit and had the
automobile checked at an Exxon Service Station. Damage to the automobile
including two wheel covers amounted to $637.23. There was also a towing charge
of $24.00 and approximately $14.00 worth of gasoline lost from the punctured
gas tank. Claimant?s insurance paid all of the loss except $14.00 for gasoline
and $100.00 deductible.
Claimant Gary Pritt testified that he had driven that same area of Interstate
77 several days before the accident and that there was no loose concrete at
that time. Carroll Monday, respondent?s supervisor of Interstate 77 in the
Sissonville area, testified that no complaints had been received about anything
in the roadway.
The law of West Virginia is well established that the State neither insures nor
guarantees the safety of motorists on its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). For the respondent to be found
liable for damages caused by road defects on this type, the claimants must
prove that the respondent had actual or constructive notice of the defect and a
reasonable amount of time to take suitable corrective action. Davis v. Dept. of
Highways, 12 Ct.Cl. 31 (1977); Hoskins v. Dept. of Highways, 12
Ct.Cl. 60 (1977); Hicks v. Dept. of Highways, 13 Ct.Cl. 310 (1980). As there was no such evidence
presented, the claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 449
Opinion issued April 22, 1983
ROGER RICHMOND and SANDRA RICHMOND
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-458)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for the respondent. WALLACE, JUDGE:
Claimant seeks to recover $67.44 for damages sustained by his 1979 Plymouth
Volare automobile.
On November 16, 1981, the claimant was a passenger in his automobile being
driven by his wife. They were proceeding at 35 to 40 miles per hour westerly on
Route 214 towards Yeager, West Virginia. It was early evening and dark. There
was no traffic in front of them. At a point about one-eighth of a mile from the
intersection of Route 214 and Route 3, an oncoming tractor-trailer approached
with its wheels on the claimants? side of the yellow line. The claimant
testified that his wife, in order to avoid the truck, drove into a hole in the
pavement damaging the vehicle. He further testified that his wife travelled
this road often going to work; that he was aware of the existence of the hole
but did not alert her; and that he did not attempt to notify the respondent of
the hole. The claimant?s wife was at work and did not testify at the hearing.
The law of West Virginia is well established that the State is neither an
insurer nor a guarantor of the safety of persons travelling on the highways. Adkins v. Sims, 130 W.Va. 645, 45 S.E.2d 81 (1947); Parsons v. State Road Comm?n, 8
Ct.Cl. 35 (1969). For the respondent to be found liable for damages caused by
road defects of this type, the claimant must prove that the respondent had
actual or constructive notice of the defect. Davis Auto Parts v. Dept. of Highways, 12 Ct.Cl. 31 (1977). Since the claimant brought forth
no evidence to that
450 REPORTS
STATE COURT OF CLAIMS [W. VA.
effect and did not meet the burden of
proof, this claim is denied.
Claim disallowed.
Opinion issued April 22, 1983
DONALD F. UDELL
vs.
BOARD OF REGENTS
(CC-B 1-359)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy
Attorney General, and Ann V. Gordon, Assistant Attorney General, for respondent.
RULEY, JUDGE:
Claimant is a piano tuner technician who seeks $102.00 for work performed under
a contract with the West Virginia State College at Institute, West Virginia.
This dispute arose out of the differing interpretations of the contract. This
contract states that it is for furnishing ?all labor, materials and equipment
necessary to tune and maintain in good working condition the pianos . . .? and lists various ?minor repairs, adjustments and
regulations.? However, the last page of the contract lists a price of $24.00
per piano for tuning alone. The claimant testified that he understood that any
work beyond tuning would not be included in the $24.00 price, particularly when
it would not be possible in advance to determine how much work a specific
instrument might need. He stated that the items listed on the contract were
simply types of work that he believed the respondent wanted him to perform. The
respondent claims that all work was included in the contract price.
The Court has reviewed the contract in question and finds that it is, by its
terms, ambiguous. Nowhere in the contract does it state that ?minor repairs,
adjustments and regulations? are part of the $24.00 base price. As the claimant
testified, some of the ?minor repairs? can be expensive. Inasmuch as the
W. VA.]
REPORTS STATE COURT OF CLAIMS 451
claimant performed work beyond tuning,
it would be inequitable not to compensate him for that work.
Award of $102.00.
Opinion issued April 22, 1983
VECELLIO & GROGAN, INC., for
PERALDO CONSTRUCTION COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-343)
Charles W. Yea ger, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. RULEY, JUDGE:
This claim for $11,585.20 arises out of a contract on Project RS-617 (21) in
Wayne County, West Virginia. The project involved the improvement of Route 52
along the Big Sandy River by extending a box culvert under the highway through
which Davis Creek flows to the Big Sandy River. Peraldo Construction Company
was the subcontractor of Vecellio & Grogan, Inc.
On December 11, P1mb Peraldo and his two sons visited the construction site
and, observing that the river was above the existing box culvert, they assumed
that, when the river receded, the flow line of the river would be below the
culvert. In fact, the flow line was three to eight feet above the culvert. In
order for the construction to proceed, it was necessary to dam the creek and
pump the water around the construction site. This claim is for the rental cost
of the pump and the cost of operating the pump beyond normal working hours. The
respondent contended that the claimant?s failure to notify respondent of these
additional costs barred any award under Section 105.17 of the Standard
Specifications of 1972, and moved to dismiss the claim.
Plinio Peraldo testified that he did not notify respondent that there would be
an additional charge for the pumping, al
452 REPORTS
STATE COURT OF CLAIMS [W. VA.
though he was aware of the provisions
for notice. He stated that Mr. Spence, whose position with the respondent was
unclear in the record, knew of the pumping because ?he was going by there every
evening and that was past work hour (sic) and he seen (sic) that the pump was
going
Section 105.17 reads in part:
?If, in any case, the contractor deems that additional compensation is due him
for work or material not clearly covered in the contract or not ordered by the
Engineer as extra work, as defined herein, the contractor shall notify the
Engineer in writing of his intention to make claim for such additional
compensation before he begins the work on which he bases the claim. If such
notification is not given, and the Engineer is not afforded proper facilities
by the contractor for keeping strict account of actual cost as required, then
the contractor hereby agrees to waive any claim for such additional
compensation. .
Neither the claimant nor the Court can
disregard that provision of the contract. It required the claimant to give the
Engineer written notice of its intention to make a claim for additional
compensation; failure to do so constituted a waiver. Accordingly, the Court
disallows this claim.
Claim disallowed.
Opinion issued April 22, 1983
GARY L. and BRENDA WORKMAN
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-132)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was originally titled in the name of Gary Workman, but when the
testimony disclosed that the damaged vehicle, a 1981 Bronco Ranger, was titled
in the joint names
W. VA.] REPORTS
STATE COURT OF CLAIMS 453
of the claimant and his wife, Brenda Workman, the Court on its own motion
joined Brenda Workman as an additional claimant.
On April 4, 1982, between 9:00 and 10:00 p.m., claimants were driving north on
West Virginia Route 85, approximately 30 miles south of Madison, West Virginia.
Route 85 is a two- lane blacktop road. The Workmans were driving at about 35 to
40 miles per hour when the vehicle struck a pothole. At the time of the
accident, it was raining and the pothole was filled with water. One wheel and
the cracked windshield had to be replaced at a total cost of $394.43.
The State is neither an insurer nor guarantor of the safety of motorists
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
respondent to be held liable for damages caused by road defects of this type,
the claimant must prove that the respondent had actual or constructive notice
of the existence of the defect and a reasonable amount of time to correct the
defect. Davis v. Department of
Highways, 11 Ct.Cl. 150 (1976). Since
the claimant did not meet that burden of proof, this claim must be denied.
Claim disallowed.
Opinion issued May 19, 1983
LESTER ROLLINGS HAINES
vs.
DEPARTMENT OF CORRECTIONS
(CC-76-89)
Elden Allamong and Charles W.
Smith, Attorneys at Law,
for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
The claimant was charged with the commission of armed robbery, which allegedly
occurred on February 13, 1971. The claimant was convicted as a principal in the
first degree in the Circuit Court of Morgan County, West Virginia, on April 12,
1971. The Supreme Court of Appeals of West Virginia, upon
454 REPORTS
STATE COURT OF CLAIMS [W. VA.
petition of the claimant, set aside
the verdict and granted the claimant a new trial, by order dated November 28,
1972. The Prosecuting Attorney of Morgan County thereupon entered a nolle prose qui order. The claimant, who was imprisoned on April 15, 1971, was released
on April 10, 1973. He seeks $200,000.00 as damages resulting from his incarceration;
The respondent filed a Motion to Dismiss based on the two- year statute of
limitations, West Virginia Code ?55-2-12. This claim was filed on August 13,
1976, three years and nine months after the verdict was set aside, and three
years and four months following the claimant?s release from the penitentiary.
Under West Virginia Code ?14-2-21, this Court cannot take jurisdiction of any
matter barred by the statute of limitations. This section reads in part:
?The court shall not take jurisdiction of any claim, whether accruing before or
after the effective date of this article, unless notice of such claim be filed
with the clerk within such period of limitation as would be applicable under
the pertinent provisions of the Code of W. Va., . .
The Court, therefore, grants respondent?s
Motion to Dismiss. Claim dismissed.
Opinion issued May 19, 1983
MILLARD A. HARMON
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-373)
Charles M. Moredock, Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
On February 21, 1980, at approximately midnight, the claimant was driving his
1978 Ford Thunderbird on Route 65, Mingo County, West Virginia. He was
travelling from his place of employment, Goff Brothers Coal Co., Inc., of
Delbarton, West
W. VA.]
REPORTS STATE COURT OF CLAIMS 455
Virginia, to his home in Pilgrim,
Kentucky. In the vicinity of Naugatuck, West Virginia, claimant?s car struck a
pothole and he lost control of the car, going into a gully, then back across
the road and down an embankment. The claimant sustained numerous injuries,
which included a broken back, ribs, and ankle, and a lacerated nose. He was
placed in a body cast for six weeks, and continues to use a back brace
intermittently. The claimant alleges that respondent negligently failed to
maintain this section of Route 65, and this failure was the proximate cause of
claimant?s injuries. He seeks an award of $200,000.00.
Claimant testified that he had travelled on Route 65 twice daily since June
1978. During that period, broken pavement and potholes had existed in the area
where the accident occurred. The berm had begun to slip and the condition of
the road had continued to deteriorate. He stated that it was possible for two
vehicles to pass one another only at a slow rate of speed. He was travelling
20-25 mph at the time of the accident. The road was repaired once that he could
remember, but after several weeks, the potholes began to reappear and the
deterioration progressed.
James Webb, assistant supervisor for Mingo County in February 1980, testified
that all of Route 65 in Mingo County was repaired during the summer of 1979.
Mr. Webb said that he had been aware of the road?s condition in 1979 and had
watched the slip after the repair. He stated that Route 65 is heavily
travelled, but he did not know whether there had been complaints about potholes
prior to February 1980. Photographs taken after the accident show a sizable
patch in the road covering all of one lane and part of the other.
In sum, it appears from the evidence that the accident was caused both by the
respondent?s negligence in failing to exercise reasonable care in the
maintenance of the highway and by the contributory negligence of the claimant
who, though being aware of the hazardous condition of the pavement at the place
where the accident happened, nonetheless drove onto it at a speed great enough
that he was unable to maintain control of his car. We are disposed to allocate
the negligence
456 REPORTS
STATE COURT OF CLAIMS [W. VA.
of the parties, respectively, at 60%
to the respondent and
40% to the claimant. Barkley vs. Dept.
of Highways, 13 Ct.Cl.
83 (1979).
The parties stipulated the following damages: lost wages of $12,597.12 and
medical expenses of $2,894.80. Claimant testified that his automobile was
totalled, but he received $4,800.00 from his insurance company. He had a
$500.00 deductible on the car. A medical evaluation by Dr. H. M. Hills, Jr.,
resulted in the determination that the claimant has a 20% permanent partial
disability as a result of his injuries. The Court determines that $24,676.32 is
a fair and just award, based on claimant?s economic losses and his pain and
suffering. Reducing this amount by 40%, we award the claimant $14,805.79.
Award of $14,805.79.
Opinion issued May 19, 1983
U. G. HARRISON AND EDNA HARRISON
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-173)
Arden J. Curry, Attorney at Law, for claimants.
Douglas Hamilton and Nancy J.
Aliff, Attorneys at Law, for
respondent.
RULEY, JUDGE:
Claimants are the owners of a tract of land on Newhouse Drive in Kanawha
County, West Virginia. This property is adjacent to and below Interstate 77.
Following the construction of 1-77, a slip occurred on the downhill side of the
highway. A land fill buttress was constructed on property purchased from the
claimants, in order to stabilize the slip. Claimants allege that this
construction resulted in a change in the drainage of surface water from 1-77,
which has caused their property to be flooded on two occasions. Prior to the
first flood in August 1978, water drained through a culvert under 1-77 which
emptied onto claimants? land. Following that flood, respondent
458
REPORTS STATE COURT OF CLAIMS
[W. VA.
lands of
Grantor, and hindering the flow of water and water courses; it being agreed
that the compensation herein provided for as purchase price is full
compensation both for the land herein described and for all rights and
easements hereby released and all damages herein mentioned which Grantor has or
may hereafter suffer.? (Emphasis supplied.)
The respondent argued that the release was a covenant that ran with the land;
that the claimants were subsequent purchasers who took the land with notice of
the prior deed; and, that the claimants were, therefore, bound by the quoted
language. When the language of a document is clear on its face, the Court will
construe the document in accordance with specific language therein. The word
?covenant? is not used in the deed, only the word ?release.? The release applies
only to the Grantor and does not purport to bind his heirs, successors, and
assigns. Therefore, the release does not bar the claimants, as subsequent
purchasers of the land, from pursuing this claim which arose subsequent to the
release.
Claimant, U. G. Harrison, testified that at the time the slip correction was
being performed, he told an unidentified engineer that inadequate provision was
being made for drainage. Photographs introduced by respondent show the lack of
a discrenable drainage ditch alongside the buttress. Mr. Harrison testified
about his concerns over the placement of the culvert, or pipe under 1-77.
?I stood on top of the hill when they put the pipe through and when they
started making the fill, and I tried my best to talk them into making a
concrete trough there to shed the water down through the ditch and in the
creek.
Now, I said, ?Fellows, that pipe through there and the way you?ve got me fixed
here?I?ll never be able to take care of it.? I said, ?You?re going to flood me
out of here.?
The respondent, through its project engineer for design, Frank Hamrick,
contended that neither the culvert nor the
W. VA.]
REPORTS STATE COURT OF CLAIMS 457
constructed a catch basin at the end
of the culvert, which attached to a pipe. This pipe extended towards the
buttress across claimants? property. The purpose of the pipe was to direct
water towards a drainage ditch, located approximately 30-40 feet from the end
of the pipe. The ditch eventually emptied into a creek which runs alongside
claimants? land. The second flood occurred after that construction. Claimants
allege damages of $32,400.84, for damages to their home, personal property, and
for mental anguish as a result of the two floods. Respondent, in its Answer,
denies any act of negligence which caused damage to the claimants. Respondent
further states that it is not liable for any alleged damages, due to a release
contained in a deed between the respondent and the claimants? predecessors in
title to this land.
The claimants purchased the property in question in 1970. This land was the
residue of a tract of land owned by the heirs of A. C. Surface, which had been
condemned by the respondent during the construction of 1-77. The deed, between
the heirs, as Grantor, and the respondent, as Grantee, contained the following
language:
?For the consideration hereinbefore set forth the Grantor hereby releases
Grantee, its successors and assigns
forever, from any and all claims for
damages or compensation of any nature whatsoever arising directly or indirectly
from the purchase of the herein described land, or from the construction and
maintenance of a highway, or the improvement and maintenance of said land and
adjoining lands of Grantee for highway purposes, or from work performed or
material placed upon or removed from said land or any adjoining land owned by
Grantee. Without limiting the generality of the foregoing, Grantor further
expressly releases all claims of Grantor for damages to any residue of land
retained, or adjoining or nearby land owned by Grantor; and all damages by
reason of increased lateral burden, loss of lateral support, diversion of water
courses and streams, concentration and discharge of water on
W. VA.]
REPORTS STATE COURT OF CLAIMS 459
extension pipe could have caused the
flooding. In his opir ion, the flooding resulted from an overflow of the creek
at a point where a 48-inch culvert passes under a driveway to claimants?
property. This culvert was insufficient to handle the creek during a heavy
rain, and the overflow would go onto claimants? land. Claimants testified that
they had never seen the creek overflow its banks.
The evidence presented at the hearing was contradictory, but it is the opinion
of the Court that the claimants have shown, by a preponderance of the evidence,
that the respondent?s actions caused the damages to their property. The
construction of 1-77 and the buttress, as well as the placement of the pipe,
have resulted in an increase in the amount of surface water discharged onto
claimants? property. One who collects and discharges surface water by means of
artificial channels, thereby diverting it from its natural course and
increasing its volume, is liable for damages caused by it. Grafton vs. Dept. of Highways, 13 Ct.Cl. 147 (1980).
The only testimony presented concerning the value of the lost personal property
was given by Mrs. Harrison. The property included various pieces of furniture,
as well as a 5- year-old freezer and the food it contained. These damages
amounted to $3,085.00. The Court has taken age and depreciation into
consideration of these damages, and has determined that $500.00 is a just, fair
and adequate measure of damages. Three estimates of damage to the real property
were submitted. The Court has determined that the amount of $7,325.00 contained
in the appraisal report, prepared by Gerald Terry on behalf of the respondent,
is a reasonable and fair determination of damages. There is, however, one item
of damage not included in this report. This is the replacement of a floor in a
small building on the property used as an apartment. As the only estimate of
replacement cost of the floor was $975.00, the Court includes that amount in
addition to the other damages. The Court, accordingly, makes an award to the
claimants in the amount of $8,800.00.
Award of $8,800.00.
460 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued Maij 19, 1983
LOIS V. HAYNES AND
E. ROBERT HAYNES
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-415)
J. P. McMullen, Jr., and Charles D.
Bell, Attorneys at Law, for claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
On December 21, 1978, at about 10:30 p.m., Lois V. Haynes was a passenger in an
automobile being driven by Yonhyong Maidens. They were traveling west on W.Va.
Route 27 towards Wellsburg, Brooke County, West Virginia. As they approached an
intersection called Brady?s Ridge intersection, at a speed of approximately
25-30 mph, they encountered ice on the road. Mrs. Maidens lost control of the
car, which struck a guardrail and then went about 200 feet down a steep
hillside. Mrs. Haynes suffered serious permanent injuries as a result of the
accident. Claimants allege that the respondent knew that ice would accumulate
at that place on Route 27 and that the respondent?s failure to provide proper drainage
or warn motorists of this condition constituted negligence. Lois Haynes claims
damages in the amount of $200,000.00 for her injuries. Her husband, Robert
Haynes, claims $50,000.00 for medical expenses and loss of the society,
pleasure, services and consortium of his wife.
Mrs. Haynes sustained injuries to her spine, legs, arms and nervous system. She
was initially hospitalized from December 22, 1978 until March 3, 1979, and
twice briefly in October and November, 1979. She continues to have difficulty
walking and has significantly impaired use of her arms. Dr. Reza P. Ash, one of
her treating physicians, reported, ?I, therefore, believe that Mrs. Haynes is
going to remain with significant degree of permanent neurological deficit which
would incapacitate her for all kind of gainful employment or any significant
physical activities.? Her medical expenses were stipulated to be $17,859.29.
W. VA.J
REPORTS STATE COURT OF CLAIMS 461
Earl Miller, a member of the Franklin
Volunteer Fire Department, testified that he was following Mrs. Maidens?
vehicle on the night of the accident. He observed the automobile go out of
control and over the embankment, so he returned to the Fire Department for
help. He estimated that there was several hundred feet of ice on the road at
and near the accident site; Route 27 had been clear to the east. Daniel
Gilchrist, a Brooke County commissioner in December 1978, testified that he had
personal knowledge of complaints made to respondent concerning ice at the place
of the accident before it occurred. Respondent?s witness, John Isinghood, a
road patrolman during the winter, testified that respondent was aware that the
accident site was hazardous, and gave it special attention. In view of the
evidence, the Court is constrained to conclude that the respondent was
negligent in failing to take reasonable measures to prevent the ice or to warn
approaching motorists of that hazard.
In view of the nature and extent of the injuries incurred, we feel that an
award of $65,000.00
to Mrs. Haynes is just.
We also make an award of $5,000.00 to Mr. Haynes. The record discloses,
however, that the claimants have received $20,000.00 from Mrs. Maidens?
insurance carrier. The respondent is entitled to a set-off in that amount, so
we accordingly reduce the award by $20,000.00.
Award of $50,000.00.
Opinion issued IViap 19, 1983
ROBERT MARCUM AND
LORETTA MARCUM
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-248)
Hazel A. Straub, Attorney at Law, for claimants.
Nancy J. Miff, Attorney at Law, for respondent.
RULEY, JUDGE:
The claimants were the owners of a house situated on Secon
462 REPORTS
STATE COURT OF CLAIMS [W. VA.
dary Route 5/5, Dempsey Branch, Logan
County, West Virginia. Route 5/5 is a dirt road. During a flood, approximately
500 feet of the road was washed away. The date of the flood was not clearly
established, although Mrs. Marcum thought it might have occurred in the summer
of 1977. In the spring of 1978, the respondent performed repair work on Route
5/5 which involved elevating the level of the road. As a result, the road,
which had been level with or below the level of the claimants? property, was at
least four inches above it. The claimants allege that the respondent was
negligent in its repair work, and has caused water to pooi on their property,
resulting in damages of $25,000.00.
The evidence established that prior to the repair work, the claimants had not
encountered any water problems on their property. Since the repair work, water
has not drained from their land, but pooled on it for up to three or four days
after a rainstorm. The floors of the house have rotted, and furniture and
clothing are damaged from mildew.
It is not clear whether the water, which has collected on the land, is due to
run-off 2rom the road?s surface or from the hillside behind the property. In
either case, it is clear that the elevation of Route 5/5 has altered the prior
drainage at claimants? location, and that the respondent has negligently failed
to provide adequate drainage. The Court concludes that respondent?s action is
the proximate cause of claimants? damages, and makes an award in their favor.
See White v. Dept. of Highways, 12 Ct.Cl. 271 (1979); Ferguson v. Dept. of Highways, 13
Ct.Cl. 103 (1980). The parties have stipulated that damage to personal property
amounted to $3,299.00. A real estate appraisal estimated the diminution of
value of the real property at $7,500.00. The Court, therefore, makes an award
of $10,799.00.
Award of $10,799.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 463
Opinion issued May 19, 1983
ANDREW S. MCGALLA
vs.
BOARD OF REGENTS
(CC?8 1-90)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
Claimant?s wife was admitted to West Virginia University Hospital in
Morgantown, on January 1, 1981. She died there on January 2, 1981. Upon her
admission, she had in her possession a medical alert necklace, a diamond
engagement ring, and a wedding ring. These items were taken and inventoried by
hospital personnel as part of their standard procedure. After the body was
taken to a morgue, claimant discovered that the rings and necklace were
missing. He valued the necklace at $10.00 and the rings, purchased as a set in
1960 for $300.00, at
$600.00.
Claimant reported the loss to Bernard Westfall, associate administrator of the
hospital, and a search was conducted to no avail. Claimant said that Mr.
Westfall showed him a copy of the inventory report which showed the items
checked into the hospital, but not checked out. Respondent presented no
evidence to the contrary. In a bailment, where one party is entrusted with the
care of another?s property, and:
?. . .where a bailor alleges and proves simply the delivery
of the property to the bailee and the latter?s failure to return it on demand,
a prima facie case is made out against the bailee; . . . But if the bailee proves that the property was stolen
or destroyed by fire or accounts for his failure to return or for the injury in
any other way which does not on its face involve negligence or call for further
explanation, the bailor must prove negligence.? 2B M.J., Bailments, ?18.
The claimant has proved a prima facie case by showing de
464 REPORTS
STATE COURT OF CLAIMS [W. VA.
livery and failure to return. Since
the respondent has presented no explanation for the loss of the items, the
Court makes an award to the claimant in the amount of $610.00.
Award of $610.00.
Opinion issued May 19, 1983
RONALD R. McGRAW
vs.
DEPARTMENT OF CORRECTIONS
(CC-78-50)
Claimant appeared in person.
Joseph Cometti, Assistant Attorney General, for respondent.
GARDEN, JUDGE:
The claimant was an inmate at the Huttonsville Correctional Center in August
1974. He was charged with escape, tried in the prison police court, and
sentenced to one extra year plus 14 days in isolation. The claimant was due for
a parole hearing in September 1974, but because of the escape, he did not
receive the hearing. In an order entered July 9, 1975, in the U.S. District
Court for the Northern District of West Virginia, the respondent was required
to expunge any reference to the escape from the claimant?s record, or hold a
new hearing on the matter which complied with constitutional requirements. The
matter was expunged. The claimant seeks $45,000.00 in damages for the extra
time he served and for the failure to receive a parole board hearing in
September 1974.
In its Answer, the respondent denies that it acted in bad faith or with malice
or willful disregard for the claimant?s rights to due process, and therefore,
the claimant is not entitled to damages. The respondent further alleges that
any claim for damages has been resolved by a court of record, and seeks
dismissal under the principle of res judicata and collateral estoppel.
The order entered by the U.S. District Court was in response to a civil action
filed by the claimant entitled ?Complaint
W. VA.] REPORTS
STATE COURT OF CLAIMS 465
for Declaratory Judgment, Injunctive Relief and Damages.? The District Court
action was filed against the then Director of the West Virginia Department of
Corrections, Warden and Associate Warden of Huttonsville Correctional Center.
This claim was also filed against those named individuals, but was amended at
the hearing. It is apparent that those individuals were sued in District Court
in their capacities as officials of the respondent. It appears from the Order
entered by the U.S. District Court in the record in this claim that the damages
sought herein were fully and sufficiently considered previously. The purpose of
the doctrine of res judicata is to end controversy. Where it appears that
parties to the controversy are the same, the doctrine makes the prior judgment
an absolute bar to all questions which were or could have been litigated in the
prior decision. The Court, therefore, dismisses the claim.
Claim dismissed.
Opinion issued May 19, 1983
PRESTON CONTRACTOR?S INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-158)
Phillip Gau jot, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. RULEY, JUDGE:
The only issue before the Court, at this time, is respondent?s defense based
upon release. The claim grows out of a construction contract which was
performed by the claimant in 1978 and 1979. At the conclusion of performance,
the parties were in disagreement as to the quantities of aggregate for which
respondent was liable, but claimant apparently agreed that respondent was
entitled to a credit of $9,716.63 inasmuch as the final estimate, which it
submitted on November 5, 1979, provided:
466 REPORTS
STATE COURT OF CLAIMS [W. VA.
?The within amount of Minus Nine
Thousand Seven Hundred Sixteen Dollars and Sixty Three Cents (?$9,716.63) set
out and shown in this final estimate, being Estimate No. 6 and Final, is hereby
accepted and approved by Preston Contractors, Incorporated as full and complete
payment and settlement for all sums, claims and monies due and owing or to
become due and owing, to it, as the contractor for Project U339-53-0.00,
Preston County, West Virginia and the said Preston Contractors, Incorporated
does hereby agree that all previous payments shown deducted therein and all
amounts retained or deducted under the provisions of the contract are proper an
correct; subject to the exception and the reservation of the right of the
Preston Contractors, Incorporated to file its petition in the West Virginia
Court of Claims against the State of West Virginia and the West Virginia
Department of Highways within 120 days, from the date of acceptance and approval of this final estimate, . . .? (Emphasis supplied.)
This claim was filed on March 20, 1980, and thereupon, the respondent filed its
Special Plea of Release asserting that, since the claim was not filed within
the 120-day limitation contained in the exception, the claim was barred. It
appears from the record that, although respondent received the final estimate
on November 6, 1979, it did not accept or approve it on that date but, rather,
promptly on November 7, 1979, returned it to the claimant with instruction. It
was not submitted again by the claimant until December 18, 1979, after which it
was accepted. The Court is unable to perceive, under those circumstances, any
legal basis for making November 5, 1979, the date from which the 120-day
limitation should be computed and, accordingly, the Special Plea of Release is
overruled.
W. VA.]
REPORTS STATE COURT OF CLAIMS 467
Opinion issued May 19, 1983
VECELLIC & GROGAN, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-81..425 and CC-82-92)
Lee M. Kenna, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. RULEY, JUDGE:
These claims were consolidated for hearing because they arise out of the same
facts. The claimant, through its subcontractor, Charleston Construction Co.,
performed paving work on Project 1-79-1 (36)2 between Mink Shoals Run and
Cooper?s Creek Interchange on Interstate 79. The claim arises out of the
reduction in payments for concrete pavement. The contract required the pavement
to be nine inches thick, but allowed for a 7/10-inch variation. Therefore,
pavement 8.3 inches thick was acceptable. The respondent, through statistical
analysis, concluded that a certain amount of the pavement was less than 8.3
inches thick and reduced the contract payments by $12,930.32 and $1,911.88,
respectively, the amounts of the two claims.
Subarticle 501.3.19 of the Standard
Specifications Roads and Bridges states:
?It is the intent of these Specifications that the pavement shall be
constructed in substantial conformity with the specified thickness. Paving
operations shall be directed toward obtaining an average and uniform thickness
equal to or greater than the specified thickness.
For the purpose of establishing an adjusted unit price for pavement areas deficient
in thickness, the thickness characteristics will be determined in accordance
with the criteria specified hereinafter.?
Subarticle 501.3.19.1 states:
?The pavement thickness characteristics shall be de
468 REPORTS
STATE COURT OF CLAIMS [W. VA.
termined from an analysis of
measurements made on cores, said cores being taken with a frequency of one core
from each sampling unit as hereinafter defined.?
Seventy-four cores were taken from the reinforced sections of pavement. The
average thickness of the cores was 9.362 inches. Eight cores were less than 9
inches thick, but all were greater than 8.3 inches. The other 66 cores were
nine inches or greater.
Twenty-seven cores were taken for the non-reinforced sections of pavement. The
average thickness of those cores was 9.489 inches. Five cores were less than 9
inches, but all were greater than 8.3 inches. The remainder were all 9 inches
or greater. The thicker cores resulted from the contractor?s filling low areas
of sub-grade with concrete. This procedure is allowed under Subarticle
501.3.4.3.
The pertinent regulations concerning payment are as follows:
?501.5.2: When the pavement is deficient in thickness, payment will be made at
an adjusted price for the entire item based on the criteria specified hereinafter.
501.5.2.1: No payment will be made for pavement areas deficient in thickness by
more than 7/10 inch.
501.5.2.2: If the mean value of the pavement thickness is equal to or greater
than the specified thickness, then the contract unit price will be paid for the
fraction of pavement having a thickness equal to or greater than the specified
thickness minus 7/10 inch.?
These regulations provide for a reduction in price only when the pavement
thickness is below a specified amount, not above. The analysis performed by the
respondent was based on the assumption that there would be as many thin cores
as thick, and that, therefore, some areas would be less than 8.3 inches thick.
The evidence presented did not bear out this assumption; in no instance was there
a core sample of
W. VA.]
REPORTS STATE COURT OF CLAIMS 469
less than 8.3 inches. The Court,
therefore, makes an award in the amounts requested for each claim.
Award of $12,930.32 in Claim No. CC-81-425.
Award of $1,911.88 in Claim No. CC-82-92.
Opinion issued May 25, 1983
APPALACHIAN POWER COMPANY
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-83-111)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $29.36 for an unpaid bill for electrical services
furnished to respondent?s Horsepen Mountain Fire Tower in Hampden, West
Virginia. Respondent admits the validity and amount of the claim. The Court,
therefore, makes an award to the claimant in the amount requested.
Award of $29.36.
Opinion issued May 25, 1983
APPALACHIAN POWER COMPANY
vs.
DEPARTMENT OF PUBLIC SAFETY
(CC-83-118)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $106.80 for an unpaid
470 REPORTS
STATE COURT OF CLAIMS [W. VA.
bill for electrical services furnished
to respondent?s Williamson, West Virginia, office. Respondent admits the
validity and amount of the claim. The Court, therefore, makes an award to the
claimant in the amount requested.
Award of $106.80.
Opinion issued May 25, 1983
BAILEY, INCORPORATED
vs.
BOARD OF REGENTS
(CC-83-35)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of the sum of $131.01 for unpaid freight charges. As the respondent
admits the validity of the claim, and as there were funds remaining in its
appropriation for the fiscal year in question from which the claim could have
been paid, the Court makes an award to the claimant in the amount requested.
Award of $131.01.
Opinion issued May 25, 1983
MILLER?S IMPLEMENT, INC.
vs.
DEPARTMENT OF HEALTH
(CC-83-43)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision based upon the pleadings, claimant seeks
payment of the sum of $92.65 for services rendered to Denmar State Hospital. In
its Answer, the respondent admits the validity of the claim and that there were
sufficient funds remaining in its appropriation for the
W. VA.J
REPORTS STATE COURT OF CLAIMS 471
pertinent fiscal year from which the
claim could have been paid. The Court, therefore, makes an award in the amount
requested.
Award of $92.65.
Opinion issued May 25, 1983
ELLERY H. MORGAN
vs.
PUBLIC EMPLOYEES INSURANCE BOARD
AND ALCOHOL BEVERAGE CONTROL COMMISSIONER
(CC-83. 13)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings, claimant seeks
payment of $2,189.24 for overpayment of his insurance premiums. Respondent?s
Answer, although admitting the validity of the claim, also states that there
were insufficient funds remaining in its appropriation for the pertinent fiscal
year from which the obligation could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, the Court is of the opinion that an award cannot be made, based on our
decision in Airkem Sales & Service,
et al. vs. Dept. of Mental Health, 8
Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued May 25, 1983
POTOMAC VALLEY HOSPITAL
vs.
DEPARTMENT OF CORRECTIONS
(CC-83-37)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings
472 REPORTS
STATE COURT OF CLAIMS [W. VA.
claimant seeks $56.10 for medical
services rendered to an inmate of the Huttonsville Correctional Center.
Respondent?s Answer, although admitting the validity of the claim, also states
that there were not sufficient funds remaining in its appropriation for the
fiscal year in question from which the obligation could have been paid.
While we feel that this is a claim which is equity and good conscience should
be paid, the Court is of the opinion that an award cannot be made, based on our
decision in Airkem Sales & Service,
et at. vs. Dept. of Mental Health, 8
Ct.Cl. 180 (1971).
Claim disallowed.
Opinion issued May 25, 1983
S. S. LOGAN PACKING COMPANY
vs.
BOARD OF REGENTS
(CC-83-26)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision based on the pleadings, the claimant
seeks payment of the sum of $819.86 for food supplies sold and delivered to
West Virginia State College, an institution under the direction of the
respondent. As the respondent admits the amount and validity of the claim, the
Court makes an award to the claimant in the amount requested.
Award of $819.86.
Opinion issued May 25, 1983
EDWIN 0. WALKER, M. D.
vs.
DEPARTMENT OF HEALTH
(CC-83- 40)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
In this claim, submitted for decision upon the pleadings,
W. VA.1 REPORTS
STATE COURT OF CLAIMS 473
claimant seeks payment of the sum of $30.00 as reimbursement for the
replacement cost of a medical school diploma. The diploma had been sent to the
West Virginia State Board of Medicine in order for claimant to be licensed to
practice medicine and was returned to him in a damaged condition. Respondent
admits the validity and amount of the claim. The Court, therefore, makes an award
in the amount requested.
Award of $30.00.
Opinion issued June 1, 1983
SHELLY & SANDS, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-165)
Sarah SuUivan, Attorney at Law, and W. Warren Upton, Attorney at
Law, for the claimant.
S. Reed Waters, Jr., Attorney at Law, for the respondent. RULEY, JUDGE:
Claimant seeks to recover liquidated damages assessed against it for delay in
completion of a contract for construction of a segment of the Appalachian
Corridor E in Monongalia County, West Virginia. The project involved
excavation, embankment, concrete paving, asphalt paving, grading, draining,
etc., all of which are a part of roadway construction projects. Claimant
required a large supply of limestone aggregate on the project which it
contracted to buy from Greer Limestone, the principal source of aggregate in
northern West Virginia.
The project began in 1972 with completion scheduled in October 1974. However,
claimant contends that inability to obtain the limestone aggregate necessary
for the project and wet weather caused actual completion of the project to be
delayed until September 19, 1975. The respondent initially assessed liquidated
damages for 270 days against the claimant but later reduced that number to 131
days.
474 REPORTS
STATE COURT OF CLAIMS [W. VA.
The project entailed earth work using
heavy equipment for excavation and embankment. Inclement weather during the
spring and fall of 1973 affected the excavation and embankment operations.
There was good weather during the construction season in 1974, but at that time
claimant needed limestone aggregate delivered to the project.
The construction of two secondary roads required limestone aggregate. Claimant
experienced a shortage of aggregate delivered to the project site during the
fall of 1974. The project was shut down on November 8, 1974, primarily due to
the aggregate shortage. During the first week of May 1975 the claimant was back
on the project. Wet weather prevented actual work on the subgrade until late
May 1975. At that time, the deliveries of aggregate were sufficient for
claimant to complete the project with actual completion on or about September
19, 1975.
The wet weather experienced during 1973, the first year of the project, was
certainly a contributing factor in the delay in completion of the project.
However, the problem of obtaining limestone aggregate contributed to the delay
in the performance of the contract. Both the governor and the former state
highway engineer testified that the State desired Interstate 79 be completed as
soon as possible. The Governor met with the president of Greer Limestone to
indicate his desire to have 1-79 completed in 1974. In fact, the governor, in
discussing the impact of directing aggregate to the 1-79 projects, testified as
follows:
?A. As a matter of fact, to reach a hypothetical question, and I realize I?m
not in the position to volunteer here, but had the question arisen that this
would have impacted other contractors and that a question would have been
arrived at as to whether or not they should have had additional time to
complete their projects, I would have directed that they be given additional
time.?
For the respondent to assess liquidated damages when it was aware of the
shortages of aggregate available to all contractors seems unreasonable. This
Court has previously enunciated the rule that liquidated damages may not be
assessed
W. VA.]
REPORTS STATE COURT OF CLAIMS 475
by a party who has contributed to
cause the delay for which the damages are sought. Whitmyer Brothers, Inc. v. Dept. of Highways, 12 Ct.Cl. 9 (1977). It is clear from the record that
the governor?s conduct at least contributed to cause the shortage of aggregate
which, in turn, contributed to cause the claimant?s delay in completion of its
contract. Furthermore, no substantial damages resulted to the respondent which
would justify liquidated damages, since the highway could not be opened until
completion of an adjacent project. J.F.
Allen Company vs. Dept. of Highways, 13
Ct.Cl. 364 (1981). The Court, therefore, grants claimant an award of
$39,300.00.
The Court has determined that the date from which to calculate an award of
interest is March 6, 1978, the date of the signing of the final estimate.
Interest is calculated at 6% per annum from the 151st day after March 6, 1978,
or August 4, 1978 to June 1, 1983, the issuance date of the opinion, in
accordance with Section 1, Article 3, Chapter 14 of the Code of West Virginia.
The interest amounts to $11,365.56, for a total award of $50,665.56.
Award of $50,665.56.
Opinion issued June 13, 1983
FOSTER & CREIGHTON COMPANY
and VECELLIO & GROGAN, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-83-153)
Lee M. Kenna, Attorney at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. PER CURIAM:
This claim was submitted upon a written order and stipulation to the effect
that the factual situation and applicable law is the same as in the claims of Veceliio & Grogan, Inc. vs. Department of
Highways, CC-81-425 and CC-82-92, and
should be considered with those claims. Based on the opinion of Vecellio
476 REPORTS
STATE COURT OF CLAIMS [W. VA.
& Grogan, Inc. vs. Department of Highways, issued on May 19,
1983, the Court makes an award to the claimant in the amount
of $2,499.74.
Award of $2,499.74.
Opinion issued June 24, 1983
JESSE J. CRANK
vs.
DEPARTMENT OF HIGHWAYS
(CC-83-1 14)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Claimant seeks $308.76 as the replacement cost of a tire and rim for his 1982
Ford Mustang which were damaged by a piece of a metal reflector which had
broken out of 1-64-77 near the 35th Street Bridge Exit in Charleston, Kanawha
County, West Virginia. Claimant testified that the piece of metal became
imbedded in the tire and he did not see the metal prior to striking it. The
incident occurred on October 31, 1982, between 3:00 and 4:00 a.m.
Ken Kobetsky, director of the traffic engineering division, testified that his
division had never received any complaints about the reflectors. There are
approximately 90,000 of these reflectors in roads in the State, and about 1%
are replaced each year. Mr. Kobetsky did not know of any prior damage being
caused by a reflector.
The State is neither an insurer nor a guarantor of the safety of travellers on
its highways. Acikins v. Sims, 130 W.Va. 645 (1947). For the State to be found liable,
it must first have had either actual or constructive notice of the defect in
the roadway. Since there was no proof in this case that the State had notice of
the defect, the claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 477
Opinion issued June 24, 1983
PAUL E. MILLER and
MARGUERITE MILLER
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-396)
Phillip D. Gaujot, Attorney at Law, for claimants.
Nancy J. A 11ff, Attorney at Law, for respondent.
LYONS, JUDGE:
Claimants Paul E. Miller and Marguerite Miller filed their claim against the
respondent for the loss of their house situate in Bancroft, West Virginia,
below W.Va. Route 35/9, just off Route 62. The claimants had lived on their
property at Ban- croft since 1950, and in 1980, as a result of slides or a
slip, their home was destroyed. An appraisal, introduced as a joint exhibit by
the parties, assessed the damages from the loss of the home as $39,000.00. The
claimants contend that the respondent has failed to properly maintain a
drainage ditch above claimants? property. Respondent?s failure to maintain the
ditch properly caused water to be discharged over claimants? property causing
the earth slippage over the hillside above claimants? property.
The respondent contends that the slide was caused by a natural drainage
condition off the hillside itself and that the hillside is a slide prone area.
There have been a number of slides on the same hillside area, but they are not
before us for decision. The slippage of earth involved here is approximately
2,000 feet wide and 300 feet long. A number of experts testified, including
Bhajan S. Saluja, who testified that the cause of the slippage was due to an
improper drainage from W.Va. Route 35/9. This condition of excessive drainage
was communicated to the respondent in 1976. Respondent admitted that the road
has caused maintenance problems that it was almost impossible to provide
drainage, and that funds were not available to correct the condition.
478 REPORTS
STATE COURT OF CLAIMS [W. VA.
A preponderance of the evidence
indicated that claimants? home was destroyed as a result of the improper
maintenance of Route 35/9, although the respondent had sufficient notice to
correct the same. The respondent is under a legal duty to use reasonable care
to maintain the ditch line in such condition that it would carry off the surface
water and not direct it onto claimants? property. See Wotring v. Dept. of Highways, 9 Ct.C1. 138 (1972); Stevens v. Dept of Highways, 12
Ct.Cl. 180 (1978).
The Court is of the opinion that claimants have shown, by a preponderance of
the evidence, that the damage resulted from the improper maintenance of the
ditch line, and makes an award to the claimants in the amount of $39,000.00.
Award of $39,000.00.
Opinion issued June 24, 1983
LAIRD MINOR and
NANCY G. MINOR
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-327)
Claimant appeared in person.
Nancy J. Aliff. Attorney at Law, for respondent.
PER CURIAM:
On November 7, 1982, at 6:30 p.m., claimants were driving in their 1981
DeLorean automobile on Route 119 north of Logan, Logan County, West Virginia.
Claimants encountered a pothole on the right edge of the road, aproximately
eight inches from the berm. The right front rim was damaged and replaced at a
cost of $397.97. Mr. Minor, the driver of the vehicle, testified that he did
not observe the pothole prior to striking it. He had no knowledge of how long
the pothole had been in the road.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
State to be found liable, it must have had either actual or constructive notice
of the defect in the roadway. Since there was no proof in this case that the
State had notice of the defect, the claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 479
Opinion issued June 24, 1983
ROBERT B. MORAN
vs.
DEPARTMENT OF MOTOR VEHICLES
(CC83? 16)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
Claimant seeks to recover $6.00 as the difference between the fees for
registration of two motor vehicles. Claimant paid $36.00 for a Class A Motor
Registration plate for a vehicle weighing 4,400 pounds. He then transferred the
plate to a vehicle of lesser weight, for which a $30.00 fee was required.
Claimant contends that since he would have been required to pay an additional
fee for transferring the plate from a lighter to a heavier vehicle, he should
be allowed the refund.
West Virginia Code ?17A-4-l provides for the transfer, surrender or retention
of plates upon expiration of registration. While this section does provide for
payment of a greater fee upon transfer, no provision is made for a refund. The
Court finds that there is no basis for a refund, and disallows the claim. See Pawnee Trucking Company, Inc. vs. Dept. of Motor
Vehicles, 13 Ct.Cl. 416 (1981).
Claim disallowed.
Opinion issued June 24, 1983
DAVID E. PAUL and
DOLORES R. PAUL
vs.
DEPARTMENT OF HIGHWAYS
(CC-82-310)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was originally filed in the name of David E. Paul, but when the
testimony disclosed that the damaged automobile,
480 REPORTS
STATE COURT OF CLAIMS [W. VA.
a 1976 Buick Century Custom, was
titled in the joint names of the claimant and his wife, Dolores R. Paul, the
Court on its own motion joined Dolores R. Paul as an additional claimant.
On August 18, 1982, the transmission pan of the claimants? vehicle was damaged
in the amount of $128.68, when it was caught on a raised corner of a steel
plate on Jefferson Road, Charleston, Kanawha County, West Virginia, which is
part of the Corridor G Construction Project. The plate was on the road to cover
a drainage ditch. David Lee Maner, project engineer for the Corridor G
Construction Project, testified that the steel plate had been placed on
Jefferson Road by Holloway Construction Company, an independent contractor,
performing the Corridor G construction.
The Court is of the opinion that the record established that an independent
contractor was engaged in the construction work, and the respondent cannot be
held liable for the negligence, if any, of such independent contractor. See Harper vs. Dept. of Highways, 13 Ct.Cl. 274 (1980); Safeco Insurance Company vs. Dept. of Highways, 9 Ct.Cl. 28 (1971). Accordingly, the Court disallows
the claim.
Claim disallowed.
Opinion issued June 24, 1983
ALEX TOTH
vs.
DEPARTMENT OF HIGHWAYS
(CC?83?113)
Andrew Toth, appeared for claimant.
Nancy J. Miff, Attorney at Law, for respondent.
PER CURIAM:
This claim was originally filed in the name of Andrew Toth, but when the
testimony disclosed that the damaged automobile, a 1974 Monte Carlo, was titled
in the name of his father, Alex Toth, the Court on its own motion amended the
style of the claim to reflect Alex Toth as the claimant.
Andrew Toth was driving his father?s automobile on Febru
W. VA.]
REPORTS STATE COURT OF CLAIMS 481
ary 14, 1983, on Route 16, south of
Squire, McDowell County, West Virginia. It was 8:30 p.m., and he was travelling
at 35 -
40 mph when he struck a crack or a slip in
the road. The vehicle?s transmission and alignment were damaged in the amount
of $491.95. Mr. Toth stated he had not travelled the road for several months
prior to February 14, and did not notice any signs warning of the condition.
Testifying for respondent was Thomas 0. Henderson, Jr., McDowell County
Maintenance Superintendent. He stated that he had been informed of the road?s
condition on February 9, 1983. On February 13, 1983, he placed ?Rough Road?
signs in both the north and southbound lanes of Route 16, approximately 500
feet from the crack or slip.
The evidence presented established that respondent had placed warning signs in
the location of the damaged area of the road. Mr. Toth, by his own testimony, did
not observe these signs. The Court concludes, therefore, that the negligence of
the driver was equal to or greater than any negligence on the part of the
respondent. The Court is of the opinion and does deny the claim.
Claim disallowed.
Opinion issued June 24, 1983
CAROLE E. UPDYKE and
LIONEL JOE UPDYKE
vs.
DEPARTMENT OF HIGHWAYS
(CC-83-122)
Claimant appeared in person.
Nancy J. A 11ff, Attorney at Law, for fesporident.
PER CURIAM:
This claim was originally filed in the name of Carole E. Updyke, but when the
testimony disclosed that the damaged automobile, a 1978 Oldsmobile Custom
Cruiser, was titled in the joint names of the claimant and her husband, Lionel
Joe
482 REPORTS
STATE COURT OF CLAIMS [W. VA.
Updyke, the Court on its own motion joined
Lionel Joe Updyke as an additional claimant.
Mrs. Updyke testified that she was travelling on Route 61, also known as
MacCorkie Avenue, Charleston, Kanawha County, West Virginia, on January 7,
1983. At approximately 2:00 p.m., she struck a piece of concrete or tar which
was located on the right-hand side of her lane. The right rear tire was
punctured, and was replaced at a cost of $86.97. She said that she thought the
concrete or tar had broken off a seam in the pavement, but had no knowledge of
how long it had been in the road.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
State to be found liable, it must first have had either actual or constructive
notice of the defect in the roadway. Since there was no proof in this case that
the State had notice of the defect, the claim must be denied.
Claim disallowed.
Opinion issued June 24, 1983
A. B. WILLIAMS
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-466)
Robert F. Gallagher, Attorney at Law, for claimant. Nancy J. A 11ff, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimant purchased property on the north side of State Route 7 near Terra
Alta, Preston County, West Virginia, in 1941. This property is on a hillside.
During the late 1940?s, substantial improvements were made to the land. The
hillside was terraced and stone retaining walls were added for support. Two
houses were built, one of which the claimant has used as her residence. The
other house has been used as rental property. A garage was constructed for each
house. An automobile
W. VA.]
REPORTS STATE COURT OF CLAIMS 483
body shop was built on the eastern
corner of the property below the houses. Claimant also purchased property on
the south side of Route 7. This tract was directly opposite the tract with the
houses, garages and body shop. On the tract of land to the south of Route 7,
claimant built a store. She no longer owns this property. There are two catch
basins on the north side property. An upper catch basin is located near the
northeast corner of the claimant?s home. This catch basin connects to a
six-inch drainpipe which runs south between the house and the body shop. The
drainpipe connects with the lower catch basin, which is located on the north
side of Route 7. The lower catch basin is maintained by the respondent, and
leads to a culvert which runs underneath Route 7. The culvert runs under the
store and exits on the south side of the store. The claimant alleges that the
respondent has failed to maintain the lower catch basin, which has caused an
increase in the water table resulting in substantial damages to the residence,
body shop, and retaining walls, for which the claimant seeks damages of
$13,500.00. She seeks an additional $567.92 for restoration of a gas line
allegedly destroyed by the respondent during a ditch cleaning operation.
Lyle Moulton, a Ph.D. in Soils and Foundations Engineering, examined the
property at the claimant?s request. Dr. Moulton testified that the clogged
catch basin has contributed to a rise in the water table which has increased
the hydrostatic pressure on the retaining walls and the buildings. The
retaining walls, as was evidenced by photographs, are in danger of collapse.
One wall of the body shop has collapsed and been replaced by a plywood wall.
On cross-examination, Dr. Moulton stated he did not know where the culvert was
clogged. He viewed where the drainpipe went under the store and stated there
were two right-angle bends in it, which was not the condition of the pipe when
the claimant owned the store. Dr. Moulton also said that there are numerous
springs on the property, which make the area ?quite wet seasonally.? This would
?depending upon the drainage that was placed behind the walls or water that
might get out through the walls, this generally would lead to higher
484 REPORTS
STATE COURT OF CLAIMS [W. VA.
lateral pressure on the wall
throughout the area.? He conceded that some of the walls are of marginal
construction.
Paul Guthrie, an employee of the respondent, stated that the only portion of
the culvert maintained by the respondent is the part which is under Route 7.
There is a ditch line along Route 7 which is adequate to drain the road. Mr.
Guthrie said that the current owner of the store closed the culvert to prevent
odor from sewage water from entering the store. It is not possible to unclog
the culvert without going into the store, which respondent cannot do.
Barney Stinnett, a soils engineer working for the respondent, testified that
the clogged culvert should not have much effect on the water table because of
the presence of the ditch line which should carry the flow of water away from
the top of the hill. In his opinion, the damage was caused by the construction
of the retaining walls, which lack weep drains which could reduce the level of
hydrostatic pressure on the walls. The springs in the hillside further serve to
lessen the general stability of the land.
After careful review of all the evidence presented, the Court finds that
several conditions existed which led to the damages to claimant?s property. The
hillside is unstable due to the presence of one or more underground springs.
The amount of construction which the claimant has performed has significantly
contributed to the increased instability of the hillside. Experts for the
claimant and respondent noted the inadequate construction of the retaining
walls, which require special construction to allow a continuing flow of water
down the hillside. The clogged culvert has, in all probability, aggravated this
situation, but it has not been established, by a preponderance of the evidence,
that any negligence of the respondent outweighed that of the claimant. Under
the doctrine of comparative negligence, therefore, the Court finds that the
negligence of the claimant was equal to or greater than that of the respondent
and disallows that portion of the claim.
The evidence established that the repairs to the ruptured gas line occurred in
May 1977. The respondent has pled that this portion of the claim is barred by
the statute of limitations.
W. VA.]
REPORTS STATE COURT OF CLAIMS 485
The claim was filed in September 1979.
Since the claim was not filed within the two-year statute of limitations, the
Court has no jurisdiction of the claim under West Virginia Code ?14-2-21.
Therefore, this portion of the claim is also denied.
Claim disallowed.
Opinion issued June 24, 1983
ROY FRANKLIN WILLIAMS, JR., and
BEVERLY WILLIAMS
vs.
DEPARTMENT OF HIGHWAYS
(CC-83-117)
Claimant appeared in person.
Nancy J. Miff, Attorney at Law, for respondent.
PER CURIAM:
This claim was originally filed in the name of Roy Franklin Williams, Jr., but
when the testimony disclosed that the damaged automobile, a 1982 Toyota Tercel,
was titled in the joint names of claimant and his wife, Beverly Williams, the
Court on its own motion joined Beverly Williams as an additional claimant.
On January 23, 1983, claimant was driving south on Route 622 near Cross Lanes,
Kanawha County, West Virginia. It was about 9:00 p.m., and it was dark and
raining. The car struck a pothole which was located approximately a foot and a
half over from the edge of the berm. The right front and rear tires had to be
replaced at a cost of $85.54. Claimant had no knowledge of how long the pothole
had been in existence.
The State is neither an insurer nor a guarantor of the safety of travellers on
its highways. Adkins v. Sims, 130 W.Va. 645 (1947). For the State to be found liable,
it must first have had either actual or constructive notice of the defect in
the roadway. Since there was no proof in this case that the State had notice of
the defect, the claim must be denied.
Claim disallowed.
486 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued June 29, 1983
BETTY COOK
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-527)
Joan L. Boettner, Jr., Attorney at Law, for claimant. Nancy J. AUff, Attorney
at Law, for respondent.
RULEY, JUDGE:
This $25,000.00 claim arises out of alleged negliger.ce of the respondent in
the location, construction, and maintenance of a drainage ditch on W.Va. Route
53, Kanawha County, West Virginia. Route 53 is also known as Buff Lick Road. In
1968, claimant purchased a house and 4-acre lot, located on the downhill side
of Buff Lick Road. Between 1968 and 1974, she experienced no problem with water
drainage on the property. In 1974, a driveway was built upon nearby property on
the uphill side of Buff Lick Road. That driveway is opposite claimant?s
driveway. The record was unclear as to who constructed the driveway, although
there was some evidence that it was constructed under a permit issued by
respondent. Concurrent with the construction of the driveway was the
construction of a ditch line. The ditch line was built on respondent?s
right-of-way. Scant description was given of the ditch line, although it was
called ?basically a homemade structure? by claimant. The ditch line was lined with
cinderblock, and underneath the driveway was a 15-inch culvert. Since that
construction, claimant has had water damage to her land and home.
The claimant testified, as did several of respondent?s employees, that she has
made numerous complaints about the ditch line since 1974. She stated that the
ditch was frequently clogged with debris, which diverted water onto her land.
Respondent would pull the ditch, but it would quickly become clogged again. In
July 1979, claimant sustained major flood damage. After that damage, respondent
repaired the ditch lire and re
W. VA.]
REPORTS STATE COURT OF CLAIMS 487
placed the 15-inch culvert with a
24-inch culvert. There have been no problems since.
Respondent?s witness, Hardeep Chawla, an engineer, testified that the clogged
ditch would have caused drainage problems for the claimant. He further stated
that while a 15-inch culvert is the minimum accepted size, this would not be an
adequate size for the location. The claimant has established by a preponderance
of the evidence that the respondent was aware of the drainage problem for
aproximately five years before making adequate repairs. The respondent has,
therefore, failed to exercise reasonable care to prevent damage to claimant?s
property, and is liable for the damages sustained. Wotring vs. Dept. of Highways, 9 Ct.Cl. 139 (1972). The only evidence of damages
presented was an estimate in the sum of $18,910.00 for costs of repair to
claimant?s house. The Court renders an award in that amount. See Jarrett vs. E. L. Harper & Son, Inc., 235 S.E.2d 362 (1977).
Award of $18,910.00.
Opinion issued June 29, 1983
KENNETH PAGE
vs.
ALCOHOL BEVERAGE CONTROL COMMISSIONER
(CC-80-357)
William L. Redd, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
Claimant alleges that he was wrongfully terminated from his position as a clerk
at respondent?s State Store on Route 60 in Huntington, West Virginia, in 1977.
Claimant alleges that the termination occurred because he was unable to perform
heavy lifting, due to a medical condition. He seeks an award of
488 REPORTS
STATE COURT OF CLAIMS [W. VA.
$33,600.00
as accumulated sick pay and back salary,
based on this alleged wrongful termination.
In June 1977, claimant was treated for chronic osteomyelitis of the left upper
arm by Dr. Hassan Vaziri. In a letter dated June 25, 1977, Dr. Vaziri stated in
part, ?He has developed pain in the left arm recently which incapacitates him
to lift heavy objects.? Claimant?s job included, but was not limited to, the
lifting of cartons of bottles from trucks and loading the bottles onto shelves.
Since the claimant was not able to do this type of work, he did not return to
work.
On August 18, 1977, Gary Hamrick, Assistant Commissioner of the Alcohol
Beverage Control Commission, sent claimant a letter which stated: ?If you are
disabled to such an extent that you cannot perform all of the duties required
by your job and if you can obtain a medical report so stating, you can obtain a
leave of absence without pay.? The letter added that if a report was not
obtained and claimant did not return to work at full capacity within 15 days,
he would be terminated. Claimant did not submit further medical evidence
concerning his condition, nor did he return to work. He was subsequently
terminated.
Claimant was originally informed by Mr. Hamrick that he would be paid his
accumulated sick leave. Lynn M. Schillings, respondent?s payroll clerk,
testified that claimant was not paid for his sick leave because the governing
regulations of the Civil Service Commission do not allow such payment to an
employee who has been terminated.
The evidence in the record does not indicate to the Court that the claimant was
wrongfully terminated. He was afforded the opportunity to either establish his
inability to work or return to work. He did neither, so his employment was
terminated. Since the claimant is not entitled to payment for his sick leave
under these circumstances, and since his termination was not wrongful, the Court
denies the claim.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 489
Opinion issued June 29, 1983
FRANCIS L. PARKER
vs.
DEPARTMENT OF HEALTH
(CC-79-679)
Garry G. Geffert, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
Claimant voluntarily admitted himself to Weston State Hospital on September 22,
1977, for treatment of nervous problems. He was originally placed on a medical
ward, and, after two or three months, was transferred to the halfway house at
Weston. The halfway house is a separate building which is the least supervised
unit at Weston. There are no guards on the unit, and only one aide for
approximately 40 patients. The halfway house is reserved for the least troublesome
patients and those about to be released. They are free to move about the
hospital grounds until curfew. On December 8, 1977, claimant was sitting in an
office in the Rehabilitation Building, when he was attacked by another patient
who resided at the halfway house. The other patient had entered an unlocked
woodshop and obtained a wrench with which he struck claimant behind the left
ear. Claimant alleges that respondent negligently breached its duty towards
claimant by failing to exercise care to protect him from the other patient.
Claimant seeks an award of $12,000.00.
Following the assault, claimant became disoriented and began vomiting. He
suffered a seizure of three to five minutes in duration. A laceration by the
left ear requiring suturing. Claimant was hospitalized until December 22, 1977.
The injury has resulted in a hearing loss in claimant?s left ear, and he
testified that he experienced severe headaches, numbness in his left side and
arm, and blurred vision immediately after the attack. While these last problems
have diminished over time, claimant testified that he still has headaches
several times a month as well as numbness in his left hand. He did not have
these problems prior to the assault.
490 REPORTS
STATE COURT OF CLAIMS [W. VA.
The patient who attacked the claimant was transferred to the halfway house on
September 15, 1977. Evidence was presented which indicated that he had a
history of violent behavior, but he had shown improvement prior to his transfer
to the halfway house. Claimant testified that the other patient had acted
hostilely towards him, calling him a ?white son-of-a-bitch? about a month
before the assault. Claimant also stated that the other patient once had thrown
an ashtray at another patient. Joel Flaxer, administrative assistant at Weston,
confirmed that this incident occurred several weeks prior to the assault on
claimant.
On December 8, the patient who attacked the claimant entered the unlocked
woodshop alone and unsupervised, even though patients were not supposed to do
so without being accompanied by an instructor. Flaxer testified:
?...I have spoken with Mr. Sutlip who was then the head of the rehab unit,
chief of vocational rehabilitation at Weston State Hospital, and the indication
I got from him was that the area was just left, the tools were there and were
available if somebody was in the area. They were not locked up and put away.?
Mr. Flaxer also indicated that the woodshop was no longer in use because there
was no instructor.
The evidence in this claim established the violent, unpredictable nature of the
patient who attacked the claimant, but also indicated improvement on his part,
just prior to his placement in the halfway house. The Court is not prepared to
find that the transfer itself was an act of negligence; the Court recognizes
the need to grant patients certain privileges in return for more acceptable
behavior. However, the Court previously has held that the State has an
obligation to exercise ordinary care to protect patients in its mental
institutions from harm at the hands of other patients. House vs. Dept. of
Mental? Health, 10 Ct.Cl. 58 (1974). Permitting the unused woodshop to
remain unlocked, thereby allowing unsupervised patients access to tools, was an
omission constituting negligence on the part of respondent and was the
proximate cause of the injuries claimant sustained. In view of the evidence
respecting
W. VA.]
REPORTS STATE COURT OF CLAIMS 491
the nature and extent of those
injuries, the Court is of the opinion that $8,000.00 is a fair award.
Award of $8,000.00.
Opinion fssued June 30, 1983
LILLIAN AKERS, ADMINISTRATRIX OF THE
ESTATE OF GARY WAYNE AKERS, DECEASED
vs.
DEPARTMENT OF HIGHWAYS
(CC-78-222)
Gordon T. Ikner, Jr., Attorney at Law, for claimant. Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
Claimant seeks recovery of damages for the alleged wrongful death of her
husband, Gary Wayne Akers, who died as the
result of a single-car accident at Bias Branch on W.Va. Route
17 near the town of Jeffrey in Boone County, at approximately
8:30 p.m., on February 24, 1977.
Akers was driving his 1974 Ford Mustang north on Route 17 on his way to a
service station to refuel the vehicle. At a curve in the road, approximately
one mile north of Jeffrey, he encountered a mudslide and the car spun, went
over an embankment and into the Little Coal River below. Akers was thrown from
the vehicle, suffering fractures of his pelvis and left humerus. He was taken
to Boone Memorial Hospital, then transferred to Charleston Area Medical Center
for surgery, where he remained for approximately three weeks. He then was taken
home, where he died on March 22, 1977, from pulmonary emboli, i.e., blood clots
within the lungs, a complication of the injuries sustained in the accident. The
autopsy report reflects that his death was attributable to those injuries.
Thomas Bias, Deputy Sheriff of Boone County, invetigated the accident. He
testified that a film of mud covered much of the road, but was greater in the
northbound than southbound
492 REPORTS
STATE COURT OF CLAIMS [W. VA.
lane. He estimated that Akers?
automobile slid 30-50 feet before going into the river.
Herbert Cook, a grader operator employed by the respondent, testified that he
had been sent with a work crew to clear mud from Route 17 on the day before the
accident. The slide had covered the road when he arrived with the grader, and
he worked from 9:00 p.m. on the 23rd until 3:00 p.m. the next afternoon. Mud
was still sliding onto the road and, despite Mr. Cook?s repeated requests, no
signs or smudge pots were placed at the scene. Mr. Cook testified that he was
unable to clear all of the mud from the road because the blade on the grader
was worn. He stated that he had requested a new blade, but his superiors denied
the request.
Barney Stennett, a soils engineer, evaluated the landslide in April 1980. He
estimated that the slide had been in existence for 15-20 years and had a ?very
low? priority correction rating.
William E. Cobb, a Ph.D. in economics, prepared three estimates of economic
loss caused by the death of Akers. The first estimate of $367,201.00 is the
most liberal figure, based on widely recognized academic assumptions. The
second figure of $142,730.00 is the ?absolute minimum in terms of the economic
damages resulting from the death of Mr. Akers.? The third figure, $248,540.00,
is Dr. Cobb?s professional estimate of economic damage. All figures were
reduced to present-day value.
The State is not an insurer of the safety of travelers on its roads and its
duty to travelers is a qualified one of reasonable care and diligence in the
maintenance of a highway under all circumstances. Parsons v. State Road Commission, 8 Ct. Cl. 35 (1969). However, the State may be found
liable ?if the maintenance of its roads falls short of a standard of
?reasonable care and diligence . . . under all
circumstances.?? Farley v. Dept. of
Highways, 13 Ct. Cl. 63 (1979). Having
knowledge of the dangerous condition of the highway, it clearly was the duty of
the respondent, under that standard, to remove the danger rather than leave it
or, at least, to erect warning signs. Pullen
v. Dept. of Highways, 13 Ct. Cl. 278
(1980). Its failure to do so constituted negligence which proximately caused
the accident
W. VA.]
REPORTS STATE COURT OF CLAIMS 493
and the resulting death of the
decedent. In view of the decedent?s previous knowledge of at least some hazard
at the p]ace of the accident, the court is disposed to find that his own
negligence contributed by 20% to cause the accident.
Considering the evidence respecting damages, the Court will make an award of
$142,730.00, reduced by 20% to $114,184.00, that sum to be distributed equally
between the decedent?s widow and two children, i.e., one-third to each. In
addition, the Court will award medical expense in the sum of $4,789.00 and
funeral expense in the sum of $1,200.00 to the administratrix pursuant to West
Virginia Code ?55-7-6, in effect at the time of the accident.
Award of $44,050.34 to Lillian Akers Meade, Administratrix of the Estate of
Gary Wayne Akers, deceased.
Award of $38,061.33 to Lillian Akers Meade, as guardian for and on behalf of
Steven Wayne Akers.
Award of $38,061.33 to Lillian Akers Meade, as guardian for and on behalf of
Christopher Lewis Akers.
Opinion issued June 30, 1983
APPALACHIAN ENGINEERS, INC.
vs.
BOARD OF REGENTS
(CC-81-55)
ELner H. Dodson and Stanley E.
Deutsch, Attorneys at Law, for
claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent.
RULEY, JUDGE:
This is a contract claim. The contract provided for the preparation of plans
and specifications for parking lot improvements and an analysis and
recommendation of regulations for permanent and transient parking at Marshall
University in
494 REPORTS
STATE COURT OF CLAIMS [W. VA.
Huntington, West Virginia. Under its
terms, the claimant was to begin performance on September 8, 1976, and complete
performance by December 31, 1976. The total cost of the study was not to exceed
$4,500.00 and travel expenses were not to exceed $500.00. The contract was
dated July 30, 1976. Actual services by the claimant began in August 1976, at
the request of officials at the university who were anxious to obtain the
results of the contemplated studies. The claimant contends that subsequent
requests by personnel of the university changed the scope of the work which was
not completed until August 1977. The claimant submitted its invoice for the
study and travel expenses in the amount of $9,434.53 to the university. The
invoice was properly processed by the university, but, ultimately, was denied
by the Department of Finance and Administration because the invoice did not
meet the time frame or the dollar limitation in the contract.
Although the total cost of this project was not to exceed 4,500.00 for the
study and $500.00 for travel expenses, the evidence is undisputed that the
claimant included parking studies for a proposed sports center and a medical
school at the request of personnel at the university.
The terms of the purchase order were not strictly adhered to by the claimant,
but the claimant was acting contrary to those terms at the request of the
officials with whom it was dealing at the university.
For the respondent to now deny the claimant payment for services admittedly
rendered to the respondent would constitute unjust enrichment. See Modern Press, Inc. vs. Board of Regents, CC-80-277, 13 Ct. Cl. 341 (1981); SincLair vs. OECD, CC-77-95, 12 Ct. Cl. 19 (1977); and Dunbar Printing Company vs. Department of Education, Division of
Vocational Education, CC-77-41, 11 Ct.
Cl. 282 (1977). For that reason, this Court is of the opinion that the claimant
is entitled to an award and, accordingly, the Court makes an award in the
amount of
$9,434.53.
Award of $9,434.53.
496 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued June 30, 1983
ARMEDA JEAN BUSH
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-204)
Ross Maruka, Attorney at Law, for the claimant.
Nancy J. Aliff, Attorney at Law, for the respondent. RULEY, JUDGE:
This claim in the sum of $50,000.00 for damages for personal injuries grows out
of an accident which happened at about 9:30 a.m., on October 17, 1979, on
W.Va.-U.S. Route 19, Jackson Street, in Fairmont, Marion County, when the
claimant fell while walking across the street. Claimant alleges that her fall
was caused by a ?hump? of blacktop pavement which, according to the undisputed
evidence, was about six inches high. Claimant contended, and the contention may
be inferred fairly from the evidence, that the hump was caused by the
respondent while removing the old blacktop with a Rotomill machine in
preparation for repavement. There was no evidence that the respondent had
utilized any warning signs or devices incident to the repairing project. The
gist of the evidence of the respondent was that the machine usually left a
relatively level surface but there was no specific testimony respecting the
surface at the time and place of the accident. However, that area was lighted
by street lamps and there was no evidence that the street surface was obscured
in any way. From that evidence, it appears that the respondent was negligent in
that it created a condition dangerous to pedestrians and then left it without
any sign or device whatever to warn pedestrians of the hazard. It also appears
that the claimant herself was negligent in failing to maintain an adequate
lookout upon the surface where she was walking. The negligence of both parties
combined to cause the accident and the Court is disposed to allocate the
negligence 70% to the respondent and 30% to the claimant.
Turning to the issue of damages, the claimant sustained a
W. VA.]
REPORTS STATE COURT OF CLAIMS 495
Opinion issued June 30, 1983
ROBERT W. BURKE
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-318)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
Claimant is the owner of property located on Midway Drive, Dunbar, Kanawha
County, West Virginia. The land is located at a low point in the road. There is
a ditch along the road, and a draft pipe under the road empties in a hollow on
claimant?s property. Claimant alleges that his property has been damaged in the
amount of $9,000.00 by water flowing out of the ditch and onto the land. Part
of this damage occurred in late August 1980, following a period of heavy rain.
The rest of the damage has occurred over the course of several years. Claimant
alleges the resurfacing of Midway Drive in October 1979 changed the elevation
of the road, diverting water onto the land.
Respondent contends that claimant?s property lies in a natural drainage area.
It was further alleged that debris placed by claimant in the hollow blocked the
outlet end of the pipe causing water to back up into the ditch. Photographs
introduced into evidence show old sinks, stoves, hot water heaters, and other
debris in the hollow. Claimant stated he had been placing this material there
for ?a great number of years? to slow erosion in the hollow.
The evidence presented indicated that claimant?s property is located in a
natural drainage area. Much of the damage occurred after a heavy rain, when the
water followed its natural course oato claimant?s land after the ditch line
back-up. The evidence does not support a finding that the elevation of the
road, even if performed in a negligent manner, was the proximate cause of the damage.
Wotring vs. Dept. of Highways, 12 Ct. Cl. 162 (1978).
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 497
fracture of her right kneecap but it does not appear from the evidence that
there was any resulting permanent injury. Her medical expense was $364.50 and
her net lost earnings were $416.39. The Court finds that $1,500.00 is a fair
and just compensation, and reduces that sum by 30% to reflect claimant?s
contributory negligence.
Award of $1,050.00.
Opinion issued June 30, 1983
HAYWARD JOBE CASTO, JR.
vs.
DEPARTMENT OF CORRECTIONS
(D?986)
Harry R. Cronin,
Jr., Attorney at Law, and A. Blake Billings- lea, Attorney at Law, for claimant.
Joseph C. Cometti, Attorney at Law, for respondent. RULEY, JUDGE:
The claimant was convicted on February 8, 1972, for a violation of the
Controlled Substances Act. On August 15, 1972, he began serving a sentence of
one to five years at the West Virginia State Penitentiary at Moundsville, West
Virginia. The claimant was discharged from prison on September 3, 1974, upon an
order of the Criminal Court of Marion County, West Virginia, which voided
claimant?s conviction after the Supreme Court of West Virginia declared the
statute under which the claimant was convicted unconstitutional. Claimant
alleges that he was illegally incarcerated and seeks $16,767.59 as compensation
for wages he could have earned during the period of his incarceration. At the
time of his conviction the claimant was employed as a truck driver. The
respondent has filed a motion to dismiss, or, in the alternative, motion for
summary judgment, for failure to state a claim upon which relief can be
granted. West Virginia Code ?62-13-5 provides for the reception of convicted
felons by the Commissioner of Public Institutions, now Dept. of Corrections.
The section provides in part:
498 REPORTS
STATE COURT OF CLAIMS [W. VA.
?All persons committed by courts of criminal and juvenile jurisdiction for
custody in penal, correction or training institutions under the jurisdiction of
the Commissioner of public institutions, shall be committed to an appropriate
institution, but the director shall have the authority to and may order the
transfer of any person committed to the division to any appropriate institution
within the division.?
Claimant was committed to the penitentiary under a law which, at the time of
his conviction, was in full force and effect. Respondent was under a statutory
duty to receive claimant into the penitentiary, and complied with that duty. It
is not within the purview of respondent?s duties to determine the
constitutionality of statutes and it does not appear that the respondent failed
to act in good faith. See Steinpreis
vs. Shook, 377 F.2d 282 (4th Cjr.
1967). Claimant?s conviction was not voided until August 29, 1974, and he was
then released pursuant to that order. The Court is of the opinion that
respondent fully and properly performed the duty required of it under the law
and finds no basis upon which to hold respondent liable for the damages sought.
The Court, therefore, grants respondent?s motion to dismiss.
Claim dismissed.
Opinion issued June 30, 1983
JAMES D. EADS
(CC-80-401a)
J. R. ALEXANDER
(CC-80-401b)
JACK D. BAYS
(CC-80-401c)
WILLIAM E. GARRETT
(CC-80-40 id)
NANCY HUGHES
(CC-80-401e)
W. VA.] REPORTS
STATE COURT OF CLAIMS 499
WILLIAM C. JOHNSON and
GLADYS M. JOHNSON
(CC-80-401f)
ZONA M. WISEMAN
(CC-80-401g)
and
EMMA JEAN RAMSEY
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-401h)
Robert Bland, Attorney at Law, for claimants.
Nancy J. A 11ff, Attorney at Law, for respondent.
RULEY, JUDGE:
These claims were consolidated for hearing as all of the claims arose out of
the same factual situation. Claimants are residents of a subdivision in South
Charleston, Kanawha County, West Virginia. Their homes either abut or front
Pike Street. In the spring of 1980, respondent performed routine maintenance on
Pike Street, which included the excavation for drainage ditches. Claimants
contend that respondent agreed to pay for and install drainpipes under their driveways.
These pipes were installed by respondent, but were purchased by claimants at an
aggregate cost of $2,857.24. They seek reimbursement for the cost of the pipes.
Respondent contends that it is not its policy to pay for drain- pipes under a
property owner?s driveway. Respondent requires a property owner, who wishes to
install a pipe under a driveway, to obtain a permit before installation, and the
costs are borne by the property owner.
From the evidence in the record, it is clear that the responsibility for
drainage under a driveway rests with the property owner. Respondent?s policy is
clear that the homeowner must pay the cost of a drainpipe under a driveway. See
also Cowan
500 REPORTS
STATE COURT OF CLAIMS [W. VA.
vs. Dept. of Highways, 13 Ct. Cl. 124 (1980). The claims are, therefore,
denied.
Claims disallowed.
Opinion issued June 30, 1983
GATES ENGINEERING COMPANY, ET AL.
vs.
BOARD OF REGENTS
(CC-82-68)
Robert B. Sayre, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. RULEY, JUDGE:
In 1977, claimant entered into a contract with respondent to provide
engineering and architectural services for construction of the West Virginia
University football stadium and team facilities building in Morgantown, West
Virginia. Under the provisions of the contract, the respondent could request
that the claimant, as architect on the project, procure the services of
additional consultants, i.e., soils engineer, surveyor, aerial mapping
consultant, etc., who would be subeonsultants to the claimant. In those
instances where claimant engaged a sub- consultant the respondent would
reimburse the claimant for the services rendered by the subconsultant. This
dispute centers on whether the claimant must be compensated for providing the
consultants under the terms of the contract which require that an additional
service be paid at a rate 2.0 times the amount billed by the consultants or
whether the claimant has been fully paid by the reimbursement of the consultant
fees. The claimant paid professional consultants the sum of $71,-
612.84. The claimant claims twice that amount or $143,225.68 is still due and
owing under the specific terms of the contract. The respondent takes the
position that it has reimbursed the claimant for the services of the
subconsultants as agreed by the terms of the contract and, therefore, the
claimant is entitled to no further compensation.
W. VA.] REPORTS
STATE COURT OF CLAIMS 501
The professional fee schedule in the contract provides for three types of
compensation, i.e., for basic services, additional services, and reimbursable
expenses.
Article S of the contract defines ?reimbursable expenses? between claimant
(Architect) and respondent (Owner) as follows:
?5.1 Reimbursable Expenses are in addition to the Compensation for Basic and
Additional Services and include actual expenditures made by the Architect, his
employees, or his professional consultants in the interest of the Project for
the expenses listed in the following Subparagraphs:
5.1.2 If authorized in advance by the Owner, direct expense of Special
Consultant Services, Land Surveys as described in Article 2.3, Test Boring and
Soils Testing as described in Article 2.4.?
Claimant seeks recovery under Section II.b.3 of the contract which provides as
follows:
?II.b. FOR ADDITIONAL SERVICES, as described in Paragraph 1.3, compensation
computed as follows:
3. Services of professional consultants at a multiple of (2.0) times the amount
billed to the Architect for such services.?
Letters from respondent to claimant requesting that claimant employ various
consultants state that authorization is given in accordance with Articles 2.3,
2.4, 2.7, and 5.1.2 of the contract.
Article 2.7 of the contract provides as follows:
?2.7 The services, information, surveys and reports required by Paragraphs 2.3
through 2.6 inclusive shall be furnished at the Owner?s expense, and the
Architect shall be entitled to rely upon the accuracy and completeness thereof.
Should the Architect, at the Owner?s
election, furnish such services, the Architect shall be reimbursed by the Owner
at cost as described in Article 5.1.2.
(Emphasis supplied.)
502 REPORTS
STATE COIRT OF CLAIMS [W. VA.
The letters indicate respondent?s
intention to reimburse claimant at cost for the hiring of consultants, and
respondent has, in fact, done so.
It is clear that certain services of a professional consultant require
respondent to pay claimant at the multiple rate of two times the cost. However,
none of the authorization letters contemplate the application of the provisions
of ?1.3 Additional Services which involve the application of Section II.b.3 of
the contract. Claimant was entitled to reimbursement for providing the
consultants, and has received it. No further payments were authorized under the
terms of the contract and none were intended by respondent as evidenced in its
authorization letters. For those reasons, the Court must deny the claim.
Claim disallowed.
Opinion issued June 30, 1983
DOROTHY M. GORE
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-61)
PETITION FOR REHEARING
RULEY, JUDGE:
Although the Court adheres to the principles of law enunciated in Dorothy M. Gore vs. Department of Highways (1982), we conclude that the claimant should be given
an additional opportunity to prove a factual situation complementary of that
existing in Smith and Smith vs.
Department of Highways, 11 Ct. Cl. 221
(1977). Since it appears that the respondent knew that the rock cut involved in
this case presented a hazard to vehicular traffic, the principal issue which
should be addressed upon rehearing is the issue of whether the respondent
reasonably could have corrected the hazard within the limits of funds
appropriated by the legislature for highway maintenance.
For the foregoing reason, the petition is granted.
W. VA.] REPORTS
STATE COURT OF CLAIMS 503
Opinion issued June 30, 1983
HOOTEN EQUIPMENT COMPANY
vs.
BOARD OF REGENTS
(CC-80-337)
Robert I-I. C. Kay, Attorney at Law, and Michael Bonasso, Attorney at
Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent.
RULEY, JUDGE:
Sometime prior to 1978, officials at the West Virginia University Medical
Center decided to renovate its cafeteria facility. Margaret Abbott, director of
the Department of Dietetics, was appointed to recommend equipment for the
remodeling. She sought the advice of James Milleville, a representative of
several food equipment manufacturers, and Al Ruff, a consultant in food
equipment layout. They drew up specifications for the equipment, which were part
of the Request for Quotations. Claimant?s bid was accepted, and a contract was
signed in July 1978. One piece of equipment to be furnished under the terms of
the contract was a salad and dessert carrousel. The Request for Quotations
listed certain requirements for the carrousel and provided as follows:
?Carrousel unit to be Model No. 1652, as manufactured by SMS Division of
Metalers Corp., St. Paul, Minn.
Or: Equal.?
The claimant furnished the carrousel from the Metalers Corp., but the equipment
did not conform to all the requirements dictated by the contract. Respondent
canceled that portion of the contract which involved the carrousel, and
claimant seeks to recover the $31,051.00 contract price from respondent.
The carrousel was required to have two revolving shelves. The upper shelf was
to be non-refrigerated, the lower refrigerated to 40 F, in order to comply with
national and state standards. After installation, it was discovered that the
504 REPORTS
STATE COURT OF CLAIMS [W. VA.
carrousel would not refrigerate to
40?F, and attempts to correct the defect failed. Metalers Corp. filed for
bankruptcy after supplying the carrousel. Claimant contends that since
respondent provided the specifications for the equipment, respondent impliedly
warranted that the named machine would meet the specifications. Claimant
further alleges that since a specific machine was listed, an ?equal? machine
could not be supplied, and even if one were provided, that in order to be an
?equal? machine with Metalers?, it, too, would not cool to 40?F. Therefore,
claimant concludes, the fault lay with the specifications and respondent should
bear the cost of the machine.
While the Court has considerable sympathy for the claimant, the Court cannot
agree with its contention. Liability for the faulty machine is with its
manufacturer, a company row in bankruptcy. Since recovery from Metalers Corp.
may be precluded, the question then becomes, as between claimant and
respondent, who should bear the cost of the machine. The contract specifications
are clear. Claimant was to furnish a machine which would refrigerate to 40 F.
It did not do that. As the supplier of goods, claimant is under an obligation
to ascertain whether the goods will conform to the specifications in the
contract. Since the machine would not refrigerate to 40?F, it failed to meet
respondent?s requirements, as well as standards established on the state and
national levels. Provision 8 of the Terms and Conditions of the Contract state:
?8. The State of West Virginia may reject, revoke, or cancel this agreement or
any part thereof, and, .
shall have the right to recover any and
all damages sustained as a result of the vendor?s failure to perform, in whole
or in part, the terms and conditions of this agreement. The State may withhold
from any remittance due the vendor under the terms and conditions of this
agreement an amount equal to the damages sustained by such failure of
performance on the part of the vendor.?
Respondent provided notice to claimant of its intent to cancel the carrousel
for failure to perform to specifications and to
W. VA.]
REPORTS STATE COURT OF CLAIMS 505
withhold payment. In view of these
circumstances, the claim must be denied.
Claim disallowed.
Opinion issued June 30, 1983
JOHN D. TONKOVICH AND SONS, INC.
vs.
DEPARTMENT OF HIGHWAYS
(CC-81-140)
Robert Q. Sayre, Jr., Attorney
at Law, for claimant.
S. Reed Waters, Jr., Attorney at Law, for respondent. RULEY, JUDGE:
The claimant was awarded a purchase order by the Purchasing Division of the Department
of Finance and Administration in the fall of 1980 to supply 2,000 tons of
winter grade asphalting mixture for use in respondent?s northern district. The
claimant alleges that the respondent, through the Purchasing Division,
wrongfully canceled this purchase order thereby causing claimant to sustain
damages in the amount of $11,563.00.
Claimant?s bid for the winter grade asphalt mix was approved on November 21,
1980. Thereafter, in early December 1980, claimant produced approximately 1,100
tons of the winter grade asphalt mix. When this material was placed on the
surface of the highway it failed to adhere. The claimant contends that the mix
failed to adhere because the respondent did not allow the mix to remain
stockpiled for a curing period of two weeks.
The parties determined that the mix might perform as specified if it were mixed
with sand which would expedite the curing period. However, the mix, with and
without the addition of sand, failed to conform to grading requirements when
tested by the respondent. The purchase order was canceled on January 26, 1981.
The tests conducted by the respondent revealed that the
506 REPORTS
STATE COURT OF CLAIMS [W. VA.
material did not meet the
specifications and was not fit for its intended use. Accordingly, the
respondent was obligated to cancel the purchase order and the claim must be
denied.
Claim disallowed.
Oprnion issued June 30, 1983
DAVID H. KISOR, ADMINISTRATOR
OF THE ESTATE OF JULIA KISOR, DECEASED
vs.
DEPARTMENT OF HIGHWAYS
(CC-79-122)
Claimant Julia Kisor appeared in
person.
Nancy J. A 11ff, Attorney at Law, for respondent.
RULEY, JUDGE:
This claim was filed by Julia Kisor. Subsequent to the hearing of the claim,
Julia Kisor died, and David H. Kisor qualified as administrator of her estate.
He maintains this claim for the estate of his mother.
This $10,000.00 claim is for damage to real property located on Green Valley
Road, Huntington, Cabell County, West Virginia. The property is located on a
hillside above the road. Claimant alleged that her home was damaged as the
result of a slide caused by respondent?s ditch cleaning operation.
Specifically, claimant alleged that respondent?s employees cut the toe of the
slope in front of the house and the subsequent slide undermined a corner of the
house.
Gary Adkins, a maintenance engineer employed by respondent, visited the
property following the slide. He testified that the slide was not caused by
actions of respondent?s employees, but rather by the continuous saturation of
the soil from the downspouts on the house. This caused instability in the land,
resulting in the slide. Mr. Adkins stated that ditch cleaning consists of
removing material that has gathered in the ditch, which would not cause a slide
of this type. He said that plans
W. VA.) REPORTS
STATE COURT OF CLAIMS 507
had been made to correct the slide, since it had affected the road surface and
that this work would benefit claimant as well as respondent.
Additional testimony was taken after the repair work. Mr. Adkins again testified.
He stated that the repairs consisted of grading claimant?s property and
building a retaining wall. This had appeared to stabilize the hill.
Respondent has the duty to maintain drainage ditches along roadways, which
includes periodically cleaning those ditches. After careful consideration of
the testimony presented, the Court is of the opinion that the claimant has not
proved by a preponderance of the evidence that respondent was negligent in
carrying out its duty. The evidence indicated that the slide resulted from the
saturation of the hillside from the drainage from claimant?s house. As no
negligence has been found, the respondent cannot be held liable for the damage
to the house. Therefore, the claim must be denied.
Claim disallowed.
Opinion issued June 30, 1983
NORMAN LEWIS
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-334)
William L. Lonesome, Attorney at Law, for Claimant.
W. Douglas Hamilton, Attorney at Law, for Respondent. RULEY, JUDGE:
Claimant owns a tract of land on Cane Fork Road near St. Albans, Kanawha
County, West Virginia. The area of the tract is approximately 1.5 acres and it
is improved by a one-story house in which claimant resides. The western side of
the property is bounded by 2 3/4 Mile Creek, and Cane Fork Road runs along the
south side. When claimant moved onto the property, there was a bridge where the
road crossed the creek. Sometime around 1974, the bridge was damaged, and
respon
508 REPORTS
STATE COURT OF CLAIMS [W. VA.
dent replaced it with two 5 or 6 foot
steel culverts. Claimant alleges that since the culverts were installed, trash
and debris have blocked the culverts and caused flooding on the property. He
seeks damages in the amount of $50,000.00.
Claimant testified that the creek had not flooded when the bridge was in place,
and this testimony was corroborated by claimant?s aunt, Edith Lewis, who has
lived on nearby property for 28 years. Claimant stated that he had made
numerous complaints to respondent concerning the condition of the culverts, but
no action was taken. Photographs introduced into evidence show extensive
flooding in the affected area, as well as debris partially blocking the
culverts. No evidence was introduced by respondent to refute claimant?s
allegation that the flooding did not occur prior to the installation of the
culverts. From those circumstances, the Court is constrained to conclude that
the fill and culverts installed by the respondent have not served their
intended purpose but, instead, have served to obstruct the natural flow of the
creek and divert its waters onto the claimant?s property. See Haught vs. Department of Highways, 13 Ct. Cl. 237 (1979); Johnson vs. Department of Highways, 13 Ct. Cl. 380 (1979); Adkins, et at. vs. Department of Highways, 12 Ct. Cl. 185 (1977); and Wotring vs. Department of Highways, 9 Ct. Cl. 138 (1972).
Claimant testified that he purchased the property intending to use .5 acres as
a ttailer court. It is this portion of the property which has been subject to
floods; no damage has occurred to the house. The floods have occurred several
times a year since the installation of the culverts, and have made the land
unsuitable for use as a trailer court.
Testimony was presented in an effort to establish rental rates in other trailer
courts near claimant?s property. However, as claimant has never had trailers on
the land, an award of damages for lost rent would be speculative. An appraisal
report prepared by Dennis A. Robinson valued the entire tract of land without
improvements at $10,000.00. Since approximately one-third has been affected by
the flooding, the Court concludes that $3,000.00 would be a suitable award.
Award of $3,000.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 509
Opinion issued June 30, 1983
MICHAEL E. WHALEN and
ANN WHALEN
vs.
DEPARTMENT OF HEALTH and
DONALD GREENE, SANITARIAN
(CC-81-219)
Paul A. Ryker, Attorney at Law, for the claimants.
Henry C. Bias, Jr., Deputy Attorney General, for the respondents.
RULEY, JUDGE:
Claimants contracted to sell their home on Sandhill Road, Point Pleasant, Mason
County, West Virginia, to Mr. and Mrs. William Curnutt on October 11, 1981.
This contract was contingent upon the Curnutt?s obtaining a loan from the Mason
County bond program. Before the loan could be granted, the septic system had to
be approved. The septic system proved unsatisfactory, and several types of
corrective measures were suggested; however, no repairs have yet been made. In
March 1981, the Curnutts asked to be released from the contract and the
claimants agreed. Claimants have rented the house since releasing the Curnutts
from the contract, and the house has been continuously occupied since that
time. The claimants allege that respondents acted in an arbitrary and
capricious mariner in denying approval for the septic system. They seek an award
of $43,000.00, which is the contract price of the home less a lien on the
property, based upon a theory of negligent interference with a contract.
Respondents have filed a motion to dismiss based on the lack of jurisdiction of
the Court to hear the claim against Donald Greene, Sanitarian. The motion to
dismiss also alleges that the Department of Health assumes no responsibility
for reviewing or approving septic systems and therefore has breached no duty
upon which liability may be predicated.
The Court sustains respondent?s motion to dismiss as to Donald Greene,
Sanitarian. Under West Virginia Code ?14-2-13,
510 REPORTS
STATE COTJRT OF CLAIMS [W. VA.
this Court is without jurisdiction to
hear a claim against an individual.
After careful review of all of the evidence presented, the Court cannot
conclude that respondent Department of Health was ultimately responsible for
approving the septic system or whether such approval was the responsibility of
officials with the county health department. A letter from the Mason County
Health Department indicates that that office would grant an approval order for
the septic system. A memorandum dated October 12, 1977, from respondent to all
health officers and sanitarians states that as of October 28, 1977, responsibility
for reviewing and approving water and sewage forms for various loan
guaranteeing agencies would rest with the local health units. In view of the
foregoing, the Court can find no basis for liability and, therefore, sustains
respondent?s motion to dismiss as to the Department of Health.
Claim dismissed.
Opinion issued June 30, 1983
JAMES WOODY AND LOTTIE L. WOODY
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-241)
HARRY W. SHOEMAKER AND WINIFRED G.
SHOEMAKER
vs.
DEPARTMENT OF HIGHWAYS
(CC-80-242)
DALE R. PENNINGTON AND GLORIA MAE
PENNINGTON
vs.
DEPARTMENT OF HIGHWAYS
(CC?80-243)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for the respondent. RULEY, JUDGE:
These claimants have alleged various amounts of damage to
W. VA.] REPORTS
STATE COURT OF CLAIMS 511
their homes situate on State Route
60/2, also known as Edge- wood Drive, near Huntington, West Virginia, as a
result of various alleged acts of negligence by the respondent.
The parties agreed that the question of liability of the respondent is the same
as to all of the claimants, but the amounts of damage, if any, are to be
determined separately as to the respective claimants, and accordingly, the
evidence upon the question of liability is made applicable to all of the claims.
In early 1980, each claimant noticed cracks in the foundation and walls of
their homes. Prior to that time, the claimants had experienced no such defects.
These cracks became progressively worse, eventually rendering the Woody and
Penning- ton homes unfit for habitation, and severely damaging the Shoemaker
home. Apparently, the cracks were caused by forces exerted on the homes by one
large landslide and several smaller landslides in the area. The claimants
allege that the damages to their homes are due to two factors: undrained ditch
lines along Route 60/2, and traffic vibrations from the nearby 1-64 bridge.
Thomas W. Olson, an Associate Professor of Engineering at Marshall University,
testified that he examined the area on two separate occasions in the spring and
summer of 1981. In his opinion, the ditch line along Route 60/2 did not drain
properly, causing the soil to become saturated and thus more subject to motion
and vibrations. He concluded that ?saturation of the soil and the vibrations of
traffic from the 1-64 bridge both contributed materially to the slide.?
However, he did not measure the water content of the soil or the vibrations
from the 1-64 bridge, and stated that ?every hillside in Huntington is
slideprone.?
Gary Adkins, an Assistant District Engineer for the respondent, testified that
he visited the Edgewood Drive area in the spring of 1980, in response to
telephone calls from the claimants. His inspection revealed a large landslide
which began near the Pennington home and extended to the area of the Shoemaker
home, running parallel to Route 60/2, a distance he estimated to be 300-500
feet. He also observed two areas of ponding along Route 60/2, and testified
that drainage pipes were installed at that time to aid the drainage process.
512 REPORTS
STATE COURT OF CLAIMS [W. VA.
The slide, however, was impossible to
correct due to its size. He concluded that neither Route 60/2 nor the 1-64
bridge had any effect on the slide, stating that the road was simply a part of
the movement rather than a contributing factor. In his opinion, both Route 60/2
and the claimants? homes were being damaged by the same slide.
Dave Bevins, an Assistant Maintenance Engineer for the respondent, also
observed the area in the spring of 1980 and agreed with the conclusions reached
by Mr. Adkins. He added that there were many slides in the area, and that the
probable cause was a combination of wet weather and unstable soil.
Gary Cooper, a Soils Engineer for the respondent, testified that he inspected
the area in June or July of 1980 and again in September of 1982. He described
the landslide in question as a ?rotational failure through part of the upper
side of Route 60/2 .
. . about 800 to 900 feet long along the
roadway and probably 300 feet between the break behind the houses on the upper
side and where you can see it?s coming out below the houses.? In July of 1980
he tested for vibrations from the 1-64 bridge, using a seismograph, which is an
instrument that measures vibrations in millimeters per second. Taking readings
when heavy trucks and buses were crossing the bridge, the highest reading
obtained was .06 mm/sec., which he testified was so low that it was ?not even
listed on the [F.H.A.J chart as being noticeable. They don?t even take the
chart that low. Anything that low is just natural vibrations of the earth
itself.? In addition, he measured the distance from the bridge to the
claimants? homes at 550 feet, and testified that the F.H.A. report on traffic
vibrations stated that ?the effect on anything over about 200 or 300 feet was
negligible.? Mr. Cooper concluded that traffic vibrations had no effect on the
slide, adding that the most likely cause was ?. . just nature. It?s actually an unstable area in the slope.?
James Amenta, a Soils Geologist for the respondent, testified that he examined
the area during the spring or summer of 1980. He opined that the slide in
question was an older slide which had recently become unstable, and that the
traffic vibrations from the 1-64 bridge had no effect on the slide.
W. VA.]
REPORTS STATE COURT OF CLAIMS 513
Mary Flora, a Seismologist-Geologist
for the respondent, made a seismograph study of traffic vibrations in the area
in September-October, 1982 (the seismograph study by Mr. Cooper was done in
July of 1980). Measurements were taken from three different sites: directly
under the east abutment of the 1-64 bridge; on the approach side of the bridge;
and 500 feet away, near the slide. The vibrations from 30-35 tractor trailers
were recorded at each site. The highest readings obtained on the abutment and
the approach sites were 1 mm/sec., while the highest reading at the site near
the slide was .06 mm/sec. Ms. Flora testified that 1 mm/sec. was ?far below the
damage level?, which begins at 100 mm/sec., and that according to the 1979 FHWA
Report, vibrations beyond 200 to 300 feet are not considered damaging. She
concluded that the traffic vibrations from the 1-64 bridge would have no effect
on the claimants? property.
Considering the evidence and testimony presented at the hearing of these three
cases, and the legal principles applicable thereto, the Court is of the opinion
that there is not sufficient proof that acts or omissions of the respondent
were the direct or proximate cause of the damages sustained by the claimants. In
stead, the overwhelming burden of the evidence suggests that the claimants
simply had the misfortune of owning homes in an extremely slide-prone area. The
Court is not unmindful of the disaster which has befallen the claimants, but,
for the foregoing reasons, we are obliged to deny these claims.
Claims disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 515
REFERENCE
S
Advisory Opinions Landslides?See also
Falling
Agency Rocks
Annual Leave Limitation of Actions
Arbitration Motor Vehicles?See also Negli Assumptio of Risk gence; Streets and
Highways
Bailment Negligence?See also Motor
Blasting Vehicles; Streets and Highways
Board of Regents Notice
Bridges Office Equipment and Supplies
Building Contracts Pedestrians
Civil Service Commission Personal Services
Colleges and Universities?See Physicians and Surgeons?See
Board of Regents also Hospitals
Comparative Negligence Prisons and Prisoners
Condemnation Public Institutions
Conspiracy Public Officers
Contracts?See also Building Real Estate
Contracts Rehearing
Contributory Negligence Res Judicata
Damages State Agencies
Department of Motor Vehicles Statutes
Drains and Sewers?See also Stipulation and Agreement
Waters and Watercourses Streets and Highways?See also
Electricity Falling Rocks; Landslide; Motor
Expenditures?See also Office Vehicles; Negligence
Equipment and Supplies Taxation
Falling Rocks?See also Trees and Timber
Landslides Trespass
Flooding Wages
Foster Children Waters and Watercourses?See
Hospitals also Drains and Sewers;
Independent Contractor Flooding
Insurance Wells
Interest W.Va. University?See Board of
Jurisdiction Regents
Landlord and Tenant Workmen?s Compensation Fund
516 REPORTS STATE
COURT OF CLAIMS [W. VA.
ADVISORY OPINIONS
An advisory determination by the Court
was sought where an institution of the respondent underpaid its statutory
contribution to Employment Security. The Court indicated that an award could
not be made based upon the Airkem decision, as sufficient funds were not
available in the proper fiscal year. Dept. of Employment Security vs. Dept.
of Corrections
(CC-81-388) 89
An advisory determination claim for accrued interest on an amount due
Employment Security when respondent?s institution underpaid its statutory
contribution to the claimant was denied as West Virginia Code ?14-2-12
precludes the payment of interest by the Court. Dept. of Employment
Security vs.
Dept. of Corrections (CC-81-388) 89
In an advisory opinion issued by the Court, the respondent was held liable for
work performed on a boiler at respondent?s institution. Respondent?s inability
to pay claimant was the result of an administrative error. Welding, Inc. vs.
Dept.
of Corrections (CC-82-76) ? 150
AGENCY
A claim for injuries sustained by the
decedent at the 34th Annual West Virginia Poultry Convention and Festival was
denied as it was not established that an agency relationship existed between
the respondent and the Poultry Association. John Mullenax, Administrator of
the Estate of Edith Mullenax
vs. Dept. of Agriculture (CC-78-157) 328
ANNUAL LEAVE
A claim for accumulated annual leave
was granted where the Court determined that the authority to establish rules
and regulations is granted to the Civil Service Commission by West Virginia
Code ?29-6-10, and, pursuant to the Code, the Civil Service Commission had
established a provision allowing certain employees to carry forward more than
thirty days from one year to the next. Ca.rol J0 Brown vs. Dept. of Health
(CC-82-81) 159
ARBITRATION
A claim for the enforcement of an
arbitration action which involved the claimant and the respondent was awarded
by the Court as the general law appears to indicate that a State or its
agencies may enter a valid contract with a private party providing for
arbitration of disputes that may arise under a contract. Hughes-Bechtol,
Inc. vs. Board of Regents (CC-81-
450) 189
In an action filed for the enforcement of an arbitration award made to the
claimant based upon a contract provision which provided for the arbitration of
disputes between the parties, the Court granted an award as it is clear that
the
W. VA.] REPORTS
STATE COURT OF CLAIMS 517
policy of the law of this State favors arbitration. HughesBechtol, Inc. vs.
Board of Regents (CC-81-450) 189
ASSUMPTION OF RISK
The Court held that the claimant
assumed the risk of any loss which resulted when claimant entrusted a ward of
the State with his vehicle, and denied the claim. John Charles Bungard vs.
Dept. of Welfare (CC-80-352) 48
The Court denied a claim for personal property of the claimant, an employee of
the respondent, as the Court held that the claimant assumed the risk in leaving
the personal property in his unlocked desk. Richard J. Lindorth vs.
Workmen?s Compensation Fund (CC-81-41) 60
The Court denied an award to the claimant for work performed where the claimant
acted without a contract and was informed by the respondent that any work done
would be performed at the claimant?s own risk. Monsanto Company vs.
Board of Regents (CC-78-282) 251
BAILMENT
Claimant sought payment for a missing
Victor 100 calculator which had been loaned to the respondent, and the Court
made an award based upon the law of bailment. Charleston Business
Machines vs. State Tax Dept. (CC-82-54) 161
While claimant was a patient at Huntington State Hospital, his property was
lost, and the Court made an award for the property based upon the law of
bailment. Larry Greathouse
vs. Dept. of Health (CC-82-64) 154
A claim for damages to claimant?s vehicle was granted where the respondent
admitted the validity and amount of the claim. The Hertz Corporation vs.
Dept. of Public Safety
(CC-82-l37) 170
In a bailment situation, where respondent took possession of claimant?s
property and failed to return it, the Court determined that claimant
established a prima facie case against respondent as bailee, and made an award
for the value of the property. Andrew S. McGalla vs. Board of Regents
(CC-81-
90) 463
The Court made an award for certain video equipment which was lost or stolen
while being loaned to the respondent as the respondent admitted the claim. Region
V?Regional Education Service Agency vs. Dept. of Employment Security
(CC-81-426) 110
BLASTING
A claim for property damage which
occurred while claimant?s property was leased to the respondent was granted, as
damages to the residence and other outbuildings were the
518 REPORTS STATE
COURT OF CLAIMS [W. VA.
result of blasting activities performed on the property to
quarry rock. Chester Jones vs. Dept. of Highways (CC-76-51) 221
The Court will deny a claim for damage to claimant?s property allegedly caused
by blasting operations performed by respondent?s contractor where the blasting
is done in a barren, rural section, or in a mountainous area far from human
habitation. Catherine Pasceri vs. Dept. of Highways (CC-78-
186) 313
BOARD OF REGENTS
The claimant was granted an award for
work performed under a contract where the award exceeded the amount of the
contract, but the claimant had performed work beyond the terms of the contract
at the request of respondent?s officials. To deny the claimant payment for the
services actually performed would unjustly enrich the respondent. Appalachian
Engineers, Inc. vs. Board of Regents (CC-81-55) 493
Where a miscalculation in claimant?s rate of pay was made, the Court granted an
award to the claimant in the amount of the underpayment. Susan L. Cale vs.
Board of Regents (CC 82-160 262
A claim for a cassette deck which disappeared from claimant?s dormitory room
was denied where there was no evidence of negligence on the part of the
respondent in maintaining proper security for the dormitory. Roger K. Clay
vs. Board of
Regents (CC-82-l23) 300
Claimant was granted an award for radio equipment lost by the respondent. General
Communications Company vs. Board
of Regents (CC-81-80) 5
When a tree on respondent?s property fell during a snowstorm, cutting the power
lines to claimant?s residence and causing his tropical fish to freeze, a claim
for the value of the fish was denied. Henry W. Gould vs. Board of Regents
(CC-79-357) 304
Due to a clerical error, the claimant did not receive a pay
increase. The Court made an award to the claimant for the
amount of the increase. Margaret Graff vs. Board of Regents
(CC?82-216) 318
A claim for breach of contract for personal services was denied by the Court
where claimant alleged he was not paid for annual leave. The Court determined
that the annual leave had been paid. Francis J. Hennessy vs. Board of
Regents
(CC-80-340) 103
The Court determined that respondent?s failure to properly inspect and maintain
the equipment in its laundry facility constftuted negligence, and this
negligence proximately caused the damage to claimants? personal property. Mr.
and Mrs.
Stephen Kent Hill vs. Board of Regents (CC-80-183) 283
W. VA.] REPORTS
STATE COURT OF CLAIMS 519
A claim for the contract price of a piece of equipment was denied where the
Court determined that the claimant failed to ascertain whether or not the
equipment would conform to the specifications in the contract, and, because the
equipment did not conform, the respondent, under the terms of the contract, had
the right to cancel that portion of the contract. Hooten Equipment Company vs. Board of Regents (CC-80-
337) ?
503
An award for damage to personal property was made where
the respondent was negligent in failing to remedy a shelf
defect of which it had prior knowledge. Charles
W. Jones vs.
Board of Regents (CC-81-35) 6
Claimant sought payment for loss of veteran?s benefits allegedly due to
counseling errors at Southern West Virginia Community College, and the Court
made an award for the loss because claimant relied upon his adviser in
selecting his course work. Raymond L.
Maynard vs. Board of Regents (CC81-206)
? 225
The Court granted an award to the claimant where it appeared that the
respondent breached a contract of employment with the claimant. William B. McGinley vs. Board of
Regents (CC-81-20) 271
A contract provision entered into by the claimant and West Virginia University,
which provided that the meat was sold on a per piece basis, was enforced by the
Court, and an award was made to the claimant based upon the terms of the
contract. Shane Meat Company vs. Board
of Regents. (CC 82-86 233
The Court denied an award where the claimant alleged damages due to changes in
the requirements for obtaining a Master?s Degree which delayed claimant?s
receipt of the degree. The Court held that a college or university is
authorized to examine students and determine whether or not they have met all
requisites for a degree. The college or university?s decision is conclusive,
provided that the degree may not be arbitrarily refused, and the Court
concluded that the delay was not arbitrary. Terry Skeen vs. Board of Regents
(CC-79-194) 412
BRIDGES
An award for personal injury was
granted by the Court when claimant, while acting as a deputy sheriff, was
standing on a bridge and fell between the steel members of the bridge deck. The
Court found that the respondent was negligent in its maintenance of the deck. Norman E. Benson vs. Dept. of
Highways (CC-79-503) 193
A claim for damage to a vehicle which struck a hole in a bridge was granted
where photographs of the pothole revealed
520 REPORTS STATE
COURT OF CLAIMS [W. VA.
the hole to be sufficient depth that the steel reinforcing rods on the bridge
were exposed. The respondent has the duty of exercising reasonable care and
diligence in the maintenance of its highways. Jack E. Brown vs. Dept. of Highways (CC 82-6 167
An award was made when a vehicle was damaged because of negligent maintenance
by the respondent of a bridge on which the deck had settled. John I?. Coffman vs. Dept. of
Highways (CC-82-5l) 216
A claim for damage to two tires of a vehicle, which occurred as the result of
the poor condition of a bridge deck, was denied as there was no evidence of a
defect, if any, in the bridge surface. John
J. Gaughan vs. Dept. of Highways (CC
80-353 ?
122
Claimant was granted an award for damage to his vehicle which struck a large hole
in the Patrick Street Bridge, which bridge was under construction, as the Court
held that the respondent was aware of the particular hole prior to claimant?s
accident. Alonzo Gibson vs. Dept. of
Highways (CC
-81-7) 57
Claimant, who sustained injuries when he fell from a bridge on which the
guardrails were missing, was denied an award as there was no proof that the
respondent had notice of the missing rails and claimant had prior knowledge of
the bridge?s
condition. Nelson Gregory vs. Dept. of
Highways (CC-79-307) 355
A claim for damage to an automobile struck by a bolt which broke from a bridge
was granted where the Court determined that the respondent was negligent in
failing to use reasonable care to keep the bridge in reasonable safe condition.
Robert Howard Latta vs. Dept. of
Highways (CC-82-
147) ?
289
An award for injuries received in a fall from a bridge was reduced under the
doctrine of comparative negligence because the claimant had prior knowledge of
the condition of
the bridge. John T. May vs. Dept. of
Highways (CC-81-165) 290
Where claimants? vehicles sustained damage when a concrete section of bridge
fell on an interstate system, the Court held that respondent had a duty to
maintain the bridge such that a major deck failure would not occur. The Court
therefore made awards to the claimants for damage to their vehicles. Thomas E. McNamee vs. Dept. of Highways (CC-81
-100); Allstate Insurance Company as
Subro gee of Jacqueline
E. Delazio and Jacqueline E. Delazio, Individually (CC-8l-
114) ?
62
A claim by a contractor for payment of a wash coat placed upon a bridge during
a painting operation was denied by the Court as the Standard Specifications of Roads and Bridges requires a wash coat if recommended by the
manufacturer.
W. VA.] REPORTS
STATE COURT OF CLAIMS 521
The Melbourne Brothers Construction
Company vs. Dept. of
Highways (CC-77-150) 226
The Court made an award for damage to claimants? vehicle
which struck a piece of steel protruding from the surface of a
bridge on West Virginia Route 52. Irlant
E. Moore and Robert L. Moore vs. Dept. of Highways (CC-82-179) 253
Where claimant?s vehicle was damaged by loose timber
decking protruding from a bridge on West Virginia Route 15,
the Court made an award to the claimant. John
Orndoff vs.
Dept. of Highways (CC-82-111) 254
A claim for damage to a vehicle which struck a pothole on a bridge was denied
as there was no evidence of notice on the part of the respondent. Randall E. Rowley vs. Dept. of High way (CC-82-16) 183
The Court made an award to the claimant for damage to a tire on his automobile
which struck a piece of metal protruding from a bridge. Thomas R. Treadway vs. Dept. of High way (CC-82-227) 296
BUILDING CONTRACTS
A claim for additional compensation as
the result of a change in the scope of a design contract was denied by the
Court because the claimant designed the highway within the scope and intent of
the agreement. A. B. Engineering
Company vs. Dept. of Highways (D-773)
42
The record in a contract claim established that an unanticipated subsurface
condition existed on the project, and this condition caused the contractor to
incur extra expense for which the Court held that the contractor was entitled
to be compensated. McAnallen Brothers,
Inc. vs. Board of Regents
(D-1031) ? 240
A claim by a contractor for payment of a wash coat placed upon a bridge during
a painting operation was denied by the Court as the Standard Specifications of Roads and Bridges requires a wash coat if recommended by the
manufacturer. The Melbourne Brothers
Construction Company vs. Dept. of
Highways. (CC-77.-150) 226
The Court denied an award to the claimant for work performed where the claimant
acted without a contract and was informed by the respondent that any work done
would be performed at the claimant?s own risk. Monsanto Company vs.
Board of Regents (CC-78-282) 251
The Court made an award to the claimant contractor who incurred increased costs
in labor and materials as the result of having been prevented from starting
construction work at the time indicated in the contract. Novo Corporation vs. Dept. of
Highways (CC-78.-175) 140
522 REPORTS STATE
COURT OF CLAIMS [W. VA.
In a contract claim for increased costs allegedly incurred by reason of delays
caused when the site preparation work was not completed in time for the
contractor to begin its work, the Court made an award for the increased costs. Novo
Corporation vs. Dept. of Highways (CC-78-175) 140
The Court denied a claim for extra work in the excavation of a sewer project
where the evidence revealed that the method of installing the storm sewer was
chosen by the contractor, and it was that method which resulted in the extra
costs claimed. The Pioneer Company and Mountain State Construction Company,
Inc. vs. Dept. of Highways (CC-76-148) 256
Claimant contractor sought to recover the cost of the installation of hot laid
bituminous concrete which resulted from delays on the part of respondent. The
Court made an award to the claimant as the delays were caused by the
respondent. Savage Construction Company, Inc. vs. Dept. of Highways
(CC-81-14) ?
274
The Court made an award for liquidated damages assessed against the claimant
for delay in the completion of a section of Corridor E where the respondent
contributed to the delay on the project. Shelly & Sands, Inc. vs. Dept.
of Highways
(CC-78-l65) 473
An award was made to the claimant for concrete grout which was supplied to the
respondent for use in certain highway projects. Wayne Concrete Co. vs. Dept.
of Highways
(CC?82?109) 259
CIVIL SERVICE COMMISSION
The Court denied a claim wherein
claimant asked the Court to rule upon a decision rendered by the Civil Service
Commission. The Court determined that the claimant did not appeal to the Commission
within the proper time period, and the decision of the Commission was correct. Gary
L. Batton vs. Civil Service Commission and Dept. of Natural Resources
(CC-81-203) 114
COLLEGES AND UNIVERSITIES?See Board of
Regents
COMPARATIVE NEGLIGENCE
In a wrongful death action, the Court
held that respondent was negligent in failing to remove a mud slide from the
road, and in not warning the traveling public of the danger. The Court also
found that the decedent, who had prior knowledge of a hazard in the road, was
negligent; accordingly, the award was reduced, based upon the doctrine of
comparative negligence. Lillian Akers, Administratris of the Estate of Gary
Wayne Akers, Deceased vs. Dept. of Highways (CC 78-222 491
W. VA.] REPORTS
STATE COURT OF CLAIMS 523
An award was made for damage to claimants? home where two trees fell on the
house. The Court determined that the trees fell when caught in a slide which
resulted when the respondent failed to maintain a ditch line; however, the
award was reduced under the doctrine of comparative negligence, as the
claimants were aware of the clogged ditch line but failed to inform the
respondent of the condition. James Burch.am
and Patricia J. Burcham vs. Dept. of Highways (CC-80-252) 441
An award for an injury sustained in a fall was reduced to reflect claimant?s
comparative negligence where the respondent left a ?hump? of blacktop pavement
in a street which was being prepared for repaving, and the evidence also showed
that the claimant was negligent in failing to maintain an adequate lookout upon
the surface of the road. Armeda
Jean Bush vs. Dept. of Highways (CC-8l-204) 496
The Court denied a claim for damage to an automobile which struck a pothole
under the doctrine of comparative negligence where the driver of the vehicle
testified that she was aware of the potholes in the road. Jerry M. Edwards
and
Edgar E. Edwards vs. Dept. of Highways (CC-82-198) 354
The Court applied the doctrine of comparative negligence in a claim for
personal injuries resulting from an automobile accident, where the respondent
negligently failed to exercise reasonable care in maintaining the road, but the
claimant was also negligent in failing to maintain proper control of his
vehicle when he was aware of the hazardous condition of the
road. Millard A. Harmon vs. Dept. of Highways (CC-80-373) 454
A claim for personal injuries and property damage to a vehicle was denied where
the evidence revealed that the claimant was very familiar with the defect in
the road which had been caused by a slip. Under the doctrine of comparative
negligence, the negligence of the claimant in traveling a road at night in rain
and fog, known by him to be in disrepair, was equal to or greater than the
negligence of the respondent in its failure to repair the road. Forrest C.
Hatfield vs. Dept.
of Highways (CC-78-227) 220
Although the respondent had actual knowledge of the hazardous condition of the
highway, the claimant operator of the vehicle also was aware of the propensity
of ice to freeze upon the highway at that particular location. The Court
applied the doctrine of comparative negligence and reduced the award to the
claimant. Robert N. Jarboe, Patricia Ann Jarboe, and Stephanie Jarboe vs.
Dept. of Highways (CC-79-297) 13
The Court applied the doctrine of comparative negligence and disallowed claims
where the negligence of the driver was equal to or greater than that of the
respondent. Keller Industries, Inc. vs. Dept. of Highways (CC-8l-29) and
Ryder Truck
Rental, Inc. vs. Dept. of Highways (CC-80-381) 417
524 REPORTS STATE
COURT OF CLAIMS [W. VA.
Although the respondent may have been negligent in failing to warn motorists of
a flooded section of road, the negligence of the claimant in failing to
exercise ordinary care equaled or exceeded the negligence of the respondent;
therefore, the Court denied the claim. Mar
go A. Keyser vs. Dept. of High way (CC-80-164)
27
In a claim for damage to a vehicle which struck a pothole, the Court applied
the doctrine of comparative negligence and denied the claim where it appeared
that the driver?s negligence was equal to or greater than the respondent?s
negligence, based upon prior knowledge of the condition of the road.
Tommy Kinder vs. Dept. of Highways (CC-82-llO) 311
Where the claimant was aware of defects in the highway and the respondent had
constructive notice of the defects, the Court followed the doctrine of
comparative negligence and denied the claim. Virginia Lewis vs. Dept. of Highways (CC
80-421 8
A claim for property damage and personal injury which occurred when claimants?
vehicle struck an endloader parked on the edge of the highway was granted, as
the Court determined that the respondent was negligent in failing to place a
warning light to indicate the existence of the endloader. Liberty Mutual Insurance Company, subro gee of Edward
E. and Jennifer Dilling, and Edward E. and Jennifer Dilling vs. Dept.
of Highways (CC-81-93) 171
An award for injuries received in a fall from a bridge was reduced under the
doctrine of comparative negligence because the claimant had prior knowledge of
the condition of the
bridge. John T. May vs. Dept. of
Highways (CC-8l-165) 290
The Court applied the doctrine of comparative negligence in a claim for water
damage to claimants? property where it appeared that the damage resulted in
part from respondent?s failure to keep a ditch line clear and in part from
claimants? negligent construction of a driveway which undercut the support of
the road. The Court held that the negligence of the claimants was equal to or
greater than that of the respondent, and denied the claim. James Pack & Ella Mae Pack vs. Dept.
of Highways (CC-79-125) 337
Under the doctrine of comparative negligence, the Court determined that the
claimant?s negligence, where he knew of the road condition which damaged his
vehicle, equalled or exceeded the negligence of the respondent, and the claim
was denied. Robert G. Riner vs. Dept.
of Highways (CC-82-
288) ?
432
Where claimant?s vehicle sustained damage when he collided with a median strip,
the Court made an award as the respondent was guilty of negligence which was
the proxi
W. VA.] REPORTS
STATE COURT OF CLAIMS 525
mate cause of the accident; however, the Court applied the doctrine of
comparative negligence and reduced the award by
20%. James Scott Sadler
vs. Dept. of Highways (CC-80-422). 17
The Court applied the doctrine of comparative negligence and denied a claim for
damage to a vehicle which struck a pothole. The Court held that the negligence
of the driver in striking a pothole located on the berm of the road equalled or
exceeded any negligence of the respondent. Robert C.
Schumacher vs. Dept. of Highways (CC-82-55)
315
Where the claimant had notified the respondent of the defect in the highway,
and further testified that she knew of the existence of the defect in the
highway, the Court denied the claim based upon the doctrine of comparative
negligence. Margaret Spataf ore and
Joseph Robert Spatafore vs. Dept.
of Highways (CC-80-185) 18
A claim for damages to an automobile was denied as the Court determined that
the claimant, with prior knowledge of the condition of the road, was negligent,
and this negligence was equal to or greater than that of the respondent. Bertie Gibbs Thomas and Carolyn Thomas vs. Dept. of
ffighways
(CC?82-163) 316
A claim for vehicle damage was denied where it was established that the
respondent had placed warning signs in the vicinity of the slip in the roadway,
and the driver testified that he did not observe the signs. The Court held that
the negligence of the driver equalled or exceeded any negligence on the part of
the respondent. Alex Toth vs. Dept. of
High way (CC-82-113) 480
A claim for damage to real property based upon respondent?s alleged negligence
in maintaining a catch basin was disallowed where the Court determined that
several conditions existed which led to claimant?s damages. The Court applied
the doctrine of comparative negligence where the claimant?s acts significantly
contributed to the problem, and this negligence was equal to or greater than
that of the respondent.
A. B. Williams vs. Dept. of Highways (CC-79-466) 482
CONDEMNATION
A claim was dismissed as it was the
proper subject for condemnation proceedings. Under the provisions of West
Virginia Code ?14-2-14(5), the Court had no jurisdiction over
the claim. Day P. Crites vs. Dept. of
Highways (CC-81-378) 428
The Court denied an award for equipment allegedly taken by respondent following
an eminent domain proceeding. There was no evidence to suggest that respondent
took possession of claimant?s equipment, and claimant had received compensation
as a result of the eminent domain proceeding. Robert Hart, d/b/a Bob?s Bake Shop vs. Dept. of Highways (CC-79-
685) ?
443
526 REPORTS STATE
COURT OF CLAIMS [W. VA.
A claim for removal of a roadway from claimant?s property was denied based upon
a provision of the lease entered into by the claimant and the respondent. Bessie
M. Stone, by Charles H. Stone, her Attorney in Fact vs. Dept. of Highways
(CC-79-35) ?
143
CONSPIRACY
The Court dismissed a complaint for
failure to state a claim upon which relief could be granted where the claimants
failed to allege facts to show that respondent?s employees formed a conspiracy
to require claimants to forfeit a bond which had been posted as security for a
strip mining permit. Ida M. Hiner and Norman F. Hiner, d/ b/a Hercules
Construction Company
vs. Dept. of Natural Resources (CC-80-150) 430
CONTRACTS?See also Building Contracts
The claimant was granted an award for
work performed under a contract where the award exceeded the amount of the
contract, but the claimant had performed work beyond the terms of the contract
at the request of respondent?s officials. To deny the claimant payment for the
services actually performed would unjustly enrich the respondent. Appalachian
Engineers, Inc. vs. Board of Regents (CC-81-55) 493
As the evidence in the claim was clear that the contract project was stopped by
the respondent, and the contract was terminated or rescinded without fault on
the part of the contractor, the Court made an award for damages sustained by
the claimant. Black Rock Contracting, Inc. vs. Dept. of High way (CC-80-222)
340
Under claimant?s contract with the respondent, claimant was to dispose of waste
material from a project, and therefore entered into a contract with a third
party for the waste material. When the respondent terminated the contract with
the claimant, the claimant incurred expenses of litigation as the result of the
breach of its contract with the third party. The Court determined that,
although the general rule is that attorney?s fees and expenses incurred in
litigation are not recoverable, an exception to that rule exists where a breach
of contract has forced a party to maintain or defend a suit with a third
person, and the Court made an award for this portion of the claim. Black
Rock Contracting, Inc. vs. Dept. of High way (CC-80-222) 340
The claimant was granted an award for additional materials used in building a
fence as the respondent failed to provide claimant with a complete diagram of
the area. To deny the award would unjustly enrich the respondent. Butler
Corporation vs. Dept. of Highways (CC-81-440) 442
The Court made an award to a contractor who filed a claim requesting payment
for increases in transportation charges for
W. VA.] REPORTS
STATE COURT OF CLAIMS 527
sand and gravel in bulk under a specific section of the Standard
Specifications for Roads and Bridges. The Court determined that the
deregulation of transportation rates occurred as the direct result of an act of
a public authority, i.e., the Federal government, and that the claimant was
entitled to the increase which resulted. Carl M. Geupel Construction Co.,
Inc. vs. Dept. of Highways (CC-79-172) 200
A delay by the respondent in approving materials through the ?green tag?
process delayed a contractor on a project for which the respondent then
assessed liquidated damages. The Court made an award to the contractor for the
liquidated damages. Cochran Electric Company vs. Dept. of Highways
(CC-76-117) 206
The Court upheld an assessment of a portion of liquidated damages against a
contractor where the evidence indicated that a portion of the delay was the
result of a late start by the contractor. Cochran Electric Company vs. Dept.
of Highways
(CC-76-1l7) 206
The Court denied an award to a contractor who alleged that the failure of the
respondent to permit the contractor from withdrawing a bid caused damages to
the contractor. The Court determined that the Director of the Purchasing
Division did not abuse the discretion granted to him under the purchasing
regulations. G. M. McCrossin, Inc. vs. Board of
Regents (CC-79-682) 265
Claimant sought recovery for services provided under an architectural agreement
with the respondent, and the Court denied the claim as it was clear that the
claimant had been reimbursed under the terms of the contract. Gates
Engineering Company, et al. vs. Board of Regents (CC-82-68) 500
A claim for breach of contract for personal services was denied by the Court
where claimant alleged he was not paid for annual leave. The Court determined
that the annual leave had been paid. Francis J. Hennessy vs. Board of
Regents
(CC-80-340) 103
The Court denied a claim for architectural work performed for the Fairmont
Emergency Hospital because claimant did not have a contract with the
respondent. Henry Elden & Associates vs. Dept. of Health and Dept. of
Finance and Admin istratio (CC-79-367) 307
The Court made an award to the claimant for redesigning certain water and sewer
facilities. The work was performed prior to the time claimant received
authorization for the work; however, the Court determined that, based on the
standard of equity and good conscience, an award must be granted. Holly,
Kenney, Schott, Inc. vs. Dept. of Highways (D-893) 381
528 REPORTS STATE
COURT OF CLAIMS [W. VA.
A claim for the contract price of a piece of equipment was denied where the
Court determined that the claimant failed to ascertain whether or not the
equipment would conform to the specifications in the contract, and, because the
equipment did not conform, the respondent, under the terms of the contract, had
the right to cancel that portion of the contract. Hooten Equipment Company vs. Board of Regents (CC-80-
337) 503
In an action filed for the enforcement of an arbitration award made to the
claimant based upon a contract provision which provided for the arbitration of
disputes between the parties, the Court granted an award as it is clear that
the policy of the law of this State favors arbitration. HughesBechtoi, Inc. vs. Board of Regents (CC-81-450) 189
A claim for the enforcement of an arbitration action which involved the
claimant and the respondent was awarded by the Court as the general law appears
to indicate that a State or its agencies may enter a valid contract with a
private party providing for arbitration of disputes that may arise under a
contract. Hughes-Bechtol, Inc. vs.
Board of Regents (CC-81-
450) 189
The Court denied a claim where the respondent canceled a purchase order for
winter grade asphalting mixture. The material did not meet specifications, and
because it was not fit for its intended use, the respondent was obliged to
cancel the purchase order. John D.
Tonkovich and Sons, Inc. vs. Dept.
of Highways (CC-81-140) ? 505
The Court denied a claim for damages based on respondent?s cancellation of a
contract for the lease of a building where the contract contained a
cancellation provision. L. R. Lewis and
B. L. Lewis vs. Dept. of Finance and Administration and
Dept. of Welfare (CC-82-235) ? 336
The Court granted an award to the claimant where it appeared that the
respondent breached a contract of employment with the claimant. William B. McGinley vs. Board of
Regents (CC-81-20) 271
The Court denied a portion of a contract claim based upon the cost of bond
required by the U.S. Coast Guard in the removal of an existing structure on a
river, as the Court determined that the contractor must bear this expense. The Melbourne Brothers Construction Company vs. Dept.
of Highways (CC-77-l50) ? 226
A claim for reimbursement for monies allegedly spent repairing a public road
was disallowed as claimant had no contract to perform the work. D. Albert Moore vs. Dept. of High way (CC-80-97a) 410
W. VA.] REPORTS
STATE COURT OF CLAIMS 529
The Court overruled respondent?s defense based on a Special Plea of Release as
claimant?s claim was filed within 120 days following claimant?s acceptance and
approval of the final estimate under a construction contract, as was provided
in the estimate. Preston Contractor?s Inc. vs. Dept. of Highways
(CC-80-158) 465
Claimant corporation created a subdivision and filed a claim for the cost of
widening an access road, which claim was denied because there was no contract
with the respondent to bear this cost. Rainbow Development Corporation vs.
Dept. of
Highways (CC-81-350) 228
An award for medical services rendered to an inmate of the State Penitentiary
at Moundsville was made where the Court determined that a Medical Respite
signed by the wife of the inmate and the Governor of West Virginia did not
establish a contract which would obligate the inmate?s family to bear the
inmate?s medical expenses. Reynolds Memorial
Hospital, Inc. vs. Dept. of Corrections (CC-82-28) 273
An agreement between claimant and a representative of respondent, by which
claimant would provide medical services to respondent at a 10% discount, was
invalid because respondent?s representative signed the agreement without the
authority to do so. While the claimant is entitled to the full value of its
services, the Court disallowed the claims based upon the decision in Airlcem
Sales and Service, et al. v. Dept. of Mental Health, 8 Ct. Cl. 180 (1971). Reynolds
Memorial
Hospital, Inc. vs. Dept. of Correction (CC-82-212a&b) 321
A contract provision entered into by the claimant and West Virginia University,
which provided that meat was sold on a per piece basis, was enforced by the
Court, and an award was made to the claimant based upon the terms of the
contract.
Sh.ane Meat Company vs. Board of Regents (CC-82-86) 233
An award was made for window cleaning services where the Court determined the
amount due under the contract after a dispute arose. Swain Window Cleaning
Services vs. Dept.
of Finance and Administration (CC-82-301) 385
Claimant was awarded additional compensation for work performed under a piano
tuning and maintenance contract where the Court determined that the contract
was ambiguous, and the claimant performed services beyond the terms of the base
price for tuning. Donald F. Udell vs. Board of Regents
(CC-81?359) 450
Claimant?s claim for additional costs under a construction contract was denied
where the claimant failed to notify the project engineering in writing of its
intention to make a claim for additional compensation as required under the
contract. Vecellio & Grogan, Inc., for Peraldo Construction Company
vs. Department of Highways (CC-81-343) 451
530 REPORTS STATE
COURT OF CLAIMS [W. VA.
The Court made awards in the amounts withheld under two paving contracts. Respondent?s
statistical analysis concluded that a certain amount of the pavement would be
below the required specification, but, as the evidence did not substantiate
this conclusion, the Court made the awards. Veceillo
& Grogan, Inc. vs. Dept. of Highways (CC-81-425 &
CC-82-92) 467
The Court dismissed a claim based upon a theory of negligent interference with
a contract due to respondent?s alleged arbitrary and capricious denial of
approval for a septic system where the evidence did not indicate that respondent
was ultimately responsible for approving the system. Michael E. Whalen and
Ann Whalen vs. Dept. of Health and Donald
Greene, Sanitarian (CC-81-219) 509
The Court held open a claim so that the parties could agree upon an amount due
the claimant based on a quantum meruit recovery. Xerox Corporation vs. Dept.
of Natural Resources
(CC-82-236) 435
CONTRIBUTORY NEGLIGENCE
The contributory negligence of the
parent operator of a vehicle cannot be imputed to a child passenger. The child
was granted an award for the injuries she received in an accident where the
respondent was found negligent. Robert
N. Jarboe, Patricia Ann Jarboe, and Stephanie Jarboe vs.
Dept. of Highways (CC-79-297) 13
Where the claimant/operator and the claimant/owner/passenger were engaged in a
joint venture at the time and place of the accident, the contributory
negligence of the operator of the vehicle will be imputed to the passenger. Robert
N. Jarboe, Patricia Ann Jarboe, and Stephanie Jarboe vs. Dept. of
Highways (CC-79-297) 13
DAMAGES
The Court made an award for damage to
real property when employees of the respondent performed negligently in certain
excavation work. Oncie E. Archer et al. vs. Dept. of Highways
(CC-81-390) 96
A claim for damages allegedly caused by respondent?s alleged negligence in
certifying a certain parcel of real estate for sale to the Commissioner of
Delinquent and Forfeited Lands contained items of damages relating to costs of
litigation or to ownership and maintenance of property, and if the claim were
viewed as a contract claim, those items of expense could not be considered
?foreseeable.? For that reason, recovery would be precluded by the doctrine
enunciated in Hadley v. Baxendale, 89 Exch. 341. Willard Casto vs.
State
Auditor?s Office (CC-79-116) 86
A delay by the respondent in approving materials through the ?green tag?
process delayed a contractor on a project for
W. VA.J REPORTS
STATE COURT OF CLAIMS 531
which the respondent then assessed liquidated damages. The Court made an award
to the contractor for the liquidated damages. Cochran Electric Company vs.
Dept. of Highways
(CC-76-117) 206
An award was made to the claimant for damage to his vehicle which struck a
broken metal drain hole cover. The Court found that respondent?s failure to
repair the broken cover was the proximate cause of the claimant?s damages.
Glenn F. Hiller vs. Dept. of Highways (CC-82-183) 269
In order for the Court to make an award for flood damages to claimant?s
property, the Court must be satisfied that respondent?s actions resulted in the
alleged damage. Since the evidence was conflicting as to the cause of the
damage, and the Court cannot base an award upon speculation, the claim was
denied. James David Hutchinson vs. Dept. of High way (CC-80-291)
335
Claimant sought recovery of liquidated damages charged against it and the Court
denied this portion of the claim as the claimant failed to complete its work on
time and the bridge under construction was not able to be opened to traffic. Savage
Construction Company, Inc. vs. Dept. of High way (CC-81-14) 274
The Court made an award for liquidated damages assessed against the claimant
for delay in the completion of a section of Corridor E where the respondent
contributed to the delay on the project. Shelly & Sands, Inc. vs. Dept.
of Highway
(CC?78-165) 473
In an action to recover liquidated damages assessed against the claimant by the
respondent for failure to complete the installation of a lighting system on
1-64, the Court made an award to the claimant for the liquidated damages,
concluding that respondent?s inadvertent error of green tagging the junction
boxes contributed to claimant?s delay in completing the project. Stark
Electric, Inc. vs. Dept. of Highways (CC-80-
193) ?
277
In an action to recover liquidated damages assessed by the respondent, the
Court made an award to the claimant for the liquidated damages as it did not
appear from the evidence that the respondent suffered any damages as a result
of the delay in completing the contract. Stark Electric, Inc. vs. Dept. of
Highways (CC-80-193) 277
DEPARTMENT OF MOTOR VEHICLES
The Commissioner of Motor Vehicles is
charged with making rules and regulations concerning the administration and
enforcement of motor vehicle inspections. A claim for the cost of converting an
automobile into a dune buggy which failed to meet inspection requirements was
denied as there was
532 REPORTS STATE
COURT OF CLAIMS [W. VA.
no evidence that the Commissioner abused his discretion in issuing the
regulations. Charles Dennis vs. Dept. of Public
Safety (CC-80-336) 301
The Court found that respondent was negligent in failing to record claimant?s
lien on a West Virginia Certificate of Title. An award was made to the claimant
for the damages sustained. General Motors Acceptance Corporation vs. Dept.
of Motor Vehicles (CC-82-46) 268
The Court denied a claim for the refund of costs experienced by the claimant
when the respondent suspended claimant?s license and registration pursuant to
West Virginia Code ?17D-3-3. Cynthia Catherine McGrath vs. Dept. of Motor Ve
hicle (CC?81-421) 132
As West Virginia Code ?17A-4-1 provides for the transfer, surrender, or retention
of plates upon expiration of registration, but makes no provision for refund of
fees, the Court denied a claim for the difference between the fees paid for
registration of two motor vehicles. Robert B. Moran vs. Dept.
of Motor Vehicles (CC-83-116) 479
An award was made to the claimant where the Court determined that the
respondent was negligent in erroneously titling claimant?s vehicle, resulting
in a higher license fee being incurred by the claimant. Harold E. Wiley vs.
Dept. of
Motor Vehicles (CC-80-331) 298
DRAINS AND SEWERS?Se also Waters and Watercourses An award was made for damage to a basement wall where
the Court determined that water was discharged onto claimant?s property due to
respondent?s failure to maintain a ditch line, and this failure was the
proximate cause of the damage sustained. Jesse C. Anderson vs. Dept. of
Highways (CC-81-
110) 360
The Court disallowed claimants? claims for property damage allegedly caused by
respondent?s failure to provide and maintain adequate drainage in the area of
their homes. The evidence indicated that other factors which were not the
responsibility of the respondent caused the damage. Anna Lou
Booten, et al. vs. Dept. of Highways (CC-81-176) 438
A claim for property damage as the result of a flood was denied where the
evidence did not establish that the culverts involved in the flooding were
clogged at the time of the storm. Doris Jane Bowen, et al. vs. Dept. of
Highways (CC80-342)
A claim for water damage to a barn allegedly caused by respondent?s improper
construction of a highway berm was denied where it was established that the
respondent conducted the highway repairs to the satisfaction of the claimant
prior to the flooding, that the flooding occurred as the result of a
W. VA.] REPORTS STATE
COURT OF CLAIMS 533
heavy rainstorm, and that the respondent did nothing to increase the flow of
water onto the claimant?s land. Charles
N. Durbin vs. Dept. of Highways (CC-81-181)
302
Claims for the costs of drainage pipes purchased by claimants and installed by
respondent were denied as the drain- pipes were installed under the claimants?
driveways, and respondent?s policy prohibited paying for drainpipes beneath
private driveways. James D. Eads, et
al. vs. Dept. of Highways
(CC-80-40 la-h) 498
The Court determined that respondent?s
construction of a new sewer system caused a substantial increase in the volume
of surface water flowing onto claimants? land, and granted an award for the
damages. Silbern D. and Metta Goddard vs.
Dept. of Corrections (CC-81-301) 281
The Court made an award to the claimant for flood damage to his home caused by
respondent?s failure to maintain a culvert located near claimant?s property. Benjamin C. Henry vs.
Dept. of Highways (CC-82-96) 371
An award was made to the claimants for damages sustained when their home was
flooded. The Court determined that the respondent negligently failed to design
and provide adequate drainage. Mark A.
Hissam and Julia A. Hissam vs. Dept. of
Highways (CC-80-375) - - 284
The evidence indicated that the slide which damaged claimant?s property was the
result of continuous saturation of the land from the drainage from claimant?s
home, and not the result of respondent?s ditch-cleaning operation. As the
evidence did not indicate that respondent acted negligently in performing its
duty of maintaining the drainage ditch, the Court denied the claim. David H. Kisor, Administrator of the Estate of Julia
Kisor, Deceased vs. Dept. of Highways (CC 79-122 506
The Court made an award for damage to claimant?s property due to flooding where
the evidence indicated that respondent?s installation of two culverts
obstructed the natural flow of the creek bordering claimant?s property and
diverted the water onto his land. Norman
Lewis vs. Dept. of Highways
(CC-80-334) - 507
The Court denied a claim for damage to a home allegedly caused by respondent?s
failure to maintain a drainage line, where it appeared that the hillside behind
claimant?s home contained subsurface water which flowed continuously, resulting
in movement of the land and damage to the house. Bernard C. Lyons
and Helen V. Lyons vs. Dept.
of Highways
(CC-79-578) 358
Where the respondent was negligent in altering the drainage which was the
proximate cause of the damages sustained by
534 REPORTS STATE
COURT OF CLAIMS [W. VA.
the claimant, the Court made an award for the damages.
Donald C. Master vs. Dept. of Highways (CC-80-131) 24
An award was made to the claimants for the loss of their home, which was
destroyed by a landslide. The preponderance of the evidence established that
the damage resulted from respondent?s improper maintenance of a ditch line
which caused water to be discharged over claimants? property, resulting in the
slide. Paul E. Miller and Marguerite
Miller vs.
Dept. of Highways (CC-81-396)
477
The Court applied the doctrine of comparative negligence in a claim for water
damage to claimants? property where it appeared that the damage resulted in
part from respondent?s failure to keep a ditch line clear and in part from
claimants? negligent construction of a driveway which undercut the support of
the road. The Court held that the negligence of the claimants was equal to or
greater than that of the respondent, and denied the claim. James Pack & Ella Mae Pack
vs. Dept. of Highways (CC-79-125) 337
The Court denied a claim for flood damage to claimant?s property allegedly
resulting from respondent?s negligent replacement of a culvert, as the evidence
did not establish that respondent acted negligently. Kenneth H. Patrick, Jr. vs.
Dept. of Highways (CC-79-315) 446
A claim for damage to property caused by water from a drainage ditch was denied
because it is the responsibility of the property owner to maintain driveways
contructed upon the rights of way of the respondent. Richard T. Philpot vs.
Dept. of Highways (CC-82-47)
181
The Court made an award to the claimants for flood damage to real and personal
property where it was established that an inadequately designed and constructed
drainage system failed to carry off water from the highway. Ruby E. Shrader vs. Dept. of Highways (CC-78-168), James
C. Martin, Jr. and Shirley B. Martin vs. Dept. of Highways (CC-78-231) 364
The Court made an award for water
damages to personal property which occurred when a culvert constructed beneath
Interstate 79 prevented the continuous flow of water from a creek near
claimant?s property and resulted in the flooding of her property. Velma Sutton vs. Dept. of Highways (CC 80-249 323
An award for property damage was granted where respondent?s failure to maintain
a drain caused water to flow across a road and onto claimants? property. Paul J. and Betty
0. tlnclerwood vs. Dept. of Highways. (CC-79-86)
-- - 242
The common law rule is that surface water is considered a common enemy, and
that each landowner may fight it off as best he can, with the modification that
an owner of higher
W. VA.] REPORTS
STATE COURT OF CLAIMS 535
ground may not inflict injury on the owner of lower ground beyond what is
necessary. The Court made an award to claimants whose properties were damaged
as the result of negligence by the respondent in the installation of drains
above the properties. Alva Katherine White vs. Dept. of Highways (D-748a)
and Paul White and Wanda White vs. Dept. of
Highways (D-748b) 212
A claim for damage to real property based upon respondent?s alleged negligence
in maintaining a catch basin was disallowed where the Court determined that
several conditions existed which led to claimant?s damages. The Court applied
the doctrine of comparative negligence where the claimant?s acts significantly
contributed to the problem, and this negligence was equal to or greater than
that of the respondent.
A. B. Williams vs. Dept. of Highways (CC-79-466) 482
ELECTRICITY
The respondent admitted the amount and
validity of a claim for an unpaid bill for electrical services, and the Court
made an award in the amount requested. Appalachian Power Company vs.
Dept. of Public Safety (CC-83-lll). See also Appalachian Power
Company vs. Dept. of Public Safety, 14 Ct. Cl.
(1983) (CC-83-118) 469
When a tree on respondent?s property fell during a snowstorm, cutting the power
lines to claimant?s residence and causing his tropical fish to freeze, a claim
for the value of the fish was denied. Henry W. Gould vs. Board of Regents
(CC-79-357) 304
The Court made an award to the claimant for damage to its secondary power line
caused by negligence on the part of the respondent?s employees. Monongahela
Power Company vs.
Dept. of Highways (CC-82-ll6) - 227
EXPENDITURES?See also Office Equipment
and Supplies
The Court made an award to the
claimant for merchandise which it delivered to the respondent but for which it
had not been paid and sufficient funds were available within the proper fiscal
year with which the agency could have paid the obligation. A. B. Dick
Company vs. Workmen?s Compensation
Fund (CC-81-323) 95
The following claims were decided upon the same principle:
American Hospital Supply vs. Dept. of Health (CC-82-197) 244
Appalachian Engineers, Inc. vs. Dept. of Finance and Ad ministratio (CC-82-90)
159 Appalachian Power Company vs. Dept. of Public Safety
(CC-83-l1l) --
-- - -- - - 469
Bailey, Incorporated vs. Board of Regents (CC-83-35) 470
536 REPORTS STATE
COURT OF CLAIMS [W. VA.
Beckman Instruments, Inc. vs. Dept. of
Health (CC-83-30) 438
Narendra Bora vs. Dept. of Health (CC-82-97) 245
Chicago Embroidery Company vs. Office
of the Secretary of
State (CC-82-91) 168
County Commission of Webster County vs.
Office of the
Supreme Court (CC-81-168) 75
Chad Cunningham vs. Dept. of Health (CC-82-323) 370
Clifford Cupp vs. Dept. of Health (CC-81-341) 53
Energy Technology Consultants, Inc. D
& M Weather Ser vice vs. Board of Regents (CC-81-443) 101
Evans Lumber Company vs. Division of
Vocational Rehabili tatio (CC-82-249)
345
Firestone Tire & Rubber Company vs.
Dept. of Natural Re source (CC-81-402)
102
C. Elaine Friend vs. Supreme Court of
Appeals (CC-82-314) 370
Hawes Elecertic Co. vs. Dept. of Health
(CC-81-431) 102
The Hertz Corporation vs. Dept. of
Public Safety (CC-82-
137) 170
Holzer Medical Center vs. Dept. of
Health (CC-83-28) 444
Howard Uniform Company vs. Dept. of
Public Safety
(CC-81-367) 91
Johnson Controls, Inc. vs. Dept. of
Finance and Administra tio (CC-81-316)
105
Johnson Controls, Inc. vs. Dept. of
Finance and Administra tio (CC-81-454)
106
Johnson Controls, Inc. vs. Dept. of
Finance and Administra tio (CC-82-87)
171
L. Robert Kimball & Associates vs.
Tax Dept. (CC-81-70) 7
Lundia, Myers Industries Inc. vs. Board
of Regents (CC 81-356 92
McDonnell Douglas Corporation vs. Dept.
of Education
(CC-81-124) - 16
Jeffrey 0. McGeary vs. Human Rights
Commission (CC 82?12 117
The Michie Company vs. Office of the
Supreme Court Ad ministrato (CC-82-3)
109
The Michie Company vs. Dept. of Health (CC-82-35) - -- 157
Miller?s Implement, Inc. vs. Dept. of
Health (CC-83-43) - 470
W. VA.] REPORTS
STATE COURT OF CLAIMS 537
Moore Business Forms, Inc. vs. Dept. of
Public Safety
(CC-82-41) 173
Moore Business Forms, Inc. vs. Dept. of
Education (CC 82-298 398
Angela Preston vs. Attorney General?s
Office (CC-82-79) 157
Region V ? Regional Education Service Agency vs. Dept. of
Employment Security (CC-81-426) 110
S. S. Logan Packing Company vs. Board
of Regents (CC 83-26 472
Southern Chemical Co. vs. Adjutant
General (CC-81-129) 29
Janet T. Surface vs. Workmen?s
Compensation Fund (CC 82-280 294
Janet T. Surface vs. Dept. of
Health (CC-83-2) 375
Weslakin Corporation vs. Dept. of
Corrections (CC-82-156) 296 Wheeling Multi-Service Center, Inc. vs. Division of
Voca tiona Rehabilitation (CC-81-133)
112
Zummach-Peerless Chemical Coatings
Corp. vs. Dept. of
Natural Resources (CC-81-135) 31
An award was made for rocks which the claimant furnished the respondent as a
by-product of claimant?s strip mining operation. Wayne K. Baker, d/b/a Baker Coal Company vs.
Dept. of Highways (CC-80-405) 424
An award was made f or repair work to respondent?s bus, as the Court concluded that to deny
the claim would result in unjust enrichment on the part of the respondent. C. W. Lewis,
Inc. vs. Dept. of Corrections (CC-82-103)
427
Where the respondent failed to insure items placed in the mail to be returned
to the claimant, the Court made an award for the loss of such items, as the
respondent failed to take the reasonable precaution of insuring the items. Carter?s Safety Systems, Inc. vs. Dept. of Finance and
Administration (CC 81?189 52
The Court made an award for back charges for phone service at the Pipestem State
Park which were discovered after an inventory of the phone system showed that
billing errors had been made. The Court held that to deny the claimant relief
would unjustly enrich the State. The
Chesapeake & Potomac Telephone Company vs. Dept. of Natural Resources (CC 81-302 332
Claimant insurer was reimbursed the cost of storage of its
insured?s vehicle when the vehicle was held by the Dept. of
Public Safety on an arson investigation. Dairyland
Insurance
Company, subrogee of Wesley D. Myers vs. Dept. of Public
Safety (CC-8l-355) 100
538 REPORTS STATE
COURT OF CLAIMS [W. VA.
In a claim for payment of unemployment benefits to two former employees of the
respondent, the Court determined that overpayments to individuals are to be
collected from the individuals, and not the agency, and denied the claim. Dept. of Employment Security vs. Dept. of Finance and Ad
ministratio (CC-82-335) 428
Where claimants have sought payment for various goods and services furnished to
respondent, but the respondent alleged that sufficient funds were not available
at the close o the fiscal years in question from which the obligations could
have been paid, the Court denied the claims based upon the principle
established in Airkem Sales and
Service, et al. vs. Dept. of Mental Health, 8 Ct.Cl. 180 (1971). Fullen
Fertilizer Company, Inc., et al. vs. Farm Management Commission (CC 81-231 36
The following claims were decided upon the same prin ciple: A. H. Robins Co. vs. Dept. of Corrections (CC-82-315) 375
B. & S. Air Taxi Service vs.
Office of the Secretary of State
(CC-82?259) 261
Bennett Publishing Company, et al. vs.
Dept. of Corrections
(CC-8l-444) 92
Gordon A. Bobbitt vs. Dept. of
Corrections (CC-82-62) 152
Boso Agri-Center, Inc. vs. Farm
Management Commission
(CC-82-318) 378
Bowlings, Inc., et al. vs. Dept. of
Corrections (CC-82-150) 261
Buckeye Gas Products Company vs. Farm
Management
Commission (CC-81-423) ? 83
C. H. James & Co. vs.
Dept. of Corrections (CC-82-326) 379
Copy Graphics, Inc. vs. Insurance
Department (CC-82-4) 99
J. P. Currence vs. Office of the
Secretary of State (CC-
82-186) 345
Dept. of Employment Security vs. Dept.
of Corrections
(CC-81-388) 89
Dept. of Finance and Administration vs.
Dept. of Corrections
(CC-81-117) 3
Dept. of Highways vs. Dept. of
Corrections (CC-82-57) 152
Dept. of Highways vs. Farm Management
Commission (CC 82-58 186
Exxon Co., U.S.A. vs.
Farm Management Commission (CC 82?136
218
Jenkins Concrete Products Co. vs. Farm
Management Com missio (CC-81-l87) 83
W. VA.) REPORTS
STATE COURT OF CLAIMS 539
Kanawha County Commission vs. Dept. of Highways (CC 81-447) 397
Elle?ry H. Morgan vs. Public Employees Insurance Board and Alcohol Beverage
Control Commission (CC-83-13) 471
Motor Car Supply Company, et al. vs. Farm Management
Commission (CC-81-346) 94
Mountaineer Motor Sales, Inc. vs. Farm Management Com missio (CC-82-106)
187
Peters Fuel Corporation, et al. vs. Dept. of Corrections
(CC-82?l85) 255
Scott Saw Sales & Service vs. Farm Management Commis sio (CC-82-165)
218
Charles H. Simmons d/b/a Simmons? Hauling, et al. vs.
Dept. of Corrections (CC-82-130) 276
Walter J. Klein Company, LTD vs. Board of Regents (CC 81-201 29
Westinghouse Electric Supply Company vs. Dept. of Cor rection (CC-82-221)
297
Wilson Welding Supply Company vs. Railroad Maintenance
Authority (CC-82-258) 298
Claimant was granted an award for typesetting a book for the respondent where
payment was not made because statutory purchasing procedures had not been
followed. Green Tab Publishing vs. Dept. of Corrections (CC-82-194) 239
The Court made an award to the claimant for goods sold under a contract with
the respondent. Industrial Gas & Supply Company vs. Dept. of Highways (CC-82-182)
288
An award was made for travel expenses incurred by claimant in his employment
with respondent. Lester A. Kubski vs.
Dept. of Health (CC-82-167) 289
The Court granted an award to claimant for goods purchased by respondent where
the goods were not paid for because respondent inadvertently failed to comply
with the technical regulations of the State purchasing procedures. Mountaineer
Office Supply, a division of F & M Supply Co., Inc. vs. Secre tar of State (CC-82-337)
382
An award for medical services rendered to an inmate of the State Penitentiary at
Moundsville was made where the Court determined that a Medical Respite signed
by the wife of the inmate and the Governor of West Virginia did not establish a
contract which would obligate the inmate?s family to bear the inmate?s medical
expenses. Reynolds Memorial Hos pital Inc. vs. Dept. of Corrections (CC-82-28)
273
540 REPORTS STATE
COURT OF CLAIMS [W. VA.
An award was made for storage and delivery costs incurred by the claimant as
the result of respondent?s failure to provide for the reconsignment of a
shipment of wire gabions. Terra
Aqua Conservation vs. Dept. of Highways (CC-82-283) 295
An award was made for the replacement cost of a medical school diploma which
claimant delivered to respondent and which was returned to claimant in a
damaged condition.
Edwin 0. Walker vs. Dept. of Health (CC-83-40) 472
An award was made to the claimant for processing and postage costs incurred as
a result of the respondent?s erroneous reporting of registered vehicles in West
Virginia. West Virginia Automobile and Truck Dealers Association vs. Dept.
of Motor Vehicles (CC-81-24) 13
FALLING ROCKS?See also Landslides
A claim for damage to a vehicle which
struck a rock in the road was denied by the Court as there was no evidence that
the respondent knew or should have known of the existence of the dangerous
condition, and it was apparent from the evidence that the rock had fallen just
prior to the accident.
Donald E. Ashley vs. Dept. of Highways (CC-82-61) 174
The Court disallowed a claim for damages to a truck struck by falling rocks
where the claimant testified that he knew the area was prone to falling rocks,
and no evidence was presented to indicate that the respondent had notice or
forewarning of the rock fall in question. Connie Lawrence Bailey
vs. Dept. of Highways (CC-81-389) 405
The Court made an award to claimants for personal injuries sustained when the
vehicle in which they were traveling struck a large rock located on the berm of
the road. The Court held that the evidence established that the respondent had
knowledge of the presence of the rock on the berm, and failure to remove the
rock created a hazardous condition which constituted negligence. Robert Conley,
Geneva Conley and Michael Conley, by his mother Geneva Conley vs. Dept.
of Highways (CC-78-145) 263
In a claim for damages based on injuries the decedent received when a rock
struck his vehicle, it must be established by a preponderance of the evidence
that the respondent knew or should have known that a dangerous condition
existed on the road. As the claimant did not meet this burden of proof, the
claim was denied. Azile Dean, Individually, and as Executrix of the Estate
of Virgil Dean, Deceased vs. Dept. of
Highways (CC-79-632) 325
A claim for damage to a vehicle which struck a rock in the roadway was denied
by the Court, as falling rock signs were present to warn the traveling public. Dorothy
M. Gore vs.
Dept. of Highways (CC-81-161) 175
W. VA.] REPORTS
STATE COURT OF CLAIMS 541
In a petition for rehearing, the Court granted the rehearing on the issue of
whether the respondent reasonably could have corrected a falling rock hazard
within the limits of funds appropriated by the Legislature for highway
maintenance.
Dorothy M. Gore vs. Dept. of Highways (CC-81-161) 502
A claim for damage to a vehicle which struck a rock slide in the road was
granted by the Court where the evidence established that the respondent had
been notified of the slide but had failed to remove the slide or provide
warning signs to the travelling public. Patricia
Ann Hall and Lacy Hall vs. Dept. f
Highways (CC-81-442) 169
A claim for damage to an automobile which struck rocks in a roadway was denied
as respondent must have had actual or constructive notice of the defect in the
roadway and a reasonable amount of time to take corrective action. Donna F.
Porterfield vs. Dept. of Highways (CC-81-91) 373
Property damage and personal injury resulted when claimant encountered a rock
slide in the roadway. The Court denied the claim as the evidence indicated that
the rock slide had occurred shortly before the accident. The claimant failed to
meet the burden of proving that the respondent failed to conform to a standard
of ?reasonable care and diligence. under all circumstances.? Keith Ray Roberts vs. Dept. of
Highways (CC-80-82) 25
A claim for damages to an automobile allegedly caused by large rocks left in
the road after respondent performed maintenance on the road was denied as the
evidence was insufficient to establish negligence on the part of respondent. Clarence Shiflet & Florence Shf let vs. Dept. of Highways (CC 82-131 339
A claim for damages to an automobile which struck a rock in the road was denied
as the evidence did not indicate that the respondent had actual or constructive
notice of the defect in the roadway, and the area was not one prone to rock
falls.
Andrew S. Young vs. Dept. of Highways (CC-81-75) 359
FLOODING
The Court made an award to the
claimants where it appeared that surface water run-off from the respondent?s
roadway was diverted onto claimants? property due to a broken curb of which the
respondent had actual notice. Gene
Brady Beegle vs. Dept. of Highways CC-81-248.
St. Paul?s Protestant
Episcopal Church vs. Dept. of Highways (CC-81-271)
361
Evidence established that a storm was of such magnitude that the water run-off
went over the culverts and the road in the area. The Court found no negligence
on the part of the respondent, and denied the claim. Doris Jane Bowen et al.
vs. Dept. of Highways (CC-80-342)
542 REPORTS STATE
COURT OF CLAIMS [W. VA.
Where the evidence showed that claimant?s property flooded due to its location
in a natural drain area, and not because the respondent elevated the road in
front of the property, the Court denied the claim. Robert W. Burke vs. Dept. of High.-
ways (CC-80-318) 495
A claim for water damage to a barn allegedly caused by respondent?s improper
construction of a highway berm was denied where it was established that the
respondent conducted the highway repairs to the satisfaction of the claimant
prior to the flooding, that the flooding occurred as the result of a heavy
rainstorm, and that the respondent did nothing to increase the flow of water
onto the claimant?s land. Charles
N. Durbin vs. Dept. of Highways (CC-81-181)
302
The claimant was granted an award after its warehouse was flooded immediately
following respondent?s redesigning of the storm drainage near the warehouse.
The Court rejected respondent?s defense based upon a release in a deed between
the parties, as the damages which occurred were not of the kind contemplated by
the parties when the release was executed. Fibair, Inc. vs. Dept. of Highways (CC-81-196) 393
The Court made an award to the claimants for damages to real and personal
property due to a flood where it was shown by a preponderance of the evidence
that respondent?s construction of 1-77 increased the amount of surface water
discharged onto claimants? property. U.
G. Harrison and Edna
Harrison vs. Dept. of Highways (CC-80-173)
456
The Court made an award to the claimant for flood damage to his home caused by
respondent?s failure to maintain a culvert located near claimant?s property. Benjamin C. Henry
vs. Dept. of Highways (CC-82-96)
- 371
An award was made to the claimants for damages sustained when their home was
flooded. The Court determined that the respondent negligently failed to design
and provide adequate drainage. Mark A.
Hissam and Julia A. Hissam vs. Dept. of
Highways (CC-80-375) -- -- 284
A claim for surface water damage to a garden was denied where it appeared that
the water followed its natural course downhill onto claimants? land. The
evidence did not warrant a finding that any action or inaction on the part of
the respondent was the sole cause of the flooding of claimants? property. Bobbie E. Holmes and Neva I. Holmes vs. Dept. of Highways
(CC-81-191) 356
An award was made to the claimant for the destruction of his home by the
respondent. The house was lifted from its foundation during a flood and came to
rest across a highway. The Court determined that the respondent did not act
reasonably in attempting to remove the house from the highway.
Ricky S. Howerton vs. Dept. of Highways
(CC-80-329) 286
W. VA.] REPORTS
STATE COURT OF CLAIMS 543
The Court made an award for damages to claimants? property where respondent?s
failure to maintain a culvert caused the flooding of claimants? property. Waitman
D. Jett and
Marilyn Jett vs. Dept. of Highways (CC-78-17) 250
An award was made for flood damage to claimant?s property where the damage was
the result of respondent?s negligent maintenance of the drainage system in the
vicinity. Ruth A.
Krippene vs. Dept. of Highways (CC-82-230) 348
The Court made an award for damage to claimant?s property due to flooding where
the evidence indicated that respondent?s installation of two culverts
obstructed the natural flow of the creek bordering claimant?s property and
diverted the water onto his land. Norman Lewis vs. Dept. of Highways (CC
80-334 507
A claim for property damage due to flooding was disallowed where the evidence
indicated that other factors, such as a high water table and low elevation,
caused the flooding, and there was no actionable negligence on respondent?s
part. Lucille
Linville vs. Dept. of Highways (CC-79-58) 408
The Court made an award for real and personal property damage where the
respondent, in raising the elevation of the road in front of claimants? home,
negligently failed to provide adequate drainage, causing water to pool on
claimants? property. Robert Marcum and Loretta. Marcum vs. Dept. of High way
(CC-78-248) 461
The Court made an award to the claimants for flood damage to real and personal
property where it was established that an inadequately designed and constructed
drainage system failed to carry off water from the highway. Ruby F. Shrader
vs. Dept. of Highways CC-78-168. James C. Martin, Jr. and
Shirley B. Martin vs. Dept. of Highways (CC-78-231) 364
Claimant sought payment for taxes paid on cases of beer
which were destroyed after being in a flood, and the Court
made an award to the claimant, as retention of the taxes
would amount to unjust enrichment on the part of the State.
State Distributing Company vs. Nonintoxicating Beer Com missio (CC-81-385)
110
The Court made an award for water damages to personal
property which occurred when a culvert constructed beneath
Interstate 79 prevented the continuous flow of water from
a creek near claimant?s property and resulted in the flooding
of her property. Velma Sutton vs. Dept. of Highways (CC 80-249 323
It is well established law that land at lower level is subject to the servitude
of receiving waters that flow naturally upon it from adjoining higher land
levels. The Court made an award to claimants for property damage resulting from
excess water being cast upon the properties of the claimants due
544 REPORTS STATE
COURT OF CLAIMS [?AT. VA.
to the installation of drains on a road above the properties of the claimants. Alva Katherine White vs. Dept. of Highways D-748a and Paul
White and Wanda White vs. Dept. of High way (D-748b) 212
FOSTER CHILDREN
A claim for expenses incurred by
claimants while they served as foster parents was denied as the claim was
barred by the statute of limitations. Thomas
Harold Anderson, Sr. and Edith lolene Anderson vs. Dept. of Welfare (CC-79-554) 376
The Court held that the claimant assumed the risk of any loss which resulted
when claimant entrusted a ward of the State with his vehicle, and denied claim.
John Charles Bungard vs. Dept. of
Welfare (CC-80-352) 48
In order for the Court to make an award for a window which was broken by a
foster child who is a ward of the State, there must be a showing of negligence
on the part of the respondent. As there was no evidence of negligence, the
Court disallowed the claim. Norma
Dornbos, dl b/a The Party Beer
Store vs. Dept. of Welfare (CC-8l-92)
407
HOSPITALS
The Court made an award for damaged
goods where respondent admitted the validity of the claim and stated that
sufficient funds were available for the payment of the claim. American Hospital Supply vs. Dept. of Health (CC-82-197) 244
An award was made for the cost of repair to the armature shaft of claimant?s
wheelchair which was broken by a rapidly closing elevator door in one of
respondent?s facilities. William E. Coy
vs. Dept. of Health (CC-82-204) 344
Claimant?s shirt was damaged by a patient at Spencer State Hospital, the
respondent admitted the amount and validity of the claim, and the Court made an
award to the claimant. Chad Cunningham vs. Dept. of Health (CC-82-323)
370
The Court denied an award for injuries sustained by the claimant when he jumped
from the roof of a building at Weston State Hospital. The Court concluded that
the injury was not foreseeable, and foreseeability is a necessary element in
establishing negligence. Nelson Eddie
Furner, an Incompetent, sues by and through Ava Elizabeth Furner Young, his
next friend, and Ava Elizabeth Furner Young, Individually vs.
Dept. of Mental Health (D-l0l0) -- - 245
Where the claimants sought payment for various medical supplies or services
furnished to the respondent, but the respondent alleged that sufficient funds
were not available at the close of the fiscal years in question from which the
obligations could have been paid, the Court denied the claims based upon the
principle established in Airkem Sales
and Service,
W. VA.1 REPORTS
STATE COURT OF CLAIMS 545
at al. vs. Dept. of Mental Health, 8 Ct. Cl. 180 (1971). Green- briar Valley Hospital, et al. vs. Dept. of Corrections (CC 81-347 39
The following claims were decided upon the same principle:
Ace Adjustment Service, Inc., Agent for
United Hospital
Center, Inc. vs. Dept. of Corrections (CC-82-78)
- 158
Grafton City Hospital vs. Dept. of
Corrections (CC-82-36) 153
E. L. Jimenez, M.D., et al. vs. Dept.
of Corrections (CC-
81-320) 84
Lois McElwee Memorial Clinic, et al.
vs. Dept. of Cor rection (CC-82-299) -- 320
Memorial General Hospital Association,
Inc. vs. Dept. of
Corrections (CC-82-256) -- --- --- 291
Ohio Valley Medical Center vs. Dept. of
Corrections (CC 81-89 10
Ohio Valley Medical Center, Inc. vs.
Dept. of Corrections
(CC-82-276) -- - - -- -- -- --
-- -- 312
B. Payman, M.D., at al. vs. Dept. of
Corrections (CC-82-205) 254 Potomac Valley Hospital vs. Dept. of Corrections (CC-
83-37) 471
Reynolds Memorial Hospital, Inc. vs.
Dept. of Corrections
(CC-82-212 a&b) - - - -- 321
Chandra P. Sharma vs. Dept. of
Corrections (CC-82-22 118
Utah Valley Hospital vs. Dept. of
Corrections (CC-82-300) 324
West Virginia School of Osteopathic
Medicine Clinic, Inc.
vs. Dept. of Corrections (CC-82-306)
349
West Virginia University Hospital vs.
Dept. of Corrections
(CC-81-413) - - 116
West Virginia University Outpatient
Pharmacy vs. Dept. of
CorrectIons (CC-82-145) 260
The Court made an award for the wrongful death of claimant?s decedent who died
from injuries inflicted by a fellow patient at Weston State Hospital. The Court
determined that the respondent failed to exercise reasonable care for the
safety of the decedent and this failure proximately caused the injury and
subsequent death. William Paul Hall,
Sr., Administrator of the Estate of William Paul Hall, Jr., vs. Dept. of
Health,
Division of Mental Health (CC-76-134)
305
The Court denied a claim where the claimant?s finger was broken in the spokes
of a wheelchair in which she was being transported as there was no evidence
that respondent?s employee pushed the wheelchair in a negligent manner. Bar bar Haynes vs. Board of Regents (CC-78-13) 327
546 REPORTS STATE
COURT OF CLAIMS [W. VA.
An award was made for the value of a jacket which disappeared while claimant
was a patient at Huntington State
Hospital. Donald R. Hogsett vs. Dept. of Health (CC-83-l6) 400
The Court made an award for the death of a patient of an institution operated
by the respondent where the decedent was placed in a ward without adequate
consideration being given to her mental history. The Court concluded that the
respondent failed to fulfill its moral and legal obligation to protect the
claimant?s decedent, and its acts constituted negligence which was the
proximate cause of the death. Thelma E. Mcintyre, Administratrix of the Estate of Wilma S. Mcintyre, deceased vs. Dept. of Health (CC-76-70)
209
An award was made for the wrongful death of a patient in respondent?s State
hospital when the Court determined that respondent failed to adequately protect
the decedent when she was placed in a ward with no bars on the windows, and she
died in a fall or jump from the window. Thelma E. Mcintyre, Administratrb of
the Estate of Wilma S. Mcintyre, deceased
vs. Dept. of Health (CC-76-70) 209
An award was made to the claimant for an injury sustained at the hands of a
fellow patient at Weston State Hospital where the Court held that the
respondent failed to exercise ordinary care to protect claimant from harm
caused by another patient. Francis L. Parker vs. Dept. of Health (CC
79-679 489
INDEPENDENT CONTRACTOR
The Court denied a claim for damages
arising out of an automobile accident which allegedly occurred because traffic
barricades obstructed the vision of the drivers, and it appeared that the
barricades were placed by an independent contractor in accordance with
respondent?s regulations. Pius
B. Chumbow vs. Dept. of Highways (CC-81-62) 363
The Court held that the respondent may not be held liable for the acts of an
independent contractor, and disallowed a claim where claimants? private road
was washed out due to a clogged culvert. The culvert had become clogged with
refuse dumped by the independent contractor. William Conner
and Lois Conner vs. Dept. of Highways (CC-80-154) 405
Claimant was denied recovery for damage to her vehicle which resulted when she
was being flagged on a construction project performed by an independent
contractor. Nellie Evans
vs. Dept. of Highways (CC-80-339) 3
The Court held that the respondent cannot be liable for the
negligence of an independent contractor engaged in construc tio work where the
claimants? vehicle struck a metal plate
in the road which had been placed there as part of the con tractor? work. David
E. Paul and Dolores H. Paul vs. Dept.
of Highways (CC-82-310) 479
W. VA.) REPORTS
STATE COURT OF CLAIMS 547
INSURANCE
A claim for overpayment of insurance
premiums was denied based upon the Airkem
decision, where the respondent
admitted the validity of the claim but stated that there were insufficient
funds remaining in its appropriation from which the claim could be paid. Ellery H. Morgan vs. Public Employees Insurance Board
and Alcohol Beverage Control Com missio (CC?83-13)
471
INTEREST
An advisory determination claim for
accrued interest on an amount due Employment Security when respondent?s
institution underpaid its statutory contribution to the claimant was denied as
West Virginia Code ?14-2-12 precludes the payment of interest by the Court. Dept. of Employment Security
vs. Dept. of Corrections (CC-81-388)
89
A request for payment of accrued interest on amounts due the Dept. of
Employment Security from certain agencies of the State was denied pursuant to
West Virginia Code ?14-2-12. Dept. of
Employment Security vs. Dept. of Correc tion (CC-82-260a et al.) 387
JURISDICTION
A claim for workmen?s compensation
benefits was denied because the Court lacked jurisdiction based upon West
Virginia Code ?14-2-14. Robert R. Brock
vs. Workmen?s Com pensatio Fund (CC-81-457)
- -- 136
A claim for workmen?s compensation benefits was denied because claimant did not
exhaust his administrative remedies. Robert
R. Brock vs. Workmen?s Compensation Fund (CC 81-457 136
This Court specifically lacks jurisdiction of a claim barred by the statute of
limitations. D. A. Burner vs. Dept. of
Public
Safety (CC-78-278) 50
A claim for workmen?s compensation benefits was denied because the Court lacked
jurisdiction based upon West Virginia Code ?14-2-14. June Dorton vs. Workmen?s Compensa tio Fund (CC-81-103) 137
The Court lacked jurisdiction of a claim based upon claimant?s alleged illegal
incarceration, as the claim was barred under the applicable statute of
limitations, West Virginia Code ?55-2-12. The Court granted respondent?s motion
to dismiss. Lester Rollings Haines vs.
Dept. of Corrections (CC 76-89 453
A claim for overtime pay was denied where the evidence established that claimant
was working for respondent under an assignment contract from an agency of the
federal government, and this agency paid the claimant?s salary. The Court
548 REPORTS STATE
COURT OF CLAIMS [W. VA.
held that it lacked jurisdiction over the claim as respondent was not
claimant?s employer. Carl R. Moore vs. Governor?s
Office of Economic and Community Development (CC-80-137) 419
LANDLORD AND TENANT
The Court denied a claim for damages
based on respondent?s cancellation of a contract for the lease of a building
where the contract contained a cancellation provision. L. H. Lewis
and B. L. Lewis vs. Dept. of Finance and Administration and
Dept. of Welfare (CC-82-235) 336
The Court made an award for rent due under a lease agreement with the
respondent where the respondent admitted the claim. Wheeling Multi-Service
Center, Inc. vs. Division of
Vocational Rehabilitation (CC-8l-133) 112
LANDSLIDES?See also Falling Rocks
The Court made an award for the
wrongful death which occurred as a result of the slippery condition caused by
respondent?s failure to properly remove all materials left on the surface of
the roadway. Matta L. Brady, Administratrix of the Estate of Shell C. Brady,
Dec., and Selected Risks Insurance Company, as subro gee of Shell C.
Brady vs. Dept. of High way (CC-80-175) 33
An award for damage to real property was made where employees of the respondent
broke a water line, causing a saturated soil condition in the area of
claimants? property. James W. Dixon and Doris A. Dixon vs. Dept. of Highways
(CC-80-365) 90
An award was made to the claimants for the loss of their home, which was
destroyed by a landslide. The preponderance of the evidence established that
the damage resulted from respondent?s improper maintenance of a ditch line
which caused water to be discharged over claimants? property, resulting in the
slide. Paul E. Miller and Marguerite Miller vs.
Dept. of Highways (CC-8l-396) 477
A claim for damage to claimant?s property as the result of a slip was denied by
the Court as it was determined by a preponderance of the evidence that the
respondent was not negligent in the maintenance of its road, and had attempted
to correct the slip on claimant?s property while remedying the slip problem in
the road. Clyde Wood vs. Dept. of Highways.
(CC-77-103) 243
In claims for slide damage to claimants? homes, the evidence indicated that the
homes were situated in a slide-prone area. There was insufficient proof that
the acts or omissions of the respondent were the cause of the damages
sustained, and the Court denied the claims. James Woody and Lottie L. Woody
vs. Dept. of Highways (CC-80-241). Harry W. Shoemaker and Winifred G.
Shoemaker vs. Dept. of Highways (CC-80-242).
W. VA.1 REPORTS
STATE COURT OF CLAIMS 549
Dale R. Pennington and Gloria Mae
Pennington vs. Dept. of
Highways (CC-80-243) 510
A claim for property damage due to a slide was disallowed where there was
insufficient proof of any acts or omissions by the respondent which were the proximate
cause of the damage. The evidence indicated that the slide was due to the
natural movement of unstable land. Martha
P. Yoak, by her
agent, Judson K. Yoak vs. Dept. of Highways. (CC-80-380) --
436
LIMITATION OF ACTIONS
A claim for expenses incurred by
claimants while they served as foster parents was denied as the claim was
barred by the statute of limitations. Thomas
Harold Anderson, Sr.
and Edith lolene Anderson vs. Dept. cf Welfare (CC-79-554) 376
A claim for property damage based on the theory that the claim was ex delicto was
denied by the Court. which applied the two-year period of limitations in
accordance with West Virginia Code ?14-2-21. Pearl Hughes Boiling and Charles
Hughes vs. Dept. of Highways (CC-79-16)
119
The Court, upon rehearing the claim, determined that the claim was not barred
by the Statute of Limitations, and made an award to the claimants for
inconvenience suffered after respondent placed dye in a well in an effort to
trace underground water to a surface mine site, and the dye contaminated
claimants? water well. Victor Frisco and Janet Frisco
vs. Dept. of Natural Resources (CC-80-l21) 346
A claim for damage to an air-conditioning unit in claimant?s dwelFng hcose was
barred by the Statute of Limitations. Joyce
Hupp vs. Office of the Chief Medical Examiner (CC-81-
238 186
MOTOR VEHICLES?See also Negligence;
Streets and Highways
An award was made to the claimants for
damages sustained by their automobile while driving through a construction
area. The Court determined that the respondent was negligent in failing to
properly maintain the construction area. Shirley
R.
Adams and Billie Adams vs. Dept. of
Highways (CC-82-146) 279
Where damages to c1amant?s insured vehicle were determined to have been caused
by respondent?s negligent snow removal and cindering operations, the Court
granted an award to the claimant for the damages sustained. Allstate
Insurance Co., as subrogee of Michael Hall vs. Dept. of Highways (CC 81-149
280
A claim for damage to a windshield was denied as the truck which threw the
gravel against the windshield went off the travelled portion of the road and
onto the berm. The Court held that this was an intervening act of negligence
which was
550 REPORTS STATE
COURT OF CLAIMS [W. VA.
the proximate cause of the damage. Leona Asbury and Tom
Asbury vs. Dept. of Highways (CC-81-54) 45
The respondent owes the duty of exercising reasonable care and diligence in the
maintenance of its highways, and where claimant?s automobile sustained damage
at a marked construction site, the Court held that the respondent had met its
duty of reasonable care, and denied the claim. David R.
Bassett vs. Dept. of Highways (CC-82-294) 426
An award was made for a damaged windshield which occurred when claimant drove
his vehicle through an area where employees of the respondent were patching the
road with tar and cinders. Larry L. Bennett vs. Dept. of High way (CC-81-434)
216
A claim for the cost of having a motor vehicle license reinstated was granted
by the Court because a clerical error in the Magistrate Court system resulted
in the expenses to the claimant. David Lee Closson vs. Office of The Supreme
Court of Appeals (CC-82-176) 237
In order for the Court to make an award in an accident claim, where a vehicle
was destroyed after the driver lost control when he drove through water on a
road, it is necessary to establish that the respondent had notice of the defect
in the road. As no evidence was presented to show such notice, the Court denied
the claim. Ronald E. Cyrus vs. Dept.
of Highways (CC-82-196) 334
A claim for damages to a vehicle owned by claimant?s insured was denied where
it was established that the damage occurred in a construction area and that the
contractor performing the work, not the respondent, was responsible for repairs
on the road in question. Dairyland Insurance Company, Subrogee of Jesse W.
Co burn, Jr. vs. Dept. of Highways (CC 82-10 300
Respondent had no notice of a dangerous condition on the highway, and the Court
denied liability for a windshield damaged by cinders. William P. Estep, Sr.
vs. Dept. of High way (CC-81-49) 55
A claim for property damage to a vehicle, which occurred when the vehicle
struck a trench across the roadway, was denied as the Court found no negligence
on the part of the respondent, and the damage occurred due to claimant?s own
negligence, Veda E. Evans vs. Dept. of High-ways (CC-81-43) 121
Damage to a vehicle which struck a pothole was denied because claimant was
aware of the existence of the hole. Diana
Lynn Hackney vs. Dept. of Highways (CC-81-139) 77
Where respondent?s flagman negligently flagged claimant?s vehicle so that it
was struck by another vehicle, the Court
W. VA.] REPORTS
STATE COURT OF CLAIMS 551
made an award to the claimant for personal injuries. Christine E. Henderson
and Rodgers Paul Henderson vs. Dept men of Highways (CC-78-234) 21
An award was made to the claimant for damage to his vehicle which struck a
broken metal drain hole cover. The Court found that respondent?s failure to
repair the broken cover was the proximate cause of the claimant?s damages.
Glenn E. Hiller vs. Dept. of Highways (CC-82-183) 269
The Court dened a claim for damage to a vehicle which occurred when the vehicle
was driven into water on the highway. The Court determined that the lighting on
the vehicle should have enabled the claimant to see the flood water before
driving into it, had she been exercising ordinary care under the circumstances.
Mar go A. Keyser vs. Dept. of Highways.
(CC-80-164) 27
The Court made an award to claimant for damage to her vehicle which occurred
when the vehicle dropped off a parking area into a large hole. The Court
determined that the negligence of the respondent was the actual cause of the
accident.
Barbara B. Krantz vs. Dept. of Highways (CC-80-39l) 116
A claim for damage to an automobile struck by a bolt which broke from a bridge
was granted where the Court determined that the respondent was negligent in
failing to use reasonable care to keep the bridge in reasonably safe condition.
Robert
Howard Latta vs. Dept. of Highways (CC-82-147) 289
A claim for property damage and personal injury which occurred when claimants?
vehicle struck an endloader parked on the edge of the highway was granted, as
the Court determined that the respondent was negligent in failing to place a
warning light to indicate the existence of the endloader. Liberty Mutual
Insurance Company, subro gee of Edward E. and Jennifer Dilling, and Edward E.
and Jennifer Dilling vs.
Dept. of Highways (CC-81-93) 171
Where the claimant testified that he did not know what caused the damage to a
tire on his vehicle, the Court denied th claim as the Court would have had to
resort to speculation or conjecture. Dores D. McDonnell, Sr. vs. Dept. of
High way (CC-81-31) 9
Where the claimant and the respondent stipulated that damage to c]&mant?s
vehicle occurred when a road sign belonging to the respondent fell and struck
the vehicle, the Court made an award to the claimant. Jimmy Polk vs. Dept.
of Highways (CC-81-132) 67
The Court denied a claim for damage to an automobile which struck a loose piece
of concrete in the road as there was no evidence that respondent had either
actual or con-
552 REPORTS STATE
COURT OF CLAIMS [?AT. VA.
structive notice of the defect. Gary L. Pritt and Jeanette
Pritt vs. Dept. of Highways (CC-81-418) 447
An award for damage to a vehicle which passed through tar applied to the
highway by respondent?s employees, who had not placed warning signs, was
granted by the Court. Frank
E. Redd vs. Dept. of Highways (CC-81-169) 231
The Court made an award for damages to a vehicle which passed through tar in an
area where respondent?s employees had failed to place warning signs. Stanley
T. Ruckman vs.
Dept. of Highways (CC-81-166) 232
Where claimant?s vehicle sustained damage when he collided with a median strip,
the Court made an award as the respondent was guilty of negligence which was
the proximate cause of the accident; however, the Court applied the doctrine of
comparative negligence and reduced the award by 20%.
James Scott Sadler vs. Dept. of Highways (CC-80-422) 16
The Court denied an award where the claimant?s vehicle struck a piece of metal
in a highway where there was no evidence that the respondent knew of the
presence of the
metal. Martha C. Scruggs vs. Dept. of Highways (CC-81-428) 411
An award for damage to a vehicle, which occurred when a truck spreading cinders
or salt on a highway passed claimant?s car and threw cinders against it, was
made by the Court. The claimant established, by a preponderance of the
evidence, that the offending truck was owned and operated by the respondent and
that the operator was negligently operating the truck at an excessive speed
under the prevailing conditions. Daniel
Serge, Jr. vs. Dept. of Highways (CC-81-95) 68
The Court made an award for damage to claimant?s automobile caused when the
vehicle struck an improperly secured metal sheet covering a road repair hole on
a State-owned and maintained highway. Charles R. Shaffer vs. Dept. of High
way (CC-81-202) 28
A claim for damage to a vehicle caused by respondent?s alleged failure to clear
dirt off a roadway after a ditch cleaning operation was denied where it
appeared that respondent performed the operation in a reasonable manner. George
A.
Stover and Carma Stover vs. Dept. of Highways (CC-81-261) 420
In a claim for damages to a vehicle and for personal injuries, the Court
determined that the respondent was in violation of West Virginia Code ? 17C- 13-1 when its employee stopped a truck in a
roadway and an accident resulted when claimants attempted to avoid the truck. Charles
W. W. Stultz and
Mary N. Stultz vs. Dept. of Highways (CC-81-12) 292
The Court may not speculate as to the cause of an accident, and denied a claim
for damage to a vehicle which struck a
W. VA.] REPORTS
STATE COURT OF CLAIMS 553
manhole cover as no evidence was presented as to how or why the accident
occurred. Billy Sutphin vs. Dept. of
High wa (CC-81-416) 415
An award was made for damage to a vehicle which occurred as a result of the
negligence of the respondent?s employee in failing to exercise ordinary care in
removing a fallen tree limb from the vehicle. John F. Tomblyn vs. Dept. of
Highways (CC-81-192) 111
The Court made an award to the claimant for damage to
a tire on his automobile which struck a piece of metal pro trudin from a
bridge. Thomas R. Treadway vs. Dept. of
Highways (CC-82-227) - - 296
A claim for storage charges assessed against claimant?s vehicle was denied as
the charges were assessed after the vehicle left respondent?s possession. United Farm Bureau Mutual
Insurance Company vs. Dept. of Public Safety (CC-82-93) 422
A claim for damage to a vehicle which struck a road grader
was denied by the Court because claimant failed to remain in
the line of traffic directed to proceed around the ditching
operation. Drema Faye Wheeler vs. Dept.
of Highways (CC 82-39 184
Recovery was denied claimant who collided with steel beams
erected on the berm of the highway to protect a steel grate
cover. Cecil Whitt, Sr. vs. Dept. of
Highways (CC-80-338) 30
NEGLIGENCE?See also Motor Vehicles;
Streets and Highways
An award was made to the claimants for
damages sustained by their automobile while driving through a construction
area. The Court determined that the respondent was negligent in failing to
properly maintain the construction area. Shirley
R. Adams and Billie Adams vs. Dept. of Highways (CC-82-
146) -
-. - 279
Where damages to claimant?s insured?s vehicle was determined to have been
caused by respondent?s negligent snow removal and cindering operations, the
Court granted an award to the claimant for the damages sustained. Allstate Insurance Co., as subro gee of Michael Hall
vs. Dept. of Highways
(CC-81-149) - 280
A claim for damage to a windshield was denied as the truck
which threw the gravel against the windshield went off the
travelled portion of the road and onto the berm. The Court
held that this was an intervening act of negligence which was
the proximate cause of the damage. Leona
Asbury and Tom
Asbury vs. Dept. of Highways (CC-8l-54)
45
Where the damages to a vehicle resulted from the negligent
operation of a mower by an employee of the respondent, the
Court made an award for damages to the vehicle. Auto Tech,
Inc. vs. Dept. of Highways (CC-81-436)
113
554 REPORTS STATE
COURT OF CLAIMS [W. VA.
A claim for money expended in repairs to a broken water line was denied as the
evidence did not establish that some negligent act or omission of the
respondent proximately caused the damage sustained by the claimant. James E.
Bailey, Jr.
vs. Dept. of Highways (CC-80-145) 423
A claim for loss of business which occurred during construction of a highway in
front of claimant?s business was denied because there was no negligence on the
part of the respondent. Steven Bellman d/b/a Baskin-Robbins vs. Dept. of
Highways
(CC-81-36) 97
An award for personal injury was granted by the Court when claimant, while
acting as a deputy sheriff, was standing on a bridge and fell between the steel
members of the bridge deck. The Court found that the respondent was negligent
in its maintenance of the deck. Norman E. Benson vs. Dept. of
Highways (CC-79-503) 193
Claimant was granted an award for damage to a high-pressure water truck which
struck a broken piece of concrete pavement on Interstate 64. The evidence
indicated that a dangerous condition existed on 1-64 for a week prior to the
accident, and the respondent was negligent in failing to discover and repair
the highway. Browning-Ferris Industries, Chemical Service, Inc. vs. Dept. of
Highways (CC-82-247) 399
Where the claimant was required to furnish his own tools, and stored them in a
locker provided by the respondent, the Court made an award for the tools when
they were stolen from the locker. L. D. Hall vs. Dept. of Highways (CC-80-
397). See CC-8l-172 & 186 58
Where respondent?s flagman negligently flagged claimant?s vehicle so that it
was struck by another vehicle, the Court made an award to the claimant for
personal injuries. Christine
E. Henderson and Rodgers Paul Henderson vs. Department
of Highways (CC-78-234) 21
The Court determined that respondent?s failure to properly inspect and maintain
the equipment in its laundry facility constituted negligence, and this
negligence proximately caused the damage to claimants? personal property. Mr.
and Mrs.
Stephen Kent Hill vs. Board of Regents (CC-80-183) 283
An award was made to the claimant for the destruction of his home by the
respondent. The house was lifted from its foundation during the flood and came
to rest across a highway. The Court determined that the respondent did not act
reasonably in attempting to remove the house from the highway. Ricky S.
Howerton vs. Dept. of Highways (CC-80-329) 286
An award for damage to personal property was made where the respondent was
negligent in failing to remedy a shelf defect of which it had prior knowledge. Charles
W. Jones vs.
Board of Regents (CC-81-35) 6
W. VA.] REPORTS
STATE COURT OF CLAIMS 555
A claim for personal injury was denied where the claimant had placed his hand
in a dangerous position in the winch cable of a bulldozer being operated by a
member of the West Virginia National Guard. The operator could not have
anticipated nor foreseen that a person would place his hand in such a position.
Douglas Edward Keller and Patty Keller
vs. Adjutant General
and Department of Highways (CC-78-219) 22
The Court made an award to claimant for damage to her vehicle which occurred
when the vehicle dropped off a parking area into large hole. The Court
determined that the negligence of the respondent was the actual cause of the
accident. Barbara B. Krantz vs. Dept. of Highways (CC-80-
391) 116
A claim for property damage and personal injury which occurred when claimants?
vehicle struck an endloader parked on the edge of the highway was granted, as
the Court determined that the respondent was negligent in failing to place a
warning light to indicate the existence of the endloader. Liberty Mutual Insurance Company, subro gee of Edward
E. and Jennifer Dilling, and Edward E. and Jennifer Dilling vs.
Dept. of Highways (CC-81-93) - 171
The Court made an award for real and personal property damage where the
respondent, in raising the elevation of the road in front of claimants? home,
negligently failed to provide adequate drainage, causing water to pool on
claimants? property. Robert Marcum and
Loretta Marcum vs. Dept. of
Highways (CC-78-248) 461
The Court made an award for damage to a vehicle which passed through tar
applied to the highway by the respondent, who failed to place proper warning
signs. Sidney Pozell and
Lillian Pozell vs. Dept. of Highways (CC-8l-l63)
227
An award was made to claimant, a State employee, for damage to her uniform,
which became covered with oil and grease from an automobile seat after the
vehicle had been serviced at respondent?s garage. Ethea M. Scott vs. Dept. of
Highways (CC-82-l02) 292
An award for damage to a vehicle, which occurred when a truck spreading cinders
or salt on a highway passed claimant?s car and threw cinders against it, was
made by the Court. The claimant established, by a preponderance of the
evidence, that the offending truck was owned and operated by the respondent and
that the operator was negligently operating the truck at an excessive speed
under the prevailing conditions.
Daniel Serge, Jr. vs. Dept. of Highways
(CC-8l-95) 68
A claim for damages to an automobile allegedly caused by large rocks left in
the road after respondent performed maintenance on the road was denied as the
evidence was insufficient to establish negligence on the part of respondent. Clar
556 REPORTS STATE
COURT OF CLAIMS [W. VA.
ence Shif let & Florence Shif let
vs. Dept. of Highways (CC 82-131 ? 339
If a claimant fails to establish negligence on the part of the respondent,
the Court will deny the claim. Therefore, the Court denied a claim for damage
to claimant?s vehicle caused by an open gate on an interstate. State Farm Mutual Automobile Insurance Company, as
Subro gee of Barbara A. Howe
vs. Dept. of Highways (CC-80-349) 71
In a claim for damages to a vehicle and for personal injuries, the Court
determined that the respondent was in violation of West Virginia Code ?17C-13-1
when its employee stopped a truck in a roadway and an accident resulted when
claimants attempted to avoid the truck. Charles
W. W. Stultz and Mary
N. Stultz vs. Dept. of Highways (CC-81-12)
292
A claim for wrongful death, which occurred when a vehicle went over the side of
the interstate, was denied because claimant failed to establish actionable
negligence on the part of the respondent. Audrey P. Tittle, Aclmin. of the Estate of Steven
B. Parcell vs. Dept. of Highways (CC-79-48)
146
NOTICE
Where there was no evidence to
establish that the respondent was aware of or had any knowledge of the
existence of a loose piece of concrete on a section of 1-64, and said piece of
concrete caused damage to claimant?s vehicle, the Court denied the claim. Bernard F. Carney vs. Dept. of Highways
(CC-8l-38) 51
The Court made an award to claimants for personal injuries sustained when the
vehicle in which they were traveling struck a large rock located on the berm of
the road. The Court held that the evidence established that the respondent had
knowledge of the presence of the rock on the berm, and failure to remove the
rock created a hazardous condition which constituted negligence. Robert Conley, Geneva Conley and Michael Conley, by his
mother Geneva Conley vs. Dept. of
Highways (CC-78-145) 263
In order for the Court to make an award in an accident claim, where a vehicle
was destroyed after the driver lost control when he drove through water on a
road, it is necessary to establish that the respondent had notice of the defect
in the road. As no evidence was presented to show such notice, the Court denied
the claim. Ronald E. Cyrus vs. Dept.
Dept. of Highways (CC-82-196) 334
Damage to a vehicle which struck a pothole was denied as there was no testimony
regarding the time the particular defect existed, nor was there any evidence
that the respondent had actual knowledge of the existence of the defect. Kath lee R. Fewell vs. Dept. of Highways (CC-81-153) 76
W. VA.] REPORTS STATE
COURT OF CLAIMS 557
Claimant, who sustained injuries when he fell from a bridge on which the
guardrails were missing, was denied an award as there was no proof that the
respondent had notice of the missing rails and claimant had prior knowledge of
the bridge?s
condition. Nelson Gregory vs. Dept. of
Highways (CC-79-307) 355
Where the evidence established that the respondent had notice of the condition
of the road and failed to remedy the defect, the Court granted an award to the
claimants for damages to their vehicle and for medical expenses. Paul Gyke
and Joe Ann Gyke vs. Dept. of Highways (CC-82-162)
282
A claim for damage to a vehicle which struck a rock slide in the road was
granted by the Court where the evidence established that the respondent had
been notified of the slide but had failed to remove the slide or provide
warning signs to the travelling public. Patricia
Ann Hall and Lacy Hall vs. Dept.
of Highways (CC-81-442) 169
For the respondent to be held liable for damages caused by road defects, the
claimant must prove that the respondent had actual or constructive knowledge of
the existence of the defects and a reasonable amount of time to take suitable
corrective action. John A. Hannigan and Carolyn Ann
Hannigan vs. Dept. of Highways (CC-81-86)
5
The following claims were decided upon the same principle:
Arlene Burgess and Charles E. Burgess
vs. Dept. of High way (CC-82-84) 160
Dreama Dawn Cook vs. Dept. of Highways (CC-82-21) 217
Maurice V. Davis vs. Dept. of Highways (CC-81-170) 54
Kenneth N. Ellison vs. Dept. of
Highways (CC-82-274) 380
Cheryl M. Fidler vs. Dept. of Highways (CC-82-50) 162
Earl F. Guthrie vs. Dept. of Highways (CC-82-l25) 304
Atholl W. Halstead vs. Dept. of
Highways (CC-82-40) 163
L. P. King, Jr. and Evelyn King vs.
Dept. of Highways
(CC?8l?61) 79
Eugene A. Knotts vs. Dept. of Highways (CC-81-107) 108
Martha White Foods vs. Dept. of Highways (CC-81-lll) 123
Mrs. Juanita McClarin vs. Dept. of
Highways (CC-81-246) 445
Eugene P. Mullins vs. Dept. of Highways
(CC-82-8) 164
Roger Richmond and
Sandra Richmond vs. Dept. of High way (CC-8l-453)
- - -
449
Richard L. Sargent vs. Dept. of
Highways (CC-82-98) 315
558 REPORTS STATE
COURT OF CLAIMS [W. VA.
Oscar D. Smith vs. Dept. of Highways (CC-81-5) 11
Larry Lee Stricker vs. Dept. of
Highways (CC-81-50) 12
David E. Utt vs. Dept. of
Highways (CC-82-115) 236
Robert Varney vs. Dept. of Highways (CC-82-304) 434
Renna J. Wilcox vs. Dept. of Highways (CC-82-63) 166
Roy Franklin Williams, Jr., and Beverly
Williams vs. Dept.
of Highways (CC-83-117) 485
Gary L. and Brenda Workman vs. Dept. of
Highways (CC 82?132 452
An award was made for injuries sustained in an automobile
accident which occurred when the vehicle encountered ice on
a roadway. The evidence established that the respondent
knew that ice accumulated at the site of the accident, but
failed to take reasonable measures to prevent the ice forma tio or to warn
motorists of the hazard. Lois V. Haynes
and
E. Robert Haynes vs. Dept. of Highways (CC-80-415)
460
A claim for property damage to a vehicle and personal injuries to the claimant,
which occurred when the vehicle struck a pothole and berm of the road, was
denied by the Court as the record did not contain sufficient evidence that the
respondent knew or should have known of the existence of the pothole in
question. Nelva Munson vs. Dept. of
Highways
(CC-80-355) 133
A claim for damage to an automobile which struck rocks in a roadway was denied
as respondent must have had actual or constructive notice of the defect in the
roadway and a reasonable amount of time to take corrective action. Donna F. Porterfield vs. Dept. of Highways (CC-81-91) 373
The Court denied a claim for damage to an automobile which struck a loose piece
of concrete in the road as there was no evidence that respondent had either
actual or constructive notice of the defect. Gary L. Pritt and Jeanette Pritt
vs. Dept. of Highways (CC-81-418) 447
A claim for damage to a vehicle which struck a pothole was denied as the
existence of road defects without notice to the respondent is not sufficient to
establish negligence on the part of the respondent. Eldean Russell vs. Dept. of Highways (CC 82-60 165
The State is neither an insurer nor a guarantor of the safety of motorists on
its highways, and the Court denied a claim where claimant?s vehicle struck a
rock in the road as the claimant did not establish that the respondent had
actual or constructive notice of the rock and a reasonable amount of time to
remove it. Calvin L. Sargent vs. Dept.
of Highways (CC 82-319 433
W. VA.] REPORTS
STATE COURT OF CLAIMS 559
The Court denied an award where the claimant?s vehicle struck a piece of metal
in a highway where there was no evidence that the respondent knew of the
presence of the
mental. Martha C. Scruggs vs. Dept. of Highways (CC-81-428)
411
In a claim for damage to a vehicle which struck a pothole, the Court granted an
award because the respondent had constructive notice of the defect in light of
the fact that the road was one of the main arteries for motorists travelling
north in Kanawha County. Harry R. Sellards and Francis A.
Sellards vs. Dept. of Highways (CC-82-83) 188
Although the Court has consistently held that the respondent is not an insurer
of the safety of persons using the highways of this State, where it has been
demonstrated that the respondent had actual knowledge of a dangerous defect in
a highway and took no action to remedy the defect, an award has been made. As
the evidence in this claim indicated that a hole in the road had been in
existence for at least three weeks prior to the accident which damaged
claimant?s vehicle, the Court made an award for the damage sustained. Ronald
P.
Stewart vs. Dept. of Highways (CC-81-65) 72
Where the claimants? vehicle struck a piece of concrete or
patch of tar in the highway, but there was no evidence that the
respondent had actual or constructive notice of the defect in
the roadway, the Court denied the claim. Carole E. Updyke
and Lionel Joe Updyke vs. Dept. of Highways (CC-83-122) - 481
OFFICE EQUIPMENT AND SUPPLIES
Claimant sought payment of unpaid rent
due on leased equipment, and the Court made an award for the amount due. Eastman
Kodak Company vs. Dept. of Finance and
Administration (CC-81-386) 101
The Court held open a claim so that the parties could agree upon an amount due
the claimant based on a quantum meruit recovery. Xerox Corporation vs. Dept.
of Natural Resources
(CC-82-236) 435
PEDESTRIANS
A motorist drove onto a defective berm
of the road to avoid striking a pedestrian. The defective berm caused the truck
to go out of control, cross the highway, and strike claimant?s de?edent. An
award was granted by the Court as the berm of a highway must be maintained in a
reasonably safe condition for use when the occasion requires. Eli
Blankenship, Jr., Administrator of the Estate of Johnny Blankenship, Deceased
vs.
Dept. of Highways (CC-76-113) 194
A claim for personal injury which occurred when claimant fell on a curb was
denied, because claimant?s failure to exercise reasonable care and maintain a
proper lookout was the proximate cause of her injuries. Dolores Moore
vs. Dept. of
Highways (CC-80-240) 179
560 REPORTS STATE
COURT OF CLAIMS [W. VA.
A claim for personal injury to the claimant, who stepped into a hole in the
sidewalk, was denied as there was no evidence that the respondent had actual or
constructive knowledge of the defect in the sidewalk. Tammy Lynn Priestley, an Infant who sues by her Mother,
Carolyn Priestley, and Carolyn
Priestley vs. Dept. of Highways (D-732)
82
PERSONAL SERVICES
Where claimants were engaged by the
respondent to defend an employee of the State, and the respondent failed to pay
the claimants for their services, the Court made an award for the services as
the fee charged was reasonable. W. H.
Ballard, II, and G. David Brumfield vs. Dept. of Natural
Resources
(CC-81-44) 46
Claimant magistrates were granted awards for wages which were not paid during
the 1981-82 fiscal year, based on the decision in Graham, et at. vs. Office of the Supreme Court of
Appeals, Ct.Cl (1983). Arthur U. Browning, et at. vs. Office of the Supreme
Court of Appeals (CC-83-50-
62 and 83-108 & 109) 402
Where a miscalculation in claimant?s rate of pay was made, the Court granted an
award to the claimant in the amount of the underpayment. Susan L. Cale vs.
Board of Regents (CC 82-160 262
Claimants were granted awards for serving as counsel for criminal indigents in
juvenile, misdemeanor, and felony proceedings, and as counsel for indigents in
mental hygiene hearings, where the attorney?s fees were not paid because the
funds had been exhausted. The Court determined that the factual situations were
identical to those in Swartling, et al.
vs. Office of the State Auditor, 13
Ct.Cl. 57 (1979). David R. Gold and
Louis H. Khourey d/b/a Gold & Khourey vs. Office of
the State Auditor (CC-82-192a & b)
? 247
248
The following claims were decided upon he same principle:
Richard D. Frum, et at. vs. Office of
the State Auditor
(CC-81-369) 32
Charles E. McCarty vs. Office of the
Supreme Court Ad ministrato (CC-81-400)
130 Eugene J. Sellaro, Jr. vs. Office
of the State Auditor (CC8-138) ? ? ? ? 85
Sterl F. Shinaberry vs. Office of the State
Auditor (CC-
81-142) 94
Larry N. Sullivan vs. Office of the State
Auditor (CC-
82-15) 119
James D. Terry vs. Office of the State
Auditor (CC-82-44) 234 The Court found
no basis for an award to the claimant, who
W. VA.] REPORTS
STATE COURT OF CLAIMS 561
sought compensation for reporting and transcribing uncontested divorce cases.
Claimant was required to perform the job as part of her employment as secretary
to a circuit court judge. Susan L. Green vs. Supreme Court of Appeals (CC-80-
385).._ ?
416
A claim for breach of contract for personal services was denied by the Court
where claimant alleged he was not paid for annual leave. The Court determined
that the annual leave had been paid. Francis
J. Hennessy vs. Board of Regents (CC
80-340 ?..----------?
?-_ 103
Where claimant sought additional compensation for service as the only
magistrate in a county designated for two magistrates, the Court determined
that the claimant received his proper salary based upon the total population
served in accordance with West Virginia Code ?50-1-3. Richard A. Spotbe vs. Administrative Office of the Supreme
Court of Appeals
(CC-80-223) 69
A claim for losses which claimant sustained as the result of prematurely
assuming employment with the Office of Emergency Services was denied by the
Court because there was no agreement between the parties concerning claimant?s
employment. William M. Truman vs. Of ftce of Emergency
Serv ices (CC?81?376) 235
PHYSICIANS AND SURGEONS?See
also Hospitals
The Court made an award to the claimant for damaged personal property where the
respondent admitted the validity of the claim and stated that sufficient funds
were available from which the claim could be paid. Narendra Bora vs. Dept.
of Health (CC-82-97) 245
The Court disallowed claims for medical and dental services based upon the Airkem doctrine
where the respondent admitted the validity and amounts of the claims but stated
that it did not have sufficient funds with which to pay them. B. Pay- man et al. vs. Dept. of Corrections (CC-82-205) 254
PRISONS AND PRISONERS
The Court held that the respondent
carried out its statutory duty under West Virginia Code ?62-13-5 when it
received claimant into the penitentiary, and no award for lost wages was
granted for the period during which claimant was incarcerated, even though his
conviction was later voided. Hayward
Jobe Casto, Jr. vs. Dept. of Corrections (D-986) 497
The Court lacked jurisdiction of a claim based upon claimant?s alleged illegal
incarceration, as the claim was barred under the applicable statute of
limitations, West Virginia Code ?55-2-12. The Court granted respondent?s motion
to
562 REPORTS STATE
COURT OF CLAIMS [W. VA.
dismiss. Lester Rollings Haines vs.
Dept. of Corrections (CC-.
76-89) ?
453
Recovery was allowed for various articles of personal property which were lost
or returned in damaged condition to claimant?s home after the articles were
removed from claimant?s possession while he was imprisoned at the West Virginia
Penitentiary in Moundsville. Donald A.
Harmon vs. Dept. of
Corrections (CC-81-381) 347
A claim for damages based upon extra time the claimant served in prison for an
escape which was expunged from claimant?s record was dismissed as barred by the
doctrine of res judicata, as the matter was fully and sufficiently considered
in a previous U.S. District Court action. Ronald H. McGraw vs. Dept. of Corrections (CC-78-50) 464
A claim for damages where claimant?s criminal conviction was declared null and
void was dismissed as the claim was barred by the applicable statute of
limitations. Charles E.
Moore vs. Dept. of Public Institutions (CC-76-127)
431
PUBLIC INSTITUTIONS
The Court denied an award for injuries
sustained by the claimant when he jumped from the roof of a building at Weston
State Hospital. The Court concluded that the injury was not foreseeable, and
foreseeability is a necessary element in establishing negilgence. Nelson
Eddie Furner, an Incompetent, sues by and thr.iuqh Ava Elizabeth Furner
Young, his next friend, and Ava Elizabeth Furner Young Individually vs.
Dept. of Mental Health. (D-1010) 245
The Court disallowed a claim for lost
wages and mental -
anguish allegedly caused by respondent?s
delay in granting claimant a license to practice registered professional
nursing. The Court concluded that the delay was not the result of any unlawful
conduct on the part of the respondent and was in large part attributable to
claimant?s own inaction. John Grey
vs. Board of Examiners for Registered Nurses (CC-81-151) 395
The Court made an award for the
wrongful death of claimant?s decedent who died from injuries inflicted by a
fellow patient at Weston State Hospital. The Court determined that the
respondent failed to exercise reasonable care for the safety of the decedent
and this failure proximately caused the injury and subsequent death. William Paul Hall, Sr., Administrator of the Estate of
William Paul Hall, Jr., vs. Dept. of
Health, Division of Mental Health (CC-76-134)
305
The Court denied a claim for damages
based on respondent?s cancellation of a contract for the lease of a building where
the contract contained a cancellation provision. L. R. Lewis and B. L. Lewis vs. Dept. of Finance and
Administration and
Dept. of Welfare (CC-82-235) 336
W. VA.] REPORTS
STATE COURT OF CLAIMS 563
The Court made an award for the death of a patient of an institution operated
by the respondent where the decedent was placed in a ward without adequate
consideration being given to her mental history. The Court concluded that the
respondent failed to fulfill its moral and legal obligation to protect the claimant?s
decedent, and its acts constituted negligence which was the proximate cause of
the death. Thelma E. Mcintyre,
Administratrix of the Estate of Wilma S. Mcintyre, deceased vs. Dept. of
Health (CC-76-70) 209
An award was made to the claimant for an injury sustained at the hands of a
fellow patient at Weston State Hospital where the Court held that the
respondent failed to exercise ordinary care to protect claimant from harm
caused by another patient. Francis L. Parker vs.
Dept. of Health (CC-79-
679) 489
A claim for injuries inflicted upon an inmate of the Anthony Forestry Center by
another inmate was denied where the respondent had no knowledge of any unusual
danger, or reason to anticipate such danger, to the claimant. Charles S. Ward, guardian of Charles F. Ward vs. Dept. of
Corrections
(CC-78-113) 368
PUBLIC OFFICERS
The Court dismissed a claim where it
was not established that the damages suffered by the claimant were caused by
any breach of duty on the part of the respondent. Mary Lynn
Cook vs. Dept. of Public Safety (CC-82-157)
331
REAL ESTATE
The Court made an award for damage to
real property when employees of the respondent performed negligently in certain
excavation work. Oncie E. Archer et al.
vs. Dept. of
Highways (CC-8l-390) - - - 96
A claim for recovery of damages caused by respondent?s alleged negligence in
certifying a certain parcel of real estate for sale to the Commissioner of
Delinquent and Forfeited Lands contained items of damage relating to cost of
litigation or to ownership or maintenance of property, and if the claim were
viewed as a tort claim, the Court could not conclude that such items of expense
proximately caused the respondent?s error. Willard Casto vs. State Auditor?s Office (CC-79-
ll6) 86
A claim for damages to unimproved real property allegedly caused by surface
water draining onto the property was denied as the ditch was a natural drainage
course and there was no evidence to attribute any legal fault to the
respondent. Ronald H. Harper and Sarah
E. Harper vs. Dept. of Highways
(CC-80-134) 78
A release in a deed between the respondent and the claim-
564 REPORTS STATE
COURT OF CLAIMS [W. VA.
ants? predecessors in title to a tract of land was not a convenant that ran
with the land, and the claimants were not barred from pursuing a claim for
damages to the land where the release only applied to the grantor and not his
heirs, successors, and assigns. U. G. Harrison and Edna Harrison vs.
Dept. of Highways (CC-80-173) 456
An award for property damage was granted based upon the cost of cleaning up the
real property and the repairs to the residence and buildings, as the
distinction between temporary and permanent damages to real estate was
overruled by the West Virginia Supreme Court in the case of Jarrett V. Harper &
Son, Inc., 160 W.Va. 399, 235 S.E.2d 362 (1977).
Chester Jones vs. Dept. of Highways (CC-76-5l) 221
Where respondent?s employees released Canada geese near claimants? farm, and
the geese ate sorghum and corn plants on claimants? property, the Court made an
award for the dan?ages sustained. Henry A. Kay and Charles E. Kay vs. Dept.
of
Natural Resources (CC-80-146) 270
REHEARING
In a petition for hearing, the Court
granted the rehearing on the issue of whether the respondent reasonably could
have corrected a falling rock hazard within the limits of funds appropriated by
the legislature for highway maintenance. Dorothy M. Gore vs. Dept. of
Highways (CC-8l-161) 502
RES JUDICATA
A claim for damages based upon extra
time the claimant served in prison for an escape which was expunged from
claimant?s record was dismissed as barred by the doctrine of res judicata, as
the matter was fully and sufficiently considered in a previous U.S. District
Court action. Ronald R. McGraw vs. Dept. of Corrections (CC-78-50) 464
STATE AGENCIES
Claimant sought to recover damages
allegedly caused by respondent?s negligence in certifying a certain parcel of
real estate for sale to the Commissioner of Delinquent and Forfeited Lands
when, in fact, the property belonged to a corporation other than the claimant,
as the property had beer. redeemed by the corporation. As the West Virginia
Code provides a legal remedy by which claimant may recover the purchase money
he paid, and a legal remedy for the recovery of taxes improperly required, the
Court has no jurisdiction over that part of the claim. Willard Casto vs.
State
Auditor?s Office (CC-79-l16) -- 86
Where the parties stipulated that the respondent, acting as the agent of the
claimant, failed to issue call notices on bonds and that the claimant incurred
losses as a result, the Court made an award in the amount of the loss. City
of Oak Hill
vs. Municipal Bond Commission (CC-82-268) 344
W. VA.] REPORTS
STATE COURT OF CLAIMS 565
The Dept. of Employment Security filed several claims against agencies of the
State of West Virginia which failed to pay the proper amount of employment
compensation tax owed by them. The Court made an award to the claimant as the
cost of providing this tax cannot be predicted for any given fiscal year. Dept. of Employment Security vs. Dept. of
Corrections (CC-82-260a et al.) 387
The Court made an award for loss of camera equipment furnished at the request
of superiors. Rabert Lee Fulks vs. Dept. of Education (CC-81-172), Ernest
W. Lowe vs. Dept.
of Education (CC-81-186) 56
The Court denied an award to a contractor who alleged that the failure of the
respondent to permit the contractor from withdrawing a bid caused damages to
the contractor. The Court determined that the Director of the Purchasing
Division did not abuse the discretion granted to him under the purchasing
regulations. G. M. McCrossin, Inc. vs.
Board of Re gent (CC-79-682)
265
The Court denied an award of sick leave where the employee was terminated as
part of a general reduction in force, and there was no policy in existence
which required that an employee, on sick leave at the time of a reduction in
force, be allowed to exhaust the balance of his sick leave hours before being
terminated. Claude W. Jarrell vs. Dept.
of
Highways (CC-81-324) 407
Claimant filed an action to recover money spent to remodel a business for a
State liquor store for which she had entered into an agreement with respondent.
The agreement was rescinded because the county had voted dry, and the Court
found that the claimant may be entitled to proven damages. Pauline G. Malcolm vs. Alcohol Beverage Control Commis
sione (CC-80-275) ? 155
The Court made an award to claimant for travel expenses incurred on State
business as the respondent admitted the validity of the claim. Jeffrey 0. McGeary vs. Human Rights
Commission (CC-82-12) 117
Claimant?s claim for accumulated sick leave and back pay due to an alleged
wrongful termination was denied where the Court determined that claimant?s
termination was not wrongful, and Civil Service Regulations do not allow the
payment of sick leave to an employee who has been terminated. Kenneth Page vs. Alcohol Beverage Control Commissioner (CC-80-357) - - 487
An allegation that respondent negligently refused to permit a gasoline service
station from opening was denied as the Court could not conclude from the
evidence that respondent ordered the closure of the station or negligently
refused
566 REPORTS STATE
COURT OF CLAIMS [W. VA.
to permit it to reopen. Southern Gas & Oil, Inc., vs. State Fire
Marshal (CC-79-56) 127
STATUTES
An award for the payment of jury
commissioners was granted in accordance with West Virginia Code ?52-1-3, since
the obligation would have been paid if it had been submitted in the proper
fiscal year. County Commission of Webster County vs. Office of the Supreme
Court (CC-81-168) 75
Where claimant sought additional compensation for service as the only
magistrate in a county designated for two magistrates, the Court determined
that the claimant received his proper salary based upon the total population
served in accordance with West Virginia Code ?50-1-3. Richard A. Spotbe vs.
Administrative Office of the Supreme Court of Appeals
(CC-80-223) 69
STIPULATION AND AGREEMENT
The Court made an award for damages to
claimant?s vehicle which was damaged by snow and debris dumped from an
interstate by employees of the respondent. Frank Bonacci
vs. Dept. of Highways (CC-82-25) 135
An award was made when a vehicle was damaged because of negligent maintenance
by the respondent of a bridge on which the deck had settled. John R. Coffman
vs. Dept. of
Highways. (CC-82-51) 216
The Court made an award where the parties stipulated that the factual situation
and applicable law were identical to the claims of Vecellio & Grogan,
Inc. vs. Dept. of Highways, (CC81-425 and CC-82-92). See also
Vecellio & Grogan, Inc. vs. Dept. of Highways, (CC-81-425 and
CC-82-92). Foster & Creighton Company and Vecellio & Grogan, Inc.
vs. Dept. of
Highways (CC-83-153) 475
Where claimant and respondent stipulated that claimant?s vehicle was damaged as
it crossed over a portion of Interstate 79 which gave way due to the existence
of a tunnel beneath the roadway, the Court made an award to the claimant. General
Accident F/L Assurance Corp., LTD., Subro gee of Innovative Industries
vs. Dept. of Highways (CC-80-386) 20
Where the claimant and the respondent stipulated that claimant?s vehicle was
damaged when it struck a steel plate covering a hole on a State highway, and
that negligence on the part of respondent in failing to properly anchor the
plate proximately caused the damage, the Court made an award to the claimant. Kanawha
Valley Regional Transportation Authority vs. Dept. of Highways (CC-81-l16)
60
Claimant?s sewer line was crushed while respondent was widening a portion of
the road adjacent to claimant?s property,
W. VA.] REPORTS
STATE COURT OF CLAIMS 567
and the Court made an award for the damages in the amount stipulated by the
parties. Lucas Tire, Inc. vs. Dept. of High way (CC-83-14) 397
The Court granted an award to the claimant for goods damaged while in the
possession of the respondent. Tn-City Welding Supply Company vs. Dept. of
Highways (CC-82-173a) -
258
The Court granted an award to the claimant for goods which were lost due to the
negligence of the respondent. Tn-City Welding Supply Company vs. Dept. of
Highways
(CC-82-l73b) 259
STREETS AND HIGHWAYS?See also Falling Rocks; Landslide; Motor Vehicles;
Negligence
A claim for damage to the tire of a
vehicle was granted where a jagged
metal protrusion in the roadway caused the damage. Jimmie G. Adams vs. Dept.
of Highways (CC-82-l39) 214
In a wrongful death action, the Court held that respondent was negligent in
failing to remove a mud slide from the road, and in not warning the traveling
public of the danger. The Court also found that the decedent, who had prior
knowledge of a hazard in the road, was negligent; accordingly, the award was
reduced, based upon the doctrine of comparative negligence. Lillian Alcers,
Administratrix of the Estate of Gary Wayne Akers, Deceased vs. Dept. of
Highways
(CC-78-222) ?
491
The Court made an award to the
claimants where it appeared that surface water run-off from the respondent?s
roadway was diverted onto claimants? property due to a broken curb of which the
respondent had actual notice. Gene Brady Beegle vs. Dept. of
Highways (CC-81-248), St. Paul?s Protestant Episcopal Church vs. Dept.
of Highways (CC-81-271) 361
A motorist drove onto a defective berm of the road to avoid striking a
pedestrian. The defective berm caused the truck to go out of control, cross the
highway, and strike claimant?s decedent. An award was granted by the Court as
the berm of a highway must be maintained in a reasonably safe condition for use
when the occasion requires. Eli Blankenship, Jr., Administrator of the
Estate of Johnny Blankenship, Deceased vs.
Dept. of Highways (CC-76-113) 194
A claim for damage to- a vehicle which struck a hole in the berm of a highway
was granted by the Court as the respondent was aware of the condition of both
the road and the berm and was negligent in failing to maintain the berm.
J. C. Boland and Michael J. Boland vs. Dept. of Highways
(CC-78-15) 196
The Court made an award for damages to claimant?s vehicle which was damaged
by snow and debris dumped from
58 REPORTS STATE
COURT OF CLAIMS [W. VA.
an interstate by employees of the respondent. Frank Bonacci
vs. Dept.
of Highways (CC-82-25) 135
The Court made an award for the
wrongful death which occurred as a result of the slippery condition caused by
respondent?s failure to properly remove all materials left on the surface of
the roadway. Matta L. Brady,
Administratrix of the Estate of Shell C. Brady, Dec., and Selected Risks
Insurance Company, as subrogee of Shell C. Brady vs. Dept. of
Highways (CC-80-175) 33
Respondent must have notice of a hazard in the road and a reasonable time to
remove it before the Court will make an award. As the tree which fell across a
road and caused damage to claimant?s automobile fell only a short time before
the accident, the Court denied the claim. Teresa Britt vs.
Dept. of Highways (CC-82-267) 378
Claimant was granted an award for damage to a high-pressure water truck which
struck a broken piece of concrete pavement on Interstate 64. The evidence indicated
that a dangerous condition existed on 1-64 for a week prior to the accident,
and the respondent was negligent in failing to discover and repair the highway.
Browning-Ferris Industries, Chemical
Service, Inc. vs. Dept. of Highways (CC-82-247)
-- 399
A claim for damage to a vehicle which struck several potholes was denied as the
claimant failed to produce evidence that the respondent had either actual or
constructive notice of the potholes. Arlene
Burgess and Charles E. Burgess
vs. Dept. of Highways (CC-82-84) 160
A claim for damage to an automobile was denied when it was established that the
road on which the incident occurred was not owned or maintained by the
respondent. Albert
G. Capinpin vs. Dept. of Highways (CC-82-l58)
299
Where there was no evidence to establish that the respondent was aware of or
had any knowledge of the existence of a loose piece of concrete on a section of
1-64, and said piece of concrete caused damage to claimant?s vehicle, the Court
denied the claim. Bernard F. Carney vs.
Dept. of High way (CC-81-38) 51
The Court denied a claim for damages arising out of an automobile accident
which allegedly occurred because traffic barricades obstructed the vision of
the drivers, and it appeared that the barricades were placed by an independent
contractor in accordance with respondent?s regulations. Pius B. Chum bo vs. Dept. of Highways (CC-81-62) 363
An award for damage to a vehicle which occurred when the vehicle passed over a
drain culvert cover which flipped up and damaged the vehicle was granted as
respondent failed to
W. VA.] REPORTS
STATE COURT OF CLAIMS 569
properly secure the culvert cover. Mason
M. Clay vs. Dept.
of Highways (CC-81-397) 115
The presence of an isolated patch of ice on a highway during the winter months
is generally insufficient to charge the State with negligent maintenance of the
highway. Wilson
R. Cole, et al. vs. Dept. of Highways (CC-77-3a-d)
350
A claim for damage to a vehicle and for personal injuries to the claimant,
which occurred when the vehicle skidded on ice and struck an embankment, was
denied by the Court based upon the case of Adkins vs. Sims, 130 W.Va. 645
(1947). Lillian West Collins and John
Collins vs. Dept. of
Highways (CC-80-292) 131
The following claims were decided upon the same principle:
Jesse J. Crank vs. Dept. of Highways (CC-83-114) 476
Dae Anne Fletcher and Paul Norman
Fletcher vs. Dept.
of Highways (CC-82-52) 219
Sandra W. Phillips Larese vs. Dept. of Highways (CC-82-
70) 164
Laird Minor and Nancy G. Minor vs.
Dept. of Highways
(CC-82-327) 478
Frank A. Payne vs. Dept. of Highways (CC-79-719) 330
Mary E. Peterson vs. Dept. of Highways (CC.-82-246) 383
Michael A. Piazza vs. Dept. of Highways (CC-81-30) 65
Doris Randolph, Frank Randolph, her
husband, and Yvonette (Suzie) Randolph, ml ant vs. Dept. of
Highways (CC-76-
12) ?
230
Calvin L. Sargent vs. Dept. of Highways (CC-82-319) 433
Ranson Bailey Ward and Debra Dawn Ward vs. Dept. of
Highways (CC-81-145) 74
Wayne F. Wiggins vs. Dept. of
Highways (CC-82-207) 386
An award was made to the claimant for damage to his home and vehicle caused by
dust from the repaving of the highway near his property. Michael Crouch vs. Dept. of Highways
(CC-78-236) 280
A claim for damage to a vehicle which struck a pothole was denied based upon
lack of actual or constructive notice to the respondent of the condition of the
roadway. Cheryl M.
Fidler vs. Dept. of Highways (CC-82-50)
- 162
A claim for damage to an automobile which struck a pothole was denied as it was
not established that the respondent knew or should have known of the existence
of the pothole.
Earl F. Guthrie vs. Dept. of Highways (CC-82-125) 304
570 REPORTS STATE
COURT OF CLAIMS [W. VA.
Where the evidence established that the respondent had notice of the condition
of the road and failed to remedy the defect, the Court granted an award to the
claimants for damages to their vehicle and for medical expenses. Paul Gyke
and Joe Ann Cyke vs. Dept. of Highways (CC-82-162)
282
A claim for damage to a vehicle was denied as there was no evidence in the
record of any prior notice to the respondent of the existence of the hole. Atholl W. Halstead vs. Dept.
of Highways (CC-82-40) 163
For the respondent to be held liable for damages caused by road defects, the
claimant must prove that the respondent had actual or constructive knowledge of
the existence of the defects and a reasonable amount of time to take suitable
corrective action. John A. Hannigan and
Carolyn Ann Hannigan vs. Dept. of Highways (CC-81-86)
The Court applied the doctrine of comparative negligence in a claim for
personal injuries resulting from an automobile accident, where the respondent
negligently failed to exercise reasonable care in maintaining the road, but the
claimant was also negligent in failing to maintain proper control of his
vehicle when he was aware of the hazardous condition of the road. Millard A. Harmon vs. Dept. of Highways (CC 80-373 454
A claim for personal injuries and property damage to a vehicle was denied where
the evidence revealed that the claimant was very familiar with the defect in
the road which had been caused by a slip. Under the doctrine of comparative
negligence, the negligence of the claimant in traveling a road at night in rain
and fog, known by him to be in disrepair, was equal to or greater than the
negligence of the respondent in its failure to repair the road. Forrest C. Hatfield vs. Dept.
of Highways (CC-78-227) 220
An award was made for injuries sustained in an automobile accident which
occurred when the vehicle encountered ice on a roadway. The evidence
established that the respondent knew that ice accumulated at the site of the
accident, but failed to take reasonable measures to prevent the ice formation
or to warn motorists of the hazard. Lois V.
Haynes
and E. Robert Haynes vs. Dept. of Highways (CC-80-415) 460
Where the respondent was aware of a potentially hazardous condition of ice on
the highway and failed to take action to remedy the situation or warn
motorists, the respondent is guilty of negligence. Robert N. Jarboe, Patricia Ann Jarboe, and Stephanie
Jarboe vs. Dept. of Highways (CC-79-297)
-. 13
The Court made an award to the
claimant for damages sustained when he lost control of his motorcycle upon
encountering gravel in the roadway. The Court held that the respon
W. VA.] REPORTS
STATE COURT OF CLAIMS 571
dent was negligent in failing to place warning devices which would indicate
that a hazardous condition existed. Teddy
Keiffer vs. Dept. of Highways (CC-82-168) 319
The Court applied the doctrine of comparative negligence and disallowed claims
where the negligence of the driver was equal to or greater than that of the
respondent. Keller fndustries, Inc. vs. Dept. of Highways (CC-81-29) and
Ryder
Truck Rental, Inc. vs. Dept. of Highways (CC-80-381) 417
A claim for loss of business based upon construction work performed by the
respondent on a highway was denied as a nonabutting property owner is not
entitled to damages for impairment of access if reasonable and adequate access
is provided in another direction or by other means. Charles L. Kinney and Joyce
I. Kinney cl/b/a The Southwood Carryout
vs. Dept. of Highways (CC-79-696) 177
The Court held that the responsibility for the general supervision of the State
road program lay with the respondent, and an award was made to the claimant
whose vehicle sustained damage when it struck a bolt on the metal plate of a
floodgate system. Thomas E. Layton, II vs. Dept. of Highways (CC
82-245 401
When claimant?s vehicle was damaged when it traveled across a section of
roadway which had been ditched across and filled with gravel by the respondent,
the Court held that the damage occurred because of the negligence of the
respondent, and made an award. Doris Leslie vs. Dept. of High way (CC-82-285)
349
A claim for damage to a vehicle which struck white dome- shaped metal lane
dividers was denied where the preponderance of the evidence indicated
negligence only on the part of the claimant. Dayton 0. B. and
Alline L. Matthews
vs. Dept. of Highways (CC-81-19) 124
As there was no proof that respondent had notice of a pothole which damaged
claimant?s car, the Court denied the claim. Mrs. Juanita McClarin vs. Dept.
of Highways (CC 81-246 445
A claim for damage to a vehicle, which occurred on a snow and ice-covered
highway, was denied where the evidence indicated that the particular road had a
priority of four, which maintenance men had not yet reached. John McKendrick
vs. Dept. of Highways (CC-81-59) 125
Where claimants? vehicles sustained damage when a concrete section of bridge
fell on an interstate system, the Court held that respondent had a duty to
maintain the bridge such that a major deck failure would not occur. The Court
therefore made awards to the claimants for damage to their vehicles. Thomas E.
McNamee vs. Dept. of Highways (CC-81-
572 REPORTS STATE
COURT OF CLAIMS [W. VA.
100), Allstate Insurance Company as
Subro gee of Jacqueline
E. Delazio and Jacqueline E. Delazio, Individually (CC-81-
114) __
62
A claim for damages to a vehicle which became stuck in mud was denied because
the road had been maintained as well as could be expected, given its
classification as a class 4/5 priority road. Earl G. Muck vs. Dept. of Highways (CC-82-
69) 180
A claim for damage to a vehicle which struck a pothole was denied as no
evidence was introduced to prove knowledge, either actual or constructive, of
the existence of the pothole on the part of the respondent. Eugene P. Mullins vs. Dept. of
of Highways (CC-82-8) 164
A claim for damage to the tire of a vehicle which struck debris left on the
highway was denied as the debris was observable to the claimant. Herbert O?Dell Parsons, III vs.
Dept. of Highways (CC-81-162) 81
Where the claimants alleged damage to their vehicle from striking potholes in
the road, and one of the claimants testified that neither she nor her husband
had ever called the respondent?s headquarters to complain about the potholes,
and that they were aware of the potholes, the Court denied the claim. Donald E. Platt and Linda E. Platt vs. Dept. of
Highways (CC-81-l01) 66
The Court made an award for damage to a vehicle which passed through tar
applied to the highway by the respondent, who failed to place proper warning
signs. Sidney Pozell and
Lillian Pozell vs. Dept. of Highways (CC-81-163)
227
Claimant corporation created a subdivision and filed a claim for the cost of
widening an access road, which claim was deflied because there was no contract
with the respondent to bear this cost. Rainbow
Development Corporation vs. Dept.
of Highways (CC-81-350) 228
An award for damage to a vehicle which passed through tar applied to the
highway by respondent?s employees, who had not placed warning signs, was
granted by the Court.
Frank E. Redd vs. Dept. of Highways (CC-81-169) 231
There was no evidence that respondent had actual or constructive notice of the
pothole which damaged claimant?s automobile; therefore, the Court denied the
claim. Roger Richmond and Sandra
Richmond vs. Dept. of Highways (CC-81-
458)
Under the doctrine of comparative negligence, the Court determined that the
claimant?s negligence, where he knew of the road condition which damaged his
vehicle, equalled or exceeded the negligence of the respondent, and the claim
was
denied. Robert G. Riner vs. Dept. of Highways (CC-82-288) - 432
W. VA.] REPORTS
STATE COURT OF CLAIMS 573
A claim for damage to a vehicle which struck a pothole was denied as the
existence of road defects without notice to the respondent is not sufficient to
establish negligence on the part of the respondent. Eldean Russell vs. Dept. of High way (CC-82-60) 165
The Court applied the doctrine of comparative negligence and denied a claim for
damage to a vehicle which struck a pothole. The Court held that the negligence
of the driver in striking a pothole located on the berm of the road equalled or
exceeded any negligence of the respondent. Robert C.
Schumacher vs. Dept. of Highways (CC-82-55)
315
An award for property damage to a vehicle which struck a pothole was granted by
the Court because the size of the pothole demonstrated its presence for a long
time prior to the date of the accident, clearly establishing negligence on the
part of the respondent. Harry R.
Sellards and Francis A.
Sellards vs. Dept. of Highways (CC-82-83)
188
An award was made for damages to claimant?s vehicle which slid into a rock
cliff after encountering mud in the road. The Court determined that respondent
had failed to clear the road of dirt following a ditch cleaning operation.
Roy G. Shawver vs. Dept. of Highways (CC-82-189) 384
The Court denied a claim where it was not established that the respondent dug
the ditch in the road which caused damage to the claimant?s automobile. Alfred W. Smith vs. Dept.
of Highways (CC-82-177) ? 374
A claim for damage to a vehicle which struck a pothole in the highway was
denied as the record contained no evidence of notice to the respondent or
failure to act on the part of the respondent. Oscar D. Smith vs. Dept. of Highways (CC 81?5 11
If a claimant fails to establish negligence on the part of the respondent, the
Court will deny the claim. Therefore, the Court denied a claim for damage to
claimant?s vehicle caused by an open gate on an interstate. State Farm Mutual Automobile Insurance Company, as
Subro gee of Barbara A.
Howe vs. Dept. of Highways (CC-80-349)
71
Although the Court has consistently held that the respondent is not an insurer
of the safety of persons using the highways of this State, where it has been
demonstrated that the respondent had actual knowledge of a dangerous defect in
a highway and took no action to remedy the defect, an award has been made. As
the evidence in this claim indicated that a hole in the road had been in
existence for at least three weeks prior to the accident which damaged
claimant?s vehicle, the Court made an award for the damage sustained. Ronald P. Stewart vs. Dept. of Highways (CC-8l-65) 72
574 REPORTS STATE
COURT OF CLAIMS rw. VA.
A claim for damages to a vehicle which struck a hole in the pavement was denied
as claimant failed to prove that the respondent had actual or constructive
knowledge of the existence of the defect and a reasonable amount of time
to take corrective action. Larry Lee Stricker vs. Dept. of High.-
ways (CC-81-50) 12
The Court denied a claim for damage to an automobile which struck a manhole as
it was not established that the manhole was maintained by respondent or was
within respondent?s right-of-way. Jack L. Taylor vs. Dept. of High
way (CC-82-243) 386
A wrongful death action, which death occurred when decendent?s vehicle went over
the side of an interstate, was denied by the Court because the decedent was
travelling at an excessive rate of speed, considering the condition of the
highway. Audrey P. Tittle, Admin. of the Estate of Steven
B. Parcell vs. Dept. of Highways (CC-79-48) 146
Where the roadway surface of Interstate 79 collapsed as a vehicle crossed over
an area under which a tunnel existed, the Court made an award for the damage to
the truck based upon failure of the respondent to properly maintain the
highway. United States Fidelity & Guaranty Company, Subro gee of H
& A Coal & Hauling, Inc. and H & A Coal & Hauling, Inc. vs.
Dept. of Highways (CC-80-258) 26
Where the claimants? vehicle struck a piece of concrete or patch of tar in the
highway, but there was no evidence that the respondent had actual or
constructive notice of the defect in the roadway, the Court denied the claim. Carole
E. Updyke and Lionel Joe Updyke vs. Dept. of Highways (CC 83-122 481
The Court denied a claim where claimant?s vehicle struck a pothole as there was
no proof of notice, either actual or constructive, to the respondent. Robert Varney
vs. Dept. of
Highways (CC-82-304) 434
A claim for damage to the tire of a vehicle which struck
a pothole was denied as the claimant failed to prove that the
respondent had actual or constructive knowledge of the
alleged defect. John J. West vs. Dept. of Highways (CC-81-
122) 129
A claim for damage to a vehicle which struck a pothole was denied as there was
no evidence that the respondent had either actual or constructive notice of the
defect. Renna J. Wilcox vs. Dept. of Highways (CC-82-63) 166
The claimants presented no proof that the respondent had notice of the pothole
which damaged their automobile, and the Court denied the claim. Roy Franklin
Williams, Jr., and Beverly Williams vs. Dept. of Highways (CC-83-l17) 485
W. VA.] REPORTS
STATE COURT OF CLAIMS 575
In a claim for damage to a vehicle which struck a pothole, no proof was
presented that the respondent had actual or constructive notice of the defect
in the roadway; accordingly, the Court denied the claim. Bob E. Willis and Ragene
Willis vs. Dept. of Highways (CC-82-l00) 317
It was not established that the respondent had actual or constructive notice of
the pothole which damaged claimants? vehicle; accordingly, the Court denied the
claim. Gary L. and
Brenda Workman vs. Dept. of Highways
(CC-82-132) 452
TAXATION
The question of beer tax refunds has
been before the Court on several occasions, and, where the State has not been
damaged, the Court has held that the retention of the taxes paid would amount
to unjust enrichment on the part of the State. The Court made an award to the
claimant where beer was rendered unfit as the result of severe storms and
flooding, and claimant had previously paid the tax on the beer. Crosby Beverage Co., Inc. vs. Nonintoxicating Beer
Coin-
mission (CC-81-lO) 19
An advisory determination by the Court was sought where an institution of the
respondent underpaid its statutory contribution to Employment Security. The
Court indicated that an award could not be made based upon the Airkem decision,
as sufficient funds were not available in the proper fiscal year. Dept. of Employment Security vs. Dept. of
Corrections (CC-8l-388) - 89
The Dept. of Employment Security filed several claims against agencies of the
State of West Virginia which failed to pay the proper amount of employment
compensation tax owed by them. The Court made an award to the claimant as the
cost of providing this tax cannot be predicted for any given fiscal year. Dept. of Employment
Security vs. Dept. of Corrections (CC-82-260a et al.) - - - - 387
The Court made an award as a refund of prepaid State excise taxes on beer as
retention of such taxes would result in unjust enrichment of the State. Henry
F. Ortlieb Brewing Co.
vs. Nonintoxicating Beer Commission (CC-8l-l75) - - 104
Where the respondent owed property taxes on real estate it purchased, the Court
made an award to the claimant for payment of the taxes. Thomas G. Kimble vs.
Dept. of Public
Safety (CC-80-396) -
- - 23
An error by the Treasurer?s Office caused claimant taxpayer to lose his tax
refund from the State Tax Dept., and the Court made an award. William P. Knight
vs. Treasurer?s
Office (CC-79-667) 106
Claimant sought payment for taxes paid on cases of beer which were destroyed
after being in a flood, and the Court
576 REPORTS STATE
COURT OF CLAIMS [W. VA.
made an award to the claimant, as retention of the taxes would amount to unjust
enrichment on the part of the State. State
Distributing Company vs. Nonintoxicating Beer Com missio (CC-81-385) 110
TREES AND TIMBER
Respondent must have notice of a
hazard in the road and a reasonable time to remove it before the Court will
make an award. As the tree which fell across a road and caused damage to
claimant?s automobile fell only a short time before the accident, the Court
denied the claim. Teresa Britt vs.
Dept.
of Highways (CC-82-267) -- - 378
An award was made for damage to claimants? home where two trees fell on the
house. The Court determined that the trees fell when caught in a slide which
resulted when the respondent failed to maintain a ditch line; however, the
award was reduced under the doctrine of comparative negligence, as the
claimants were aware of the clogged ditch line but failed to inform the
respondent of the condition. James
BuTcham and Patricia J. Burch.am vs. Dept. of Highways (CC80-252) ? 441
An award was made for the value of two trees which were damaged when employees
of respondent trespassed onto claimant?s property while surveying. The parties
stipulated the value of the trees. C. 0. Smith, Jr.
vs. Dept. of Highways
(CC-82-311) 385
An award was made for damage to a vehicle which occurred as a result of the
negligence of the respondent?s employee in failing to exercise ordinary care in
removing a fallen tree limb from the vehicle. John F. Tom blyn vs. Dept. of Highways
(CC-81-192) 111
TRESPASS
An award was made for the value of two
trees which were damaged when employees of respondent trespassed onto
claimant?s property while surveying. The parties stipulated the value of the
trees. C. 0. Smith, Jr. vs. Dept. of
Highways
(CC-82-311) -- 385
WAGES
The Court made an award for back wages
improperly held by the respondent while claimant was a patient at respondent?s
hospital, where the respondent admitted the validity and amount of the claim. Clifford Cupp vs.
Dept. of Health
(CC-81-341) - ..-- 53
Magistrates who filed claims based upon payment of wages not paid in accordance
with the results of the 1980 decennial census were granted awards by the Court
following the decision in Ruth A. Donaldson, Magistrate, etc., et al. vs.
Gainer, Jr., Auditor et al. (June 30, 1982) W.Va. . Richard D.
W. VA.] REPORTS
STATE COURT OF CLAIMS 577
Graham, Jr. vs. Office of The Supreme Court of Appeals (CC-82-190)
and Howard R. Nordeck vs. Office of The Su prem Court of Appeals (CC-82-209)
238
See Graham & Nordeck vs. Office of the Supreme Court of Appeals, 14
Ct.C1. 238 (1982). Robert A. Isner vs. Office of
The Supreme Court of Appeals (CC-82-229) 239
WATERS AND WATERCOURSES?See also
Drains and Sewers; Flooding
In a claim for water damage to real
property, an award was made where the claimant established that the
respondent knew of the drainage problem, and the Court determined that the
respondent failed to exercise reasonable care to prevent the damage to
claimant?s property. Betty Cook vs. Dept.
of Highways (CC-79-527) 486
A claim for damages to unimproved real property allegedly
caused by surface water draining onto the property was
denied as the ditch was a natural drainage course and there
was no evidence to attribute any legal fault to the respon dent Ronald H.
Harper and Sarah E. Harper vs. Dept. of
Highways (CC-80-134) 78
A claim for water damage was denied where the evidence
indicated that claimant?s property was located in the natural
drainage course. Geneva Hill vs. Dept. of Highways (CC-
78-241) 249
WELLS
The Court, upon rehearing the claim,
determined that the claim was not barred by the Statute of Limitations, and
made an award to the claimants for inconvenience suffered after respondent
placed dye in a well in an effort to trace underground water to a surface mine
site, and the dye contaminated claimant?s water well. Victor Frisco and
Janet Frisco vs.
Dept. of Natural Resources (CC-80-121) 346
W.VA. UNIVERSITY?See Board of
Regents
WORKMEN?S COMPENSATION FUND
A claim for workmen?s compensation
benefits was denied because claimant did not exhaust his administrative
remedies.
Robert R. Brock vs. Workmen?s Compensation Fund (CC 81-457 136
A claim for excessive premiums paid to the respondent was
denied under the general rule that, where an administrative
remedy is provided by statute, relief must he sought from the
administrative body. Chaf in Coal Company vs. Workmen?s
Compensation Fund (CC-79-161) 98
A claim for workmen?s compensation benefits was denied
because the Court lacked jurisdiction based upon West Vir gini Code ? 14-2-14. June
Dorton vs. Workmen?s Compen satio Fund (CC-8l-103) 137