STATE OF WEST VIRGINIA
Report of the Court of Claims 1977-1979
Volume 12
STATE OF WEST
VIRGINIA REPORT OF THE COURT OF CLAIMS
For the Period from July 1, 1977 to June 30, 1979
By
CHERYLE M. HALL
CLERK
VOLUME XII
(Published by authority Code 14-2-25)
BJW PRINTERS, BECKLEY, WV E3 C.E41
IV PERSONNEL OF
THE STATE COURT OF CLAIMS
PERSONNEL
OF THE
STATE COURT OF CLAIMS
HONORABLE JOHN B. GARDEN Presiding
Judge
HONORABLE GEORGE S. WALLACE, JR Judge
HONORABLE DANIEL A. RULEY, JR. Judge
CHERYLE M. HALL Clerk
CHAUNCEY BROWNING, JR Attorney General
FORMER JUDGES
HONORABLE JULIUS W. SINGLETON, JR July 1, 1967
?July 31, 1968
HONORABLE A. W. PETROPLUS August 1, 1968
?June 30, 1974
HONORABLE HENRY LAKIN DUCKER July 1, 1967
?October 31, 1975
HONORABLE W. LYLE JONES July 1, 1967
?June 30, 1976
CONTENTS Ifl
TABLE OF
CONTENTS
Claims reported, table of _LII
Claims classified according to statute, list of XXX
Court of Claims Law VII
Letter of transmittal V
Opinions of the Court I
Personnel of the Court IV
References 355
Rules of Practice and Procedure XX
Terms of Court VI
LETTER OF
TRANSMITTAL V
LETTER OF
TRANSMITTAL
To His Excellency
The Honorable John D. Rockefeller, IV
Governor of West Virginia
Sir:
In conformity with the requirements of section twenty-five of the Court of
Claims law, approved March eleventh, one thousand nine hundred sixty-seven, I
have the honor to transmit herewith the report of the State Court of Claims for
the period from July one, one thousand nine hundred seventyseven to June
thirty, one thousand nine hundred seventy-nine.
Respectfully submitted,
CHERYLE M. HALL,
Clerk
VI TERMS OF
COURT
TERMS OF COURT
Two regular terms of court are
provided for annually the second Monday of April and September.
STATE COURT OF
CLAIMS LAW VII
STATE COURT OF
CLAIMS LAW
CHAPTER
14 CODE
Article
2. Claims Against the Stat..
?14-2-1. Purpose.
? 14-2-2. Venue for certain suits and actions.
? 14-2-3. Definitions.
? 14-2-4. Creation of court of claims; appointment and terms of judges;
vacancies.
? 14-2-5. Court clerk and other personnel.
?14-2-6. Terms of court.
? 14-2-7. Meeting place of the court.
?14-2-8. Compensation of judges; expenses.
? 14-2-9. Oath of office.
?14-2-10. Qualifications of judges.
? 14-2-11. Attorney general to represent State.
?14-2-12. General powers of the court.
? 14-2-13. Jurisdiction of the court.
?14-2-14. Claims excluded.
? 14-2-15. Rules of practice and procedure.
? 14-2-16. Regular procedure.
?14-2-17. Shortened procedure.
? 14-2-18. Advisory determination procedure.
? 14-2-19. Claims under existing appropriations.
? 14-2-20. Claims under special appropriation.
?14-2-21. Periods of limitation made applicable.
?14-2-22. Compulsory process.
? 14-2-23. Inclusion of awards in budget.
? 14-2-24. Records to be preserved.
? 14-2-25. Reports of the court.
? 14-2-26. Fraudulent claims.
? 14-2-27. Conclusiveness of determination.
? 14-2-28. Award as condition precedent to appropriation.
?14-2-29. Severability.
?14-2-1. Purpose.
The purpose of this article is to
provide a simple and expeditious method for the consideration of claims against
the State that because of the provisions of section 35, article VI of the
Constitution of the State, and of statutory restrictions, inhibitions or
limitations, cannot be determined in the regular courts of the State; and to
provide for proceedings in which the State has a special interest.
VIII STATE COURT
OF CLAIMS LAW
?14-2-2. Venue for certain suits and
actions.
(a) The following proceedings shall be
brought and prosecuted only in the circuit court of Kanawha county:
(1) Any suit in which the governor, any other state officer, or a state agency
is made a party defendant, except as garnishee or suggestee.
(2) Any suit attempting to enjoin or otherwise suspend or affect a judgment or
decree on behalf of the State obtained in any circuit court.
(b) Any proceeding for injunctive or mandamus relief involving the taking, title,
or collection for or prevention of damage to real property may be brought and
presented in the circuit court of the county in which the real property
affected is situate.
This section shall apply only to such proceedings as are not prohibited by the
constitutional immunity of the State from suit under section 35, article VI of
the Constitution of the State.
?14-2-3. Definitions.
For the purpose of this article:
?Court? means the state court of claims established by section four [14-24J of
this article.
?Claim? means a claim authorized to be heard by the court in accordance with
this article.
?Approved claim? means a claim found by the court to be one that should be paid
under the provisions of this article.
?Award? means the amount recommended by the court to be paid in satisfaction of
an approved claim.
?Clerk? means the clerk of the court of claims.
?State agency? means a state department, board, commission, institution, or
other administrative agency of state government:
Provided, that a ?state agency? shall not be considered to include county
courts, county boards of education, municipalities, or any other political or
local subdivision of this State regardless of any state aid that might be
provided.
STATE COURT OF
CLAIMS LAW IX
?14-2-4. Creation of court of claims; appointment and terms of judges;
vacancies.
The ?court of claims? is hereby
created. It shall consist of three judges, to be appointed by the president of
the senate and the speaker of the house of delegates, by and with the advice
and consent of the senate, one of whom shall be appointed presiding judge. Each
appointment to the court shall be made from a list of three qualified nominees
furnished by the board of governors of the West Virginia State bar.
The terms of the judges of this court shall be six years, except that the first
members of the court shall be appointed as follows: One judge for two years,
one judge for four years and one judge for six years. As these appointments
expire, all appointments shall be for six year terms. Not more than two of the
judges shall be of the same political party. An appointment to fill a vacancy
shall be for the unexpired term.
?14-2-5. Court clerk and other
personnel.
The court shall have the authority to
appoint a clerk and a deputy clerk. The salary of the clerk and the deputy
clerk shall be fixed by the joint committee on government and finance, and
shall be paid out of the regular appropriation for the court. The clerk shall
have custody of all records and proceedings of the court, shall attend meetings
and hearings of the court, shall administer oaths and affirmations, and shall
issue all official summonses, subpoenas, orders, statements and awards. The
deputy clerk shall act in the place and stead of the clerk in the clerk?s absence.
The joint committee on government and finance may employ other persons whose
services shall be necessary to the orderly transaction of the business of the
court, and fix their compensation.
?14-2-6. Terms of court.
The court shall hold at least two
regular terms each year, on the second Monday in April and September. So ?far
as possible, the court shall not adjourn a regular term until all claims then
upon its docket and ready for hearing or other consideration have been disposed
of.
X STATE COURT
OF CLAIMS LAW
Special terms or meetings may be called by the clerk at the request of the
court whenever the number of claims awaiting consideration, or any other
pressing matter of official business, make such?a term advisable.
?14-2-7. Meeting place of the court.
The regular meeting place of the court shall be at the state capitol, and the
joint committee on government and finance shall provide adequate quarters
therefor. When deemed advisable, in order to facilitate the full hearing of
claims arising elsewhere in the State, the court may convene at any county
seat.
?14-2-8. Compensation of judges; expenses.
Each judge of the court shall receive one hundred seven dollars for each day
actually served, and actual expenses incurred in the performance of his duties.
The number of days served by each judge shall not exceed one hundred in any
fiscal year, except by authority of the joint committee on government and
finance. Requisitions for compensation and expenses shall .be accompanied by
sworn and itemized statements, which shall be filed with the auditor and
preserved as public records. For the purpose of this section, time served shall
include time spent in the hearing of claims, in the consideration of the
record, in the preparation of opinions, and in necessary travel.
?14.2-9. Oath of office.
Each judge shall before entering upon the duties of his office, take and
subscribe to the oath prescribed by section 5, article IV of the Constitution
of the State. The oath shall be filed with the clerk.
?14.2-10. Qualifications of judges.
Each judge appointed to the court of claims shall be an attorney at law,
licensed to practice in this State and shall have been so licensed to practice
law for a period of not less than ten years prior to his appointment as judge.
A judge shall not be an officer or an employee of any branch of state
government, except in his capacity as a member of the court
STATE COURT OF
CLAIMS LAW XI
and shall receive no other compensation from the State or any of its political
subdivisions. A judge shall not hear or participate in the consideration of any
claim in which he is interested personally, either directly or indirectly.
?14-2-11. Attorney general to represent State.
The attorney general shall represent the interests of the State in all claims
coming before the court.
?14-2-12. General powers of the court.
The court shall, in accordance with this article, consider claims which, but
for the constitutional immunity of the State from suit, or for some statutory
restrictions, inhibitions or limitations, could be maintained in the regular
courts of the State. No liability shall be imposed upon the State or any state
agency by a determination of the court of claims approving a claim and
recommending an award, unless the claim is (1) made under an existing
appropriation, in accordance with section nineteen [ 14-2-19] of this article, or (2) a claim under a
special appropriation, as provided in section twenty [14-2- 20] of this
article. The court shall consider claims in accordance with the provisions of
this article.
Except as is otherwise provided in this article, a claim shall be instituted by
the filing of notice with the clerk. In accordance with rules promulgated by
the court, each claim shall be considered by the court as a whole, or by a
judge sitting individually, and if, after consideration, the court finds that a
claim is just and proper, it shall so determine and shall file with the clerk a
brief statement of its reasons. A claim so filed shall be an approved claim. The
court shall also determine the amount that should be paid to the claimant, and
shall itemize this amount as an award, with the reasons therefor, in its
statement filed with the clerk. In determining the amount of a claim, interest
shall not be allowed unless the claim is based upon a contract which
specifically provides for the payment of interest.
?14-2-13. Jurisdiction of the court.
The jurisdiction of the court, except for the claims excluded by section
fourteen [14-2-14], shall extend to the following matters:
XII STATE
COURT OF CLAIMS LAW
1. Claims and demands, liquidated and
unliquidated, ex contractu and ex delicto, against the State or any of its
agencies, which the State as a sovereign commonwealth should in equity and good
conscience discharge and pay.
2. Claims and demands, liquidated and unliquidated, ex contractu and ex
delicto, which may be asserted in the nature of setoff or counterclaim on the
part of the State or any state agency.
3. The legal or equitable status, or both, of any claim referred to the court
by the head of a state agency for an advisory determination.
?14-2-14. Claims excluded.
The jurisdiction of the court shall
not extend to any claim:
1. For loss, damage, or destruction of property or for injury or death incurred
by a member of the militia or national guard when in the service of the State.
2. For a disability or death benefit under chapter twenty- three [23-1-1 et
seq.] of this Code.
3. For unemployment compensation under chapter twenty- one-A [21A-1-1 et seq.]
of this Code.
4. For relief or public assistance under chapter nine [9-1-1 et seq.] of this
Code.
5. With respect to which a proceeding may be maintained against the State, by
or on behalf of the claimant in the courts of the State.
?14-2-15. Rules of practice and
procedure.
The court shall adopt and may from
time to time amend rules of procedure, in accordance with the provisions of
this article, governing proceedings before the court. Rules shall be designed
to assure a simple, expeditious and inexpensive consideration of claims. Rules
shall permit a claimant to appear in his own behalf or be represented by
counsel.
Under its rules, the court shall not be bound by the usual common law or
statutory rules of evidence. The court may
STATE COURT OF
CLAIMS LAW XIII
accept and weigh, in accordance with
its evidential value, any information that will assist the court in determining
the factual basis of a claim.
?14-2-16. Regular procedure.
The regular procedure for the
consideration of claims shall be substantially as follows:
1. The claimant shall give notice to the clerk that he desires to maintain a
claim. Notice shall be in writing and shall be in sufficient detail to identify
the claimant, the circumstances giving rise to the claim, and the state agency
concerned, if any. The claimant shall not otherwise be held to any formal
requirement of notice.
2. The clerk shall transmit a copy of the notice to the state agency concerned.
The state agency may deny the claim, or may request a postponement of proceedings
to permit negotiations with the claimant. If the court finds that a claim is
prima facie within its jurisdiction, it shall order the claim to be placed upon
its regular docket for hearing.
3. During the period of negotiations and pending hearing, the state agency,
represented by the attorney general, shall, if possible, reach an agreement
with the claimant regarding the facts upon which the claim is based so as to
avoid the necessity for the introduction of evidence at the hearing. If the
parties are unable to agree upon the facts an attempt shall be made to
stipulate the questions of fact in issue.
4. The court shall so conduct the hearing as to disclose all material facts and
issues of liability and may examine or cross- examine witnesses. The court may
call witnesses or require evidence not produced by the parties; may stipulate
the questions to be argued by the parties; and may continue the hearing until
some subsequent time to permit a more complete presentation of the claim.
5. After the close of the hearing the court shall consider the c]aim and shall
conclude its determination, if possible, within thirty days.
XIV STATE COURT
OF CLAIMS LAW
?14-2-17. Shortened procedure.
The shortened procedure authorized by this section shall apply only to a
claim possessing all of the following characteristics:
1. The claim does not arise under an appropriation for the current fiscal year.
2. The state agency concerned concurs in the claim.
3. The amount claimed does not exceed one thousand dollars.
4. The claim has been approved by the attorney general as one that, in view of
the purposes of this article, should be paid.
The state agency concerned shall prepare the record of the claim consisting of
all papers, stipulations and evidential documents required by the rules of the
court and file the same with the clerk. The court shall consider the claim
informally upon the record submitted. If the court determines that the claim
should be entered as an approved claim and an award made, it shall so order and
shall file its statement with the clerk. If the court finds that the record is
inadequate, or that the claim should not be paid, it shall reject the claim.
The rejection of a claim under this section shall not bar its resubmission
under the regular procedure.
?14-2-18. Advisory determination procedure.
The governor or the head of a state agency may refer to the court for an
advisory determination the question of the legal or equitable status, or both,
of a claim against the State or a state agency. This procedure shall apply only
to such claims as are within the jurisdiction of the court. The procedure shall
be substantially as follows:
1. There shall be filed with the clerk, the record of the claim including a
full statement of the facts, the contentions of the claimant, and such other
materials as the rules of the court may require. The record shall submit
specific questions for the court?s consideration.
2. The clerk shall examine the record submitted and if he finds that it is
adequate under the rules, he shall place the claim on a special docket. If he
finds the record inadequate, he shall refer it back to the officer submitting
it with the
STATE COURT OF
CLAIMS LAW XV
request that the necessary additions or changes be made.
3. When a claim is reached on the special docket, the court shall prepare a
brief opinion for the information and guidance of the officer. The claim shall
be considered informally and without hearing. A claimant shall not be entitled
to appear in connection with the consideration of the claim.
4. The opinion shall be filed with the clerk. A copy shall be transmitted to
the officer who referred the claim.
An advisory determination shall not bar the subsequent consideration of the
same claim if properly submitted by, or on behalf of, the claimant. Such
subsequent consideration, if undertaken, shall be de novo.
?14.2-19. Claims under existing appropriations.
A claim arising under an appropriation made by the legislature during the
fiscal year to which the appropriation applies, and falling within the
jurisdiction of the court, may be submitted by:
1. A claimant whose claim has been rejected by the state agency concerned or by
the state auditor.
2. The head of the state agency concerned in order to obtain a determination of
the matters in issue.
3. The state auditor in order to obtain a full hearing and consideration of the
merits.
The regular procedure, so far as applicable, shall govern the consideration of
the claim by the court. If the court finds that the claimant should be paid, it
shall certify the approved claim and award to the head of the appropriate state
agency, the state auditor, and to the governor. The governor may thereupon
instruct the auditor to issue his warrant in payment of the award and to charge
the amount thereof to the proper appropriation. The auditor shall forthwith
notify the state agency that the claim has been paid. Such an expenditure shall
not be subject to further review by the auditor upon any matter determined and
certified by the court.
?14-2-20. Claims under special appropriations.
Whenever the legislature makes an appropriation for the payment of claims
against the State, then accrued or arising
XVI STATE COURT
OF CLAIMS LAW
during the ensuing fiscal year, the determination of claims and the payment
thereof may be made in accordance with this section. However, this section
shall apply only if the legislature in making its appropriation specifically so
provides.
The claim shall be considered and determined by the regular or shortened
procedure, as the case may be, and the amount of the award shall be fixed by
the court. The clerk shall certify each approved claim and award, and
requisition relating thereto, to the auditor. The auditor thereupon shall issue
his warrant to the treasurer in favor of the claimant. The auditor shall issue
his warrant without further examination or review of the claim except for the
question of a sufficient unexpended balance in the appropriation.
?14-2-21. Periods of limitation made
applicable.
The court shall not take jurisdiction
of any claim, whether accruing before or after the effective date of this
article [July 1, 1967], unless notice of such claim be filed with the clerk
within such period of limitation as would be applicable under the pertinent
provisions of the Code of West Virginia, one thousand nine hundred thirty-one,
as amended, if the claim were against a private person, firm or corporation and
the constitutional immunity of the State from suit were not involved and such
period of limitation may not be waived or extended. The foregoing provision
shall not be held to limit or restrict the right of any person, firm or
corporation who or which had a claim against the State or any state agency,
pending before the attorney general on the effective date of this article [July
1, 1967], from presenting such claim to the court of claims, nor shall it limit
or restrict the right to file such a claim which was, on the effective date of
this article [July 1, 1967], pending in any court of record as a legal claim
and which, after such date was or may be adjudicated in such court to be
invalid as a claim against the State because of the constitutional immunity of
the State from suit.
?14-2-22. Compulsory process.
In all hearings and proceedings before
the court, the evidence and testimony of witnesses and the production of
documentary evidence may be required. Subpoenas may be issued by the
STATE COURT OF
CLAIMS LAW XVII
court for appearance at any designated
place of hearing. In case of disobedience to a subpoena or other process, the
court may invoke the aid of any circuit court in requiring the evidence and
testimony of witnesses, and the production of books, papers and documents. Upon
proper showing, the circuit court shall issue an order requiring witnesses to
appear before the court of claims; produce books, papers and other evidence;
and give testimony touching the matter in question. A person failing to obey
the order may be punished by the circuit court as for contempt.
?14-2-23. Inclusion of awards in
budget.
The clerk shall certify to the
department of finance and administration, on or before the twentieth day of
November of each year, a list of all awards recommended by the court to the
legislature for appropriation. The clerk may certify supplementary lists to the
governor to include subsequent awards made by the court. The governor shall
include all awards so certified in his proposed budget bill transmitted to the
legislature.
?14-2-24. Records to be preserved.
The record of each claim considered by
the court, including all documents, papers, briefs, transcripts of testimony
and other materials, shall be preserved by the clerk and shall be made
available to the legislature or any committee thereof for the reexamination of
the claim.
?14-2-25. Reports of the court.
The clerk shall be the official
reporter of the court. He shall collect and edit the approved claims, awards
and statements, shall prepare them for submission to the legislature in the
form of an annual report and shall prepare them for publication.
Claims and awards shall be separately classified as follows:
1. Approved claims and awards not satisfied but referred to the legislature for
final consideration and appropriation.
2. Approved claims and awards satisfied by payment out of regular
appropriations.
XVIII STATE
COURT OF CLAIMS LAW
3. Approved claims and awards
satisfied by payment out of a special appropriation made by the legislature to
pay claims arising during the fiscal year.
4. Claims rejected by the court with the reasons therefor.
5. Advisory determinations made at the request of the governor or the head of a
state agency.
The court may include any other information or recommendations pertaining to
the performance of its duties.
The court shall transmit its annual report to the presiding officer of each
house of the legislature, and a copy shall be made available to any member of
the legislature upon request therefor. The reports of the court shall be
published biennially by the clerk as a public document. The biennial report
shall be filed with the clerk of each house of the legislature, the governor
and the attorney general.
?14-2-26.
Fraudulent claims.
A person who knowingly and wilfully presents or attempts to present a false or
fraudulent claim, or a state officer or employee who knowingly and wilfully
participates or assists in the preparation or presentation of a false or
fraudulent claim, shall be guilty of a misdemeanor. A person convicted, in a
court of competent jurisdiction, of violation of this section shall be fined
not more than one thousand dollars or imprisoned for not more than one year, or
both, in the discretion of such court. If the convicted person is a state
officer or employee, he shall, in addition, forfeit his office or position of
employment, as the case may be.
?14.2-27. Conclusiveness of determination.
Any final determination against the claimant on any claim presented as provided
in this article shall forever bar any further claim in the court arising out of
the rejected claim.
?14-2-28. Award as condition precedent to appropriation.
It is the policy of the legislature to make no appropriation to pay any
claims against the State, cognizable by the court, unless the claim has first
been passed upon by the court.
RULES OF PRACTICE
AND PROCEDURES XIX
?14-2-29.
Severability.
If any provision of this article or the application thereof to any person or
circumstance be held invalid, such invalidity shall not affect other provisions
or applications of the article which can be given effect without the invalid
provision or application, and to this end the provisions of this article are
declared to be severable.
XX RULES OF
PRACTICE AND PROCEDURE
Rules of Practice
and
Procedure
of the
STATE COURT OF CLAIMS
(Adopted by the Court
September 11, 1967.
Amended February 18, 1970
Amended February 23, 1972
Amended August 1, 1978.)
RULES OF PRACTICE
AND PROCEDURE XXI
TABLE OF RULES
Rules of Practice and Procedure
RULE
1. Clerk, Custodian of Papers, etc.
2. Filing Papers.
3. Records.
4. Form of Claims.
5. Copy of Notice of Claims to Attorney General and State Agency.
6. Preparation of Hearing Docket.
7. Proof and Rules Governing Procedure.
8. Appearances.
9. Briefs.
10. Continuances: Dismissal For Failure to Prosecute.
11. Original Papers Not To Be Withdrawn: Exceptions.
12. Withdrawal of Claim.
13. Witnesses.
14. Depositions.
15. Re-Hearings.
16. Records of Shortened Procedure Claims Submitted by State Agencies.
17. Application of Rules of Civil Procedure.
XXII RULES OF
PRACTICE AND
PROCEDURE
RULES OF PRACTICE
AND PROCEDURE
OF THE
COURT OF CLAIMS
STATE OF WEST VIRGINIA
RULE 1. CLERK, CUSTODIAN OF
PAPERS, ETC.
The Clerk shall be responsible for
all papers and claims filed in his office; and will be required to properly
file, in an index for that purpose, any paper, pleading, document, or other
writing filed in connection with any claim. The Clerk shall also properly
endorse all such papers and claims, showing the title of the claim, the number
of the same, and such other data as may be necessary to properly connect and
identify the document, writing or claim.
RULE 2. FILING PAPERS.
(a) Communications addressed to the Court or Clerk and all notices,
petitions, answers and other pleadings, all reports, documents received or
filed in the office kept by the Clerk of this Court, shall be endorsed by him
showing the date of the receipt or filing thereof.
(b) The Clerk, upon receipt of a notice of a claim, shall enter of record in
the docket book indexed and kept for that purpose, the name of the claimant,
whose name shall be used as the title of the case, and a case number shall be
assigned accordingly.
(c) No paper, exclusive of exhibits, shall be filed in any action or proceeding
or be accepted by the Clerk for filing nor any brief, deposition, pleading,
order, decree, reporter?s transcript or other paper to be made a part of the
record in any claim be received except that the same be upon paper measuring 8?
inches in width and 11 inches in length.
RULES OF
PRACTICE AND PROCEDURE XXIII
RULE 3. RECORDS.
The Clerk shall keep the following record books, suitably indexed in the
names of claimants and other subject matter:
(a) Order Book, in which shall be recorded at large, on the day of their
filing, all orders made by the Court in each case or proceeding.
(b) Docket Book, in which shall be entered each case or claim made and filed,
with a file or case number corresponding to the number of the case, together
with brief chronological notations of the proceedings had in each case.
(c) Financial Ledger, in which shall be entered chronologically, all
administrative expenditures of the Court under suitable classifications.
RULE 4. FORM OF CLAIMS.
Verified notice in writing of each claim must be filed with the Clerk of
the Court. The notice shall be in sufficient detail to identify the claimant,
the circumstances giving rise to the claim, and the State Agency concerned, if
any. The Court reserves the right to require further information before
hearing, when, in its judgment, justice and equity may require. It is
recommended that notice of claims be furnished in triplicate. A suggested form
of notice of a claim may be obtained from the Clerk.
RULE 5. COPY OF NOTICE OF CLAIMS TO ATTORNEY GENERAL AND STATE AGENCY.
Upon receipt of a notice of claim to be considered by the Court, the Clerk
shall forthwith transmit a copy of the notice to the State Agency concerned, if
any, and a copy thereof to the office of the Attorney General of the State, and
the Clerk shall make a notice of the time of such delivery.
XXIV RULES OF
PRACTICE AND PROCEDURE
RULE 6. PREPARATION OF HEARING DOCKET.
On and after the date of adoption of
these rules by the Court, the Clerk shall prepare fifteen days previous to the regular
terms of Court a docket listing all claims that are ready for hearing by the
Court, and showing the respective dates, as fixed by the Court for the hearing
thereof. The Court reserves the right to add to, rearrange or change said
docket when in its judgment such addition, rearrangement or change would
expedite the work of the term. Each claimant or his counsel of record and the
Attorney General shall be notified as to the date, time, and place of the
hearing.
RULE 7. PROOF AND RULES GOVERNING
PROCEDURE.
(a) Claims asserted against the State,
including all the allegations in a notice of claim, are treated as denied, and
must be established by the claimant with satisfactory proof, or proper
stipulation as hereinafter provided before an award can be made.
(b) The Court shall not be bound by the usual common law or statutory rules of
evidence. The Court may accept and weigh, in accordance with its evidential
value, any information that will assist the Court in determining the factual
basis of the claim.
(c) The Attorney General shall within twenty days after a copy of the notice
has been furnished his office file with the Clerk a notice in writing, either
denying the claim, requesting postponement of proceedings to permit
negotiations with the claimant, or otherwise setting forth reasons for further
investigation of the claim, and furnish the claimant or his counsel of record a
copy thereof. Otherwise, after said twenty-day period, the Court may order the
claim placed upon its regular docket for hearing.
(d) It shall be the duty of the claimant or his counsel in claims under the
regular procedure to negotiate with the Office of the Attorney General so that
the claimant and the State Agency and the Attorney General may be ready at the
RULES OF PRACTICE
AND PROCEDURE XXV
beginning of the hearing of a claim to read, if reduced to writing, or to
dictate orally, if not reduced to writing, into the record such stipulations,
if any, as the parties may have been able to agree upon.
(e) Where there is a controversy between a claimant and any State Agency, the
Court may require each party to reduce the facts to writing, and if the parties
are not in agreement as to the facts, the Court may stipulate the questions of
fact in issue and require written answers to the said stipulated questions.
(f) Claims not exceeding the sum of $1,000.00 may be heard and considered, as
provided by law, by one judge sitting individually.
RULE 8. APPEARANCES.
Any claimant may appear in his own
behalf or have his claim presented by counsel, duly admitted as such to
practice law in the State of West Virginia.
RULE 9. BRIEFS.
(a) Claimants or their counsel, and
the Attorney General, may file with the Court for its consideration a brief on
any question involved, provided a copy of said brief is also presented to and
furnished the opposing party or counsel. Reply briefs shall be filed within
fifteen days.
(b) All briefs filed with, and for the use of, the Court shall be in
quadruplicate ?
original and three copies. As soon as any
brief is received by the Clerk, he shall file the original in the Court file
and deliver the three copies, one each, to the Judges of the Court.
RULE 10. CONTINUANCES: DISMISSAL FOR
FAILURE TO PROSECUTE.
(a) After claims have been set for
hearing, continuances are looked upon by the Court with disfavor, but may be
allowed when good cause is shown.
(b) A party desiring a continuance should file a motion showing good cause
therefor at the earliest possible date.
XXVI RULES OF
PRACTICE AND PROCEDURE
(c) Whenever any claim has been docketed for hearing for three regular terms of
Court at which the claim might have been prosecuted, and the State shall have
been ready to proceed with the trial thereof, the Court may, upon its own
motion or that of the State, dismiss the claim unless good cause appear or be
shown by the claimant why such claim has not been prosecuted.
(d) Whenever a claimant shall fail to appear and prosecute his claim on the day
set for hearing and shall not have communicated with the Clerk prior thereto,
advising of his inability to attend and the reason therefore, and if it further
appear that the claimant or his counsel had sufficient notice of the docketing
of the claim for hearing, the Court may, upon its own motion or that of the
State, dismiss the claim.
(e) Within the discretion of the Court, no order dismissing a claim under
either of the two preceding sections of this rule shall be vacated nor the
hearing of such claim be reopened except by a notice in writing filed not later
than the end of the next regular term of Court, supported by affidavits showing
sufficient reason why the order dismissing such claim should be vacated, the
claim reinstated and the trial thereof permitted.
RULE 11. ORIGINIAL PAPERS NOT TO BE
WITHDRAWN:
EXCEPTIONS.
No original paper in any case shall be
withdrawn from the Court files except upon special order of the Court or one of
the Judges thereof in vacation. When an official of a State Department is
testifying from an original record of his department, a certified copy of the
original record of such department may be filed in the place and stead of the
original.
RULE 12. WITHDRAWAL OF CLAIM.
(a) Any claimant may withdraw his
claim. Should the claimant later refile the claim, the Court shall consider its
former status, such as previous continuances and any other matter affecting its
standing, and may re-docket or refuse to re-docket the claim as in its
judgment, justice and equity may require under the circumstances.
RULES OF PRACTICE
AND PROCEDURE XXVII
(b) Any department or State Agency, having filed a claim for the Court?s
consideration, under either the advisory determination procedure or the
shortened procedure provision of the Court Act, may withdraw the claim without
prejudice to the right of the claimant involved to file the claim under the
regular procedure.
RULE 13. WITNESSES.
(a) For the purpose of convenience and
in order that proper records may be preserved, claimants and State Departments
desiring to have subpoenas for witnesses shall file with tne Clerk a memorandum
in writing giving the style and number of the claim and setting forth the names
of such witnesses, and thereupon such subpoenas shall be issued and delivered
to the person calling therefor or mailed to the person designated.
(b) Requests for subpoenas for witnesses should be furnished to the Clerk well
in advance of the hearing date so that such subpoenas may be issued in ample
time before the hearing.
(c) The payment of witness fees, and mileage where transportation is not furnished
to any witness subpoenaed by or at the instance of either the claimant or the
respondent State Agency, shall be the responsibility of the party by whom or at
whose instance such witness is subpoenaed.
RULE 14. DEPOSITIONS.
(a) Depositions may be taken when a
party desires the testimony of any person, including a claimant. The deposition
shall be upon oral examination or upon written interrogatory. Depositions may
be taken without leave of the Court. The attendance of witnesses may be
compelled by the use of subpoenas as provided in Rule 13.
(b) To take the deposition of any designated witness, reasonable notice of time
and place shall be given the opposite party or counsel, and the party taking
such deposition shall pay the costs thereof and file an original and three
copies of such deposition with the Court. Extra copies of exhibits will not be
required; however, it is suggested that where exhibits
XXVIII
CLASSIFICATION OF CLAIMS AND AWARDS
are not too lengthy and are of such a nature as to permit it, they should be
read into the deposition.
(c) Depositions shall be taken in accordance with the provision of Rule 17 of
this Court.
RULE 15. RE-HEARINGS.
A re-hearing shall not be allowed
except where good cause is shown. A motion for re-hearing may be entertained
and considered ex parte, unless the Court otherwise directs, upon the petition
and brief filed by the party seeking the re-hearing. Such petition and brief
shall be filed within thirty days after notice of the Court?s determination of
the claim unless good cause be shown why the time should be extended.
RULE 16. RECORDS OF SHORTENED
PROCEDURE
CLAIMS SUBMITTED BY STATE AGENCIES.
When a claim is submitted under the
provisions of Chapter 14, Article 2, Paragraph 17 of the Code of West Virginia,
concurred in by the head of the department and approved for payment by the
Attorney General, the record thereof, in addition to copies of correspondence,
bills, invoices, photographs, sketches or other exhibits, should contain a
full, clear and accurate statement, in narrative form, of the facts upon which
the claim is based. The facts in such record among other things which may be
peculiar to the particular claim, should show as definitely as possible that:
(a) The claimant did not through neglect, default or lack of reasonable care,
cause the damage of which he complains. It should appear he was innocent and
without fault in the matter.
(b) The department, by or through neglect, default or the failure to use
reasonable care under the circumstances caused the damage to claimant, so that
the State in justice and equity should be held liable.
(c) The amount of the claim should be itemized and supported by a paid invoice,
or other report itemizing the damages, and vouched for by the head of the department
as to correctness and reasonableness.
CLASSIFICATION OF
CLAIMS AND AWARDS XXIX
RULE 17. APPLICATION OF RULES OF CIVIL
PROCEDURE.
The Rules of Civil Procedure will
apply in the Court of Claims unless the Rules of Practice and Procedure of the
Court of Claims are to the contrary.
Adopted by Order of the Court
of Claims, September 11, 1967.
Amended February 18, 1970.
Amended February 23, 1972.
Amended August 1, 1978.
CHERYLE M. HALL, Clerk
REPORT
OF THE COURT OF CLAIMS
For the Period July 1, 1977 to June 30, 1979
(1) Approved claims and awards not
satisfied but to be referred to the 1980 Legislature for final consideration
and C appropriation:
C11
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-76-9 Black Rock Contracting, Inc.
Department of Highways $
40,122.32 $ 8,067.79 3-29-79
CC-79-60 Capitol Business Interiors,
Department of Finance 141.00 141.00 6-13-79
Div. of Capitol Business & Administration
Equipment, Inc. o
CC-79-22 Clinic Private Division, Division
of Vocational 842.00 842.00 6-30-79
University of Virginia Rehabilitation
CC-79-94 Dill?s Mountaineer Department of Health 2,406.00 2,406.00 6-30-79
Associates Inc.
CC-79-70 Greenlee, Drema D. & Department of Highways 54.00 54.00 6-13-79
Stephen E. Greenlee CI)
CC-79-36 Heck?s Inc. Division of
Vocational 245.56 245.56 6-13-79
Rehabilitation
CC_77_155* Metz, Lewis Dale Department of Corrections 5,000.00 No Award 6-21-79
CC-79-150 Nationwide Insurance Co., Department of Highways 179.22 179.22
6-30-79
subrogee of Phillip W.
Alexander
CC-78-259 Smith, Larry Keith Department of Highways 296.30 296.30 6-30-79
CC-78-68 Spradling, Charles H., Jr. Department of Highways 117.62 117.62
4-10-79
CC-78-270 Weber, Harold L., Jr. Department of Health 10,144.22 9,791.91 3-23-79
* NOTE: A Motion to Dismiss certain named individuals was
granted; the portion of the Motion to Dismiss as to the Department of
Corrections and Board of Probation and Parole was denied. The Court ordered the
claim be set for hearing at a later date.
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1977, to June 30, 1979:
0
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
u
CC-79-3 Abbott Laboratories Board of Regents $ 637.72 $ 637.72
3-23-79
CC-79-7 Ace Glass, Inc. Board of Regents 71.49 71.49 3-23-79
CC-77-78 Adkins, William J. Department of Highways 13,820.00 2,000.00 10-23-78
etal.
CC-79-6 Air Products and Board of Regents 204.37 204.37 3-23-79 0
Chemicals, Inc.
CC-77-156 Alert Sanitation Office of the Governor? 2,700.00 2,350.00 2-9-78 0
Emergency Flood tJ
Disaster Relief 0
D-990 Alford, Elvin S. Department of Highways 8,496.65 2,800.00 10- 17-77
CC-77-1l0 Allison, Curtis Department of Highways 429.00 244.85 2-10-78
CC-77-62 Alvis, David E. Department of Highways 99.85 99.85 12-12-77
CC-78-265 American Hospital Supply Department of Health 424.32 424.32 1-31-79
CC-76-66 Appalachian Power Co. Department of Highways 2,359.94 2,303.35 8-8-77
CC-77-220 Arthritis Care Associates Division of Vocational 25.40 25.40 2-10-78
Rehabilitation
CC-78-224 Baker, Carl L., Jr. Department of Health 6,975.46 6,975.46 1-26-79
CC-78-173 Barfield, Gladys Office of the Governor? 700.16 700.16 1-9-79
Emergency Flood
Disaster Relief
CC-77-l4l Barr, Frank G. Department of Highways 595.68 595.68 1-6-78
CC-76-24 Bastin, Olie G. and Department of Highways 4,500.00 4,500.00 2-10-78
Priscilla Bastin
CC-78-276 Bayliss, Wayne Department of Highways 251.83 251.83 1-31-79
CC-77-84 Belmont, Raymond N. Department of Highways 124.50 80.00 12-22-77
CC-78-203 Bernhardt?s Clothing Inc. Department of Corrections 1,986.80 1,986.80
1-9-79
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1977, to June 30, 1979:
0
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-78-251 Curry, H. M. Department of Health 6,798.78 6,798.78 1-26-79
CC-77-86 Custer, George M. Department of Motor 302.00 300.00 12-12-77
Vehicles
CC-79-28 Cutter Laboratories, Inc. Board of Regents 1,248.00 1,248.00 3-23-79
CC-78-88 Dalessio, Lillian Board of Regents 300.00 300.00 1-9-79
D-996b Davis, Billy Joe Department of Highways 10,500.00 750.00 11-14-77 Z
D-996a Davis, Frank and Billy Department of Highways 135,000.00 21,125.00
11-14-77
Joe Davis, d/bla Davis
Auto Parts 0
CC-78-230 Davis Memorial Hospital Department of Corrections 3,233.19 3,233.19
1-9-79
(a-c)
D-927g DeWeese, Icy Mae Division of Vocational 4,504.80 202.50 11-16-78
Rehabilitation Cl)
CC-79-29 Diagnostic Isotopes, Inc. Board
of Regents 81.60 81.60 3-23-79
CC-77-151 Direct Mail Service Co. Board of Regents 70.00 750.00 12-12-77
CC-79-4 Ehrenreich Photo- Board of Regents 388.95 388.95 3-23-79 Optical md.
Inc.
CC-76-143 Eisenberg, Jacquelyn B., Board of Regents 7,500.00 1,500.00 2-13-78
parent and next friend
of Mark Harrold Eisenberg,
an infant
D-927e Engegno, Ethel Division of Vocational 6,957.60 4,989.22 11-16-78
Rehabilitation
CC-79-8 Fairmont Supply Company Board of Regents 20.40 20.40 3-23-79 CC-77-162
Fentress, Albert D. and Department of Highways 122.68 122.68 2-10-78
Hazel S. Fentress
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1977, to June 30, 1979:
C)
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-78-77 Fields, Rush Department of Highways 1,142.18 1,142.18 6-22-78
CC-77-201 Frazier, Bradford G. Department of Highways 160.48 160.48 1-6-78 C)
CC-78-3 Fredlock, A.M., II Department of Highways 235.20 235.20 10-23-78 >
CC-77- 125 Friden Mailing Equip- Department of Corrections 147.00 147.00 2-
10-78 ment Corporation
D-927f Fury, Rondal Division of Vocational 5,778.48 4,296.92 11-16-78 Z
Rehabilitation C
CC-78-237 Garrett, Joseph Larry Department of Public 290.56 290.56 1-9-79
Safety
CC-78-153 Gillispie, Teresa K. Department of Highways 99.13 99.13 1-9-79 &
Johnny Wayne Gillispie
CC-77-197 Gore, Charles R. Department of Highways 332.49 332.49 8-10-78
CC-77-153 Gott, Peggy S. Department of Health, 4,332.00 4,332.00 2-10-78
Div. of Mental Health
CC-77-147 Grimmett, Timothy J. Department of Highways 271.44 271.44 12-12-77
CC-78-244 Guyan Transfer and Department of Finance 4,290.00 4,290.00 1-31-79
Sanitation, Inc. & Administration
CC-78-264 Halliburton Services Department of Highways 22856 228.56 1-31-79
CC-78-260 Hamilton, Linda E. Department of Highways 92.00 92.00 1-31-79
? CC-78-226 Haney, Douglas Department of Highways 309.50 309.50 1-9-79 e CC-77-124 Hart, Michael J. Department of Highways 46.49
46.49 12-12-77 (?2
CC-76-125 Hartford Accident &
Department of Highways 26,667.95 21,826.50 11-14-77
Indemnity Company
CC-77-94 Hastings, Robert M. & Department of Highways 365.00 365.00 12-8-77
Linda Hastings, d/b/a
Hastings Stables
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period
July 1, 1977, to June 30, 1979:
1:-I
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-78-281 Haynes, Howard A. Department of Highways 300.19 300.19 1-31-79
CC-78-l30 Heater, Arnold G. & Department of Highways 3,500.00 2,500.00 2-20-79
Geraldine Heater
CC-77-190 Henry Elden & Associates Department of National 4,000.00 4,000.00
10-11-78
Resources Z
CC-78-269 Henry Elden & Associates Department of Finance 71,889.00
71,889.00 1-11-79 o
& Administration and
Department of Health
CC-76-l08 Herron, Ora T. Department of Public 18.00 18.00 1-31-79 t
Safety
CC-77-200 Hills, H. M., Jr. & Department of Public 105.00 105.00 1-6-78
Luis A. Loimil Safety
CC-77-l34 Hogan Storage & Department of Agriculture 8,000.00 6,000.00
2-10-78
Transfer Company & Department of Health Z
CC-79-5 Hubbard Pump Co. Board of Regents 20.89 20.89 3-23-79 d
CC-77-83 Hubbs, Kermit Reed Department of Highways 435.90 435.90 12-6-77
CC-77-52 Hudnall, McHenry, Jr. Department of Highways 147.73 147.73 11-1-77
CC-77-68 Hunter, Alvin 0. Department of Highways 223.00 223.00 10-23-78 ?
CC-77-1 IBM Corporation Department of
Motor 239.22 123.65 8-8-77
Vehicles
CC-78-l72 Jarrell, R. L. Department of Highways 291.42 291.42 3-23-79
CC-77-146 Johnson, Robert H. Department of Highways 1,500.00 900.00 2-10-78
CC-77-207 Jones Printing Company, Inc Governor?s Office of 235.00 235.00
2-10-78
Economic and Community
Development
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1977, to June 30, 1979:
0
1-I
Amount Amount Date of
No. Name of Claimant
Name of Respoadent Claimed Awarded
Determination
CC-77-2l2 Kanawha Valley Division of 109.00 109.00 2-10-78
(a-k) Radiologists, Inc. Vocational Rehabilitation 0
D-927b Keeling, Ralph Division of Vocational 4,593.88 4,593.88 11-16-78 >
Rehabilitation
CC-78-38 Keyser, Peggy Department of Highways 113.56 113.56 10-23-78 0
CC-77-37 King, Forest Joe Department of Highways 50,000.00 11,000.00 10-24-78 Z
CC-77-37 Patricia Ann King Department of Highways 20,000.00 10-24-78 0
CC-77-37 Forest Joe King, as Department of Highways 2,500.00 10-24-78
father & next friend of
Denny Joe King
CC-77-37 Forest Joe King, as Department of Highways 2,500.00 10-24-78
father & next friend of
Beverly King
D-1041 Korthals, Theodore & Department of Highways 12,000.00 3,500.00
12-12-77
Emile Korthals
CC-76-44 Lafferty, Eugene and Department of Highways 10,500.00 10,500.00 2-10-78
Wanda Lafferty
CC-77-193 Lambert, Thomas F. Department of Welfare 457.60 457.60 2-10-78
D-927k Leach, Paul Division of Vocational 3,831.39 2,394.65 11-16-78
Rehabilitation
CC-77-210 Linda Lester and Department of Highways 199.63 187.63 2-10-78
Leon Lester
CC-79-2 Light Gallery and Board of Regents 31.00 31.00 3-23-79
Supply Co.
CC-77-133 Lilly, Herman F. Department of Highways 1,200.00 1,200.00 7-12-78
CC-77-228 Lively, Debris J. Department of Highways 98.88 98.88 7-12-78
REPORT
OF THE COURT OF CLAIMS (Continued)
(2)
Approved claims and awards satisfied
by payments out of appropriations made by the Legislature for the period July
1, 1977, to June 30, 1979:
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded
Determination
cj
CC-78-115 Long, Charles P. Department of
Highways 43.76 43.76 8-10-78 CC-78-253 Lucas, Harry Glenn, Jr. Department of
Public 283.52 283.52 1-9?79
Safety
CC-77--175 Lynch, Gerald J. Department of Highways 206.76 206.76 2-10-78
CC-77-221 McCloy Construction Department of Natural 233,750.00 27,000.00
2-20-79
Company, Inc. Resources z
D-737 Mcintyre, Rhoda Raynett Department
of Highways 10,000.00 500.00 10-24-78
CC-77-136 Mahaffee, Harold Department of Highways 94.24 94.24 10-24-78 TJ
CC-76-65 Marcum, Alice Department of
Natural 100,182.00 2,171.00 10-24-78 Resources
CC-77-199 Massie, Robert L. and Office of the Governor? 465.00 465.00 2-9-78
Mae Massie Emergency Flood
Disaster Relief
CC-78-238 Maxey, Lowell J. Department of Public 265.80 259.20 1-9-79 Safety Z
CC-77-l18 Mayfield, Hugh C. Department of Highways 400.00 400.00 12-12-77
CC-76-71b Maynard, Arthur & 15,000.00 2,475.00 8-12-77
Mollie Maynard Department of Highways
CC-76-71a Maynard, Norman & 10,000.00 1,250.00 8-12-77 Shirley Maynard
Department of Highways
CC-79-38 Memorial General Hospital Department of Corrections 10,077.71
10,077.71 2-10-79 CC-78-23 Moore Business Forms, Inc. Department of Motor
195.97 195.97 2-20-78
Vehicles
CC-78-46 Moore Business Forms, Inc. Department of Health, 51.42 51.42 10-24-78
Div. of Mental Health
CC-78-36 Morrison Printing Co., Inc. Department of Highways 3,000.00 3,000.00
5-1-78
REPORT
OF THE COURT OF CLAIMS (Continued)
(2)
Approved claims and awards satisfied
by payments out of appropriations made by the Legislature for the period July
1, 1977, to June 30, 1979:
0
(12
-I
?-I
-4
0
0
(12
z
?-I
|
|
|
Amount |
Amount |
Date of |
No. |
Name of Claimant |
Name of Respondent |
Claimed |
Awarded |
Determination |
CC-77-211 |
New Martinsville/Wetzel County Emergency Squad, Inc. |
Division of Vocational Rehabilitation |
162.00 |
162.00 |
2-10-78 |
D-936 |
Norvell, Helen L. Exec. of the Estate of Glenn Hartsel Norvell, dec. |
Department of Highways |
112,500.00 |
15,000.00 |
2-10-78 |
CC-76-109 |
Offutt, Arizona M. |
Department of Highways |
2,000.00 |
1,625.00 |
2-10-78 |
CC-78-96 |
Orkin Exterminating, Inc. |
Department of Health, |
269.70 |
212.00 |
10-24-78 |
(a-c) |
Ostrin Electric Co. |
Div. of Mental
Health |
1,397.50 |
997.50 |
2-1-79 |
CC-77-204 |
Otis Elevator Company |
Department of Health, Div. of Mental Health |
95.00 |
95.00 |
2-10-78 |
D-927a |
Parker, Ralph |
Division of Vocational Rehabilitation |
4,302.96 |
2,070.77 |
11-16-78 |
CC-78-211 |
Patrick Plaza Dodge, Inc. |
Office of the Treasurer |
142.50 |
142.50 |
1-9-79 |
D-927d |
Petts, Elva |
Division of Vocational Rehabilitation |
7,104.00 |
3,985.42 |
11-16-78 |
CC-77-131 |
Phillips, Anna Jane |
Department of Highways |
82.40 |
82.40 |
12-22-77 |
CC-77-107 |
Polls Brothers |
Department of Health, Div. of Mental Health |
239.90 |
239.90 |
2-10-78 |
CC-77-l17 |
Positive Peer Culture, Inc. |
Department of Corrections |
26,341.15 |
26,341.15 |
1-31-79 |
D-927j |
Preston, Gertrude |
Division of Vocational Rehabilitation |
6,822.80 |
5,771.49 |
11-16-78 |
D-927i |
Preston, James |
Division of Vocational Rehabilitation |
6,754.80 |
5,888.75 |
11-16-78 |
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1977, to June 30, 1979:
Amount Amount Date of P
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-77-224 Private Diagnostic Clinic Division of Vocational 399.18 399.18
5-1-78
Rehabilitation
CC-78-223 Rader, Jack L. Department of Health 5,488.05 5,488.05 1-26-79 9
CC-76-123 Raleigh Motor Sales, Inc.
Department of Natural 1,952.36 1,452.36 11-1-77
Resources
CC-77-192 Ray, Alex Office of the Governor?. 1,175.00 1,175.00 2-9-78
Emergency Flood
Disaster Relief
CC-77-202 Rexrode, Jerry Austin Department of Natural 2,943.72 2,943.72 2-10-78
Resources
CC-79-l9 Roche Laboratories, Inc. Board of Regents 1,702.50 1,702.50 3-23-79
CC-77-138 Rosi, Anthony R. Department of Motor 271.60 271.60 2-10-78
Vehicles
CC-77-132 Ross, Franklin and Department of Highways 347.80 347.80 2-10-78 .
Elsie M. Ross Z
CC-78-147 Roton, Larry Department of Highways 203.40 177.73 1-9-79
CC-78-81 Russell, Mae Department of Highways 807.13 700.00 8-10-78
CC-77-l89 Ryan, James and Department of Highways 25,000.00 7,050.00 4-10-79
Joyce Ryan
CC-77-119 S. B. Wallace & Co. Department of Corrections 165.73 157.49
12-22-77
CC-77-74 Sanders Floor Covering, Inc. Board of Regents 1,819.00 1,819.00 1-6-78
CC-76-131 Schooley, Charles E. Department of Highways 7,550.05 7,000.00 11-1-77
D-669b Shah, Saleem A. and Department of Highways 60,000.00 3,500.00 2-10-78
Theresa A. Shah
CC-77-66 Sharp, Mary Jo Department of Health, 458.00 458.00 2-10-78
Div. of Mental Health
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the July 1, 1977, to June
30, 1979:
Legislature for the period
Name of Claimant
Sherwood, Carolyn Crisp
Shreve, Mary Jo
Siclair, Sam d/b/a
Galion Canvas Products
Company
Skaggs, Lawrence Craig
Smith, Robert &
Elizabeth Smith
Spagnuolo, A. A.
Spangler, Odlund
Haney, Jr.
Spitzer, Barbara H.
State Chemical
Manufacturing Company
State Farm Mutual Auto
Insurance Co., subrogee
of Dana Lee Selvig
Stevens, Polly, Guardian of
the Estate of James Walter
Stevens and Timothy Stevens
CC-78-177 Stone, Connie Ann
CC-78-l1 Stone, Thelma J.
CC-79-14 Stuart?s Drug &
Surgical Supply Co.
Name of
Respondent
Department of Highways
Department of Highways
Governor?s Office of
Economic & Community
Development
Department of Highways
Department of Highways
Department of Highways
Department of Employment
Security
Department of Highways
Department of Highways
Board of Regents
Department of Highways
Office of the Governor? Emergency Flood
Disaster Relief
Board of Regents
No.
CC-77-2 14
CC-77-70
CC-77-95
CC-77-56
CC-78-290
CC-78- 134 CC-78-86
CC-78-164 CC-77-79
CC-78- 162
Amount
Claimed
237.00
288.00
808.80
102.23
20,000.00
480.00
88.50
300.00
2,217.50
308.99
D-688
Amount
Awarded
237.00
100.00
808.80
102.23
4,000.00
480.00
88.50
300.00
2,217.50
308.99
Department of Highways
Cl
Li
Ci)
Ci)
Cl
I-?
0
0
C)
1.1
?-I
CI)
Ci)
Date of
Determination
2-10-78
8?19?77
10- 17-77
8-8-77
1-31-79
8-10-78
6- 15-78
2-20-79
8? 19?77
1-31-79
8- 10-78
1?9?79
10-23-78
3-23-79
14,285.00 8,450.00
176.73
2,500.00
176.73
2,500.00
757.16 757.16
Li
?-I
REPORT
OF THE COURT OF CLAIMS
(Continued)
(2) Approved claims and awards satisfied
by payments out of appropriations made by the Legislature for the period July
1, 1977, to June 30, 1979:
cJ
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
CC-79-18 Syva, Inc. Board of Regents 80.48 80.48 3-23-79
CC-78-206 Taylor, Charles E. Department of Highways 5,374.29 1,566.75 1-9-79
&
Mary P. Taylor
CC-77-158 Teets, Williard P., Department of Highways 16,016.50 3,000.00
10-23-78
Attorney in Fact for 0
Percy E. Teets 2
D-669a Testa, Fred K. and Department of Highways 65,000.00 4,500.00 2-10-78 0
Claudia I. Testa IT]
CC-77-7 Thompson, Edith Ann &
Department of Natural $70,000.00 9,627.36 4-3-78 c
Roger Dale Thompson Resources
CC-77-177 Thompson?s of Board of Regents 901.77 901.77 1-6-78
Morgantown, Inc.
CC-77-194 3M Business Products Department of Motor 957.50 957.50 2-10-78
Sales, Inc. Vehicles
CC-77-80 Tillinghast, John & Department of Highways 6,000.00 4,000.00
7-12-78
Janet Tillinghast
CC-78-4 Transport Motor Public Service 837.00 837.00 10-11-78 ?
Express, Inc. Commission
CC-77-91 Travenol Laboratories, Inc. Department of Health, 53.52 53.52 12-22-77
Div. of Mental Health
CC-78-l78 Tyre, Albert K. Department of Corrections 178.10 178.10 1-9-79
CC-78-53 Uarco, Inc. Board of Regents 713.18 713.18 6-22-78
D-9l4 Vecellio & Grogan, Inc. Department of Highways 176,477.58 117,122.44
2-1-79
D-918
(Par. C)
D-993
REPORT
OF THE COURT OF CLAIMS (Continued)
(2) Approved claims and awards
satisfied by payments out of appropriations made by the Legislature for the
period July 1, 1977, to June 30, 1979:
Amount Amount Date of
No. Name of Claimani Name of Respondent Claimed Awarded Determination >
0,
CC-78-204 Ware, Todd W. and Board of
Regents 3,096.51 3,096.51 1-9-79 Taylor Publishing Co.
CC-79-9 Warren Associates Board of Regents 23.20 23.20 3-23-79 0
CC-78-191 Webb, W. F. Department of Highways 1,374.00 1,100.00 10-23-78
CC-77-229 Weber, John M. Board of Regents 19,816.42 3,400.00 1-9-79
CC-77-219a Weekly, Richard L. Office of Emergency 1,025.85 1,025.85 3-8-78 0
Services
CC-77-219b Weekly, Richard L. Office of Emergency 1,144.98 1,144.98 3-8-78 0
Services
CC-77-184 Welch, Marvin Roy Department of Highways 50.00 50.00 1-6-78 D-927c
Wells, Harry Division of Vocational 4,702.16 3,423.80 11-16-78 .
Rehabilitation
CC-77-205 West, Patrick Department of Highways 4,000.00 950.00 10-11-78 D-927h
White, Arthur Division of Vocational 8,155.52 5,217.75 11-16-78
Rehabilitation
CC-78-139 White, Loraine & Department of Highways 10,000.00 1,000.00 1-9-79
Velma White
D-571 Whitmyer Brothers, Inc. Department of Highways 450,000.00 110,082.53
9-26-77 CC-78-158 Wiersma, Silas C. Department of Health, 1,120.00 1,120.00
12-8-78
Div. of Mental Health
CC-77-92 Wilder, John R. and Department of Highways 233.36 233.36 10-17-77
Norma J. Wilder (I?
CC-78-41 Wilson, Patricia, Office of
the Governor? 1,200.00 1,200.00 2-1-79 George P. Wilson, and Emergency Flood
Gladys V. Wilson Disaster Relief
CC-78-209 Wood County Bank Department of Motor 2,749.55 2,749.55 1-11-79
Vehicles
1-4
-I
L-l
I-?
Cl
0
z
0
CI
Ci)
Cl,
162.63 Disallowed
10-23-78
120.90 Disallowed 12-22-77
147.09 Disallowed 1-9-79
REPORT OF THE COURT OF CLAIMS (Continued) |
|
|
(3) Approved claims and awards satisfied by payment out of a special |
appropriation made |
by the Legislature to pay |
claims arising during the fiscal year: (None). |
|
|
(4) Claims rejected by the Court with reasons therefor: |
|
|
No. Name of Claimant Name of Respondent |
Amount Claimed |
Amount Date of Awarded Determination |
CC-78-83 Adkins, Arthur, Jr. Department of Highways |
$ 202.25 |
Disallowed 3-23-79 |
CC-78-132 Akers, Sadie Jean and Department of Highways |
1,600.00 |
Disallowed 2-28-79 |
Thomas E. Akers |
|
|
CC-76-56 Arthur, Ervin, Admm. Department of Health, |
115,000.00 |
Disallowed 4-3-78 |
of the Estate of Cecil Div. of Mental Health |
|
|
C. Brumfield, dec. |
|
|
CC-78-49 Bailey, Jack D. and Department of Highways |
521.00 |
Disallowed 3-23-79 |
Betty Louise Bailey |
|
|
CC-78-1 19 Banhart, James R. Department of Highways |
190.76 |
Disallowed 1-9-79 |
CC-78-l Bolyard, Arnold W. Department of Highways |
1,377.30 |
Disallowed 6-30-79 |
CC-77-130a Boone Remodeling Co. Departments of |
1,580.00 |
Disallowed 2-10-78 |
Corrections |
|
|
CC-78-30 Bradshaw, Cynthia Lou Department of Highways |
140.76 |
Disallowed 10-11-79 |
CC-77-26 Cavalier Crushing Company Department of Highways |
32,177.50 |
Disallowed 10-24-78 |
CC-78-63 Childers, Lawrence Department of Highways |
649.20 |
Disallowed 8-10-78 |
CC-78-79 Church, Arnell Department of Highways |
198.00 |
Disallowed 8-10-78 |
CC-76-102 Clark, Elwood, Admin. State Fire Marshal |
160,827.50 |
Disallowed 2-9-78 |
of the Estate of Sharon |
|
|
Marie Clark, deceased |
||
CC-77- 114 Cooksey, Ilene Clark Department of Highways |
||
CC-76-77 Cummings, John F. Department of Highways |
||
C-78-9l DeLancey, Merton M. Department of Highways |
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with reasons theref or:
No.
CC-78-67
CC-78-225
CC-76-32
CC?77- 127
CC-78- 109
CC-78-100
CC-77-89
CC-78-205
CC-77-50
CC?77-75
CC-77- 191
C-77-2
D?1025
CC-77-123
CC-78-82
CC-77- 179
CC-77- 170
CC-77-81
Name of Claimant
Dodrill, Aileen W.
Dykes, James L.
Econo-Car International,
Evans, Charles R. &
Ernestine Evans
Evans Lumber Company
Ferguson, Lawrence &
Claudette
Flaherty, Pauline E.
Giolitto, Larry A.
Griffing, William C.
Grose, Charles W.
Gwinn, Lloyd Harding
Haddad, Nathan, Jr.
Hall, Mary Jo
Haller, Karen
Hanson, William L., Sr.
& William L. Hanson, Jr.
Heater, Robert A.
Hersom, Harold and
Eleanore Hersom
Heverley, Robert V., Jr. &
Kathleen Heverley, d/b/a
Frances Shoppe, Inc.
Name of
Respondent
Department of Highways Department of
Highways
InciJepartment of Highways Department of Banking
Department of Highways Department of Highways
Department of Finance &
Administration
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Dept. of Motor Vehicles
& Dept. of Finance &
Administration
Board of Regents
Department of Highways
Department of Highways
Department of Highways
Department of Natural
Resources
Department of Labor
tl
tJ
0
II
0
(j
LI
(12
0
Amount |
Amount |
Date of |
Claimed |
Awarded |
Determination |
227.46 |
Disallowed |
10-23-78 |
68.86 |
Disallowed |
6-30-79 |
669.75 |
Disallowed |
2-9-78 |
7,712.95 |
Disallowed |
8?10?78 |
892.27 |
Disallowed |
1-9-79 |
86.95 |
Disallowed |
4-10-79 |
646.00 |
Disallowed |
12-12-77 |
417.84 |
Disallowed |
1-9-79 |
95.88 |
Disallowed |
4-3-78 |
358.04 |
Disallowed |
11-1-77 |
517.00 |
Disallowed |
4-3-78 |
Unliquidated |
Disallowed |
4-3-78 |
50,000.00 |
Disallowed |
12-8-78 |
1,700.00 |
Disallowed |
4-10-79 |
1,000.00 |
Disallowed |
10-23-78 |
2,038.00 |
Disallowed |
5-1-78 |
444.29 |
Disallowed |
2-20-79 |
85,000.00 |
Disallowed |
1-9-79 |
REPORT
OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
CC-78-78
CC-76-79
CC-77-188
CC-78-54
CC-77-120
CC-77-85
CC-77-19
CC-77-53
CC-78-48
CC-78-144a
CC-78-144b
CC-76-33
CC?77?215b
CC-77- 173
CC-78-33
CC-76- 124
CC-78- 136
CC-77-208
CC-78-97
CC-78- 122
CC-77-69
Name of Claimant
Holstein, Lillian M.
Hoskins, Patricia S.
Keith, James G.
Kratovil, James T.
Larch, Frances J. &
William E. Larch
Lavender, John, Jr.
Lavinder, Gregory D.
Light, Daniel Lewis
Lipscomb, Gregory K.
MacKnight, James C.
MacKnight, James C.
McCarthy, Geraldine May,
Admin. of the Estate of
Robert Eugene McCarthy
May, Harold F.
Mayse, David L.
Melling, Rodger C.
Miller, Connie Lynn
Pauley, Charles Edward
Pauley, Maxine V.
Poe, Dallas
Pratt, Robert M.
Proffit, Tom and
Myrna Proff it
Name of
Respondent
Public Employees
Retirement System
Department of Highways
Department of Highways
Department of Health,
Div. of Mental Health
Department of Natural
Resources
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Amount
Claimed
Unliquidated
Amount Date of
Awarded Determination
Disallowed 7-12-78
No.
181.75
95.62
140.00
Disallowed
Disallowed
Disallowed
100,000.00 Disallowed
w
t-l
:xj
0
I.zj
Cl
Cl)
LTJ
Co
zj
0
Lxi
186.44
125.00
131.00
200.00
53.00
182.00
111,985.95
50.00
255.00
99.73
6,300.35
203.39
206.05
100.00
377.36
154.85
Department of
Highways
Board of Regents
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Highways
12-22?77
10-23-78
10-23-78
2-1?79
12?12?77
10- 17?77
12-22-77
3-23-79
6-13-79
6-13-79
5?1?78
7- 12-78
10? 11?78
8-10-78
5-1-78
10-24?78
5?1?78
10-23?78
8-10-78
10? 17?77
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
Disallowed
REPORT OF THE COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with reasons therefor:
No.
Name of Claimant
Name of Respondent
Amount Claimed
Amount Date of Awarded Determination
CC-76-47
CC-77-99
CC?77-55
CC-77-213
CC-77-33
CC?77..36
CC-77-82
CC-78-64
CC-76-80
CC-76-129
CC-77-51
CC-77-145
CC-76-120
CC-77-165
D- 1007
CC-77-215a
Quigley, Charles
C.
R. H. Bowman Distributing
Co., Inc.
Rakes, Timothy, by his
father and next friend,
Andrew Rakes, and
Andrew Rakes
Rice, Meredith K., Adm.
of the Estate of Syed
Q. Abbas, decreased
Rick?s Ambulance
Robinson, Jeanne
Sadd, Marie T.
Samples, Randall I.
Sayre, Romie C.
Sheets, Patty, Admin. of
the Estate of Ray
Samuel Six, deceased
Smith, Roy D.
Sowers, Joseph and
Marie Sowers
Stanley, Hayes
Starcher, Foster
Tinsley, Gerald E. and
Lois C. Tinsley
Toppings, Ruth Ann
U.S.A.A. Insurance Co.
Department of
Highways Department of Highways
Board of Education of Lincoln County
Department of Highways
Department of Welfare
Department of Highways
Department of Highways
Department of Highways
Department of Highways
Department of Health,
Div. of Mental Health
Department of Highways Department of Highways
Department of Highways Department of Highways
2,500.00
Disallowed
1,410.77 Disallowed
125,000.00 Disallowed
110,000.00 Disallowed
422.50 Disallowed
209.93 Disallowed
50,000.00
Disallowed
184.89 Disallowed
8-12-77
7-12-78
5-25-78
11? 1?77
10?17?77
1-9-79
7-12-78
D-875
0
?xi
0
a)
Lxi
0
.3 Lxi
|
9?27-77 |
|
898.75 |
Disallowed |
1-9-79 |
15,500.00 |
Disallowed |
5-1-78 |
600.00 |
Disallowed |
12-22-77 |
10,739.05 |
Disallowed |
10-24-78 |
533.48 |
Disallowed |
8-10-78 |
11,398.64 |
Disallowed |
4-10-79 |
Department of Highways |
462.00 |
Disallowed |
1-9-79 |
Department of Highways |
293.91 |
Disallowed |
7-12-78 |
Department of Highways |
6,000.00 |
Disallowed |
4-3-78 |
-4
?-4
?-4
REPORT OF THE
COURT OF CLAIMS (Continued)
(4) Claims rejected by the Court with
reasons therefor:
w
Amount Amount Date of tJ
No. Name of Claimant Name of Respomlent Claimed Awarded Determination
CC-77-218 Vannort, Arthur Department of Veterans? 10,500.00 Disallowed
1-9-79
Affairs & Adjutant
General
CC-77-157 Vinson, Billy Joe & 60,000.00 Disallowed 10-24-78 Paul F. Vinson
Department of Highways
D-750 W & H Contracting Co., Department of Highways 12,843.20 Disallowed
10-17-77 Inc. and Burke-ParsonsBowlby
Corp. 0
CC-77- 161 Weddington, John Thomas Department of Highways 109.55 Disallowed
7-12-78
CC-77-17 Welch, Dema Marie Department of Highways 25,000.00 Disallowed 4-3-78
t?i
CC-78-170 Winer, Chrystine Department of Highways 171.12 Disallowed 6-30-79
CC-77-140 Wotring, Bliss R. Department of Highways 2,500.00 Disallowed 7-12-78
w
REPORT OF THE COURT OF CLAIMS (Continued)
(5) Advisory determinations made at
the request of the Governor or the head of a State agency:
C)
Amount Amount Date of
No. Name of Claimant Name of Respoidenl Claimed Awarded Determination
(I)
CC-78-43 Department of Employment
Department of Health $
2,426.57 $ 1,917.17 5-25-78 Security
CC-78-2 Edward L. Nezelek, Inc. Department of Finance 439,004.92 439,004.92
1-17-78 & Administration
tTI
REPORT
OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature in the 1977 and 1979
Legislative sessions:
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded Determination
?
CC-78-232 Ailing & Cory Department of Corrections $ 4,401.40 Disallowed 1-9-79
CC-77-90 Ambrosio, Pedro N. Department of Health, 272.00 Disallowed 10-17-77
Div. of Mental Health
CC-77-148 C. H. James & Co., Div. of Department of Corrections 39.91
Disallowed 11-14-77
James Produce Co., Inc. 0
CC-77-108 Capitol Business Board of Regents 951.06 Disallowed 10-24-78
Equipment, Inc.
CC-78-283 Charleston Area Medical Department of Health 20,000.00 Disallowed
1-11-79
Center, Inc. LI
CC-77-109 County Commission of Department of Public 3,600.00 Disallowed
10-11-78
Mason County Safety
CC-77-65 Department of Highways Department of Corrections 3,040.00 Disallowed
12-8-77
CC-78-112 Eastman Kodak Co. Secretary of State 275.00 Disallowed 8-10-78 0
CC-77-35 Graves-Humphreys, Inc. Department of Corrections 1,604.99 Disallowed
8-8-77
CC-78-277 IBM Corporation Department of Corrections 3,962.30 Disallowed 1-31-79
CC-77-104 Pfizer Corporation, Department of Health, 608.00 Disallowed 12-8-77
Roerig Division Div. of Mental Health
CC-77-76 Physicians Fee Office Department of Health, $2,145.23 Disallowed
10-17-77
Div. of Mental Health
CC-78-74 Physicians Fee Office Department of Corrections 2,956.50 Disallowed
8-10-78
CC-78-174 Smith, R. L., d/b/a Department of Public 879.91 Disallowed 10-24-78
Architectural Associates Safety
CC-78-127 Texaco, Inc. Secretary of State 33.09 Disallowed 8-10-78
CC-79-77 3M Company Department of Motor 3,000.00 Disallowed 6-30-79
Vehicles
REPORT
OF THE COURT OF CLAIMS (Continued)
(6) Claims rejected by the Court but
payments made by special appropriations by the Legislature in the 1977 and 1979
Legislative sessions:
(I
Amount Amount Date of
No. Name of Claimant Name of Respondent Claimed Awarded
Determinalion
Cj2
CC-77-172 W. Va. Public Employees
Department of Motor 5,563.68 Disallowed 2-9-78
Insurance Board Vehicles LJ
(7) Approved claims and awards satisfied by payment by the State agency through
an opinion decided by the Court under the Shortened Procedure: (None).
OPINIONS
TABLE OF CASES
REPORTED LIII
TABLE
OF CASES REPORTED
Abbot Laboratories v. Board of Regents
321
Ace Glass, Inc. v. Board of Regents 321
Adkins, Arthur, Jr. v. Department of Highways 316
Adkins, William J., Dorothy Marie Adkins, Armilda
Wiley, and Dorothy Marie Adkins, as next friend of
Mary Jane Adkins & Peggy Joyce Adkins v.
Department of Highways 185
Air Products and Chemicals, Inc. v. Board of Regents 321
Akers, Sadie Jean and Thomas E. Akers v.
Department of Highways 315
Alert Sanitation v. Office of the Governor?
Emergency Flood Disaster Relief 76
Alford, Elvin S. v. Department of Highways 14
Alling & Cory v. Department of Corrections 235
Allison, Curtis v. Department of Highways 84
Alvis, David E. v. Department of Highways 47
Ambrosio, Pedro N. v. Department of Health,
Div. of Mental Health 15
American Hospital Supply v. Department of Health 278
Appalachian Power Co. v. Department of Highways 1
Arthritis Care Associates v. Division of
Vocational Rehabilitation 85
Arthur, Ervin, Admin. of the Estate of Cecil C.
Brumfield, dec. v. Department of Health,
Div. of Mental Health 124
Bailey, Jack D. and Betty Louise Bailey v.
Department of Highways 317
Baker, Carl L., Jr. v. Department of Health 277
Banhart, James R. v. Department of Highways 236
Barfield, Gladys v. Office of the Governor?
Emergency Flood Disaster Relief 237
Barr, Frank G. v. Department of Highways 65
Bastin, Olie G. and Priscilla Bastin v.
Department of Highways 86
Bayliss, Wayne v. Department of Highways 279
Belmont, Raymond N. v. Department of Highways 57
Bernhardt?s Clothing, Inc. v. Department of Corrections 238
Black Rock Contracting, Inc. v. Department of Highways 324
Bolyard, Arnold W. v. Department of Highways 344
LIV TABLE OF
CASES REPORTED
Bondurant, Donald M. v. State Tax Department 24
Boone Remodeling Co. v. Department of Corrections
(CC-77-130a) 89
Boone Remodeling Co. v. Department of Corrections
(CC-77-130b) 89
Boone Remodeling Co. v. Department of Corrections
(CC-77-130c) 89
Boone Remodeling Co. v. Department of Corrections
(CC-77-130d) 89
Boone Remodeling Co. v. Department of Corrections
(CC-77-130e) 89
Boone Sales, Inc. v. Department of Highways 92
Bowman, Charles A. v. Department of Highways 66
Bradshaw, Cynthia Lou v. Department of Highways 187
Brown, Minnie Lee v. Department of Highways 125
Bubar, Jeffrey D. v. Department of Highways 204
Buckner, Darrell E. & Betty S. Buckner v.
Department of Highways 41
C. H. James & Co., Div. of James Produce Co., Inc. v.
Department of Corrections 30
C & P Telephone Co. of West Virginia v. Department of
Highways (CC-76-132) 194
C & P Telephone Co. of West Virginia v. Department of
Highways (CC-77-71) 239
C & P Telephone Co. of West Virginia v. Department of
Natural Resources (CC-78-105) 164
C & P Telephone Co. of West Virginia v. Board of
Regents (CC-78-152) 240
Capitol Business Equipment, Inc. v. Board of Regents 205
Capitol Business Interiors, Div. of Capitol Business
Equipment, Inc. v. Department of Finance &
Administration 338
Cavalier Crushing Company v. Department of Highways 206
Cecil E. Jackson Equipment, Inc. v.
Department of Corrections 58
Central State Resources, Inc. v. Board of Regents 289
Charbeneau, Eleanor F. and Eleanor B. v.
Department of Highways 67
Charleston Area Medical Center, Inc. v.
Department of Health 272
TABLE OF CASES
REPORTED LV
Childers, Lawrence v. Department of Highways 346
Church, Arnell v. Department of Highways 165
Circuit Clerk of Kanawha County, West Virginia v.
State Auditor of West Virginia 56
Clark, Elwood, Admin. of the Estate of Sharon Marie
Clark, deceased v. State Fire Marshal 77
Claywood Park Public Service District v.
Department of Highways 194
Clemente, Sandra S. v. Department of Motor Vehicles 48
Clendenin Lumber & Supply Company v. Department of
Health, Div. of Mental Health 119
Climate Makers of Charleston, Inc. v. Board of Regents 166
Clinic Private Division, University of Virginia v.
Division of Vocational Rehabilitation 347
Coen, Michael H. and Ruth Coen v.
Department of Highways 119
Collins, Ishmael v. Department of Highways 31
Cook, Virginia Sue v. Department of Highways 58
Cooksey, Ilene Clark v. Department of Highways 195
Cooper, Richard L. v. Department of Natural Resources 93
Cosner, Stanley N. v. Department of Highways 240
Cottle, B. H. and B. H. Cottle, Executor of the Estate
of Lucy M. Cottle, deceased v. Department of Highways 167
County Commission of Mason County (The) v.
Department of Public Safety 188
Crocker-Fells Company (The) v. Board of Regents 321
Cummings, Clyde W. & Betty L. Cummings v.
Department of Highways 41
Cummings, John F. v. Department of Highways 59
Cunningham, Richard L. v. Department of Public Safety 241
Curnutte, James H., Jr. & Deborah L. Curnutte v.
Department of Highways 290
Curry, H. M. v. Department of Health 277
Custer, George M. v. Department of Motor Vehicles 48
Cutter Laboratories, Inc. v. Board of Regents 321
Dalessio, Lillian v. Board of Regents 242
Davis, Billy Joe v. Department of Highways 31
Davis, Frank and Billy Joe Davis, d/b/a Davis Auto
Parts v. Department of Highways 31
Davis Memorial Hospital v. Department of Corrections 244
LVI TABLE OF
CASES REPORTED
DeLancey, Merton M. v. Department of
Highways 245
Department of Employment Security v.
Department of Health 146
Department of Highways v. Department of
Public Institutions 43
DeWeese, Icy Mae v. Division of
Vocational Rehabilitation 222
Diagnostic Isotopes, Inc. v. Board of Regents 321
Dill?s Mountaineer Associates, Inc. v.
Department of Health 348
Direct Mail Service Co. v. Board of Regents 49
Dodrill, Aileen W. v. Department of Highways 196
Dykes, James L. v. Department of Highways 349
Eastman Kodak Co. v. Secretary of State 167
Econo-Car International v. Department of Highways 80
Edward L. Nezelek, Inc. v. Department of Finance and Administration &
Department of Health 74
Ehrenreich Photo-Optical md. Inc. v. Board of Regents 321 Eisenberg, Jacquelyn
B., Parent and next friend of Mark Harold Eisenberg, an infant v. Board of
Regents 273
Engegno, Ethel v. Division of Vocational Rehabilitation 222
Evans, Charles R. & Ernestine Evans v.
Department of Banking 168
Evans Lumber Company v. Department of Highways 246
Fairmont Supply Company v. Board of Regents 321
Fentress, Albert D. and Hazel S. Fentress v.
Department of Highways 94
Ferguson, Lawrence & Claudette v. Department
of Highways 326
Fields, Rush v. Department of Highways 149
Flaherty, Pauline E. v. Department of Finance
and Administration 50
Frazier, Bradford G. v. Department of Highways 69
Fredlock, A. M., II v. Department of Highways 197
Friden Mailing Equipment Corporation v.
Department of Corrections 95
Fury, Rondal v. Division of Vocational Rehabilitation 222
Garrett, Joseph Larry v. Department of Public Safety - 247 Gillispie, Teresa K. & Johnny Wayne Gillispie
v.
TABLE OF CASES
REPORTED LVII
Department of Highways 248
Giolitto, Larry A. v. Department of Highways 249
Gore, Charles R. v. Department of Highways 172
Gott, Peggy S. v. Department of Health,
Div. of Mental Health 95
Graves-Humphreys, Inc. v. Department of
Public Institutions 1
Greenlee, Drema D. & Stephen E. Greenlee v.
Department of Highways 338
Griffing, William C. v. Department of Highways 127
Grimmett, Timothy J. v. Department of Highways -- 51
Grose, Charles W. v. Department of Highways 25
Guyan Transfer and Sanitation, Inc. v. Department of
Finance & Administration 20
Gwinn, Lloyd Harding v. Department of Highways 128
Haddad, Nathan, Jr. v. Department of Motor Vehicles
and Department of Finance & Administration 130
Hall, Mary Jo v. Board of Regents 232
Haller, Karen v. Department of Highways 327
Halliburton Services v. Department of Highways 281
Hamilton, Linda E. v. Department of Highways 282
Haney, Douglas v. Department of Highways 250
Hanson, William L., Sr. and William L. Hanson, Jr. v.
Department of Highways 197
Hart, Michael J. v. Department of Highways 52
Hartford Accident & Indemnity Company v.
Department of Highways 31
Hastings, Robert M. & Linda, d/b/a Hastings Stables v.
Department of Highways 44
Haynes, Howard A. v. Department of Highways 283
Heater, Arnold G. & Geraldine Heater v.
Department of Highways 310
Heater, Robert A. v. Department of Highways 137
Heck?s Inc. v. Division of Vocational Rehabilitation 339
Henry Elden & Associates v. Department of
Natural Resources (CC-77-190) 189
Henry Elden & Associates v. Department of Finance &
Administration and Department of Health (CC-78-269) -- 275
Herron, Ora T. v. Department of Public Safety 284
LVIII TABLE OF
CASES REPORTED
Hersom, Harold and Eleanore Hersom v.
Department
of Natural Resources 312
Heverley, Robert V., Jr. & Kathleen Heverley, d/b/a
Frances Shoppe, Inc. v. Department of Labor 251
Hills, H. M., Jr. & Luis A. Loimil v.
Department of Public Safety 70
Hogan Storage & Transfer Company v. Department of
Agriculture and Department of Health 96
Holstein, Lillian M. v. Public Employees
Retirement System 151
Hoskins, Patricia S. v. Department of Highways 60
Hubbard Pump Co. v. Board of Regents 321
Hubbs, Kermit Reed v. Department of Highways 39
Hudnall, McHenry, Jr. v. Department of Highways 26
Hunter, Alvin 0. v. Department of Highways 198
IBM Corporation v. Department of Motor Vehicles
(CC-77-1) 2
IBM Corporation v. Department of Corrections
(CC-78-277) 284
Jarrell, R. L. v. Department of Highways 319
Johnson, Robert H. v. Department of Highways 98
Jones Printing Company, Inc. v. Governor?s Office of
Economic and Community Development 99
Kanawha Valley Radiologists, Inc. v. Division of
Vocational Rehabilitation 100
Keeling, Ralph v. Division of Vocational Rehabilitation 222
Keith, James G. v. Department of Highways 199
Keyser, Peggy v. Department of Highways 199
King, Forest Joe, et al. v. Department of Highways 208
Korthals, Theodore & Emile Korthals v.
Department of Highways 53
Kratovil, James T. v. Department of Health,
Div. of Mental Health 200
Lafferty, Eugene and Wanda Lafferty v.
Department of Highways 100
Lambert, Thomas F. v. Department of Welfare 101
Larch, Frances J. & William E. Larch v.
Department of Natural Resources 291
TABLE OF CASES
REPORTED LVIX
Lavender, John, Jr. v. Department of
Highways 54
Lavinder, Gregory D. v. Department of Highways 16
Leach, Paul v. Division of Vocational Rehabilitation 222
Lester, Linda and Leon Lester v.
Department of Highways 102
Light, Daniel Lewis v. Department of Highways 61
Light Gallery and Supply Co. v. Board of Regents 321
Lilly, Herman F. v. Department of Highways 153
Lipscomb, Gregory K. v. Department of Highways 322
Lively, Debris J. v. Department of Highways 153
Long, Charles P. v. Department of Highways 173
Lucas, Harry Glenn, Jr. v. Department of
Public Safety 253
Lynch, Gerald J. v. Department of Highways 103
MacKnight, James C. v. Department of Highways
(CC-78-144a) 340
MacKnight, James C. v. Department of Highways
(CC-78-144b) 341
McCarthy, Geraldine May, Admin. of the Estate of Robert
Eugene McCarthy v. Department of Highways 139
McCloy Construction Company, Inc. v.
Department of Natural Resources 312
McIntyre, Rhoda Raynett v. Department of Highways - 213
Mahaffee, Harold v. Department of Highways 211
Marcum, Alice v. Department of Natural Resources 211
Massie, Robert L. and Mae Massie v. Office of the
Governor??Emergency Flood Disaster Relief 82
Maxey, Lowell J. v. Department of Public Safety 254
May, Harold F. v. Department of Highways 159
Mayfield, Hugh C. v. Department of Highways 55
Maynard, Arthur & Mollie Maynard v.
Department of Highways 4
Maynard, Norman & Shirley Maynard v.
Department of Highways 4
Mayse, David L. v. Board of Regents 191
Melling, Rodger C. v. Department of Highways 174
Memorial General Hospital v. Department of Corrections - 313
Metz, Lewis Dale v. Department of Corrections 342
Miller, Connie Lynn v. Department of Highways 140
LX TABLE OF
CASES REPORTED
Moore Business Forms, Inc. v.
Department of
Motor Vehicles (CC-78-23) 104
Moore Business Forms, Inc. v. Department of
Health, Div. of Mental Health (CC-78-46) 214
Morrison Printing Co., Inc. v. Department of Highways 142
Nationwide Insurance Co., Subrogee of Phillip W.
Alexander v. Department of Highways 350
New Martinsville/Wetzel County Emergency Squad,
Inc. v. Division of Vocational Rehabilitation 105
Norvell, Helen L., Exec. of the Estate of Glenn Hartsel
Norvell, dec. v. Department of Highways 106
Offutt, Arizona M. v. Department of Highways 107
Orkin Exterminating, Inc. v. Department of Health,
Div. of Mental Health 215
Ostrin Electric Co. v. Department of Natural Resources -- 293 Otis Elevator Company v. Department of Health,
Div. of Mental Health 108
Parker, Ralph v. Division of Vocational Rehabilitation 222
Patrick Plaza Dodge, Inc. v. Office of the Treasurer 255
Pauley, Charles Edward v. Department of Highways 215
Pauley, Maxine V. v. Department of Highways 143
Petts, Elva v. Division of Vocational Rehabilitation 222
Pfizer Corporation, Roerig Division v. Department of
Health, Div. of Mental Health 45
Phillips, Anna Jane v. Department of Highways 62
Physicians Fee Office v. Department of Health, Div.
of Mental Health (CC-77-76) 17
Physicians Fee Office v. Department of
Corrections (CC-78-74) 175
Poe, Dallas v. Department of Highways 201
Polis Brothers v. Department of Health,
Div. of Mental Health 109
Positive Peer Culture, Inc. v. Department of Corrections - 285
Pratt, Robert M. v. Department of Highways 176
Preston, Gertrude v. Division of Vocational
Rehabilitation 222
Preston, James v. Division of Vocational Rehabilitation -- 222 Private Diagnostic Clinic v. Division of
Vocational Rehabilitation 144
TABLE OF CASES
REPORTED LXI
Proffit, Tom and Myrna Proffit v.
Department of Highways 18
Quigley, Charles v. Department of Highways 5
R. H. Bowman Distributing Co., Inc. v.
Department of Highways 156
Rader, Jack L. v. Department of Health 277
Rakes, Timothy by his father and next friend, Andrew
Rakes, and Andrew Rakes v. Board of Education
of Lincoln County 147
Raleigh Motor Sales, Inc. v. Department of
Natural Resources 26
Ray, Alex v. Office of the Governor?
Emergency Flood Disaster Relief 83
Rexrode, Jerry Austin v. Department of
Natural Resources 110
Rice, Meredith, K., Admin. of the Estate of Syed Q.
Abbas, deceased v. Department of Highways
12
Rick?s Ambulance v. Department of Welfare 255
Robinson, Jeanne v. Department of Highways 145
Roche Laboratories, Inc. v. Board of Regents 321
Rosi, Anthony R. v. Department of Motor Vehicles 110
Ross, Franklin and Elsie M. Ross v.
Department of Highways 111
Roton, Larry v. Department of Highways 256
Russell, Mae v. Department of Highways 177
Ryan, James and Joyce Ryan v. Department of Highways 329
S. B. Wallace & Co. v. Department of Corrections 62
Sadd, Marie T. v. Department of Highways 63
Samples, Randall I. v. Department of Highways 217
Sanders Floor Covering, Inc. v. Board of Regents 71
Sayre, Romie C. v. Department of Highways 178
Schooley, Charles E. v. Department of Highways 28
Shah, Saleem A. and Theresa A. Shah v.
Department of Highways 115
Sharp, Mary Jo v. Department of Health,
Div. of Mental Health 112
Sheets, Patty, Admin. of the Estate of Ray Samuel Six,
deceased v. Department of Health,
Div. of Mental Health -
- 332
LXII TABLE OF
CASES REPORTED
Sherwood, Carolyn Crisp v. Department
of Highways 104
Shreve, Mary J0 v. Department of Highways 7
Siclair, Sam, d/b/a Galion Canvas Products Company
v. Governor?s Office of Economic & Community
Development 19
Skaggs, Lawrence Craig v. Department of Highways 3
Smith, Larry Keith v. Department of Highways 351
Smith, R. L., d/b/a Architectural Associates v.
Department of Public Safety 218
Smith, Robert & Elizabeth Smith v.
Department of Highways 287
Smith, Roy D. v. Department of Highways 29
Sowers, Joseph and Marie Sowers v.
Department of Highways 21
Spagnuolo, A. A. v. Department of Highways 180
Spangler, Odlund Haney, Jr. v. Department of
Employment Security 148
Spitzer, Barbara H. v. Department of Highways 314
Spradling, Charles H., Jr. v. Department of Highways 336
Stanley, Hayes v. Department of Highways 258
Starcher, Foster v. Department of Highways 157
State Chemical Manufacturing Co. v.
Department of Highways 8
State Farm Mutual Auto Insurance Co., subrogee of
Dana Lee Selvig v. Board of Regents 288
Stevens, Polly, Guardian of the Estate of James Walter
Stevens and Timothy Stevens v. Department
of Highways 180
Stone, Connie Ann v. Department of Highways 259
Stone, Thelma J. v. Office of the Governor?
Emergency Flood Disaster Relief 202
Stuart?s Drug & Surgical Supply Co. v.
Board of Regents 321
Syva, Inc. v. Board of Regents 321
Taylor, Charles E. & Mary P. Taylor v.
Department of Highways 261
Teets, Willard P., Attorney in Fact for Percy E. Teets
v. Department of Highways 203
Testa, Fred K. and Claudia I. Testa, v.
Department of Highways 115
TABLE OF CASES
REPORTED LXIII
Texaco, Inc. v. Secretary of State 184
Thompson, Edith Ann & Roger Dale Thompson v.
Department of Natural Resources 132
Thompson?s of Morgantown, Inc. v.
Board of Regents 72
3M Business Products Sales, Inc. v.
Department of Motor Vehicles 118
3M Company v. Department of Motor Vehicles 352
Tillinghast, John & Janet Tillinghast v.
Department of Highways 159
Tinsley, Gerald E. and Lois C. Tinsley v.
Department of Highways 134
Toppings, Ruth Ann v. Department of Highways 261
Transport Motor Express, Inc. v.
Public Service Commission 192
Travenol Laboratories, Inc. v. Department of Health,
Div. of Mental Health 64
Tyre, Albert K. v. Department of Corrections 263
U.S.A.A. Insurance Co. v. Department of Highways 159
Uarco, Inc. v. Board of Regents 150
Vannort, Arthur v. Department of Veterans? Affairs
& Adjutant General 267
Vecellio & Grogan, Inc. v. Department of Highways 294
Vinson, Billy Joe & Paul F. Vinson v.
Department of Highways 219
W & H Contracting Co., Inc. and The Burke-Parsons Bowlb Corp. v. Department
of Highways 22
Ware, Todd W. and Taylor Publishing Co. v.
Board of Regents 269
Warren Associates v. Board of Regents 321
Webb, W. F. v. Department of Highways - - -- 204
Weber, Harold L., Jr. v. Department of Health 323
Weber, John M. v. Board of Regents 270
Weddington, John Thomas v. Department of Highways 161
Weekly, Richard L. v. Office of Emergency
Services (CC-77-219 a & b) - 123
Welch, Dema Marie v. Department of Highways 136
Welch, Marvin Roy v. Department of Highways - - - 73
LXIV TABLE OF? CASES REPORTED
Wells, Harry v. Division of Vocational
Rehabilitation 222
West, Patrick v. Department of Highways 193
W. Va. Public Employees Insurance Board v.
Department of Motor Vehicles 84
White, Arthur v. Division of Vocational Rehabilitation 222
White, Loraine & Velma White v.
Department of Highways 271
Whitmyer Brothers, Inc. v. Department of Highways 9
Wiersma, Silas C. v. Department of Health,
Div. of Mental Health 234
Wilder, John R. and Norma J. Wilder v.
Department of Highways 24
Wilson, Patricia, George P. Wilson, and
Gladys V. Wilson v. Office of the Governor?
Emergency Flood Disaster Relief 309
Winer, Chrystine v. Department of Highways 353
Wood County Bank v. Department of Motor Vehicles 276
Wotring, Bliss R. v. Department of Highways 162
Cases
Submitted and Determined
in the Court of Claims in the
State of West Virginia
Opinion issued August 8, 1977
APPALACHIAN POWER COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-66)
Charles W. Peoples, Jr., Attorney at Law, for the claimant. Nancy J.
Norman, Attorney at Law, for the respondent.
PER CURIAM:
Upon the stipulation of the parties to the effect that on February 28, 1975,
blasting operations conducted by the respondent near Madison Creek Road in
Cabell County, West Virginia, caused damage in the sum of $2,303.35 to the
claimant?s electrical distribution line and related electrical equipment, an
award in that sum should be, and is hereby, made.
Award of $2,303.35.
Opinion issued August 8, 1977
GRAVES-HUMPHREYS, INC.
vs.
DEPARTMENT OF PUBLIC INSTITUTIONS
(No. CC-77-35)
Louie A. Paterno, Jr., Attorney at Law, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
RULEY, JUDGE:
Beginning in March, 1975, and ending in August, 1975, and pursuant to
respondent?s purchase order, claimant delivered to
2 REPORTS
STATE COURT OF CLAIMS [W. VA.
the Huttonsville Correctional Center a
lathe and various accessory equipment for a purchase price of $1,604.99. The
respondent, by its counsel, has admitted that the purchase order was placed
with the claimant and that the materials covered by it were received by the
respondent. The only reason for non-payment was an insufficiency of funds
appropriated in the pertinent fiscal year. Following the precedent of Airkem Sales and Service, et al. v. Department of
Mental Health, 8 Ct. Cl. 180 (1971),
it is apparent that the claim must be denied.
Claim disallowed.
Opinion issued August 8, 1977
IBM CORPORATION
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-77-1)
Thomas R. Bradley, Operations Analyst, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
RULEY, JUDGE:
The claimant and the respondent entered into a written contract entitled
?Extended Term Lease Plan?, dated November 5, 1976, relating to a ?word
processing? unit composed of magnetic card typewriters and other machines. This
claim subsequently was made for a transportation charge in the sum of $123.65
relating to typewriters, and a transportation charge in the sum of $115.57
relating to a copier. The copier was returned shortly after its delivery to the
respondent, and from the evidence, it is apparent that there never was a
meeting of minds between the parties as to whether the copier was or was not a
part of the word processing unit. For that reason, the Court is of the opinion
to deny the claim for the transportation charge related to the copier, and to
allow the claim for the
4 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued August 12, 1977
NORMAN MAYNARD & SHIRLEY MAYNARD
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-71a)
and
ARTHUR MAYNARD & MOLLIE MAYNARD
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-71b)
Larry D. Taylor, Attorney at Law, for the claimants.
Nancy J. Norman, Attorney at Law, for the respondent. WALLACE, JUDGE:
The above two claims grew out of the same land slippage. The respondent having
admitted liability, the claims were consolidated and heard by the Court as to
the issue of damages.
The parties filed with the Court their written stipulations indicating that the
claimants, Arthur Maynard and Mollie Maynard, are the owners of a 30-acre tract
of land south of Wayne, West Virginia, fronting 2000 feet on Ferguson Branch
Road, which is Local Service Road 52/21 maintained by the respondent. It is a
dirt and gravel base road. The claimants, Norman Maynard and Shirley Maynard,
are the son and daughter-in-law of the Arthur Maynards. Their home is located
on a parcel of land acquired from his parents, and fronts 200 feet on Local
Service Road 52/21. It was further stipulated that the respondent maintained a
drainage ditch parallel with the road across the road from claimants? property.
Pipes were placed under the road to drain water from the drainage ditch. One of
these pipes was installed under the road in front of the claimants? properties.
In April and May of 1975, the drainpipe became stopped up, causing surface
water to drain across the road onto the claimants? properties. The claimants
notified the respondent, but no action was taken until a land slippage
developed in an area between the homes of the claimants.
W. VA.) REPORTS STATE
COURT OF CLAIMS 3
transportation charge related to the typewriters, inasmuch as there is
provision for the same in the contract.
Award of $123.65.
Opinion issued August 8, 1977
LAWRENCE CRAIG SKAGGS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-56)
Lawrence Craig Skaggs, the claimant, in person.
Nancy J. Norman, Attorney at Law, for the respondent. PER CURIAM:
Upon the stipulation of the parties to the effect that on February 26, 1977,
the claimant?s 1972 model Mercury automobile struck a metal plate that had
become dislodged from a hole which it covered on W.Va.-U.S. Route 60 in Kanawha
County, West Virginia; and that the claimant thereby sustained damage to his
automobile in the sum of $102.23; an award in that sum should be, and is
hereby, made.
Award of $102.23.
W. VA.] REPORTS
STATE COURT OF CLAIMS 5
The respondent corrected the drainage problem. Neither residence was damaged.
Expert witnesses on behalf of the claimants and the respondent submitted
appraisals of the properties showing the values before and after the slippage.
The Court, having considered the stipulations in both cases, photographs of the
respective properties, and the record as it pertains to damages, assesses
damages as follows: to Arthur Maynard and Mollie Maynard, $2,475.00, &nd to
Norman Maynard and Shirley Maynard, $1,250.00.
Award of $2,475.00 to Arthur and Mollie Maynard.
Award of $1,250.00 to Norman and Shirley Maynard.
Opinion issued August 12, 1977
CHARLES C. QUIGLEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-47)
Claimant appeared in person.
Nancy Loar, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant was driving alone in his 1973 Caprice automobile the night of April
30, 1974, at approximately 9:40 p.m. in Charleston, West Virginia. It was
raining and the streets were wet. He was proceeding from his home at Campbells
Creek on U.S. Rt. 60 to his job in Parkersburg, West Virginia. His usual route
was over Piedmont Road, crossing the Spring Street Bridge and entering
Interstate 77 at the Westmoreland approach. On the night of the accident, due
to construction, he proceeded westerly on Kanawha Boulevard intending to go
from there to Pennsylvania Avenue. He turned off Kanawha Boulevard in a
northerly direction onto relocated Columbia Avenue, which is a one-way street
going north. For several blocks north of Kanawha Boulevard, Columbia Avenue
6 REPORTS STATE
COURT OF CLAIMS [W. VA.
was a construction area in connection with its relocation and work on adjacent
interstate bridge approaches. The claimant testified that he followed another
car along the Avenue, crossing the intersections of Virginia Street and
Randolph Street. After crossing Randolph Street, the car in front stopped and
turned around because the road was blocked by a crane and construction material.
The claimant was also forced to turn around. As he retraced his course, he
re-entered, without stopping, the intersection of Randolph Street. As he drove
into the intersection he was struck by an automobile coming from the east. The
claimant contends that there were no signs or signals to warn of the danger.
The claimant testified that the owner of the car that struck him threatened to
sue for damages, and to avoid litigation, he settled for $716.00. He further
stated that repairs to his car amounted to $1,200.00, that he lost two weeks?
work, and that he incurred medical expenses of $150.00 as the result of two or
three broken ribs. No documentary proof of these damages was introduced,
although the claimant was allowed additional time to supply the Court with the
same.
Larry Allen Deitz, Project Engineer for the respondent, testified that, during
the construction of the road, there were barricades and signs which were
removed in December, 1974. He stated that the signs and barricades were moved
from time to time for the movement of equipment, but that Columbia Avenue was
not kept open because of various materials and equipment.
Danny Lee Lucas, an inspector for the Department of Highways, testified that in
April, 1974, there were ?Street Closed? signs on Columbia Avenue at its
intersection with the Kanawha Boulevard, but there was ample room for a vehicle
to go around. On Randolph Street there were ?Construction Ahead? signs and
amber flasher lights mounted on 55-gallon drums to warn of the construction. He
also stated that the signs and barricades were so placed as to allow people who
lived in the construction area a means of ingress and egress.
Willis J. Cox, the Superintendent of Construction for Bates and Rogers
Construction Corporation, testified that he super-
W. VA.] REPORTS
STATE COURT OF CLAIMS 7
vised the construction job from about 50 feet north of Kanawha Boulevard
northerly to Washington Street. He stated that at the time of the accident,
Columbia Avenue was paved, but there were barricades and signs which stated
either ?Street Closed? or ?Road Closed?, which signs remained until the road
was opened for traffic. He further testified that, although equipment was
parked on the Avenue, a portion was left open to allow local residents to come
and go. Also, a fire lane was required to be left open in case of fire.
The Court finds that the record does not indicate any negligence on the part of
the respondent that would warrant a recovery for the claimant. The record
establishes that the claimant was driving in a construction area over an avenue
that was closed to the public. The claimant testified that there were several
factors that prevented him from knowing he was crossing the intersection;
namely, it was raining, he was following another car, and he wasn?t looking. It
is apparent from the record that the claimant?s negligence was the cause of the
accident.
Accordingly, the Court hereby disallows the claim. Claim disallowed.
Opinion issued August 19, 1977
MARY JO SHREVE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-70)
Claimant appeared in person.
James W. Wit hrow, Attorney at Law, for respondent. PER CURIAM:
The written stipulation of the parties reveals that in July of 1976, the
respondent, through its Equipment Division, spray painted its building located
at 101 Kerns Avenue in Elkins; that in so doing, the claimant?s automobile was
damaged be-
8 REPORTS STATE
COURT OF CLAIMS [W. VA.
cause of an over-spray, and that the claimant?s automobile was damaged to the
extent of $100.00. Believing that liability exists and that the claimed damages
are reasonable, the Court hereby makes an award in favor of the claimant in the
amount of $100.00.
Award of $100.00.
Opinion issued August 19, 1977
STATE CHEMICAL MANUFACTURING CO.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?77-79)
Claimant appeared by Dave Carpenter, its Territorial Manager.
Stuart Reed Waters, Jr., Attorney at Law, for the respondent. PER CURIAM:
The written stipulation of the parties reveals that in January of 1977,
respondent purchased from claimant 80,000 pounds of glycol treated urea for use
in its ice control program. A price of 19 cents per pound for that quantity was
agreed upon with the further understanding that claimant would also, free of
charge, deliver 110 gallons of liquid ice chek activator. An emergency purchase
order was thereupon issued for the above. Respondent thereafter decided to
reduce the order in respect to the amount of glycol treated urea. It thereupon
voided the original emergency purchase order and issued a new order without
negotiating a new price per pound for the redueed order of glycol treated urea.
Ultimately, 39,000 pounds of glycol treated urea and 110 gallons of liquid ice
chek activator were delivered by claimant to respondent, and claimant billed respondent
22 cents per pound for the glycol treated urea in lieu of the 19 cents per
pound as originally agreed upon, and $1,237.50 for the 110 gallons of liquid
ice chek activator. The respondent, in the stipulation, admits that it was
improper for it to unilaterally
W. VA.] REPORTS
STATE COURT OF CLAIMS 9
reduce the quantity of glycol treated urea ordered without renegotiating the
price, and that the claimant is entitled to additional compensation in the
amount of $2,217.50.
Being of opinion that the stipulation sets forth a fair and equitable
resolution of this dispute, the Court hereby makes an award to the claimant in
the above-stated amount.
Award of $2,217.50.
Opinion issued September 26, 1977
WHITMYER BROTHERS, INC.
vs.
DEPARTMENT OF HIGHWAYS
(No. D-571)
James K. Stewart, Attorney at Law, for the claimant.
Dewey B. Jones and Stuart
Reed Waters, Jr., Attorneys at Law,
for the respondent.
RULEY, JUDGE:
This case involves a claim for damages in the sum of $450,000.00 growing out of
performance of a contract requiring the claimant to construct approximately
190,000 linear feet of fence along the right of way of Interstate Route 64 in
Kanawha, Cabell, Putnam, and Wayne Counties. Several items of the claim were
eliminated by the Order heretofore entered on September 1, 1976, sustaining the
respondent?s motion to dismiss. Subsequently, the case was tried insofar as it
related to the remaining items of the claim, viz.: (1) a claim for labor and
material allegedly furnished incident to providing extra terminal posts; and
(2) a claim for relief from liquidated damages asserted by the respondent.
To facilitate understanding of the claim relating to extra terminal posts, it
must be understood that all fence posts may be classified as line posts (which
require no bracing member) or as terminal posts (which require at least one
bracing
10 REPORTS STATE
COURT OF CLAIMS [W. VA.
member). Terminal posts may be sub-classified as end posts (which require one
bracing member), pull posts (which require two bracing members), or corner
posts (which require two bracing members). All terminal posts and their bracing
members were required to be set in concrete and were larger and heavier than
line posts, the purpose of the latter being only to support the fence between
the terminal posts. The importance of the distinctions insofar as cost is
concerned is apparent without further explanation.
The respondent?s plans and drawings, which were incorporated into the contract,
showed 854 terminal posts. The claimant?s bid was based on a projected
installation of 925 terminal posts, the increase representing an allowance for
additional terminal posts at points where either the horizontal or vertical
angle of the fence was 15? or more. In that connection, the preponderance of
the evidence clearly established the trade practice or custom of not installing
terminal posts at points where an angle in a fence is less than 15?. Based on
the calculation of 925 terminal posts, the claimant?s successful unit price bid
was $1.79 per linear foot of fence ? one
cent lower than the respondent?s estimate of $1.80. As the fence was
constructed, the respondent required the claimant to install 1,927 terminal
posts.
The contract specifications in the last two paragraphs of ?2.131.3 (F),
apparently intending to relate to line posts and terminal posts, respectively,
provided:
?Posts shall be spaced in the line of fence as shown on the plans with
tolerances of minus two (?2) feet. Spacing of post shall be as uniform as
practicable under local conditions. Additional posts shall be set at each
abrupt change in grade.
Pull posts, as defined in these specifications, shall be placed approximately
three hundred thirty (330) feet apart in straight runs and at each vertical
angle point, all as directed by the engineer. Corner posts shall be placed at
each horizontal angle point.?
The patent inconsistency and ambiguity of these provisions (which literally
would require both a line post and a pull post
W. VA.1 REPORTS
STATE COURT OF CLAIMS 11
at each vertical angle point) must be construed and resolved in the light of
the proven trade practice and custom and common sense. Raleigh Lumber Co. v. Wilson & Son, 69 W.Va. 598, 72 S.E. 651 (1911); Bragg v. Lumber Co., 102 W.Va. 587, 135 S.E. 841 (1926). In addition, broad
delegations of power must be exercised in a reasonable manner under the
particular circumstances of each case, and not in an arbitrary or capricious
manner. Tn-State Stone Corp. v. The
State Road Commission of West Virginia, 9
W.Va. Ct. Cl. 90, at 106 (1972). The evidence demonstrates that the claimant
was required to install 641 terminal posts at horizontal or vertical angle
points of less than 15?, with the vast majority at angles of less than 10? and
a very substantial number at angles under 5? ? none of these were points where end posts or maximum spacing terminals
were necessary. From a preponderance of the evidence, it appears that those 641
terminal posts were unnecessary (that is, that line posts would have served
just as well), and that their requirement was arbitrary. The undisputed
evidence is that the additional cost to the claimant, above the cost of a line
post, of each terminal post was $131.33. Accordingly, it appears that the
claimant should be awarded the sum of $84,182.53 for extra terminal posts.
Turning to the matter of liquidated damages, it appears that the respondent
assessed and imposed (withholding the sum from the claimant?s final payment)
$25.900.00 in liquidated damages calculated pursuant to the contractual formula
at the rate of $100.00 per day for 259 days of alleged delay in performance of
the contract. It is undisputed that the claimant failed to complete its work
under the contract until 286 days after the contract completion date. The
respondent granted an extension time of 27 days, leaving 259 days for which
liquidated damages were assessed. Evidence respecting several reasons for the
delay was offered by the claimant as bearing upon the issue of whether the
delay should be excused, but the Court does not need to consider that issue
because of the general rule enunciated in 22 Am. Jur. 2d ?Damages?, ?233,
p. 319, as follows:
?The plaintiff cannot recover liquidated damages for a breach for which he is
himself responsible or to which he
12 REPORTS
STATE COURT OF CLAIMS [W. VA.
has contributed, and as a rule there can be no apportionment of
liquidated damages where both parties are at fault. Hence, if the parties are
mutually responsible for the delays, because of which the date fixed by the
contract for completion is passed, the obligation under which another date can
be substituted, cannot be revived.? (emphasis supplied)
It could not be contended that the installation of 641 extra terminal posts did
not contribute to cause the delay. In addition, there is no evidence as to the
amount of actual damage, if any, sustained by the respondent as a result of the
delay in constructing the right of way fence. For that reason, this case would
seem to fall within the purview of the rule enunciated in J. I. Ilass Co., Inc. v. State Road Commission, 7 W.Va. Ct. Cl. 209, at 212 (1969). Accordingly, the
assessment by the respondent of liquidated damages must be rejected and the
claimant awarded the additional sum of $25,900.00.
Award of $110,082.53.
Opinion issued September 27, 1977
MEREDITH K. RICE, ADM. OF THE ESTATE
OF SYED Q.
ABBAS, DECEASED
vs.
DEPARTMENT OF HIGHWAYS
(No. D-875)
K. Paul Davis and Michael
Bee, Attorneys at Law, for the claimant.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
On February 18, 1974, Syed Q. Abbas,
claimant?s decedent, was killed in a single-car accident. The evidence in the
case reveals that Mr. Abbas was travelling south on U. S. Route 119, south of
the City of Marmet, at approximately 9:45 a.m., when his car crossed the
northbound lane, left the highway,
W. VA.]
REPORTS STATE COURT OF CLAIMS 13
and collided with a tree, killing him.
After a night of heavy frost, the day was clear and cold. Although there was no
precipitation on February 17 or on February 18, 1974, prior to the collision,
the road in the vicinity of the place where the accident happened had a ?dark
glaze? of ice upon its paved surface. The highway and its berm near that place
are bounded to the east by Lens Creek and to the west by a backwater pond,
which drains under the highway into Lens Creek through a concrete flume located
approximately 480 feet north of the tree which claimant?s decedent struck.
The claimant alleges that the respondent was negligent in failing to provide
adequate drainage for the backwater pond, thereby causing water from the pond
to overflow and freeze upon the roadway, resulting in Mr. Abbas? accident and
death.
Pursuant to an Opinion of this Court dated October 18, 1976, this hearing was
conducted solely on the issue of liability.
This Court has held consistently that the State of West Virginia is not a
guarantor nor insurer of the safety of persons who travel on its roads. See Lowe v. Department of Highways, 8 Ct. Cl. 210. Neither does the presence alone of ice
on a roadway prove negligence on the part of the Department of Highways. Bodo v. Department of Highways (CC-76-28). In the case at hand, the evidence failed to
establish flooding or any connection whatsoever between the water in the
backwater pond and the ice on the highway. Absent any proof that the pond
encroached on the roadway, this Court need not confront either the question of
the respondent?s alleged negligent response to an alleged drainage problem, or
its affirmative defense of contributory negligence. The claimant has failed to
prove that the respondent?s alleged negligence caused the accident and death.
Accordingly, the claim must be denied.
Claim disallowed.
14 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued October 17, 1977
ELVIN S. ALFORD
vs.
DEPARTMENT OF HIGHWAYS
(No. D-990)
No appearance by claimant.
Gregory W. Evers, Attorney at Law, for respondent. PER CURIAM:
The claimant and the respondent filed a written stipulation indicating that on
or about March 19, 1975, at approximately 2:30 p.m., the claimant was driving
his 1972 Comet automobile on Smith Creek Road in Kanawha County, West Virginia,
which road is part of the respondent?s highway system. The claimant?s vehicle
struck a water-filled hole in the surface of the highway which was
approximately 7? inches deep and two to three feet wide. It was stipulated that
the hole had existed for some time prior to the accident. The claimant?s
vehicle, upon striking the hole, went out of control, left the road, and went
into a creek.
As a result, the claimant suffered damages both to his automobile and his
person in the amount of $5,000.00. The claimant has received $2,200.00 from his
insurance, which amount has been subrogated to his insurance carrier, United
States Fidelity & Guaranty Company. The claimant sustained doctor bills in
the amount of $364.40 and hospital and ambulance bills in the amount of
$932.25.
The Court, believing that liability exists on the part of the respondent and
that the damages are reasonable, hereby makes an award of $2,800.00 to the
claimant.
Award of $2,800.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 15
Opinion issued October 17, 1977
PEDRO N. AMBROSIO, M.D.
vs.
DEPARTMENT OF HEALTH
(DIVISION OF MENTAL HEALTH)
(No. CC-77-90)
No appearance on behalf of claimant.
Gregory W. Bailey, Assistant Attorney General, for respondent.
GARDEN, JUDGE:
The claimant is a physician from Spencer, West Virginia, who rendered
professional services periodically from February 5, 1976, through June 29,
1976, to one Archie Hackett, a patient at Spencer State Hospital. Claimant?s
statement for services was not submitted to respondent until August 30, 1976,
but, for some reason not apparent on the record, the statement was not paid.
Respondent, by its Amended Answer, admits the validity of the claim and that
the services were necessary and reasonable in amount. The pleading further
reveals that at the close of fiscal year 1976-77, the respondent expired the
sum of $171.74 in the account from which claimant?s statement should have been
paid. The claim is thus controlled by this Court?s decision in Airkern Sales and Service v. Department of Mental
Health, 8 Ct. Cl. 180 (1971), and for
the reasons set forth in that opinion, this claim must be denied.
Claim denied.
16 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued October 17, 1977
GREGORY D. LAVINDER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77?19)
Claimant appeared in person.
Nancy Norman, Attorney at Law, for respondent.
WALLACE, JUDGE:
On February 14, 1977, at approximately 9:25 p.m., the claimant, Gregory D.
Lavinder, was driving his 1976 Ford Granada automobile in a westerly direction
along Midland Drive, or Local Service Route 60/12, in the town of Rand in
Kanawha County, West Virginia. Route 60/12 is a two-lane asphalt road
maintained by the respondent. The claimant testified that he was driving at
approximately 30 mph. It was dark and raining, and visibility was poor. This
automobile struck a water-filled hole on the right-hand side of the highway.
The right front wheel struck first and was undamaged. The rim of the right rear
wheel was bent, and it was later determined that the tire was ruined. The
claimant testified that after the accident, he drove his automobile into his
driveway, which was approximately 500 to 600 feet from the scene of the
accident. He stated that, although the accident occurred near his home, he rode
to work with another person and had never noticed the hole before. He also
stated that the road was in such bad shape he couldn?t pinpoint any particular
hole. Although an apparent defect existed in the road, there is no showing that
the respondent had knowledge of the hole, or, if it did, that the hole was of
such magnitude as to put respondent on notice of the possibility of an
accident.
The law of West Virginia is well established that the State is not a guarantor
of the safety of travelers on its roads. Parsons
v. State Road Commission, 8 Ct. Cl.
35. The case of Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81, holds that:
?Every user of the highways travels at his own risk. The
State does not, and cannot, assure him a safe journey.
W. VA.] REPORTS
STATE COURT OF CLAIMS 17
The maintenance of highways is a governmental function and funds available for
road improvements are necessarily limited.?
In the opinion of the Court, the claimant has not proved such a positive
neglect of duty on the part of the respondent as would impose a moral
obligation on the State to pay the claimant?s damages.
Accordingly, the Court is of the opinion to and does disallow the claim.
Claim disallowed.
Opinion issued October 17, 1977
PHYSICIANS FEE OFFICE
vs.
DEPARTMENT OF HEALTH
(DIVISION OF MENTAL HEALTH)
(No. CC-77-76)
No appearance on behalf of claimant.
Gregory W. Bailey, Assistant Attorney General, for respondent.
GARDEN, JUDGE:
The claimant is an organization that handles the billing and collection of
charges for professional services rendered by physicians at the Medical Center
at West Virginia University. From April 9, 1974, through May 8, 1974, various
members of claimant?s organization rendered professional services to one Roy
Bryan, who was a patient of respondent?s Lakin State Hospital. The total charge
for these services was in an amount of $2,145.23, but the same was never paid.
Respondent filed an Amended Answer admitting the validity of the claim, and
also filed as an exhibit a letter dated April 10, 1977, written by Jane B.
Neal, Acting Director of the Division of Mental Health, stating that the
services were neces
18 REPORTS
STATE COURT OF CLAIMS [W. VA.
sary and that the charge was
reasonable. The letter explained that the charge did not come to the attention
of respondent until December 3, 1974, after the close of the fiscal year during
which the services were rendered. The letter fu?ther stated that, at the close
of fiscal year 1973-74, the sum of $82.05 was expired from the account from
which this claim would have been paid.
It would appear that, had payment of this claim been made during fiscal year
1973-74, it would have constituted an over- expenditure, and as such, would
have been illegal. Consequently, based on the principles set forth in Airkem Sales and Service v. Department of Mental
Health, 8 Ct. Cl. 180 (1971), we
cannot make an award.
Claim denied.
Opinion issued October 17, 1977
TOM PROFFIT and MYRNA PROFFIT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-69)
Claimant, Myrna Pro ff
it, appeared in person.
Gregory W. Evers, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimants were the owners of a 1977 Grand Prix automobile which was damaged
to the extent of $154.85 on the 11th of April, 1977, when it struck a pothole
on U.S. Route 61 in Kanawha County, West Virginia. The testimony of the
claimant, Myrna Proffit, revealed that she was proceeding in an easterly
direction toward her home in Hansford around 10:00 p.m. at a speed of about 20
to 25 miles per hour; that the hole was from five to six inches in depth and
extended from the center of the two-laned road into both lanes of travel; and
that she was fully aware of the existence of this particular hole but was
unable to straddle it, as she had done on prior occasions, by reason of the
approach of a vehicle in the opposite lane.
W. VA.] REPORTS
STATE COURT OF CLAIMS 19
The respondent is, of course, not an insurer of those using the highways of
this State, but we have made awards in ?pothole? claims under various factual
situations. Here, however, and without deciding the issue of the respondent?s
negligence, we feel that it is clear from the testimony that the negligence of
the claimant was the proximate cause, or, at least, a proximately contributing
cause, of the accident and resultant damage to the automobile. With admitted
knowledge of the existence of the condition of the road and of the particular
pothole, claimant chose to approach the same at a speed of 20 to 25 miles per
hour. We feel that this demonstrates a lack of due care on her part, and, for
this reason, we must deny the claim.
Claim disallowed.
Opinion issued October 17, 1977
SAM SICLAIR, d/b/a GALlON
CANVAS PRODUCTS COMPANY
vs.
OFFICE OF ECONOMIC &
COMMUNITY DEVELOPMENT
(No. CC-77-95)
Claimant appeared in person.
Gregory W. Bailey, Assistant Attorney General, for respondent.
WALLACE, JUDGE:
During the early part of 1976, the claimant was contacted by telephone by a
William Milhorn, who, the evidence disclosed, was employed by the Research
Division of the Office of Federal-State Relations (As of July 1, 1977, this
agency ceased to exist and became a part of the Office of Economic &
Community Development). Mr. Milhorn requested that the claimant, who is in the
tent and awning business, make six tents which would be replicas of tents used
by soldiers of the Continental Army during the American Revolution. Mr. Milhorn
explained that these tents were to be used during the
20 REPORTS
STATE COURT OF CLAIMS [W. VA.
celebration of the 1976 Bicentennial
Year, and that, because it was a rush job, the usual purchase order could not
be issued but the claimant would receive payment.
Claimant, who apparently had some expertise in the manufacture of such tents,
agreed to do the work. Before starting the work, however, he made at least one
call to the respondent?s office in Charleston and was assured that indeed
William Milhorn was employed in that office. The tents were manufactured by
claimant and delivered to respondent, and claimant forwarded invoices in the
total amount of $808.80 to ?William Milhorn, Prickett?s Fort Militia Research
Division, Federal- State Relations, Charleston, West Virginia?, but payment of
the invoices was not made. Respondent, although admitting that the tents were
received and used on at least one occasion at Prickett?s Fort near Fairmont,
contends that William Milhorn had no authority to order these tents, and that
because no purchase order had ever been authorized or issued, claimant does not
have an enforceable claim.
While it is true that a vendor dealing with a representative of a State agency
is charged with the affirmative duty of ascertaining whether such
representative has the authority to contract for that agency, and further that
the existence of a valid purchase order is essential in order to bind the
State, we are of the opinion that to deny an award to this claimant would be
unconscionable. The respondent accepted and used these tents, and for it now to
escape payment would constitute unjust enrichment. We therefore make an award
to claimant in the amount of $808.80.
Award of $808.80.
W. VA.]
REPORTS STATE COURT OF CLAIMS 21
Oprnion issued October 17, 1977
JOSEPH and MARIE SOWERS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-51)
Claimants appeared in person.
James W. Wit 1-irow, Attorney at Law, for respondent. GARDEN, JUDGE:
At approximately 9:00 p.m. on March 25, 1977, the claimants were proceeding in
an easterly direction on old U.S. Route 60 in Kanawha County in their 1974
Cutlass automobile at a speed of 25 miles per hour when the right wheels of
their automobile struck a pothole on the right-hand side of their lane of
travel. Both right wheels were damaged, and the cost of their repair and the
cost of a new tire amounted to $209.93. Prior to the accident, it had been
raining hard, and, as a result, as we understand the testimony, certain
portions of the highway were covered with water, including the area where the
pothole was located.
The claimant, Marie Sowers, testified that she and her husband were familiar
with the highway, generally travelling it several times a week. She also quite
candidly admitted that they were aware of the existence and location of the
pothole. Photographs taken several days after the accident portrayed the
existence of a rather large hole on the southerly side of old U.S. Route 60,
one which should have been apparent and which should have been repaired by
respondent. However, even assuming that respondent was guilty of negligence in
failing to repair the pothole, we are compelled to find that the claimants,
knowing of the existence and location of the pothole, were guilty of
contributory negligence in failing to exercise a proper lookout in order to avoid
striking the hole. For these reasons, we must refuse to make an award.
Claim disallowed.
22 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued October 17, 1977
W & H CONTRACTING CO., INC. and
THE BURKE-PARSONS-BOWLBY CORP.
vs.
DEPARTMENT OF HIGHWAYS
(No. D-750)
Michael I. Spiker, Attorney at Law, for claimants.
Stuart Reed Waters, Jr., Attorney at Law, for respondent. WALLACE, JUDGE:
The claimants and the respondent entered into a written stipulation which was
introduced into evidence as Joint Exhibit
A. The parties stipulated that on or about August 5, 1969, the respondent
awarded to the claimant, W & H Contracting Co., Inc., a contract for
certain grading and paving for Project 1-79-2 (35)48 in Braxton County, West
Virginia. On or about October 28, 1969, the claimant, W & H Contracting
Co., Inc., entered into a contract with the claimant, The Burke-ParsonsBowiby
Corporation, as subcontractor for limestoning, fertilizing, seeding, and
mulching the project, with the contract to cover 177 acres. As determined from
the daily batch tickets, 170.35 acres were seeded. The respondent paid the
claimant, W & H Contracting Co., Inc., for 142.43 acres, 27.92 acres being
in dispute. It was further stipulated that if the Court found for the claimants,
the recovery could not exceed $12,843.20.
The record reveals that the respondent was responsible for paying for all
seeding and mulching within the construction limits. Any areas outside the
construction limits or areas that had to be re-seeded were the responsibility
of the claimants. The claimants contend that the entire 170.35 acres were
within the construction limits, and that they should be compensated for the
entire acreage.
The testimony and the evidence of the respondent disclosed that the construction
limits were actually exceeded in some areas. Exact measurements and exact
acreages were not introduced to the Court.
W. VA.] REPORTS
STATE COURT OF CLAIMS 23
Pete I. Shaluta, the construction engineer on the ob for the respondent,
testified that he never actually computed the acreage seeded outside the
construction limits, but knew that such acreage existed by checking the cross
section measurement of the project. He further testified that the respondent?s
liability lay within the construction area, and it was not his responsibility
to find the claimants? error. He stated that the 142.43 acres stipulated as the
quantity paid for by the respondent was the actual acreage within the
construction limits.
The parties introduced, as a joint exhibit, batch tickets showing the acreage
seeded, location of areas, amount of seed, etc. These tickets set out the
entire acreage seeded, but not the pay acreage. The claimants were paid on the
respondent?s measurements of the project which were from the ?as built? plans.
The claimants were paid for 142.43 acres and claim that they are due
compensation for an additional 27.92 acres. Witnesses for the respondent
contend their calculations are correct and that the difference lies in areas
outside the construction limits. The claimants contend, except for waste areas,
that they did not exceed the construction limits.
The Court finds, from the testimony and the evidence, that certain seeded areas
were outside the construction limits and that the evidence is not sufficient to
show that the respondent?s calculations are incorrect. Accordingly, the Court
disallows the claim.
Claim disallowed.
24 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued October 17, 1977
JOHN R. WILDER
and NORMA J. WILDER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-92)
No appearance by claimant.
James W. Withrow, Attroney at Law, for respondent.
PER CURIAM:
The claimant and, respondent have filed a written stipulation indicating that
on or about March 14, 1977, the respondent by and through its employees was
blasting a rock which was resting on Local Service Route 19/2 in Jackson
County, West Virginia. As a result of the blasting, pieces of rock were thrown
against claimants? trailer, causing damage to the panels. It was stipulated
that $233.36 is a fair and equitable estimate of the damage sustained by the
claimants. Believing that liability exists on the part of the respondent and
that the damages are reasonable, the Court hereby makes an award of $233.36 to
the claimants.
Award of $233.36.
Opinion issued November 1, 1977
DONALD M. BONDURANT
vs.
WEST VIRGINIA TAX DEPARTMENT
(No. CC-77-142)
Donald M. Bondurant, the claimant, in person.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
RULEY, JUDGE:
This claim in the sum of $5,585.34 was based upon a contract for personal
services rendered by the claimant as a consultant
W. VA.) REPORTS
STATE COURT OF CLAIMS 25
to the State Tax Department. At the hearing on October 14, 1977, the respondent
conceded the validity of the claim and moved to withdraw the defense pleaded in
its Answer based oa the doctrine of Airkem
Sales and Service v. Department of Mental Health, 8 W.Va. Ct. Cl. 180 (1971). Accordingly, an award in
the sum of $5,585.34 should be, and is hereby, made.
Award of $5,585.34.
Opinion issued November 1, 1977
CHARLES W. GROSE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-.77-75)
Charles W. Grose, the claimant, in person.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
On April 6, 1977, the claimant?s automobile was damaged when it struck a loose
piece of blacktop on New Hope Road near Elkview, West Virginia. The claimant
alleges that the respondent was negligent and asks for damages in the sum of
$358.04.
The State is neither an insurer nor a guarantor of its roads. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). The initial requirement to establish
negligence in this case would be proof that the respondent either knew or, in
the exercise of ordinary care, should have known about the defect in the road.
See Frazier v. Department of Highways, 9 Ct. Cl. 171 (1972) and Jones v. Department of Highways, 9 Ct. Cl. 117 (1972). The sum of the testimony in this
case revealed that the respondent occasionally blacktopped the road in question
and that the road, at the place where the accident occurred, was in ?pretty
good? condition. This Court cannot conclude from that evidence that even the
initial requirement of proof was met. Accordingly, the claim must be denied.
Claim disallowed.
26 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued November 1, 1977
McHENRY HUDNALL, JR.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?77-52)
McHenry Hudnall, Jr., the claimant, in person.
James W. Withrow, Attorney at Law, for the respondent. RULEY, JUDGE:
Upon stipulation of the parties to the effect that respondent negligently
failed to secure a steel plate covering a large hole in Route 60 in South
Charleston, West Virginia; that claimant, on February 26, 1977, was driving his
vehicle in a lawful manner when it went into the hole; and that, as a result of
respondent?s negligence, claimant?s car was damaged in the amount of $147.73,
an award in that amount should be, and is hereby, made.
Award of $147.73.
Opinion issued November 1, 1977
RALEIGH MOTOR SALES, INC.
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-76-123)
Raleigh Motor Sales, Inc., the claimant, by Roger Andrew Sharp, its President.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
RULEY, JUDGE:
In February, 1976, the claimant, Raleigh Motor Sales, Inc., repaired a
four-wheel drive vehicle belonging to the respondent, Department of Natural
Resources. Unable to get bids on the job because of the nature of the repair
work, employees
W. VA.] REPORTS
STATE COURT OF CLAIMS 27
of the Department of Natural Resources had taken the vehicle to the claimant
and asked the claimant to repair the four- wheel drive, overhaul the engine,
and fix the starter and clutch. The respondent?s employees informed the
claimant that they could authorize repairs only up to $500.00; the claimant?s
employees informed them that the job certainly would cost more than $500.00.
The respondent?s employees left the vehicle, assuming that they would be
notified when the cost of repair exceeded $500.00. The claimant?s employees
assumed that they were to repair the vehicle and that any excess would be
easily requisitioned. Total cost of the repairs came to $1,952.36. The
Department of Natural Resources paid only the
$500.00. The claimant seeks recovery of the remaining $1,452.36.
It appears from the evidence that the parties agreed to have the vehicle
repaired, but achieved only a misunderstanding regarding the $500.00 limitation
or the total cost of repairs. The repairs took about a month to perform and the
respondent does not contend that the total cost was excessive. As a result of
the misunderstanding, the claimant performed over $1,900.00 of services and
received only $500.00 in payment.
In cases where the State has been unjustly enriched because of a misunderstanding,
this Court has not hesitated to make an award in claims which ?in equity and
good conscience? the State should pay. Brunetti
Hardware and Painting vs. Department of Mental Health, 10 Ct. Cl. 96 (1974). See also Smith v. Alcohol Beverage Control Commission, 8 Ct. Cl. 127 (1970). The West Virginia Supreme Court
of Appeals held, in In re Estate of Paul S.
Thacker, 152 W.Va. 455, 164 S.E.2d 301
(1968), Syllabus pt. 3:
?When personal services are performed by one person at the instance and request
of another person who is benefited by such services and there is no blood or
family relationship between them and no legal or moral obligation that such
services should be performed, the law implies a contract that the person who
performs such services shall be paid reasonable compensation for such services
unless it is shown that the persons intended that such compensation should not
be paid.?
28 REPORTS STATE
COURT OF CLAIMS [W. VA.
In view of the facts of this case and the law applicable to them, it appears
that an award in the sum of $1,452.36 should be, and is hereby, made.
Award of $1,452.36.
Opinion issued November 1, 1977
CHARLES E. SCHOOLEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?76?131)
Robert B. Black, Attorney at Law, for the claimant.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
Upon stipulation of the parties to the effect that, on October 11, 1976, the
claimant lawfully drove his 1973 dump truck across a bridge which collapsed on
Local Service Route 5/5 in Taylor County, West Virginia, thereby damaging the
truck in the amount of $7,000.00; that the respondent, upon an inspection in
1974, had found the bridge to have a load limit of zero tons; that the
respondent had made no effort to repair the bridge or post a weight limit upon
it since 1974; and that no warning signs were in place upon or near the bridge
on the day the accident happened, an award in the sum of $7,000.00 should be,
and is hereby, made.
Award of $7,000.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 29
Opinion issued November 1, 1977
ROY D. SMITH
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-129)
James W. St. Clair, Attorney at Law, for the claimant.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
This claim in the sum of $422.50 grows out of damage to the claimant?s 1965
model Chevrolet automobile which allegedly was sustained as the result of an
accident which happened between 9:30 and 10:00 p.m. on September 10, 1976, when
the front end of the claimant?s car fell through a hole in the wooden floor of
an old, narrow bridge on Rock Camp Road near Milton, West Virginia. The
evidence indicates that the bridge had been closed in June, 1976; that the
respondent then had erected barricades at each end of the bridge composed of
striped 55-gallon drums with 3 x 10 or 3 x 12 timbers placed across their tops;
that the respondent had placed a sign 32 inches high and somewhat wider reading
?Bridge Closed? in a position where it faced traffic approaching the bridge, as
the claimant had approached it, from W.Va.-U.S. Route 60; that the respondent
periodically inspected the barricades and sign, and both were present on
September 5, 1976, the date of the last inspection before the accident; that
the timbers on the barricades occasionally were moved or removed by unknown
third persons; and that the claimant did not see the sign or any part of the
barricades as he approached the place where the accident happened that night.
These facts fail to establish negligence on the part of the respondent and do
establish negligence on the part of the claimant which at least contributed to
cause the accident and resulting damage. Accordingly, this claim must be
denied.
Claim disallowed.
30 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued November 14, 1977
C. H. JAMES & CO., DIVISION
OF JAMES PRODUCE CO., INC.
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-77-148)
Claimant appeared by Charles H. James,
II, its president.
Frank M. Ellison, Deputy Attorney General, for the respondent.
GARDEN, JUDGE:
On May 18, 1976, and on May 19, 1976, the claimant delivered certain
merchandise to respondent?s Work/Study Centers located at Charleston and
Beckley, respectively. The total cost of this merchandise for which claimant
invoiced respondent was $39.91. For some reason, these invoices were not paid
prior to the close of fiscal year 1975-76. Respondent, by its Answer, admits
the validity of these invoices and this claim, but alleges that there were not
sufficient funds remaining at the close of the fiscal year from which these
invoices could have been paid. Under these circumstances and in accordance with
the reasoning of this Court as expressed in Airkem Sates and Service v. Department of Mental Health, 8 Ct. Cl. 180 (1971), we must refuse to make an award.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 31
Opinion issued November 14, 1977
COURT OF CLAIMS
STATE OF WEST VIRGINIA
FRANK DAVIS and BILLY JOE
DAVIS, d/b/a DAVIS AUTO PARTS
(Claim No. D-996a)
and
BILLY JOE DAVIS
(Claim No. D-996b)
and
HARTFORD ACCIDENT &
INDEMNITY COMPANY and
ISHMAEL COLLINS,
(Claim No. CC-76-125)
Claimants,
vs.
DEPARTMENT OF HIGHWAYS,
Respondent.
John Troelstrup, Attorney at Law, for the claimants.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
These three claims all grow out of the same accident and, accordingly, were
consolidated. The physical facts in this case are clear. Claimants, Billy Joe
Davis and Frank Davis, doing business as Davis Auto Parts in Paintsville,
Kentucky, operate a wrecker service. On Friday, June 13, 1975, Bill Joe Davis
undertook to tow a large coal truck belonging to Ishmael Collins from Pain
tsville to Hurricane, West Virginia. At about 2:00 p.m., while travelling
toward Charleston on Route 1-64 in the outside eastbound traffic lane, Davis?
tow truck struck a hole in the surface of a bridge located approximately .8
mile east of milepost 19 on 1-64, near the town of Ona. The irregularly shaped
hole measured approximately 44 by 48 inches, and, at its location, all of the
pavement had dropped out of
32 REPORTS STATE
COURT OF CLAIMS [W. VA.
the bridge, leaving only the steel reinforcing rods in place. When the right
wheels of the vehicle hit the hole, in what must have been a spectacular accident,
the tow truck went out of control and dragged the coal truck across the inside
eastbound lane, past the bridge, across the median strip, and into the
westbound traffic lanes. There the vehicles flipped and separated. The coal
truck came to rest on its side in the westbound lanes, and the tow truck
flipped over, landing back on its wheels in the median strip. Both trucks were
damaged, and Billy Joe Davis sustained personal injuries.
Davis? testimony and pictures taken after the accident establish that Friday
the 13th was a clear, dry, sunny day. Davis? testimony and that of John
Mullins, driver of the car immediately behind Davis? truck, also establish that
Davis was driving carefully and within the speed limit. There were no signs
warning approaching motorists about the hole in the pavement. Davis could not
have stayed in the outside eastbound lane and avoided the hole, but neither
could he have swerved into the inside eastbound lane to avoid it, because
Mullins was in the inside lane, beginning to pass Davis.
The claimants allege that the respondent negligently failed to maintain the
bridge and negligently allowed the hole to exist in the bridge without repairs
or warning to motorists.
Since the landmark case of Adkins v.
Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947), it has been established in West Virginia that the State is neither an
insurer nor a guarantor of the safety of persons travelling on its roads. See
also Lowe v. Dept. of Highways, 8 Ct. Cl. 210 (1971). The duty imposed on the
Department of Highways is that of ?reasonable care and diligence * * * under all circumstances?. Parsons v. State Road Commission, 8 Ct. Cl. 35 (1969). This Court has more recently
stated that the State?s duty has been fulfilled ?if streets and sidewalks are
in a reasonably safe condition for travel in the ordinary modes, by day and
night?. Shaffer v. Board of Regents, 9 Ct. Cl. 213 (1973).
Turning to the case at hand, respondent, in its brief, citing four Opinions of
this Court, contends that the State properly performed its duties regarding the
bridge on Route 1-64, and
W. VA.] REPORTS
STATE COURT OF CLAIMS 33
was not negligent. This case differs significantly from the cases cited [Janus v. S.R.C., 1 Ct. Cl. 343 (1942); Harris v.
S.R.C., 7 Ct. Cl. 189 (1968); Varner v. Department of Highways, 8 Ct. Cl. 119 (1970); Lowe v. Department of Highways, 8
Ct. Cl. 210 (1971)]. All of those cases involve either falling rocks or
placement of guardrails; none involve defects in the road?s surface, as does
the instant case. All of those cases concern the two-lane, winding sort of
highway for which West Virginia is known (described in Adkins, supra, as
?narrow, with steep grades and sharp curves?); none of them concerns a modern,
four-lane, interstate highway such as Route 1-64 (unheard-of at the time of the
Adkins decision). The Depart- men t of Highways has a duty to
keep such interstate highways reasonably safe for traffic travelling at
authorized speeds, and a concomitant duty to make a reasonable and diligent
effort to discover and warn motorists of hazards which foreseeably would make
such travel dangerous. On a road where the facts, circumstances, or speed limit
would dictate a low speed, a hole such as the one in question might not pose a
threat to motorists. But such a hole in a bridge on an interstate highway is an
extreme hazard for ordinary traffic. In County
Commissioners of Carroll County v. Staubitz, 231 Md. 209, 190 A.2d 79 (1963), it was stated:
?Although the standard of reasonable care remains constant, what is reasonable
care in a given situation varies with the conditions present on such road or
highway. Reasonable care on a busy, often travelled highway requires greater
diligence on the part of the county commissioners than that required on a
relatively little- travelled road.? (citations omitted)
See also Jenkins v. Maryland, 25 Md. App. 558, 334 A.2d 549
(1975), Braswell Motor Freight Lines,
Inc. v. Toups, La. App.,
255 So. 2d 155 (1971), and 4 Blashfield Automobile Law and
Practice, 3rd edition, ?161.9 ?Extent
of Liability?.
Does the respondent?s failure to
repair the hole or warn approaching motorists constitute negligence? This Court
stated in Frazier v. Dept. of
Highways, 9 Ct. Cl. 171 (1972), ?It
also seems fundamental that an important cross-country highway
34 REPORTS STATE
COURT OF CLAIMS [W. VA.
such as U.S. Route 60 *
* * would be expected to afford safe
passage at or near a posted speed limit of 45 miles per hour.? And in Varner, supra, this
Court held that ?when the State Road Commission knows or should know that an
unusually dangerous condition exists, there is a duty to inspect and correct
the condition within the limits of funds appropriated by the Legislature for
maintenance purposes?. The State was found negligent in Varner for
failing to correct a known, dangerous condition which caused the rockslide
which killed Mrs. Varner. The State has been found negligent for failing to
discover and correct a hazard on a bridge which a ?casual inspection? would
have revealed. Randall v. Dept. of
Highwcvys, 8 Ct. Cl. 147 (1970). The
State also has been found responsible for property damage caused by a landslide
attributable to water backed-up behind a plugged drain along a highway, when
the evidence revealed that employees of the Department of Highways had patched
cracks in the road caused by the same backwater and should, therefore, have
done something to correct the condition of the drain. Olive v. Department of Highways, 8 Ct. Cl. 148 (1970).
The evidence in this case impels the conclusion that the Department of
Highways, in the exercise of ordinary care, should have known of the existence
of the hole in the bridge before the accident happened. Mullins attested to its
existence as early as 9:30 p.m. the day before the accident happened. In view
of the evidence that the interstate highway bridges in the area apparently had
required surface repairs several times before the accident, the Department of
Highways had an obligation to inspect them with reasonable frequency and care.
Four employees of the Department of Highways testified that they drove across
the bridge in question between the hours of 9:00 a.m. and 12:30 p.m. the day of
the accident. None of them saw the hole in question. The respondent suggests
that it should be inferred from the testimony of its employees that the hole
came into existence only momentarily before the accident happened, but that
seems improbable and would require the Court to disregard the Mullins
testimony.
The respondent contends that, even if it were negligent, awards should be
precluded by the contributory negligence of
W. VA.] REPORTS
STATE COURT OF CLAIMS 35
Billy Joe Davis. Davis had not driven over the bridge in three months. Although
he knew that other bridges on the interestate were rough and patched, he had
negotiated them safely, and certainly had no reason to expect to encounter the
large hole in the bridge. He was travelling at 45 mph (his testimony) or 50 mph
(Mullins), below the speed limit. He saw the hole 30 or 40 feet before he hit
it, couldn?t swerve to the left to avoid it because Mullins was about to pass
him, and had no choice but to drive over the hole. After giving the issue due
consideration, this Court cannot conclude that Davis was guilty of contributory
negligence. To the contrary, it appears that the respondent?s negligence was
the sole cause of the accident, and, accordingly, the issue of liability must
be resolved in favor of the claimants.
Turning to the issue of damages, the claimants, Frank Davis and Billy Joe
Davis, doing business as Davis Auto Parts, have asserted a claim in the sum of
$66,000.00 attributable to damage to the 1969 Ford model 950 wrecker truck
which was owned by them. Although both claimants testified that the wrecker
truck was a total loss (and there was no evidence to the contrary), it was
rebuilt by Frank Davis, who worked on it part-time for approximately one year.
Frank Davis testified that it could have been rebuilt in three months if he had
worked on it 40 hours per week. Included in this claim are items for the cost
of repair of the truck, loss of use of the truck, loss of a large quantity of
tools which it was claimed were in the truck at the time of the accident and
apparently were carried away by unknown third persons, and a towing charge in
the sum of $325.00 for moving the wrecker truck from Hurricane back to
Paintsville. The undisputed evidence is that the fair market value of the
wrecker truck was $35,- 000.00 immediately before the accident and $10,000.00
immediately after the accident, the difference being the sum of $25,000.00, but
that the cost of repair was $18,800.00, viz., $14,000.00 for parts and materials
and $4,800.00 for labor. In Cato v.
Silling, 137 W.Va. 694, 73 S.E.2d 731
(1952), Syl. 7, the general rule is stated as follows:
?[T]he proper measure of damages for injury to personal property is the
difference between the fair market value
36 REPORTS
STATE COURT OF CLAIMS [W. VA.
of the property immediately before the
injury and the fair market value immediately after the injury, plus necessary
reasonable expenses incurred by the owner in connection with the injury. When,
however, injured personal property can be restored by repairs to the condition
which existed before the injury and the cost of such repairs is less than the
diminution of the market value due to the injury, the measure of damages may be
the amount required to restore such property to its previous condition.?
Accordingly, the award to these claimants should include the cost of repair in
the sum of $18,800.00 plus the towing charge of $325.00. It appears from the
evidence and under applicable law that the award should also include some
reasonable sum for loss of use of the wrecker truck. See Jarrett v. E. L. Harper & Son, Inc. W.Va , 235 S.E.2d 362 (1977). A tortfeasor ?is held
responsible for all the consequences of his negligent act which are natural and
probable?. Ohio-West Virginia Co. v.
Chesapeake and Ohio Railway Co., 97
W.Va. 61, 124 S.E. 587 (1924). See also Stewart
v. Poliack-Forsch Co., 105 W.Va. 453,
143 S.E. 98 (1928). The respondent?s negligence certainly caused these
claimants to lose the use of the wrecking truck, and the claimants deserve an
award for loss of use for a period of time reasonably required to effect
repairs on the truck. The proof offered for determining damages due to loss of
use consisted of Davis Auto Parts? records for receipts from their wrecker
operations covering the period from 18 months before the accident to a date two
years after the accident. Those records showed that, before the accident, Davis
Auto Parts? three wreckers (the large one damaged in this accident and two
smaller ones) produced an average gross income of $1,786.00 per month; during
the time the truck was under repair, wrecker income averaged only $445.00, a
difference of $1,341.00 per month. Testimony regarding the expenses of
operating the large wrecker included a definite figure of $60.00 per month for
gasoline, with no definite proof of the cost of oil, tries, or any maintenance,
which the Davis brothers did themselves. A loss of profit, when not awarded, is
generally excluded because ?there are no criteria by which
W. VA.] REPORTS
STATE COURT OF CLAIMS 37
their amount can be ascertained with
reasonable certainty or definiteness.? Stewart
v. Pot Vack-Forsch. Co., supra. Thus,
prospective profits of a new business (Ohio-W.Va.
Coat Co. v. Chesapeake and Ohio Railway Co., supra; Shatzer v. Free port Coat, 144 W.Va. 178, 107 S.E.2d 503 [1959]; Whitehead v. Cape Henry Syndicate, 69 S.E. 263 [Va., 1910]) or losses due to a reduction
of public confidence (Ohio-W.Va. Coat
Co., supra) are generally denied as
too speculative or conjectural. But if a business is well established, as Davis
Auto Parts was, damages may be awarded for loss of profits. Whitehead, supra. In
addition, ?Uncertainty as to amount of the damages does not prevent a recovery,
if the evidence affords a sufficient basis for estimating their amount in money
with reasonable certainty [citations omitted].? Haddad v. Western Contracting, 76 F. Supp. 987 (N.D.W.Va., 1948). While the evidence
in this case as to loss of use is not as definite as might be desired, we do
not believe that it is so uncertain that recovery should be denied. It is our
opinion, based upon the evidence, that damages for loss of use for a period of
three months is reasonable and that the sum of $2,000.00 would be a fair and
just compensation for that loss of use. Inasmuch as the larceny of the tools
could not have been a foreseeable consequence of the respondent?s negligence,
no recovery for that item can be allowed. From the foregoing, it is apparent
that the total award to the claimants, Frank Davis and Billy Joe Davis, doing
business as Davis Auto Parts, should be the sum of
$21,125.00.
Billy Joe Davis, who was 27 years of age when these claims were heard on
December 7, 1976, has asserted an individual claim in the sum of $10,500.00 for
personal injuries which he sustained in the accident and for loss of a wrist
watch. The only evidence respecting the value of the wirst watch, which was
damaged beyond repair, was that its cost on December 18, 1974, was $131.25.
Respecting his personal injuries, there was evidence that he sustained cuts and
bruises, a fracture of his skull, and a fracture of his twelfth thoracic
vertebra. There was no evidence whatsoever concerning the extent or severity of
either of the fractures, but there was evidence that, for some time after the
accident, Billy Joe suffered from headaches
38 REPORTS STATE
COURT OF CLAIMS [W. VA.
and vertigo. Although he testified that he saw a doctor two or three times
after the accident for treatment of injuries related to it, the only evidence
of medical expense incurred is an item of $50.00 for an x-ray on June 14, 1975,
an item of $35.00 for an x-ray on June 16, 1975, and a charge in the sum of
$25.00 by E. E. Musgrave, M.D., for an office visit. The evidence of Joseph P.
Seltzer, M.D., who performed a complete orthopaedic and neurological
examination upon the claimant on behalf of the respondent on November 29, 1976,
was that, as of that date, he had made a complete recovery without any
permanent residuals. In view of these circumstances, it appears that an award
in the sum of $750.00 will compensate the claimant, Billy Joe Davis, for the
personal injuries and damages which he sustained.
The claimants, Hartford Accident & Indemnity Company and Ishmael Collins,
the collision insurer and owner, respectively, of the 1974 model Brockway coal
truck, have asserted a claim in the sum of $26,667.95 for damage to it. The
undisputed evidence is that the damage to the coal truck rendered it a total
loss. It appears that the claim which is asserted is made up of the sum of
$26,167.95 paid by Hartford to Collins (and to which Hartford thereupon became
subrogated) and the sum of $500.00 representing Collins? deductible portion of
his collision insurance. Although there was some confusion about the matter in
the evidence, it appears from the evidence that the fair market value of the
coal truck immediately before the accident was $24,550.00 and that it was sold
for salvage subsequent to the accident for the sum of $2,723.50. Accordingly,
an award in the sum of $21,826.50 should be made to these claimants.
Award of $21,125.00 to claimants, Frank Davis and Billy Joe Davis, doing
business as Davis Auto Parts.
Award of $750.00 to claimant, Billy Joe Davis.
Award of $21,826.50 to claimants, Hartford Accident & Indemnity Company and
Ishmael Collins.
W. VA.]
REPORTS STATE COURT OF CLAIMS 39
Opinion issued December 6, 1977
KERMIT REED HUBBS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-83)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimant is the owner of a farm located on Shepherd?s Ridge, a rural area
in Marshall County, eight miles from the City of Moundsville, West Virginia.
This farm is bisected by a secondary road which is maintained by respondent.
The farm fronts on both sides of this secondary road for a distance of about
one-half mile. The claimant kept cattle on the farm; consequently, his property
on both sides of the road was fenced. The claimant did not live on the farm but
did visit it daily for the purpose of feeding his cattle.
During the month of January, 1977, this area of Marshall County, as was true in
other areas in West Virginia, received a very large accumulation of snow as the
result of three or four severe snowstorms. As a matter of fact, the snow on the
road and property of the claimant in some areas was as deep as 12 feet. As a
result, the respondent?s regular road crews did not have the necessary manpower
to clear the roads in Marshall County, and thus the Office of Emergency
Services directed the National Guard to assist the respondent in clearing the
roads of snow.
The claimant testified that employees of respondent had removed snow from the
road on three or four occasions prior to the day in January when members of the
National Guard started their removal operations. Claimant was present at the
farm when the National Guard was attempting to remove the snow, and he
requested that they not push the snow from the road directly into his fence
line, but rather, that they push the snow up and down the road and through a
small break in the fence line that had been made previously by employees
40 REPORTS STATE
COURT OF CLAIMS [W. VA.
of respondent. The members of the National Guard refused to comply with
claimant?s request, and as a result, a large length of the fence line was
destroyed, including some 65 fence posts and a 14-foot wooden gate. The
claimant repaired this damage, and the cost of the necessary material and labor
amountd to $435.90.
One of the basic statutory responsibilities imposed on the West Virginia
Commissioner of Highways is the maintenance of the roads and highways of this
State. (See Code 17-2A-8.) Certainly included within the term ?maintenance?
would be the responsibility for snow removal to make the highways safe and
passable for motorists, and we are of the opinion that this duty is
nondelegable and nonassignable.
The respondent was not directing or supervising the activities of the National
Guard. This is the basis for respondent?s contention that the National Guard
was an independent contractor and that respondent is therefore not responsible
for the negligence of the members of the National Guard. We agree that the
National Guard occupied the position of an independent contractor, but the
general rule of nonliability is subject to certain well-defined exceptions,
such as where the undertaking is particularly hazardous, where the employer
interferes with the conduct of the work, where the injury is the direct or
natural result of the work, or where
the law imposes a special duty. (Emphasis
supplied) See Chenoweth v. Settle
Engineers, Inc., 151 W.Va. 830, 156
S.E. 2d, 297 (1967). While the ends attained as the result of snow removal are
most salutary, we are of the opinion that the respondent cannot escape
liability by attempting to delegate the performance of this special duty to
third parties.
Being of the opinion that the members of the National Guard performed their
work in a negligent manner, and that, as a proximate result of such negligence,
the claimant sustained damages, we hereby make an award in favor of the
claimant in the amount of $435.90.
Award of $435.90.
W. VA.] REPORTS
STATE COURT OF CLAIMS 41
Opinion issued December 8, 1977
DARRELL E. BUCKNER & BETTY S. BUCKNER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?77-129)
Claimants appeared in person.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
The parties in this claim filed a written stipulation which revealed that, on
March 24, 1977, the claimant, Betty S. Buckner, was driving their vehicle on
Secondary Route 60/12 in the vicinity of Belle in Kanawha County; that
respondent had negligently allowed a hole to remain in the road which was
covered with water on the date of the accident; and that claimant, Betty S.
Buckner, without fault on her part, struck the hole and damaged their vehicle
in the amount of $63.46, which sum is a fair and equitable estimate of the
damage sustained. Based on the foregoing, an award in the above amount is
hereby made to the claimants.
Award of $63.46.
Opinion issued December 8, 1977
CLYDE W. CUMMINGS & BETTY L. CUMMINGS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-102)
Clyde W. Cummings appeared in person.
Richard Carltan, Attorney at Law, for respondent.
GARDEN, JUDGE:
As a result of heavy snows during the months of January and February, 1977, and
because respondent?s snow removal equip-
42 REPORTS STATE
COURT OF CLAIMS [W. VA.
ment was insufficient, the respondent, through special purchase orders, which
were introduced into evidence, rented from L. C. Coal Company of Kingwood, two
endloaders, two 4-wheel drive pickups, one mechanic?s truck (all with
operators), and one base control system. During the evening of February 4,
1977, while engaged in snow removal on Secondary Route 112 in Preston County,
one of the above-mentioned endloaders, for reasons not clearly explained, left
the right-of-way of the road, broke through claimants? fence, and went over the
hill some 200-250 feet into the claimants? farm. At the time of the incident,
the endloader was being operated by an employee of
L. C. Coal Company, and apparently, no representatives of respondent were in
the area.
The operator of the endloader was unable to extricate the endloader from
claimants? property, and, as a result, L. C. Coal Company hired an independent
bulldozer operator who bulldozed a road through claimants? property which was
then used as a means of egress by the bulldozer and the endloader. In the
process of bulldozing the road, a considerable number of valuable trees of the
claimants were destroyed. Three competitive estimates, for repairing the fence,
restoring the claimants? property to its former condition, and including the
value of the trees, were introduced into evidence, the lowest being in the
amount of $1,030.00.
Certainly the failure of the endloader operator to confine his activities
within the right-of-way of the road constituted negligence, and for the reasons
expressed by the Court in the recently decided claim of Hubbs v. Department of Highways, Claim No. CC-77-83, we hereby make an award in favor of
the claimants in the amount of $1,030.00.
Award of $1,030.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 43
Opinion issued December 8, 1977
DEPARTMENT OF HIGHWAYS
vs.
DEPARTMENT OF PUBLIC INSTITUTIONS
(No. CC-77-65)
Hershel R. Hark, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN,
JUDGE:
This claim was submitted for decision on the pleadings which consisted of
claimant?s Notice of Claim and respondent?s Amended Answer. From these
pleadings it would appear that in June of 1976, the claimants sold and
delivered a quantity of heating oil to respondent?s Huttonsville Correctional
Center, and on June 30, 1976, claimant invoiced respondent for the cost thereof
in the amount of $3,040.00. Claimant seeks an award for the amount of the
invoice and, in addition, interest thereon from June 14, 1976, the date of
delivery of the last shipment of oil to respondent.
In respect to the interest claimed, the record fails to disclose the existence
of any contract between the parties specifically providing for the payment of
interest; thus, pursuant to Code 14-2-12, we are precluded from giving
consideration thereto. Further, the respondent?s Amended Answer alleged that no
funds were remaining in its appropriation at the close of fiscal year 1975-76
from which this claim could have been paid, and we must therefore refuse to
make an award on the basis of our decision in Airkem Sales and Service, et
al. v. Department of Mental Health, 8 Ct. Cl. 180 (1971).
Claim disallowed.
44 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued December 8, 1977
ROBERT M. HASTINGS & LINDA HASTINGS,
d/b/a HASTINGS STABLES
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-94)
Claimants appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimants are the owners of property which fronts on the Old Kingwood Pike
in Monongalia County. On this property they maintain a small stable where they
board horses. They also use part of the property as a pasture field which was
fenced prior to the severe winter of 1976-77. Claimants testifield that, during
the winter, employees of respondent, in conducting snow plowing operations,
damaged a .2 mile-long section of the pasture field fence fronting on the Old
Kingwood Pike. Claimants contend that as a result of this damage, they have
been unable to turn horses out in this pasture, and their business has
suffered, although no evidence of the amount of such loss was introduced into
evidence.
Robert M. Hastings testified that on one occasion during the winter, he
observed respondent?s equipment being used to clear snow from Old Kingwood Pike
at its intersection with Green- bag Road. On that occasion, the respondent?s
employees were pushing all of the snow over and against the subject fence line,
and the claimant observed a grader on top of the drifting snow actually
breaking the top off of the fence posts. Mr. Hastings was of the opinion that
the weight of the snow being pushed into and on top of the fence was the reason
for the fence line?s being damaged.
Linda Hastings testified that she observed respondent?s equipment during the
winter working in the fence line area of the road clearing snow, and that she
never observed anyone else such as the National Guard or other independent
parties
W. VA.] REPORTS
STATE COURT OF CLAIMS 45
engaged in snow removal. She testified further that, in order to repair the
fence, she and her husband would have to purchase 110 locust posts at $1.50
each and 8 rolls of 12? gauge barbed wire at $25.00 per roll, for a total
expense of $365.00.
Fred Siegworth, a general foreman of respondent, testified that he was familiar
with the road situation in the subject area during the winter of 1976-77, and
that the respondent had contracted with one Raymond Dalton to plow Old Kingwood
Pike, and that Dalton furnished his own equipment and men. However, he did not
testify that employees of respondent were never engaged in plowing operations
during the winter on Old Kingwood Pike.
Whether the damage to the claimants? fence was caused by employees of the
respondent or by employees of Raymond Dalton, in our opinion, is not material;
the damage resulted from negligent conduct, and in accordance with our
reasoning set forth in the recently decided claim of Hubbs v. Department of Highways, Claim No. CC-77-83, we hereby make an award in favor of
the claimants in the amount of $365.00.
Award of $365.00.
Opinion issued December 8, 1977
PFIZER CORPORATION,
ROERIG DIVISION
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-77-104)
Daniel L. Lynch appeared on behalf of claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer. In April of 1976, the respondent?s Spencer
State Hospital placed
46 REPORTS STATE
COURT OF CLAIMS [W. VA.
an order with claimant for 160 bottles of Navane Oral Concentrate at a cost of
$638.40, as reflected in the 1976-77 West Virginia Drug Contract Book. The
order was delivered to the Spencer State Hospital, and claimant invoiced
respondent for $1,246.40. Respondent paid claimant only $638.40 in accordance
with the price as listed in the Drug Contract Book, and in this claim, the
claimant now seeks an award of $608.00, the difference between the invoice
price and the amount paid.
It developed that a mistake had been made in the Drug Contract Book in respect
to a 160-bottle order. The Drug Contract Book also listed the cost of one
bottle of Navane as $14.51, and the cost of a 32-bottle order as $348.16. The
mistake becomes apparent when one realizes that the cost per bottle in a
160-bottle order is only $3.99, compared to a $10.88 cost per bottle in a
32-bottle order and a single-bottle order cost of. $14.51.
In its Answer, the respondent admits that it ordered, received, and used the
160 bottles of Navane, and that a pricing mistake had been made in the Drug
Contract Book. The pricing mistake was not discovered until after the close of
fiscal year 1976-77, and the respondent alleges that there were not sufficient
funds remaining in respondent?s appropriation at the close of the fiscal year
from which the claim could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are of further opinion that an award cannot be made, based on our
decision in Airkem Sales and Service,
et al. v. Department of Mental Health, 8
Ct. Cl. 180 (1971).
Claim disallowed.
W. VA.J REPORTS
STATE COURT OF CLAIMS 47
Opinion issued December 12, 1977
DAVID E. ALVIS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77?62)
No appearance by claimant.
Gregory W. Evers, Attorney at Law, for respondent. PER CURIAM:
The claimant and the respondent have stipulated that on or about February 12,
1977, at approximately 7:45 p.m., the claimant was operating his automobile in
the westbound lane of W.Va. Route 33 two miles west of Spencer, West Virginia.
It was dark and a light rain was falling. The claimant?s automobile struck a
hole in the westbound lane which was full of water and obscured from view. It
was further stipulated that the respondent had patched the hole three times
within one week of claimant?s accident, but the patch continued to ?boil? out.
There were no warning signs or barricades. As a result of the accident, the
right rear wheel and radial tire of claimant?s vehicle were damaged, and $99.85
is a fair and equitable estimate of the damages sustained by the claimant.
Believing that liability exists on the part of the respondent and that the
damages are reasonable, the Court hereby makes an award of $99.85 to the
claimant.
Award of $99.85.
48 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued December 12, 1977
SANDRA S. CLEMENTE
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-77-167)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant, Sandra S. Clemente, filed this claim requesting a refund of the
5% tax paid to the respondent as a result of the purchase of a secondhand car
from Rogers Motor Sales in Parkersburg, West Virginia. The claimant was not
satisfied with the automobile, and the dealer refunded her money.
It is the opinion of this Court that, since by mutual agreement between the
parties the sale was nullified and the claimant?s money refunded, the tax paid
in the amount of $73.75 should be refunded to the claimant. Accordingly, an
award in the sum of $73.75 should be, and is hereby, made.
Award of $73.75.
Opinion issued December 12, 1977
GEORGE M. CUSTER
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-77-86)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
This claim is for a refund of the 5% tax paid to the respondent as a result of
the claimant?s purchase of an automobile. The claimant, George M. Custer, of
Wheeling, West Virginia, purchased a 1977 Oldsmobile Delta 88 automobile from
Bob?s Chevrolet, Inc. in Barnesville, Ohio. He paid the West Virginia
W. VA.] REPORTS
STATE COURT OF CLAIMS 49
Department of Motor Vehicles, through the Wheeling Automobile Club, the sum of
$302.00, representing the 5% tax on the automobile purchased and a $2.00 title
fee. It was later determined that the automobile was equipped with a Chevrolet
engine. The dealer was unable to replace the engine or the automobile. The
claimant?s money was refunded and the automobile transferred to the dealer.
It is the opinion of the Court that in equity and good conscience, since the
parties nullified the transaction, the tax paid should be refunded. The title
to the automobile was assigned to the dealer. The title fee should not be
returned. Accordingly, an award in the sum of $300.00 should be, and is hereby,
made.
Award of $300.00.
Opinion issued December 12, 1977
DIRECT MAIL SERVICE COMPANY
vs.
BOARD OF REGENTS
(No. CC-77-151)
No appearance by claimant.
Frank M. EUison, Deputy Attorney General, for respondent. PER CURIAM:
The claimant, Direct Mail Service Company, filed its claim in the amount of
$750.00 against the respondent for design and art work for brochures furnished
Southern West Virginia Community College at Logan, West Virginia. The
respondent filed its Answer admitting liability and recommending payment of the
claim. The Answer admitted that the services were ordered and received by the
respondent, that the funds were available, and that the claimant was not paid
due to the fault of the respondent in not timely processing the claimant?s
invoice. Therefore, it is the opinion of the Court on the basis of the
pleadings that the claim in the amount of $750.00 should be allowed.
Award of $750.00.
50 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued December 12, 1977
PAULINE E. FLAHERTY
vs.
DEPARTMENT OF FINANCE & ADMINISTRATION
(No. CC-77-89)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
The claimant, a self-employed practical nurse from Wheeling, had traveled to
Charleston to attend Governor Rockefeller?s Inauguration on January 17, 1977.
As any who were in attendance can attest, the weather was extremely cold, and
most of the grounds outside the Capitol complex were covered with a sheet of
ice. The claimant was apparently working her way up to the speaker?s stand and
was on a sidewalk which she described as being a glare of ice with people
sliding everywhere. She was wearing leather, ribbed-soled boots without heels.
She testified that she was not pushed or jostled but simply slipped on the ice
which she recognized as being slippery and dangerous. In any event, this
slippery condition caused her to fall, and, as a result, she suffered a
fracture near the head of the humerus of her right arm.
She received emergency treatment at the Capitol Dispensary and was thereafter
taken to Thomas Memorial Hospital where the fracture was diagnosed and where
her arm was immobilized. Despite her injury, the claimant was of sufficient
fortitude to return to the Capitol that evening, and she did attend the reception
and dance in honor of Governor Rockefeller. She returned to Wheeling where she
continued to receive medical treatment. At the time of the hearing in October,
1977, she testified that she had made a good recovery, but still was
periodically required to obtain a cortisone injection in her right shoulder.
Mrs. Flaherty testified that her out-of-pocket expenses resulting from her fall
were in the amount of $646.00. Included in that amount was a $260.00 wage loss
and an expense of $100.00 for hiring a third party to drive her invalid
W. VA.]
REPORTS STATE COURT OF CLAIMS 51
husband to the hospital and doctor?s
office. The balance represented her actual medical expenses.
Falling and sustaining a personal injury is always a most traumatic and painful
experience, particularly when a person is many miles from home, and we have the
greatest sympathy for the claimant, but, even assuming that the respondent was
guilty of negligence in failing to exercise ordinary care to keep the Capitol
grounds in a reasonably safe condition, we must conclude that the claimant is
barred from recovering by virtue of the doctrine of assumption of risk. The law
is clear that where a dangerous condition is created by one party and such
dangerous condition is recognized as such by another party who nevertheless
exposes himself to such condition and is injured as a result, the injured party
is barred from recovery from the party who created such dangerous condition. We
must, therefore, reluctantly refuse to make an award to claimant.
Claim disallowed.
Opinion issued December 12, 1977
TIMOTHY J. GRIMMETT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-147)
No appearance by claimant.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
By written stipulation filed with the Court, the claimant and the respondent
stipulated that on or about August 3, 1977, the respondent was repairing holes
in the floor of the Montgomery Bridge, Bridge No. 10-6-0.12, located at
Montgomery, West Virginia, in Kanawha County. It was further stipulated that
the claimant was driving his truck across the bridge and struck a hole over
which sheet metal had been inadequately placed. The claimant?s vehicle
sustained damage in the amount of $271.44.
52 REPORTS
STATE COURT OF CLAIMS [W. VA.
The Court, being of the opinion that
liability exists on the part of the respondent and that the damages are
reasonable, hereby makes an award of $271.44 to the claimant.
Award of $271.44.
Opinion issued December 12, 1977
MICHAEL J. HART
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-124)
No appearance by claimant.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
The claimant and the respondent filed a written stipulation with the Court in
which the parties stipulated that the respondent, on June 28, 1977, was making
certain maintenance repairs utilizing welding rods on the Williamstown Bridge
on W.Va. Route 14 at Williamstown, Wood County, West Virginia. It was further
stipulated that the respondent?s employees left pieces of welding rod material
on the bridge after completing the day?s work. At or about 6:00 p.m. the same
day, the claimant?s motorcycle tire and tube were punctured by a piece of
welding rod material as he was proceeding across the bridge, sustaining damage
in the amount of $46.49.
The Court, believing that liability exists on the part of the respondent and
that the damages are reasonable, hereby makes an award of $46.49 to the
claimant.
Award of $46.49.
W. VA.] REPORTS
STATE COURT OF CLAIMS 53
Opinion issued December 12, 1977
THEODORE KORTHALS
& EMILE KORTHALS
vs.
DEPARTMENT OF? HIGHWAYS
(No. D-1041)
No appearance by claimants.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
By written stipulation entered into by the claimants and the respondent and
filed with the Court, it was stipulated that the claimants own property at #2
Cecil Place, in Wheeling, Ohio County, West Virginia. The right-of-way fence of
Interstate 70 is located along the rear boundary line of claimants? property.
It was further stipulated that in the summer of 1975, the respondent sprayed a
weed killer known as Hyvar X-L along its right-of-way fence adjacent to
claimants? property, knowing that Hyvar X-L killed weeds and plants by being
absorbed into the soil and the roots of weeds and plants. As a result, at least
19 trees and 3 shrubs at the rear of claimants? property died or were damaged
in the amount of $3,500.00. On the basis of the above, and from the exhibits
filed with the stipulation that the damages are reasonable, the Court believes
that liability exists, and hereby directs an award to the claimants in the
amount of $3,500.00.
Award of $3,500.00.
54 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued December 12, 1977
JOHN LAVENDER, JR.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-85)
Claimant appeared in person.
James W. Wit hrow, Attorney at Law, for respondent. WALLACE, JUDGE:
This claim in the amount of $186.44 was filed by John Lavender, Jr. and his
daughter, Tammy Sue Lavender, for damages to a 1976 MG Midget automobile owned
by the claimant, John Lavender, Jr. Since the damaged automobile was owned by
the claimant, John Lavender, Jr., respondent?s motion to designate him the sole
claimant was sustained.
The evidence revealed that in the early part of April, 1977, Tammy Sue Lavender
was driving the claimant?s automobile on W.Va. Route 61 in East Bank, West
Virginia. It was dark, and the weather was clear. The road was blacktopped.
Tammy Sue Lavender testified that she was driving approximately 30-35 miles per
hour. She stated that she had driven the road previously going to and from
school, but had turned off the road before reaching the point of the accident.
She further stated that she proceeded over a hill, and as she entered into a
curve, the automobile struck ?chug holes? in the pavement. Due to the approach
of an oncoming automobile, she was unable to miss them. The claimant, who later
went to the scene of the accident to assist his daughter, had no trouble
because he was familiar with the highway and was driving a bigger automobile.
To establish negligence on the part of the respondent, there must be proof that
the respondent either knew, or, in the exercise of ordinary care, should have
known about the defects in the highway. Although apparent defects existed,
there is no showing that the respondent had knowledge of the holes, or, if it
did, that the holes were of such magnitude as to put respondent on notice of
the possibility of an accident.
W. VA.] REPORTS
STATE COURT OF CLAIMS 55
The law of West Virginia is well established that the State is not a guarantor
of the safety of travelers on its roads. Parsons
v. State Road Comm?n., 8 Ct. Cl. 35.
The case of Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 held:
? . the user of the highways travels at his own risk and
that the State does not and cannot assure him a safe journey..
From the record in this case, the Court is of the opinion that the claimant has
not proved such negligence on the part of the respondent as to establish
liability. Accordingly, the Court is of the opinion to, and does, disallow the
claim.
Claim disallowed.
Opinion issued December 12, 1977
HUGH C. MAYFIELD
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-118)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
On a weekend in February, 1977, during the height of a series of critical
snowstorms in Preston County, members of the National Guard were attempting to
plow Secondary Route 7/13 in the area of the claimant?s 400-acre farm. In the
course of this plowing operation, done with a bulldozer, the boom on the
claimant?s 33-A power loader was struck by the bulldozer and was damaged to the
extent that it was rendered irreparable. The evidence disclosed that the width
of the right-of-way of Secondary Route 7/13 at and near claimant?s farm was 30
feet and that the power loader was located some 22 feet from the center of the
road, or at least 7 feet from the right-of-way, clearly located on claimant?s
property.
56 REPORTS STATE
COURT OF CLAIMS [W. VA.
The claimant testified that, during a weekend morning in February, 1977, a
bulldozer operator had pushed snow from the road onto his property, and as a
result, had covered the power loader with snow. Operators on the bulldozer were
then switched, and the new operator, being unaware of the presence of the power
loader, struck the boom while continuing the snow removal operation. Obviously,
when this occurred, the operator was at least 7 feet from the edge of
respondent?s right-of-way. While there was a conflict in the evidence as to
whether agents of respondent were supervising the operation of the bulldozer,
it was agreed that agents of respondent were generally instructing the National
Guard as to which roads in Preston County the latter should devote their snow
removal operations.
In line with our reasoning in the recently decided claim of Hubbs v. Department of Highways, Claim No. CC-77-83, we believe that liability for this
damage must rest with the responent. Claimant testified that when the damage
occurred, the cost of a new boom for the power loader was $400.00, and we
therefore make an award to claimant in that amount.
Award of $400.00.
Opinion issued December 12, 1977
PHYLLIS J. RUTLEDGE, CIRCUIT CLERK
OF KANAWHA COUNTY, W.VA.
vs.
OFFICE OF THE STATE AUDITOR
(No. CC-77-77)
No appearance by claimant.
Gregory W. Bailey, Assistant Attorney General, for respondent.
PER CURIAM:
The claimant, Phyllis J. Rutledge, Circuit Clerk of Kanawha County, West
Virginia, filed a claim in the amount of $314.00,
W. VA.] REPORTS
STATE COURT OF CLAIMS 57
representing the fees incident to instituting the suit of State of W.Va. vs.
AAA Building, Inc., et al. The Answer filed by the respondent admits the
validity of the claim and that there were sufficient funds for the fiscal year
in question from which the claim could have been paid, but it was not paid due
to an oversight. Therefore, it is the opinion of the Court, on the basis of the
pleadings, that this claim in the amount of $314.00 should be allowed.
Award of $314.00.
Opinion issued December 22, 1977
RAYMOND N. BELMONT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-84)
Raymond N. Belmont, the claimant, in person.
James W. Wit hrow, Attorney at Law, for the respondent. PER CURIAM:
Upon stipulation of the parties to the effect that employees of the respondent,
while directing traffic, negligently instructed the claimant to proceed across
a road onto which respondent?s employees had just dumped a substance known as
?reddog?; that those instructions, when followed by the claimant, caused the
claimant to receive two flat tires on his vehicle; and that $80.00 is a fair
and equitable estimate of the value of those damages, an award in that amount
should be, and is hereby, made.
Award of $80.00.
58 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued December 22, 1977
CECIL E. JACKSON EQUIPMENT, INC.
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-77-97)
Jack Turney, Attorney at Law, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
RULEY, JUDGE:
This claim was submitted upon the pleadings by agreement of the parties. In its
Amended Answer, the respondent admits the validity of the claim and represents
to the Court that sufficient funds remained in the respondent?s budget from
which the claim could have been paid. Accordingly, the claimant?s request for
$415.24 in payment for goods sold and delivered is granted.
Award of $415.24.
Opinion issued December 22, 1977
VIRGINIA SUE COOK
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-144)
Virginia Sve Cook, the claimant, in person.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
Upon stipulation of the parties to the effect that, on the 13th of July, 1977,
an employee of the respondent, while removing debris from a right of way,
negligently threw a rock against the claimant?s vehicle, breaking the
windshield, and that the claimant?s vehicle thereby was damaged in the amount
of $112.27, an award in that amount should be, and is hereby, made.
Award of $112.27.
W. VA.] REPORTS
STATE COURT OF CLAIMS 59
Opinion issued December 22, 1977
JOHN F. CUMMINGS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-77)
John F. Cummings, the claimant, in person.
Richard Canton, Attorney at Law, for the respondent.
RULEY, JUDGE:
On Thursday evening, June 17, 1976, an automobile owned by the claimant and
operated by the claimant?s wife struck a hole in the inside, eastbound lane of
Route 1-70 between the Wheeling Tunnel and the Elby off-ramp, sustaining damage
for which the claimant seeks $120.90.
This accident involves the same pothole which was involved in the case of Hoskins v. Department of Highways, 12 Ct. Cl 60 (1977). That case is controlling. The
evidence clearly indicates that the hole appeared suddenly and without warning.
Proof of actual or constructive notice is a prerequisite to establishing
negligence on the part of the respondent. Davis
v. Department of Highways, 12 Ct. Cl.
31 (1977); Hoskins, supra. Respondent did not have notice of this particular hole
in the road in time to take action to prevent this accident. Since negligence
is, therefore, not shown, and since the State is neither an insurer nor a
guarantor of the safety of motorists on its highways (Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 [1947]), this claim must be denied.
Claim disallowed.
60 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opirnon issued December 22, 1977
PATRICIA S. HOSKINS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-79)
Patricia S. Hoskins, the claimant, in person.
Nancy J. Norman, Attorney at Law, for the respondent. RULEY, JUDGE:
On Thursday evening, June 17, 1976, an automobile driven by the claimant struck
a large hole in the inside, eastbound lane of Route 1-70, just beyond the
Wheeling Tunnel. The claimant alleges that respondent?s negligence caused the
resulting damage to her vehicle, and seeks an award in the amount of
$181.75.
Although this case closely resembles Davis
Auto Parts v. Department of Highways, 12
Ct. Cl. 31 (1977), one essential element of proof in Davis is not
present in this case. In Davis, the evidence indicated that the defect in Route 1-64
had been present for at least 15 hours prior to that accident; in this case,
the hole apparently came into existence within an hour of the accident.
Although the respondent?s duty of ?reasonable care and diligence in the
maintenance of a highway under all the circumstances? (Parsons v. State Road Commission, 8 Ct. Cl. 37 [1969]) may require respondent to put
greater effort into the maintenance of superhighways than in the maintenance of
lesser-travelled country roads (Davis,
sup?ra, and Bartz v. Department of Highways, 10 Ct. Cl. 170 [19751), proof of actual or constructive
notice is rcquired in all cases. Davis,
supra, Lowe v. Department of Highways, 8
Ct.Cl. 210 (1971), Varner v.
Department of Highways, 8 Ct. Cl. 119
(1970). Such proof, found in Davis, cannot be found in the record in this case. To the
contrary, the evidence indicates that the dangerous condition appeared
suddenly, and that the respondent promptly moved to take safety precautions as
soon as it became aware of the problem. Since negligence is not proved, and
since Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947), holds
W. VA.] REPORTS
STATE COURT OF CLAIMS 61
that the State is neither an insurer nor a guarantor of the safety of motorists
on its highways, this claim must be denied.
Claim disallowed.
Opinion issued December 22, 1977
DANIEL LEWIS LIGHT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-53)
Daniel Lewis Light, the claimant, in person.
Richard Canton, Attorney at Law, for the respondent.
RULEY, JUDGE:
In late March, 1977, an automobile owned and operated by the claimant struck a
pothole on Route 19 between Morgan- town and Westover, bending the rim of the
right front wheel, causing a flat tire, breaking a shock absorber, and knocking
the front end out of alignment, for which the claimant seeks $131.00 in
damages.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645, 46 S.E.2d 81
(1947). For negligence of the Department of Highways to be shown, proof that
the respondent had actual or constructive notice of the defect in the road is
required. Davis Auto Parts v.
Department of Highways, 12 Ct. Cl. 31
(1977); Lowe v. Department of
Highways, 8 Ct. Cl. 210 (1971); Varner v. Department of Highways, 8 Ct. Cl. 119 (1970). There is no evidence in the
record of any notice to the respondent, and the simple existence of a defect in
the road does not establish negligence per se. See Bodo v. Departmeiit of Highways, 11 Ct. Cl. 179 (1977), and Rice v. Department of Highways, 12 Ct. Cl. 12 (1977). This claim must be denied.
Claim disallowed.
62 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued December 22, 1977
ANNA JANE PHILLIPS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-131)
Anna Jane PhiUips, the claimant, in person.
Richard Car iton, Attorney at Law, for the respondent.
PER CURIAM:
Upon stipulation of the parties to the effect that a flagman, employee of the
respondent, directed the claimant to drive her automobile around a repair site
and between an asphalt truck and a barricade; that claimant objected,
contending that the gap was too small to accommodate her vehicle; that the
flagman, over her objections, negligently caused her to proceed; that the
claimant?s car then came into contact with the barricade, damaging the vehicle;
and that the amount of $82.40 represents full and fair compensation to the
claimant for the damages, an award in that amount should be, and is hereby,
made.
Award of $82.40.
Opinion issued December 22, 1977
S. B. WALLACE & COMPANY
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-77-119)
S. B. Wallace & Company, a corporation, the claimant, by Lee A. Smith, President.
Frank M. Eflison, Deputy Attorney General, for the respondent.
RULEY, JUDGE:
This claim was submitted upon the pleadings by agreement of the parties. The
respondent admits in its Answer that four
W. VA.] REPORTS
STATE COURT OF CLAIMS 63
invoices or bills for goods sent by claimant to the respondent represent valid
claims in the total amount of $157.49, and that funds were available in
respondent?s budget to pay for those goods. The claim for the fifth invoice, in
the amount of $8.24, is barred by the five-year statute of limitations set
forth in West Virginia Code ?55-2-1. Accordingly, an award in the amount of
$157.49 should be, and is hereby, made.
Award of $157.49.
Opinion issued December 22, 1977
MARIE T. SADD
vs.
DEPARTMENT OF HIGHWAYS
No. CC-77-36)
Marie T. Sadd, the claimant, in person.
James W. Wit hrow, Attorney at Law, for the respondent. RULEY, JUDGE:
On Monday, February 28, 1977, while travelling north on Route 62 past the Route
34 intersection, the claimant drove her automobile off her right-hand side of
the pavement of the highway into a ditch, damaging the vehicle. The claimant
alleges that the accident was caused by the allegedly negligent design of the
highway, which narrows to the left at the place where the accident occurred.
Narrow, winding roads are a fact of life in the State of West Virginia. See Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). Recognizing the nature of the
State?s terrain and the constraints inherent in a limited budget, our Courts
have long held that the State is neither an insurer nor a guarantor of the
safety of persons travelling on its roads. Adkins, supra, and Lowe v. Department of Highways, 8 Ct.C1. 210 (1971). Establishing liability on the part
of the Department of Highways requires proof of a violation of the respondent?s
duty of ?reasonable care and diligence in the maintenance of a high-
64 RE-PORTS STATE
COURT OF CLAIMS [W. VA.
way under all the circumstances.? Parsons
v. State Road Commission, 8 Ct. Cl.
35, 37 (1969). No proof of negligence exists in the case at hand. Although the
road did narrow at the point of the accident, the respondent had 15
miles-per-hour speed limit signs posted, and another sign warning motorists of
a bump in the road near the accident site. There were no defects in the
pavement. A motorist travelling at the posted speed limit, exercising any
moderate degree of care, should have encountered no difficulties while
travelling along Route 62. The respondent met its required standard of care,
and was not negligent. Accordingly, this claim must be denied.
Claim disallowed.
Opinion issued December 22, 1977
TRAVENOL LABORATORIES, INC.
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-77?91)
Travenol Laboratories, Inc., the claimant, by Charles Bordo, its agent.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
RULEY, JUDGE:
This claim was submitted upon the pleadings by agreement of the parties. The
parties agree that the respondent paid the claimant for pharmaceutical products
at old prices instead of new ones, when the price agreement between the parties
provides that prices are subject to change. The respondent?s Amended Answer
also admits that there were sufficient funds remaining in the respondent?s
budget from which this claim could have been paid. Accordingly, claimant is
entitled to an award in the amount of $53.52, representing the amount of the
price increase.
Award of $53.52.
W. VA.] REPORTS
STATE COURT OF CLAIMS 65
Opinion issued January 6, 1978
FRANK G. BARR
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-141)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimant is the owner of an 8-acre tract of land which abuts on the Cool
Spring-Mount View Road, a road which is maintained by respondent. The property
is located about 8 miles south of Morgantown and is used by the claimant for
gardening and pasture land. During January and February, 1977, approximately
1200 feet of claimant?s fence were damaged as the result of snow plowing to
remove the heavy accumulation of snow on Cool Spring-Mount View Road along
which the 1200 feet of fence ran. The fence was of woven wire with a single
strand of barbed wire on the top, and the fence posts were spaced about 10 feet
apart. The claimant did not indicate that the fence had been struck by any snow
plowing equipment, but he was of the opinion that the tremendous volume of
snow, with its attendant weight, was pushed into and against the fence and
caused the damage. The claimant testified that he had obtained an estimate in
the amount of $595.68 for the repair of his fence.
Claimant testified that the snow removal was conducted by employees of
respondent and its authorized personnel. Upon being asked what he meant by
authorized personnel, the claimant testified that he was referring to one
Raymond Dalton, who was a neighbor of his, engaged in the timber business but
employed by respondent to assist in the snow removal. The claimant was unable
to state that any of respondent?s employees were directing Dalton?s activities.
Fred Siegwarth, a general foreman for respondent, testified that Dalton had
been hired by respondent to assist in the heavy snow removal because he had the
necessary equipment, unavailable to respon
66 REPORTS STATE
COURT OF CLAIMS [W.VA
dent. He further testified that no personnel of respondent worked with Dalton,
nor was he supervised by personnel of respondent.
Whether the damage to claimant?s fence was caused by respondent?s employees or
by respondent?s independent contractor, Raymond Dalton, we are of the opinion,
based on this Court?s reasoning in the claim of Hubbs vs. Dept. of Highways, Claim No. CC-77-83, that the liability for the damage
rests upon respondent. We therefore make an award in favor of claimant in the
amount of $595.68.
Award of $595.68.
Opinion issued January 6, 1978
CHARLES A. BOWMAN
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-137)
Claimant appeared in person.
Gregory W. Evers, Attorney at Law, for respondent. GARDEN, JUDGE:
On June 29, 1977, around 1:00 p.m., the claimant was proceeding from his home
in Alum Creek to the Big Bend Golf Course and was travelling on the Coal River
Road near the Tornado Bridge. He was operating his 1975 Dodge van. Before
reaching the Tornado Bridge, he was stopped in a line of traffic by one of
respondent?s flagmen. The road at this point was a narrow, two-lane road of
asphalt construction. After being motioned to proceed and after he had passed
the flagman, the claimant discovered for the first time that respondent had
placed tar on both lanes of the road, and for a distance of about 100 yards, he
was forced to drive his van through this tarred area. Prior to getting into
this tarred area, he had not been warned of the condition of the road by
warning signs or other means.
W. VA.] REPORTS
STATE COURT OF CLAIMS 67
As a result of the foregoing, the claimant?s van was heavily splashed with tar.
He proceeded to Big Bend and played golf, but, upon his return home some 5 or 6
hours later, he attempted to remove the tar with the use of gasoline and
kerosene, but to no avail. Subsequently, the tar was removed by the Royal
Oldsmobile Company of Charleston at a cost of
$154.50.
The respondent called Lewis Caruthers, Jr., the respondent?s foreman on this
particular project, who admitted that respondent had done the tarring on the
road on or about the date in question. He further testified that he had
successfully removed similar tar from vehicles with the use of diesel fuel, if
the same was used shortly after the tar had become applied. We, of course,
agree that the claimant is under a legal duty to minimize his damage, but we do
not feel that the claimant?s efforts to remove the tar were unreasonable. We
are of the further opinion that respondent?s failure to warn the claimant of
the presence of this tar or its failure to tar only one lane of traffic at a
time constituted negligence. We therefore make an award in favor of the
claimant in the amount of $154.50.
Award of $154.50.
Opinion issued January 6, 1978
ELEANOR F, CHARBENEAU
& ELEANOR B. CHARBENEAU
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-73)
The claimants appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimants, Eleanor F. Charbeneau & Eleanor B. Charbeneau, mother and
daughter, are the joint owners of a farm located in the rural area of Marshall
County. The property
68 REPORTS STATE
COURT OF CLAIMS [W, VA.
was subjected to heavy snowfalls during January and February of 1977, to the
extent that the State-maintained road which bisected their farm became
unpassable. One day early in February, the claimants observed a bulldozer
attempting to plow the road, and the man who was operating the bulldozer came
to their home to inquire about the condition of other roads in the area. During
the conversation that ensued, the claimants received the definite impression
that he was employed by respondent.
Later the same day while walking out to the road to pick up their mail, the
claimants observed that the bulldozer had driven off the right-of-way and onto
their property, and, in so doing, had destroyed 227 feet of fencing, a 16-foot
gate, and 30 fence posts. They presented an estimate in the amount of
$253.45 for the repair of the damage. They also testified that as a result of
the damage, they were unable to rent a portion of the farm to third parties for
pasturing purposes, and thus lost income. They testified that they were not
seeking recovery of this loss, but were seeking only sufficient funds to enable
them to restore the fence line. Moreover, their testimony relating to the loss
of income was too speculative to support an award for this item of damage.
Arnold Rush, a foreman of respondent in the Marshall County area, testified
that respondent had hired Mountaineer Excavation of Moundsville to assist
respondent in bulldozing roads, and that, while he couldn?t be sure, he was of
the opinion that Mountaineer Excavation equipment did work in the area of the
claimants? property.
Under these facts, we are of the opinion that the claimants are entitled to an
award in accordance with the Court?s opinion in the recently decided claim of Hubbs v. Dept. of Highways, Claim No. CC-77-83, and an award is thus made to
claimants in the amount of $253.45.
Award of $253.45.
W. VA.] REPORTS
STATE COURT OF CLAIMS 69
Opinion issued January 6, 1978
BRADFORD G. FRAZIER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-201)
No appearance on behalf of claimant.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted for decision on the agreed facts set forth in a
written stipulation, which revealed the following:
that on September 19, 1977, respondent was engaged in the repair of a portion
of 1-64 near the Ona Exchange and had routed traffic on 1-64 onto the exit ramp
at the exchange; that respondent had knowledge of a large hole on the paved
portion of the ramp but had made no repairs and had failed to erect any warning
signs; that on September 19, 1977, at about 6:30 a.m., the claimant was
directed onto the ramp by respondent; that the claimant was exercising due care
but did not observe the hole until it was impossible to stop and avoid striking
the same; and that as a proximate result of respondent?s negligence, the
claimant?s vehicle struck the hole and was damaged to the extent of $160.48. By
reason of the foregoing, and believing that the amount of damages is fair and
reasonable, we hereby make an award in favor of the claimant in the amount of
$160.48.
Award of $160.48.
70 REPORTS STATE
COURT OF CLAIMS [W. VA.
0ptnon tssued January 6, 1978
H. M. HILLS, JR.
& LUIS A. LOIMIL
vs.
DEPARTMENT OF PUBLIC SAFETY
(No. CC-77-200)
No appearance on behalf of claimants.
Frank M. Eflison, Deputy Attorney General, for respondent. PER CURIAM:
The claimants are medical doctors practicing their profession in Charleston,
West Virginia. From March 25, 1976, through June 14, 1976, they rendered
professional services to Trooper Lloyd Aker, who had been injured in the line
of duty. They submitted their statement to the Workmen?s Compensation Fund but
were later advised that the statement should be submitted to respondent, who is
liable for medical bills of members of the Department injured in the line of
duty. Respondent refused to pay the statement because it was submitted well
after the close of the fiscal year during which the services were rendered. The
Answer filed by respondent admits the validity of the claim and that the
claimants are entitled to payment; we accordingly make an award in favor of the
claimants in the amount of $105.00.
Award of $105.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 71
Opinion issued January 6, 1978
SANDERS FLOOR COVERING, INC.
vs.
BOARD OF REGENTS
(No. CC-77-74)
Elbert E. Sanders, President, Sanders Floor Covering, Inc., appeared for
claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant, Sanders Floor Covering, Inc., filed its claim in the amount of
$1,819.00 for the installation of Bigelow carpet in the office and conference
room of the School of Pharmacy at West Virginia University. The claimant
installed the carpet on June 23 and 24, 1976, pursuant to a purchase order
issued to it dated June 8, 1976. On June 26, 1976, the claimant received a
cancellation of the purchase order from West Virginia University, which
cancellation was dated June 16, 1976.
The respondent acknowledged receipt of the carpeting as installed and in its
Answer admits that there were sufficient funds to pay the purchase order.
The Court is of the opinion that the claimant is entitled to payment;
accordingly, an award of $1,819.00 is made in favor of the claimant.
Award of $1,819.00.
72 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued January 6, 1978
THOMPSON?S OF MORGANTOWN, INC.
vs.
BOARD OF REGENTS
(No. CC-77-177)
No appearance on behalf of claimant.
Frank M. EUison, Deputy Attorney General, for respondent. PER CURIAM:
The claimant, on June 26, 1976, being the low bidder, was awarded a contract
for the installation of a quantity of furniture at the West Virginia University
Medical Center. Claimant thereafter delivered and installed the furniture and
invoiced respondent in August, 1976, in the amount of $901.77. Payment was not
received, and upon inquiry, claimant was advised that the order had been
cancelled. Claimant denies having received any cancellation order and has filed
this claim seeking payment of $901.77 and 1% per month service charge. We, of
course, cannot consider the service charge claim, being prohibited by statute
from awarding interest on claims, but the Answer filed by respondent having
admitted the validity of the claim and that claimant is entitled to payment, we
hereby make an award in favor of the claimant in the amount of $901.77.
Award of $901.77.
W. VA.) REPORTS
STATE COURT OF CLAIMS 73
Opinion tssued January 6, 1978
MARVIN ROY WELCH
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-184)
Robert G. Wolpert, Attorney at Law, for claimant.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
The claimant and respondent, by counsel, have filed a written stipulation in
this claim which reveals the following:
that the respondent, on August 30, 1977, owned and maintained a one-lane
bridge, No. 20-45-5.20, over Little Sandy Creek on State Route 45 near Elkview
in Kanawha County; that on the above-mentioned date the claimant, while
exercising due care, drove his vehicle upon the bridge, and the vehicle ran
over a loose piece of sheet metal which had been negligently installed by
respondent?s employees; that as a result, the claimant?s vehicle sustained
damage to the extent of $99.98; that $49.98 was paid to claimant by his
collision carrier, and the remaining $50.00 of the damage was paid by the
claimant.
Believing that liability exists and that the damages are reasonable, an award
is hereby made to claimant in the amount of $50.00.
Award of $50.00.
74 REPORTS STATE
COURT OF CLAIMS [W. VA.
Advisory Opinion issued January 17, 1978
EDWARD L. NEZELEK, INC.
vs.
DEPARTMENT OF FINANCE & ADMINISTRATION
AND DEPARTMENT OF HEALTH
(No. CC-78-2)
James K. Brown, Attorney at Law, for Edward N. Nezelek, Inc.
Henry C. Bias, Jr., Deputy Attorney General, for petitioner. RULEY, JUDGE:
Pursuant to the provisions of West Virginia Code, Chapter 14, Article 2,
Sections 13(3) and 18, Miles E. Dean, Commissioner of the Department of Finance
and Administration, has filed a petition seeking an advisory determination
respecting the claim of Edward L. Nezelek, Inc., a corporation, based upon the
following facts.
By a duly executed purchase order dated August 20, 1976, the Department of
Mental Health (now the Department of Health) entered into a contract with
Nezelek by which Nezelek became obligated to complete the first phase of
construction of a Central Mental Health Complex near Pocatalico in Kanawha
County for the sum of $5,851,000.00. The total cost of the project was estimated
to be $25,000,000 to $30,000,000 excluding the cost of necessary roads and
bridges. It is undisputed that the parties entered into the contract in good
faith. The contract provided that it was to be performed within 470 working
days after August 20, 1976. Several months later, an administrative
determination to the effect that the contract should be cancelled was made, and
that determination was communicated to Nezelek by letter dated March 4, 1977,
from Mr. Dean. The reasons assigned for such determination were: that the
isolated location of the complex was not suitable for its intended purpose and
was in
conflict with the concept of community
health centers that were being constructed in other parts of the state: that
the location was not served by water, sewer, or other utilities; that the
location was not served by a public means of transporta
W. VA.] REPORTS
STATE COURT OF CLAIMS 75
tion; that the location would have required road construction involving two
river crossings estimated to cost $5,300,000; and that the nature of the
commitment, once the project was under way, was substantially greater than that
which had been either contemplated or funded. Notwithstanding those reasons, it
is the opinion of this Court, and it is conceded by the petitioner and the
Agencies involved, that the cancellation constituted a breach of contract
entitling Nezelek to recover its resulting damages. By the time the contract
was cancelled, Nezelek had entered subcontracts for various parts of the work
and materials which have resulted in obligations from it to thirty-four
different subcontractors. Litigation in prosecution of some of those
subcontract claims presently is pending against Nezelek. Nezelek had been paid
the sum of $164,589.00 for part of its work done before the contract was
cancelled. Specifically, the petitioner now seeks an advisory determination
approving payment of a settlement or compromise in the sum of $439,004.92,
which has been negotiated with Nezelek subject to such approvaL It appears that
such sum is substantially less than Nezelek would seek to recover if it were
prosecuting its claim in this Court. It has been estimated reliably that
Nezelek will expend $355,604.92 in settling the claims of its subcontractors,
and, if that is correct, it will leave $83,400.00 to Nezelek for its own costs
and expenses. In any event, it has been acknowledged that Nezelek will have the
sole responsibility for settling subcontractors? claims. The applicable measure
of damages is set forth in 3A Michie?s Jurisprudence, ?Building Contracts?,
?30, pages 494-5, as follows:
?A contractor under a building contract who, after having performed a portion
of the contemplated work, is prevented from completing the same by the owner,
or is justified in his abandonment thereof by the owner, may recover not only
the value of the labor and materials bestowed upon the property and expenses
necessarily incident to the work done and provided for in the contract, but
also such profits as he could have made if he had been permitted to complete
the work.?
The Court does not have before it all of the facts necessary to apply that
measure to this case, but it certainly appears prob
76 REPORTS STATE
COURT OF CLAIMS [W. VA.
able and it is the plain representation of the petitioner that the sum thus
computed would exceed the proposed settlement. Accordingly, it is the
determination of this Court that the approval sought by the petitioner should
be, and it is hereby, granted, and the petitioner is advised that the sum of
$439,004.92 should be paid to Nezelek in full discharge of all obligations
under the contract. The Clerk is directed to file this advisory opinion and to
transmit a copy thereof to petitioner.
Advisory Opinion issued February 9, 1978
ALERT SANITATION
vs.
OFFICE OF THE GOVERNOR?
EMERGENCY FLOOD DISASTER RELIEF
(No. CC-77-156)
No appearance on behalf of claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. GARDEN, JUDGE:
As an aftermath of the tragic flood in Williamson, West Virginia, in April of
1977, the respondent rented one small and seven large portable toilets from
claimant. After the emergency, the claimant proceeded to Williamson to recover
the toilets, but was unable to locate them. Subsequently, one of the large
toilets was located and returned to claimant. The six missing large toilets had
a fair market value of $350.00 each, nd the small toilet had a fair market
value of $250.00. Respondent has filed an Answer admitting the validity of the
claim, and has requested an advisory opinion of this Court pursuant to Code
14-2-13 (3).
We are of the opinion that as a result of the unlawful conversion of these
toilets by the respondent, the claimant is legally entitled to be reimbursed
for their fair market value of $2,350.00, which amount we believe should be
paid by respondent to claimant. The Clerk is directed to file this advisory
opinion and to transmit a copy thereof to respondent.
W. VA.] REPORTS
STATE COURT OF CLAIMS 77
Opinion issued February 9, 1978
ELWOOD CLARK, ADMIN. OF THE ESTATE
OF SHARON MARIE CLARK, DEC.
vs.
STATE FIRE MARSHAL
(No. CC-76?102)
WiUiam B. Carey, Attorney at Law, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
RULEY, JUDGE:
Claimant?s decedent was killed in a fire which destroyed the Washington House
Hotel at Berkeley Springs, West Virginia, on the night of August 24-25, 1974.
Claimant alleges that respondent?s failure to inspect the hotel and cause it to
cease operations constituted negligence and was the proximate cause of the fire
and death. Claimant seeks damages for the alleged wrongful death under the
provisions of West Virginia Code 55-7-5 and 6. Respondent has moved to dismiss,
contending that
the claim is barred by the two-year period
of limitation set forth in West Virginia Code ?55-7-6.
Claimant?s decedent died on August 25, 1974. Thus, under Code ?55-7-6, the
claim had to be filed on or before August 25, 1976. Claimant?s attorney
commenced this proceeding by mailing the Notice of Claim to the Clerk of this
Court by special delivery on August 23, 1976. However, the Clerk did not
receive the Notice of Claim until September 2, 1976, eight days after the
expiration of the statutory period. Although the postal service may have caused
the claim to be filed after August 25, this Court cannot ignore the statutory
requirement that the Notice of Claim ?be filed with the clerk? within the
appropriate period. Code, ?14-2-21. See also Huntington Steel & Supply
Company v. West Virginia State Tax Commissioner, 8 Ct. Cl. 123. Timely filing
of a claim with the Clerk is clearly the responsibility of claimant or
claimant?s attorney, who may choose any method of delivery he considers
expeditious. In this case, the failure of the postal service to deliver the
Notice
78 REPORTS STATE
COURT OF CLAIMS [W. VA.
of Claim within three days, although regrettable, does not provide any legal
ground for this Court to deny respondent?s motion to dismiss.
Claimant also contends that the period of limitation was tolled by at least one
of two extraordinary circumstances in this case. The first involves the
incapacity of decedent?s mother. West Virginia Code ? 55-7-6
provides that only the personal representative of the deceased may bring an
action for wrongful death. See Silvious
v. Helmick, 291 F. Supp. 716
(N.D.W.Va., 1968). Only a distributee can be appointed administrator within the
first thirty days after the death of a person dying intestate. West Virginia
Code ?44-1-4. Under the wrongful death statute in effect at the time of the
fire, distributees were to be determined by the statute of descent, Code,
?42-1-1. At the time of her death, the decedent?s sole distributee was her
mother. But her mother was mentally incapacitated. Thus, claimant contends that
the mother?s disability tolled the statute at least for the thirty days
immediately following the death, under the provisions of West Virginia Code ? 55-2-15,
entitled ?General savings as to persons under disability?.
The second extraordinary circumstance is the delay in appointing an
administrator for decedent?s estate. The administrator, decedent?s brother, was
not appointed until April 8, 1976, less than four months before the period of
limitation expired. Citing the general proposition from 28 A.L.R.3d 1144 that
?an action cannot be maintained until there is a person in being capable of
suing?, claimant argues that the period was tolled until the administrator was
appointed.
Claimant?s arguments treat the limitation period in West Virginia Code ?55-7-6
like a statute of limitation. Since Lam-
bert v. Ensign, 42 W.Va. 813 (1896),
West Virginia courts have refused to apply any of the Code provisions which
would toll a statute of limitation to the two-year period of limitation in the
wrongful death statute.
?8? *
* the cause of action (wrongful death)
did not exist at common law but is created by statute. The bringing of the suit
within two years *
* * is made an essential element of the
right to sue, and it must be accepted in all
W. VA.]
REPORTS STATE COURT OF CLAIMS 79
respects as the statute gives it. And
it is made absolute, without saving or qualification of any kind whatever.
There is no opening for explanation or excuse. Therefore, strictly speaking, it
is not a statute of limitations.? Lam-
bert, supra.
Since the period of limitation is
viewed, not as a limit on the remedy, but as a condition on a statutory right
to sue, there are no exceptions to its application. ?The two year limitation on
commencing an action for wrongful death is an integral part of the cause of
action, and statutes in derogation of common law will be strictly construed?
(citations omitted). Rosier v. Garson,
156 W.Va. 861, 199 S.E.2d 50 (1973).
Thus, in Rosier and in Smith
v. Eureka Pipe, 122 W.Va. 277, 8
S.E.2d 890 (1942), the provisions of Code, ?55-2-18, (granting the right to
institute a new action within one year after an order, not on the merits,
disposing of a pending action) were held not to apply to wrongful death
actions. By analogy, Code, ?55-2-15, does not apply to wrongful death actions,
and the incapacity of the decedent?s mother does not extend the period of
limitation. Similarly, following the logic of Smith, Rosier, and Lambert, this
Court cannot change the law and toll the period of limitation until an
administrator is appointed. Most jurisdictions reach a similar conclusion
regarding administrators. See 70 A.L.R. 472. For additional discussions
relating to conditions and limitations on wrongful death actions, see 132
A.L.R. 292 and 67 A.L.R. 1070.
The motion to dismiss is granted.
Claim dismissed.
80 REPORTS
STATE COURT OF CLAIMS [W. VA.
Opinion issued February 9, 1978
ECONO-CAR INTERNATIONAL, INC.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-32)
Robert J. Louder back, Attorney at Law, for claimant. Gregory W. Evers, Attorney at Law, for respondent.
GARDEN, JUDGE:
On April 26, 1974, one Ronald Keller was operating claimant?s 1973
International tractor-trailer at and near the junction of Route 460 and
Interstate 77 near Princeton, West Virginia. At this point, Keller, who had
been driving for about 3? hours, decided to rest and make some entries in his
driver?s log. He proceeded onto the one-lane entrance ramp to Interstate 77,
and, observing a wide berm of crushed stone to his right, he drove his unit
onto the berm. In so doing, five of the tires on the right side of his
tractor-trailer were damaged when they passed over a stub of a metallic post
which extended out of the crushed stone berm some two or three inches. No
evidence was introduced to indicate who was responsible for placing this metallic
object in the berm, but the implication was clear that Vecellio & Grogan, a
Beckley highway contractor who had constructed the subject interchange, was
responsible. Damage to the tires in a total amount of $669.75 was stipulated by
claimant and respondent.
The evidence revealed that the contract for this project, which bore Project
Name ?1-77 & U.S. 460 Interchange?, was awarded by respondent to Vecellio
& Grogan on April 4, 1972, and work on the same commenced on May 22, 1972.
Through Ralph Beckett, an engineer employed by Vecellio & Grogan, the
claimant introduced into evidence respondent?s Form HL416 entitled ?Contract
Completion Report?. This form, which was dated April 16, 1974, clearly reflects
that the contract was completed on December 7, 1973, and this date of
completion was further confirmed by the testimony of Mr. Beckett. This witness
further established that as of December 7, 1973, Vecellio
W. VA.]
REPORTS STATE COURT OF CLAIMS 81
& Grogan had removed all of its
equipment from the project site, and that the interchange had been opened to
public travel. The claimant thus contends that since the subject incident
occurred five months after Vecellio & Grogan had completed the project and five
months after the interchange had been opened to the public, the respondent is
liable for the damage to its equipment.
On the other side of the coin, the respondent vigorously contends that while
the contractor, Vecellio & Grogan, may have completed the construction on
December 7, 1973, the contract or project was not finally accepted by the
respondent until May 2, 1974, a date subsequent to the subject incident; thus,
any liability must rest upon Vecellio & Grogan. David Murphy, the Finals
Engineer for the Construction Division of respondent, testified that it was his
responsibility to determine the amount of final payment to contractors and
whether the project had been completed in accordance with the plans and
specifications. Mr. Murphy testified that the Contract Completion Form was
prepared by personnel in respondent?s District 10 office on April 16, 1974, who
then forwarded it to the respondent?s Charleston office, where it was approved
and signed by the Director of the Construction Division and then finally
approved by the State Highway Engineer on May 2, 1974. Although the exact date
in May does not clearly appear on the form introduced into evidence, Mr.
Murphy, testifying from other official records from his office, clearly
established that the form was approved and signed by the State Highway Engineer
on May 2, 1974. Immediately above the State Highway Engineer?s signature, the
following language appears:
?The contractor having completed the contract on the above project, the
Commissioner, upon the recommendation and approval as shown hereon, hereby
accepts said contract and releases said contractor from any further
responsibility in connection therewith.?
We believe that the above-quoted language is clear and unambiguous, and that
while a delay of almost five months between the completion date and the date of
final acceptance by respondent casts a burden on the contractor, we do not feel
82 REPORTS STATE
COURT OF CLAIMS [W. VA.
that the respondent can be held liable for the negligent maintenance of this
particular section of highway until May 2, 1974. For this reason, we refuse to
make an award in favor of the claimant.
Claim disallowed.
Advisory Opinion issued February 9, 1978
ROBERT L. MASSIE
and MAE MASSIE
vs.
OFFICE OF THE GOVERNOR?
EMERGENCY FLOOD DISASTER RELIEF
(No. CC-77-199)
No appearance on behalf of claimants.
Frank M. Ellison, Deputy Attorney General, for respondent. GARDEN, JUDGE:
Pursuant to Code ?14-2-13 (3), the respondent has requested this Court to
render an advisory opinion in respect to the following factual situation: In
April of 1977, during the cleanup following the devastating flood in
Williamson, West Virginia, a contractor employed by respondent damaged the
residence of the claimants when a piece of the contractor?s Hi Lift equipment
struck the rear of the residence. The claimants incurred a bill in the amount
of $465.00 to have the damage repaired. The respondent has filed an Answer
which, in effect, admits the existence of liability and that the amount of damage
is reasonable.
We agree that liability exists, and we are of the opinion that respondent
should pay damages to the claimants in the amount of $465.00. The Clerk is
directed to file this advisory opinion and to transmit a copy thereof to
respondent.
W. VA.] REPORTS
STATE COURT OF CLAIMS 83
Advisory Opinion issued February 9,
1978
ALEX RAY
vs.
OFFICE OF THE GOVERNOR?
EMERGENCY FLOOD DISASTER RELIEF
(No. CC-77-192)
No appearance on behalf of claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. GARDEN,
JUDGE:
The respondent, pursuant to Code ?
14-2-13(3), has requested the Court to
render an advisory opinion as to the legal status of this claim which arises
from the following factual situation.
Following the devastating flood in Williamson, West Virginia, on April 4, 1977,
the respondent engaged the services of Burgett Construction Company to assist
in cleaning up the resultant debris. During this operation, an employee of
Burgett, while operating an endloader, destroyed a wall and gate at the rear of
the claimant?s property. The wall was constructed of concrete block and was 30
feet long and 4 feet tall. An estimate in the amount of $1,175.00 for the
replacement of the wall and gate was presented. The respondent has filed an Answer
admitting liability for the damage and asserting that the claim should be paid.
We agree that under the factual situation set forth above, liability rests with
respondent, and it should respond in damages to claimant in the amount of
$1,175.00. The Clerk is directed to file this advisory opinion and to transmit
a copy thereof to respondent.
84 REPORTS STATE
COURT OF CLAIMS [W. VA.
Advisory Opinion issued February 9,
1978
WEST VIRGINIA
PUBLIC EMPLOYEES INSURANCE BOARD
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-77-172)
Cletus B. Hanley, Attorney at Law, for the claimant.
Frank M. Ellison, Deputy Attorney General, for the respondent.
PER CURIAM:
The claimant seeks to recover the sum of $5,563.68, representing the premium
due from the Department of Motor Vehicles to the West Virginia Public Employees
Insurance Board for the month of June, 1977. The Answer admits the validity of
the claim, and the case was submitted upon the pleadings. However, in the
Notice of Claim filed on September 15, 1977, it is stated that ?there were
insufficient moneys in the proper account to pay this sum for the last fiscal
year?. Following the precedent of Airkem
Sales and Service, et al. v. Department of Mental Health., 8 W.Va. Ct. Cl. 180 (1971), the Court must deny the
claim.
Claim disallowed.
Opinion issued February 10, 1978
CURTIS ALLISON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-11O)
No appearance by claimant.
Richard Cctrlton, Attorney at Law, for respondent.
PER CURIAM:
The parties have filed a written stipulation with the Court in which they have
stipulated that the respondent maintained
W. VA.] REPORTS
STATE COURT OF CLAIMS 85
State Route 3 near Gap Mills, West Virginia, in Monroe County, and that the
claimant owns and operates a service station, restaurant, and grocery store at
the foot of an upgrade on State Route 3. The respondent constructed and
maintains two culverts under the road, the first of which was inadequate to
carry off the overflow from heavy storms. It was further stipulated that the berm
of the road was negligently constructed so that it was elevated above the
blacktopped portion of the highway. Water from the first culvert eroded a ditch
in the berm, causing the surface water to bypass the second culvert. Although
the respondent had knowledge of the condition, it failed to take corrective
measures. On two occasions, July 31, 1976, and October 9, 1976, as a result of
respondent?s negligence, water entered claimant?s business damaging the
claimant?s sewer system and various retail items in the amount of $244.85 as
listed on the estimate of damages filed with the stipulation. Believing that
liability exists on the part of the respondent and that the damages are
reasonable, the Court is of the opinion to, and does, make an award to the claimant
in the amount of
$244.85.
Award of $244.85.
Opinion issued February 10, 1978
ARTHRITIS CARE ASSOCIATES
vs.
DIVISION OF VOCATIONAL REHABILITATION
(No. CC-77-220)
Arthritis Care Associates, the claimant, by Paul D. Saville, M.D.
Henry C. Bias, Jr., Deputy Attorney General, for the respondent.
PER CURIAM:
This case was submitted upon the pleadings, in which respondent admits
liability for services rendered by claimant in the amount of $25.40. An award
in that amount is hereby made.
Award of $25.40.
86 REPORTS STATE
COURT OF CLAIMS [W. VA.
Opinion issued February 10, 1978
OLIE G. BASTIN AND PRISCILLA BASTIN
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-24)
Charles G. Johnson, Attorney at Law, for the claimants.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
This claim was before the Court a second time upon a motion for rehearing,
which more accurately would be designated as a motion for reconsideration,
since no additional evidence was taken. The claimants, whose property in Elk
District, Harrison County, was the subject of an eminent domain proceeding
incident to the construction of Interstate Route 79, seek an award of $4,500.00
in ?relocation assistance funds?. The claim was submitted upon a stipulation
which included the following matters:
?* *
*
The claimants contend and the Department of Highways admits that the Department
had actual knowledge of the claim and its amount within the eighteen (18) month
period. *
* * The Department of Highways admits that
the claimants would be entitled to recover the sum of Four Thousand Five
Hundred Dollars ($4,500.00) except for the failure of the claimants to file a
formal claim. (Emphasis supplied.)
* *
*?
The sole defense asserted by the
respondent was that the claimants failed to file a formal written claim for the
relocation assistance funds as required by a typewritten 18-page document
entitled ?Brochure Relocation Advisory Assistance? published by the respondent.
On page 4 of that document, it is stated:
?* *
*
(c) Claim must be filed within eighteen
months of date you were required to relocate.
* *
*?,
W. VA.] REPORTS
STATE COURT OF CLAIMS 87
Other provisions imply that a written form must be filed. When the claim was
argued upon its reconsideration, the Court pointed out to counsel that the
decision might turn on whether the brochure did or did not constitute rules or
regulations duly promulgated by the respondent and thus have the force and
effect of law. The authority to make rules and regulations pertaining to
relocation expense is contained in Code ?
17-2A-20, which provides, in part:
?4 *
*
Payments under this section are subject to
the following limitations and to any rules and regulations made by the
commissioner as herein authorized:
The commission shall establish by rules and regulations
a procedure for the payment of relocation costs within the limits of and
consistent with the policies of this section.
* *
*,,
Nothing whatever in the ?brochure?
indicates that it is to be regarded as rules and regulations or that it was
made or promulgated by the commissioner. In its first paragraph on page 1, it
is stated:
?* *
*
Your State Road Commission wishes to aid
and assist in relocating and re-establishing you, your family, your business,
your farm, the nonprofit organization, and the owner of other personal property
who will be displaced because of the construction of Federal-aid highways. It
is our desire to accomplish this in an orderly, timely, equitable, and
efficient manner so as to assure that those individuals dislocated do not
suffer disproportionate injuries because of the highway program designed for
the benefit of the public as a whole.
* *
*?
and, on page 17, it is stated in capital
letters:
?* *
*
88 REPORTS STATE
COURT OF CLAIMS [W. VA.
THIS IS AN INFORMAL SUMMARY OF
BENEFITS AVAILABLE TO PERSONS WHO ARE
FORCED TO RELOCATE THEIR FAMILY, FARM, BUSINESS OR NONPROFIT ORGANIZATION FROM
A HIGHWAY PROJECT IN WEST VIRGINIA. (Emphasis supplied.)
* *
*?
It thus appears. that the ?brochure? did
not constitute rules and regulations and did not have the force and effect of
law. Granted on page 18 of the brochure, it also is stated in capital letters:
?* *
*
A COPY OF THE BASIC FEDERAL REQUIREMENTS
OF THE BUREAU OF PUBLIC ROADS GOVERNING
PAYMENTS IS CONTAINED IN IM 80-1-68, AS REVISED.
* *
*?
and Instructional Memorandum 80-1-71 [a 65
page document relating to ?Relocation Assistance and Payments ? Interim Operating Procedures (RCS 34-01-03) (0MB
04-R-2211) j? published by the Federal Highway Administration, at page 31,
provides:
?* *
*
o. CLAIMS
In order to obtain a moving expense payment, a relocated person must file a
written claim with the State agency on a form provided by the agency for that
purpose within a reasonable time limit determined by the State.
* *
*,,
but it does not appear from any evidence
before the Court that TM 80-1-71 is anything more than what it proclaims itself
to be, viz., an instructional memorandum.
In view of the circumstances that the respondent did have actual knowledge of
the Bastin claim for relocation expense (including knowledge of the amount of
the claim) within eighteen months, and that there is no dispute as to the
amount which they should receive, viz., $4,500.00, the Court is of opin
W. VA.] REPORTS
STATE COURT OF CLAIMS 89
ion to, and does hereby, reverse its earlier decision and make an award to the
claimants in that sum.
Award of $4,500.00.
Opinion issued February 10, 1978
BOONE REMODELING COMPANY
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-77-130a-e)
J. R. Rogers, Attorney at Law, for claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. GARDEN, JUDGE:
These five claims were consolidated for hearing purposes, and this Opinion will
address itself to each claim in alphabetical order.
(No. CC-77-130a)
The claimant had been requested by respondent to deliver and install carpeting
in an office of respondent in property located on Washington Street which was
being rented by respondent from a private owner. In September of 1976, the
respondent rescinded the order, but not before the claimant had purchased
material and expended labor in a total amount of
$1,580.00.
At the hearing it was agreed that the respondent was prohibited by Regulation
3.01 from entering into such a contract by reason of the fact that the offices
where the improvements were to be installed were leased premises, and the
claimant, by counsel, thereupon advised the Court that it desired to withdraw
its claim, and the claim was thereupon dismissed.
(No. CC-77-103b)
While claimant was performing a contract for respondent at the Industrial
School for Boys at Neola, West Virginia, the respondent?s 0. V. Wright,
Supervisor of Maintenance, requested
90 REPORTS STATE
COURT OF CLAIMS [W. VA.
claimant to change some electrical wiring in a newly constructed building. This
additional work was to be done for $4,300.00, and it was represented to
claimant that a change order would be issued covering this additional item of
cost. The necessary material and labor were furnished by claimant and the work
was completed. Thereafter, the change order was requested, but the same was not
approved.
Respondent, in its Answer, admits that it ordered and received the work
described in the requested change order, and that the amount of $4,300.00 is
due and owing to the claimant. Accordingly, we hereby make an award in favor of
the claimant in the amount of $4,300.00.
(No. CC-77-130c)
While claimant was engaged in the performance of a contract at respondent?s
Industrial Home for Girls at Salem, West Virginia, the respondent?s 0. V.
Wright, Supervisor of Maintenance, requested claimant to install some 526 yards
of fire- rated carpeting and padding at a cost of $2,630.00, and it was
represented that this expense would be handled by the issuance of a change
order. After the carpeting was installed, a change order was submitted but was
refused.
Respondent, in its Answer, admits that it ordered and received the carpeting,
and that the amount of $2,630.00 is due and owing the claimant. We therefore
make an award in favor of the claimant in the amount of $2,630.00.
(No. CC-77-103d)
In 1976, the Legislature had appropriated $88,000.00 to cover the cost of
conducting extensive renovations at Sutton Hall Cottage, which is one of the
buildings at respondent?s Industrial School for Girls at Salem, West Virginia.
0. V. Wright, who at the time was respondent?s Supervisor of Maintenance,
requested estimates for this work from several contractors, and the estimates so
received well exceeded the appropriate $88,000.00.
0. V. Wright testified that it therefore became necessary for him to delete
some of the work originally included in the Request for Quotations, and that he
therefore deleted the originally included fluorescent lights and bedroom
lights. Request for bids was then advertised. Claimant was low bidder at $85,-
W. VA.] REPORTS
STATE COURT OF CLAIMS 91
000.00, and, as 0. V. Wright testified, ?Well, of course, I had
$3,000.00 to play with.?
Claimant was required to perform certain electrical work under the original
contract, and during the progress of this work, Wright conferred with
claimant?s president, Eugene Ferrell, concerning the furnishing and
installation of the fluorescent and bedroom lights which had earlier been
deleted from the Request for Quotations. Mr. Ferrell agreed to furnish and
install 58 fluorescent and 28 bedroom lights for the sum of $3,000.00. At that
time, both gentlemen were aware that the wiring to the hall lights and bedroom
lights would not pass inspection by the State Fire Marshal and that it would
have to be removed and replaced by a better grade of wiring. At this point, we
believe that a preponderance of the evidence clearly demonstrates that claimant
agreed to perform this wiring in return for respondent?s deleting several items
of work required under the terms of the original contract, namely, the
requirement on the part of claimant to clean the copper pipe on the exterior of
the building and the furnishing and installation of a new 100-ampere panel on
the first floor with all necessary breakers to handle the load.
While there was testimony to the effect that the claimant attempted to clean
the exterior copper on three occasions, it was generally conceded that this
work was not, in fact, performed. Two witnesses, including a witness for
claimant, testified that they would not undertake the work of cleaning the
exterior copper for any figure less than $5,000.00, and implied that claimant
had received a credit in that amount by being excused from the performance of
this part of the original contract.
Instead of invoicing respondent for the agreed-upon amount of $3,000.00, the
claimant is requesting an award of $6,367.00, which claimant contends covers
the cost of furnishing and installing the fluorescent and bedroom lights, the
cost of the wire, and the labor for the installation of the same. Since
claimant has, so to speak, received a $5,000.00 credit against the original
contract, we believe that an award of the full amount requested would
constitute unjust enrichment to claimant. We therefore limit the claimant?s
award to $3,000.00.
(No. CC-77-130e)
92 REPORTS
STATE COURT OF CLAIMS {W. VA.
Claimant was contacted by 0. V.
Wright, Supervisor of Maintenance of respondent?s Anthony Center at Neola, West
Virginia, and was requested to construct a roof on a dormitory at the Center.
Wright assured the claimant that a purchase order for this work would be
secured. The work was completed by claimant, and on March 23, 1977, respondent
invoiced claimant for $11,475.00. The invoice has not been paid, primarily
because the necessary purchase order was never authorized and issued. The
respondent, in its Answer, admits that it ordered and received the work, but
denies that the proper charge for such service is $11,475.00. Respondent
alleges that the correct amount of the charge should be $7,000.00, which sum,
it admits, is due and owing the claimant.
At the hearing, counsel for the parties advised the Court that claimant was
willing to accept the sum of $7,000.00 in discharge and full satisfaction of
its claim, and the Court therefore makes an award in favor of the claimant in
the amount of $7,000.00.
To recapitulate, these claims are disposed of in the following manner:
CC-77-130a?Claim disallowed.
CC-77-130b??Award of $4,300.00.
CC-77-130c?Award of $2,630.00.
CC-77-130d?Award of $3,000.00.
CC-77-130e?Award of $7,000.00.
Opinion issued February 10, 1978
BOONE SALES, INC.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?76-119)
No appearance in behalf of claimant.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
By written stipulation entered into by the parties and filed with the Court, it
was agreed that the claimant entered into a
W. VA.]
REPORTS STATE COURT OF CLAIMS 93
contract to purchase certain real
estate on U. S. Route 119 near the top of Lens Creek Mountain in Boone County,
West Virginia, and that a building located on the property had previously been
damaged by fire and not repaired. On October 14, 1975, respondent?s employees,
through the Rehabilitation Environmental Action Program, tore down the damaged
building. A deed for the property was executed and delivered three days later,
transferring legal title and this cause of action to the claimant. It was
further stipulated that the claimant sustained $1,100.00 in damages to the
building. Believing that liability exists on the part of the respondent and
that the damages are reasonable as shown by the estimates filed with the
stipulation, the Court hereby makes an award to the claimant in the amount of
$1,100.00.
Award of $1,100.00.
Opinion issued February 10, 1978
MRS. RICHARD L. COOPER
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-77-60)
Claimant appeared in person.
Gregory Bailey, Assistant Attorney General, for respondent.
WALLACE, JUDGE:
The claimant is the owner of a seven or eight-acre parcel of real estate upon
which her residence is erected in Winifrede, Kanawha County, West Virginia. On
March 17, 1977, a rather severe forest fire was burning on top of a mountain
about 1? miles from the claimant?s property. The fire ultimately burned an area
of over 100 acres. During the morning of the fire, and while the claimant was
away from her home, two or three young men who had been recruited by respondent
to fight the fire entered upon claimant?s property and started either a
backfire or a line fire for the purpose of resisting the larger fire.
94 REPORTS STATE
COURT OF CLAIMS [W. VA.
As a result of the backfire or line fire, certain property of the claimant was
destroyed. The claimant testified that 500 feet of 1 1/2-inch plastic water
pipe was destroyed and that the cost of new plastic pipe and the labor for
installing the same totaled $175.00; that a wooden boat having a value of
$50.00 was destroyed; and that a cinder block pump house and a pump located
therein having a total value of $550.00 were also destroyed.
Code ?20-3-4 authorizes the respondent and its duly authorized agents to enter
upon private property and to start backfires and take such other countermeasure
for the purpose of fighting forest fires. While this statute exonerates fire
fighters from criminal responsibility, it does not mean that property owners?
property can be destroyed without compensation being made. We therefore are of
the opinion that the claimant is entitled to an award.
The claimant was not represented by counsel at the hearing, and as a result,
her testimony relating to damages did not meet the usual requirements relating
to measure of damages. Nevertheless, we believe that an award of $475.00 would
constitute equitable compensation for the claimant?s loss.
Award of $475.00.
Opinion issued February 10, 1978
ALBERT D. FENTRESS
and HAZEL S. FENTRESS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-162)
Albert D. Fentress and Hazel S.
Fentress, the claimants, in person.
Gregory W. Evers, Attorney at Law, for the respondent. PER CURIAM:
Upon stipulation of the parties to the effect that the respondent, during road
grading operations, damaged claimants? fence
W. VA.] REPORTS
STATE COURT OF CLAIMS 95
in the amount of $122.68, an award in that amount should be, and is hereby,
made.
Award of $122.68.
Opinion issijed February 10, 1978
FRIDEN MAILING EQUIPMENT CORPORATION
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-77-125)
Friden Mailing Equipment Corporation, a corporation, the claimant, by Betsy Curry, its
Credit Manager.
Frank M. Ellison, Deputy Attorney General, for the respondent.
PER CURIAM:
This case was submitted upon the pleadings, in which the respondent admitted
liability for an unpaid balance in the sum of $147.00 due the claimant for
lease of a postage meter. An award in that amount is hereby made.
Award of $147.00.
Opinion issued February 10, 1978
PEGGY S. GOTT
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-77-153)
No appearance by the claimant.
Frank M. EUlson, Deputy Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision upon the pleadings by agreement of the
parties. The claimant was employed by the respondent from August 1, 1974, until
August 31, 1975, at an
96 REPORTS STATE
COURT OF CLAIMS [W. VA.
agreed salary of $20,000 per year, but she was paid on the basis of an annual
salary of $16,000. This claim, in the amount of $4,332.00, is for the
difference between the agreed salary and the salary actually paid. The
respondent?s Answer admits the validity of the claim and the amount due.
Accordingly, the Court makes and award to the claimant in the amount of
$4,332.00.
Award of $4,332.00.
Opinion issued February 10, 1978
HOGAN STORAGE & TRANSFER COMPANY
vs.
DEPARTMENT OF AGRICULTURE
and DEPARTMENT OF HEALTH
(No. CC-77-134)
Lafe P. Ward, Attorney at Law, for claimant.
Frank M. EllFison, Deputy Attorney General, for respondents. GARDEN,
JUDGE:
The facts giving rise to this claim are tragic, but bizarre. The claimant is a
licensed motor carrier of general commodities with its principal place of
business in Williamson, West Virginia. At the close of business on April 4,
1977, the claimant had about 18 trailers, 13 tractors, and six straight trucks
located in its terminal. The trailers and trucks were in various stages of
being loaded with commodities for later delivery. One of the trailers, a 1964
Strick semitrailer tandem, was loaded for departure the next morning with about
40,000 pounds of Banner Sausage and Armour Products. That night the Tug River
overflowed its banks, causing complete devastation in Williamson, including the
inundation of the trailer mentioned above.
Charles Dawson, president and general manager of claimant, testified that after
the flood waters had subsided and he had an opportunity to inspect his
terminal, and in particular the subject trailer, he became concerned as to
whether the cargo had
W. VA.] REPORTS
STATE COURT OF CLAIMS 97
become contaminated as a result of the flood waters. As soon as the telephones
in Williamson became operational, about three days after the flood, Mr. Dawson
contacted the Interstate Commerce Commission Office in Charleston, which in
turn referred him to the United States Department of Agriculture Office in
Charleston. He was finally referred to the West Virginia Department of
Agriculture, and that agency sent two of its representatives, Swansey L. Evans
and Herma G. Hanshew, to Williamson in order to determine if the subject cargo
had in fact been contaminated.
Mr. Evans and Mrs. Hanshew inspected the subject trailer?s cargo at claimant?s
terminal early on the 12th of April and advised Mr. Dawson that the cargo was
in fact contaminated and would have to be destroyed. At that point, a Lt.
Williams of the National Guard was contacted, and it was agreed that the
trailer would be taken to the city dump where its cargo would be disposed of,
the city dump being located about four miles from the claimant?s terminal. The
National Guard assisted the claimant and pulled the flood-disabled tractor,
which had previously been hooked to the subject trailer, from the trailer.
Claimant thereafter used one of its functioning tractors to move the trailer to
the city dump. At the city dump, the trailer was positioned in accordance with
the instructions of one Francis H. Leary, an employee of the West Virginia
Department of Health with expertise in the field of solid waste collection
facilities.
Mr. Leary testified that he had been sent to Williamson by his superiors on
April 7 and had been placed in charge of the operations at the city dump. He recalled
the trailer?s being brought to the dump and that the driver of the rig had
positioned the same in the dump in accordance with his instructions. He
testified that he had been contacted earlier by Mr. Evans, a lady coworker, and
a Lt. Williams as to whether the load of contaminated meat could be disposed of
at the city dump. He advised them that it could, but that they would have to
bring sufficient personnel with them to unload the trailer and remove it from
the site. Mr. Leary testified that, after the trailer had been spotted as
instructed by him, he and Mr. Evans went to the rear of the trailer and looked
in the door and
98 REPORTS STATE
COURT OF CLAIMS [W. VA.
then went to the front of the trailer and discovered that the tractor was gone.
He then, quite significantly in our opinion, testified ?and my blood pressure
went up several degrees because it showed me that there was a foul-up
somewhere, the trailer was not being removed immediately.?
On April 14, the cargo of the trailer not having been removed, and, in what we
detect, a bit of anger, Mr. Leary ordered the destruction of the trailer, which
was thereupon bisected by a bulldozer and thereafter buried with cargo in the
city dump. Mr. Evans testified that on the morning of April 14, he orally
advised Mr. Dawson on the downtown streets of Williamson that his trailer was
to be destroyed that day. Mr. Dawson, in rebuttal testimony, denied that Mr.
Evans imparted this information to him. Thus, the curtain fell on an episode,
very reminiscent of a ?Keystone Cop? comedy of the past.
Whether the destruction of the trailer resulted from a misunderstanding or
failure of communication between Mr. Evans and Mr. Leary, we firmly believe
that the respondents are liable for the unlawful conversion of claimant?s
trailer. Testimony was presented at the hearing which leads us to the con-
elusion that on April the 14th, the claimant?s trailer had a fair market value
of $6,000.00, and we thus make an award in favor of the claimant in that
amount.
Award of $6,000.00.
Opinion issued February 10, 1978
ROBERT H. JOHNSON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-146)
Claimant appeared in his own behalf.
Richard Canton, Attorney at Law, for the respondent.
RULEY, JUDGE:
Claimant?s 1956 Volkswagen bus was taken from his property and crushed by
respondent under the auspices of the REAP
W. VA.] REPORTS
STATE COURT OF CLAIMS 99
program. Respondent admits that it failed to follow proper statutory procedures
which would have allowed claimant to reclaim his vehicle. Thus, respondent
admits liability. This hearing was held solely on the issue of damages.
The standard measure of damages for injury to personal property is the loss of
fair market value, plus reasonable and necessary expenses incurred by the owner
in connection with the injury. Cato v.
Silling, 137 W. Va. 694, 73 S.E.2d
731 (1952). The bus was a total loss. Claimant testified that the bus was
operable when taken, and worth $900.00, based on his experience with similar
vehicles. Respondent offered no evidence to the contrary. Accordingly, an award
of $900.00 should be, and is hereby, made.
Award of $900.00 to claimant.
Opinion issued February 10, 1978
JONES PRINTING COMPANY, INC.
vs.
GOVERNOR?S OFFICE OF ECONOMIC
AND COMMUNITY DEVELOPMENT
(No. CC-77-207)
No appearance by the claimant.
Frank M. EUison, Deputy Attorney General, for the respondent.
PER CURIAM:
This claim was submitted to the Court for decision upon the pleadings. The
claimant filed its claim in the amount of $235.00 for printing five hundred
copies of the newspaper, Intouch, ordered by the respondent. The respondent?s Answer
admits the validity of the claim and the amount due.
Accordingly, the Court is of the opinion to and does make an award to the
claimant in the amount of $235.00.
Award of $235.00.
100 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opimon issued February 10, 1978
KANAWHA VALLEY RADIOLOGISTS, INC.
vs.
BOARD OF VOCATIONAL EDUCATION,
DIVISION OF VOCATIONAL REHABILITATION
(No. CC-77-212a-k)
Kanawha Valley Radiologists, Inc., a corporation, the claimant.
Frank M. Ellison, Deputy Attorney General, for the respondent.
PER CURIAM:
This case was submitted upon the pleadings, in which the respondent admitted
the validity of the claim for $109.00 for services rendered. Accordingly, an
award in that amount should be, and is hereby, made.
Award of $109.00.
Opinion issued February 10, 1978
EUGENE LAFFERTY and WANDA LAFFERTY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-44)
Fred A. Jesser, III, Attorney at Law, for the claimants.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
An Opinion of this Court, dated March 22, 1977*, held the respondent negligent
in this case, but disallowed the claim due to inadequate proof of damages.
Pursuant to Rule 15 of the Rules of Practice and Procedure, a rehearing was
held on August 9, 1977, on the issue of damages.
Expert testimony on the claimant?s behalf placed the reduction in market value
of the claimants? land at $10,500.00, caus *Se La4ferty v. Department of Highways, 11 Ct.Cl. 239 (1977).
W. VA.] REPORTS
STATE COURT OF CLAIMS 101
ed by respondent?s construction of a highwall for Route 19 and the resulting
increase in water draining across claimants? land. The expert witness for the
claimants was a real estate appraiser with considerable experience in real
estate transactions in Fayette County, where the claimants? property is
located.
His estimates of value before and after the damage were based in part upon a
comparison of recent transactions involving similar real property in Fayette
County. The respondent?s expert witness placed the diminution of value at $4,000.00,
but his estimate was based solely on a description of the property without
seeing or inspecting it and was based on only minimal experience with real
property in Fayette County.
This Court finds that claimants have incurred damages of $10,500.00, that
amount representing the diminution in value caused by respondent?s negligence.
Diminution in market value being the proper measure of damage to property in
cases like this, (Jarrett v. E. L.
Harper and Son, Inc., -
- W.Va 235 S.E.2d 362 [1977]), an award in
the sum of $10,500.00 should be, and is hereby, made.
Award of $10,500.00.
Opinion issued February 10, 1978
THOMAS F. LAMBERT
vs.
DEPARTMENT OF WELFARE
(No. CC-77-193)
Thomas F. Lambert, the claimant, in person.
Frank M. Ellison, Deputy Attorney General, for the respondent.
PER CURIAM:
The claimant was dismissed from the employ of the respondent on August 6, 1976,
but was reinstated. The respondent has
102 REPORTS
STATE COURT OF CLAIMS [W. Va.
not paid the claimant the $457.60 it owes him for the period of his suspension,
and admits the validity of the claim in its Answer. Thus, an award in the
amount of $457.60 is hereby made.
Award of $457.60.
Opinion issued February 10, 1978
LINDA LESTER and LEON LESTER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-210)
Linda Lester and Leon Lester, the claimants.
Richard Canton, Attorney at Law, for the respondent.
PER CURIAM:
Claimants seek recovery of property damage in the sum of $199.63 sustained by
their 1975 model Ford automobile on June
5, 1977, when a loose plank in a wooden bridge runner in the Mohawk Bridge on
West Virginia Route 1/2, in McDowell County struck the underside of the
automobile. The claim was submitted upon a stipulation which revealed that the
respondent had constructive knowledge, viz., that it should have known of the
need for repairs to the bridge before the accident happened. It also was
stipulated that the claimants had exercised reasonable care for their own
safety. It thus appears that the respondent was guilty of negligence which
caused the accident and resulting damage, and that the claimants themselves
were not guilty of contributory negligence. Accordingly, an award is hereby
made in the sum of $187.63 (the stipulated amount of damage).
Award of $187.63.
W. VA.1 REPORTS
STATE COURT OF CLAIMS 103
Opinion issued February 10, .1978
GERALD J. LYNCH
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-175)
Claimant appeared in person.
Gregory W. Evers, Attorney at Law, for respondent. PER CURIAM:
When this claim was heard, the parties dictated a stipulation into the record
which revealed the following facts:
On August 4, 1977, the claimant was driving his 1974 Cadillac across a bridge
connecting Woodward Drive and Route 21 in Kanawha County, which bridge was
owned and maintained by respondent. While claimant was crossing the bridge, a
wooden plank unexpectedly came loose and damaged the exhaust system of
claimant?s vehicle. The respondent had notice of the disrepair of the bridge,
but failed to warn claimant of the defective condition of the bridge. The
parties agreed that the claimant?s cost of repairs in the amount of $206.76 was
fair and accurate.
Believing that liability exists on the basis of the stipulation as recited
above, and that the damages are fair and accurate, we hereby make an award in
favor of the claimant in the amount of $206.76.
Award of $206.76.
104 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued February 10, 1978
MOORE BUSINESS FORMS, INC.
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-78-23)
No appearance on behalf of claimant.
Frank M. Eflison, Deputy Attorney General, for respondent. PER CURIAM:
In the spring of 1976, the respondent issued a purchase order for 1978 license
plate decals at an agreed price of $87.95 per thousand. Claimant made an error
in billing and invoiced respondent at the rate of $87.59 per thousand. Claimant
also failed to bill respondent for the freight charges, even though the
purchase order reflected that the sale was F.O.B. claimant?s factory. The
respondent has filed an Answer admitting that it owes claimant the sum of
$195.97, and we therefore make an award to claimant in the amount of $195.97.
Award of $195.97.
Opinion issued February 10, 1978
CAROLYN CRISP SHERWOOD
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-214)
No appearance by claimant.
Gregory W. Evers, Attorney at Law, for respondent. PER CURIAM:
By written stipulation submitted to the Court by the parties herein, it was
stipulated that on or about April 5, 1976, the respondent?s employees were
engaged in welding operations on the Willow Wood Bridge on Local Service Route
3 in Summers County, West Virginia, and that the claimant was properly
W. VA.] REPORTS
STATE COURT OF CLAIMS 105
driving her 1975 Oldsmobile across the bridge when one of respondent?s
employees negligently dropped hot welding slag on the windshield of claimant?s
automobile causing damage in the amount of $237.00. Believing that liability
exists on the part of the respondent, and that the damages are reasonable, the
Court is of the opinion to and does make an award of $237.00 to the claimant.
Award of $237.00.
Opinion issued February 10, 1978
NEW MARTINSVILLE/WETZEL COUNTY
EMERGENCY SQUAD, INC.
vs.
DIVISION OF VOCATIONAL REHABILITATION
(No. CC-77-211)
No appearance by claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. PER CURIAM:
The claimant, at the request of a representative of respondent?s Clarksburg,
West Virginia office, did on November 25, 1975, and again on December 1, 1975,
make round trips between New Martinsville and Charleston for the purpose of
transporting by ambulance a Donald H. Lancaster from Institute to New
Martinsville and back again six days later. For this service, the claimant
billed respondent $162.00, but claimant?s bill was never paid. The respondent
has filed an Answer admitting the validity of the claim, and that claimant is
entitled to receive the amount of its claim. Therefore, an award is hereby made
in favor of claimant in the amount of $162.00.
Award of $162.00.
106 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued February 10, 1978
HELEN L. NORVELL, EXECUTRIX OF THE
ESTATE OF GLENN HARTSEL NORVELL, DECEASED
vs.
DEPARTMENT OF HIGHWAYS
(No. D-936)
W. Dale Greene, Attorney at Law, for the claimant.
Gregory W. Evers, Attorney at Law, for the respondent. PER CURIAM:
This wrongful death claim was submitted upon stipulation of the parties to the
effect that the respondent knew of dangerous, slippery road conditions caused
by a tar spill on State Route 4 in Clay County, and negligently failed to
correct those conditions; that the respondent knew of several vehicle accidents
at the point of the spill, near Ivydale, one of which had torn out guardrails;
that the respondent negligently failed to take any action to replace those
rails or warn motorists of the dangerous conditions; that such negligence by
the respondent caused the accident on April 25, 1973, as a result of which
claimant?s decedent died; and that the sum of $15,000.00 represents a fair and
reasonable award in settlement of this claim. Therefore, an award in that
amount should be, and is hereby, made.
Award of $15,000.00.
W. VA.1 REPORTS
STATE COURT OF CLAIMS 107
Opinion issued February 10, 1978
ARIZONA M. OFFUTT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-109)
David A. Glance, Attorney at Law, for the claimant.
Nancy J. Norman, Attorney at Law, and James W. Withrow, Attorney
at Law, for the respondent.
RULEY, JUDGE:
On December 23, 1975, a 1970 Ford Torino, owned by claimant and driven by
claimant?s son, slid on a patch of ice on Boulevard Avenue, near Fairmont,
skidded off the road, and
fell about twenty feet down a hillside. In
the place where the accident happened, part of Boulevard Road had collapsed,
reducing it from a two-lane to a one-lane road. Claimant, seeking recovery for
damage to the automobile in the sum of $2,000.00, alleges that respondent
negligently failed to repair Boulevard Avenue and failed to keep the road clear
of ice, thus causing the accident.
The evidence in this case reveals that Boulevard Avenue had collapsed in the
spring of 1975, a full eight months before this accident occurred. Respondent
made no effort to repair the road, and at the time of the accident, had only
two ?One Lane? signs and reflectors in place to warn motorists of the hazard.
The signs and reflectors were within 20 feet of the collapsed portion of the
road. The evidence also leads to the conclusion that, although the respondent
knew that the road was icy on the day before the wreck, no cinders or salt were
put on the road until after the accident. When the Department of Highways knows
that a road is too narrow for two-lane traffic, and knowingly allows a dangerous
condition to exist on such a road, it is negligent and liable for damages
caused by such negligence. Jones v.
Department of Highways, 9
Ct.Cl. 117 (1972). The Court finds the respondent negligent.
108 REPORTS STATE
COURT OF CLAIMS [W. Va.
The evidence also impels the conclusion that claimant?s son was familiar with
the road and was driving slowly (approximately 10 mph) and carefully as he
approached the collapsed portion of the road. The Court finds no evidence of
contributory negligence. Therefore, respondent is found liable.
On the issue of damages, the only evidence offered consisted
of claimant?s testimony that the car had a book value of
$1,700.00 at the time of the accident, and a salvage value of
$75.00. Accordingly, claimant should be awarded the sum of
$1,625.00 in damages.
Award of $1,625.00.
Opinion issued February 10, 1978
OTIS ELEVATOR COMPANY
vs.
DEPARTMENT OF HEALTH, DIVISION
OF MENTAL HEALTH
(No. CC-77-204)
Otis Elevator Company, the claimant, by John
C. Regnier, its Manager.
Frank M. Ellison, Deputy Attorney General, for the respondent.
PER CURIAM:
The respondent owes the claimant $95.00 for routine maintenance services. The
respondent, in its Answer, admits the validity of the claim. Accordingly, an
award in the amount of $95.00 should be, and is hereby, made.
Award of $95.00.
W. VA.) REPORTS
STATE COURT OF CLAIMS 109
Opinion issued February 10, 1978
POLlS BROTHERS
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-77-107)
Polis Brothers, the claimant, by Joseph
L. Polis.
Henry C. Bias, Jr., Deputy
Attorney General, for the respondent.
RULEY, JUDGE:
By agreement of the parties, this claim was submitted upon the pleadings and an
affidavit by Joseph L. Polis, who, with his brother, Anthony, does business as
Polis Brothers, claimant in this action.
The claim and affidavit assert that Polis Brothers sold and delivered eggs and
quartered fryers worth $239.90 to a place called Roney?s Point Center in
Triadeiphia, for the use and benefit of the respondent. Attached to the
affidavit were copies of the two invoices for that merchandise, addressed to
Roney?s Point. The respondent?s Answer denies the allegations and asserts that
the claimant has failed to state a claim for which relief may be granted.
The pleadings do not explain what, if any, relationship exists between Roney?s
Point and the respondent. Indeed, it is un clear whether Roney?s Point is an
institution, a place on the map, or whatever. If the Court had only the
pleadings before it, the claim would have to be denied. But Mr. Polis?
affidavit clearly implies that respondent is liable for bills sent to Roney?s
Point. Going beyond the evidence, the Court notes that the 1976 edition of the
West Virginia Blue Book, Volume 60, at page 410, lists Roney?s Point as a state
institution under the control of the Mental Health Department. Accordingly, we
hold the respondent liable in the amount of $239.90. An award in that amount
should be, and is hereby, made.
Award of $239.90.
110 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued February 10, 1978
JERRY AUSTIN REXRODE
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-77-202)
Jerry Austin Rexrode, the claimant, in person.
Frank M. Eflison, Deputy Attorney General, for the respondent.
PER CURIAM:
This case was submitted upon the pleadings, in which respondent admits
liability for a balance of $2,943.72 owed the claimant for construction of a
fireplace in a picnic shelter at the Cass Scenic Railroad. An award in that
amount is hereby made.
Award of $2,943.72.
Opinion issued February 10, 1978
ANTHONY R. ROSI
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-77-138)
No appearance by the claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings by agreement of the
parties. The claimant purchased a 1977 Plymouth Volare automobile from Country
Club Chrysler-Plymouth in Clarksburg, West Virginia. Because of numerous
problems with the automobile, the claimant returned it and received a refund of
the purchase price. The dealer was unable to refund the 5% tax paid to the
respondent ir1 the sale. This
W. VA.] REPORTS
STATE COURT OF CLAIMS Ill
claim is for a refund of the $271.60 tax paid. It is the opinion of this Court
that since the sale was nullified between the parties and the sales price
refunded, the tax paid in the amount of $271.60 should be refunded to the
claimant. (George M. Custer vs.
Department of Motor Vehicles, CC-77-86,
12 Ct. Cl. 48; Sandra S. Clemente vs.
Department of Motor Vehicles, CC-77-
169, 12 Ct. Cl. 48). Accordingly, an award in the sum of $271.60 should be, and
is hereby, made.
Award of $271.60.
Opinion issued February 10, 1978
FRANKLIN ROSS and ELSIE M. ROSS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-132)
No appearance by claimants.
Richard Canton, Attorney at Law, for respondent.
PER CURIAM:
The parties have filed a written stipulation with the Court in which they have
stipulated that the respondent is responsible for the maintenance and control
of the 1-64 bridge at the point the bridge passes over the 1600 block of
Madison Avenue in Huntington, West Virginia. On July 6, 1977, the claimant,
Elsie M. Ross, drove a 1973 Ford automobile owned by the claimant, Franklin
Ross, westerly on Madison Avenue under the bridge. A light from a sign on the
bridge fell on the automobile causing damage to the automobile in the amount of
$347.80. Believing that liability exists on the part of the respondent and that
the damages are reasonable, the Court is of the opinion to and does make an
award to the claimaflt in the amount of $347.80.
Award of $347.80.
112 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued February 10, 1978
MARY JO SHARP
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-77-66)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy
Attorney General, for respondent. GARDEN, JUDGE:
The claimant, who previously had been employed at the Guthrie Center in Kanawha
County as an executive housekeeper, was transferred to Barboursville State
Hospital on July 1, 1976, as a Teacher I, a part-time position. It was further
established, by exhibit, that the employment was of a temporary nature, for a
period of four months, and that the claimant was to work 28.8 hours per week.
In addition, the claimant?s employment was extended an additional five months,
expiring March 31, 1977, at a monthly salary of $586.00 (representing 71.9% of
the full-time salary of $815.00 for the position which she held on a part-time
basis).
On November 17, 1976, the claimant, feeling that her duties at Barboursville
were becoming fewer, conferred with James Clowser, who at that time was the
Deputy Director of Mental Health, about becoming employed at Barboursville on a
full- time basis. Mr. Clowser was agreeable, and in the claimant?s presence he
telephoned Dr. Glen T. Roberts, the Chief Personnel Officer for the Department
of Health, and told him that it was his desire that the claimant be placed on
full-time status as of December 1, 1976. Dr. Roberts, who testified at the
hearing, confirmed this conversation and testified that he had told Mr. Clowser
that there would be no problem if the claimant could be reached on the
appropriate Civil Service register. Dr. Roberts testified that he then
contacted George Pozego, Superintendent at Barboursville, and told him of Mr.
Clowser?s request and that Mr. Pozego then initiated the necessary paperwork to
bring about the full-time appointment of claimant from the Civil Service
register.
W. VA.]
REPORTS STATE COURT OF CLAIMS 113
On December 1, 1976, the claimant,
believing that she had attained full-time status, worked an eight-hour day, but
on the following day during which she worked another eight hours, her
supervisor, Violet Waggoner, questioned her about the number of hours she was
working. Mrs. Waggoner advised the claimant that she had not been advised
officially as to claimant?s full-time status, and the claimant suggested that
Mrs. Waggoner check with Central Office for verification of claimant?s
full-time status. The claimant continued to work on a full-time basis through
December of 1976, but when she submitted her time sheet for that month, her
supervisor, Mrs. Waggoner, refused to approve it and wrote the following
notation on the sheet. ?I refuse to sign this Time Sheet, as this employee is
scheduled only to work 28.8 hours per week. She is working additional time on
her own.? When this occurred, the claimant testified that she called Mr.
Clowser?s office and was advised that notice as to her full-time status had been
forwarded to Barboursville. Claimant continued to work on a full-time basis
until January 27, 1977, when she received a letter from Superintendent Pozego
that her employment would be terminated on March 31, 1977, and that until that
time she would continue to work 28.8 hours per week as originally planned when
her appointment was made. Claimant thereafter confined her working hours to
28.8 hours per week, and she admits that during her employment at
Barboursville, she never received anything in writing officially stating that
she was a full-time employee. Claimant is seeking an award of $458.00, which
represents the difference in her total pay as a full-time employee during the
months of December and January and what she did receive during that period as a
part-time employee.
In explanation of this matter, Dr. Roberts testified that in December of 1976,
all superintendents in the Department of Mental Health were requested to review
their budgets relating to personal services to determine if it would be necessary
to request a deficiency appropriation from the Legislature. Mr. Pozego?s
projection developed that there would be insufficient monies to pay claimant
past the month of March, 1977. Dr. Roberts also testified that as a result of
Mr. Pozego?s original paperwork, approvals had been received from Civil Service
114 REPORTS
STATE COURT OF CLAIMS [W. Va.
and from the Department of Finance and
Administration in respect to claimant?s full-time status, but by this time the
insufficiency of funds for personal services had become apparent, and Mr.
Pozego therefore prepared the necessary papers to cancel claimant?s status as a
full-time provisional employee. Dr. Roberts further testified that, although it
was the intention of respondent to elevate claimant to that of a full-time
employee, such elevation was in fact never carried out.
While we are critical of claimant?s voluntarily working on a full-time basis in
December and January, when she had to be aware of some problem in obtaining
official approval of her full-time status, she did devote a substantial amount
of her time for which she has not been compensated. We believe that equity and
good conscience require us to make an award covering these uncompensated
working hours, and we therefore make an award in favor of claimant in the
amount of $458.00.
Award of $458.00.
W. VA.J
REPORTS STATE COURT OF CLAIMS 115
Opinto.n issued February 10, 1978
COURT OF CLAIMS
STATE OF WEST VIRGINIA
FRED K. TESTA and
CLAUDIA I. TESTA,
Claimants,
CLAIM NO. D-669a
vs.
DEPARTMENT OF HIGHWAYS
Respondent,
and
SALEEM A. SHAH and
THERESA A. SHAH,
Claimants,
CLAIM NO. D-669b
vs.
DEPARTMENT OF HIGHWAYS
Respondent.
Peter L. Chakmakian, Attorney at Law, for the claimants. Gregory W. Evers, Attorney
at Law, for the respondent.
RULEY, JUDGE:
The claimants in these consolidated cases allege that the respondent unlawfully
cut down a total of fifty-seven trees belonging to them and ask for treble
damages as provided in Code ?61-3-48a, ?Cutting, damaging or carrying away
without permission, timber, trees, growing plants or the products thereof;
treble damages provided.? The respondent does not deny that the trees in
question were beyond the thirty-foot right of way (15 feet from center) on
Secondary Route 9/3 in Jefferson County, but contends that the trees were
within a prescriptive easement enjoyed by the State along the road.
There is no question that the trees were beyond the thirty- foot right of way
the Department of Highways enjoys. Hark
116 REPORTS
STATE COURT OF CLAIMS [W. Va.
v. Mountain Fork Lumber
Co., 127 W.Va. 586, 34 S.E.2d 348
(1945). The right of way may also include, however, embankments, slopes,
ditches, and other areas necessary for the maintenance of travel. W.Va. Code
?17-1-3, Hark, supra. If the land on which the trees stood had been
maintained by the State as part of the road for at least ten years, the
respondent would not be liable. Riddle
v. Department of Highways, 154
W.Va. 722, 179 S.E.2d 10 (1971). But the evidence indicates that the area in
question had not been a part of the roadway, had not been in ?continued and
uninterrupted use or enjoyment for at least ten years? (Riddle, supra) by the State. In fact, the cutting of the trees was the first step in
the respondent?s plan to widen the road in 1971. The respondent?s agents
wrongfully cut the trees, and, even though they believed they had a right to do
so, the respondent is liable to the claimants for damages.
The claimants seek recovery of treble damages under the provisions of Code
?61-3-48a, which read:
?Every person, firm, association, partnership or corporation, who shall cut,
damage, or carry away without permission from the rightful owner thereof, any
timber, trees, logs, posts, fruit, nuts, growing plant or product of any
growing plant, shall be liable to the rightful owner to the amount of three
times the value of such as damages, which shall be in addition to and
notwithstanding any other penalties by law provided.?
Although the same subject, viz., unlawful cutting of trees, was involved in Blair v. Department of Natural Resources, 9 W.Va. Ct. Cl. 69 (1972), the issue of
treble damages was not addressed expressly by the Court and it awarded only
compensatory damages. In 52 Am. Jur. 2d ?Logs
and Timber?, ?135, p. 101, under a
subheading relating to punitive and multiple damages, it is stated:
?135. Generally.
In many states, statutes have been enacted providing for double or treble
damages and penalties in certain circumstances. Many of these statutes expressly
pertain to trespass on timberlands and provide for double or treble damages for
the cutting or removal of timber. In some
W. VA.] REPORTS
STATE COURT OF CLAIMS 117
states, the statute is regarded as remedial and not penal, notwithstanding a
provision therein for treble damages. But
it has been held that equity will not decree multiple damages under such
enactments, because such damages are in the nature of penalties which are not
enforceable in courts of equity.? (Emphasis
supplied)
Code ?
14-2-13 confers upon this Court
jurisdiction of ?Claims and demands * * * which
the State as a sovereign commonwealth should in equity and good conscience
discharge and pay.
* * ?
While that statute does not make this
Court a court of equity, it is our opinion that, when it and other related
statutes are considered together, it appears implicit that equitable principles
should govern the amount of awards which this Court makes. In addition, in 52
Am. Jur. 2d ?Logs and Timber?, ?137, p. 103, it is stated:
?It is generally held that where timber is cut or carried away under a bona
fide mistake of fact, as, for example, where the trespasser believes that he is
on his own land or the lands of another upon which he is authorized to go, the
penalty statutes do not apply, even though they contain no exculpatory
provisions. *
* ?K?
and there is no evidence in this case that
the respondent cut the claimants? trees under anything other than a bona fide
mistake of fact. For these reasons, we believe that compensatory rather than
treble damages should be awarded.
The evidence shows that the respondent cut 30 trees on the Testa property. They
were of mixed variety, many of them hackberry, but others were walnut, elm,
ash, hickory, cherry, and locust, ranging in size from 0.4 feet to 2.0 feet in
diameter. The evidence shows that the respondent cut 27 trees of similar mixed
variety and size on the Shah property. There was an uncommon divergence of
expert opinion evidence as to the value of the trees, ranging from $332.24 to
$11,602.50 for the Testa trees, and from $107.75 to $9,601.10 for the Shah
trees. The opinions as to the lower sums were ?forest tree? value and were
based on the premise that only value for timber should be considered. However,
the undisputed evidence is that the trees were in proximity to Secondary Route
9/3 along the back side
118 REPORTS STATE
COURT OF CLAIMS [W. Va.
of the Testa and Shah properties, and that, although they were located a
substantial distance from dwelling houses, they did have functional use in
screening for privacy, abatement of highway noise, and as a windbreak. The
opinions as to the higher sums were expressed by Donald S. Frady, a nationally
respected arborist of Falls Church, Virginia, but it appears that they were
based, at least in part, upon ?shade tree? value and utilized the ?shade tree
formula?. It appears that neither the ?forest tree? nor the ?shade tree? label
or classification fits the facts of this case very well. In view of all of the
evidence, it is the opinion of the Court that $4,500.00 would be a fair
compensation for the damage sustained by the claimants Testa, and $3,500.00
would be a fair compensation for the damage sustained by the claimants Shah.
Judge Wallace disqualified himself and did not participate in the consideration
of these claims.
Award of $4,500.00 to Fred K. Testa and Claudia I. Testa.
Award of $3,500.00 to Saleem A. Shah and Theresa A. Shah.
Opinion issued February 10, 1978
3M BUSINESS PRODUCTS SALES, INC.
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC?77-194)
No appearance by claimant.
Frank M. Etlison, Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted to the Court upon the pleadings, which consist of
claimant?s Notice of Claim for unpaid invoices in the amount of $957.50 and
respondent?s Answer admitting the validity of the claim and the amount due.
Accordingly, the Court makes an award to the claimant in the amount of $957.50.
Award of $957.50.
W. VA.] REPORTS
STATE COURT OF CLAIMS 119
Opinion issued March 8, 1978
CLENDENIN LUMBER & SUPPLY COMPANY
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-78-14)
No appearance on behalf of claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. PER CURIAM:
Claimant furnished Armstrong Excelon floor tile and brushon adhesive for use at
Guthrie Center. Purchase Order Number 109 in the amount of $458.85 was not paid
because it was submitted after the close of the fiscal year during which the
supplies were furnished. The respondent admits the validity of the claim, that
there were sufficient funds with which to pay the claim, and that the claimant
is entitled to payment.
Accordingly, the Court makes an award in favor of the claimant in the amount of
$458.85.
Award of $458.85.
Opinion issued March 8, 1978
MICHAEL H. COEN
and RUTH COEN
vs.
DEPARTMENT OF fflGHWAYS
(No. D-1008)
Martin S. Bogarad & William R. Kiefer, Attorneys at Law, for claimants.
Gregory W. Evers, Attorney at Law, for respondent. WALLACE, JUDGE:
This claim, filed by Michael H. Coen and Ruth Coen, his wife, was the result of
an automobile accident which occurred at approximately 11:20 a.m. on October
17, 1973, on West Vir
120 REPORTS
STATE COURT OF CLAIMS [W. Va.
ginia Route 2 in Wellsburg, West
Virginia. The weather was clear and the temperature ranged between 45 and 55
degrees.
Route 2, from a point on the north side of Wellsburg at 27th Street southerly
to 12th Street, is a dual four-lane highway consisting of a concrete medial
strip between two southbound lanes and two northbound lanes.
On the clay of the accident, employees of the respondent had sprayed portions
of the area of Route 2 with a combination of linseed oil and mineral spirits as
an anti-spalling compound for the preservation of the concrete to prevent spalling
caused by salt on the highway.
The claimant, Michael H. Coen, was driving his 1970 Chevrolet Impala automobile
in a southerly direction in the right or outside lane of West Virginia Route 2.
At the intersection of Route 2 and 16th Street, his automobile collided with an
automobile driven by Raymond A. Lengyel. Lengyel testified that he was driving
his 1968 Pontiac Catalina automobile 35 to 40 miles per hour northerly on Route
2, and that, as he started to pass a tractor trailer, his automobile started to
slide. He lost control, slid across the medial strip into the southbound lane
of the highway, and was struck by the southbound Coen automobile. He further
testified that he noticed a discoloration of the surface of the highway from
the point where it changed from a two-lane to a four-lane highway, and that
there were no barricades or warning signs. Lengyel, who received only minor
injuries, was taken to the hospital in an ambulance with Michael H. Coen. He
stated that he returned to the accident scene later and that the intersection
and all lanes of the highway were slippery and discolored.
Employees of the respondent testified that on the morning of the accident, they
started spraying the highway at approximately 8:00 a.m., spraying the outside
or right-hand lane of the four-lane section of Route 2 south from 27th Street
to 12th Street in Wellsburg and the outside or right-hand lane north to Cross
Creek. The spraying was done by a Ford tractor equipped with a 200-gallon tank
and a spray bar which was set six inches above the surface of the road. An
automobile preceded the tractor which was followed by a pickup truck. There
were no
W. VA.]
REPORTS STATE COURT OF CLAIMS 121
flagmen, barricades, or warning signs
used. The equipment had flashing lights. The tractor traveled at approximately
six miles per hour. It did not stop during the spraying process but continued
until the job was completed. The men applying the material had never done this
type of work before except on two bridges in Brooke and Hancock Counties the
day before the accident.
Certain of the claimants? witnesses testified to the effect that all four lanes
of the highway were sprayed. The respondent?s witnesses testified that only the
outside lanes were treated. Various witnesses for the claimant and the
respondent stated that the material applied to the highway was tracked from one
lane to the other by traffic using the road. Some described the road surface as
tacky, others for the claimants described it as slippery.
The testimony of expert witnesses for the claimants and the respondent
pertained to the variables that affect the drying time of the anti-spalling
compound. Weather, temperature, age of the road surface, speed of the spraying
vehicle, quantity, and rate of application are necessary factors to be
considered. Various factors affect the application of the mixture. The expert
for the respondent testified that the compound should be dry in 2? hours.
However, the testimony of certain witnesses for the claimants and the respondent
indicated that the mixture was not dry at the time of the accident.
The claimant, Michael H. Coen, was seriously injured. He suffered severe
contusions of his lung and shoulder and various injuries to his ribs, head,
neck, and back. He lost 50% use of the right shoulder. The record reveals that
prior to the accident he had emphysema and his breathing capacity was reduced
to 44% but he was not incapacitated; he worked full time as a locomotive
engineer for the Wheeling-Pittsburgh Steel Company and was able to bowl, play
golf, and lead a normal life. The lung injury aggravated the emphysema, and he
has been unable to work since the accident. Michael Coen is required to use
oxygen continually for all but a few moments on his better days. He is in
continuous pain. His inability to breathe has necessitated frequent
hospitalization. According to the medical
122 REPORTS
STATE COURT OF CLAIMS [W. Va.
testimony, the claimant, Michael H.
Coen, is totally and permanently disabled, and his disabled lung, disabled shoulder,
facial scarring, and continuous pain are a proximate result of the accident.
His wife, the claimant, Ruth Coen, and other members or his family care for him
constantly. It has been necessary to expend large sums of money for physicians,
hospital, pharmacies, oxygen supplies, and other incidentals. The admitted
costs incurred by reason of the injuries were: $2,922.- 00 for doctors,
$22,940.00 for hospital costs, $2,825.68 for pharmacy expense, $77620 for
oxygen supplies and equipment, and $143.70 for ambulance service. At the time
of the accident Michael Coen was earning approximately $12,000.00 per year.
Since the accident he has been unable to work.
From the evidence, it is the opinion of the Court that the negligence of the
respondent was the proximate cause of the accident. Respondent failed to
provide for the safety of the traveling public during and after the application
of the antispalling compound to the highway. The surface of the highway was
treated by inexperienced personnel of the respondent. There were no warning
signs nor flagmen before, during, or after the job was completed. Accordingly,
the Court, after considering the medical expenses and loss of wages both
present and future, finds from the record that the claimants are entitled to recover,
and makes an award to the claimants in the amount of $65,000.00.
Award of $65,000.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 123
Opinion issued March 8, 1978
RICHARD L. WEEKLY
vs.
OFFICE OF EMERGENCY SERVICES
(No. CC-77-219a&b)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Claims CC-77-219a and CC-77-219b filed by the claimant, Richard L. Weekly,
against the respondent were consolidated for hearing.
CC-77-219a is a claim for $1,025.85 for 26 3/4 days leave which accrued to the
claimant as Administrative Officer for the respondent prior to his appointment
as Acting Director. Upon the hearing of the claim, the respondent, by counsel,
admitted the validity of the claim and that it should be paid.
CC-77-219b represents a claim for $1,144.98 filed by the claimant for the
difference between his salary as Acting Director of the respondent agency and
that of Administrative Officer for the months of July, August, and September.
1973. West Virginia Civil Service System Form CS-4 was introduced as Claimant?s
Exhibit No. 1. The Form, properly executed and approved, appointed the claimant
as respondent?s Acting Director effective July 2, 1973, at a salary of
$1,166.66 per month. The claimant was paid $785.00 per month for the months of
July, August, and September.
In view of the admissions made by the respondent in Claim CC-77-219a and the
evidence presented in Claim CC-77-219b, the Court is of the opinion to and does
make awards to the claimant as follows:
Claim No. CC-77-219a?$1,025.35
Claim No. CC-77-219b?-$1,144.98.
124 REPORTS STATE
COURT OF CLAIMS fW. Va.
Opinion issued April 3, 1978
ERVIN ARTHUR, ADMINISTRATOR OF THE ESTATE
OF CECIL C. BRUMFIELD, DECEASED
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-76-56)
E. G. Marshall, Attorney at Law, for the claimant.
Henry C. Bias, Jr., Deputy Attorney General, and Gerald Lacy, Assistant
Attorney General, for the respondent.
RULEY, JUDGE:
The claimant seeks damages in the sum of $115,000.00 for the alleged wrongful
death of Cecil C. Brumfield which occurred on August 6, 1975. On June 16, 1975,
Mr. Brumfield, then aged 77 years, was admitted as a patient to Huntington
State Hospital. He had been a patient there on one previous occasion, in 1967.
Without going into needlessly embarrassing detail, the evidence demonstrated
clearly that his condition both mental and physical, from the time of his
admission until his demise, was poor. At about 1:30 am, on June 22, 1975, he provoked
an altercation with another patient but apparently sustained no noticeable
injury. On July 30, 1975, he fell while walking in a hallway. He was examined
promptly after that fall by Vermald N. Constantino, M.D., a staff physician
who, incident to physical examination, ordered x-rays of the hips which were
interpreted as negative by both Dr. Constantino and G. M. Tolley, M.D., a
radiologist on the staff of Cabell Huntington Hospital.
On August 3, 1975, the claimant and his wife, who are the daughter and
son-in-law of the decedent, visited him at Huntington State Hospital and were
understandably upset and distressed by the radical change in his physical
appearance and condition. Following their visit, additional x-rays were taken
which were interpreted as showing a ?slightly displaced fracture involving the
neck of the right femur?. Mr. Brumfield was transferred to Cabell Huntington
Hospital on August 4, 1975, and expired there two days later.
W. VA.] REPORTS
STATE COURT OF CLAIMS 125
Numerous allegations of misconduct on the part of the respondent are made, but,
in sum, they assert that Mr. Brumfield?s death was caused by negligence of the
respondent in failing to provide proper care for him and, in particular, in
failing to transfer him to Cabell Huntington Hospital on July 30, 1975. In
fact, the decedent?s daughter testified that if he had been ?put in the
hospital the night he fell, July 30th? there would have been no claim.
To make an award in this case, the Court would be obliged to conclude that it
has been shown by a preponderance of the evidence that the respondent was
guilty of negligence which proximately caused the death of Mr. Brumfield. It is
urged that the Court should reach that conclusion solely upon the evidence of
the decedent?s physical condition on and after August 3, 1975. We cannot agree.
To do so would require speculation (in the absence of any direct evidence
whatever, it might be added) and, of course, this Court should not and cannot
base decisions on speculation. In that connection, Irvin M. Sopher, M.D., Chief
Medical Examiner of the State of West Virginia, who performed an autopsy upon
the decedent?s body, expressed the opinion that the decedent ?died as a result
of pneumonia and apparent cardiac failure complicating a fracture of the right
hip? and added that the pattern of bodily injuries which he had noted in his
report was not sufficiently specific to allow conclusions to be drawn regarding
their etiology or cause.
Claim disallowed.
Opinion issued April 3, 1978
MINNIE LEE BROWN
vs.
DEPARTMENT OF HIGHWAYS
(No. D-999)
Michael R. Crane, Attorney at Law, for claimant.
Nancy Norman, Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim was filed as the result of surface water damage to claimant?s
property. The claimant lives at 822 Avesta Drive
126 REPORTS STATE
COURT OF CLAIMS [W. Va.
in St. Albans, West Virginia. Avesta Drive is also Route 12/9 and has been
maintained by the respondent since 1950. Route 12/9 or Avesta Drive serves the
claimant and her neighbors and terminates 500 to 600 yards beyond the
claimant?s house. Avesta Drive was an unimproved dirt and gravel road 16 to 20
feet wide previous to the summer of 1976, at which time the respondent graded
the existing material and applied a 60- pound surface treatment of bituminous
material and aggregate to the road. Claimant?s property, which fronts 206 feet
on the road, is approximately 17? feet from the center of the road. The road
runs generally in an east-west direction and slopes downhill past the claimant?s
house. Originally, claimant?s house was below the level of the road. In 1970
she had her house raised 5 to 6 courses of cinder blocks to make it level with
the road. The area between the front of the house and the road was filled with
fill dirt. Across the road from the claimant?s home is a hill section. The
natural drainage of this area flows into a drain at the edge of the road
emptying into a culvert and pipe which carries the water under the road and
into a natural ravine on claimant?s property 20 to 25 feet from her house.
The claimant testified that, over the years, the respondent?s road maintenance
consisted of grading and filling holes with additional dirt and rock. The
continual filling of holes and grading of the road raised the elevation of the
road and caused surface water to flow down the road and off in front of her
house. The water washed out the fill in front of the house, damaged the porch
and downspout, and created some dampness in the basement. She further testified
that the pipe under the road had not been maintained properly, causing the
water to flow under rather than through it, the resulting soil erosion causing
damage to her property. She complained to the respondent on many occasions, but
little was done to correct the damage problems. In an effort to improve the
flow of water under the road she put an extension an the existing pipe.
Joseph T. Deneault, respondent?s maintenance engineer for Kanawha County,
testified that the road was not a high speed, highly constructed road. The road
is crowned and the surface water flows to both sides. He stated that a section
of the road approximately 5 feet wide and extending approximately 30
W. VA.] REPORTS
STATE COURT OF CLAIMS 127
feet in front of claimant?s house slopes towards the house, and that surface
water flows onto claimant?s property at this point. He further testified that
the re-surfacing of the road in 1976 probably raised the elevation of the road
one inch. He was unable to testify as to the maintenance in previous years
because he had been in his present position for only approximately 1? years. He
stated that the pipe under the road had settled away from the existing culvert,
causing water to flow underneath the pipe, except in heavy concentrations of
water when it flows under and through the pipe. The water under the pipe causes
the soil to erode. From the evidence, it is the opinion of the Court that the
respondent was negligent in its failure to provide proper maintenance to the
road and the drainpipe under it. The lack of proper maintenance was the
proximate cause of the damage to claimant?s property, and she is entitled to
recover. The Court, having considered the record and the values established in
the appraisals offered into evidence, makes an award of $4,500.00 to the
claimant.
Award of $4,500.00.
Opinion issued April 3, 1978
WILLIAM C. GRIFFING
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-50)
The claimant appeared in person.
Gregory W. Evers, Attorney at Law, for the respondent. WALLACE, JUDGE:
On March 3, 1977, the claimant was driving his 1970 Toyota automobile on the
main road through Cabin Creek, Kanawha County, West Virginia. Although the
record does not disclose the road designation, the respondent admitted that it
was maintained by the Department of Highways. The road is a two-lane highway.
The weather was clear, the road dry. Although it was not yet dark, the
claimant?s automobile lights were on.
128 REPORTS STATE
COURT OF CLAIMS [W. Va.
The claimant testified that the road was in bad shape and that he was driving
at approximately 10 to 15 miles per hour. As he rounded a curve or bend in the
highway, his automobile struck a hole in the pavement. His right front wheel
rim and tire were damaged.
The law of West Virginia is well established that the State is neither an
insurer nor a guarantor of the safety of travellers on its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947), Parsons v. State Road Commission, 8 Ct. Cl. 35. There is no evidence in the record of any prior notice to
the respondent. The existence of road defects without notice to the respondent
is not sufficient to establish negligence. Proof that respondent had notice of
the defect in the road is necessary. Lowe
v. Department of Highways, 8
Ct. Cl. 210 (1971).
Accordingly, the Court is of the opinion to and does hereby disallow the claim.
Claim disallowed.
Oprnon tssued April 3, 1978
LLOYD HARDING GWINN
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?77-191)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
WALLACE, JUDGE:
On August 24, 1977, at about 10:30 a.m., the claimant was driving his 1976 Ford
Bronco in a northerly direction on West Virginia Route 20. He was proceeding
from his home in Leivasy to keep an appointment with a doctor in Richwood. At
the time it was raining very hard, and, according to the claimant, it had
rained throughout the entire night. As the claimant came out of a turn near the
Nettie Grade School, he observed a large accumulation of water on the road
about eighty to ninety feet
W. VA.]
REPORTS STATE COURT OF CLAIMS 129
ahead of him. Route 20 at this point
is a two-lane asphalt road, one lane for northbound traffic and one lane for
southbound traffic, and the lanes are separated by double yellow lines. The
road is crowned in the middle to facilitate drainage, and, as was established
by the evidence, is seven inches higher in the center of the road than at the
edges of the roadway.
The claimant testified that he was traveling between 30 and 35 miles per hour
when he first observed the water which was entirely covering his northbound
lane of travel, and that while he slowed his vehicle, he lost control of it
when it entered the water. As a result, the vehicle struck the embankment on
the right-hand side of the road and was damaged to the extent of $517. Claimant
also testified that he had unobstructed vision
150 to 175 feet north of the accident scene and that no traffic was approaching
from the opposite direction, but that he did not avoid the water by proceeding
left of center for fear that he would be violating the law in crossing a double
line.
The testimony further revealed that the water had accumulated on the road as
the result of a clogged culvert on the east side of the road. The claimant was
of the opinion that the water was from 12 to 18 inches deep on the right-hand
or east edge of the road, and Hubert H. Greathouse, who resided near the
accident scene and who testified on behalf of claimant, was of the opinion that
the water was 18 inches deep at the edge of the road. On the other hand, H. B.
Dodrill, a maintenance foreman of respondent, testified that when he arrived at
the accident scene shortly after claimant?s vehicle had been removed, the water
at the right-hand side of the road was only 4 inches deep.
The witness Greathouse clearly established that respondent had prior knowledge
of the clogged culvert. Two weeks prior to the accident he had visited
respondent?s headquarters and complained about stagnant water standing in the
culvert, and a week later, respondent?s employees had inspected the culvert but
made rio repairs. Greathouse further testified that at approximately 9:00 am.
on the morning of the accident, his wife, at his request, phoned respondent?s
headquarters and reported the water accumulation, but nothing was done until
after claimant?s accident. While this Court is of the opinion
130 REPORTS STATE
COURT OF CLAIMS [W. Va.
that the negligence of the respondent in failing to maintain the subject
culvert has been established, we are equally convinced that the claimant?s own
testimony demonstrates that he was guilty of contributory negligence which
proximately contributed to claimant?s accident. While it is most laudable for
claimant to have refused to cross the double line for fear of violating the law,
his falure to do so when there was no approaching traffic for a distance of
some 150 to 175 feet constituted negligence, and, for that reason, we make no
award.
Claim disallowed.
Opinion issued April 3, 1978
NATHAN HADDAD, JR.
vs.
DEPARTMENT OF MOTOR VEHICLES
& DEPARTMENT OF FINANCE & ADMINISTRATION
(No. CC-77-2)
Stephen A. Mallory, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
This claim was filed by Nathan Haddad, Jr. against the respondents for pay
allegedly due for unpaid accumulated compensatory time while an employee of the
respondents. The claimant started work with the Department of Motor Vehicles in
1963. He was transferred to Information Systems Services Division (ISSD) of the
Department of Finance and Administration in 1971. During most of his
employment, his immediate supervisor was Fred Michael, Jr. Rachael Pendleberry,
the secretary for Michael, gave the claimant a slip of paper with her typed
signature on it which stated that as of August 31, 1973, the claimant had
accumulated 517? hours of compensatory time. She testified that she kept her
own records which were not official.
Employees of the respondent were called as witnesses by the claimant. The
testimony of these witnesses established that
W. VA.i REPORTS
STATE COTJRT OF CLAIMS 131
there was no record made of compensatory time. Fred Michael testified that
during the time the claimant worked for the Department of Motor Vehicles,
employees were allowed time off during slack periods to compensate for periods
when they were required to work overtime. The claimant had the same right as
other employees, and Michael testified that the claimant had taken time off
under this program.
Civil Service was started in the fall of 1968, at which time compensatory time
could not be accumulated in excess of 40 hours without written permission of
the appointing authority. There was no evidence that written authority was
given to accumulate compensatory time for the claimant.
Harold Casali, Director of ISSD, testified that he had no knowledge of claimant?s
claim until 1976, just prior to his resignation to take other employment. He
stated that for the past five years, the West Virginia Wage and Hour Law
requirements had been met. Compensatory time was either taken within two weeks
or the employee was paid overtime.
The claimant testified that 75 to 80 percent of the time claimed was accrued
while he was employed by the Department of Motor Vehicles. The witness Michael
testified that if there was accumulated compensatory time, 90 percent accrued
prior to claimant?s transfer from the Department of Motor Vehicles in 1971. The
evidence does not disclose the existence of any record which would justify an
award by this Court. The only evidence of compensatory time is the slip of
paper introduced as Claimant?s Exhibit No. I showing 572? hours accrued time as
of August 31, 1973. The secretary who prepared the slip stated that the
information was not taken from any official records but was a continuation of
work of prior secretaries. The claimant?s superiors testified that there were
no records kept; that compensatory time was not transferable; and that time
could not accumulate in excess of 40 hours without written permission.
The respondents, in addition to denying the claim, alleged that the claim was
barred by the Statute of Limitations under the provisions of West Virginia Code
Chapter 21, Article 5C, Section 8, which provides:
132 REPORTS STATE
COURT OF CLAIMS [W. Va.
?(a) Any employer who pays an employee less than the applicable wage rate to
which such employee is entitled
by virtue of this article shall be liable to such employee for the unpaid
wages; .
(d) In any such action the amount
recoverable shall be limited to such unpaid wages as shall have been paid by
the employer within two years next preceding the commencement of such action.. .
This claim was filed on January 5, 1977.
Claimant?s Exhibit No. 1 purports to show 517? hours accrued compensatory time
as of August 31, 1973. There is no evidence of time claimed subsequent to this
date. Therefore, the provisions of the statute are applicable to this claim.
For reasons herein set out, the Court disallows the claim of the claimant.
Claim disallowed.
Opinion issued April 3, 1978
EDITH ANN THOMPSON
& ROGER DALE THOMPSON
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-77-7)
Thomas M. Hayes and Charles
Moredock, Attorneys at Law, for
claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
This claim arose as the result of an accident in the Kanawha State Forest in a
picnic area known as Rattle Snake Run maintained by the respondent. On July 17,
1976, the claimants and their children arrived at the Rattle Snake Run picnic
area at approximately 2:30 p.m. for a family picnic. They selected a spot where
two picnic tables had been placed together. The
W. VA.]
REPORTS STATE COURT OF CLAIMS 133
tables were eight to ten feet from a
fireplace. The claimant, Roger Dale Thompson, was building a fire in the
fireplace. His wife, Edith Ann Thompson, was nursing her nine-week-old baby at
the picnic table. Without warning, a large limb from a dead tree near the table
fell on Mrs. Thompson. She was injured and the table was damaged. The baby was
unhurt. Mrs. Thompson received a fracture of the right arm, a macerated
abrasion over her right ankle, a bump on the forehead, and an abrasion on her
right hip.
The Forest Superintendent, Osbra Eye, testified that he had knowledge of the
tree and that it had died the previous summer. It had not been removed because
he did not think it was a hazard. He stated that maintenance crews were
frequently in the area and did not report to him any apparent danger from the
tree. However, he further testified that decayed limbs from dead trees often
fail without warning, and after viewing photographs taken of the tree the day
after the accident, he stated that the tree appeared to be dangerous. The
photographs indicated that the top of the tree was in a state of advanced decay
and that many limbs had apparently fallen prior to the accident. The testimony
revealed that users of the picnic area often moved tables from one place to
another and that it was not the custom for maintenance crews to change their
location. In the instant case, no effort had been made by the respondent to
remove the tree or relocate the tables, although it was known the tree was dead
and in a decaying condition.
From the evidence, it is the opinion of the Court that the respondent was
negligent in failing to remove the dead tree, and its negligence was the
proximate cause of the injuries to the claimant, Edith Ann Thompson. Although
there were no permanent injuries, she required hospitalization and treatment.
The admitted costs incurred as a result of the accident were $1,230.50 for
doctors, $2,214.70 for hospital costs, $34.06 for medication, $112.00 for
radiology fees, and $36.05 for ambulance service. The Court finds that the
claimants are entitled to recover, and hereby makes an award in the amount of
$9,627.36.
Award of $9,627.36.
134 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued April 3, 1978
GERALD E. TINSLEY and
LOIS C. TINSLEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-165)
Claimants appeared in person.
Richard Canton, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Gerald E. Tinsley, a paramedic employed by the Charleston
Emergency Ambulance Service, and his wife, Lois Tinsley, also a claimant, were
riding his Suzuki motorcycle on the afternoon of July 13, 1977, in an easterly
direction on Coopers Creek Drive (W.Va. Route 41) in Kanawha County, and were
approaching its intersection with Ada Mae Drive. The claimant, Gerald E.
Tinsley, was operating the motorcycle. As they approached the above-mentioned
intersection, they entered a rather sharp turn to their right. As they rounded
the curve, they found that their lane of travel was almost completely covered
with an accumulation of water and mud resuiting from a clogged drainage ditch
located on the south side of Coopers Creek Drive.
Gerald E. Tinsley testified that when the motorcycle entered the water and mud
area, it started to fishtail and proceeded into the opposite lane of traffic
which was dry. At this point, Mr. Tinsley attempted to turn the motorcycle to
the right to avoid certain mailboxes located on the north berm of the road, but
by reason of the presence of gravel on that side of the road, the motorcycle
slid out from under them. As a result, Mr. Tinsley suffered a fracture of his
right clavicle or collar bone, and abrasions and cuts of his right shoulder and
knee. He was taken by ambulance to the Charleston Area Medical Center where he
received treatment in the emergency room and was discharged. No testimony was
introduced in respect to the injuries, if any, sustained by the claimant, Lois
Tinsley.
W. VA.J REPORTS
STATE COURT OF CLAIMS 135
In addition to suffering intense pain for a period of three days, the claimant
was unable to return to his employment for a period of ten weeks. At the time
of the accident, he was earning approximately $200.00 per week; he thus
suffered a loss of income of about $2,000.00. He incurred an ambulance bill of
$30.00 and total medical expenses of $172.75. Also, his motorcycle was damaged
to the extent of $300.97.
In respect to the issue of liability, we have consistently held that the
respondent is not an insurer of the safety of the users of the highways of this
State. Respondent?s duty in claims such as this one is to use ordinary care to
maintain Coopers Creek Drive in a reasonably safe condition, and the lack of or
failure to exercise ordinary care must be established by a preponderance of the
evidence. While the claimant testified that the mud and water on the road
resulted from a clogged drainage ditch on the south side of the road, no
evidence was introduced establishing how long this condition had existed prior
to the afternoon of the accident. Mr. Ti.nsley testified that he returned to
the accident scene the following day for the purpose of taking photographs of
the accident scene and that the road was clear of any mud and water.
Furthermore, there was a complete failure to establish that the respondent had
notice, either actual or constructive, of the condition of this portion of
Coopers Creek Drive. Such notice is an essential ingredient for establishing
liability. See Davis Auto Parts v.
Dept. of Highways, 12 Ct. Cl.
31(1977), Lowe v. Dept. of Highways, 8 Ct. Cl. (1971), and Varner v. Dept. of Highways, 8
Ct. Cl. 119 (1970). Being of the opinion that negligence on the part of
respondent has not been proved, this Court hereby denies the claim.
Claim disallowed.
136 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued April 3, 1978
DEMA MARIE WELCH
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-17)
Edward C. Goldberg, Attorney at Law, for the claimant.
Gregory W. Evers, Attorney at Law, for the respondent. WALLACE, JUDGE:
This claim arose as the result of a fall by the claimant in a hole on the
bridge across Elk River at Clendenin, West Virginia. The claimant had lived in
the vicinity for approximately 40 years, and in Clendenin for six years prior
to her accident.
On the morning of August 16, 1976, the claimant and her daughter,
granddaughter, and daughter-in-law were going by bus to Charleston. With other
passengers, they walked westerly across the Clendenin Bridge to the bus stop on
West Virginia Route 119. They used the pedestrian walkway on the right-hand or
upper side of the bridge. The claimant testified that the walkway was of wood
construction and was in bad condition. She further testified that a board was
missing in the walkway when she crossed over it on the morning of the day of
the accident. The party returned by bus that day. It was still daylight. The
claimant, carrying her purse and glasses in her hand and several packages in
her arms, proceeded with other bus passengers easterly across the bridge on the
same walkway she had used in the morning. There were people in front and in
back of her. As she was proceeding across the bridge, her daughter-in-law
warned her of the hole in the walkway. She fell into the hole about the same
time the warning was given. A policeman and others assisted her in getting out
of the hole. Her daughter-in-law drove her to a Charleston hospital where she
was a patient for almost two weeks. She suffered from bruises, abrasions, and
shock.
The claimant, according to the evidence presented in the record of this case,
was guilty of contributory negligence as a matter of law. Had she exercised the
reasonable care required
W. VA.]
REPORTS STATE COURT OF CLAIMS 137
of her under the circumstances and
maintained a proper and effective lookout for the hole which she knew to be
there, she would have seen it in time to avoid injury. To be actionable, the
negligence of the respondent must be the proximate cause of the injury. The
Court is of the opinion and finds that under the circumstances of this case,
the condition of the bridge was not the proximate cause of the accident. The
claimant?s failure to take the necessary precautions for her own safety was the
proximate cause of her injury.
Accordingly, the claim is disallowed.
Claim disallowed.
Opinion issued May 1, 1978
ROBERT A. HEATER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?77-179)
No appearance by the claimant.
Gregory W. Evers. Attorney at Law, for the respondent. WALLACE, JUDGE:
This claim in the amount of $2,038.00 was submitted to the Court upon the
pleadings. The claimant was Chief Inspector for the respondent on Project
APD-484 (11)C-2. On June 4, 1975, he became involved in an argument with Dewey
Moore, an employee of the J. F. Allen Company, contractor for the project. The
argument apparently resulted in a fight between the claimant and Moore. As a
result of the altercation, the claimant entered a plea of nob contendere to a
charge of assault and battery and was fined $38.00. He settled for $1,500.00 in
a civil action filed against him by Moore, and incurred attorney fees in the
amount of $500.00. This claim was filed to recover these amounts from the
respondent.
The respondent filed its Answer admitting that the claimant was an employee
working within the scope of his employment
138 REPORTS STATE
COURT OF CLAIMS [W. Va.
and further admitting the allegations of the claim and exhibits and that the
respondent is obligated in the amount of the claim. The Court disagrees.
The test of liability of the principal for the tortious act of his agent is
whether the agent at the time of the commission of the act was acting within
the scope of his authority in the employment of the principal, and not whether
the act was in accordance with his instructions. If such act is done within the
scope of authority and in furtherance of the principal?s business, the
principal is responsible. But if the agent steps outside the boundaries of the
principal?s business, for however short a time, the agency relation is for that
time suspended, and the agent is not acting within the scope of his employment.
TnState Coach Corporation v. Walsh, 188 Va. 299, 49 S.E.2d 363 (1948). In the case of Porter v. South Penn Oil Company, 125 W.Va. 361, 24 S.E. 2d 330 (1943), the Supreme Court
of Appeals of West Virginia held:
?Before a master can be held liable for an assault upon a third person,
committed by his servant, it must be shown that such assault was committed,
either by the direction of the master, or in the performance by the servant of
duties within the scope of his employment, or in the course of and connected
with such employment.?
The action of the claimant as an employee of the respondent was not within the
scope of his employment and was not such action that could reasonably be expected
of an employee in the type of work he was performing. Therefore, there could be
no liability on the part of the respondent. The pleadings and exhibits
submitted to the Court for decision revealed that the claimant entered a plea
of nob contendere to a charge of assault and battery and settled a civil action
resulting from the criminal charge, neither of which is anticipated as being
within the scope of his employment. For the reasons herein stated, the Court
disallows the claim.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 139
Opinion issued May 1, 1978
GERALDINE MAY McCARTHY, ADMINISTRATRIX
OF THE ESTATE OF ROBERT EUGENE McCARTHY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-33)
David Robertson and Martin
Gaughan, Attorneys at Law, for the
claimant.
Henry C. Bias, Jr., Deputy Attorney General, and Gregory W. Evers, Attorney at Law, for the respondent.
RULEY, JUDGE:
On June 5, 1975, claimant?s decedent was driving north on West Virginia Route 2
near Follansbee when his car slid to the left, crossed three lanes of traffic,
and collided with a telephone pole, killing him. Claimant, seeking damages for
the alleged wrongful death, alleges that the respondent negligently caused
gravel and slate to be on the road which, moistened by rain, caused the road to
be slippery and thereby caused the accident.
The State is neither an insurer nor a guarantor of the safety of motorists
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947); Lowe v. Department of Highways, 8 Ct. Cl. 210 (1971). Thus, establishing negligence on
the part of the respondent requires proof that respondent failed to conform to
a standard of ?reasonable care and diligence * * * under all circumstances.? Parsons v. State Road Commission, 8 Ct. Cl. 35 (1969). The evidence in this case fails to
meet that burden of proof. In fact, the evidence is conflicting regarding the
very existence of the alleged dangerous condition. Several witnesses testified
that road repair crews, working on the berm near the accident site on the day
of the accident, did not leave any dirt or slag on the highway. The police
officer who arrived on the scene immediately after the accident testified that
the road was wet, but that there was no debris on the highway. Others reported
?dirt and mud laying on Route 2?, and one witness said, ?The road was covered
with slag and cinders.? Even if the Court concludes that there was debris on
the road, it could not
140 REPORTS
STATE COURT OF CLAIMS [W. Va.
conclude that its presence there was
caused by negligence on the part of the respondent.
The evidence also is conflicting as to whether the road was wet or dry. Wet
roads, like roads with a splattering of dirt or gravel, are obvious dangers for
which drivers should take reasonable precautions. ?Ordinary prudence requires a
driver to take greater care in keeping control of his vehicle under such
adverse (wet) conditions.? Frazier v.
Department of Highways, 9
Ct. Cl. 171 (1972). Certainly, the respondent cannot be held responsible for
whatever moisture, if any, fell on the roadway. If the respondent knew or in
the exercise of ordinary care should have known that rain would create an
especially dangerous condition at the place where the accident happened, and
failed to take reasonable precautions to protect motorists, then perhaps the
respondent would have been guilty of negligence. (See Frazier, supra:) But there was no evidence to that effect. For the foregoing reasons, the
claim must be denied.
Claim disallowed.
Opinion issued May 1, 1978
CONNIE LYNN MILLER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-124)
Larry S keen, Attorney at Law, for claimant.
James W. Withrow, Attorney at Law, for respondent. WALLACE, JUDGE:
The claimant seeks damages in the amount of $6,300.35 from the respondent
occasioned by an automobile accident on June 17, 1976. The accident occurred at
approximately 5:30 a.m. The claimant lived about three miles north of Spencer,
West Virginia, at Tariff, West Virginia. She was employed by Norris Industries
in Spencer. On the morning of the accident, the claimant was driving alone to
work on West Virginia Route 14 in her 1974 Ford Pinto. There had been unusually
heavy rain-
W. VA.]
REPORTS STATE COURT OF CLAIMS 141
fall during the night. At a point
approximately 1/z
mile from Spencer, she entered a curve
in the highway where she encountered gravel across the highway washed there by
the night rain. She testified that the speed limit was 25 miles per hour and
that she was travelling at 20 to 25 miles per hour. She stated that she
attempted to slow down but the automobile started to slide. The vehicle slid
into an embankment on the left side of the highway, proceeded back across the
road, over a guardrail, and down into a ravine. The automobile was destroyed.
The claimant received injuries requiring hospitalization for five days. She was
unable to return to work until July 12, 1976.
Corporal Stanley B. Rexrode of the West Virginia State Police testified that
after being notified of the accident he arrived at the scene at approximately
6: 10 a.m. He assisted in the removal of the claimant from her automobile. His
investigation revealed that the claimant?s automobile had skidded 75 feet
before hitting the embankment, then proceeded across the highway, over the top
of the guardrail, and into a ravine, a total distance of 151 feet. He stated
that there was a heavy concentration of gravel in the curve of the roadway from
the washout due to summer thunderstorms the night before. The road had recently
been blacktopped, and the berm had been raised to correspond with the blacktop.
Gravel had been placed on the berm the entire contract length. He stated that
during the construction there had been gravel on the road on one other
occasion. This was reported, and the gravel was removed by the respondent.
In line with decisions of the Supreme Court of Appeals of West Virginia, this
Court has consistently held that the State is not a guarantor of the safety of
travelers on its roads. The user of the highways travels at his own risk. Acikins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947); Parsons v. State Road Comm?n., 8
Ct. Cl. 35 (1969). For negligence of the respondent to be shown, proof that the
respondent had actual or constructive notice of the defect in the road is
required. Davis Auto Parts v.
Department of Highways, 12
Ct. Cl. 31 (1977); Lowe v. Department of Highways, 8 Ct. Cl. 210 (1971); Varner v. Department of Highways, 8 Ct. Cl. 119 (1970). There is no evi
142 REPORTS STATE
COURT OF CLAIMS [W. Va.
dence in the record of any notice to the respondent that the gravel had washed
on the highway during the night; the existence of the gravel in the road does
not in itself establish negligence per se. Light v. Department of Highways, 12 Ct. Cl. 61 (1978).
From the record, the Court does not believe there is a clear showing that the
respondent knew or should have known a condition existed which would be
expected to cause injury or damage to the claimant.
Accordingly, this Court finds that the claimant is not entitled to recover the
damages sustained by her, and hereby disallows the claim.
Claim disallowed.
Opinion issued May 1, 1978
MORRISON PRINTING CO., INC.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-36)
Claimant appeared through its president, J.
C. Morrison. Anthony G. Halkias, Attorney
at Law, for respondent.
PER CURIAM:
According to a written stipulation filed by the parties, the respondent
contracted with the claimant whereby the latter was to print the West Virginia
State Map. The stipulation further provides that employees of respondent
wrongfully delayed claimant from performing the contract within the contract
time schedule, and as a result, claimant suffered financial losses and damages;
that the losses and damages sustained by claimant include, but are not limited
to, loss of 140 hours of press time, the purchase of press time from another
printer, loss of time by claimant?s employees in re-scheduling of printing, and
an expense for insuring and warehousing additional paper in inven
W. VA.]
REPORTS STATE COURT OF CLAIMS 143
tory at the close of claimant?s fiscal
year; and that claimant sustained losses and damages in the amount of
$3,000.00.
Pursuant to the stipulation as outlined above, an award in favor of claimant in
the amount of $3,000.00 is hereby made.
Award of $3,000.00.
Opinion issued May 1, 1978
MAXINE V. PAULEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-208)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Maxine V. Pauley, seeks damages in the amount of $206.05 incurred
when she drove her 1973 Mercury Montego automobile over a manhole in Nitro,
West Virginia, on October 4, 1977. The claimant had parked her automobile on an
unpaved portion of land on the west side of West Virginia Route 25 across the
highway from the Rite-Aid Pharmacy at 23rd Street in Nitro. When she returned
to her automobile she started forward and the left front wheel of her
automobile dropped into a manhole. The left front fender was damaged and the
chrome strip was torn from the door.
George P. Sovick, Chief Engineer of respondent?s Right of Way Division,
testified that the manhole in question was located on a twelve-foot strip of
land twelve feet from the right of way of West Virginia Route 25 on the line
between property belonging to the City of Nitro and the New York Central
Railroad. He further stated that the manhole was not maintained by the
respondent, and this testimony was not rebutted. The respondent introduced as
its Exhibit No. 2 a certified copy of a deed by which the City of Nitro
acquired in 1959 the twelve- foot strip of land adjacent to West Virginia Route
25 on which the claimant had parked her automobile.
144 REPORTS
STATE COTJRT OF CLAIMS [W. Va.
It is apparent from the record that
the accident did not occur on State-owned property and the manhole in question
was not maintained by the respondent. Accordingly, the claimant?s claim is
disallowed.
Claim disallowed.
Opinion issued May 1, 1978
PRIVATE DIAGNOSTIC CLINIC,
SURGiCAL PROFESSIONAL PROGRAMS OFFICE
vs.
DIVISION OF VOCATIONAL REHABILITATION
(No. CC-77-224)
No appearance by the claimant.
Frank M. Ellison, Deputy Attorney General, for the respondent.
PER CURIAM:
This claim was submitted upon the pleadings by agreement of the parties. The
claimant filed its claim in the amount of $399.18 alleging it had not received
payment on an authorization for medical expenses incurred by a patient at the
Duke University Medical Center in 1975. The respondent?s Answer admits the
validity of the claim and states that there were sufficient funds with which to
pay the claim but that the invoice had not been timely submitted.
Accordingly, the Court makes an award in favor of the claimant in the amount of
$399.18.
Award of $399.18.
W. VA.] REPORTS
STATE COURT OF CLAIMS 145
Opinion issued May 1, 1978
JEANNE ROBINSON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-33)
Lawrence L. Manypenny, Attorney at Law, for claimant.
Richard Canton, Attorney at Law, for respondent.
WALLACE, JUDGE:
Claimant filed a claim in the amount of $15,500.00 against the respondent for
injuries received as the result of a fall. Claimant was an employee of the
Department of Welfare. On April 17, 1975, at approximately 3:00 p.m., the
claimant, with a friend, was returning to her automobile across the street from
the Welfare Office in the 400 block of Main Street in Wheeling, West Virginia.
Main Street is also West Virginia Route 2. The weather was clear, the sun shining.
As the claimant approached the other side of the street from the Welfare
Office, and before her companion could warn her, she stepped into a hole in the
surface of the pavement and fell. She received a sprained fracture of her left
ankle and was hospitalized until April 21, 1975.
It is well established that the State is neither an insurer nor guarantor of
the safety of persons travelling on its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E. 2d 81 (1947). The same is applicable to
pedestrians crossing the highway. To establish negligence, there must be proof
that the respondent had actual or constructive notice of the defect in the
road. Light v. Department of Highways, 12 Ct. Cl. 61 (1978); Lowe v. Department of Highways, 8
Ct. Cl. 210 (1971); Varner v.
Department of Highways, 8 Ct. Cl. 119
(1970). Without notice to the respondent, the mere existence of a defect in the
road surface is not negligence per se. Light
v. Department of Highways, 12 Ct. Cl.
61 (1978).
Accordingly, the Court is of the opinion to and does disallow the claim.
Claim disallowed.
146 REPORTS
STATE COURT OF CLAIMS [W. Va.
Advisory Opinion issued May 25,
1978
DEPARTMENT OF EMPLOYMENT SECURITY
vs.
DEPARTMENT OF HEALTH
(No. CC-78..43)
Herman E. Rubin, Special Counsel, for claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for an advisory opinion pursuant to Code 14-2-18. From
the Notice of Claim and the respondent?s Answer, it appears that Barboursville
State Hospital, as a result of a miscalculation, underpaid its statutory
contribution to claimant in the last two quarters of fiscal 1975-76. This
underpayment amounted to $1,917.17. Claimant is also seeking interest on this
underpayment at the rate of one percent per month pursuant to Code 21A-5-17.
The accrued interest on the underpayment, as of the date of the submission of
the claim to this Court, amounted to $509.40, resulting in a total claim of
$2,426.57.
The respondent, in its Answer, admits that there were sufficient funds
available at the close of the pertinent fiscal year from which this claim could
have been paid. It is therefore clear that the respondent is legally liable to
claimant in the amount of $1,917.17, the amount of the underpayment. With
respect to the claim for accrued interest, being restricted by Code 14-2-12
from awarding interest unless the claim arises on a contract specifically
providing for the payment of interest, we conclude that respondent is not
legally liable for the payment of the accrued interest. Since this is an
advisory opinion, no award will be made, but the Clerk of this Court is
directed to file this opinion and to forward copies thereof to the respective
department heads of claimant and respondent.
W. VA.]
REPORTS STATE COURT OF CLAIMS 147
Optnion issued May 25, 1978
TIMOTHY RAKES, by his father
and next friend, ANDREW RAKES,
and ANDREW RAKES
vs.
BOARD OF EDUCATION OF THE
COUNTY OF LINCOLN,
and BENJAMIN HATTEN
(No. CC-77-55)
Robert W. Lawson, III, Attorney at Law, for claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondents. PER CURIAM:
In this claim, claimant Andrew Rakes, as next friend of his son, Timothy Rakes,
seeks recovery for injuries received by his son in a physical education class
conducted at the Harts High School in Harts, Lincoln County, West Virginia; in
addition, he seeks recovery in his individual capacity for medical expenses
incurred by him in effecting a cure of his son?s injuries. The high school was
controlled and maintained by respondent Board of Education of Lincoln County,
and the physical education class was under the supervision of the respondent,
Benjamin Hatten, an agent and employee of the Board of Education of Lincoln
County.
The respondents have filed a Motion to Dismiss, and a more detailed discussion
of the facts is not needed in order to rule on this motion. In the motion, the
respondents contend that this Court has no jurisdiction to hear a claim against
an individual employee of the State, and with this contention we agree. The
respondents further contend that this Court has no jurisdiction to hear a claim
against a board of education, and with this contention we also agree. The
jurisdiction of this Court is clearly set forth and limited by Code 14-2-13,
which reads in part as follows:
?The jurisdiction of the court, except for the claims excluded by section
fourteen (? 14-2-14), shall extend to the following matters:
148 REPORTS
STATE COURT OF CLAIMS [W. Va.
1. Claims and demands, liquidated and
unliquidated, ex contractu and ex delicto, against the State or any of its agencies ? (Emphasis supplied.)
Code 14-2-3 defines the term ?state agency? as follows:
??State agency? means a state department, board, commission, institution, or
other administrative agency of state government: Provided, that a ?state agency? shall not be
considered to include county
courts, county boards of education, municipalities, or any other political or local
subdivision of the State regardless of any state aid that might be provided.?
(Emphasis supplied.)
It is apparent from the foregoing that the respondents? Motion to Dismiss must
be granted.
Opinion issued June 15, 1978
ODLUND HANEY SPANGLER, JR.
vs.
DEPARTMENT OF EMPLOYMENT SECURITY
(No. CC-78-86)
Claimant appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The pleadings establish that the claimant was hired by respondent on a 30-day
emergency appointment from January 16, 1978 through February 15, 1978, as an
Employment Interviewer I at a monthly salary of $608.00. Due to a clerical
error, the official records reflect that the claimant was hired as a Clerk I (a
lower salaried classification), all of which resulted in a gross pay for the
month in question of $88.50 less than the amount to which he was entitled, The
Answer of respondent admits these facts, and states that respondent attempted
to rectify the error but that the State Auditor has refused to make payment to
the claimant on the basis that such a payment would constitute a retroactive
salary increase contrary to State
W. VA.] REPORTS
STATE COURT OF CLAIMS 149
law. As this situation arose due to an error, the payment does not constitute a
retroactive increase. The Court hereby makes an award to the claimant in
accordance with the provisions in W. Va. Code, Chapter 14, Article 2, Section
19.
Award of $88.50.
Opinion issued June 22, 1978
RUSH FIELDS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-77)
John F. Bronson, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
On February 13, 1978, the claimant?s wife was operating his 1974 Chevrolet
Caprice on Route 52 in Gilbert, West Virginia, and was crossing the Gilbert
Bridge when it struck a ?? metal plate which had become loose and was in an
upright position. The parties have stipulated that the bridge was owned and
maintained by the respondent, and that the claimant?s vehicle sustained damages
amounting to $1,142.18. Being of the opinion that liability exists and that the
claimed damages are reasonable, the Court hereby makes an award in favor of the
claimant in the amount of $1,142.18.
Award of $1,142.18.
150 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued June 22, 1978
UARCO, INCORPORATED
vs.
BOARD OF REGENTS
(No. CC-78-53)
Milton S. Koslow, Attorney at Law, for claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. PER CURIAM:
The Notice of Claim reflects that in March of 1976, the respondent?s West
Virginia Institute of Technology forwarded a purchase order to claimant for
10,000 printed forms. These forms were shipped by claimant to respondent on May
14, 1976, and claimant thereafter invoiced respondent on July 13, 1976, for
$713.18. Respondent has filed an Answer admitting ordering and receiving the
subject forms, but assigning as a reason for the non-payment of the invoice
that it was not received prior to the close of fiscal year 1975-76. The Answer
further admits that the sum of $713.18 is due and owing the claimant, and that
sufficient funds were available to pay the invoice had the same been submitted
prior to the close of fiscal year 1975-76.
On the basis of the foregoing, an award in favor of claimant in the amount of
$713.18 is hereby made.
Award of $713.18.
W. VA.] REPORTS
STATE COURT OF CLAIMS 151
Opinion issued July 12, 1978
LILLIAN M. HOLSTEIN
vs.
PUBLIC EMPLOYEES RETIREMENT SYSTEM
(No. CC-78-78)
Claimant appeared in person.
Edward Gardner and Gregory Elliott, Assistant Attorneys General, for respondent.
GARDEN, JUDGE:
The claimant, a former employee of the Department of Welfare, is requesting
this Court to direct the respondent to pay her retirement benefits which she
claims she is legally entitled to receive. Counsel for the respondent filed a
Motion to Dismiss asserting, inter alia, that this Court does not have
jurisdiction to grant the requested relief. At the hearing, a ruling on the
Motion to Dismiss was taken under advisement, and evidence was presented on the
merits of the claim.
The evidence disclosed that the claimant was first employed by the Department
of Welfare on August 23, 1965, where she remained in varying capacities until
May 11, 1974, a service credit period of some 104 months. Prior to her
employment by the Department of Welfare, the evidence further disclosed that
claimant had been employed as a substitute teacher by the Raleigh County Board
of Education during fiscal year 1963-64, and also that she had been employed by
the same agency on a full-time basis during fiscal year 1964-65. Apparently during
the early part of 1974, the claimant was offered a more attractive position
with the federal Social Security Administration, but before resigning from her
position with the Department of Welfare, she made inquiry of employees of
respondent who assured her that if she had attained two years of service credit
as a result of her service with the Raleigh County Board of Education, that she
would be eligible for retirement benefits under the West Virginia Public
Employees Retirement System. With this information the claimant resigned and
accepted employment with the federal government, but most re
152 REPORTS
STATE COURT OF CLAIMS [W. Va.
grettably, within six weeks she was
forced to resign from her position due to a serious illness, and as a result,
has been unable to resume her working activities.
Jewell Dye, chief retirement consultant for respondent, testified that she
indeed recalled talking by phone with the claimant on several occasions in the
early months of 1974, and that she did advise the claimant that if she had paid
into the retirement fund for a period of two years with the Teachers Retirement
Fund, that with the excess of eight years of service with the Department of
Welfare she would have attained the necessary service credit of ten years which
would entitle her to retirement benefits. Ms. Dye testified that she advised
claimant that before a final determination as to eligibility could be
determined, it would be necessary to obtain confirmation of the prior service
from the Teachers Retirement Fund. After requesting such confirmation, it was
determined that claimant, during fiscal year 1963-64, had been employed only on
a substitute teacher basis, and that during that year had only worked for a
one-month period in excess of 10 days, and that as a result was only entitled
to one month?s service credit for fiscal year 1963-64, which coupled with the
12 months credit for fiscal year
1964-65, meant claimant had only 13 months available for transfer from the
Teachers Retirement System to the West Virginia Public Employees Retirement
System. All of this was regrettably determined after the claimant terminated
her employment with the Welfare Department, and thus after 9 years and 9 months
of satisfactory service, the claimant was 3 months shy of attaining the
necessary 10 years of service credit.
While it is most lamentable that these situations occur, we are of the opinion
that we do not possess the statutory jurisdiction to direct the respondent to
award retirement benefits to claimant, and for that reason, the Motion to
Dismiss should be sustained, but beyond that, because on the merits of the case
we do not feel that the claimant has established that she is entitled to the
claimed retirement benefits, we must and do hereby refuse to make an award to
the claimant.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 153
Opinion issued July 12, 1978
HERMAN F. LILLY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-133)
Walton S. Shepherd, III, Attorney at Law, for claimant. Nancy J. AUff, Attorney
at Law, for respondent.
PER CURIAM:
This claim was submitted for decision on the agreed facts set forth in a
written stipulation which revealed that during the year 1971, respondent
performed work on Project 6811 on Kanawha County Route 1/4 known as Angel Fork
Road in Jefferson District; that respondent?s work blocked a stream on the
property of the claimant causing periodic flooding; that claimant?s property
was also damaged by a slip caused by work on the project; that respondent had
knowledge of the conditions caused by its work but failed to take corrective
measures; that claimant employed Lovell Johnson to perform corrective work at a
cost of $1,200.00. By reason of the foregoing and believing that liability
exists on the part of the respondent, the Court makes an award in favor of the
claimant in the amount of $1,200.00.
Award of $1,200.00.
Opinion issued July 12, 1978
DELORIS J. LIVELY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-228)
Debris J. Livety, the claimant, appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
Claimant testified that she was operating her 1971 Chevrolet automobile in a
northerly direction on Green brier Street in
154 REPORTS STATE
COURT OF CLAIMS [W. Va.
Charleston on the morning of July 7, 1977, and was making a left turn from that
street in order to proceed in a westerly direction on Interstate 64. She was
ascending a hill on Greenbrier Street as she approached its intersection with
Interstate 64 when she suddenly came upon a large ?blotch? of yellow paint
which apparently had been spilled on the street. She further testified that
yellow center lines in the immediate area appeared to be freshly painted and
that she also observed a truck in the area with a center line painting
attachment on its rear, but that she could not identify it as being one of
respondent?s pieces of equipment.
Claimant, after arriving at her place of employment, phoned respondent?s office
and reported the incident, and she was advised that they (the respondent) were
aware of the spilled paint and that she should obtain an estimate of the cost
to remove the paint from her car and take photographs of her car depicting the
areas damaged by the paint. The claimant thus obtained an estimate for the
paint removal from Tag Galyean Chevrolet, Inc. in the amount of $98.88, and
photographs of her car were introduced into evidence which clearly reflected
the existence of yellow paint on the right wheels and lower portion of the
right-hand side of the body of her car.
E. E. Goodwin, chief claims investigator of respondent, testified that
respondent maintained records reflecting the activities of its center line painting
crews and that he had carefully examined the pertinent records during the early
part of July 1977, and that they failed to disclose that respondent had
performed any center line painting at the subject intersection or had
transported any paint through the area.
The hearing in this claim was held on March 29, 1978, and the facts as set out
above were established. The Court was of the opinion that the claim should be
disallowed because the claimant had failed to establish by a preponderance of
the evidence that the respondent had in fact spilled the paint. However, prior
to the issuance of an opinion, it was brought to the attention of the Court
that employees of respondent did indeed spill the paint. As a result, the
Court, on its own motion, reopened the claim on July 5, 1978, to permit the
introduction of
W. VA.] REPORTS
STATE COURT OF CLAIMS 155
this after-discovered evidence in the form of the testimony of Bill G. Shuler.
Mr. Shuler testified that he is employed by respondent as a chemist with the
Materials Control Soil and Testing and that among his duties was the testing of
road paint for durability. He further indicated that on July 7, 1977, he and
other employees of respondent were transporting paint for testing purposes from
their office on Michigan Avenue in Charleston to Nitro; that they were using a
stake body truck with a section of the tailgate missing, and to keep the paint
cans from falling from the truck, they had placed garbage cans on the truck to
more or less block the missing tailgate section.
Mr. Shuler further testified that, as the truck neared the intersection of
Greenbrier Street and 1-64, two one-gallon cans of yellow paint fell from the
truck and ruptured when they struck the street. Before respondent?s employees
could get back to the area to warn motorists of the paint spill, Mr. Shuler
testified that cars were proceeding through the wet paint. He further indicated
that he called his office from Nitro and reported the incident but that he
never filed a report in writing, which accounts for E. E. Goodwin?s testimony;
that he (Goodwin) could find no record of painting or of paint being
transported at this intersection.
Being of the opinion that the respondent?s employees were negligent in
attempting to transport this paint in a truck with a missing tailgate section,
and being of the further opinion that the claimant was not guilty of
contributory negligence, we hereby make an award in favor of the claimant in
the amount of $98.88.
Award of $98.88.
156 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued July 12, 1978
R. H. BOWMAN DISTRIBUTING CO., INC.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-99)
W. H. Johnson, Business Manager of R. H. Bowman Distributing Co.,
Inc., appeared on behalf of claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
On April 15, 1976, Robert F. Hewitt, an employee of claimant, was operating
claimant?s tractor-trailer rig in a southerly direction on Secondary Route 79.
He was proceeding from Rainelle to the Pure Oil Refinery near Cabin Creek.
Secondary Route 79 at the time of the accident was a two-lane blacktop road. It
was daylight and the weather was clear and the roadway dry. Hewitt had just
driven onto Secondary Route 79 from Route 61 and was some 600 feet south of the
intersection of these two routes when he saw a flagman and a crew working on
Secondary Route 79. The flagman motioned for Hewitt to proceed, and as he
proceeded through the work area he encountered mud on the road. Hewitt
testified that as he proceeded through the mud something jerked his rig to the
right and into the ditch along the west side of the road. He was not sure
whether it was a pothole or something else that caused his rig to be jerked to
the right. The rig, principally the trailer whose frame had been bent, was
damaged, and the repair bill, including labor and material, amounted to
$1,410.77.
The Notice of Claim alleges that the accident was due to ?inadequate flagging
on a mud-slick section of the road.? The respondent denies that it was negligent
in any manner and further denies that the flagman who motioned Hewitt through
the work area was its employee. In support of this contention the respondent
called as a witness one of its foremen, Jerry Easter, who testified that on the
day of the accident the firm of Orders & Haynes was widening Secondary
Route 79 a distance of two feet and that it was necessary for the contractor
?to cut the road out and then put it back in with blacktop.?
W. VA.] REPORTS
STATE COURT OF CLAIMS 157
Easter further testified that the respondent had no supervisory personnel on
the job, but that they did have one employee, Miguel Rodriguez, on the job
simply for the purpose of taking tickets from Orders & Haynes? truck
drivers so that respondent would have a record of loads and tonnage of dirt
arid other material that the contractor had moved during the construction.
Driver Hewitt in his testimony indicated that he recognized vehicles belonging
to respondent at the job site from the emblems on the doors, but he admitted that
he could not identify the flagman as an employee of respondent. Deputy Sheriff
J. T. Meadows, who investigated the accident, testified that he did not observe
any vehicles of the respondent at the job site during the course of his
investigation.
The Court believes that the record fails to demonstrate that the subject
flagman was an employee of respondent but most probably was an employee of the
independent contractor, Orders & Haynes, and as such, the respondent cannot
be held liable for the negligence, if any, of such flagman. For this reason the
claim is disallowed.
Claim disallowed.
Opinion issued July 12, 1978
FOSTER STARCHER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-120)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
The claimant filed this claim against the Department of Highways for damages to
his motor vehicle. On September 22, 1976, the claimant was driving his 1974
Suburban Cheyenne 20 pulling a 25-foot Terry Trailer northerly on W.Va. Route 26
near Tunnelton, West Virginia, in Preston County. It was approximately 10:15
a.m. It was raining. He was alone. A tractor and trailer proceeding southerly
on Route 26 was passing the claimant on his left side. He was travelling at
about 20-30 mph.
158 REPORTS STATE
COURT OF CLAIMS [W. Va.
The claimant?s vehicle struck a channel iron-type signpost lying in the road.
When the front wheel of the vehicle struck the post, it curved up and wedged
itself in the right front door causing damage in the amount of $293.91. The
claimant testified that he did not see the signpost because he was watching the
tractor and trailer on his left. Claimant further testified that he had no way
of knowing the post was one used by the respondent except that he was familiar
with the type used by it. He did not know whether the respondent had had a sign
erected at the place of the accident and that it was possible it could have
been dumped with other trash and debris in a roadside dump in the area of the
accident.
Norman Blake Ridenour, a foreman for the respondent, testified that he works
the area where the accident occurred, and that he travels the road at least
twice a day going to and from respondent?s headquarters. He stated that there
was a roadside dump at the place of the accident; that it was not maintained by
the respondent, and, to the best of his knowledge, there had rever been a sign
in the area maintained by the respondent.
For the Court to make an award, the claimant must prove by a preponderance of
the evidence that the negligence of the respondent was the cause of his damage.
In this case the claimant?s vehicle struck a signpost in the road. There is no
evidence that the post belonged to the respondent, nor is there evidence that
it was knocked from the side of the road onto the highway. The claimant
testified that the post was the type used by the respondent. Respondent?s
witness testified that the respondent had no signposts in the area of the
accident. Without more evidence, the Court cannot make an award. The law is
well established in West Virginia that the State is not an insurer of the user
of the highways but that he travels at his own risk. Adkins v. Sims, 130 W.Va. 645, 46 S.E. 2d 81(1947).
From the record, the Court is of the opinion that the claimant has not
established by a preponderance of the evidence that the damage to his vehicle
was the result of actionable negligence on the part of the respondent.
Accordingly, the claim of the claimant is disallowed.
Claim disallowed.
W. VA.J REPORTS
STATE COURT OF CLAIMS 159
Opinion issued July 12, 1978
JOHN TILLINGHAST
& JANET TILLINGHAST
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-80)
Gordon T. Ikner, Jr., Attorney at Law, for claimants. Nancy J. Alijf , Attorney
at Law, for respondent.
PER CURIAM:
This claim was submitted to the Court upon written stipulation of the parties.
It was stipulated that in February, 1976, the respondent was constructing a
road near Danville in Boone County, West Virginia, and that blasting activities
of the respondent damaged the claimants? property. It was further stipulated
that the claimants sustained damage to their property in the amount of
$4,000.00. Believing that liability exists on the part of the respondent and
that the damages are reasonable, the Court makes an award to the claimants in
the amount of
$4,000.00.
Award of $4,000.00.
Opinion issued July 12, 1978
U.S.A.A. INSURANCE CO.
& HAROLD F. MAY
vs.
DEPARTMENT OF HIGHWAYS
(No. 77?2 15 a&b)
Claimant appeared in person.
Richard Carton, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Harold F. May, filed this claim in the amount of $184.89 against
the respondent for damages to his 1977 Monte
160 REPORTS STATE
COURT OF CLAIMS [W. Va.
Carlo automobile. On or about August 25, 1977, he was driving his automobile on
W.Va. Route 6/6 near St. Albans, West Virginia. It was late afternoon. It was
raining heavily. The claimant testified that there was a work crew spreading
material on the surface of the highway. He stated that he did not know if the personnel
and equipment were those of the respondent or a private contractor. The traffic
was not stopped. He did not see a flagman. Several days later he had his
automobile washed, and discovered foreign material on the rocker panel moulding
and on the undersides of the bumpers. Various efforts to remove the substance
failed. He was advised that the damaged areas would have to be refinished.
Doyle Thomas, the respondent?s foreman for the area in question, testified that
surface material could not be applied to a highway during a rain or when the
road was wet. He identified his daily time sheets for August 22, 23, 24, 25,
and 26, 1977. These sheets, which were introduced as Respondent?s Exhibit No.
1, reflect the type of work performed, equipment used, and the location of the
work for each day. The sheets revealed that no work was performed by the
respondent on W.Va. Route 6/6 on any of the days covered by the sheets
introduced.
From the record, the Court is of the opinion that the claimant has not shown by
a preponderance of the evidence that the damages sustained were the result of
actionable negligence on the part of the respondent. Accordingly, the claim is
disallowed.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 161
Opinion issued July 12, 1978
JOHN THOMAS WEDDINGTON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-161)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
GARDEN, JUDGE:
This claim in the amount of $109.55 was filed by the claimant against the
respondent for damages to his 1970 Montego automobile. The home of the claimant
is located at 157 First Avenue in Nitro, West Virginia. First Avenue is also
W.Va. Route 25. To reach First Avenue or the highway by automobile from the
claimant?s house, the claimant backs down a steep driveway. Before entering the
highway, it is necessary to watch for traffic. On August 25, 1977, at
approximately 7:40 a.m., the claimant backed down his driveway to the highway.
The weather was clear. An ambulance was proceeding along the highway. To permit
the ambulance to pass, the claimant drove his automobile along the berm of the
highway. As he was driving along the berm of the highway, the left front wheel
of his automobile struck a rock. The claimant stated he was driving less than
10 mph and that the rock was about six feet from the paved portion of the
highway. The rock struck under the automobile damaging the muffler, tail pipe,
and exhaust pipe. The claimant testified that he knew there were rocks on the
berm; that he drove in and out of his driveway at least twice a day going to
and from work, and that he saw rocks on the berm the day before the accident.
He also testified that the respondent had spread rocks on the berm to build it
up. The claimant?s wife testified that the rocks were scraped up shortly after
the accident. She did not know who did the work but the equipment was painted
yellow. The claimant stated that he did not complain to the respondent about
the rocks on the berm.
Claude Bartley, area supervisor for the respondent, testified that the area
where the accident occurred was in the area of
162 REPORTS STATE
COURT OF CLAIMS [W. Va.
his responsibility. He further testified he investigated time records of work
performed in the area and that no work had been done on the berm in front of
claimant?s house from July 1, 1977, to the date of the hearing of this claim.
The record in this case does not justify that an award be made by the Court.
The claimant was driving on the berm of the highway over rocks which he knew
were there. He could have waited for the ambulance to pass his driveway and
then entered the paved portion of the highway as he was accustomed. Aside from
the conduct of the claimant, the Court does not believe that the claimant has
established by a preponderance of the evidence any actionable negligence on the
part of the respondent. Accordingly, the claim is disallowed.
Claim disallowed.
Gpinin issued July 12, 1978
BLISS R. WOTRING
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-140)
Claimant appeared in person.
Richard Canton, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Bliss Wotring, filed this claim in the amount of $2,500.00
against the respondent for water damage to his property located on the south
side of W.Va. Route 7 five miles west of Kingwood, West Virginia, in Preston
County, The natural terrain slopes downhill from Route 7 to the claimant?s
house. The road down the hill from Route 7 to the claimant?s home was formerly
part of old Route 7 which was abandoned after the present highway was
constructed and is now claimant?s private road. It is not a part of the highway
system and is not maintained by the respondent.
W. VA.] REPORTS
STATE COURT OF CLAIMS 163
On July 25, 1977, there was a heavy rain causing water to flow down the road
and into claimant?s field. The claimant testified approximately 11/2? of rain
fell. The respondent?s witness testified that the records maintained by the
respondent in Kingwood indicated there were 2.49 inches of rainfall.
The claimant testified that the culverts on Route 7 and one under his private
road were stopped up due to the respondent?s failure to keep them open. He
stated this caused the water from the heavy rain to flow down his road and into
his field causing considerable damage. He also stated that dirt from the
construction of a private road on the north side of Route 7 filled the drainage
ditches causing the water to flow down his road. The claimant did not complain
to the respondent of the condition until the day after the heavy rain.
This Court made an award to the claimant herein in 1972 under similar
circumstances as in the instant case. See Wotring v. Dept. of Highways, 9
Ct. Cl. (1972). In the 1972 case, no evidence was introduced by the respondent
to refute the claimant?s claim. The uncontradicted evidence indicated a
drainage problem existed and that the State had been notified months before the
damage and failed to correct the problem. In the instant case, the claimant
testified that a culvert on Route 7 was stopped up as well as the culvert under
his private road. The respondent had no notice of an existing problem. To the
contrary, Gerald M. Lowe, an inspector for the respondent, testified the
ditches along W.Va. Route 7 in the vicinity of claimant?s property were pulled
with a grader on July 17, 18, and 19, 1977, to remove debris, and that the
inlets and outlets of drains were cleaned in preparation for paving the road.
Ernest W. Shaffer, respondent?s Preston County road superintendent, testified
that he went to the claimant?s property with another employee on July 27, 1977,
in response to the complaint of the claimant the previous day. He stated the
claimant?s road was in ?pretty good shape? and that he saw no debris in the
ditches along W.Va. Route 7.
From the record in this case it is most difficult for the Court to believe that
the diversion of surface water caused by a stopped culvert, if actually stopped
up, was the sole cause of
164 REPORTS
STATE COURT OF CLAIMS [W. Va.
he damages claimed. The water from the
-heavy rain followed its natural course down the slope of the hill and
claimant?s road. To hold that a diversion of water from a stopped culvert was
the sole, direct, and proximate cause of the damage, is unwarranted from the
evidence.
Accordingly, the Court is of the opinion that the claimant has not shown by a
preponderance of the evidence that the damages claimed were the result of
actionable negligence on the part of the respondent, and hereby disallows the
claim.
Claim disallowed.
Opinion issued Auiust 10, 1978
THE C & P TELEPHONE CO. OF W. VA.
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-78-105)
David K. Hall, Attorney at Law, for claimant.
Gregory Elliott and Ed
Gardner, Assistant Attorneys General,
for respondent.
PER CURIAM:
On or about April 29, 1976, employees of respondent, acting within the scope of
their employment, were training students from Sherman High School in Seth, West
Virginia, to shoot firearms. The employees had negligently selected the site
for such activities and negligently supervised the students. As a result,
bullets from the firearms struck claimant?s telephone cables, causing damage in
the amount of $884.71. Claimant has received the sum of $442.35 from the Boone
County Board of Education in partial payment of the damages, and now claimant
seeks the sum of $442.36 from respondent. Believing that liability exists on
the part of the respondent and that the damages are reasonable, the Court makes
an award to the claimant in the amount of $442.36.
Award of $442.36.
W. VA.]
REPORTS STATE COURT OF CLAIMS 165
Opinion issued August 10, 1978
ARNELL CHURCH
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-79)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
RULEY, JUDGE:
On March 9, 1978, at about 12:30 am., the claimant, while proceeding from Oak
Hill to Pineville in his 1977 Grand Prix automobile, drove over and along what
is commonly referred to as the Old Rhododendron Trail. The claimant described
the road, other than the area where the pothole was located, as a great piece
of highway, and he explained that he struck the pothole because it was filled
with water and thus could not be observed. No evidence was introduced to
establish that respondent knew or should have known of the existence of this
pothole. Damages were in the total amount of $198.00.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W. Va. 645, 46 S.E. 2d 81
(1947). For negligence of the Department of Highways to be shown, proof that
the respondent had actual or constructive notice of the defect in the road is
required. Davis Auto Parts v.
Department of Highways, 12 Ct. Cl. 31
(1977); Lowe v. Department of
Highways, 8 Ct. Cl. 210 (1971); Varner v. Department of Highways, 8 Ct. Cl. 119 (1970). There is no evidence in the
record of any notice to the respondent; and the simple existence of a defect in
the road does not establish negligence per se. See Light v. Department of Highways, 12 Ct. Cl. 61 (1978); Bodo v. Department of Highways, 11
Ct. Cl. 179 (1977); and Rice v.
Department of Highways, 12 Ct. Cl. 12
(1977). This claim must be denied.
Claim disallowed.
166 REPORTS STATE
COURT OF CLAIMS [W. Va,
Opinion issued August 10, 1978
CLIMATE MAKERS OF CHARLESTON, INC.
vs.
BOARD OF REGENTS
(No. CC-78-90)
J. B. Fisher, Attorney at Law, for claimant.
Gregory Elliott and Ed
Gardner, Assistant Attorneys General,
for respondent.
PER CURIAM:
Claimant seeks payment of the sum of $903.00 for three room air-conditioning
units purchased by respondent on April 26, 1977. Respondent, in its Answer,
admits the validity of the claim and declares that there were sufficient funds
remaining in its appropriation for the fiscal year in question from which the
claim could have been paid. Respondent denies, however, that part of the claim
attributable to the interest on the $903.00.
Pursuant to Chapter 14, Article 2, Section 12 of the West Virginia Code of
1931, as amended, this Court cannot allow any claim for interest unless the
claim is based upon a contract which specifically provides for the payment of
interest. Since there was no proof of such a contract in this case, we are of
the opinion to and do hereby make an award to the claimant in the amount of
$903.00.
Award of $903.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 167
Opinion issued August 10, 1978
B. H. COTTLE AND B. H. COTTLE, EXECUTOR OF
THE ESTATE OF LUCY M. COTTLE, DECEASED
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-49)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
The parties in this claim filed a written stipulation which revealed the
following: that, on July 20, 1972, a ?stone quarry agreement? was made between
the claimant and respondent, under which the Department of Highways performed
stone quarrying operations while constructing a highway near Scott Depot. West
Virginia; that while engaged in the quarrying activities, the Department of
Highways caused some degree of damage to claimant?s land; and that respondent
is thereby liable to claimant for the sum of $1,200.00, which amount is a fair
estimate of the damage sustained by the claimant.
Based on the foregoing, an award in the above amount is hereby made.
Award of $1,200.00.
Opinion issued August 10, 1978
EASTMAN KODAK CO.
vs.
OFFICE OF THE SECRETARY OF STATE
(No. CC-78?112)
No appearance by claimant.
Gregory Elliott and Ed Gardner,
Assistant Attorneys General, for
respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
168 REPORTS
STATE COURT OF CLAIMS [W. Va.
Claimant Eastman Kodak Company seeks
payment of a bill for renewal equipment performance program for a Miracode
Microfilmer in the amount of $275.00.
The respondent admits the validity of the claim, but states also that it lacked
the requisite funds in its appropriation for the fiscal year in question from
which the claim could have been paid.
While we feel that this is a claim which is equity and good conscience should
be paid, we are of further opinion that an award cannot be made, based on our
decision in Airkem Sales and Service, et al. v. Department of
Mental Health, 8 Ct. Cl. 180 (1971).
Claim disallowed.
Opinion issued August 10, 1978
CHARLES R. EVANS
& ERNESTINE EVANS
vs.
DEPARTMENT OF BANKING
(No. CC-77-127)
Claimants appeared in person.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant, Charles R. Evans, filed this claim in the amount of $3,658.49,
later amended to $7,712.95, against the Commissioner of Banking (1968),
Department of Banking, Receiver of Parkersburg Savings & Loan Company,
Commissioner of Banking (1976), the Governor (1967), and the Legislature
(1967), State of West Virginia. None of the individuals occupying the
above-named positions was specifically named.
Ernestine Evans was joined by the Court as a claimant.
During the hearing, the claimants filed a motion requesting the Court to
convert the claim into a class action, and the
W. VA.] REPORTS
STATE COURT OF CLAIMS 169
amount of damages was increased to $2,608,473.70. The persons constituting the
class in this instance are not so numerous as to make it impracticable to bring
them all before the Court as required by Rule 23 (a) of the Rules of Civil
Procedure. Therefore, the motion is overruled.
The claim as filed alleged:
(1) that there was an unlawful scheme of reorganization of the Parkersburg
Savings & Loan Company of Parkersburg, West Virginia;
(2) that the governor and legislature were negligent in failing, prior to
October 1967, to provide statutes sufficient to protect the people in their
dealings with industrial loan companies;
(3) that respondents unlawfully permitted the scheme of reorganization to be
accomplished;
(4) that satisfaction of certain accounts constituted fraud by W. Bruce Hoff,
the Receiver of the Parkersburg Savings & Loan Company, and Commissioner of
Banking;
(5) that the Department of Banking was negligent in its failure to prevent
criminal fraud;
(6) that the distribution of assets by the Receiver of the Parkersburg Savings
& Loan Company was inequitable; and
(7) that the Commissioner of Banking and Department of
Banking in 1976 unlawfully permitted the Parkersburg
Savings & Loan Company to become the Parkersburg
Industrial Financing Corporation.
The hearing commenced February 3, 1978, and, after being continued, was
completed on May 24, 1978. The Court considered all the evidence presented by
the parties including certain exhibits subject to respondent?s objections.
This Court was created under the provisions of Chapter 14 of the Code of West
Virginia. The jurisdiction of the Court extends to claims and demands against
the State or any of its
170 REPORTS STATE
COURT OF CLAIMS [W. Va.
agencies with certain exclusions. The statute provides that the Court shall
consider claims which, but for the constitutional immunity of the State from
suit, or for some statutory restrictions, inhibitions, or limitations, could be
maintained in the regular courts of the State. The Court has no jurisdiction to
make an award against an individual. Accordingly, the Court dismisses the claim
against the Commissioner of Banking (1968), the Receiver of Parkersburg Savings
& Loan Company, the Commissioner of Banking (1976), the Governor (1967),
and the Legislature (1967), leaving the Department of Banking as the sole
remaining respondent.
The record discloses that the Parkersburg Savings & Loan Company was in
financial difficulty in 1967. The Commissioner of Banking placed the business
in receivership and appointed a receiver. A plan of reorganization was
submitted to the Department of Banking to reopen the business. The plan
provided that the depositors would be paid 50% of their deposits over a
five-year period and receive stock in the company for the remaining balance of
their accounts. After certain changes required by the Commissioner of Banking
were made, the reorganization plan was submitted to the depositors for approval
or disapproval.
W. Bruce Hoff, the attorney for Parkersburg Savings & Loan Company, who was
instrumental in drafting the reorganization plan, sent letters to the
depositors advising that the plan would fail without 100% participation of the
depositors. Ninety-five per cent of the depositors, including the claimant,
Charles R. Evans, approved the reorganization of the company. Chapter 31 of the
Code of West Virginia, now Chapter 31a, requires
75% approval before a reorganization can be approved by the Department of
Banking. The commissioner of banking, in accordance with the law, approved the
reopening of the business and directed the receiver to deliver the assets in
his hands to the reorganized company.
The claimants contend that 100% approval was necessary to reorganize the
company as represented by the attorney for the company. They also stated that
certain of the depositors who did not approve the reorganization plan were
allowed by the company to withdraw their deposits in full.
W. VA.] REPORTS
STATE COURT OF CLAIMS 171
W. Lovell Higgins, Deputy Commissioner of Banking, after the commencement of
the hearing and at the request of the claimants, investigated claimants?
charges. Mr. Higgins testified that the business reopened on September 13,
1968; that he examined the records of the company, and 95% of the total
deposits were converted under the reorganization plan; that certain of the
unconverted accounts were paid in full after April 1, 1969, which was
subsequent to the reopening of the business; that W. Bruce Hoff indicated that
some accounts of non-approving depositors had been purchased by persons outside
of the company; and that Mr. Hoff had, in fact, indicated by letter to the
depositors that 100% participation was necessary to accomplish the
reorganization of the company. Mr. Higgins further testified that there was no
statutory requirement for 100% participation, and that 75% was required by
Chapter 3]., now Chapter 31a, of the Code of West Virginia. Mr. Higgins stated
he found nothing illegal in his investigation of the reorganization and the
reopening of the business.
Claimants based the amount of their claim on the dollar value of the stock
issued in the reorganization multiplied by an inflation adjustment factor
obtained from a publication by the United States Bureau of the Census entitled Statist?caL Abstract of the United States (97th ed. 1976). This Court, by statute, cannot award
interest unless the claim is based on a contract which specifically provides
for the payment of interest. The claimant, Charles R. Evans, recognized this
statutory prohibition in his testimony at the time he introduced the inflation
factor. The claimants, by claiming an inflation adjustment, are in effect
requesting the Court to do indirectly that which it cannot do directly.
The claimants were not represented by counsel, and the Court, in an attempt to
determine the validity of the claim, received in evidence subject to
respondent?s objections testimony and exhibits which, in a court of law, would
be inadmissible. The Court, in arriving at its decision, has assessed the
materiality of and the weight to be afforded the evidence presented.
There is no evidence in the record that the reorganization of the Parkersburg
Savings & Loan Company was unlawful as al
172 REPORTS STATE
COURT OF CLAIMS [W. Va.
leged, nor is there evidence that the respondent, Department of Banking,
unlawfully permitted the reorganization. It was alleged that the Department of
Banking was negligent in its failure to prevent criminal fraud. The record does
not sustain this allegation. There was no evidence that the Department of
Banking unlawfully permitted the Parkersburg Savings & Loan Company to
become the Parkersburg Industrial Financing Corporation.
Accordingly, the Court finds that the claimants have failed to prove the
allegations of their complaints and have not established a claim against the
Department of Banking. The record established that the Department of Banking
permitted the reorganization of the Parkersburg Savings & Loan in
compliance with the law after it was approved by 95% of the depositors. There
is no evidence that non-approving depositors were allowed to withdraw their
accounts prior to the reorganization.
Actions by the Parkersburg Savings & Loan Company, its officers, and
employees are not within the jurisdiction of this Court.
For the reasons herein, the Court disallows the claim of the claimants.
Claim disallowed.
Judge Ruley disqualified himself and did not participate in the consideration
of this claiiri.
Opinion issued August 10, 1978
CHARLES R. GORE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-197)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damage
W. VA.]
REPORTS STATE COURT OF CLAIMS 173
in the sum of $332.49 sustained by the
claimant?s vehicle when, on September 20, 1977, it collided with a limb which
had fallen upon West Virginia Route 3, near Lowell, in Summers County, from a
dead tree located near that highway. Accordingly, an award in that sum should
be, and is, hereby made.
Award of $332.49.
Opinion issued August 10, 1978
CHARLES P. LONG.
vs.
DEPARTMENT OF HIGHWAYS
V (No. CC-78-115)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stip ulation to the
effect that the respondent is liable for damages in the sum of $43.76, based
upon the following facts: In April, 1978, claimant was driving across the
Shadle Bridge in Mason County, West Virginia. While claimant was crossing the
bridge, which is owned and maintained by respondent, a piece of steel flooring
punctured one of the tires on claimant?s car. The tire was damaged beyond
repair. Respondent is therefore liable to claimant for the sum of $43.76, which
is a fair and equitable estimate of the damages sustained by claimant.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $43.76.
174 REPORTS STATE
COURT OF CLAIMS [W, Va.
Opinion issued August 10, 1978
RODGER C. MELLING
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-33)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent. RULEY, JUDGE:
The claimant, a project engineer for the respondent, has filed a claim in the
amount of $99.73, representing the cost of repairing the damage to his
automobile as a result of striking a pothole on U. S. 119 near Elkview on
January 25, 1978. The claimant was on his way home at approximately 5 o?clock
in the evening, driving north. The claimant testified that respondent had
widened this road about two years prior to the accident by constructing a
section 30 inches wide on the east side of this two-lane asphalt road. The
pothole, which the claimant described as being 12 feet long, 12 to 18 inches
wide, and 8 inches deep, was located in and near the seam that was created
between the old road and the widened section. Claimant admitted that he had
previously observed potholes in the general area, but not the one which he
struck. He testified that the hole was completely filled with water, which
accounted for his failure to observe the same prior to the accident. Apparently
in an effort to establish notice of this pothole to respondent, claimant
testified that one of respondent?s maintenance garages was located within a
quarter of a mile of the accident scene and that it was in an area frequently
used by respondent?s employees as a lunch stop.
Gary Huffman, a foreman of respondent, testified that one of his duties was the
repairing of potholes, and that during winter months, the only material
available for filling potholes was ?cold mix?. He described this ?cold mix? as
a very poor substitute for ?hot mix?, which was not available until the spring
of each year. Huffman testified that the subject pothole had been filled three
or four times during the winter, but he
W. VA.] REPORTS
STATE COURT OF CLAIMS 175
could not state whether any of these fills had been prior to January 25, 1978.
Testifying from his official records, he also established that his work crew
was kept almost continually busy during the month of January, 1978, in the
removal of ice and snow.
The evidence fails to establish that respondent breached any legal duty owed to
claimant. The respondent?s duty was that of ordinary care to keep this road in
a reasonably safe condition. The respondent being neither an insurer nor a
guarantor of the safety of persons travelling on the highways of this State, Adkins v. Sims, 130
W.Va. 645, 46 S.E. 2d 81 (1947), we must disallow this claim.
Claim disallowed.
Opinion issued August 10, 1978
PHYSICIANS FEE OFFICE
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-78-74)
No appearance by claimant.
Gregory Elliott and Ed Gardner,
Assistant Attorneys General, for
respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer. Claimant seeks payment of the sum of
$2,956.50 for services rendered to an inmate of the respondent Department of
Corrections.
The respondent admits the validity of the claim, but states also that it lacked
the requisite funds in its appropriation for the fiscal year in question from
which the claim could have been paid.
176 REPORTS
STATE COURT OF CLAIMS [W. Va.
While we feel that this is a claim
which in equity and good conscience should be paid, we are of further opinion
that an award cannot be made, based on our decision in Airkem Sales and Service, et al. v. Department of Mental
Health, 8 Ct. Cl. 180 (1971).
Claim disallowed.
Opinion issued August 10, 1978
ROBERT M. PRATT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-122)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
GARDEN, JUDGE:
Claimant?s son, John M. Pratt, was operating his father?s 1973 Oldsmobile in a
southerly direction on Route 214 in Kanawha County on the evening of March 3,
1978, when the right wheels of the car struck a pothole which was filled with
water and as such, unobservable. Claimant seeks an award of $377.36 which was
the cost of repairing the damage to the car.
John M. Pratt and two companions testified that they had no knowledge of the
existence of the pothole; that the speed of the car was between 30 and 40 miles
per hour; and that none of them saw the hole prior to impact because the
pothole was filled with water. The claimant testified that he had observed the
subject pothole some two weeks before the accident. He further testified that
after the accident he measured the hole, which was elliptical in shape, and
found it to be 15 to 20 inches on the short axis and 20 to 25 inches on the
long axis. No testimony was presented which would establish that respondent
knew or should have known of the existence of this pothole.
W. VA.]
REPORTS STATE COURT OF CLAIMS. 177
It is axiomatic that the State is
neither an insurer nor a guarantor of the safety of persons travelling on its
highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E. 2d 81 (1947). In order to
establish negligence on the part of the respondent, it is necessary to
establish that it had notice, either actual or constructive, of the defect in
the road. Davis Auto Parts v.
Department of Highways, 12
Ct. Cl. 31 (1977); Lowe v. Department of Highways, 8 Ct. Cl. 210 (1971); Varner v. Department of Highways, 8 Ct. Cl. 119 (1970). Mr. Pratt testified that he had observed the
pothole two weeks before the accident. We do not feel that this is sufficient
to establish constructive notice to respondent of the pothole?s existence. The
simple existence of this pothole does not establish negligence per Se. See Light v. Department of Highways, 12 Ct. Cl. 61 (1978); Bodo v. Department of
Highways, 11 Ct. Cl. 179 (1977); and Rice v. Department of Highways, 12 Ct. Cl. 12 (1977). By reason of the above, this
claim is disallowed.
Claim disallowed.
Opinion issued August 10, 1978
MAE RUSSELL
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-81)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $700.00, based upon the
following facts:
On or about August 24, 1977, the Department of Highways was engaged in
construction activities across U. S. 119 near claimant?s house. As a result of
this construction, water was blocked in the storm sewer lines, causing the same
to back up
178 REPORTS STATE
COURT OF CLAIMS [W. Va.
through the basement floor drains and flood claimant?s basement. As a result,
claimant?s two washing machines, dryer, tools, and furnace were damaged. In
addition, claimant incurred expenses for the removal of water, mud, sludge, and
other debris. The parties agree that the sum of $700.00 is a fair and equitable
estimate of the damages sustained by the claimant.
The Court finds that the respondent was negligent in its construction
activities, proximately causing injury to the claimant?s property, and that the
respondent is liable to the claimant for damages in the amount stipulated.
Award of $700.00.
Opinion issued August 10, 1978
ROMIE C. SAYRE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-64)
Wayne King, Attorney at Law, for claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
In March of 1978, the claimant and his wife were proceeding in his 1977
Chevrolet Caprice automobile to their home near Peach Fork, which is located
between Porter?s Creek and Clendenin in Kanawha County. The road over which
they were travelling was apparently in a poor state of repair due mainly to the
severity of the winter weather. It was dusk and it had been raining most of the
day. At some point the car became stuck in a rut in the road, and the claimant,
with the aid of a bumper jack, was able to extricate the car from the rut. From
this point the claimant, with his wife driving, pushed the car for a distance
of 100 feet, where it slipped into a ditch and was damaged to the extent of
$533.48. The claimant testified that previous to the accident he and his neighbors
had made numerous complaints to respondent, and this testimony was
uncontradicted by respondent.
W. VA.J REPORTS
STATE COURT OF CLAIMS 179
James Huffman, a foreman of respondent, testified that he was familiar with the
road where the accident occurred and that it was among the roads that he and
his crew maintained. According to Huffman, the road was assigned a low
priority, and usually it was graded twice a year and the ditch line was
dragged. He testified that the road was a rock base road, and the drainage
ditch along the side of the road was probably a foot to a foot and a half in
depth. According to Huffman, he put some 144 tons of stone on the road on the
3rd and 4th days of January, 1978. He further indicated that the road was
difficult to maintain due to its inaccessibility. In order for heavy equipment
to reach this area, it is necessary for them to proceed through Clay County
because of the existence of a low weight limit bridge on the most direct route
in Kanawha County.
We have held many times that the respondent is neither an insurer nor a
guarantor of the safety of persons travelling on its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E. 2d 81 (1947). Judge Jones in Cassei v. Department of Highways, 8 Ct. Cl. 259 (1971), stated the duty as follows:
?Following decisions of the Supreme Court of Appeals of West Virginia, this
Court has consistently held that the State is not an insurer and its duty to
travelers is a qualified one, namely, reasonable care and diligence in the
maintenance of its highways under all the circumstances. The maintenance of
highways is a governmental function and funds available for road repairs are
necessarily limited.?
We do not believe as a matter of law that the record in this case establishes
by a preponderance of the evidence that the respondent failed to exercise
reasonable care and diligence in the maintenance of this road. This conclusion
thus eliminates the necessity of exploring possible contributory negligence or
assumption of risk on the part of the claimant. Accordingly, we disallow the
claim.
Claim disallowed.
180 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued August 10, 1978
A. A. SPAGNUOLO
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-134)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
The parties in this claim filed a written stipulation which revealed the
following: that, on or about February 2, 1978, the claimant entered into an
agreement to sell certain wheels and axles to the respondent; that the
respondent is presently in possession of the wheels and axles but has not paid
for them; and that respondent is liable to claimant for the sum of $480.00,
which amount is a fair and equitable estimate of the value of the said wheels
and axles.
Based on the foregoing, an award in the above amount is hereby made.
Award of $480.00.
Opinion issued August 10, 1978
POLLY STEVENS, GUARDIAN OF THE
PERSON AND ESTATE OF JAMES WALTER
STEVENS AND TIMOTHY STEVENS
vs.
DEPARTMENT OF HIGHWAYS
(No. D-688)
William. S. Steele arid Wade H.
Bronson, Jr., Attorneys at Law, for
claimant.
Nancy Norman, Attorney at Law, for respondent.
GARDEN, JUDGE:
James Walter Stevens and Timothy Stevens were the owners of certain real estate
situate on Jenny?s Creek in Mingo
W. VA.]
REPORTS STATE COURT OF CLAIMS 181
County, West Virginia. When the claim
was filed, they were under the age of eighteen years, and consequently the
claim was filed in their mother?s name as guardian. Their property was located
on a hillside above Jenny?s Creek. On the property was a frame house consisting
of five rooms and a bath. Farther up the hill and behind the house was an
unimproved, narrow, two-lane road which was owned and maintained by the
respondent. On the uphill side of this road was a ditch line designed for the
purpose of diverting the surface water coming from the hillside above and thus
preventing the same from washing away the road.
Mrs. Stevens testified that through the years the respondent had failed to
devote any maintenance to this ditch line; that as a result, the same had
become clogged with debris; and that surface water, instead of being carried
off, would wash down the road and onto her wards? property. Mrs. Stevens
further indicated that as early as 1969 she noticed that the surface water was
also carrying away portions of he road and de positing the same on the property
behind the residence where she and her two sons lived. The condition of the
hillside continued to worsen, and in 1971, Mrs. Stevens went to respondent?s
local maintenance garage and requested assistance. On one visit she conferred
with one Lester Messer and on another visit with Tom Marcum, the county
maintenance supervisor. Mrs. Stevens also testified that she registered
complaints with the Governor?s Office by phone on at least fourteen or fifteen
occasions.
As a result of these complaints, Mrs. Stevens testified that respondent would
dump large quantities of sand, gravel, and rubbish in the washed-out areas of
the road, but that this newly deposited material would only be washed down on
her wards? property during the next rainfall and increase the amount of
unstable earth above the residence. Mrs. Stevens testified that never during
these filling operations by respondents was any attempt made to drag the ditch
line in order to eliminate its clogged condition. Finally, during the early
morning hours of February 18, 1972, a landslide occurred which, with the
exception of one room which was damaged, completely destroyed the residence as
well as seven apple trees located
182 REPORTS STATE
COURT OF CLAIMS [W. Va.
on the property. After this occurred, Mrs. Stevens stated that with the aid of
a bulldozer, the partially damaged one room was moved to an adjoining piece of
property where it was attached to an existing one-room structure where she and
her two children resided until February, 1973, when another slide occurred
destroying this structure. This claim, however, is limited to the damages
resulting from the 1972 slide.
Tom Marcuin, who was at that time the respondent?s county maintenance
supervisor, testified on behalf of the claimant and confirmed that he received
a visit from Mrs. Stevens who was seeking assistance and relief from the
condition on the hillside. He testified that for at least a year prior to the
destruction of the residence, after each rain he would place at least fifteen
truckloads of creek gravel, crushed stone, ?and about anything that they could
get hold of? on the road in order to bring the road up to grade so that school
buses could get through. He also testified that this was the only maintenance
performed, confirming, at least by implication, Mrs. Stevens? testimony that no
attempt was ever made to clean out the ditch line.
The respondent called as an expert witness William E. Bennett, a geologist with
nineteen years? experience. Mr. Bennett testified that he had inspected the
property on July 8, 1976, four days prior to the date of the hearing held in
this claim and well over four years after the landslide occurred. Based on his
inspection of the property, his experience, and his knowledge of geological
conditions in West Virginia, Mr. Bennett was of the opinion that the landslide
was caused by an unstable condition created by subsurface water percolating or
running beneath the slide area, but that the slide was triggered as a result of
the removal of the toe of the slope from the slide area. Mr. Bennett testified
that he observed the ditch line along the road, and that, in his opinion, it
was sufficient to handle the surface water runoff. While his testimony was most
persuasive, we cannot ignore the direct testimony of Mrs. Stevens, who
testified that on many occasions she saw the water being cast onto the property
because of the improperly maintained ditch. While Mr. Bennett was of the
opinion that the slide was triggered by the removal of the toe of the slope, no
testimony was introduced as to when this removal occurred, and, if so,
W. VA.] REPORTS
STATE COURT OF CLAIMS 183
by whom. The only testimony relating to bulldozing activities was that of Mrs.
Stevens, who indicated that a bulldozer was on her property after the slide and
helped move the one remaining room of the house to adjoining property.
We believe that the respondent was under a legal duty to use reasonable care to
maintain the subject ditch line in such condition that it would carry off the
surface water and prevent it from being cast upon the Stevens property. See Wotring v. Department of Highways, 9 Ct. Cl. 138 (1972); Olive v. Department of Highways, 8
Ct. Cl. 148 (1970). We believe that the claimant has proved by a preponderance
of the evidence that the respondent failed to maintain the ditch line properly
and that such failure proximately caused the landslide and the damage to the
Stevens property.
In support of her claim for damages, the claimant, without objection,
introduced into evidence a written report from S. P. Goodman, a real estate
appraiser from Williamson, W.Va. Mr. Goodman, whose report indicated that he
had been appraising property for half a century, was of the opinion that the
fair market value of the property was $14,285.00. The respondent called as its
expert Gary S. Tokarcik, who personally testified to the method he followed in
reaching his opinion regarding the fair market value of the property before the
landslide and the fair market value of the property after the landslide, which
is, of course, the proper method of establishing damage to real estate. His
opinion was that the difference in these two values was $8,450.00. We believe that
the testimony of Mr. Tokarcik is entitled to much more weight than the written
report of Mr. Goodman, and we therefore make an award in favor of the claimant
in the amount of $8,450.00.
Award of $8,450.00.
184 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued August 10, 1978
TEXACO, INC.
vs.
OFFICE OF THE SECRETARY OF STATE
(No. CC-78-127)
No appearance by claimant.
Gregory Elliott and Ed Gardner,
Assistant Attorneys General, for
respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant Texaco seeks payment of the sum of $33.09 for petroleum purchases made
by respondent. In its Answer, respondent admits that the claim is valid and
that the claimant is entitled to receive payment, but further alleges that
there were not sufficient funds remaining in respondent?s appropriation at the
close of that fiscal year from which the claim could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are of further opinion that an award cannot be made, based on our
decision in Airkem Sales and Service,
et al. v. Department of Mental HeaVth, 8
Ct. Cl. 180 (1971).
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 185
Opinion issued October 11, 1978
WILLIAM J. ADKTNS, DOROTHY MARIE
ADKINS,
ARMILDA WILEY AND DOROTHY MARIE ADKINS,
AS NEXT FRIEND OF MARY JANE ADKINS
AND PEGGY JOYCE ADKINS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-.78)
Houston A. Smith, Attorney at Law, for claimants.
James W. Wit hrow, Attorney at Law, for respondent. WALLACE, JUDGE:
William J. Adkins and Dorothy Marie Adkins filed their claim against the
Department of Highways in the amount of $5,200.00 for damages to their home
caused by flood water.
In the course of the hearing, it developed not only that title to the real
estate involved in the claim was vested in William J. Adkins and Dorothy Marie
Adkins, but that the deed to the property, introduced as Respondent?s Exhibit
No. 2, granted their children an interest subject to the life estate of Armilda
Wiley. Accordingly, Armilda Wiley and Dorothy Marie Adkins, as next friend of
Mary Jane Adkins and Peggy Joyce Adkins, the Adkins? daughters, were added by
the Court as additional claimants.
The subject property consists of approximately 10 acres of land fronting about
2500 feet on W.Va. Route 37/2 in Lincoln County, West Virginia. The home of the
claimants is a one- story, four-room frame house with a front porch and a
closed- in back porch. The house rests on piers of concrete blocks about two
feet above the ground.
Leander Wiley, the father of the claimant, Dorothy Marie Adkins, built the
house 25 to 30 years ago and lived in it for approximately 10 years. He
conveyed the property to the claimants, who have lived there since.
The claimant, Dorothy Marie Adkins, testified that approxirnately four years
ago the respondent constructed a fill and
186 REPORTS
STATE COURT OF CLAIMS [W. Va.
installed a three-foot culvert in
Bruner Creek, which runs within 25 feet of their house. She stated that after
the culvert was installed, the creek overflowed during heavy rains, and the
excessive water washed under the house. She complained to the respondent?s
superintendent at West Hamlin, West Virginia, and to Commissioner Ritchie, arid
wrote to the Governor. The respondent replaced the culvert with a four-foot
culvert approximately one and a half years ago, which has not corrected the
problem. She further testified that the creek has overflowed four times since
the culverts were installed, the last time being April 4, 1977. She stated that
the respondent had been notified each time the water overflowed the creek
banks.
The claimants maintained that the culverts were improperly installed by the respondent,
causing the flooding to occur. No evidence was introduced by the respondent to
refute the claimants? allegation. The record establishes that flooding did not
occur prior to the installation of the culverts by the respondent, and that the
claimants notified the respondent, but no action has been taken to remedy the
problem.
The claimants introduced as their Exhibit No. 2 an estimate of the cost to
repair the entire house. The repairs listed on the estimate in the amount of
$13,820.00 were in excess of damages actually caused by the water. The estimate
included replacing the closed-in back porch and the front porch, paneling of
three interior rooms, and replacing the roof shingles.
The parties admitted by agreement Respondent?s Exhibit No. 4, which was an
appraisal of the damaged property.
The appraiser determined that there was physical damage to the house caused by
the flooding of the creek, but that there was no damage to the land from
erosion or soil movement. Primary damage to the property consisted of the
weakening of the pier foundation through erosion around the pillars. The
appraiser considered the damages claimed to the house roof, but since the roof
was over 25 years old and the covering had an actual age of 22 years, it was at
the end of its economic life. Other areas of the house claimed to be damaged
were the result of physical deterioration, not the flooding. The only before
and after value of the property introduced in the record
W. VA.1 REPORTS
STATE COURT OF CLAIMS 187
was established by the respondent. The appraiser established the market value
to be $8,500.00 prior to the damage, and $6,500.00 after the damage.
Therefore, from the evidence and exhibits, the Court finds that the claimants
suffered water damage to their property as a result of the negligence of
respondent, and makes an award of $2,000.00 to claimants William J. Adkins,
Dorothy Marie Adkins, Armilda Wiley, and Dorothy Marie Adkins, as next friend
of Mary Jane Adkins and Peggy Joyce Adkins.
Award of $2,000.00.
Opinion issued October 11, 1978
CYNTHIA LOU BRADSHAW
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-30)
Gregory W. Evers and John P.
Carter, Attorneys at Law, for
claimant.
Nancy J. Aliff, Attorney at Law, for respondent. WALLACE, JUDGE:
Claimant filed this claim in the amount of $140.76 against the respondent for
damages sustained to a tire and rim on her 1975 Chevrolet Camaro automobile as
a result of striking a pothole. The accident occurred on January 31, 1978, at
approximately 8: 15 p.m. on W.Va. Route 25 in Nitro, West Virginia. It was dark
and it was raining. The claimant was traveling at approximately 25 mph
intending to make a right-hand turn from Route 25 into a bowling alley in
Nitro. There was a vehicle about 25 feet in front of her and another behind.
She testified that she saw the lead vehicle hit something in the road which was
later determined to be a pothole in the surface of the highway. She stated that
she was unable to slow down or stop because of the traffic. Her automobile
struck the hole, damaging the right rear tire and rim.
188 REPORTS
STATE COURT OF CLAIMS [W. Va.
The consistent position of the Court
with respect to cases involving alleged highway defects is set out in the case
of Parsovs v. State Road Commission,
8 Ct. Cl. 35 (1969), wherein the Court
stated in part as follows:
?This Court has many times held that the State is not a guarantor of the safety
of its travelers on its roads and bridges. The State is not an insurer and its
duty to travelers is a qualified one, namely, reasonable care and diligence in
the maintenance of a highway under all the circumstances. The case of Adkins v. Sims, 130 W.Va. 645, 46 S.E. (2d) 81, decided in 1947, holds that the user of
the highway travels at his own risk, and that the State does not and cannot
assure him a safe journey. The maintenance of highways is a governmental
function and funds available for road improvements are necessarily limited.?
It was not established by the record that the respondent had notice of a
dangerous condition in the highway, nor was such a neglect of duty proved that
would create liability on the part of the respondent. Accordingly, the Court is
of the opinion to and does disallow this claim.
Claim disallowed.
Opinion issued October 11, 1978
THE COUNTY COMMISSION
OF MASON COUNTY
vs.
DEPARTMENT OF PUBLIC SAFETY
(No. CC-77-109)
W. Dan Roll, Mason County Prosecuting Attorney, for claimant.
Gregory Elliott and Edward
Gardner, Assistant Attorneys General,
for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the
claimant?s Notice of Claim and the respondent?s Amended Answer.
W. VA.] REPORTS
STATE COURT OF CLAIMS 189
Claimant originally sought payment of the sum of $5,200 for back rent due under
a lease agreement with respondent. Claimant later reduced this amount to $3,600
in a letter of settlement to respondent.
In its Amended Answer, the respondent admits that it is indebted to the
claimant for back rent in the sum of $3,600, but also alleges that there were
not sufficient funds in its appropriation for the fiscal year in question from
which the claim could have been satisfied.
While we feel that this is a claim which in equity and good conscience should
be paid, we are of further opinion that an award cannot be made, based on our
decision in Airkem Sales and Service,
et al. v. Dept. of Mental Health, 8
Ct. Cl. 180 (1971).
Claim disallowed.
Opinion issued October 11, 1978
HENRY ELDEN & ASSOCIATES
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-77-190)
Michael T. Chaney, Attorney at Law, for claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant filed its claim in the amount of $4,000.00 for services rendered
the respondent. The claimant entered into a contract with the respondent to
make a feasibility study for an activity center at Twin Falls State Park,
maintained and operated by the respondent. The study was to be divided into
four phases, the claimant to be paid $5,000.00 upon the completion of each phase.
Although the contract provided for a completion date of June 30, 1977, claimant
was directed to finish by the end of February, 1977, so that appropriate
legislation could be presented to the isgislature for approval and funding
190 REPORTS STATE
COURT OF CLAIMS [W. Va.
of the project. In all effort to meet the deadline imposed by the respondent,
the claimant worked on all phases of the contract.
By letter dated February 10, 1977, David C. Callaghan, respondent?s director,
advised the claimant that the respondent did not desire to complete the study
and cancelled the contract. No reasons were given for the cancellation of the
contract.
After the contract was cancelled, the respondent had no further contact with
the claimant, and the claimant filed this claim for services rendered.
Respondent contends that no single phase of the contract was completed, and
there was insufficient work performed to justify the compensation claimed by
the claimant.
To support the amount of the claim, the claimant introduced, as its Exhibits
Nos. 3 and 4, sheets showing the percentage of work performed on each phase of
the contract and the compensation claimed.
The record establishes that the claimant attempted to complete the contract
with the respondent only to have it cancelled. It does not disclose the
specific reasons for the termination. The Court finds that the respondent
breached the contract and that the claimant is entitled to be compensated for
the services rendered the respondent. Accordingly, the Court makes an award of
$4,000.00 to the claimant.
Award of $4,000.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 191
Opinion issued October 11, 1978
DAVID L. MAYSE
vs.
BOARD OF REGENTS
(No. CC?77-173)
Claimant appeared in person.
Frank M. Eltison, Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant instructed an automobile technology program at Parkersburg
Community College, Parkersburg, West Virginia. During the spring semester of
1976, he agreed to repair an unlicensed, 1967 Ford Mustang belonging to William
Satoris as a part of his class instruction. Mr. Satoris was to pay for the
parts. After class periods, the automobile was parked in the area reserved for
teacher parking. Following the spring semester and a six-week summer course,
the claimant left the school for a month on a school-sponsored trip. The
vehicle was left on the teachers? parking lot. In the trunk were a transmission
and alternator, belonging to the claimant.
The claimant testified he had parked old automobiles on the parking lot
previously, but for not more than two hours at a time.
A security employee of the respondent observed that the Mustang and two other
automobiles had been on the parking lot for some time and reported the fact to
his superior. He was instructed to tag them with a notice requesting their
removal within seven days. Such notices were placed on the vehicles. The
automobiles were not removed by the owners, and after seven days they were
towed away.
The claimant, upon his return to the school, discovered the Satoris automobile
missing. His investigation revealed that it had been towed away and he found it
on the premises of H & M Wrecking, the firm that towed the vehicles. The
engine had been removed. He did not inspect the truck to ascertain whether his
transmission and alternator were still there. He
192 REPORTS
STATE COURT OF CLAIMS [W. Va.
made no effort to pay the towing and
storage charges to repossess the vehicle, nor did he notify Mr. Satoris of the
loss of his automobile and its subsequent location at H & M Wrecking.
The claimant filed this claim for the loss of the automobile belonging to Mr.
Satoris and for the loss of his transmission and alternator.
From the record, there is no basis for the respondent to be held liable to the
claimant for the loss of an automobile belonging to Mr. Satoris, nor is there
any liability upon the respondent for tile loss of the transmission and
alternator belonging to the claimant.
The claimant left the Mustang with its contents on the parking lot knowing that
he would be absent from the school for some time. Personnel at the school were
not advised as to the ownership of the automobile nor were any arrangements
made to leave it parked on the parking lot. The action taken by the respondent
was readily foreseeable under the circumstances. There was no negligence or
wrongdoing proved on the part of the respondent which would justify recovery.
The claim of the claimant is disallowed.
Claim disallowed.
Opinion issued October 11, 1978
TRANSPORT MOTOR EXPRESS, INC.
vs.
PUBLIC SERVICE COMMISSION
(No. CC-78-4)
Transport Motor Express, Inc., the
claimant, by Darrell L. Bauer, its agent.
Frank M. Ellison, Deputy Attorney General, for the respondent.
PER CURIAM:
This claim was submitted upon the pleadings. It is admitted by the respondent
that the claimant inadvertently duplicated
W. VA.] REPORTS
STATE COURT OF CLAIMS 193
and twice paid the sum of $837.00 for an order of 279 Uniform Vehicle
Identification Stamps at the rate of $3.00 per vehicle. It is the position of
the respondent that West Virginia Code ?11-1-2a, providing for refund of taxes
erroneously collected, is limited to taxes and cannot be extended by
interpretation to -
fees such as this; hence, the claimant can
recover its inadvertent second payment only through an award in this Court. See
46 Op. Att?y. Gen. 253 (1955). It is readily apparent that an award in the sum
of $837.00 should be, and it is hereby, made.
Award of $837.00.
Opinion issued October 11, 1978
PATRICK WEST
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-205)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation which
revealed the following: During a road construction project of respondent, which
called for the construction of a fill on land adjacent to claimant?s property,
respondent was negligent in failing to provide a drain for the fill. Twice
during heavy rains, mud and water washed into an apartment on claimant?s land,
causing damage in the sum of
$950.00.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $950.00.
194 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued October 23, 1978
THE C&P TELEPHONE COMPANY OF W.VA.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-132)
No appearance by claimant.
Henry Haste backer, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that on or about November 19, 1974,
employees of the respondent were digging on the land of Durstine Perrine,
located near State Route 5/6 in Braxton County, West Virginia; and to the
effect that, while engaged in said digging, the respondent negligently damaged
telephone cables belonging to the claimant in the amount of $239.68; the Court
finds the respondent liable, and an award in the above-stated amount is hereby
made.
Award of $239.68.
Opinion issued October 23, 1978
CLAYWOOD PARK PUBLIC SERVICE DISTRICT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-87)
William R. Pfalzgraf, Attorney at Law, for the claimant. Nancy J. Aliff, Attorney at Law, for the respondent.
PER CURIAM:
Upon stipulation to the effect that respondent?s sign crew damaged claimant?s
water main in the amount of $162.50 while installing a STOP sign, an award in
that amount is hereby made.
Award of $162.50.
W. VA.] REPORTS
STATE COURT OF CLAIMS 195
Opinion issued October 23, 1978
ILENE CLARK COOKSEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-114)
Ilene Clark Cooksey, the claimant, in person.
Gregory W. Evers, Attorney at Law, for the respondent. RULEY, JUDGE:
On March 23, 1977, an automobile owned and driven by the claimant struck a
pothole in Route 60, near Belle, damaging the right front tire and wheel. The
claimant asserts that the accident was caused by the respondent?s negligence
and seeks damages in the sum of $162.63.
The State is neither an insurer nor a guarantor of the safety of motorists
travelling on its highways. Adkins v. Sims, 130 W.Va. 645 (1947); Lowe v. Department of Highways, 8
Ct. Cl. 210 (1971). Therefore, claimant must prove that respondent failed to
conform to a standard of ?reasonable care and diligence * * * under all the circumstances.? Parsons v. State Road Commission, 8 Ct. Cl. 35 (1969). In the instant case, the pothole
was located near the claimant?s right-hand edge of the pavement. It also was
filled with water, from a rain earlier in the day. There is no evidence that
respondent had either actual or constructive notice of the pothole. See Davis v. Department of Highways, 12 Ct. Cl. 31 (1977); Swift v. Department of Highways, 10 Ct. Cl. 56 (1974). Accordingly, the evidence is not sufficient to
establish negligence on the part of the respondent, and this claim must be
denied.
Claim disallowed.
196 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued October 23, 1978
AILEEN W. DODRILL
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-67)
Aileen W. Dadrill, the claimant, in person.
Nancy J. Aliff, Attorney at Law, for the respondent. RULEY, JUDGE:
On February 13, 1978, claimant?s automobile struck a water- covered pothole on
Route 60 between South Charleston and St. Albans, damaging the car in the
amount of $227.46. The claimant alleges that respondent was negligent and is
liable for those damages.
West Virginia neither insures nor guarantees the safety of motorists on its
highways. Adkins v. Sims, 130 W.Va. 645 (1947). Potholes are a persistent and
unavoidable problem, one of which all motorists should be aware. For the State
to be found liable for pothole-caused damages, claimants must first establish
that the State had actual or constructive notice of the particular hazard in
the roadway which caused the accident. Davis
v. Department of Highways, 12 Ct. Cl.
31 (1977). Claimant brought forth no evidence that the State had either actual
or constructive notice, and, accordingly, the claim must be denied.
Claim disallowed.
W. VA.J REPORTS
STATE COURT OF CLAIMS 197
Opinion issued October
23, 1978
A. M. FREDLOCK, II
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-3)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that the claimant, A.M. Fredlock II, was
an employee of the respondent during the time of December 6, 1977 through
December 10, 1977; that the claimant was sick during such period and had
accumulated enough sick leave to cover that perhxl; and that the respondent
improperly deducted said period of absence from claimant?s pay; the Court finds
the respondent liable, and an award of $235.20 is hereby made to the claimant.
Award of $235.20.
Opinion issued October 2J3, 1978
WILLIAM L. HANSON, SR. AND
WILLIAM L. HANSON, JR.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-82)
William L. Hanson, Sr., and William L.
Hanson, Jr., the claimants, in person.
Nancy J. Aliff, Attorney at Law, for the respondent. RULEY, JUDGE:
On March 16, 1978, the claimant, William L. Hanson, Jr., was driving south on
Route 119 at Elkview when an accident occurred which damaged the automobile owned
by the claim-
198 REPORTS STATE
COURT OF CLAIMS [W. Va.
ant, William L. Hanson, Sr., in the amount of $1,000.00. The claimants allege
that the accident was caused by potholes in the road and seek damages from the
respondent.
The simple existence of a pothole in the road does not make the State negligent
per se. For the State to be found negligent, it must have had actual or
constructive notice of the particular road defect which allegedly caused the
accident and must have unreasonably allowed that defect to continue to exist. Davis
v. Department if Highways, 12 Ct. Cl.
31 (1977). The record in this case contains no evidence of any notice to
respondent or failure to act on respondent?s part. Thus, respondent cannot be
found negligent. Recognizing that the State is neither an insurer nor guarantor
of the safety of persons travelling on its highways (Adkins v. Sims, 130 W.Va. 645 [1947] ), and that,
therefore, no award can be made without proof of negligence, the Court must
deny this claim.
Claim disallowed.
Opinion issued October 23, 1978
ALVIN 0. HUNTER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-68)
J. D. Miller, Attorney at Law, for the claimant.
Richard Canton, Attorney at Law, for the respondent.
PER CURIAM:
Upon stipulation to the effect that, on February 10, 1977, the claimant?s
automobile was damaged in the amount of $223.00 when a portion of ceiling tile
fell from the Wheeling Tunnel ceiling onto the car; and to the effect that
respondent is responsible for the maintenance of the Wheeling Tunnel; the Court
finds the respondent liable, and an award of $223.00 is hereby made to the
claimant.
Award of $223.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 199
Opinion issued October 23, 1978
JAMES G. KEITH
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-188)
James G. Keith, the claimant, in person.
Richard Canton, Attorney at Law, for the respondent.
RULEY, JUDGE:
The claimant?s automobile struck a pothole located two feet to the right of the
eastbound lane of the ramp from Route 61 to the Montgomery bridge. The claimant
seeks damages in the amount of $95.62 from the respondent.
The State is neither an insurer nor a guarantor of the safety of persons
travelling on its highways. Adkins v.
Sims, 130 W.Va. 645 (1947). For the
State to be found liable, it must first have had either actual or constructive
notice of the defect in the roadway. It appears in this case that the State had
no notice at all, and, accordingly, cannot be found liable.
Claim disallowed.
Opinion issued October 23, 1978
PEGGY KEYSER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78.-38)
Peggy Keyser, the claimant, in person.
Nancy J. Aliff, Attorney at Law, for the respondent. RULEY, JUDGE:
On October 27, 1977, the claimant was lawfully driving east on 1-64 towards
Huntington when her car ran over a sign lying flat on the roadway, which sign
flipped up and damaged her automobile?s exhaust system in the sum of $113.56.
200 REPORTS
STATE COURT OF CLAIMS [W. Va.
The Court finds that the sign (a long,
narrow sign with yellow and black diagonal stripes, like those used by
respondent) was respondent?s property; that leaving it upon the travelled
portion of the highway constituted negligence on respondent?s part; and that an
award therefore should be made to the claimant in the amount of $113.56.
Award of $113.56.
Opinion issued October 23, 1978
JAMES T. KRATOVIL
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-.78-54)
James T. Kratovil, the claimant, in person.
Gregory E. Elliott, Attorney at Law, for the respondent.
RULEY, JUDGE:
The claimant alleges that the respondent was negligent in issuing a pass to an
involuntarily committed patient, permitting the patient to leave Weston
Hospital to seek legal assistance from the claimant, a lawyer in Weston. While
in the claimant?s office, the patient became excited, asked claimant for money
and, when he refused, smashed his typewriter against the wall. The claimant
seeks damages in the amount of $140.00, the price of the ruined typewriter.
The fact that a mental patient, while temporarily released from a hospital,
causes damage to someone?s property does not make the institution granting the
release negligent per se. Such releases may be an integral part of the
patient?s therapy. The claimant must establish that the hospital and its staff
did not ?exercise that degree of care, in diagnosing the illness of a patient
and in calculating the possibilities that his assaultive tendencies may assert
themselves, which is commensurate with the risks involved in opening the doors
of the hospital to him
W. VA.]
REPORTS STATE COURT OF CLAIMS 201
for leaves of absence during which he
will be free of professional care, supervision or restraint.? Eanes v. U.s.,
407 F.2d 823, 38 A.L.R.3d 696, at 698
(4th Cir., 1969). See also annotation at 38 A.L.R.3d 699. In this case, there
is no evidence whatever before the Court regarding the patient?s background,
the hospital?s reasons for granting the pass, the degree of care exercised by
the hospital staff, or anything else which would convince this Court that the
respondent was negligent in calculating the risks to the public and granting
the pass to the patient. Without such evidence, the claim must be disallowed.
Claim disallowed.
Opinion issued October 23, 1978
DALLAS POE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-97)
Dallas Poe, the claimant, appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
At about 7:00 p.m. on April 9, 1978, the claimant was operating his 1969
Chevrolet automobile in an easterly direction on Route 60 near Hurricane in
Putnam County, when he struck a pothole which he estimated to be about 15 to 20
inches wide and 9 inches deep. As a result, his automobile sustained damages in
the amount of $101.46. Mr. Poe testified that he was travelling at about 45
miles per hour in a 55-mile-per- hour area; that the highway was fairly
straight; that it was still daylight and the weather was clear and the highway
was dry; and that there were no vehicles in front of him which would have
obstructed his vision or ability to see the pothole which he struck.
Mr. Poe further testified that the following morning he telephoned respondent?s
headquarters in Winfield and reported
202 REPORTS STATE
COURT OF CLAIMS [W. Va.
the incident. The lady with whom he spoke did not identify herself but did
advise Mr. Poe that they knew about the pot hole and that they had received
other complaints. The lady apparently did not advise Mr. Poe as to the length
of time that they had knowledge of the existence of this pothole.
Proof of actual or constructive notice of the existence of a pothole is a
necessary ingredient to the establishment of negligence on the part of
respondent. Cummings v. Department of
Highways, 12 Ct. Cl. 59 (1977); Hoskins v. Department of Highways, 12 Ct. Cl. 60 (1977). Additionally, it must be
established that after receiving notice, the respondent had sufficient time
within which to take remedial action. This element was not established in this
claim. Further, this Court feels that the failure of the claimant to observe
the pothole and avoid striking it, certainly, at least, contributed to the
accident.
For the foregoing reasons, this claim is denied.
Claim disallowed.
Opinion issued October 23, 1978
THELMA J. STONE
vs.
OFFICE OF THE GOVERNOR?
EMERGENCY FLOOD DISASTER RELIEF
(No. CC-78-11)
Thelma J. Stone, the claimant, in person.
Frank M. ElUson, Attorney at Law, for the respondent. PER CURIAM:
The respondent admits liability for damages in the amount of $2,500.00 to a
rock wall owned by the claimant, caused by the State?s workers during the
clean-up of flood debris in Williamson on or about April 19, 1977. Accordingly,
an award of $2,500.00 is hereby made.
Award of $2,500.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 203
Opinion issued October 23, 1978
WILLARD P. TEETS, ATTORNEY IN FACT FOR
PERCY E. TEETS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-158)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $3,000.00, based upon
the following facts: During the month of January, 1977, the respondent was
engaged in snow removal operations on State Route 47 in Preston County, West
Virginia, in the vicinity of property belonging to Percy E. Teets, represented
herein by his Attorney in Fact, William P. Teets. In the course of these
operations, the respondent negligently caused snow to be piled on the property
of Percy E. Teets, killing certain trees. Respondent is therefore liable to
claimant for the sum of $3,000.00, which is a fair and equitable estimate of
the damage sustained by the aforementioned Percy E. Teets.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $3,000.00.
204 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued October 23, 1978
W. F. WEBB
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-191)
No appearance by claimant.
Henry Haste bacher, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that claimant resides at 115 Brown
Street in Clarksburg, West Virginia; that damages to the foundation of
claimant?s dwelling in the amount of $1,100.00 were caused by water run-off
from a nearby road right-of-way owned by the respondent; and to the effect that
negligence on the part of the respondent was the proximate cause of said
damage, the Court finds the respondent liable, and hereby makes an award in the
above-stated amount.
Award of $1,100.00.
Opinion issued October 24, 1978
JEFFREY D. BUBAR
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-27)
Jeffrey D. Bubar, the claimant, in person.
Richard Canton, Attorney at Law, for the respondent.
RULEY, JUDGE:
A contractor employed by the respondent as its agent was removing snow from
1-64 on January 22, 1978, when its endloader caught the end of an expansion
joint in the roadway, bending it upward four inches. The contractor did not
report the incident. A courtesy patrol driver reported it sometime before 11:00
A.M., and the respondent?s witness testified that the damage was repaired by
11:30.
W. VA.]
REPORTS STATE COURT OF CLAIMS 205
Sometime shortly before the damage was
repaired, the claimant?s car struck the bent expansion joint, damaging his
automobile?s exhaust system in the amount of $92.24. There is no evidence of
any contributory negligence of the claimant.
General principles of tort and agency law require that the Court find the
respondent liable. The contractor damaged the expansion joint, and negligently
failed to make any effort to notify the respondent or warn motorists. Any such
effort could have prevented the damage to the claimant?s car. ?Where an agent
acts negligently in the regular course of his employment, the law is well
settled that the prnicipal must bear the consequences of his agent?s negligence
* *
?. 1A M.J., ?Agency?, ?86.
The contractor negligently performed his appointed task; the respondent is
therefore liable to the claimant. Accordingly, an award is hereby made in the
amount of $92.24.
Award of $92.24.
Opinion issued October 24, 1978
CAPITOL BUSINESS EQUIPMENT, INC.
vs.
BOARD OF REGENTS
(No. CC-77-108)
Fred F. Holyroyd, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted upon the pleadings by agreement of the parties. The
respondent admits that on June 7, 1976, West Virginia University received 262
Model No. 3015 Heavy Duty Hirsch traverse rods, with attachments, pursuant to
its Order No. 812405, for the sum of $951.06, but avers that there were not
sufficient funds appropriated by the Legislature for the fiscal year in
question from which payment could be made. Following the precedent of Airkem
Sales and Service, et al. v. Dept. of Mental Health, 8 Ct. Cl. 180
(1971), the claim must be denied.
Claim disallowed.
206 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued October 24, 1978
CAVALIER CRUSHING COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-.77-26)
Donald A. Lambert, Attorney at Law, for the claimant.
Gregory Evers, Attorney at Law, for the respondent.
RULEY, JUDGE:
In early July, 1976, the claimant crushing company received a letter from the
respondent announcing an auction sale of ?approximately 1350 junk cars?, to be
held at the site where the cars were located near Belington, in Barbour County,
on July 23, 1976. In response to the letter, Mr. Mason Herring, owner of the
crushing company, visited the site on the day before the auction and attempted,
without success, to count the number of vehicles located there. On the day of
the auction and prior to the sale, employees of respondent announced that an
additional 158 units had been added to the lot, making a total of 1508. The
auctioneer, an employee of the respondent, informed the prospective bidders
that they were to bid on what they could see, and the bidders were given ample
time to inspect the site and attempt to evaluate the junk. The claimant was the
high bidder and proceeded to crush the junk and sell the scrap to a metal
recycling company. The claimant contends that it found only 756 junk cars,
instead of the 1350 advertised by the respondent, that it incurred a monetary
loss of $32,177.50 as a result of the respondent?s alleged misrepresentation,
and asks for an award in that amount.
The respondent contends that the auction was a sale in gross (that is, a sale
of whatever junk was on the site, not a sale of any specific number of junk cars) and that
the respondent performed its part of the sale and, therefore, is not liable.
Several persons who attended the auction testified that, although the
auctioneer mentioned the number 1508, he also pointed to the lot and told the
bidders, ?You?re buying what
W. VA.]
REPORTS STATE COURT OF CLAIMS 207
you see.? The auctioneer testified
that he told the bidders that the lot contained 1508 ?units?, and that he
proceeded to explain that ?unit? was a term used by respondent in
record-keeping. He also testified that, in his explanation to the bidders, he
defined a ?unit? as one load of junk dumped by respondent?s employees at the
site, said loads often consisting of less than one junk car.
?A sale by auction is complete when the auctioneer so announces by the fall of
the hammer or in other customary manner.? W. Va. Code ?46-2-328. Thus, although
this sale was later reduced to a written contract (which, incidentally, made no
reference to any specific number of cars or units), this Court must analyze the
terms of the sale as understood by the parties at the time the hammer fell.
?Where the terms and conditions of the sale are plain and unambiguous and are
plainly announced at the time and place of sale, they are binding upon a
purchaser at the sale, whether he heard them or not and though he may not have
understood them.? 2A M.J. ?Auctions
and Auctioneers?, ?9. The evidence in
this case clearly reveals that the bidders understood that they were bidding
for the right to clear the site of the junk located there, not for any
particular number of vehicles. Mr. Herring and his son, apparently not
intending to rely on the advertised estimate, visited the site on the day
before the auction to count the cars and estimate the value of the junk, and
saw the site and the junk again on the day of the sale. Others engaged in the
crushing business testified that their concern is with the weight of the junk,
since they sell it by the ton. The number of cars may be a useful tool for
estimating the weight and, hence, the value of the junk, but it is understood
to be an imprecise measure. From the evidence, the Court is constrained to
conclude that the number of cars at the site was not a material element of the
sale. Both claimant and respondent understood the terms of the sale to include
all the vehicles, parts of vehicles, or other junk at the site, irrespective of
the number of cars there. Mr. Herring?s failure to hear the auctioneer?s
explanation of ?unit? does not make the respondent responsible for Mr.
Herring?s failure to estimate accurately the amount of junk at the site.
208 REPORTS STATE
COURT OF CLAIMS [W. Va.
In a similar Virginia case, an auctioneer stated that a tract of land for sale
consisted of two acres, but pointed to the enclosure of the tract at the same
time. The successful bidder, upon finding that the tract contained only ?one
acre and twelve poles?, refused to pay. The seller was granted a bill for
specific execution against the buyer, the Court holding that ?it was a purchase
of the lot of ground, such as it was, whether it was more or less than two
acres?, and denied the buyer?s request for abatement of the price. Foley v. McKeown, 4 Leigh 627, 31 Va. 1059 (1833). See also Grantland v. Wight, 2 Munford 179, 16 Va. 357 (1811). The same principles apply to this case
inasmuch as this was a sale of the lot of vehicles, cars, or junk. Thus, under
the facts of this case and the applicable law, the Court must find the
claimant?s contention to be without merit and deny this claim.
Claim disallowed.
Opinion issued October 24, 1978
FOREST JOE KING, ET AL.,
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-37)
James H. Coleman, Attorney at Law, for the claimant. Nancy J. Aliff, Attorney at Law, for the respondent.
RULEY, JUDGE:
The claimants in this case are Forest Joe King and Patricia Ann King, husband
and wife, and their two infant children, Denny Joe King and Beverly King, all
of whom seek damages for personal injuries which they sustained in a
single-vehicle accident which happened at approximately 2:20 P.M., on Saturday,
March 13, 1976, at a point on West Virginia Route in the village of Hotchkiss,
in Raleigh County. At the time and place of the accident, Forest Joe King was
driving his 1971 model Ford F-100 truck in a general southerly direction upon
the highway and the other claimants were passengers in
W. VA.]
REPORTS STATE COURT OF CLAIMS 209
it. His claim includes the following
special damages: $5,134.00, representing the total medical expense incurred by
all four occupants of the truck for the treatment of their injuries; $1,300.00
for damage to his vehicle; $1,267.00 for lost wages; and $1,000.00 for services
of a housekeeper, prescriptions, and transportation. All of those sums and
items were received in evidence by agreement and stipulation of the parties.
The evidence shows that, as a southbound vehicle approached the place where the
accident happened, it travelled around a curve to the right and then entered a
straight stretch of highway at least 300 feet long at the end of which there
was a curve to the left. The highway was paved with a blacktop surface which
was dry at the time of the accident. At about 100 feet from the south end of
the straight stretch, there were three large potholes in proximity to each
other in the southbound traffic lane. The evidence shows that they had been in
existence for a substantial length of time before March 13, 1976. In fact,
Trooper Bradford Vaughan of the Department of Public Safety, who investigated
the accident, testified that he himself had hit the holes while operating his
cruiser in either February or March before the accident happened. The evidence
shows that the holes were of sufficient size to present a considerable danger
or hazard to vehicular traffic but that the respondent had not taken any action
to warn vehicle operators of that danger. Mr. King travelled over the straight
stretch at about 30 to 40 miles per hour. He saw the first of the three
potholes at a distance of about 100 to 200 feet and then slowed to about 20 to
25 miles per hour. Due to oncoming traffic, he was unable to miss the hole
nearest the south end of the straight stretch which was struck by the right
wheels of the truck. That hole was about 3 feet wide, 3 feet long, and 6 to 8
inches deep. The impact of that collision broke the steering mechanism of the
truck, causing it to leave the pavement and travel 96 feet over the west berm
of the highway and down an imbankment into a ditch. This evidence impels the
Court to resolve the issue of liability in favor of the claimants. While it is
true that the respondent?s county maintenance supervisor testified in effect
that the respondent was doing all that it could do to maintain the highways of
Raleigh County
210 REPORTS
STATE COURT OF CLAIMS {W. Va.
before the accident happened, no
explanation was offered for its failure to warn motorists of the danger created
by the potholes which precipitated this accident. And the evidence plainly
shows that such dangerous condition had existed for a sufficient length of time
that the respondent either knew, or, in the exercise of ordinary care, should
have known of its existence.
Turning to the matter of damages, the evidence shows that, in addition to the
special damage aggregating $8,701.00 previously delineated, Forest Joe King
sustained undisplaced complete vertical fractures of the anterior aspects of
the left third and fourth ribs and a sprain of his cervical spine. Patricia Ann
King sustained a compound comminuted fracture of the mid-shaft of her left
femur and a compound fracture of her nose. Denny Joe King sustained a fracture
of the right frontal portion of his skull. Beverly King sustained a cerebral
contusion. All of the occupants of the truck sustained abrasions and contusions
and all of them were admitted as patients to Raleigh General Hospital following
the accident. Beverly King was discharged from the hospital on March 16, 1976,
Denny Joe King was discharged on March 18, 1976, and Patricia Ann King was
discharged on April 3, 1976. There is no evidence of the date on which Forest
Joe King was discharged. Apparently, no member of the family sustained a
permanent injury other than Mrs. King. In the report of an orthopedic
evaluation performed March 20, 1978, it is stated that she has a one-half inch
shortening of the left lower extremity with generalized muscular atrophy and
limitation of flexion of the knee by 30%. The orthopedist estimated her
disability at 15%. At the time of the examination, she was 22 years of age. In
view of the evidence, the Court is disposed to make awards as follows: to
Forest Joe King, the sum of $11,000.00; to Patricia Ann King, the sum of
$20,000.00; to Denny Joe King, the sum of $2,500.00; and to Beverly King, the
sum of $2,500.00.
Award of $11,000.00, to Forest Joe King;
award of $20,000.00, to Patricia Ann King;
award of $2,500.00, to Denny Joe King; and
award of $2,500.00, to Beverly King.
W. VA.] REPORTS
STATE COURT OF CLAIMS 211
Opinion issued October 24, 1978
HAROLD MAHAFFEE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC.-77-136)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $94.24, based upon the
following facts:
On or about July 1, 1977, claimant was lawfully operating his 1973 Ford Torino
on and over the Market Street Bridge, also known as U.S. Route 250, in
Wheeling, West Virginia. Due to the negligence of the respondent, the
claimant?s automobile was damaged by a MEN WORKING sign, which blew over and
struck said automobile. Respondent is therefore liable to claimant for the sum
of $94.24, which is a fair and equitable estimate of the damage sustained by
the claimant.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $94.24.
Opinion issued October 24, 1978
ALICE MARCUM
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-76-65)
Raymond F. Crooks, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant, Alice Marcum, age 60, filed her claim against the respondent for
injuries received from a fall in an outhouse
212 REPORTS
STATE COURT OF CLAIMS [W. Va.
in Laurel Run State Park which is
maintained by respondent. The claimant was attending a church school picnic in
the park on June 22, 1975. It was a hot, clear day. The church group,
consisting of 30 to 40 persons, arrived at the park at approximately 9:30 a.m.
on the morning of the day of the accident. The picnic area was near the
swimming pool area. After church services, the group had their picnic lunch.
The claimant testified that after eating she went to an outhouse, but because
of the dirty conditions, she did not enter, but proceeded to another. As she
attempted to enter the outhouse, where she had never been before, she opened
the door, stepped up from the ground level onto the outhouse floor, slipped on
the floor, and fell. She stated that the interior was dark, and that the floor
had paper and water on it. The claimant fractured her left elbow in the fall,
and, as a result of her injury, will always have a limitation of motion.
Brenda Droughts, a witness for the claimant, testified that she attended the
picnic the day the claimant was injured and had been in the park each of the
three previous days; that she took her children to the park several times a
week to picnic and was familiar with the outhouse in question as well as the
others in the area. She further testified that they were always a mess. The
floors were covered with paper plates, paper, and water. Rather than use the
outhouses, she took her children to the restrooms at the swimming pool because
they were much cleaner.
The record establishes that the respondent knew or with reasonable effort
should have known of the condition of the outhouses and taken such action as
was necessary to correct the situation. The failure of the respondent to
properly maintain the facilities placed in the park for public use constitutes
negligence on the part of the respondent.
The claimant incurred doctor bills in the amount of $149.00 and a hospital bill
of $22.00, and sustained limited permanent injury to her elbow. The Court finds
that the negligence of the respondent caused the injury to the claimant, and
makes an award of $2,171.00.
Award of $2,171.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 213
Opinion issued October 24, 1978
RHODA RAYNETT McINTYRE
vs.
DEPARTMENT OF HIGHWAYS
(No. D-737)
Frank T. Litton and James M.
Sturgeon, Jr., Attorneys at Law, for
the claimant.
James W. Withrow, Attorney at Law, for the respondent. RULEY, JUDGE:
On the night of Wednesday, May 17, 1972, the claimant, in company with her
mother, went into the Cohen Drugstore on Washington Street in Pocatalico to do
some shopping. They left the drugstore at about 10:00 P.M., intending to cross
Washington Street at a point directly in front of it. While her mother was
crossing the street uneventfully, the claimant stepped off the sidewalk into a
pothole in the blacktop surface of the pavement adjacent to the curb, which
caused her to fall. On cross-examination, she testified that the ?oblong? hole
was about a foot and a half long, four or five inches deep, and about thirty
feet from the intersection of Rebecca Street. She also testified that, while it
was not raining at the time of the accident, it had rained earlier in the
evening and there was water in the hole. When she fell, the claimant was
carrying packages containing various items including a hamster cage. The
claimant was unaware of the hole until she stepped down into it. There was no
claim that the respondent had actual knowledge of the pothole, but constructive
knowledge was established, albeit without great weight, by the undisputed
testimony of an expert witness who testified that, in his opinion, it would
have taken more than two months for the hole to develop to its size at the time
of the accident. Such constructive knowledge, without any remedial measures or
warning action, establishes negligence on the part of the respondent. The Court
could not conclude that the claimant was guilty of contributory negligence
without resorting to speculation, and, accordingly, the issue of liability must
be resolved in her favor.
214 REPORTS STATE
COURT OF CLAIMS [W. Va.
Turning to the matter of damages, it appears that the claimant sustained
abrasions of her right knee and a bruise of her right ankle. She has sought
medical attention for those injuries on only two occasions, viz., May 22, 1972,
and January 6, 1977, when she went to the office of Jean P. Cavender, M.D.,
incurring expense in the sum of $22.00. On the latter occasion, it was reported
that
?She states that the right ankle and right knee ache and sometimes swell after
being on them too much. She tried to work in a drug store last year and found
that the joints were painful after being on them for 7-8 hours.?
but no objective symptoms were noted, and there was full range of motion in
both joints. In view of the evidence, the Court is disposed to make an award in
the sum of $500.00.
Award of $500.00.
Opinion issued October 24, 1978
MOORE BUSINESS FORMS, INC.
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-78-46)
Moore Business Forms, Inc., the claimant, by James Ruziska, its agent.
Edward W. Gardner, Assistant Attorney General, for the respondent.
PER CURIAM:
This claim was submitted upon the pleadings. Upon the admission of the
respondent that it received and accepted an excess of 770 business forms
(10,770 on an order for 10,000), having a value of $51.42, an award in that sum
is hereby made.
Award of $51.42.
W. VA.]
REPORTS STATE COURT OF CLAIMS 215
Opinion issued October 24, 1978
ORKIN EXTERMINATING, INC.
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-78-96a-c)
Ray Summer field, Branch Manager, Orkin Exterminating, Inc., appeared for
the claimant.
Gregory E. Elliott and Edward W.
Gardner, Assistant Attorneys General,
for the respondent.
RULEY, JUDGE:
At the hearing upon this claim, the respondent admitted liability for failure
to pay for services rendered to Roney?s Point Center, and admitted that funds
remained in the budgets for the years in question from which the bills could
have been paid. However, neither the claimant nor the respondent accurately
added the amounts clue. Performing its own addition, the Court finds respondent
liable to claimant in the amount of $110.00 for claim 96a, $68.00 for claim
96b, and $34.00 for claim
96c, for a total award of $212.00.
Award of $212.00.
Opinion issued October 24, 1978
CHARLES EDWARD PAULEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-136)
Charles Edward Pauley, the claimant, in person.
Nancy J. Aliff, Attorney at Law, for the respondent.
WALLACE, JUDGE:
This claim is for property damage in the sum of $203.39 sustained by the
claimant?s Dodge automobile in a single-
216 REPORTS
STATE COURT OF CLAIMS [W. Va.
vehicle accident which occurred at about
11:45 P.M., on Wednesday, April 26, 1978, when the claimant drove that
automobile into a depression about 10.5 feet wide and 3 feet deep in Secondary
Route 3/3, commonly called High Street, near St. Albans. The claimant testified
that there had been a chronic and recurring problem, of which he was aware,
caused by slipping of the road base at the place where the depression was
located. He also testified that, at the time of the accident, it was raining.
He testified further that he had observed the depression when he drove over the
road on the morning of April 26, 1978, but that its depth had increased between
then and the time of the accident. Under the law of West Virginia, it is well
settled that contributory negligence on the part of a claimant, however slight,
which contributes to proximately cause an accident and resulting injuries, will
preclude the recovery of damages. 13B Michie?s Jurisprudence, ?Negligence?,
?26, p. 280. Under the facts of this claim, it is apparent that, irrespective
of whether the respondent was or was not negligent in the performance of its
duties relating to Secondary Route 3/3, the claimant was himself guilty of
negligence which at least contributed to cause the accident and his resulting
damage. Being aware of the depression, its propensity to become worse, and the
fact that it was raining, he failed to take sufficient precautions to protect
his own safety and property. Accordingly, this claim must be denied.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 217
Opinion issued October 24, 1978
RANDALL I. SAMPLES
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-82)
Charles M. Kincaid, Attorney at Law, for the claimant. Gre go?ry W. Evers, Attorney
at Law, for the respondent.
RULEY, JUDGE:
This claim grows out of a single-vehicle accident which occurred at about 10:00
P.M., on Sunday, May 22, 1975, at a point of West Virginia Route 4 near Corton
in Kanawha County. The claimant was driving his van in a general easterly
direction around a curve, following a vehicle being driven by an unidentified
woman, when a large oak tree fell across the highway between the two eastbound
vehicles. The claimant?s van then collided with the tree, with resultant
damages and injuries being sustained by the van and the claimant, respectively.
Upon agreement of counsel, only the issue of liability was tried.
The claimant testified that when he first saw the oak tree on the night of the
accident, it had just fallen onto the pavement about 30 feet in front of his
van, which he was operating at about 40 miles per hour. The trunk of the oak
tree was about three feet in diameter and it was about 50 to 60 feet tall.
Before it fell, it was located above the highway and near the top of an
embankment on its north side. The terrain at and near the place where the
accident happened was densely wooded on both sides of the highway. The tree was
alive. Although the evidence respecting the location of the tree may have been
somewhat equivocal, the only evidence before the Court, offered by two
witnesses on behalf of the respondent, was that the tree was not on the public
right-of-way. It was uncontroverted, however, that at least some portion of it
extended over the highway. It also was uncontroverted that, shortly before the
accident occurred, a severe thunderstorm accompanied by gusting winds had
passed through the area.
218 REPORTS
STATE COURT OF CLAIMS [W. Va.
The claimant testified that he was
familiar with the oak tree and its location, having noticed it frequently
before the accident happened. There was no evidence that the respondent, or
anyone else, had been working in the area from which the tree fell.
The Court is constrained to conclude that it is not established by a
preponderance of the evidence that the respondent knew or, in the exercise of
ordinary care, should have known that the oak tree posed a hazard to traffic on
the highway. See Widlan v. Department of Highways, 11 Ct. Cl. 149 (1976) and Criss v. Department of Highways, 8 Ct. Cl. 175 (1970). Accordingly, the claim must be
denied.
Claim disallowed.
Opinion issued October 24,
1978
R. L. SMITH, D/B/A
ARCHITECTURAL ASSOCIATES
vs.
DEPARTMENT OF PUBLIC SAFETY
(No. CC-78-174)
No appearance by claimant.
Ellen F. Warder, Assistant Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer. Claimant seeks payment of the sum of $879.91
for architectural services performed on a project involving the State Police
Academy Dormitory at Institute, West Virginia.
The respondent admits the validity of the claim, but states also that there
were not sufficient funds remaining in Special Revenue Account 8352-36 from
which the claim could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are of further opinion that an
W. VA.]
REPORTS STATE COURT OF CLAIMS 219
award cannot be made, based on our
decision in Airkem Sales and Service,
et al. v. Department of Mental Health, 8
Ct. Cl. 180 (1971).
Claim disallowed.
Opinion issued October 24, 1978
BILLY JOE VINSON
AND PAUL F. VINSON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-157)
James M. Cagle, Attorney at Law, for the claimants.
Nancy J. Aliff, Attorney at Law, for the respondent. RULEY, JUDGE:
These claims for damages for personal injuries sustained by each claimant
respectively, and for property damage to the 1966 model Cadillac automobile
owned by the claimant, Paul F. Vinson, arise out of a single-vehicle accident
which happened at approximately 10:00 P.M. on August 27, 1975, when that
automobile collided with a concrete pier or abutment separating the two traffic
lanes of W.Va.-U.S. Route 119 at a railroad underpass in Marmet, Kanawha
County. At the time and place of the accident, Paul F. Vinson was driving his
automobile with its headlights on, and his brother, Billie Joe Vinson, was
riding in the right front seat. They were traveling in a general northerly
direction from their former home in Logan to Cleveland where they then resided.
Paul F. Vinson had driven through the underpass before and was familiar with
it.
The claimants contend that the accident was caused by negligence on the part of
the respondent in failing to repair several holes in the northbound lane of the
highway south of the underpass, and in failing to warn motorists of their
existence. Paul F. Vinson testified that those holes were two to three inches
deep and about ten to fifteen inches ?around?. Billie Joe Vinson described the
highway at that place as a
220 REPORTS
STATE COURT OF CLAIMS [W. Va.
?rough road?. Neither claimant saw the
holes before the automobile struck the first one. Both claimants and other
witnesses called in their behalf testified to the effect that at the time of
the accident, there were no signs warning northbound drivers of any danger or
hazard. Billie Joe Vinson testified that Paul said, ?Brace yourself? when the
car encountered the rough road and that the car hit the pier about three or
four seconds later. Paul F. Vinson testified that, prior to striking the holes,
he had been driving at a speed of 35 or 40 miles per hour. He also testified
that, when he hit the holes, he hit the brakes, but they didn?t stop the car,
adding that, ?They didn?t hold the car back. The car kept going.? It is a rule
of thumb that miles per hour may be converted to feet per second by multiplying
the miles per hour by one and one-half. Thus, a vehicle traveling 35 miles per
hour travels 52.5 feet in one second, 157.5 feet in three seconds, and 210 feet
in four seconds.
On August 2, 1975, a train had derailed and had fallen on Route 119 on the
south side of the underpass causing extensive damage to the paved surface of
the highway. The undisputed evidence is that from that date until a new surface
was applied (sometime after August 27, 1975) the respondent made repairs,
including patches, in that area several times each week. In addition, several
employees of the respondent, the investigating police officer of the City of
Marmet, J. W. Armentrout, and Dan Toney, an emergency medical technician
employed by the Marmet Fire Department and Ambulance Service, testified to the
effect that a warning sign or signs were erected (although there was divergence
in their testimony as to the type of sign) and in place at the time of the
accident warning northbound motorists of the rough or hazardous road. Jerry
Easter, a foreman employed by the respondent, testified that a ?Rough Road?
sign had been erected facing northbound traffic at a point about one hundred
yards south of the underpass. Messrs. Toney and Armentrout confirmed that
testimony.
Significantly, Officer Armentrout testified that, incident to his investigation
of the Vinson accident, he took a statement from Paul F. Vinson which read:
W. VA.]
REPORTS STATE COURT OF CLAIMS 221
??Going north on U.S. 119, I saw a sign, I
hit my brakes, the car lights blinded me, and the car slid, onto the dirt and
rocks.?? (Emphasis supplied.)
Officer Armentrout also made the following answers to the following questions
regarding a conversation with Paul F. Vinson at the Charleston Area Medical
Center:
?Q Were the people, then, sitting right outside of the
emergency room at Charleston Area Medical Center?
A Right, the driver was, right.
Q Okay. Do you specifically recall these words being said
to you about signs, or do you recall them after reading your report that you
submitted?
A I remember him saying something about he saw the signs.
Q Do you remember what signs he was talking about?
A They ?
he said he saw the sign just before he entered the construction site, and as well as I remember, the only signs that was
there was the hazard signs.? (Emphasis supplied.)
The duty owed by the respondent to motorists traveling upon state highways is a
qualified one, namely, reasonable care and diligence in the maintenance of its
highways under all the circumstances. Cassel
v. Department of Highways, 8
Ct. Cl. 254, at 259 (1971). The undisputed evidence respecting frequent repairs
to the surface of the highway between the train derailment on August 2 and the
claimants? accident on August 27, 1975, precludes a finding that the respondent
was negligent in failing to repair the highway. Although there is a substantial
conflict in the evidence as to the existance of a warning sign at the time of
the accident, the Court feels obliged (particularly in view of the statement
made by Paul F. Vinson to Officer Armentrout, shortly after the accident
happened, to the effect that he saw such sign) to resolve that conflict in
favor of the respondent. It necessarily follows that the Court must conclude
that the respondent was not guilty of negligence
222 REPORTS
STATE COURT OF CLAIMS [W. Va.
which proximately caused the accident
and, hence, deny these claims.
Claims disallowed.
Opinion issued November 16, 1978
ELVA B. PETTS
vs.
DIVISION OF VOCATIONAL REHABILITATION
(No. D-927d)
AND
JAMES M. PRESTON
vs.
DIVISION OF VOCATIONAL REHABILITATION
(No. D-927i)
Michael J. Farrell, Attorney at Law, for claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
These claimants are seeking awards for overtime compensation during a period of
time that they were employed as houseparents at the respondent?s facility at
Institute, West Virginia. Actually, a total of eleven claims were filed, but
counsel agreed to present testimony in only two, believing that the testimony
of these two claimants would be representative of all pending claims. Ten of
the claims, including these two, were filed on February 21, 1975, and the
eleventh, the claim of Paul Leach, was filed on April 23, 1975.
Initially, what must be determined is the applicable period of time during
which the claimants allegedly failed to receive the overtime wages to which
they were entitled under the West Virginia Minimum Wage and Maximum Hours
Standards For Employees. Code 21-5C-8 provides as follows:
W. VA.]
REPORTS STATE COURT OF CLAIMS 223
?Any employer who pays an employee
less than the applicable wage rate to which such employee is entitled under or
by virtue of this article shall be liable to such employee for the unpaid
wages; an agreement by an employee to work for less than the applicable wage
rate is hereby declared by the legislature of West Virginia to be against
public policy and unenforceable.
In any such action the amount recoverable shall be limited to such unpaid wages
as should have been paid by the employer within
two years next preceding the commencement of such action. Nothing in this article shall be construed to limit the
right of an employee to recover upon a contract of employment.? (Emphasis
supplied.)
Claimants contend that, although the actions (with the exception of one) were
commenced on February 21, 1975, through their attorney they presented their
claims to the Wage and Hour Director of the West Virginia Department of Labor
on or about November 15, 1974, and after conducting an investigation, the
Director suggested that the claimants file their claims in this Court. Thus,
the claimants contend that the two-year period should run from November 15,
1972 to November 15, 1974. With this contention we cannot agree. The wording of
the statute quoted above is clear and unambiguous, and we thus hold that the
statute mandates the two-year period to be between February 21, 1973 and
February 21, 1975. During the early part of this period, the claimants were
required to work nine straight days, and then they would be entitled to five
straight off days, after which they would again work nine straight days. Under
this schedule the claimants were paid a monthly salary in addition to receiving
free meals and lodging. On May 1, 1974, as a result of an amendment, the Federal
Wage and Hour law became applicable to State employees. Thereafter, on June 7,
1974, the respondent?s housemothers began working a daily eight-hour shift, and
the housefathers, on June 30, 1974, went to the eight-hour shift. The evidence
in respect to the date of the implementation of the shift work was conflicting,
and for the sake of consistency, we here hold that the period of time in
question for both housemothers and housefathers is from February 21, 1973
224 REPORTS STATE
COURT OF CLAIMS [W. Va.
through June 30, 1974. The claim of Paul Leach having been instituted on April
23, 1975, the period in question for him is April 23, 1973 through June 30,
1974.
Counsel for the respondent vigorously contends that at the close of fiscal year
1972-73 and fiscal year 1973-74, insufficient funds were expired in the
personal service accounts from which these claims for overtime compensation
could have been paid, arid that the ability of this Court to make awards has
been foreclosed by the decision in Airkem
Sales and Service, et al.
v. Department of Mental Health, 8
Ct. Cl. 180 (1971). Pay stubs were introduced into evidence by the claimants
reflecting that their salaries were paid interchangeably from account numbers
4400-06 and 8044-04. There were insufficient funds in the former account at the
close of fiscal 1972-73 and fiscal 1973-74 to pay these claims, but there were
sufficient funds in the latter account from which these claims could have been
paid each year. Respondent contends that account number 8044-04 is funded by
federal monies and that at the close of the fiscal years in question, these
funds are not expired and returned to the general revenue account, but are
simply transferred to the same account for use during the following fiscal year.
Since these claims were submitted for decision, the Supreme Court of Appeals of
West Virginia has decided the case of State
ex rel. Crosier v. Callaghan W.Va . , 236 S.E. 2d 321 (1977), and we believe that case to be
dispositive of this particular issue. Crosier,
a mandamus action, involved a
successful attempt on the part of conservation officers of the Department of
Natural Resources to recover overtime wages. Among other defenses, the
respondent contended that Code 12-3-17 precluded him from complying with a writ
of mandamus, because there were insufficient funds in the current fiscal
appropriation to pay for overtime worked by con servation officers. Suffice it
to say that Code 12-3-17 was the basis for reaching this Court?s result in Airkem, supra.
Justice Harshbarger, speaking for the Court in Crosier, used
the following language in disposing of the Airkem defense:
?In this case, Code 12-3-17 and 21-5C-8 must be construed in pan materia. Code
12-3-17, subject to specified excep
W. VA.] REPORTS
STATE COURT OF CLAIMS 225
tions, prohibits any state officer from authorizing or paying any account
incurred during any fiscal year out of the appropriation for the following
year. Code 21-5C-8, however, expressly authorizes payment of back overtime
wages for two consecutive years immediately preceding an employee?s action for
unpaid wages. To the extent that retroactive liability for unpaid wages is
incurred against an employer, it is incurred at the time liability is
determined. Theoretically, an employer could fail to pay correct overtime wages
for many years; his liability for two years back payment, however, is not
legally incurred under Code 21-5C-8 until the employee prevails in an action to
recover the money due. Thus, while work may be performed by government
employees in the course of prior fiscal years, the government?s liability for
payment of back wages arises at the time they are found to be due.?
Thus, it seems clear that the balance in accounts 4400-06 and 8044-04 at the
close of fiscal years 1972-73 and 1973-74 is immaterial. If liability for
unpaid wages is determined in this proceeding at this time, it will be paid out
of the current personal services appropriation or from a special appropriation.
This was made clear by Justice Harshbarger in Crosier, supra, when he used
the following language:
?We also find unpersuasive respondent?s argument that mandamus does not lie
because there are insufficient funds in this year?s Department of Natural
Resources? personal services appropriation from which to pay petitioner?s
overtime compensation. Nor do we believe that it is petitioner?s responsibility
to demonstrate factually that there will be an adequate surplus in this year?s
fiscal appropriation to cover the payment.
Inherent in respondent?s argument is the premise that petitioner?s right to
back wages is contingent upon his finding a fund from which he can be paid and
then submitting a blueprint for payment to the Court that does not infringe
upon designated fiscal appropriations. This is not correct when, as here, an
employee is lawfully entitled to remuneration for services rendered. Where
there are un
226 REPORTS
STATE COURT OF CLAIMS [W. Va.
expended funds in any account which
may be lawfully charged with payment of this debt, whether it be from the
personal services appropriation or from the general fund in the state treasury,
then petitioner is entitled to mandamus directing payment of the amount due.?
During the periods from February 21, 1973, and April 23, 1973 (Leach claim),
through June 30, 1974, which we will hereafter refer to as the ?critical
period?, the minimum wage from February 21, 1973 to June 30, 1973 was $1.40 per
hour, and from July 1, 1973 to June 30, 1974, the minimum wage was $1.60 per
hour. See Code 21-5C-2. In respect to overtime, Code
21-5C-3 provides in part as follows:
?(a) On and after January one, one thousand nine hundred sixty-seven, no
employer shall employ any of his employees for a workweek longer than
forty-eight hours, unless such employee receives compensation for his
employment in excess of the hours above specified at a rate not less than one
and one-half times the regular rate at which he is employed.?
As indicated earier, the claimants during the critical periods were being paid
a monthly salary, and during the hearing it appeared that there was a dispute
as to the proper method of converting a monthly salary to an hourly rate. We
believe that the proper method of conversion should follow the following
principles. The evidence established that claimant Preston, during fiscal
1973-74, was being paid a monthly salary of $410.00. We are of the opinion that
this figure should be multiplied by 12 to establish an annual salary, or in
this case, $4,920.00. Dividing this figure by the 52 weeks in any given year
reflects a weekly salary of $94.62. Again dividing this figure by the 48-hour
work week, an hourly wage of $1.97 per hour is determined.
In addition to the above, Code 21-5C-4 provides as follows:
?In determining whether an employer is paying an employee wages and overtime
compensation as provided in sections two and three (21-5C-2 and 21-5C-3) of
this article, there shall be provided in accordance with the regulations which
shall be promulgated by the commission-
W. VA.] REPORTS
STATE COURT OF CLAIMS 227
er a credit of twenty-five cents an hour for an employee customarily receiving
gratuities, and a reasonable credit for board and lodging furnished to an
employee. The commissioner shall promulgate regulations relating to maximum
allowances to employers for room and board furnished to employees.?
Some discussion between counsel took place at the hearing concerning credits
that respondent should be allowed for meals and lodging furnished to
houseparents, and it was suggested that a credit of $1.00 per day for meals and
a credit of $26.00 per month for lodging should be allowed. By the same token,
if these credits are allowed for respondent, the claimants should be permitted
to add these items to their monthly salaries in order to determine their true hourly
rate of compensation. Claimant Preston?s salary thus would become $466.00 per
month, or an hourly rate of $2.24 per hour. The unfairness of allowing the
respondent a monthly credit for meals and lodging, and the corresponding
increase in hourly rate to the claimants, is due to the fact that we believe
each of the claimants handled his five-day-off periods differently. Claimant
Preston permanently remained in his dormitory room at Institute, while claimant
Petts, whose home was located in nearby Dunbar, obviously left Institute and
spent her five- day-off period at her own residence. For the most part, we
believe that increasing claimants? hourly rate and allowing the respondent a
credit for meals and lodging would amount to little more than a washout, and if
allowed on an equitable basis, would certainly create a bookkeeping nightmare.
We thus conclude and so hold that any allowances for meals and lodging shall
not be considered a credit to respondent or by the claimants in arriving at
their respective hourly rates.
The pivotal question for decision in these claims is what constitutes ?hours
worked? and what constitutes ?off duty? time as those terms are defined in the
statute and in the rules and regulations as promulgated by the Commissioner of
Labor. Workweek and hours worked are defined in Code 21-5C-1 as follows:
?(g) ?Workweek? means a regularly recurring period of one hundred sixty-eight
hours in the form of seven
228 REPORTS
STATE COURT OF CLAIMS [W. Va.
consecutive twenty-four-hour periods, need
not coincide with the calendar week, and may begin any day of the calendar week
and any hour of the day.
(h) ?Hours worked,? in determining for the purposes of sections two and three
(21-5C-2 and 21-5C-3) of this article, the hours for which an employee is
employed, there shall be excluded any time spent in changing clothes or washing
at the beginning or end of each workday, time spent in walking, riding or
traveling to and from the actual place of performance of the principal activity
or activities which such employee is employed to perform and activities which
are preliminary to or postliminary to said principal activity or activities,
subject to such exceptions as the commissioner may by rules and regulations
define.?
What is a houseparent and what are his or her duties? The job description of a
houseparent as defined by the Division of Vocational Rehabilitation states that
a houseparent is a person responsible for supervising students in a dormitory
or other living facility. Specific job duties are delineated, such as keeping
order in the meal lines during meals, supervising students in the dormitory for
cleanliness and care of their rooms, making bed check at night for absenteeism,
driving cars to transport students, driving an ambulance in an emergency,
reporting abnormal behavior to counselors, supervising grounds during late
evening hours, trying to create a home-like atmosphere in the dormitory, and
accompanying students on shopping trips. Claimants would expand this list with
such activities as providing students with fresh linens, seeing that students
are provided with cleaning supplies, meeting weekly with counselors, and
driving students to various hospitals, bus depots, and railroad stations; but,
by and large, these activities described by the claimants fall within the
specific job duties outlined by respondent.
As earlier indicated, during the critical period, houseparents would work for
nine straight days and then be off for a period of five days. Thus, it is
necessary for us to determine the number of ?hours worked? during the first
seven days of the nine straight working day periods. A typical houseparent?s
W. VA.]
REPORTS STATE COURT OF CLAIMS 229
day would commence at approximately
6:00 a.m., and after washing and dressing, they would report to the dining room
at 7:00 a.m. to monitor the breakfast line until 8:30 a.m., an undisputed hour
and one-half of work. At 11:45 a.m. until 12:45 p.m., they would again report
to the dining facility for an additional admitted one hour of work. From 4:45
p.m. to 5:45 p.m., they again would monitor in the dining area, again admitted
as an hour worked. From 6:00 p.m. until 10:00 p.m., the houseparents were
required to patrol the grounds or be in attendance with the students in the
recreation hall, an admitted four hours of work. Between 10:00 p.m. and 11:00
p.m., the houseparents conducted bed checks and supervised lights out.
Basically, the hours in dispute are the hours between breakfast (3 hours and 15
minutes), the hours between lunch and supper (4 hours) and the sleeping hours,
roughly between 11:00 p.m. and 6:00 a.m. Much testimony was introduced on
behalf of the claimants establishing that quite frequently the sleeping hours
of the houseparent would be interrupted by students returning to the center in
an intoxicated condition, students locking themselves out of their rooms when
going to the toilet, students becoming ill during the night, and a myriad of
other nocturnal disturbances. We believe that the issue of the compensability
of sleeping hours is answered by the regulations promulgated by the West
Virginia Department of Labor, specifically, Section 3.11 of Regulation III,
which reads as follows:
?(a) Where an employee is required to be on duty twenty-four hours or more, the
employer and employee may agree on bona fide meal periods and a bona fide
regularly scheduled sleeping period of not more than eight hours from hours
worked, provided adequate sleeping facilities are furnished by the employer and
the employee can usually enjoy an uninterrupted night?s sleep. Where no expressed or implied agreement to the
contrary is present, the eight hours of sleeping time and lunch periods
constitute hours worked.? (Emphasis
supplied.)
The record is entirely silent of either an expressed or an implied agreement
that sleeping hours and lunch periods are
230 REPORTS STATE
COURT OF CLAIMS [W. Va.
not to be considered hours worked, and we are thus constrained to hold that the
same are to be considered hours worked.
An abundance of testimony, undisputed by claimants, was introduced by
respondent establishing that it was the custom of respondent to excuse
claimants from duty upon their request so that they might attend to personal
matters. These requests, depending on the individual claimants, varied as to
frequency but would take place during the morning and afternoon hours. In an
attempt to be fair and equitable, in view of what may be considered an
artificial and unjustified posture in respect to sleeping time, we are of the
opinion that a one-half hour period in the morning and a like period in the
evening should not be considered hours worked in accordance with Code 21-5C-1
(h). We also believe that, of the total time (7 hours and 15 minutes) between
breakfast and lunch and lunch and dinner, at least five hours should not be
considered hours worked. Consequently, in each of the first seven days of the
nine straight days worked by claimants, we hold that they should be credited
with 18 hours worked. This results in a work week of 126 hours, 48 of which are
at the regular hourly rate and the remaining 78 hours at the rate of one and
one-half times the regular rate.
It probably should have been noted at the outset of this opinion that this
Court was not requested to arrive at monetary awards, but rather was requested
only to establish guidelines from which counsel for the parties could compute
any awards that might be due the various claimants. We have indicated our
opinion in respect to the initial seven straight days worked by the respective
claimants. The remaining two days of the nine-day schedule would, so to speak,
be worked at the regular rate of 18 hours per day and as a consequence,
claimants would not be entitled to overtime compensation.
Both claimant and respondent have access to records establishing during the
?critical period? the days worked and the days taken by the claimants as either
annual leave time or sick time, during which the claimants should be paid on a
48-hour- per-week basis computed on the hourly rate as set forth earlier
W. VA.] REPORTS
STATE COURT OF CLAIMS 231
in this opinion. Also to be included under the same reasoning is the two-week
leave period granted to claimant Preston, and denominated ?professional leave?
following his attack by a student during which claimant suffered personal
injuries in February of 1974.
The Court trusts that within the parameters laid down in this opinion, counsel
for the parties can agree in respect to additional compensation that may be due
and owing, if any, to each of the claimants. If that can be done and an
appropriate Stipulation be thereafter tendered, appropriate awards could then
be made by this Court.
IN THE COURT OF CLAIMS OF THE
STATE OF WEST VIRGINIA
ELVA B. PETTS,
Claimant,
(No. D-927d)
vs.
DIVISION OF VOCATIONAL REHABILITATION,
Respondent.
and
JAMES M. PRESTON,
Claimant,
(No. D-927i)
vs.
DIVISION OF VOCATIONAL REHABILITATION,
Respondent.
ORDER
Pursuant to an opinion of this Court issued on November 16, 1978, counsel for
the parties in the above-styled matters and other related claims have conferred
and computed the monetary amounts of additional compensation due and owing each
232 REPORTS STATE COURT OF CLAIMS [W. Va.
of the claimants and have filed a written Stipulation reflecting the amounts of
additional compensation due and owing each of said claimants, which Stipulation
is hereby ORDERED filed. Pursuant to this Court?s opinion herein referred to
and said Stipulation, awards are hereby made in favor of the following named
claimants in the following stated amounts.
James Preston $
5,888.75 D-927i
Ralph Keeling 4,593.88 D-927b
Paul Leach 2,394.65 0-927k
Elva Petts 3,985.42 D-927d
Rondal Fury 4,296.92 D-927f
Arthur White 5,217.75 D-927h
Gertrude Preston 5,771.49 D-927j
Harry Wells 3,423.80 D-927c
Ralph Parker 2,070.77 D-927a
Icy Mae DeWeese 202.50 D-927g
Ethel Engegno 4,989.22 D-927e
Dated this 5th day of January, 1979.
JOHN B. GARDEN
Presiding Judge
Opinion issued December 8, 1978
MARY JO HALL
vs.
BOARD OF REGENTS
(No. 0-1025)
Ross Maruka, Attorney at Law, for
claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The claimant, Mary Jo Hall, filed this claim against the respondent for
injuries received as a result of a fall when leaving a ladies? rest room at
Fairmont State College. The claimant had enrolled in the school in late August
or early
W. VA.]
REPORTS STATE COURT OF CLAIMS 233
September of 1973. On November 12,
1973, she went to a ladies? rest room on the second floor of the Administration
Building near her classroom. She had never used this rest room previously. The
elevation of the rest room floor was seven inches higher than the level of the
hallway floor. To enter the rest room, it was necessary to step up into the
room; when leaving, it was necessary to step down. There were no obstructions
on the floor of the rest room nor in the hail. Before entering the room, it was
necessary for the claimant to allow two girls to leave. She then proceeded to
enter, stepping up into the room. She stayed for a very short time and as she
was leaving, she opened the door, missed the step, and fell into the hail. The
claimant testified, ?I didn?t see the step when I opened the door and stepped
out; I didn?t see it.? The claimant received a severe fracture of the left arm
which required extensive medical treatment, surgery to the elbow, and
hospitalization. At the time of the accident, the claimant was carrying two
books in her left arm and a strap purse over her right shoulder. There were no
signs inside or outside the rest room warning of the step. The evidence
indicated that there had been a sign inside the rest room, but someone had
removed it.
The claimant was a student at Fairmont State College and
? ? students in a building are generally held to have the
status of invitees to whom the school owes a duty to make the premises
reasonably safe,? 34 A.L.R.3d 1179. The claimant, as a student, was an invitee
upon the premises of the school, and the duty of the school is limited to that
owed to an invitee.
Although we are most sympathetic toward the claimant for the injuries she
sustained, the absence of a sign in the rest room is not sufficient to
establish liability on the part of the respondent. Having stepped up when she
entered the rest room, she must, had she been exercising ordinary care, have
known that she would have to step down when she departed. The claimant
testified that she was carrying two books in her left arm, had a strap purse
over her shoulder, and did not see the step when she opened the door.
Considering the record in this case, the only conclusion is that the accident
was one which would not have occurred if
234 REPORTS STATE
COURT OF CLAIMS [W. Va.
the claimant had been exercising ordinary care when leaving the rest room. The
claimant?s lack of such care was contributory negligence on her part, if not
the sole proximate cause of the fall. Accordingly, this claim is disallowed.
Claim disallowed.
Opinion issued December 8, 1978
SILAS C. WIERSMA, M.D.
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-78-158)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the
claimant?s Notice of Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $1,120.00 for salary due him for medjcal
coverage at Barboursville State Hospital from June 13, 1977 through June 16, 1977
for 70 hours of work performed at $16.00 per hour.
In their Answer, respondents admit the validity of the claim and join in the
claimant?s request that it be honored. Respondents further allege that there
were sufficient monies remaining in the funds appropriated for that purpose at
the close of the fiscal year in question.
Based on the foregoing, an award in the above amount is hereby made.
Award of $1,120.00.
W. VA.j REPORTS
STATE COURT OF CLAIMS 235
Opinion issued January 9, 1979
ALLING & CORY
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-78-232)
No appearance by claimant.
Joseph C. Cometti, Assistant Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $4,401.40 for merchandise which was
ordered, shipped, and received, but for which no payment was made by
respondent.
In its Answer, the respondent admits the allegations of fact set forth in the
Notice of Claim, but further alleges that there were no funds remaining in the
respondent?s appropriation for fiscal year 1977-1978 from which the obligation
could have been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are of further opinion that an award cannot be made, based on our
decision in Airkem Sales and Service,
et al. v. Department of Mental Health, 8
Ct. Cl. 180 (1971).
Claim disallowed.
236 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued January 9, 1979
JAMES R. BANHART
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-119)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
On May 9, 1978, at approximately 7:30 a.m., the claimant was operating his 1978
Chevrolet half-ton truck at a speed of about 25 miles per hour in an easterly
direction on State Route 61 in Handley, West Virginia. The weather conditions
were clear, but it had been raining during the night. The road at the point of
the accident is a two-laned highway of blacktop construction. The claimant
testified that he was aware of potholes in the eastbound lane and had
consequently pulled left of center or into the westbound traffic, but an
approaching motorist caused him to return to the eastbound lane. There, he
struck a water-filled pothole, which, in his opinion, was about nine inches
deep. As a result, the claimant sustained damages to his truck amounting to
$190.76.
The respondent called as a witness on its behalf Jerry Easter, who testified
that he was employed by the respondent as a maintenance foreman working out of
Marmet, and that he was very familiar with the existence of the potholes to
which the claimant had referred. While Mr. Easter could not be specific as to
dates, he did indicate that employees of respondent had attempted, on several
occassions, to repair these holes through the use of both hot mix and cold mix.
He explained that the City of Handley was having a drainage problem, and that
as a result, water would accumulate and stand on Route 61. Easter explained
that this would cause both hot or cold mix to wash out and thus re-create the
former pothole.
The Court is of the opinion that the claimant has failed to establish
negligence on the part of the respondent. Respondent
W. VA.]
REPORTS STATE COURT OF CLAIMS 237
is not an insurer of those using the
highways of this State, but is under a duty only to use reasonable care to keep
the highways in a reasonably safe condition. The Court is of the opinion that the
respondent has discharged this duty in this particular case. For the reasons
assigned, this claim is disallowed.
Claim disallowed.
Opinion issued January 9, 1979
GLADYS BARFIELD
vs.
GOVERNOR?S OFFICE?
EMERGENCY FLOOD DISASTER RELIEF
(No. CC-78-173)
Claimant appeared in person.
Gregory Bailey, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Gladys Barfield, filed this claim in the amount
of $505.84 against the respondent for damage to a small stone
and brick house located on her land behind her residence at
305 East 3rd Avenue, Williamson, West Virginia. At the hearing the claim was
amended and the amount increased to
$700.16.
The first floor of the small house was used by the claimant for storage
purposes. On the second floor was an apartment which the claimant rented.
During the cleanup operation following the April 1977 flood in Williamson,
certain of the damaged houses and buildings were marked for demolition. The
claimant?s small house was not one designated to be removed.
The claimant testified that respondent?s employees started to demolish the
small house on her property, and before she succeeded in stopping the
demolition, the house was damaged. She was instructed to contact Paul Hicks,
who she was told
238 REPORTS STATE
COURT OF CLAIMS [W. Va.
was in charge of house removal. When she contacted Mr. Hicks in regard to the
damage to her house, Hicks told her ?it would be no problem?. No action was
taken by the respondent, and the claimant attempted to have the damage to the
house repaired.
Cancelled checks totalling $700.16 introduced by the claimant indicated that
she paid the following sums: $285.00 to Pete Hoyer for labor; $407.25 to J. D.
West & Son, Inc., for materials; and $7.91 to Maynard Paint and Hardware for
materials.
From the record, the Court is of the opinion that the claimant?s damage was
caused by the negligence of the respondent, and that the claimant is entitled
to recover the sums expended to repair her house in the amount of $700.16.
Award of $700.16.
Opinion issued January 9, 1979
BERNHARDT?S CLOTHING, INC.
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-78-203)
No appearance by claimant.
Joseph C. Cometti, Assistant
Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $1,986.80 for goods and services rendered
to respondent. Invoices were sent by the claimant to the West Virginia State
Penitentiary, but no payment was received.
In its Answer, respondent admits the allegations of fact set forth in the
Notice of Claim and states that there were sufficient funds on hand at the
close of the fiscal year from which the claim could have been paid.
W. VA.] REPORTS
STATE COURT OF CLAIMS 239
In view of the foregoing, this Court hereby makes an award to the claimant in
the amount of $1,986.80.
Award of $1,986.80.
Opinion issued January 9, 1979
THE C&P TELEPHONE COMPANY OF WEST
VIRGINIA
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-71)
David K. Hall, Attorney at Law, for claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $1,160.29, based upon
the following facts: On or about March 15, 1975, a landslide occurred in Wetzel
County, West Virginia, blocking off State Route 2 and damaging claimant?s
telephone cables. Claimant repaired the damage by the placement of temporary
cables.
On or about April 25, 1975, respondent negligently cut two of the temporary
cables during cleanup operations. Respondent is therefore liable to claimant
for the sum of $1,160.29, which is a fair and equitable estimate of the damage
sustained by the claimant.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $1,160.29.
240 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued January 9, 1979
THE CHESAPEAKE AND POTOMAC TELEPHONE
COMPANY OF WEST VIRGINIA
vs.
BOARD OF REGENTS
(No. CC-78-152)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
On or about June 16, 1976, respondent?s employees negligently failed to
ascertain the location of claimant?s underground cables while digging a trench
for the purpose of placing electric wires. As a result, claimant?s cables were
damaged in the amount of $144.34.
In its Answer, the respondent acknowledges the validity of the claim and joins
the claimant in its request for judgment in favor of the claimant.
Accordingly, this Court hereby makes award to the claimant in the above amount.
Award of $144.34.
Opinion issued January 9, 1979
STANLEY N. COSNER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-182)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for
W. VA.1 REPORTS
STATE COURT OF? CLAIMS 241
damages in the sum of $246.00, based
upon the following facts:
During the months of January, February, and March of 1978, heavy snow caused
the respondent to perform snow removal operations on County Route 15/1, also
known as Broad Hollow Road, in Mineral County. Route 15/1 is owned and
maintained by the respondent.
In the course of these snow removal operations, respondent was negligent, and
damaged claimant?s fencing on that part of his land adjacent to the road. Since
the respondent?s negligence was the proximate cause of the claimant?s damage,
the respondent is liable to the claimant for the sum of $246.00, which is a
fair and equitable estimate of the damage.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $246.00.
Opinion issued January 9, 1979
RICHARD L. CUNNINGHAM
vs.
DEPARTMENT OF PUBLIC SAFETY
(No. CC-78-258)
No appearance by claimant.
Ellen F. Warder, Attorney at Law, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $290.00 for overtime worked during the
month of June, 1978.
In its Answer, the respondent admits the validity of the claim, and further
states that there were sufficient funds remaining in the appropriation for the
Department of Public Safety for the fiscal year in question from which the
overtime could have been paid; however, said overtime request was not
242 REPORTS STATE
COURT OF CLAIMS [W. Va.
honored because it was not presented for payment within the fiscal year in
which the services were rendered and the liability incurred.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $290.00.
Opinion issued January 9, 1979
LILLIAN DALESSIO
vs.
BOARD OF REGENTS
(No. CC-78-88)
Claimant appeared in person.
Frank M. Ellison, Deputy Attorney General, for respondent. GARDEN, JUDGE:
During the academic year 1977-78, the claimant was a student at West Virginia
University and occupied a room in the Towers Dormitory. At the suggestion of
those in charge of the dormitory, the students locked their personal
possessions in the closets located in the dormitory rooms for security reasons
during the Christmas recess, which, during that academic year, was between
December 18. 1977 and January 4, 1978.
Upon claimant?s return to school at the conclusion of the Christmas recess, she
was advised that a pipe had burst and that water had quite possibly gotten into
the closet containing her personal possessions. An examination of the closet
revealed that water had in fact entered the closet and had ruined many of
claimant?s personal possessions, including a tennis racket and cover, a pair of
boots, a pair of shoes, a sleeping bag, stereo headphones, two stereo speakers,
and eight record albums. Claimant testified that these items were ruined, but
that prior to the water damage they had a combined fair market value of
$300.00.
W. VA.] REPORTS
STATE COURT OF CLAIMS 243
Franklin Glasscock, respondent?s maintenance supervisor, testified that he had
investigated the cause of the water damage and found that a hose running from a
faucet to an automatic washer had ruptured in the utility room located on the
floor above the claimant?s room. Mr. Glasscock testified that while his crew
periodically checked these hoses, it was his opinion that the hose had ruptured
as a result of ordinary wear.
The law on this subject is well stated in 49 Am. Jur. 2d ?881 Landlord and
Tenant (1970) as follows:
?While a landlord?s liability for water overflow damage from appliances in his
control may be based on his failure to keep an agreement or covenant to repair
or breach of a statutory duty to repair, the prevailing view is that he may be
found liable where negligence is shown in the construction, maintenance, or
repair of the appliances even though he is not under a contractual or statutory
duty to repair, although there is contrary authority.?
This Court is of the opinion that the legal relationship existing between the
respondent and the claimant is that of landlord and tenant. As early as the
decision of the Supreme Court of Appeals in Marsh v. Riley, 118 W.Va. 52,
188 S.E. 748 (1936), it was held that a landlord is under a duty to maintain
premises used in common by his tenants in a reasonably safe condition. The
utility room located above claimant?s room was certainly an area used in common
by many students, and this Court is of the opinion that respondent?s failure to
properly maintain the hose on this washer constituted negligence, and that such
negligence was the proximate cause of the damage to the claimant?s personal
property.
Award of $300.00.
244 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued January 9, 1979
DAVIS MEMORIAL HOSPITAL
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-78-230a-c)
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
In October of 1977, hospital services were rendered by claimant to three
inmates of respondent?s Huttonsville Correctional Center in the following
amounts: Charles Michael Adkins, $433.75; David Selby, $2,418.21; and Harry E.
Willis, $381.23, for a total of $3,233.19. Billing for these services was
submitted to Huttonsvjlle Correctional Center, but no payment was received by
the claimant.
Respondent, in its Answer, admits the allegations in the Notice of Claim, and
states further that there were sufficient funds in the appropriation for the
Department of Corrections for the fiscal year in question from which the claim
could have been paid.
Based on the foregoing facts, an award in the above amount is hereby made to
the claimant.
Award of $3,233.19.
W. VA.] REPORTS
STATE COURT OF CLAIMS 245
Opinion issued January 9, 1979
MERTON M. DELANCEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-91)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
On the morning of March 14, 1978, at approximately 7:30, the claimant was
operating his automobile in a westerly direction on U.S. 60 in the City of
Belle, West Virginia. The weather was clear but cloudy, and the road at the
point of the accident was a two-lane blacktop road. The pavement was wet and
covered with slush. The claimant testified that, as a car was approaching him
from the opposite direction, he veered slightly to the right to avoid hitting
the approaching motorist and hit a pothole which was obscured by water and
slush on the right- hand side of the road.
Claimant testified that the pothole was in the extreme north side of the road,
was at least 20 feet in length, and extended into the road anywhere from a foot
to a foot and one-half. Claimant was travelling at about 25 miles per hour, and
as a result of striking the hole, the two tires on the right-hand side of his
car were ruined. Claimant testified that he incurred a charge of $147.09 to
repair the damages to his car. Claimant admitted that he saw the pothole before
striking it, but he did not realize the severity or size of the hole.
Consistently, this Court has followed the decision of our Supreme Court of
Appeals in the case of Adkins v. Sims,
130 W.Va. 645, 46 S.E.2d 81 (1947),
where it was held that the State is neither an insurer nor a guarantor of the
safety of persons travelling on its highways. This Court has further held that
before the respondent can be held liable in a pothole case, there must be some
showing that respondent knew
246 REPORTS STATE
COURT OF CLAIMS [W. Va.
or should have known of the existence of the pothole. See Keith v. Department of Highways, 12 Ct. Cl. 199 (1978). The record is devoid of any
evidence to this effect, and, as a result, an award in favor of the claimant
cannot be made.
Claim disallowed.
Opinion issued January 9, 1979
EVANS LUMBER COMPANY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-109)
L. Leslie Evans, Vice-President of Evans Lumber Company, for claimant.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Evans Lumber Company, a corporation, filed its claim against the
respondent in the amount of $892.27 for the cost of gas lost by reason of a
3/4-inch break in its private gas line. The gas line was a 2-inch steel line
which furnished gas to claimant?s sawmill. The line was constructed by the
claimant approximately twenty years ago on claimant?s property along W.Va. Route
4 on Elk River in Kanawha County. The line was approximately six inches under
the ground.
L. Leslie Evans, Vice-President of the Company, testified that he thought
respondent?s snow plow had damaged the line because local people had said that
respondent?s trucks turned around off the highway at the point of the break in
the line. He further stated that there was salt on the ground at this point.
The break apparently occurred sometime between early February and March of
1978.
Claims agents testifying for the respondent stated that they found no evidence
of scraping in the area that might have
W. VA.]
REPORTS STATE COURT OF CLAIMS 247
been caused by a snow plow; that they
had no knowledge of whether respondent?s trucks turned around at the point of the
line break; and that the bare ground indicated the area was used by vehicles
for this purpose.
Mr. Evans, testifying for the claimant, stated, ?as to whether the State truck
did it, I can?t tell you. All I?m saying is that people who lived there say all
of them turn at this point.?
From the evidence presented in this claim, the Court is of the opinion that it
is not sufficient to find that the negligence of the respondent caused the
break in claimant?s gas line. Therefore, the claim is disallowed.
Claim disallowed.
Opinion issued January 9, 1979
JOSEPH LARRY GARRETT
vs.
DEPARTMENT OF PUBLIC SAFETY
(No. CC-78-237)
No appearance by claimant.
Ellen F. Warder, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $290.56 for overtime worked during the
month of June, 1978.
In its Answer, the respondent admits the validity of the claim, and further
states that there were sufficient funds remaining in the appropriation for the
Department of Public Safety for the fiscal year in question from which the
overtime could have been paid; however, said overtime request was not honored
because it was not presented for payment within the fiscal year in which the
services were rendered and the liability incurred.
248 REPORTS STATE
COURT OF CLAIMS [W. Va.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $290.56.
Opinion issued January 9, 1979
TERESA K. GILLISPIE and
JOHNNY WAYNE GILLISPIE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-153)
Claimants appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimants, who reside on West Virginia Route 214 at Alum Creek, seek
recovery of $99.13, such sum being the cost of repair of damage to the gas tank
of their automobile. Teresa K. Gillispie testified that the respondent graded
the road on June 12, 1978, and that at about 7:00 a.m. on June 13, 1978, her
husband, while backing their car into their driveway at a point near the road,
struck a large rock which had been knocked to that location by the grader and
left there. No evidence was offered on behalf of the respondent. The evidence
impels the Court to conclude that the accident was caused by negligence on the
part of the respondent without contributory negligence on the part of the
claimants. Accordingly, an award in the sum of $99.13 is hereby made.
Award of $99.13.
W. VA.]
REPORTS STATE COURT OF CLAIMS 249
Opinion issued January 9, 1979
LARRY A. GIOLITTO
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-205)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
GARDEN, JUDGE:
During the late afternoon of July 10, 1978, a warm and sunny day when the roads
were dry, the claimant was proceeding from Cedar Grove to Belle in his 1968
Nova automobile. Although the record is not too clear, he was proceeding up a
two-lane road in order to obtain access to Route 60, a four- lane highway,
where he intended to turn left and then proceed west on Route 60 to Belle. He
had kept to the extreme right of the access road in order that he would not
impede traffic which might be turning onto the access road from Route 60. He
had come to a stop in obedience to a stop sign, and, seeing that traffic was
clear, he then proceeded at a speed of three to four miles per hour when his
right front wheel struck a pothole. The claimant described this hole as being
round with a diameter of some 12 inches and from 8 to 11 inches in depth.
The claimant quite candidly admitted that he was aware of the existence of this
hole, but insisted that he was forced to drive his car in its vicinity to avoid
other motorists who might be turning onto the access road from Route 60. In
addition to extensive damage to the right front tire, the front end of the car
was knocked out of alignment, the coil spring was broken, and the ball joint
was knocked out. Claimant suffered a fracture of his right thumb.
This particular pothole was not located in Route 60, but apparently was near
the right-hand or easterly edge of the access road. No evidence was introduced
to prove knowledge, either actual or constructive, that respondent was aware of
the
250 REPORTS STATE
COURT OF CLAIMS [W. Va.
existence of this hole. In addition, the claimant?s admission of his knowledge
of the existence of this hole leads this Court to the inescapable conclusion
that the claimant?s own negligence was the proximate cause of the accident and
the ensuing damages and personal injury.
Claim disallowed.
Opinion issued January 9, 1979
DOUGLAS HANEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-226)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $309.50, based upon the
following facts:
During snow removal operations in the winter of 1977-1978, respondent?s crews
negligently damaged certain portions of claimant?s fence on Dogtown Road in
Barbour County, West Virginia. Respondent is therefore liable to claimant for
the sum of $309.50, which is a fair and equitable estimate of the damage
sustained by the claimant.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $309.50.
W. VA.]
REPORTS STATE COURT OF CLAIMS 251
Opinion issued January 9, 1979
ROBERT V. HEVERLEY, JR.
& KATHLEEN HEVERLEY, D/B/A
FRANCES SHOPPE, INC.
vs.
DEPARTMENT OF LABOR
(No. CC-77-81)
Paul Hull, Attorney at Law, for claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent.
WALLACE, JUDGE:
This claim, in the amount of $85,000.00, was filed against the respondent by
Robert V. Heverley, Jr., Kathleen Heverley, and Frances Shoppe, Inc., the
Heverleys being the stockholders and, as such, the owners of the business.
It was alleged that the respondent interfered with a closing- out sale of the
Frances Shoppe, Inc. by threatening prosecution for law violations and refusing
to renew the sale license, which resulted in loss of sales and the illness of
one of the claimants.
The Frances Shoppe, Inc. was a ladies? ready-to-wear apparel store operated by
the Heverleys at 126 Adams Street in Fairmont, West Virginia. By letter dated
February 23, 1976, the landlord gave written notice to vacate the premises
effective April 30, 1976. Efforts to obtain a new lease were not successful.
However, after the premises were sold, the claimants were able to obtain from
the new owners a one-month lease of the premises at twice the previous rental.
It was then decided to close the business. Max Caplan, a professional in
conducting closing-out sales, was employed to conduct such a sale. Mr. Caplan
testified that he always advised his clients of the legal requirements
necessary to conduct such a sale. He advised Mr. Heverley that it was necessary
to obtain a license from the respondent, which necessitated the furnishing of a
bond, a complete inventory of items to be sold, and a fee of $50.00.
252 REPORTS
STATE COURT OF CLAIMS [W. Va.
A copy of the executed license
application introduced as Claimants? Exhibit No. 3 lists the same requirements
as testified to by Mr. Caplan, and further, that bond shall be furnished in
accordance with Chapter 47, Article 11 B, Section 9 of the Code of West
Virginia. The application form provided spaces to be checked for the type of
sale to be conducted. The space provided for ?fire sale? was checked on the
application filed by the claimants.
In an effort to obtain a bond, Mr. Heverley testified that he made inquiry of
his attorney, the bank, and insurance agent about the bond requirements. He
stated that he did not show them the application form. He sent in the license
application with the $50.00 fee and an inventory of the items to be sold.
A fire sale license was issued effective April 10, 1976, and terminating on May
10, 1976. Mr. Heverley testified that he changed the license from a ?fire sale?
by adding the word ?closing-out sale?. The sale commenced April 10, 1976.
Mack Combs, Assistant Director of the Consumer?s Protection Division of the
Department of Labor, testified that during the sale, a complaint was received
from Ralph Garrison of the Fairmont Businessmen?s Association about the
possibility of some goods being brought into the Frances Shoppe for resale
during the sale. Fred Cavallers, an inspector for the respondent, was
instructed to investigate Mr. Garrison?s complaint, determine what type of sale
was being conducted, and why no bond had been furnished. Cavallers made his
investigation and reported that some old swimsuits, found in a storage box,
were added to the items being sold; that the sale was a going- out-of-business
sale, and that there was no bond. He requested that a bond form be sent to the
claimants.
Mr. Combs subsequently investigated the sale, and Mr. Heverley inquired about a
license renewal to continue the sale beyond May 10, 1976. Mr. Combs testified
that he advised Heverley that he didn?t believe the department could issue a
renewal of a license for a fire sale to be used for a closing-out sale, and
further, no bond had been furnished. He also stated that he advised Mr.
Heverley of the penalty for violating the requirements of the law for the
conduct of the sale. The last
W. VA.)
REPORTS STATE COURT OF CLAIMS 253
day Combs was on the premises was
between the 3rd and 5th of May. He stated that his superior, Mr. Griffith,
advised him to allow the sale to continue until May 10, 1976, without the bond,
since the license period had practically expired.
No bond was ever furnished, and no renewal application was filed.
From the record, it is the opinion of the Court that the claimants did not
comply with the legal requirements for conducting the sale, and further, that
the record does not establish improper conduct toward the claimants on the part
of the agents and employees of the respondent. Accordingly, the claim is
disallowed.
Claim disallowed.
Opinion issued January 9, 1979
HARRY GLENN LUCAS, JR.
vs.
DEPARTMENT OF PUBLIC SAFETY
(No. CC-78-253)
No appearance by claimant.
Ellen F. Warder, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $283.52 for overtime worked during the
month of June, 1978.
In its Answer, the respondent admits the validity of the claim, and further
states that there were sufficient funds remaining in the appropriation for the
Department of Public Safety for the fiscal year in question from which the
overtime could have been paid; however, said overtime request was not honored
because it was not presented for payment within the fiscal year in which the
services were rendered and the liability incurred.
254 REPORTS STATE
COURT OF CLAIMS [W. Va.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $283.52.
Opinion issued January 9, 1979
LOWELL J. MAXEY
vs.
DEPARTMENT OF PUBLIC SAFETY
(No. CC-78-238)
No appearance by claimant.
Ellen F. Warder, Attorney at Law, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $265.80 for overtime worked during the
month of June, 1978.
In its Answer, the respondent admits the validity of the claim, but declares
that the claimant is entitled to receive the amount of $259.20 under the laws
of the State of West Virginia and not $265.80 as set forth in the Notice of
Claim.
Respondent further states that there were sufficient funds remaining in the
appropriation for the Department of Public Safety for the fiscal year in
question from which the overtime could have been paid; however, said overtime
request was not honored because it was not presented for payment within the
fiscal year in which the services were rendered and the liability incurred.
Based on the foregoing facts, an award in the amount of $259.20 is hereby made
to the claimant.
Award of $259.20.
W. VA.] REPOITS
STATE COURT OF CLAIMS 255
Opinion issued January 9, 1979
PATRICK PLAZA DODGE, INC.
vs.
TREASURER?S OFFICE
(No. CC-78-211)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $142.50 for repair work performed by its
service shop. Respondent had refused payment because the Treasurer?s Office was
presented with copies of the bill instead of the original bill, as is required.
In its
Answer, respondent admits that the claim
is a legitimate one, and further states that there were sufficient funds
remaining in the appropriation at the close of the fiscal year in question from
which the claim could have been satisfied.
Based on the foregoing, an award in the above amount is hereby made.
Award of $142.50.
Opinion issued January 9, 1979
RICK?S AMBULANCE
vs.
DEPARTMENT OF WELFARE
(No. CC-77-213)
Claimant appeared in person.
Frank M. Ellison, Deputy Attorney General, for respondent. RULEY, JUDGE:
Richard Saunders, doing business as Rick?s Ambulance Service, filed this claim
in the sum of $898.75 for twenty-one rural
256 REPORTS STATE
COURT OF CLAIMS [W. Va.
ambulance service calls made from his place of business at Elkview in Kanawha
County between February 21 and August 30, 1977, all of which allegedly were
authorized by the respondent. In connection with most of the calls, the
respondent had paid the claimant for the ?trip in? (from the patient?s home to
the hospital) but had declined to pay for the ?trip out? (the return trip from
the hospital to the patient?s home). In most, if not all, of those instances,
the patient was treated at the emergency room for some ailment or infirmity and
then released.
It appears that the claim is controlled by the respondent?s regulations, which,
among other items, provided:
?. .
. Ambulance service is covered when ***: 1) The patient?s physical condition requires ambulance
service as certified by the attending
physician; i. e., the use of any other
method of transportation is medically contraindicated and is not for the
patient?s convenience.?
There is no evidence of any required certification, nor does it appear that any
other method of transportation was medically contraindicated as to the calls to
which this claim relates. Accordingly, the claim must be denied.
Claim disallowed.
Opinion issued January 9, 1979
LARRY ROTON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-147)
Claimant, Larry Roton, appeared in person.
Henry Haste bacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, a resident of Falling Rock, West Virginia, in order to reach his
place of employment, was in the habit of
W. VA.] REPORTS
STATE COURT OF CLAIMS 257
using a road known interchangeably as Reamer Road and Falling Rock Hollow
(actually designated Secondary Route 63/3). The claimant testified that the
road was maintained by respondent, and this testimony was not denied by the
respondent.
At some point on this road, a bridge had been erected across a creek. Several
weeks prior to May 10, 1978, respondent?s crews were making repairs to the road
and attempted to cross this bridge with a dump truck loaded with gravel. As a
result, the bridge collapsed, and the dump truck was retrieved by respondent
through the use of a bulldozer. No attempt was made by respondent to repair the
bridge or provide any alternative means of crossing the creek. On May 10, 1978,
the claimant, having no other route to follow to get to his place of
employment, attempted to ford the creek in the area of the destroyed bridge. He
was operating his 1974 Dodge Ram Charger, a four-wheel drive vehicle, but in
fording the creek, he struck a large rock, causing considerable damage to the
lower portions of his vehicle. An estimate of repairs from Patrick Plaza Dodge
in the amount of $177.73 was presented.
A similar factual situation was presented to this Court in the claim of Shafer v. Department of Highways, issued on October 31, 1975. In that claim, the late
Judge Henry Lakin Ducker made an award in favor of the claimant, basing the
same on the respondent?s failure to repair the bridge or to provide a
reasonable alternative route. Adhering to the doctrine of stare decisis, this
Court likewise makes an award in favor of the claimant in the amount of
$177.73.
Award of $177.73.
258 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued January 9, 1979
HAYES STANLEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?77-145)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
GARDEN, JUDGE:
During the evening of June 3, 1977, the claimant?s son, Bruce Erwin Stanley,
was driving his father?s 1977 Chevrolet Monza through the Dingess Tunnel in
Mingo County when he struck a rather large hole located approximately 45 feet
from the end of the tunnel. As a result, young Stanley lost control of the
vehicle, and as he emerged from the tunnel, he struck some brush that had been
placed on the side of the road but close to the travelled portion of the road.
According to the claimant, the brush further caused him to lose control of the
automobile, and it then proceeded over an embankment, striking several trees.
The car was rendered a total loss, and the claimant?s insurance carrier paid
him the sum of $4,750.00. Claimant seeks an award in the amount of $462.00,
being the difference between the amount paid by the insurance carrier and the
amount which the claimant believes to be the true value of the automobile.
Young Stanley testified that the length of the tunnel was between a half mile
and three quarters of a mile, that the tunnel was narrow and would only
accommodate one lane of traffic, and that no artificial lighting was provided.
Young Stanley also testified that he was travelling at a speed of 35 miles per
hour and that he was quite familiar with the tunnel because he passed through
it on his way to and from school. He further admitted that he was well aware of
the existence of the hole, but simply had forgotten about it on the evening of
the accident.
The claimant and owner of the car, Hayes Stanley, testified that he was the
Postmaster at Breeden, West Virginia, and
W. VA.) REPORTS
STATE COURT OF? CLAIMS 259
that, like his son, he was aware of the existence of the hole in Dingess
Tunnel. He stated that he and other postmasters in the area had registered
complaints at respondent?s garage in Williamson, and that in April of 1977,
several months before the subject accident, he personally conferred with
respondent?s assistant supervisor, Willard Sturgill, and was told by the latter
that they were going to get to it. Needless to say, no repairs were made to the
large hole prior to June 3, 1977.
The Court is of the opinion that the respondent was on notice of this defect in
the tunnel, and that its failure to effect repairs constituted negligence. On
the other hand, the Court feels that young Stanley, in driving at a speed of 35
miles per hour through a one-lane, unlighted tunnel with knowledge of this
rather large hole, was likewise guilty of negligence which proximately
contributed to the accident. For this reason, we must decline to make an award.
Claim disallowed.
Opinion issued January 9, 1979
CONNIE ANN STONE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-177)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
GARDEN, JUDGE:
At approximately 7:30 p.m. on April 22, 1978, the claimant was operating her
1977 Mustang automobile in a southerly direction on Route 119, on a section of
that road commonly referred to as the Mileground. The road at the point of the
accident is two-laned, of asphalt construction, and about one and one-half
miles from the northern corporate limits of the City of Moundsville. The claimant,
a resident of Morgantown, West Virginia, was returning home after having
attended a wedding in Latrobe, Pennsylvania. She was travelling at 35 miles per
hour in a 40-mile-per-hour zone. There were no cars preceeding her nor
following her, but two cars were approaching
260 REPORTS
STATE COURT OF CLAIMS [W. Va.
from the opposite direction as she
suddenly struck a large pothole on the right-hand side of the southbound lane,
causing damage in the amount of $176.73 to her automobile.
No testimony was introduced in respect to the dimensions of the pothole, but
two photographs, taken the day following the accident, were introduced into
evidence from which it could easily be determined that the pothole was quite
wide, extremely long, and very deep. Claimant immediately reported the incident
to the Morgantown police, and their report, which was also introduced into
evidence, reflected that the claimant had ?hit a very deep pothole . . . . While changing tire, three other cars also lost tires
in same manner within a half hour. This is an unavoidable hazard.? The police
reported this road hazard to an agent of respondent that night, but the pothole
was not repaired until some three weeks later.
The claimant testified that she was unaware of the existence of this particular
pothole, and did not see it before striking it. This Court cannot conclude that
the claimant was guilty of contributory negligence in failing to observe and
avoid striking the pothole. Conceivably, her lookout was impaired by the two cars
that were approaching her from the opposite direction. Certainly her speed,
which was well within the posted limit, was not a factor.
While respondent is not an insurer of the safety of motorists using the
highways of this State, it does have the affirmative duty of using reasonable
care to keep the same in a reasonably safe condition. Also, while there was no
direct evidence that respondent had actual knowledge of the existence of this
defect, this Court is of the opinion that it certainly should have been on
notice of this defect. Route 119 is one of the main arteries for motorists
travelling to Morgantown from the north. Furthermore, the size of the pothole,
as reflected in the photographs, graphically demonstrates its presence for a
long period of time prior to the date of the accident. Being of the opinion
that the record as a whole clearly establishes negligence on the part of the
respondent, this Court hereby makes an award in favor of the claimant in the
amount of $176.73.
Award of $176.73.
W. VA.] REPORTS
STATE COURT OF CLAIMS 261
Opinion issued January 9, 1979
CHARLES E. AND MARY P. TAYLOR
Vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-206)
No appearance by claimants.
Nancy J. A 11ff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that the claimants, Charles E. and Mary
P. Taylor, are the owners of real property located on West Virginia Route 3,
near Tornado, in Kanawha County, West Virginia; that the respondent failed to
maintain a ditch adjacent to said Route 3 in front of claimants? property; that
on August 30, 1978, after a rainfall, claimants? home and contents were damaged
by water and mud; and that this damage was proximately caused by the
rspondent?s negligence; the Court finds the respondent liable, and an award of
$1,566.75 is hereby made to the claimants.
Award of $1,566.75.
Opinion issued January
9, 1979
RUTH ANN TOPPINGS
Vs.
DEPARTMENT OF HIGHWAYS
(No. D-1007)
Bill Wertman and Bob
Golchesky, Attorneys at Law, for
claimant.
Nancy J. A 11ff, Attorney at Law, for respondent. RULEY, JUDGE:
In 1975, Walter Toppings filed this claim in the sum of $50,000.00 for damages
to land allegedly sustained as a result of diversion of a natural drain course
by the respondent in
262 REPORTS STATE
COURT OF CLAIMS [W. Va.
1973. At the trial, it appeared that Mr. Toppings acquired the subject property
in 1971 but conveyed it to his daughter, Ruth Ann Toppings, in 1974.
Accordingly, Ruth Ann Toppings should be substituted as the claimant.
The subject property, located near Chapmanville in Logan County, West Virginia,
is approximately eighty-seven feet wide and one hundred thirty feet deep lying
between the Guyandotte River on the west and a railroad track and W.Va. Route
10 on its east. It is adjoined on one side by a tract owned by Narlis Watts. A
dwelling house occupied by Mr. Toppings is located upon the Toppings property.
In the vicinity of the common line between the two properties, there is a
ravine or gully estimated to be from thirty to forty-five feet deep at a point
opposite the Toppings home. That gully which is of varying width provides a
natural drain course and empties into the river. After Mr. Toppings acquired
the property, he placed eighteen automobile bodies in the gully for the purpose
of inhibiting erosion, and, in 1973, at his request and apparently as an
accommodation to him, the respondent covered those vehicles with somewhere
between ten and twenty truck loads of dirt and rock. In order to do that, the
respondent?s trucks had to travel over the Watts property inasmuch as it was
impossible to reach the vehicles from the Toppings property. While the vehicles
did not totally impede the flow of surface water through the area they
occupied, the fill which was made upon and over them, did, and, as a result,
the main channel of the gully was moved closer to the side upon which the
Toppings? dwelling house was located. It appears that this could have caused
acceleration of erosion on that side of the gully near the house. In fact, in
April, 1977, the slide or erosion extended to a point only three feet from the
house. However, some doubt was injected into the matter of causation by the
following answer to the following question during the crossexamination of
Patrick Luke, a district conservationist employed by the USDA Soil Conservation
Service (the only witness who testified on that issue):
?Q. If this area had been left as a natural drain without
any human intervention at all, would this area be eroding?
W.VA.] REPORTS
STATE COURT OF CLAIMS 263
A. Yes. I can?t say that it would be eroding at a lesser rate or at a greater
rate. That?s hard to say.?
Leaving that doubt aside and assuming that the Court should conclude that the
respondent caused acceleration of erosion near the claimant?s home, the Court
then would face the dilemma of trying to determine what part of the erosion was
caused by the rsepondent without any evidence at all on the matter. That would
require the Court to engage in pure speculation and, of course, it cannot do
that.
The evidence, or lack of it, on the subject of damages is comparable to that
respecting causation. The Court is sympathetic to the claimant?s plight but it
cannot substitute its imagination, individual or collective, as to matters for
which the law wisely requires evidence. Sheppard
v. Department of Highways, 9 Ct. Cl.
142 (1972). Accordingly, this claim must be denied.
Claim disallowed.
Opinion issued January 9, 1979
ALBERT K. TYRE
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-78-178)
Claimant appeared in person.
Gregory Bailey, Assistant Attorney General, for respondent.
GARDEN, JUDGE:
The claimant in this claim resides in Randolph County, his home being located
about one mile southwest of the Huttonsyule Correctional Center. On the evening
of June 22, 1978, two inmates walked away from the Correctional Center and
stole the claimant?s 1969 Chevrolet half-ton pickup truck. The truck had been
parked in a meadow near the claimant?s home, and while the keys had not been
left in the truck, the inmates pulled the switch wires out and burned the
switch open. The
264 REPORTS
STATE COURT OF CLAIMS [W. Va.
truck was later recovered when the
inmates were recaptured, but not until the truck had sustained damage in the
amount of $150.00. The record disclosed that these two inmates had simply
walked away from the correctional institution and thereafter commandeered the
claimant?s truck. Claimant testified that, while the security arrangements are
now better at Huttonsville, at the time of this particular incident, the
facility was not even fenced. At the hearing, the claimant made the remark that
the State had never paid a claim for damage inflicted by escaped prisoners, and
for that reason we deem it important to examine the prior decisions of this
Court involving this issue.
In the claim of Miller v. State Board
of Control, 1 Ct. Cl. 97 (1942), a
sixteen-year-old delinquent had been sentenced to the industrial school at
Pruntytown, but because it was determined that the infant was afflicted with
syphilis, he was sent to a hospital in Fairmont for treatment before being
turned over to the authorities at Pruntytown. While being treated at the
hospital, he escaped, stole the claimant?s car, and damaged it. While the Court
denied a recovery, it indicated quite strongly that the reason for the denial
was that the sixteen- year-old had not been fully placed in the custody of the
official of Pruntytown. In Dodrill v.
State Road Commission, 1 Ct. Cl. 251
(1942), liability was again denied, but a reading of that opinion, written by
the Honorable Charles J. Schuck, clearly reflects that liability was denied
principally because the claimant twice failed to appear and present testimony
of his claim.
Again, in Lamberv v. Board of Control,
2 Ct. Cl. 198 (1943), the Court
declined to make an award when an inmate escaped from Pruntytown and in turn
stole the claimant?s car and damaged it. The Court found that the method of
escape was so unique that liability could not be imposed, but did make the
following comment on page 202 of the opinion:
We do not subscribe to the rule that the state department involved can at all
times escape liability, but do insist that lack of reasonable care must be
shown in each instance and that the negligence must be so extreme as to be
directly the cause for the commission of the tort and
W. VA.] REPORTS
STATE COURT OF CLAIMS 265
thus place the responsibility squarely on the shoulders of
the authorities involved.?
In the claim of Johnson v. State Board
of Control, 2 Ct. Cl. 203 (1943),
an award was made when six prisoners from the penitentiary, who were working on
a road gang near Keyser, West Virginia, burglarized a store owned by the
claimant. There were a total of 170 prisoners in the camp who were being
attended by 20 guards, and the Court concluded that with such a number of
guards, the escape could not have been effected, absent negligence. An award
was also niade in the claim of Fl1etcher
v. State Board of Control, 2 Ct. Cl.
280 (1944), where an inmate who had escaped on three prior occasions escaped
for the fourth time, stole the claimant?s car, and subsequently damaged it.
Distinguishing the claim from Lambert,
supra, Judge Schuck held that the
respondent, in failing to provide extra restraint in respect to an individual with
three previous escapes, was negligent. On the other hand, an award was denied
by the Court in Worrell v. State Road
Commission, 2 Ct. Cl. 342 (1944), by
reason of the failure of the claimant to prove by a preponderance of the
evidence that convicts from the penitentiary had in fact stolen certain items
of personal property from the claimant.
Moving on in this review of former cases involving this issue, we find that the
Court in Arrick v. State Board of
Control, 3 Ct. Cl. 141 (1945) and
again in Parsons v. State Board of
Control, 3 Ct. Cl. 147 (1946), refused
to make awards by reason of the failure on the part of the respective claimants
to fully establish negligence on the part of the State agency, and that such
negligence contributed to and made possible the escape of the respective
inmates.
An award of $3,500.00 was made in the claim of Davis Trust Company v. State Board of Control, 3 Ct. Cl. 188 (1946), resulting from the rape and
murder of claimant?s decedent. In that claim, one Lucy Ward, who resided on a
farm near the medium security prison at Huttonsville, was raped and murdered on
January 20, 1945, by one James Chambers, who had originally been convicted of a
murder in 1935, with a recommendation of mercy, and sentenced to life
imprisonment in the State penitentiary in Moundsville. The opinion is silent as
266 REPORTS STATE
COURT OF CLAIMS [W.Va.
to why Chambers was later transferred to Huttonsville where, at that time,
inmates were treated almost as members of a country club. Suffice it to say
that on the evening of the atrocity, Chambers left the Huttonsville facility,
committed his dastardly crime, and then returned to the prison without the
officials even being aware of the fact that he had been absent. In our opinion,
an award was never more justified. The payment of this award was later
successfully contested and reference is hereby made to State ex ret. Davis Trust Company v. Sims Auditor, 130 W.Va. 623, 46 S.E. 2d 90 (1947).
Awards in favor of claimants were made by the Court in Got dsboro v. West Virginia Board of Control, 5 Ct. Cl. 187 (1950) and in Lewis v. Department of Public Institutions, 7 Ct. Cl. 192 (1968), and an award was denied in State Farm Mutual Automobile Insurance Company v.
Department of Public Institutions, 7
Ct. Cl. 146 (1968), but from a reading of these last three opinions and the
other opinions cited herein, it is apparent that each claim has been and should
be decided on its own particular facts.
In this particular claim, no testimony was introduced by respondent in defense
of the claim. The record as submitted for decision simply reveals that two
unattended and unsupervised inmates walked away from the correctional
institution and stole and damaged the claimant?s truck. To deny recovery to
this claimant would simply amount to imposing a penalty upon a citizen of this
State for living near a correctional institution. Such a ruling would be
illogical and without justification.
The claimant testified that he purchased the necessary parts for the repair of
his truck in a total amount of $45.10. He further testified that he did the
repair work in seven hours and that he was of the opinion that his time was
worth $9.00 per hour. He is also requesting an allowance of $10.00 per day for
the period the truck was inoperable, a period which he claims extended from
June 22, 1978 to August 25, 1978. We feel that this period is unreasonably long
and evidences no attempt on the part of claimant to minimize his damages. We
would reduce the allowable down-time to seven days. Based on the foregoing,
W. VA.] REPORTS
STATE COURT OF CLAIMS 267
an award is made in favor of claimant in the amount of
$178.10.
Award of $178.10.
Opinion issued January 9, 1979
ARTHUR VANNORT
vs.
DEPARTMENT OF VETERANS? AFFAIRS
AND ADJUTANT GENERAL
(No. CC-77-218)
Frank L. Abbott, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy
Attorney General, for respondents.
WALLACE, JUDGE:
This claim was filed by the claimant against the respondents for compensation
for injuries alleged to have been received while the claimant was on riot duty
with the West Virginia National Guard at Weston, West Virginia, in December of
1910. The claimant alleges in his claim that he suffered a skull fracture and
subsequently lost the hearing in his right ear and hecariie sensitive to heat
and sunlight. He also alleged that he requested a disability discharge from the
National Guard. Filed with his claim was a copy of his discharge which
indicates that he was discharged on June 30, 1916, for failure to take the federal
oath.
The respondents filed a motion to dismiss the claim on the grounds that this
Court lacks jurisdiction under the provisions of West Virginia Code 14-2-14,
and further, that the claim is barred by the statute of limitations.
The claimant?s brief in opposition to the motion to dismiss contends that a
request for a disability discharge is tantamount to a claim for a disability
injury. West Virginia Code 15-1B-18 is cited and provides: ?all claims arising
under this section shall be inquired into by a board of three officers . . ., to be appointed upon the application of the member
claiming to be
26 REPORTS STATE
COURT OF CLAIMS {W. Va.
so incapacitated, .
. . by the commanding officer of the
organization or unit to which such member is attached or assigned.?
The brief does not indicate that the claimant requested that a board be
convened under this statute to determine his eligibility for disability
benefits. Apparently, no action was taken by the claimant from the time of his
alleged injury in 1910 until this claim was filed before this Court.
West Virginia Code 14-2-14, pertaining to the jurisdiction of this Court,
provides: ?The jurisdiction of the Court shall not extend to any claim:
1. For loss, damage, or destruction of property or for injury or death incurred
by a member of the militia or national guard when in the service of the State.?
and West Virginia Code 14-2-21 further provides that this Court shall not take
jurisdiction of any claim that is barred by the statute of limitations under
pertinent provisions of the Code of West Virginia.
The claimant was on active duty with the West Virginia National Guard at the
time of the injury in 1910, and was later discharged from the Guard for failure
to take the federal oath. Since injury occurred while in the service of the
State with the National Guard, this claim is specifically excluded from the
jurisdiction of the Court under the provisions of West Virginia Code 14-2-14.
This Court is a court of limited jurisdiction and cannot entertain claims that
are specifically excluded by statutory law. Moore v. State Road Comm?n of West Virginia, 9
Ct. Cl. 148 (1972).
Even if this claim were not excluded from the jurisdiction of the Court by
statute, the Court would be bound nontheless, by express statutory law, to
apply the statute of limitations in all cases where the statute would be
applicable if the claim were against a private person, firm, or corporation.
West Virginia Code 14-2-21; Shered v.
Department of Highways, 9
Ct. Cl. 137 (1972).
For the reasons herein stated, the Court is of the opinion to and does sustain
the respondents? motion, and hereby dismisses the claim.
Claim dismissed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 269
Opinion issued January 9, 1979
TODD W. WARE and
TAYLOR PUBLISHING CO.
vs.
BOARD OF REGENTS
(No. CC-78-204)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $3,096.51, representing the balance due on
an agreement between the claimant and Potomac State College to publish the
latter?s yearbook. The books were delivered and accepted by the school, which
made payment of $1,277.60 to the claimant, leaving a balance of $3,096.51.
In its Answer, the respondent admits the allegations of fact set forth in the
Notice of Claim, and admits that there were sufficient funds on hand at the
close of the fiscal year from which this claim could have been paid.
In view of the foregoing, this Court hereby makes an award to the claimant in
the above-stated amount.
Award of $3,096.51.
270 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued January 9, 1979
JOHN M. WEBER
Vs.
BOARD OF REGENTS
(No. CC-77-229)
Edgar F. HeiskelV, III, Attorney at Law, for claimant.
Frank M. Ellison, Deputy Attorney General, for respondent. PER CURIAM:
The parties in this claim have filed a duly executed written stipulation to the
effect that the respondent is liable for damages in the amount of $3,400.00
resulting from the respondent?s breach of an employment contract with the
claimant.
Two notices of appointments (contracts) were entered into by the claimant, John
M. Weber, and the respondent, West Virginia University, to employ claimant as
Director of Transportation for West Virginia University; the first contract
covering the period of May 15, 1977 through June 30, 1977, and the second
covering a period of July 1, 1977 through June 30, 1978. Claimant?s salary was
$26,004.00 per year, payable in twelve monthly installments.
On May 19, 1977, claimant was informed by respondent that his position as Director
of Transportation would not be continued after June 30, 1977.
In the stipulation filed with the Court, the parties agee that the amount of
$3,400.00 is a just and proper sum to be paid in full settlement and compromise
of this claim.
Based on the foregoing facts, an award in the above amount is hereby made to
the claimant.
Award of $3,400.00.
W. VA.) REPORTS
STATE COURT OF CLAIMS 271
Opinion issued January 9, 1979
LORAINE WHITE & VELMA WHITE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-139)
No appearance by claimants.
Henry Haslebctcher, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation which
revealed the following facts.
Claimants? house is located beside Cost Avenue and a bridge connecting Cost
Avenue to West Virginia Route 20 in Stone- wood, West Virginia. Cost Avenue and
said bridge are a part of West Virginia Route 58, a highway owned and
maintained by the respondent.
As a result of the respondent?s negligent resurfacing activities and inadequate
drain design and maintenance of Cost Avenue and the bridge, excessive water
run-off occurred which damaged the claimants? home and landscape.
It is further stipulated by the parties that the sum of $1,000.- 00 is a fair
and equitable estimate of the damage sustained by the claimants.
Based on the foregoing, an award in the above amount is hereby made.
Award of $1,000.00.
272 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued January 11, 1979
CHARLESTON AREA MEDICAL CENTER, INC.
vs.
DEPARTMENT OF HEALTH
(No. CC-78-283)
Cynthia L. Turco, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $20,000.00 due under the terms of an
agreement entered into by the Charleston Area Medical Center (?CAMC?) and the
West Virginia Department of Mental Health, whereby The CAMC Children?s Diagnostic
Center, also known as the Early Childhood Diagnostic Center (the ?ECDC
Project?), was established.
By letter from the respondent, claimant was advised that the State of West
Virginia would reimburse CAMC in an amount not to exceed $20,000.00 for operating
losses incurred in connection with the operation of this project. In reliance
upon the assurances of the aforesaid letter, CAMC continued to operate the ECDC
Project. and sustained a net operating loss in the amount of $29,043.58. CAMC
submitted an Invoice for Deficit for payment to the Department of Mental
Health, but received no funds from the Department.
In its Answer, the respondent admits the allegations of fact set forth by the
claimant, and further states that there were not sufficient funds remaining in
the appropriation at the close of the fiscal year in question from which the
claim could have been paid.
While it appears that the claimant?s loss, to the extent of $20,000.00, in
equity and good conscience should be paid, the
W. VA.] REPORTS
STATE COURT OF CLAIMS 273
Court is precluded from making an
award in that sum by the doctrine of Airkem
Sales and Service, et at. v. Department of Mental Health, 8 Ct. Cl. 180 (1971).
Claim disallowed.
Opinion issued January 11, 1979
JACQUELYN B. EISENBERG, PARENT
AND NEXT FRIEND OF MARK HAROLD
EISENBERG, AN INFANT
vs.
BOARD OF REGENTS
(No. CC-76-143)
Ward D. Stone, Jr., Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondnt
GARDEN, JUDGE:
During the summer of 1975, the infant claimant, Mark Harold Eisenberg, was
attending the Fine Arts Camp at West Virginia University in Morgantown, and at
the time he was fourteen years of age. Previously, in 1974, he had attended the
three-week session of the camp, enjoyd it, and had thus returned the following
year. The evidence disclosed that Mark was an above-average violinist for his
age, having taken violin lessons since he was six years of age.
It was the custom to house the students attending the camp in the Towers
Dormitory, but the students would attend their musical pursuits at the
University?s Creative Arts Center, which is located some 2000 yards or more
from the Towers Dormitory. There is a road and sidewalk leading from the Towers
Dormitory to the Creative Arts Center, but apparently the distance is shorter
if the students, as was apparently their custom, proceeded along a dirt path in
an open field that separates the Towers Dormitory and the Creative Arts Center.
The infant claimant denied that he had ever been advised by anyone at the camp
that this path should not be used, but Donald Portnoy, Professor of Music at
the University and
274 REPORTS STATE
COURT OF CLAIMS [W. Va.
the Director of the Fine Arts Camp, and whose evidentiary deposition was
introduced into evidence, testified that all of the students during orientation
were instructed to use the sidewalk and not the dirt path through the open
field. In fact, through the deposition, a notice dated July 17, 1974, was
introduced into evidence which recommended that students should use the paved
route rather than the dirt path. Professor Portnoy testified that a copy of the
notice or bulletin was given to each student and that copies were posted on
each floor of the dormitories. While the notice introduced into evidence was
dated in 1974, Professor Portnoy stated that the same procedure was followed in
1975. In any event, the record is clear that the director and counselors at the
camp were fully aware that, in spite of the warning, the students were using
the dirt path instead of the paved sidewalk.
On the evening of July 17, 1975, at about 8: 15, Mark and several other
students were returning to the dormitory from an orchestra rehearsal at the
Creative Arts Center. They were using the dirt path in lieu of the paved
sidewalk. In attempting to pass other students who were walking more slowly
along the path, Mark walked some 5 to 10 feet off the path and suddenly fell
into a hole some 48 inches wide and 42 inches deep. As a result, he fractured
his right arm just above the wrist. The presence of this rather large hole was
obscured by the existence of long grass around it. Mark?s recovery was
uneventful, and his medical expenses were less than $100.00. He remained at the
camp, but because his arm was in a cast, he could not actively play his violin.
The most serious consequence of the injury, however, was the fact that Mark
lost interest in playing the violin, and at the time of the hearing, some two
years after the accident, he had not resumed his lessons.
Cases in respect to liability of public schools and institutions of higher
learning are collected in an excellent annotation appearing in 37 ALR 3d 738.
Generally, the cases hold that the institution is under a duty of ordinary or
reasonable care with regard to the condition of its grounds to see that they
are maintained in a reasonably safe condition. We do not feel that the evidence
justifies a finding of contributory negligence on the part of this 14-year-old
claimant. On the other hand, we
W. VA.] REPORTS
STATE COURT OF CLAIMS 275
believe that the respondent, being aware that students were using this area,
was under a duty to see that the same was maintained in a reasonably safe
condition. We further believe that the respondent failed in this duty and was
guilty of actionable negligence. To attempt to award damages for Mark?s loss of
interest in the playing of the violin would involve speculation on our part,
which we refuse to do. The claimant testified at the hearing that his arm had
completely healed and was as good as new, but to compensate him for his pain,
suffering, and nominal medical expenses, we do hereby make an award of
$1,500.00.
Award of $1,500.00.
Opinion issued January 11, 1979
HENRY ELDEN & ASSOCIATES
vs.
DEPARTMENT OF FINANCE AND
ADMINISTRATION and DEPARTMENT OF HEALTH
(No. CC-78-269)
Michael T. Chaney, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondents.
PER CURIAM:
By written contract dated June 28, 1976, which incorporated a Standard Form of
Agreement Between Owner and Architect prepared by the American Institute of
Architects, the claimant became obligated to design and prepare plans for a new
hospital and boiler plant for Welch Emergency Hospital. It is alleged that the
claimant performed work under the contract for which it rendered invoices of
$167,000.00, of which $83,000.00 was paid, leaving a balance of $83,900.00
which was disputed. The parties joined in the submission of that dispute,
pursuant to the contract, to arbitration by the American Arbitration
Association. On August 18, 1978, the arbitrators, Wilson Anderson, Esquire,
Harry N. Barton, Esquire, and Robert N. Bland, Esquire, made an award in the
sum of $70,700.00 plus adminis
276 REPORTS STATE
COURT OF CLAIMS [W. Va.
trative fees in the sum of $1,189.00, making a total of $71,889.00, which is
the amount of this claim. The claim was submitted for decision upon the
pleadings. In their Answer, the respondents admit all of the foregoing facts,
aver that they have no defense to the claim, and declare that the claimant is
entitled to the relief sought. Accordingly, an award in the sum of $71,- 889.00
is hereby made.
Award of $71,889.00.
Opinion issued January 11, 1979
WOOD COUNTY BANK
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-78-209)
Harold W. Wilson, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision upon the pleadings. The claimant alleges
that on October 7, 1974, it advanced credit in the sum of $2,565.90 to the
owner of a 1972 model Volkswagen automobile, which was secured by a lien on
that vehicle, but that the respondent thereafter negligently issued a new title
in the name of the owner without the lien being recorded thereon. In addition,
it appears from exhibits that the respondent, on April 20, 1978, obtained a
judgment upon the aforesaid debt against the owner in the sum of $2,749.55, but
that execution on that judgment on September 5, 1978, was returned unsatisfied
with the endorsement ?Nothing Found?. It appears that the delay in reducing the
debt to a judgment was occasioned by difficulty in locating the owner, who
apparently was in Pennsylvania at one time and later was in Virginia. The
Answer of the respondent admits the salient facts and joins in the claimant?s
prayer for an award in the sum of $2,749.55. Accordingly, it appears that an
award in that sum should be made.
Award of $2,749.55.
W. VA.] REPORTS
STATE COURT OF CLAIMS 277
Opinion issued January 26, 1979
JACK L. RADER
vs.
DEPARTMENT OF HEALTH
(No. CC-78-223)
CARL L. BAKER, JR.
vs.
DEPARTMENT OF HEALTH
(No. CC-78-224)
and
H. M. CURRY
vs.
DEPARTMENT OF HEALTH
(No. CC?78-251)
Claimants appeared in person without counsel.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
The above-captioned claims arise from the same factual situation. The claimants
seek compensation for overtime worked as verified by the West Virginia
Department of Health and certified by the West Virginia Department of Labor for
fiscal years 1975-76, 1976-77, and 1977-78.
In its Answers, the respondent asserts that sufficient funds expired in fiscal
year 1975-76 and fiscal year 1977-78 had payinent been made to the claimants;
however, in fiscal year 1976- 77, there were NOT sufficient funds on hand at
the close of that fiscal year from which those portions of each claim could
have been paid.
Respondent cites in support of its denial of the claims for fiscal year 1976-77
the decision of this Court in Airkem
Sales and Service, et at. v. Department of
Mental Health, 8 Ct. Cl.
278 REPORTS STATE
COURT OF CLAIMS [W. Va.
180 (1971). The Airkem decision is based upon West Virginia Code 12-3-17,
which prohibits any State officer from authorizing or paying any account
incurred during any fiscal year out of the appropriation for the following
year.
In the decision of Elva B. Petts and
James M. Preston vs. Division of Vocational Rehabilitation, Claim Nos. D-927d and D-927i, this Court held that
personal services will not be denied, based upon the theory applied in
over-expenditure claims for merchandise, as the balance in the prsonal services
account is immaterial. The Court relied upon the recent Supreme Court case of State ex -rel. Crosier v. Callaghan -- W.Va , 236
S.E. 2d 321 (1977), wherein that Court held that ?to the extent that
retroactive liability for unpaid wages is incurred against an employer, it is
incurred at the time liability is determined.?
The Court therefore finds the respondent, the Department of Health, liable for
the overtime worked by each of the claimants, and makes awards as follows:
$6,975.46 to Carl L. Baker, Jr., $6,798.78 to H. M. Curry, and $5,488.05 to
Jack L. Rader.
Awards of $6,975.46 to Carl L. Baker, Jr.
$6,798.78 to H. M. Curry
$5,488.05 to Jack L. Rader
Opinion issued January 31, 1979
AMERICAN HOSPITAL SUPPLY
vs.
DEPARTMENT OF HEALTH
(No. CC-78-265)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
W. VA.] REPORTS
STATE COURT OF CLAIMS 279
Claimant seeks payment of the sum of $424.32 for merchandise shipped to
respondent on June 2, 1977 and June 30, 1977. Three invoices were sent to Welch
Emergency Hospital, but no payment was received by the claimant.
In its Answer, the respondent admits the validity of the claim and states
further that there were sufficient funds remaining in the appropriation for the
fiscal year in question from which the claim could have been paid.
In view of the foregoing, an award in the above amount is hereby made.
Award of $424.32.
Opinion issued January 31, 1979
WAYNE BAYLISS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-276)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damages to claimant?s truck in the
amount of $251.83 were caused when said vehicle struck a plate and bolts
protruding from the highway, which highway is Interstate-64 and Interstate-77
in Kanawha County, West Virginia; and to the effect that negligence on the part
of the respondent was the proximate cause of said damage, the Court finds the
respondent liable, and herby makes an award to the claimant in the abovestated
amount.
Award of $251.83.
280 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued January 31, 1979
GUYAN TRANSFER AND SANITATION, INC.
vs.
DEPARTMENT OF FINANCE AND ADMINISTRATION
(No. CC-78-244)
Marvin W. Masters, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. GARDEN, JUDGE:
By contract dated May 25, 1972, the
claimant agreed to provide pickup and disposal service of trash and garbage for
occupants in mobile home sites operated jointly by the State of West Virginia
and HUD in flood disaster areas in Logan County. The contract was renewed by a
Renewal Agreement dated May 3, 1974, for the period from May 1, 1974 through
April 30, 1975. The original contract or a copy thereof could not be located by
either the claimant or the respondent, but the Renewal Agreement, which was in
the form of a Purchase Order, provided as follows:
?RENEWAL AGREEMENT
This Purchase Order constitutes acceptance of Agreement made by and between the
State of West Virginia, by the Commissioner of Finance and Administration, for
and on behalf of the Department of Finance and Administration and Guyan
Transfer and Sanitation, Inc., Amherst- dale, West Virginia, for renewal to
contract No. 226-L, to provide pickup and disposal service of trash and garbage
for all occupants in the mobile home sites operated jointly by the State of
West Virginia and HUD in flood disaster areas in Logan and environs thereof all
as set forth in the contract dated May 25, 1972 now in effect and hereby
renewed for a further term of one year commencing May 1, 1974 through April 30,
1975 unless cancelled prior thereto with option to renew by the State for
further term of yearly periods thereafter. All in accordance with original
agreement.
ESTIMATED MONTHLY COST?$4,290.00?
W. VA.]
REPORTS STATE COURT OF CLAIMS 281
Pursuant to the original contract, the
respondent, by letter to the claimant dated August 14, 1974, terminated the
contract as of midnight on September 14, 1974. A. Douglas McKee, claimant?s
president, testified that from May 1, 1972 to September 15, 1974, his company
performed the services as contemplated by the agreement. He stated that, even
though the Renewal Contract reflected that the ?Estimated Monthly Cost? of the
services would be $4,290.00, that figure was the actual amount paid monthly by
the respondent. Mr. McKee further testified, that his company had been paid in
full except for the month of July, 1974, and that as a result, the respondent
was indebted to claimant in the amount of $4,290.00.
The respondent did not present any evidence to refute this claim, and, based on
the record, an award in favor of the claimant in the amount of $4,290.00 is
hereby made.
Award of $4,290.00.
Opinion issued January 31, 1979
HALLIBURTON SERVICES
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-264)
No appearance by claimant.
Henry Haslebacher, Attorney at Law, for respondent.
PER CURIAM:
Upon stipulation to the effect that damages to claimant?s truck in the amount
of $228.56 were caused when said vehicle struck a piece of metal protruding
from a bridge owned and maintained by respondent, which bridge is a part of
Route 16 between Ellenboro, West Virginia, and Harrisville, West Virginia; and
to the effect that negligence on the part of the respondent was the proximate
cause of said damage, the Court
282 REPORTS STATE
COURT OF CLAIMS [W. Va.
finds the respondent liable, and hereby makes an award to the claimant in the
above-stated amount.
Award of $228.56.
Opinion issued January 31, 1979
LINDA E. HAMILTON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-260)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
Upon written stipulation to the effect that damages to claimant?s automobile in
the amount of $92.00 were caused when said vehicle struck a board protruding
from the Home- wood Bridge in Mannington, Marion County, West Virginia, which
bridge is part of West Virginia Route 3; and to the effect that negligence on
the part of the respondent was the proximate cause of said damage, the Court
finds the respondent liable, and hereby makes an award to the claimant in the
above-stated amount.
Award of $92.00.
W. VA.]
REPORTS STATE COURT OF CLAIMS 283
Opinion issued January 31, 1979
HOWARD A. HAYNES
Vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-281)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $300.19, based upon the
following facts.
On or about October 30, 1978, claimant was operating his automobile on
Interstate-64 East near Broad and Capitol Streets in Charleston, West Virginia,
when he ran over some construction plates which were not securely fastened
down. This resulted in damage to the undercarriage of claimant?s vehicle.
Since the damage occurred because of the negligence of the respondent, and this
negligence was the proximate cause of the claimant?s damages, this Court hereby
makes an award to the claimant in the amount of $300.19, which sum is a fair
and equitable estimate of the damages sustained.
Award of $300.19.
284 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued January 31, 1979
ORA T. HERRON
vs.
DEPARTMENT OF PUBLIC SAFETY
and DEPARTMENT OF CORRECTIONS
(No. CC-76-108)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Amended Answer.
Claimant seeks reimbursement for paying a towing fee of $18.00 on her
automobile. The fee was incurred after an inmate from the Huttonsville
Correctional Center had stolen the auto, and, upon his capture, the West
Virginia State Police had it towed to Green Bank, West Virginia.
In their Amended Answer, the respondents admit the claims set forth in the
Notice of Claim, and further state that there were substantial funds on hand at
the close of the fiscal year from which the claim could have been paid.
In view of the foregoing, an award in the amount of $18.00 is hereby made to
the claimant.
Award of $18.00.
Opinion issued January 31, 1979
IBM CORPORATION
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-78-277)
No appearance by claimant.
Joseph C. Cometti, Assistant Attorney General, for respondent.
PER CURIAM:
W. VA.j REPORTS
STATE COURT OF CLAIMS 285
Upon written stipulation to the effect that respondent entered into Service and
Lease Agreements with claimant on various copying equipment and typewriters in
the amount of $3,962.30, and to the effect that respondent received invoices
but made no payment to claimant, the Court finds that this is a claim which in
equity and good conscience should be paid. However, we are of further opinion
that, since there were no funds remaining in the respondent?s appropriation for
fiscal year 1977-78 from which the obligation could have been paid, an award in
this claim is barred, based on our decision in Airkem Sales and Service, et at. v. Department of Mental
Health, 8 Ct. Cl. 180 (1971).
Claim disallowed.
Opinion issued January 31, 1979
POSITIVE PEER CULTURE, INC.
vs.
DEPARTMENT OF CORRECTIONS
(No. CC?77?117)
Jahn H. Tinney, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
The respondent, Department of Corrections, entered into a contract with the
claimant for certain services to be provided by the claimant at the West
Virginia Industrial School for Boys at Pruntytown and the West Virginia
Industrial Home for Girls at Salem, West Virginia. The claimant was to provide
psychological services for the inmates of these institutions and establish a
program for rehabilitation. The contract also required the claimant to provide
training and consultant services to respondent?s staff. The claimant was to be
paid $90,000.00 for its services, which were to start on January 18, 1975, and
be completed in twelve months. At the request of the respondent, performance of
the contract did not commence until the third week of February, 1975.
286 REPORTS STATE
COURT OF CLAIMS [W. V..
Respondent?s Exhibit No. 2 indicates that payments totalling $63,658.85 were
made by the respondent under the contract. Subsequent payments were withheld
pending an investigation of one of claimant?s employees. Although statements
were submitted, they were not paid. This claim is for the balance due under the
contract.
In November of 1975, the parties negotiated and signed an agreement to extend
the program for an additional nine months, which extension was never approved
by the Governor?s Committee on Crime and Delinquency nor by the Department of
Finance and Administration.
The contract provided that if the respondent was not fully satisfied with the
performance of the contract, it could terminate the contract upon thirty days?
written notice to the claimant. Such a notice was not given. Just prior to the
expiration of the term of the contract, Betty Light, Administrative Assistant
to respondent?s Commissioner, Calvin A. Calendine, notified Harry H. Vorrath,
claimant?s president, by telephone on January 14, 1976, that the contract would
expire as of January 17, 1976, and that the claimant would receive no
compensation for the last sixty-five days of the contract.
By letter dated February 6, 1976, after the contract had been terminated,
Commissioner Calendine wrote Mr. Vorrath stating in part:
?...Positive Peer Culture failed in several instances to fulfill the
requirements of the original contract. I was disappointed that we could not
negotiate reasonable times for the completion of this program...
However, since we have failed to reach such an agreement, we now feel that
payments already made to Positive Peer Culture, Inc. are sufficient
remuneration for the actual accomplishment and services rendered. .
In his testimony, Mr. Vorrath stated that
he was unaware of any dissatisfaction with the services being provided until
the January telephone call from Betty Light, and that he thought the
compensation was being withheld by reason of the investigation of one of
claimant?s employees.
W. VA.] REPORTS
STATE COURT OF CLAIMS 287
The record establishes that the claimant entered into the performance of the
contract and that an extension was contemplated although never consummated. The
record does not establish dissatisfaction with the claimant?s performance
during the term of the contract, nor that any effort was made on behalf of the
respondent to terminate the contract under its terms. Therefore, from the
record, the Court makes an award to the claimant in the amount of $26,341.15,
representing the balance due under its contract with the respondent.
Award of $26,341.15.
Opinion issued January 31, 1979
ROBERT SMITH and ELIZABETH SMITH
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-290)
No appearance by claimants.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $4,000.00, based upon
the following facts.
On and prior to October 1, 1977, claimants were occupying an apartment owned by
Patrick West, in Princeton, West Virginia. Also prior to that date, the
respondent had been engaged in a road construction project in the immediate
vicinity of the aforesaid apartment.
Respondent, during these construction activities, placed a landfill on land
adjacent to claimants? apartment without making any provisions for drainage of
surface water. As a result of such negligence, mud and water washed into the
apartment on or about October 1, 1977, damaging personal property owned by the
claimants and forcing them to find other living quarters.
288 REPORTS
STATE COURT OF CLAIMS [W. Va.
Claimants? expenses included money for
food, rent, and three days? lost wages.
In a cause of action styled Patrick West v.
Department of Highways, Claim No.
CC-77-205, the claimant Patrick West, owner of the apartment in the instant
case, sought compensation from the respondent for damage to the building
itself. A written stipulation filed therein indicated that the respondent
admitted both negligence and liability for causing the mud and water to wash
into the apartment building.
In view of the foregoing facts, this Court hereby makes an award to the
claimants in the amount stipulated by the parties, which sum is $4,000.00.
Award of $4,000.00.
Opinion issuea January 31, 1979
STATE FARM MUTUAL AUTO INSURANCE CO.,
SUBROGEE OF DANA LEE SELVIG
vs.
BOARD OF REGENTS
(No. CC-78-162)
No appearance by claimant.
Henry C. Bias, Jr.,
Deputy Attorney General, for
respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Amended Answer.
Claimant seeks payment of the sum of $308.99 for damages to its insured?s
automobile which occurred when the insured?s vehicle was lawfully parked on the
campus of West Virginia University. Maintenance employees, while mowing the
grass, scattered rocks and gravel against the finish of said vehicle.
In its Amended Answer, the respondent acknowledges the validity of the claim.
W. VA.) REPORTS
STATE COURT OF CLAIMS 289
Based on the foregoing facts, an award in the amount of $308.99 is hereby made
to the claimant.
Award of $308.99.
Opinion issued February 1, 1979
CENTRAL STATES RESOURCES, INC.
vs.
BOARD OF REGENTS
(No. CC-78-18)
Lewis A. George, Attorney at Law, for claimant.
Frank M. Ellison, Deputy Attorney General for respondent.
WALLACE, JUDGE:
This claim was submitted to the Court upon the pleadings.
Claimant was awarded a contract to supply Bakerstown coal at $32.00 per ton to
West Virginia University beginning in October of 1976. In January, 1977, due to
abnormally cold weather, the Bakerstown coal was insufficient to provide the
necessary BTU?s on an abnormal-need basis. It was determined that Pittsburgh
coal was necessary to meet the abnormal BTU demand. Claimant was informed that
the weather conditions were so severe that an emergency existed and that it
should do what was necessary to obtain Pittsburgh coal. Claimant obtained
Pittsburgh coal at $38.75 per ton and delivered 3,018.44 tons to West Virginia
University.
The University was invoiced for the coal at the increased price, but the coal
was paid for at the contract price of $32.00 per ton.
Claimant filed its claim against the respondent for $20,374.47, representing
the difference between $32.00 per ton and $38.75 per ton. As a compromise, the
claimant reduced its claim to $37.75 per ton, or $17,356.03.
In its Amended Answer, respondent admitted receipt of the coal, and it agreed
to compensate the claimant at the rate of $37.75 per ton.
290 REPORTS
STATE COURT OF CLAIMS [W.Va
Accordingly, from the pleadings, the
Court makes an award to the claimant in the amount of $17,356.03.
Award of $17,356.03.
Opinion issued February 1, 1979
JAMES H. CURNUTTE, JR.
& DEBORAH L. CURNUTTE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-150)
Claimant, James H. Curnutte, Jr., appeared in person. Nancy J. Aliff, Attorney at
Law, for respondent.
WALLACE, JUDGE:
The claimants filed their claim against the respondent for loss of water
service to their home due to slide conditions on Buffalo Creek Road in Wayne
County, West Virginia.
The claimants purchased their home in October of 1977 for $32,900.00. The house
was newly constructed. During the winter months of January, February, and
March, 1978, difficulty was experienced with the water supply in the home.
After the winter snow had thawed, it was discovered that a slide from Buffalo
Creek Road, behind the house, had disrupted the water line. The center of the
road is approximately 110 feet from the back of the house.
The road was built many years ago, and became part of the State road system by
a legislative act of 1933. According to a witness for the respondent, it was
constructed by the cut and cast method of building roads in hill sections. This
method consists of cutting into the hillside and casting the cut material over
the side opposite the hill. Respondent?s witness also testified that he knew of
at least four times in the seven years he was employed by the respondent that
this method had been used to repair this road. He stated that cuts into the
hillside were about four feet each time. The material cut from the hill
W. VA.] REPORTS
STATE COURT OF CLAIMS 291
was cast over the other side onto the natural slope. The testimony indicated
that the natural hill was composed of a silty, clay material subject to slides.
The record reveals that the road has been repaired and widened over the years,
but now the edge of the road has broken away. Studies have been made, due to
the complaint of the claimants, as to the best way to correct the situation.
The claimants filed their claim in the amount of $3,000.00, and in the course
of the hearing, it developed that estimated damages would exceed that amount.
The claimants asked to amend their claim to correspond with the evidence, which
request was granted by the Court.
From the record, the Court is of the opinion that the negligence of the
respondent in its failure to properly maintain Buffalo Creek Road was the cause
of the claimants? damage. The evidence reveals that, from the estimates and
costs already expended, the claimants are entitled to recover $4,604.73.
Accordingly, the Court makes an award to the claimants in that amount.
Award of $4,604.73.
Opinion issued February 1, 1979
FRANCES J. LARCH
and WILLIAM E. LARCH
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-77-120)
Phillip D?Orazio and Donald M.
O?Rourke, Attorneys at Law, for
claimants.
Frank M. Ellison, Deputy Attorney General, for respondent. WALLACE,
JUDGE:
This claim was filed by the claimants, Frances J. Larch and her husband, William
E. Larch, against the Department of
292 REPORTS
STATE COURT OF CLAIMS fW. Va.
Natural Resources for injuries
received by Mrs. Larch on May 30, 1976, in North Bend State Park. The park,
maintained by the respondent, is located in Ritchie County, approximately two
miles from Cairo, West Virginia.
On the day of the accident, the claimants had gone to the park to fish along
the banks of the North Fork of the Hughes River which meanders through the
park. They had driven from their home in Vienna, West Virginia, and arrived at
the park at 1:30 p.m. The weather was clear and calm. They parked their
automobile beside a paved road within the park, and proceeded on foot around a
locked gate some 12 feet from the road. The two then continued along the bed of
an abandoned railroad, left the roadbed, and went through an open area, used by
deer, to the river, a distance of some 400 to 600 yards. They traveled
appxoximately 15 feet down the bank to the river. Along both sides of the
roadbed were a natural growth of brush and small and large trees.
The area was marked as a wildlife sanctuary. There were no signs indicating
that it was a ?no fishing? area. Mr. Larch testified that he had fished in the
area many times over a period of four or five years, and that he had seen other
people fishing there.
The claimants fished beside the river for about three hcurs. Mrs. Larch was
sitting on a gravel bar in the river while fishing, and her husband was a few
feet up the stream. As she was sitting on the gravel bar, Mrs. Larch was
injured when a dead limb or a portion of a dead tree on top of the river bank
fell without warning, striking her on her left side and knocking her down.
A small boy, in the area at the time, ran to the park lodge for help. After
leaving instructions to notify the Harrisville Emergency Squad of the
occurrence of an accident, the park superintendent, Robert F. Rogers, proceeded
to find the area of the accident. The superintendent searched the area and
located the claimants on the river bank. After advising the claimants that help
was on the way, he returned to his vehicle to direct the emergency squad to the
scene of the accident. When the emergency squad arrived, Mr. Rogers unlocked
the
W. VA.]
REPORTS STATE COURT OF CLAIMS 293
gate to permit the vehicle to proceed
as close as possible to the accident scene. The claimants proceded to the
Camden- Clark Hospital in Parkersburg.
Superintendent Rogers testified that the area in which the claimants were
fishing was part of the area reserved as a wildlife sanctuary, and was not an
area designated for fishing. He further stated that the area was not patrolled
nor maintained as were other sections of the park.
From the record, the Court finds that the respondent was not negligent in the
maintenance of the area where the accident occurred, and that the injuries
suffered by Mrs. Larch were not foreseeable. Accordingly, the claim is
disallowed.
Claim disallowed.
Opinion issued February 1, 1979
OSTRIN ELECTRIC CO.
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-78-169)
Milton S. Koslow, Attorney at Law, for claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Purchase Order No. 8141 in the amount of $8,175.00 was issued February 9, 1978,
to the claimant to do certain work for the respondent in a laboratory at 1201
Greenbrier Street in Charleston, West Virginia. The contract was accepted by
the Department of Finance & Administration on March 14. Some two months
after the claimant commenced preliminary work on the contract, the respondent
cancelled the contract because the location of the laboratory was to he changed
for fire safety reasons.
The claimant filed its claim in the amount of $1,397.50 for the cost of
equipment, labor, and overhead incurred prior to
294 REPORTS STATE
COURT OF CLAIMS [W. Va.
the cancellation of the contract. The claim consists of $800.00 for an
electrical panel and parts; ten hours for labor at $19.75 per hour, totalling
$197.50; and $400.00 for insurance, overhead, and taxes.
The respondent admitted that the purchase order was issued, but demanded proof
of the value of goods and services performed.
Invoices and time records were introduced which substantiated the cost of
material and labor, but the evidence was not sufficient to establish the $400.00
claimed for insurance, overhead, and taxes.
The record indicates that the panel and parts could not be returned and that
there was no known market for resale.
Accordingly, the Court finds that the claimant is entitled to recover the
$997.50 expended for the panel, parts, and labor.
Award of $997.50.
Opinion issued February 1, 1979
VECELLIO & GROGAN, INC.
vs.
DEPARTMENT OF HIGHWAYS
(No. D-914, D-993, D-918 Par. C)
Robert B. Sayre, Attorney at Law, for claimant.
Stuart Reed Waters, Jr., Attorney at Law, for respondent. GARDEN, JUDGE:
These claims involve a multitude of issues arising on three separate contracts
between Vecellio & Grogan, Inc. of Beckley, West Virginia, the claimant
(hereinafter referred to as V & G), and the respondent. They will be
?discussed in the order in which they were presented at the hearing.
Issue No. 1. Federal Explosive Impost
Charge (D-914)
On November 2, 1970, V & G entered into an agreement with respondent for
the construction of 2.6 miles of U.S. 19 Express-
W. VA.] REPORTS
STATE COURT OF CLAIMS 295
way in Nicholas County, West Virginia, being respondent?s Project No. APD-482
(30). By letter dated February 15, 1971, V & G?s explosive supplier advised
V & G that, pursuant to the provisions of the Organized Crime Control Act
of 1970, Commerce in Explosives, Part 181, and Internal Revenue Regulations
issued pursuant thereto, Austin Powder Company was required to place an
immediate impost on explosive sales. It was stipulated between the parties that
these requirements were based on regulations promulgated in the Federal
Register, Volume 36, Number 10, dated January 15, 1971, a copy of which was
attached to the Stipulation. It was further stipulated that, as a result of
explosives purchased to perform the above-mentioned contract, V & G was
required to pay its explosive supplier the sum of $1,929.10 over and above the
price set forth in their contract. A careful reading of the Federal Register
fails to reveal any provision which would authorize the purchaser of explosives
to pass this charge on to the ultimate consumer, namely, the respondent. We are
also unaware of exactly when contract prices may be altered by respondent (with
the exception of increases or decreases in common carrier freight rates). This
Court feels that this is simply one of the hazards, unforseen as it may be, of
doing business, and for this reason, this portion of the claim is denied.
Issue No. 2. Pres?plitting
Tethnique (D-914)
An additional controversy has arisen
in connection with the performance of contract APD-482 (30) involving the
dynamiting technique known as presplitting. This is a procedure which was first
developed in the early 1960?s. It is a technique by which modern blasters split
or crack a rock deposit along the line marking the edges of a cut prior to
production blasting.
The specifications of the contract in question required that the technique of
presplitting be followed. It was agreed that the performance of this contract
was governed by respondent?s 1968 Standard Specifications?Roads and Bridges and
by respondent?s Special Provisions dated January 1, 1970. Section 207.1 of the
1968 Standard Specifications reads in part as follows:
296 REPORTS
STATE COURT OF CLAIMS [W. Va.
?This work shall consist of excavation
for the roadway
.in reasonably close conformity with the lines, grades, thicknesses and cross
sections shown on the plans or established by the Engineer.?
Section 207.3.1.1.2 of the 1968 Standard Specifications authorizes the use of
the presplitting technique, but does not provide details as to how the
technique is to be performed. Also, in another Section, 207.3.1.3, entitled
Rock Excavation, the following appears:
?A tolerance of 18 inches, measured in a horizontal plane, for cut slopes back
of the ditch line will be permitted in rock cuts . .
To further complicate the matter, the
respondent, in its January 1, 1970 Special Provisions, deleted former Section
207.3.1.1.2 and substituted the following:
?When called for in the contract, rock excavation shall incorporate the
?presplitting? technique. This involves a single row of holes drilled along the neat excavation line
The end result is intended to yield a
minimum of breakage outside the neat line of the plan cross sections.?
(Emphasis added.)
Claimant readily admitted that it did not drill along the neat excavation line
which was simply defined as the template line shown on the cross sections. V
& G?s officers and employees testified that it is impossible to drill on
the template line and ultimately arrive at the proper point in the ditch line
as shown on the cross sections. They explained that the drilling equipment
currently being used by road contractors in West Virginia simply will not
physically permit them to drill on template, and that as a result, they started
their drilling behind template, believing that they were entitled to a
tolerance of 18 inches as set forth in 207.3.1.3. The presplitting provisions
are contained in a separate section, and in that section, tolerances are not
mentioned and the contractor is required to drill on the neat excavation line.
For the main part, the respondent has refused to pay V & G for the
excavation of this unclassified material behind the neat
W. VA.] REPORTS
STATE COURT OF CLAIMS 297
excavation line. If back breaking due to poor material fell out, the record
indicates that V & G was paid. While we feel that V & G is not entitled
to the 18? tolerance, we are of the opinion that equity demands an extension of
some tolerance to them, and we believe that a tolerance of 12 inches is
equitable. With this figure in mind, we directed the respondent?s engineers and
the officials of V & G to make a determination of the additional
unclassified excavation performed by V & G, and to determine, at the rate
of $0.99 per cubic yard, the additional compensation which should be paid to V
& G.
The parties have reported to the Court that, as a result of the 12-inch
tolerance outlined above, V & G is entitled to be paid for the excavation
of an additional 6,264 cubic yards of unclassified material at the rate of
$0.99 per cubic yard, or the sum of $6,201.36, and an award to V & G in
that amount is hereby made.
Issue No. 3. Fat Fill (D-918)
On June 24, 1970, V & G entered
into a contract with the respondent for the grading, draining, and paving of a
portion of U.S. 460 Expressway in Mercer County, West Virginia, which was
respondent?s Project No. APD-200 (19).
A written stipulation filed at the hearing reflects that V & G excavated
217,531 cubic yards of unclassified borrow excavation and that respondent
certified and paid V & G for 203,495 cubic yards, or a difference of 14,036
cubic yards, and that the unit bid price was $0.89 per cubic yard. The parties
further agreed that respondent?s 1968 Standard Specifications governed all work
under the contract. The pertinent provisions of these Specifications are as
follows:
Article 105.3
?All work performed and all materials furnished shall be in reasonably close conformity with the lines, grades, cross sections, dimensions and
material requirements, including tolerances shown on the Plans, or indicated in
the Specifications.? (Emphasis added.)
Article 105.8
?The Contractor shall be responsible for having the finished work in reasonably close conformity with the lines, grades,
298 REPORTS STATE
COURT OF CLAIMS [W. Va.
elevations and dimensions called for in the Plans or established by the
Engineer.? (Emphasis added.)
Article 207.1
?(Embankment) work shall consist of . . . constructing
embankments with excavated material . . . in
accordance with these Specifications and in
reasonabl!y close conformity with the
lines, grades, thicknesses and cross sections shown on the Plans or established
by the Engineer.? (Emphasis added.)
Article 211.3.1
?If the borrow is obtained in such quantity or in such manner that a waste of
unclassified excavation, slips or excess material is caused, the amounts of
such waste shall be deducted from the borrow volume.?
It was remarked during the testimony in respect to this claim that all fills
are fat, and this Court has concluded that such a statement is correct. Where
fills are required on road construction, the contractor is furnished with cross
sections showing the template lines of the slopes and, of course, a template
line reflecting the location of the roadbed. The Standard Specifications
require larger rocks to be placed near the outer part of the embankment and
smaller rocks and spalls near the center. At the very bottom of the fill where
rocks of three or four feet in diameter are used, some part of the rock by its
very nature must extend beyond the template line in order to support material
placed on them. Also, on the slopes where the sides of the embankment are being
compacted by a bulldozer, it is necessary that extra material be used to obtain
the require d compaction and to make sure that the slope meets the template
line.
Itis to be noted that the Specifications repeatedly refer to ?in reasonably
close conformity?. What does this term mean? A witness for V & G was of the
opinion that it meant a distance of six inches to two feet, whereas a witness
for respondent opined that a distance of one foot would constitute ?in
reasonably close conformity?. It has come to the attention of the Court that on
January 5, 1978, the respondent issued a Special Provision relating to
Excavation and Embankment and added this language to Section 207.7.1:
W. VA.] REPORTS
STATE COURT OF CLAIMS 299
?Slope lines for all embankments shall conform to the lines shown on the Plans
or established by the Engineer, except
that a construction tolerance of plus or minus one foot, measured
in a horizontal plane, will be permitted, except further that the roadbed width due to the tolerance shall not be
less than plan width .
. .? (Emphasis added.)
Based on the testimony and all of the evidence in the record, this Court is of
the opinion that one foot should be considered as being ?in reasonably close
conformity?. We requested the engineers for the respective parties to review
and determine the actual fat fill on this job with this tolerance in mind so
that a proper award might be made.
The parties have now agreed that within this one-foot line beyond the template
lines there are 5,689 cubic yards of unclassified borrow or fat fill. The
contract entitled V & G to be paid a unit price of $0.88 per cubic yard for
this material, and, consequently, an award of $5,063.21 is hereby made in favor
of V & G.
Issue No. 4. Deduction for Fat Fill on
Contract which
was Bid Originally as a Waste Job (D-993)
This issue, and the following three issues, deal with project APD-323 (23). By
agreement dated December 23, 1969, V & G contracted with the respondent to
construct one segment of
U. S. 119 Expressway in Mingo County, West Virginia. The testimony established
that the plans indicated that the project would be a ?waste job? as opposed to
a ?borrow job?. By way of explanation, a ?waste job? is a project where the un-
classified excavation in the cut areas provides more than sufficient suitable
material to construct the fills and embankments in the same project. On the
other hand, a ?borrow job? is one where the unclassified excavation obtained
from the cuts produces an insufficient amount of suitable material to construct
the fills and embankments. In the latter situation, it becomes necessary for
the contractor to borrow additional suitable material from the project site or
outside of the project site, and, of course, the contractor in such instances
submits a unit price bid for this item in submitting a bid.
300 REPORTS
STATE COURT OF CLAIMS {W. Va.
During the course of this
construction, it became apparent to V & G that the amount of suitable
material to be obtained from the cuts would be insufficient to construct the
fills and embankments. By letter dated December 10, 1970, and introduced into
evidence, V & G informed the respondent that a borrow in the range of
100,000 cubic yards would be necessary to complete the work and, apparently,
with the approval of the respondent, V & G prepared additional plans and
cross sections of various cuts on the project where V & G would excavate
behind the template lines. From that source, V & G would obtain the
additional needed suitable material to construct the fills and embankments.
It was stipulated by the parties that V & G, in the performance of the
contract, excavated a total of 1,871,199 cubic yards of unclassified excavation
and was paid for all of the excavation at a unit bid price of $1.27 per cubic
yard. However, when the final cross sections were taken by the respondent, a
procedure in which V & G participated, it was determined that some 45,000
cubic yards of unclassified excavation were outside of the template lines of
the fills and embankments as the template lines were shown on the original
plans. As a result, the respondent deducted these 45,000 cubic yards as a fat
fill at the above-stated unit price of $1.27, or a total of $57,150.00, from
the final payment to V & G. Respondent contends that it had the right to
make this deduction in the final pay pursuant to Section 1.5.1 of the 1960
Standard Specifications?Roads and Bridges, which reads in part as follows:
The Engineer shall determine the amount and quantity of the several kinds of
work performed and materials furnished which are to be paid for under this
Contract and his decision shall be final. .
V & G does not dispute the fact that
the disputed 45,000 cubic yards of material were beyond the template lines, but
it contends that this material consisted of material within one foot of the
template line (?in reasonably close conformity,? as discussed earlier),
unsuitable material, and material from slides (at least four in number) which
occurred after the fills and embankments had been constructed. It should be
noted, however, that Howard Lane, V & G?s project superintendent,
W. VA.]
REPORTS STATE COURT OF CLAIMS 301
admitted that at least some of the
45,000 cubic yards consisted of suitable material that had been wasted.
The respondent vigorously contends that it consistently advised V & G
during the construction of the project that it would not pay for any suitable
material that was wasted outside of the template lines as shown on the plans,
and various entries from respondent?s job diaries were introduced into evidence
to substantiate the fact that these warnings were given. The job diaries
further established that respondent called to V & C?s attention the fact
that suitable material was being wasted at certain waste pits, and that V &
G advised the respondent that such suitable material would be reclaimed later
if the same was needed, but that such reclamation was never performed.
While this Court is of the opinion that the respondent?s action in making this
deduction was proper, it also feels that the deduction was extreme. The
evidence is insufficient to permit this Court to determine the exact amount of
the 45,000 cubic yards which constituted fat fill, but it is convinced that
certainly a portion thereof constituted fill ?in reasonably close conformity?
to the template, unsuitable material, and material resulting from slides,
Perhaps arbitrarily, the Court is of the opinion that V & C should be paid
for 30% of the 45,000 cubic yards deducted by respondent, or for 13,500 cubic
yards at a unit price of $1.27 per cubic yard. Accordingly, an award in favor
of the claimant in the amount of $17,145.00 is hereby made. The Court is also
of the opinion that V & G is entitled to interest on this award at the rate
of six per centum per annum from March 28, 1973, to February 1, 1979, the
issuance date of this opinion, in accordance with Code 14-3-1, as hereinafter
discussed. Calculated, this interest amounts to $6,017.70, or a total award or.
this issue of $23,162.70.
Issue No. 5. Interest on
Public Contracts
In 1969, the Legislature, in an
attempt to protect vendors and contractors dealing with State agencies, enacted
Article 3 of Chapter 14 of the West Virginia Code, which requires the payment
of interest on public contracts by the State of West Virginia when final
payment is delayed. Code 14-3-1 provides in part as follows:
302 REPORTS STATE
COURT OF CLAIMS [W. Va.
?All public construction contracts relating to roads or bridges let by the
state road commissioner, entered into on and after March one, one thousand nine
hundred sixty- nine, shall contain the following paragraph:
?Within one hundred fifty days after the approving authority notifies the
contractor, in writing, of the final acceptance by such approving authority of
the project for which this contract provides, the balance due the prime
contractor shall be paid in full. Should such payment be delayed for more than
one hundred fifty days beyond the date that the approving authority notifies
the contractor of the final acceptance of the project in accordance with the
terms of the contract and the plans and specifications thereof, said prime
contractor shall be paid interest, beginning on the one hundred fifty-first
day, at the rate of six per centum per annum on such unpaid balance: Provided,
that if the prime contractor does not agree to the amount of money determined
by the approving authority to be due and owing to the prime contractor and set
forth on the final estimate document, and the approving authority makes an
offer to pay the amount of the final estimate to the said prime contractor,
then the prime contractor shall not be entitled to receive any interest on the
amount set forth in said final estimate, but shall only be entitled to the
payment of interest at the rate of six per centum per annum on the amount of
money finally determined to be due and owing to the said prime contractor, less
the amount of the final estimate that the approving authority had originally
offered to pay to the said prime contractor.? ?
The first part of the statute is clear.
After a project has been completed and the approving authority notifies the
contractor in writing that the same has been accepted, the balance due the
prime contractor shall be paid in full, and if not paid within 150 days of the
date of acceptance, interest at the rate of six per centum per annum shall be
paid on the unpaid balance. It is the proviso portion of the statute which
makes the application of the statute difficult.
W. VA.]
REPORTS STATE COURT OF CLAIMS 303
Project APD-323 (23), the U.S. 119
Expressway in Mingo County, was completed by V & G on September 18, 1972,
and the project was accepted by the respondent on October 27, 1972. The
evidence established that a tentative final estimate was submitted to V & G
on May 1, 1973. Apparently, V & G did nothing in respect to the tentative
final estimate until August 23, 1973, when V & G wrote a letter to
respondent which was received by respondent on August 27, 1973, and in which V
& G took exception to the quantities set out in the tentative final estimate.
Thereafter, on January 10, 1974, respondent paid V & G the sum of
$138,927.40, which was the amount the respondent contended was due and owing V
& 0 under the tentative final estimate. On May 20, 1975, a voucher
estimate, which was designated as ?Estimate No. 58 & Final?, was accepted
and approved by V & G, with V & 0 reserving its right to file its claim
in this Court. Estimate No. 58 & Final reflected that the respondent owed
nothing to V & 0; on the contrary, it indicated that V & G owed the
respondent $6,300.00 as liquidated damages for failing to timely complete this
contract. The respondent contends that this instrument is the final estimate
referred to in the proviso portion of the code section set out above, and that,
consequently, interest cannot be charged to the respondent because this
estimate fails to reflect that any monies are due and owing V & G.
This Court does not agree with respondent?s contention. Such a construction of
14-3-1 would completely destroy the obvious intent of the Legislature and would
permit the respondent to avoid payment of any interest simply by failing to
present a final estimate to an involved contractor.
The project was accepted by the respondent on October 27, 1972, and the 150-day
period contemplated by the statute commenced to run as of that date. The
respondent became liable for the payment of interest on March 28, 1973 (the
151st day subsequent to October 27, 1972). As indicated earlier, the tentative
final estimate was submitted to the contractor on May 1, 1973, which estimate
reflected that the contractor was entitled to $138,927.40. The Court is of the
opinion that interest should be charged to the respondent from March 28, 1973
to May 1, 1973. The record indicates that, after receiving this tentative
304 REPORTS
STATE COURT OF CLAIMS fW. Va.
final estimate, V & G did nothing
until writing its letter of August 23, 1973, which letter was received by
respondent on August 27, 1973. This Court does not feel that interest during
this period, namely, May 1, 1973 to August 27, 1973, should be charged to
respondent. The $138,927.40 was paid by respondent to V & G on January 10,
1974, and the Court believes that interest should be charged to respondent for
this period of time, that is, from August 27, 1973 to January 10, 1974. It
would thus appear that V & G is entitled to interest for a period of 171
days, which amounts to an interest charge of $3,905.64, and an award in that
amount is made in favor of V & G.
Issue No. 6. Additional
Construction Layout Stakes (D-993)
This issue is interrelated with Issue No. 4, again arising from the contract
entered into between V & G and the respondent dated December 23, 1969, and
whereby the former was to construct a segment of U.s. 119 Expressway in Mingo
County, West Virginia. As indicated earlier, this project was considered by the
respondent to be a waste, or at the very least, a balanced, job. In any event,
the proposal submitted by V & G did not contain a line item for the
excavation of unclassified borrow material.
During the course of construction, when it was determined and agreed by both
parties that there was insufficient material on the job site to complete the
slopes and embankments, it was decided that an additional 166,000 cubic yards
of material to complete the slopes and embankments would have to be obtained
(in engineering parlance, they would have to ?lay back the cuts?). In road
construction, the contractor does not prepare the plans and specifications but
is required to stake out the project (other than the location of the center
line) so that the completed highway will conform to the cross sections, etc.
This involves an extensive amount of engineering and surveying work, and, as a
matter of fact, in V & G?s proposal there was a line item in its bid of $100,000.00
to cover the cost of this work as originally contemplated by the plans and
specifications.
As the result of an apparent mistake in the plans and specifications, and for
other reasons, it was agreed that V & G would
W. VA.]
REPORTS STATE COURT OF CLAIMS 305
be granted a 96-day extension in order
to complete the contract (actually the contract was 117 days late in being
completed). During this period of time, additional engineering and surveying
work was done in order to ?lay back the slopes? to obtain the necessary
additional material to complete the slopes and embankments. George Shimmel,
Chief Engineer for V & G, testified that he was responsible for making the
computations for the engineering stake-out cost overruns on the project, and
that the cost to V & G for this additional engineering was $17,933.60.
Respondent made no attempt to show that this expense was inflated, but seemed
to be distressed by the fact that they had never been furnished an itemized
breakdown of this additional expense.
We believe that the claimant has established, by a preponderance of the
evidence, that this cost overrun amounted to $17,933.60, through no fault on
its part. We thus make an award to the claimant on this particular issue in the
amount of $17,933.60. The Court also believes that V & G is entitled to
interest on this award at the rate of six per centum per annum from March 28,
1973, to February 1, 1979, the issuance date of this opinion, in accordance
with Code 14-3-1, as hereinabove discussed. Calculated, this interest amounts
to $6,294.60, or a total award on this issue of $24,228.20.
Issue No. 7. Liquidated
Damage Claim (D-993)
This issue, too, arises from Project APD-323 (23), Mingo County. The contract,
which was dated December 23, 1969, provided that the work on the project was to
be completed by October 31, 1971. As earlier indicated and set forth in the
written stipulation filed by the parties, a time extension of 96 days was
granted, which extended the completion date until July 23, 1973. Nevertheless,
the project was not completed until August
17 1972, amounting to 21 days beyond the revised completion date. As a result,
the respondent assessed a liquidated damage penalty against V & G of
$300.00 per day, or a total of $6,300.00, all as provided in the contract. V
& G contends that the imposition of this penalty was unjustified in view of
the many problems that arose during the performance of the work.
The respondent directed a letter to V & G dated January 20, 1975, which was
introduced into evidence as Claimant?s Exhibit
306 REPORTS
STATE COURT OF CLAIMS [W. Va.
No. 9. In this letter, the respondent
sets forth an analysis of the reason for respondent?s proposal to extend the
contract completion date 96 days. For the additional unclassified excavation, a
period of 76 days was allowed; for a health hazard strike, 18 days were
allowed; and for inclement weather, 2 days were allowed. V & G responded to
this letter by their letter of March 11, 1975, which likewise was introduced
into evidence. In that letter, V & G did, of course, accept the 96- day
extension granted in respondent?s letter of January 20, 1975; but V & G
requested an additional extension of 209 days for reasons set forth in the
letter.
Respondent contends that the CPM network submitted by V & G stated that
work on the project would start on February 6, 1970, in the form of clearing
and grubbing, which could be performed during inclement weather. The testimony
established that the work actually commenced on March 9, 1970. Consequently, the
respondent argues that if work had started in accordance with the CPM, the
project would have been completed on time.
One of the requests for a time extension contained in V & G?s letter of
March 11, 1975, hereinabove referred to, was set forth in the letter as
follows:
?Item 6 ?
September 28, 1971 letter, we requested
forty-five (45) days time extension for the truckers strike and delay in
utility relocations that set back Bridges 2798 and 9796. The truckers strike
caused delay in pipe delivery which caused us to change our sequence of
operations. The delay in utility relocation caused our bridge subcontractor to
change his schedule. When this happened, our sub-contractor started other work
and when the bridge sites were ready for him, he had not completed his other
work; therefore, the delay was compounded.
We request forty-five (45) days for these delays
(Item 6) 45 days?
No additional testimony was introduced at the hearing with respect to the
truckers? strike mentioned in the above-quoted portion of the letter, and the
Court is of the opinion that the facts stated in the letter are true. Section
1.8.5 of the Standard
W. VA.]
REPORTS STATE COURT OF CLAIMS 307
Specifications?Roads and Bridges
(Adopted 1960) and introduced into evidence as Joint Exhibit 2 provides in part
as follows:
?In computing time spent in the execution of the work, working days will not be
charged for Saturdays, Sundays or Legal Holidays, unless the Contractor
utilizes Saturday as a working day, or for delays due to causes beyond the
reasonable control and without the fault or negligence of the Contractor,
including, but not restricted to, acts of God, acts of the Commission, floods, strikes, state
of National emergency, or freight embargoes, provided such delays prevent the Contractor
from proceeding toward completion of the current controlling major operation or
operations; and providing further that the Contractor has used every reasonable
means to remove the cause of such delays.? (Emphasis added.)
The Court is of the opinion that, if the requested 45-day extension had been
partially caused by the truckers? strike, through no fault of V & G, and
there was no evidence to the contrary, some additional extension of time should
have been granted.
In the claim of Whitmyer Brothers,
Inc. v. The Department of Highways, Claim
No. D-571, this Court rejected the Department of Highways? claim for liquidated
damages, and cited 22 Am. Jur. 2d ?Damages?,
?233, p. 319, as follows:
?The plaintiff cannot recover liquidated damages for a breach for which he is
himself responsible or to which he has
contributed, and as a rule there can
be no apportionment of liquidated damages where both parties are at fault.
Hence, if the parties are mutually responsible for the delays, because of which
the date fixed by the contract for completion is passed, the obligation under
which another date can be substituted, cannot be revived.? (Emphasis added.)
It is apparent that some of the delays resulted from the incorrect plans, which
necessitated additional engineering services on the part of the claimant and
additional excavation to obtain material for constructing the fills and
embankments.
308 REPORTS
STATE COURT OF CLAIMS [W. Va.
Furthermore, there was no evidence as
to the amount of actual damage, if any, sustained by the respondent as a result
of the delay in constructing this highway, which was another reason this Court
in Whitmyer, supra, rejected the liquidated damage claim.
On May 9, 1975, in view of the fact that the final estimate reflected that the
claimant owed the respondent $6,300.00 in the form of liquidated damages, the
respondent wrote to V & G and requested payment of this sum. Claimant had
previously deposited securities with respondent totalling $30,000.00, and, in
order to recover these securities, the claimant paid the sum of $6,300.00 to
respondent on May 22, 1975. This Court, being of the opinion that the
imposition of the liquidated damage charge was improper, hereby awards the
claimant the amount of $6,300.00. Furthermore, in accordance with Code 14-3-1,
an award of interest at the rate of six per centum per annum from May 22, 1975
to February 1, 1979, which amounts to $1,- 298.16, is also made. On this issue an
award is thus made in favor of the claimant in the total amount of $7,598.16.
As a result of the above, the following awards are hereby made.
Issue No. 1 ?
No award
Issue No. 2 ?
Award of $6,201.36
Issue No. 3 ?
Award of $5,063.21
Issue No. 4 ?
Award of $23,162.70
Issue No. 5 ?
Award of $3,905.64
Issue No. 6 ?
Award of $24,228.20
Issue No. 7 ?
Award of $7,598.16
Total award of $70,159.27.
W. VA.] REPORTS
STATE COURT OF CLAIMS 309
Opinion issued February 1, 1979
PATRICIA WILSON, GEORGE P. WILSON
and GLADYS V. WILSON
vs.
OFFICE OF THE GOVERNOR?
EMERGENCY FLOOD DISASTER RELIEF
(No. CC-78-41)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
GARDEN, JUDGE:
Several weeks after the devastating flood in Williamson, West Virginia in early
April of 1977, the operator of an end- loader engaged in the cleanup operation
damaged a wall along the front of property which, according to the Notice of
Claim, was owned by the claimant, Patricia Wilson. At the hearing, it was
revealed that the legal owners of the property were the father-in-law and
mother-in-law of the claimant, namely, George P. Wilson and Gladys V. Wilson.
Mr. and Mrs. George P. Wilson were thereupon named as additional claimants.
The claimant, Patricia Wilson, testified that the endloader in question was
painted yellow and that she therefore assumed that it was owned and operated by
an employee of the Department of Highways, which State agency was named the
respondent in the Notice of Claim. However, Courtney Joslin testified that, in
April of 1977, he was employed by the Department of Highways as a Management
Analyst with the Management Services Division, and that he and about six other
employees of the Department were sent to the Williamson area to supervise the
cleanup effort. According to Joslin, at that time the Department of Highways
had no equipment in the area, it having been inundated by the flood waters. As
a result, it was necessary to hire local contractors with the equipment
required to perform the actual work. Most importantly, Joslin further stated
that all of the work done in the Williamson area was done under the direction
of Governor Rockefeller.
310 REPORTS STATE
COURT OF CLAIMS [W. Va.
As far as damages are concerned, an estimate of repairs was introduced into
evidence. Prepared by one John B. Lamanca, the estimate reflected that the cost
of material and labor to replace this wall would be about $1,600.00. On the
other hand, claimant Patricia Wilson testified that, in her opinion and the
opinion of other members of her family, the cost would not exceed the sum of
$1,200.00.
This Court heard several other claims resulting from this destructive flood
wherein the Office of the Govern or?Emergency Flood Disaster Relief was the
respondent. The Court is of the opinion that this claim was improperly filed
against the Department of Highways and that no award can be made as far as that
agency is concerned, but the Court on its own motion hereby substitutes the
Governor?s Office?Emergency Flood Disaster Relief as respondent.
The Court therefore awards the amount of $1,200.00 to claimants Patricia
Wilson, George P. Wilson, and Gladys V. Wilson.
Award of $1,200.00.
Opinion issued February 20, 1979
ARNOLD G. HEATER and
GERALDINE HEATER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-130)
Claimants appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
RULEY, JUDGE:
This claim was asserted to recover damages in the sum of $3,500.00 allegedly
sustained by the claimants? dwelling house as the result of blasting done by
the respondent incident to excavating a cut through a hill. The blasting began
in March or April, 1977, and continued over a period of six or seven
W. VA.] REPORTS
STATE COURT OF CLAIMS 311
months. The claimants? dwelling house was about 900 feet from the excavation.
The blasting began at an elevation of 1026 feet but continued in depth to 987
feet, which was the elevation of the claimants? home. The same rock strata in
which the blasting was done extended to the claimants? home. The respondent?s
superintendent, who was in charge of the blasting, testified that, to the best
of his knowledge, rock strata lay on a horizontal plane. The initial blasts
were in patterns of approximately 63 holes with one stick of dynamite and one
and one-half pounds of ammonite in each. Toward the end of the blasting, only
six to eight holes were being shot at the same time. The respondent?s
superintendent was careful to say that he could not deny that there had been
vibrations which extended to the claimants? home. The photographic evidence in
the case showed severe damage to the dwelling house consistent with the
claimants? own testimony that it was caused by vibrations from the respondent?s
blasting. In view of that evidence, a conclusion to any other effect by the
Court would be speculation. Of course, it always has been the law of West
Virginia that liability for damage proximately caused by blasting is absolute.
See Konchesky v. Groves, 148 W.Va. 411, 135 S.E. 2d 299 (1964). The claimant testified,
without objection, that it would cost $2,500.00 to repair the damage sustained
by his dwelling. There was no other evidence respecting the amount of damage.
Accordingly, an award in that sum should be made.
Award of $2,500.00.
312 REPORTS STATE
COURT oF? CLAIMS [W. Va.
Opinion issued February 20, 1979
HAROLD HERSOM and
ELEANORE HERSOM
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-77-170)
Claimant appeared in person.
Frank M. Ellison, Deputy Attorney General, for respondent. WALLACE, JUDGE:
This claim is in the sum of $444.29 for property damage sustained by the
claimants? automobile when a limb fell onto it while it was parked in a parking
1t located in Berkeley Springs State Park. The accident happened at about 2:00
p.m. on Monday, August 8, 1977. The claimant testified that it was a sunny day
and that there had been no wind and ro storms. According to the undisputed
evidence, the limb was about fifteen to eighteen feet in length, about three
inches in diameter, and was green, showing no evidence of rot or deterioration.
Although there is no explanation of why the limb fell, there also is no
evidence that its fall was caused by negligence on the part of the respondent.
For that reason, the claim must be denied. See Shortridge v. Dept. of Highways, 11 Ct. Cl. 45 (1975).
Claim disallowed.
Opinion issued February 20, 1979
McCLOY CONSTRUCTION COMPANY, INC.
vs.
DEPARTMENT OF NATURAL RESOURCES
(No. CC-77-221)
Jack 0. Friedman, Attorney at Law, for claimant.
Frank M. Ellison, Assistant Attorney General, for respondent.
WALLACE, JUDGE:
The claimant, McCloy Construction Company, Inc., was awarded the contract to
construct for the respondent the lodge
W. VA.]
REPORTS STATE COURT OF CLAIMS 313
facilities at Canaan Valley State
Park. During the months of October and November of 1975, rock was encountered
unexpectedly along the front line of the building. The claimant contends that
the architect?s representative and respondent?s inspector on the construction
site were advised of the rock and that claimant was advised to submit a claim
for the rock excavation. The claimant did so file, in the amount of
$233,750.00, which sum was based upon the excavation of 935 cubic yards of rock
at $250.00 per cubic yard. The respondent denied the claim and asserted in its
Answer that if the claimant had removed any rock for which it had not been
paid, the compensation should be that which is recognized in the construction
industry, and not $250.00 per cubic yard.
Subsequent to the pre-trial conference held in this matter, the parties filed a
written stipulation with the Court in which it was agreed that the claimant
should be paid $27,000.00 for the excavation of 300 cubic yards of rock at the
rate of $90.00 per cubic yard.
Having considered the pleadings and the stipulation, the Court makes an award
to the claimant in the amount of
$27,000.00.
Award of $27,000.00.
Opinion issued February 20, 1979
MEMORIAL GENERAL HOSPITAL
vs.
DEPARTMENT OF CORRECTIONS
(No. CC-79-38)
No appearance by claimant.
Joseph C. Cometti, Assistant Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
314 REPORTS
STATE COURT OF CLAIMS [W. Va.
In October of 1977, hospital and
outpatient services were rendered by claimant to two inmates of respondent?s
Huttonsyule Correctional Center in the following amounts: Clarence Jenkins,
$5,872.55; and Billy Elkins, $4,205.16, for a total of $10,077.71.
Respondent, in its Answer, admits all the allegations of fact made in the
Notice of Claim, and further states that there were funds remaining in the
respondent?s appropriation at the close of the fiscal year in question from
which the claim could have been paid.
Based on the foregoing, an award in the above amount is hereby made to the
claimant.
Award of $10,077.71.
Optnion issued February 20, 1979
BARBARA H. SPITZER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-164)
Claimant appeared in person.
Nancy J. Miff, Attorney at law, for respondent. RULEY, JUDGE:
On September 29, 1977, the respondent repaired, and in part, relocated
Hollybush Road, a secondary road in Lincoln County, at a point where it adjoins
or passes through property owned by the claimant. As a result of damage to the
front yard of the claimant?s property, which the respondent neglected to
repair, the claimant was obliged to incur expense in the sum of $100.00. In
addition, the respondent made a cut approximately half way through, and thereby
killed, a black walnut tree upon the claimant?s property. It was neither shown
nor claimed by the respondent that it was necessary to cut the tree. The
claimant testified that the tree was approximately two and onehalf feet in
diameter and that its value was $200.00. For the
W. VA.]
REPORTS STATE COURT OF CLAIMS 315
foregoing reasons, it appears that an
award to the claimant in the sum of $300.00 should be made.
Award of $300.00.
Opinion issued February 28, 1979
SADIE JEAN AKERS and
THOMAS E. AKERS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-132)
Claimants appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
RULEY, JUDGE:
This property damage claim in the sum of $1,600.00 grows out of an accident
which happened at approximately 12:30 p.m. on May 5, 1978, on Hewitt Creek
Road, a secondary road in Boone County. At the time and place of the accident,
Hewitt Creek Road had a paved blacktop surface and was wide enough to
accommodate two lanes of vehicular traffic. On April 11 or 12, 1978, the
respondent had dug a ditch across the road, installed a drain pipe, and then
backfilled the ditch. In the interim between that date until the time of the
accident, the backfill settled, and on one or more occasions, additional
backfill material was placed in the ditch. The claimants? home was located
about one mile from the ditch. On the day of the accident, Mrs. Akers drove
from her home to a service station, crossing the ditch on one side of the road
uneventfully, and then began to return to her home. On the return trip, when
her 1970 model Plymouth traversed the ditch on the other side of the road, its
rear wheels caught. Remarkably, the wheels (along with their connecting
undercarriage) were torn free from the vehicle, causing its front end to swing
to the right and collide with a tree. According to the claimants? testimony,
the ditch at that place and on that side of the road was six to eight inches
deep, and the speed of the Plymouth, when it entered the ditch, was
approximately ten miles per hour.
316 REPORTS
STATE COURT OF CLAIMS [W. Va.
The respondent?s Boone County
Supervisor testified that he personally checked the ditch nearly five times
during the 23 or 24-day period between the date it was dug and the date of the
accident; that a foreman also checked it from time to time; that it was checked
at least once or twice every week; that, whenever it was found that the
backfill had settled, it again was leveled; and that it was re-paved on May 25,
1978. In addition, he testified that the only complaints about the ditch
received before May 5 were two or three telephone calls, the gist of which were
inquiries concerning re-paving and comments that the ditch was a little rough.
Although the backfilled ditch would appear to have a relatively high potential
for creating a dangerous condition, due to the propensity of backfill to settle
unevenly, it is not an inherently dangerous object. Its high risk potential
apparently was recognized, inasmuch as the respondent checked its condition
frequently and endeavored to keep the backfill even with the pavement, in view
of all of the evidence, the Court cannot conclude that the respondent was
guilty of negligence which proximately caused the accident, and, accordingly,
this claim should be denied.
Claim disallowed.
Opinion issued March 23, 1979
ARTHUR ADKINS, JR.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-83)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
Arthur Adkins, Jr. filed this claim against the Department of Highways in the
amount of $202.25 for damages to his 1973 Pontiac automobile.
W. VA.] REPORTS
STATE COURT OF CLAIMS 317
The accident occurred at 7:30 a.m. on October 21, 1977, on old West Virginia
Route 61 in Hansford, West Virginia, approximately 300 yards from the
claimant?s home. The road was 18? feet wide at the place of the accident. The
claimant was not in his automobile at the time; it was being driven by his
daughter-in-law, Sheila Adkins, who was not present to testify. Re-surfacing of
the road and drainage work beside the highway had just been completed. The
claimant stated that there was a drainage ditch beside the road 12 feet long
and 4 feet deep at its deepest point. He further related that his
daughter-in-law stopped his automobile for a school bus, and when she started
up again, she drove off the road into the ditch because the elevation of the
road prevented her from seeing where she was going.
Jerry Easter, an employee of the respondent, was called to the scene of the
accident. He testified that West Virginia Paving Company was doing the
re-surfacing and drainage work, and, in his opinion, neither the fresh blacktop
nor the drainage ditch presented a problem to approaching motorists. There is
no evidence in the record to show that the negligence of the respondent caused
the accident. Since negligence is not shown, and since the State is neither an
insurer nor a guarantor of the safety of motorists on its highways, Adkins v. Sims, 130 W.Va. 645, 46 S.E. 2d 81(1947), this claim is denied.
Claim disallowed.
Opinion issued March. 23, 1979
JACK D. BAILEY & BETTY LOUISE
BAILEY
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-49)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
This claim was filed against the respondent for damages sustained by a 1972
Ford Galaxy automobile registered in the
318 REPORTS
STATE COURT OF CLAIMS [W. Va.
name of the claimant, Jack D. Bailey.
The claimants lived on Sweeneysburg Road, about eight miles from Beckley, West
Virginia. The two-lane road is maintained by the respondent. On the morning of
December 15, 1977, at approximately 10:00 a.m., the claimant, Betty Louise
Bailey, was driving to Beckley on Sweeneysburg Road at 35 miles per hour. The
road was wet. Nearly a mile from her home, as she was entering a curve in the
road, she came upon a pickup truck belonging to the respondent parked on the
right-hand side of the road facing in her direction. She testified that the
wheels on the right side of the truck were on the highway. She further stated
that a dump truck of the respondent was approaching from the opposite direction
over the center line on the highway. The truck, proceeding slowly, returned to
its lane of traffic as she approached. Mrs. Bailey slowed down, applied her
brakes, and skidded into the dump truck. There were no signs or flagmen to warn
of the parked pickup truck. The highway was about fifteen feet wide, and the
width of the berm where the pickup was parked was about six feet.
The driver of the respondent?s dump truck, Gary Wayne Rollison, testified, ?I
seen her way ahead of the straightaway. So, I was slowing down. She was coming
around there pretty fast it seemed like to me. Now, when she come around that
pickup, she just looked at me and just got scared and laid on the brakes and
slid sideways and hit me. I had already put my truck in the ditch by that
time.? Mr. Rollison further testified that there were no flagmen because
respondent?s vehicle was not on the highway.
From the record, it is the opinion of the Court that claimants have not proved
by a preponderance of the evidence that the accident was caused by the
negligence of the respondent. Accordingly, the claim is disallowed.
Claim disallowed.
W. VA.]
REPORTS STATE COURT OF CLAIMS 319
Opinion issued March 23, 1979
R. L. JARRELL
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-172)
Claimant appeared in person without
counsel.
Henry Haslebacher, Attorney at Law, for respondent.
RULEY, JUDGE:
Although several residents of Greer Road, a secondary road in Mason County,
joined in filing this claim, only the claimant, R. L. Jarrell, appeared and
prosecuted his portion of it. His claim is for damage to his pickup truck and
station wagon allegedly caused during 1977 and 1978 by disrepair of a three-
mile stretch of Greer Road over which he was obliged to drive in order to reach
his home. In support of his claim, an invoice in the sum of $105.77 for repair
of the exhaust system on the truck, an estimate in the sum of $107.80 for
replacement of four heavy-duty shock absorbers on the truck, and an estimate in
the sum of $175.00 for repairs to the front end of the station wagon were
offered and admitted into evidence. Mr. Jarrell testified that from September,
1977, when he moved to Greer Road, until August, 1978, when it was re-surfaced,
the three- mile stretch of road was in such a state of disrepair that it took
approximately fifteen minutes to drive over it, for motorists had to stop almost
completely in order to negotiate the deeper holes. During that period of time,
Mr. Jarrell often complained to the respondent?s superintendent in Mason
County, but to no avail. The respondent offered no evidence. The evidence which
was adduced establishes negligence on the part of the respondent. The doctrine
of assumption of risk is asserted as a defense, but it is apparent that it has
no application, because it applies only when a claimant voluntarily elects to
travel over a dangerous route when an alternative safe route is reasonably
available. See Ratcliff v. Dept. of
Highways, 11 Ct. Cl. 291, at 293
(1977). It does not appear that the claimant was guilty of contributory
negligence by failing to exercise ordinary care for
320 REPORTS
STATE COURT OF CLAIMS [W. Va.
his own safety. As stated in 13B
Michie?s Jurisprudence ?Negligence?, ?24:
?The essence of contributory negligence is carelessness; of assumption of risk,
venturousness.?
There was no proof that the claimant was either careless or venturous. Mr.
Jarrell candidly conceded that approximately twenty-five percent of the
estimate for repairs to the front end of his station wagon should be charged to
use before he began to travel over Greer Road and that the truck?s shock
absorbers previously had 20,000 miles on them. For those reasons, the Court
believes that the sum of $291.42 would compensate him fairly for his damage,
and an award in that sum is hereby made. All of the other claims are dismissed
for failure to prosecute.
Award of $291.42.
W. VA.] REPORTS
STATE COURT OF CLAIMS 321
Opinion issued March 23, 1979
LIGHT GALLERY AND SUPPLY CO.
(No. CC-79-2)
ABBOTT LABORATORIES
(No. CC-79-3)
EHRENREICH PROTO-OPTICAL IND. INC.
(No. CC-79-4)
HUBBARD PUMP CO.
(No. CC-79-5)
AIR PRODUCTS AND CHEMICALS, INC.
(No. CC-79-6)
ACE GLASS, INC.
(No. CC-79-7)
FAIRMONT SUPPLY COMPANY
(No. CC-79-8)
WARREN ASSOCIATES
(No. CC-79-9)
THE CROCKER-FELLS COMPANY
(No. CC-79-1O)
STUART?S DRUG & SURGICAL SUPPLY INC.
(No. CC-79-14)
SYVA, INC.
(No. CC-79-18)
ROCHE LABORATORIES, INC.
(No. CC-79-19)
CUTTER LABORATORIES, INC.
(No. CC-79-28)
and
DIAGNOSTIC ISOTOPES, INC.
(No. CC-79-29)
vs.
BOARD OF REGENTS
No appearance by claimants.
Henry C. Bias, Jr., Deputy Attorney General, for respondent.
PER CURIAM:
These claims were submitted for decision based on the alle gation of the
Notices of Claim and the respondent?s Answers.
322 REPORTS
STATE COURT OF CLAIMS [W. Va.
Claimants herein seek compensation for goods furnished and services rendered to
West Virginia University. In its Answers, respondent admits the validity of
each claim, and states further that there were sufficient funds on hand at the
close of each fiscal year in question from which these claims could have been
paid.
Based on the foregoing, an award is hereby made to each of the claimants in the
following amounts:
Light Gallery and Supply Co. $
31.00
Abbott Laboratories $
637.72
Ehrenreich Photo-Optical md. Inc. $
388.95
Hubbard Pump Co. $ 20.89
Air Products and Chemicals, Inc. $
204.37
Ace Glass, Inc. $ 71.49
Fairmont Supply Company $
20.40
Warren Associates $ 23.20
The Crocker-Fells Company $
560.86
Stuart?s Drug & Surgical Supply Inc. $
757.16
Syva, Inc. $ 80.48
Roche Laboratories, Inc. $1,702.50
Cutter Laboratories, Inc. $1,248.00
Diagnostic Isotopes, Inc. $
81.60
Opinion issued March 23, 1979
GREGORY K. LIPSCOMB
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-48)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
RULEY, JUDGE:
Claimant, Gregory K. Lipscomb, filed this claim against the Department of
Highways in the amount of $200.00 for damages to his 1974 Alfa Romeo Veloce
automobile sustained on Feb
W. VA.] REPORTS
STATE COURT OF CLAIMS 323
ruary 15, 1978. At approximately 11:30 p.m., the claimant was driving his
automobile at 45-50 miles per hour southbound on Corridor G, also known as
Route 214, between MacCorkle Ayeiue and Oakwood Road in Charleston, West
Virginia. The road is a four-lane highway. At the intersection of Route 214 and
Hickory Road, the claimant encountered ice on both southbound lanes. He lost
control of his automobile and slid sideways into the median strip where his
automobile was damaged by ice and snow piled there.
Claiman.t testified that he drove this road two to four times a day and that he
had noticed ice on the road before, but not to the extent found at the
accident. He further stated that on the night of the accident, there was ice
and snow along the highway, but none on the roadway, except at the accident
scene. No evidence was introduced to prove knowledge, either actual or
constructive, that respondent was aware of the ice on the highway. The law is
well established in West Virginia that the State is neither an insurer nor a
guarantor of the safety of persons traveling on its highways. Adkins v. Sims,
130 W.Va. 645, 46 S.E. 2d 81(1947); Jeter
v. Dept. of Highways, 11 Ct. Cl. 154
(1976). Before the respondent can be held liable, there must be some showing
that the respondent knew or should have known of the existence of ice on the
highway. See Keith v. Dept. of
Highways, 12 Ct. Cl. 199 (1978).
Accordingly, the Court disallows this claim.
Claim disallowed.
Opinion issued March 23, 1979
HAROLD L. WEBER, JR.
vs.
DEPARTMENT OF HEALTH
(No. CC-78-270)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
324 REPORTS
STATE COURT OF CLAIMS [W. Va.
Claimant seeks payment of the sum of
$10,144.22 for overtime worked during calendar years 1976 and 1977.
In its Answer, the respondent admits that the claimant is entitled to be
compensated for the overtime in the amount of $9,791.91, as evidenced by
letters from the Department of Health.
In a recent decision by this Court, involving three other overtime claims
against the Department of Health, the Court held that payments on accounts for
personal services would not be denied, even though such payments were incurred
during a previous fiscal year wherein said agency expended all of the funds in
its personal services account. Jack L.
Rader et al. vs. Department of Health (CC-78-223).
Based on the foregoing, an award in the amount of $9,791.91 is hereby made to
the claimant.
Award of $9,791.91.
Filed with Court of Claims on March 29,
1979
BLACK ROCK CONTRACTING, INC.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-76-9)
ORDER AND STIPULATION
This day came Black Rock Contracting,
Inc., claimant, by Charles L. Woody, its attorney, and came the West Virginia
Department of Highways, State of West Virginia, respondent, by Stuart Reed
Waters, Jr., its attorney, and jointly represented to the Court, that in view
of the Opinion of the Court heretofore filed in deciding the claims of Vecellio
& Grogan, Inc., vs. Department of Highways, covering Claims No. D-914,
D993, D-918 Par. C, in which the factual situation and the law applicable
thereto were the same as that involved in the above styled case, the parties have
agreed upon a stipulation to be filed in the above-styled action as follows:
It is hereby stipulated and agreed by and between Black Rock Contracting, Inc.,
claimant, and the West Virginia De
W. VA.]
REPORTS STATE COURT OF CLAIMS 325
partment of Highways, State of West
Virginia, respondent, that the claimant is entitled to recover from the
respondent, the West Virginia Department of Highways, State of West Virginia,
the following sum of money on the following item alleged in its Notice of Claim
under Item I, Presplitting Technique, 6,519 cubic yards, at $1.03 per cubic
yard, $6,714.57.
It is further stipulated and agreed by and between the claimant and the
respondent hereto that all other items of claim and the parts of the above set
out and described item of claims not agreed to be paid in this stipulation, as
set out and alleged in claimant?s Notice of Claim filed in this action, are to
be disallowed and not considered by the Court for any award and are to be
dismissed.
Upon consideration of the claimant?s and the respondent?s representations, the
Opinion of the Court heretofore filed in deciding the claims of Vecellio &
Grogan, Inc., vs. Department of Highways, covering Claims No. D-914, D-993,
D-9l8 Par. C, and the stipulation set out aforesaid, the Court is of the
opinion to and does sustain the same and the same are hereby received, filed,
and accepted; and it is hereby further ordered that the claimant be, and it is
hereby granted an award against the respondent for the following sum on the
following item:
Presplitting Technique 6,519 cy at $1.03 $6,714.57
Interest at the rate of 6% per annum on
$6,714.57, from September 23, 1975, to February
1, 1979, in accordance with Chapter 14,
Article 3, Section 1 of the Official Code of
West Virginia, 1931, as amended. $1,353.22
Total Award $8,067.79
It is hereby further ordered that all other items of claim and the parts of
claims set out and alleged in claimant?s Notice of Claim, which were not
allowed in the above award, are hereby disallowed.
ENTER:
John B. Garden
Judge
326 REPORTS STATE
COURT OF CLAIMS [IV. Va.
APPROVED BY:
BLACK ROCK CONTRACTING, INC.
claimant,
By: Charles L. Woody
Its Counsel
WEST VIRGINIA DEPARTMENT OF
HIGHWAYS, STATE OF WEST VIRGINIA,
respondent,
By: Stuart Reed Waters, Jr.
Its Counsel
Opinion issued April 10, 1979
LAWRENCE & CLAUDETTE FERGUSON
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-100)
Claimants appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim, in the amount of $86.95, was filed against the Department of
Highways by the claimants for damages sustained by their 1978 Delta 88
Oldsmobile automobile.
On January 27, 1978, at approximately 7:00 p.m., the claimants were
traveling westerly on U. S. Route 60 just west of Montgomery, West Virginia.
The claimant Lawrence Ferguson was driving at approximately 40 to 45 miles per
hour. It was dark, and the road was clear. As they were proceeding around a
curve, the automobile struck a pothole in the high.. way, damaging a tire,
rims, and hubcaps. Mr. Ferguson testified that he had seen other potholes prior
to the accident and that he saw the one he struck just prior to the accident,
but
W. VA.]
REPORTS STATE COURT OF CLAIMS 327
was unable to stop or miss it because
of the traffic behind him.
The consistent position of the Court with respect to cases involving alleged
highway defects is set out in the case of Parsons v. State Road Comm?n., 8
Ct. Cl. 35 (1969), wherein the Court stated in part as follows: ?This Court has
many times held that the State is not a guarantor of the safety of its
travelers on its roads and bridges. The State is not an insurer, and its duty
to travelers is a qualified one; namely, reasonable care and diligence in the
maintenance of a highway under all the circumstances.? The case of Adkins v. Sims, 130 W.Va. 645, 46 S.E. 2d 81 (1947) holds that the user of the highway
travels at his own risk and that the State does not and cannot assure him a
safe journey. The maintenance of highways is a governmental function, and funds
available for road improvements are necessarily limited.
There is no evidence in the record that the respondent had notice of the
pothole prior to the accident, and the existence of a defect in the road does
not establish negligence per se. See Bodo
v. Dept. of Highways, 11
Ct. Cl. 179 (1977) and Light v. Dept.
of Highways, Claim No. CC-77-53.
Accordingly, the Court is of the opinion to and does disallow this claim.
Claim disallowed.
Opinion issued April 10, 1979
KAREN HALLER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC?77-123)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant filed this claim against the respondent for medical and dental
expenses incurred as the result of an accident on August 16, 1975. Damages to
her automobile were recovered from insurance.
328 REPORTS
STATE COURT OF CLAIMS [W. Va.
About 9:00 p.m. on the evening of the
accident, the claimant left her home in Montrose, West Virginia, in Tucker
County, to go to Saint George to visit friends. She was driving her 1972 Ford
Pinto automobile. It had rained heavily for about three hours. On her return
from Saint George, she was proceeding on Route 21 approximately two and
one-half miles from her home. As she approached the intersection of Local
Service Route 17, she started to make a left-hand turn and encountered water
across the road. Applying the brakes, she was unable to stop, and struck a
portion of the road where a culvert had washed out. The impact caused her head
to hit the windshield and steering wheel. She suffered injuries to her teeth
and knee. A companion with her received injuries to his teeth and knees. After
the accident, she and her friend opened the door of the automobile, climbed
over the hood, and walked to a neighbor?s house. They were taken to Tucker
County Hospital in Parsons, West Virginia. Later, her mother took them to the
University Hospital at West Virginia University. The claimant testified that
she was familiar with the road and that the culvert was not blocked two days
before the accident.
Jesse Roy, an employee of the respondent, was County Supervisor of Tucker
County at the time of the accident. He testified that on the night of the
accident, it was raining very hard and there were flooding conditions. The
Chief of Police of Parsons notified him of the accident and told him that signs
were needed. He proceeded to the accident scene, put out signs, and closed
Route 21. The only way to cross the washed out area of the road was to use the
car as a bridge. The water was swift. Roy further testified that no complaints
had been received indicating that that particular culvert was out of shape,
filled with debris, or would not carry water. He stated that heavy rains can
wash timber cuttings and other debris down from the hills and block the
culverts.
From the evidence, there is no showing that the respondent knew or should have
known that there was a clogged culvert or other defect causing the flooding of
the highway, nor was there a showing that the respondent was negligent in
permitting the partial flooding of the highway. See Varner v. Department of Highways, 9 Ct. Cl. 219 (1973). The State is not a
W. VA.]
REPORTS STATE COURT OF CLAIMS 329
guarantor of the safety of travelers
on the highways, and the user of the highways travels at his own risk. See Parsons v. State Road Commission,
8 Ct. Cl. 35 (1969); Adkins v. Sims, 130 W.Va. 645, 46 S.E. 2d 81(1947).
For the reasons herein stated, the Court disallows claimant?s claim.
Claim disallowed.
Opinion issued April 10, 1979
JAMES RYAN & JOYCE RYAN
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-77-189)
Arthur M. Recht, Attorney at Law, for claimants.
Henry Haslebacher, Attorney at Law, for respondent.
GARDEN, JUDGE:
In the afternoon of March 20, 1977, the claimants were returning to their home
in Wheeling from a weekend trip to Spruce Knob. They were travelling west on
Interstate 70 in Ohio County, West Virginia, and were approaching what is
commonly referred to as the Dallas Pike Interchange. The claimant James Ryan
was driving a 1976 Honda automobile which was owned by his wife, the claimant
Joyce Ryan. Interstate 70 at and near the scene of the accident is a typical
interstate highway with two lanes for westbound traffic and two lanes for
eastbound traffic, the westbound and eastbound lanes being separated by a wide
median strip. While the weather was overcast, the roads were dry, and the
claimant James Ryan testified that he was travelling 55 miles per hour and was
proceeding in the curb or right-hand lane of the two westbound lanes.
James Ryan testified that traffic was heavy and that there were cars
continually passing them on the left or in the passing lane. Suddenly the Honda
struck a large broken section of
330 REPORTS STATE
COURT OF CLAIMS [W. Va.
the right-hand lane. Ryan testified that the broken section covered the entire
right-hand lane and was at least ten feet in length and covered the entire
width of the curb lane. As a resuit of striking this defective section of the
highway, the Honda turned over and left the highway, landing on its roof on the
berm to the right of the westbound lanes. Both claimants testified that neither
of them observed any warning signs indicating that they were approaching a
section of broken pavement, nor were there any barricades erected which would
have prevented motorists from striking the broken pavement.
As a result of the accident, both claimants were taken by ambulance to the
emergency room at Wheeling Hospital. Mr. Ryan was x-rayed for possible broken
ribs, but the x-rays were negative for any fractures. He testified that he had
a pain in his chest and that the next day he experienced pain in his neck. As a
result of the neck pain, he made an appointment with an orthopedic specialist
in Wheeling. His appointment with the doctor could not be arranged until June
30, 1977, and by that time, Mr. Ryan testified that he had recovered from his
neck injury; nevertheless, he was examined by the doctor, who was of the
opinion that he has recovered from all of his injuries. Mr. Ryan also testified
that after the accident he experienced some ringing in his ears and consulted
another doctor for this condition. The ringing sensation eventually
disappeared, and we believe it is clear that Mr. Ryan suffered no permanent
injuries as a result of the accident. The total medical expenses incurred by
Mr. Ryan, including ambulance servi?e, amounted to $191.20.
The claimant Joyce Ryan, on the other hand, was more seriously injured,
although not extensively, in the form of injury to her teeth. She was taken by
ambulance to Wheeling Hospital, and although she was experiencing pain in her
neck, she was not x-rayed, but simply treated for bruises. Mrs. Ryan testified
that about ten years prior to the accident, she had fallen and chipped two of
her upper right front teeth which were capped by Dr. John G. Kramer of Martins
Ferry, Ohio. As a result of the accident, her upper right central incisor was
fractured and was surgically removed by an oral surgeon. Dr. Kramer then fitted
her with a temporary partial denture, and,
W. VA.] REPORTS
STATE COURT OF CLAIMS 331
at a later date, a permanent partial denture. At the hearing, Mrs. Ryan
testified that she was not suffering any pain but was concerned about her
appearance from a cosmetic standpoint. In addition to the damage to her
automobile, which was stipulated by counsel to be in the amount of $2,930.00,
she incurred medical and dental expenses in a total amount of
$825.00.
Edward L. Schafer, respondent?s superintendent for Interstate 70 in Ohio
County, testified that he was aware of the condition of this particular section
of interstate, and he was of the opinion that the breakup of the concrete
surface was due to the unstable condition of the ground below the surface of the
highway. He was not certain as to when he first became aware of the condition,
but upon receiving complaints, he had begun a program of filling the defective
section with blacktop until permanent repairs could be effected. He described
the broken- up section as rectangular in shape, covering a width of 10 feet of
this 12-foot lane of traffic and a length of about 5 feet. He testified that on
at least seven or eight occasions prior to the Ryan accident, this particular
section of the road was filled with blacktop. Wilbur J. Breiding, an employee
of the sign department of respondent in Ohio County, testified that on April 9,
1976, he and a crew of three installed a sign displaying the word ?BUMP? within
about 1,000 feet to the east of this defective area of the roadway, the purpose
of which was to warn approaching motorists of the existence of what we deem to
have been a dangerous condition.
We have consistently held that the respondent is not an insurer of the safety
of the travelling public using its highways, but we also have held that the
respondent is under a duty to exercise reasonable care to maintain the highways
of this State in a reasonably safe condition and to warn motorists of any
defects or impending dangers in the highways. To knowingly permit this
dangerous condition to remain in varying degrees of defectiveness for a period
of at least 11 months prior to the Ryan accident, and to fail to take more
effective action to warn motorists of the condition of this highway, in our
opinion, constitutes negligence. Believing that such negligence was the
proximate cause of the Ryans? accident and their resulting iii-
332 REPORTS
STATE COURT OF CLAIMS [W. Va.
juries, we hereby make awards in favor
of James and Joyce Ryan in the amounts of $800.00 and $6,250.00, respectively.
Award of $800.00 to James Ryan and
Award of $6,250.00 to Joyce Ryan.
Opinion issued April 10, 1979
PATTY SHEETS, ADMINISTRATRIX
OF THE ESTATE OF RAY SAMUEL SIX, DECEASED
vs.
DEPARTMENT OF HEALTH,
DIVISION OF MENTAL HEALTH
(No. CC-76-80)
Michael S. Francis and David
Underwood, Attorneys at Law, for
claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. WALLACE,
JUDGE:
Patty Sheets, as Administratrix of the Estate of Ray Samuel Six, deceased,
filed this claim against the respondent for damages as the result of the death
of Ray Samuel Six. Patty Sheets, a daughter of the deceased, lived with her
family at Star Route 1, Littleton, West Virginia. The decedent also lived in
Littleton with his wife, another daughter, and her son. He was a large man in
his early 70?s. He retired from his employment with the Baltimore & Ohio
Railroad in 1950 due to a disability.
On July 17, 1975, he was referred to Dr. Jose Mendoza, Director of the Northern
Panhandle Mental Health Center in Wheeling, West Virginia, by the director of
mental health in New Martinsburg for examination and commitment to Weston State
Hospital. He was brought to Dr. Mendoza?s office in an ambulance under
restraint. Dr. Mendoza?s diagnosis was that of ?an old man in his 70?s, very
confused, disoriented? suffering from ?organic brain syndrome due to
arteriosclerosis .
. or dementia?. Dr. Mendoza prescribed
that the decedent be hos
W. VA.]
REPORTS STATE COURT OF CLAIMS 333
pitalized at Weston State Hospital
with subsequent transfer to a nursing home. He was admitted to the hospital on
July
18, 1975.
The claimant testified that she was very close to her father and that she had
had him over for dinner on July 16, 1975. She did not know he was committed to
the hospital until noon on July 18. Although she tried, she did not see him
again until his admission to the University Hospital at West Virginia
University on July 23, 1975. She further testified that she believed that her mother
and sister had referred her father to Dr. Mendoza, and that the ?people around
town knew he had hardening of the arteries?. On July 20, he was treated by Dr.
Baldonado Hao, staff physician at the Weston hospital, for a superficial
scratch on the left middle finger of his left hand, which he received while
attempting to jump the fence. Dr. Hao ordered 24-hour mechanical restraints
because the patient was ?agitated and unmanageable, confused, disoriented, and
combative?. Later, Mr. Six was referred to Dr. Hao for treatment of diarrhea
and fever. At 8:00 a.m. on July 21, she examined him for injuries received when
he fell against the wall of his room. He received a hematoma, contusion, and
ecchymosis around the left eye. She prescribed ice compress on the eye and
medication for the inflammation. She further ordered x-rays of the eye and
skull and ordered him transferred to the medical center at the hospital. During
the examination, he did not respond, and was very confused and out of contact
with reality.
At the time Mr. Six fell, he was attended by two aides, Nellie Bell Watson and
James Meyers. He was in a private room furnished with two beds, a chest of
drawers, and a potty chair. He was suffering from a severe case of diarrhea.
The aides changed his bed four times the night of his fall. Just prior to his
injury, the two aides had untied the restraints, washed and cleaned the
patient, and sat him down on the potty chair while they changed the bed. Meyers
was behind the bed, and Mrs. Watson was on the other side with her back to the
patient. Mr. Six, unsteady on his feet, jumped up from the chair and went out
into the hail. The aides found him standing in the hail and led him back to the
room.
334 REPORTS STATE
COURT OF CLAIMS [W. Va.
Mrs. Watson explained what happened.
?When we got in the bedroom and got inside the door, he was jerking trying to
get away from us, you know, and we was trying to hold on to him. Mr. Meyers
went in the door first, and then Mr. Six he had hold of his arm, and I had hold
of his other arm. Then I came on in and just as I got inside the door, he
hauled off and gave me a jerk and slung me over in the corner into the chest of
drawers, just like a whirligig . . . When I
turned back around, Mr. Meyers didn?t have ahold of him, and he went staggering
and he fell into the wall and hit his head against the wall . . . Mr. Meyers was standing over from Mr. Six and he didn?t
have ahold of Mr. Six when I turned around. Mr. Six was very unsteady on his
feet, and he stumbled, and he went into the wall, hit his head against the?I
call it the door facing.?
Mrs. Watson further responded.
?Q. Meyers try to restrain him with force?
A. Meyers just tried to hold onto his arm same as I did
to keep him from falling and to try to get him back into his room.
Q. Didn?t he grab him by the arm and shake him?
A. No. He didn?t shake him.?
During the hearing, the hospital employees were questioned about Mr. Meyers?
treatment of the patients. Apparently, there were rumors about Mr. Meyers, but
that was the extent of the testimony. Mrs. Watson testified that, because of
the rumors, she asked that she not be assigned to work with him again. She also
stated that ?.
. . He seemed like a nice somebody to work
with. He helped me good. I have no complaint about his working or helping me,
and I never heard him say anything out of the way to any of the patients that
night whatsoever.?
The record indicated that Mr. Meyers was reported for insubordination and later
discharged.
Mr. Six was transferred to the University Hospital at West Virginia University
on July 23, 1975. Dr. G. Robert Nugent
W. VA.] REPORTS
STATE COURT OF CLAIMS 335
attended him at the University Hospital. He stated that he was agitated and
confused; that he would talk when made to talk, but didn?t make sense.
Mr. Six?s condition deteriorated, developing into pneumonia, which is a common
problem with elderly people injured in falls. Mr. Six died on August 8, 1975.
Patty Sheets testified that, while in the University Hospital, her father, in
response to a question as to what happened to him, responded, ?They beat me?.
After completion of the testimony, respondent?s objection to this testimony was
withdrawn. However, the record does not establish that there was a physical
beating of the decedent.
The claimant relied upon the doctrine of res ipsa loquitur to establish
liability, which doctrine the Court finds is not applicable to this case. The
doctrine of res ipsa loquitur cannot be invoked where the existence of
negligence is solely a matter of conjecture and the circumstances are not
proved but must themselves be presumed, or when it may be inferred that there
was no negligence on the part of the defendant. The doctrine applies only in
cases where defendant?s negligence is the only inference that can reasonably
and legitimately be drawn from the circumstances. Davidson?s Inc. v. Scott, 149 W.Va. 470, 140 S.E. 2d 207 (1965); MuUins v. Board of Governors of W. Va.
University, 8 Ct. Cl. 33 (1969). The
testimony is unrefuted that the decedent fell after freeing himself from the
hospital aides and received injuries resulting in his ultimate death. The Court
finds that the claimant has failed to prove by a preponderance of the evidence
that the injury and subsequent death of the decedent were caused by the
negligence of the respondent. Accordingly, the claim is disallowed.
Claim disallowed.
336 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued April 10, 1979
CHARLES H. SPRADLING, JR.
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-68)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
This claim against the respondent, in the amount of $117.62, was filed by the
claimant for damage sustained by an automobile he was driving.
On January 22, 1978, at approximately 11:45 a.m., the claimant, driving a 1973
Vega automobile belonging to one Betty Slater, entered 1-64 and 1-77 at the
Washington Street ramp in Charleston, West Virginia. It was cold and the road
was clear. There was an automobile beside him, but no one was directly in front
as he approached the highway at 30-35 miles per hour. The front end of the
automobile went into a hole. The claimant testified that he heard a scraping
noise on the bottom of the vehicle, after which the transmission ceased to function
and the transmission fluid leaked out. The claimant further stated that he
returned to the scene of the accident the next day and found that a piece of
steel, four inches wide, was sticking up about five inches in the middle of the
hole. After the accident, he had the automobile repaired and returned it to the
owner.
Robert Glen, a foreman for the respondent, testified that a courtesy patrol
driver reported that equipment being operated by the Union Boiler Company
caught the end of an expansion joint in the highway and lifted it above the
road surface. The Union Boiler Company was employed by the respondent to assist
in the removal of piles of snow from the highway. Glen stated that the
notification from the patrol driver was received at approximately 10:00 a.m. on
January 22, the morning of the accident. Although the testimony is not clear,
Glen apparently went to the scene with other employees of the re
W. VA.] REPORTS
STATE COURT OF CLAIMS 337
spondent and with sledge hammers beat back the expansion joint, returning to
the office by lunch time.
The claimant testified that the accident occurred at approximately 11:45 a.m.
Mr. Glen testified that repairs were made after 10:00 a.m. Spradling also stated that the piece of steel was still there the
next day.
However conflicting the testimony, general principles of tort and agency law
require that the Court find the respondent liable. The Union Boiler Company, as
agent for the respondent, damaged the expansion joint, and negligently failed
to make any effort to notify the respondent or to warn motorists. Any such
effort could have prevented the damage to the car. ?Where an agent acts
negligently in the regular course of his employment, the law is well settled
that the principal must bear the consequences of his agent?s negligence * * s?. 1A M.J. Agency
?86. The contractor negligently
performed his appointed task; the respondent is therefore liable. Bubar v. Dept. of
Highways, 12 Ct. Cl. 204 (1978).
The damage was sustained by an automobile belonging to Betty Slater. The
claimant was the bailee of the automobile. ?A bailee in possession may sue for
and recover judgment for the wrongful damage or destruction by another of the
bailed property. This principle applies to a gratuitous bailee, as well as to a
bailee for hire.? Petrus v. Rcibbins, 196 Va. 322, 83 S.E. 2d 408 (1954), 2B M. J. Bailments ?8.
Accordingly, the Court makes an award to the claimant in the amount of $117.62.
Award of $117.62.
338 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued June 13, 1979
CAPITOL BUSINESS INTERIORS,
DIVISION OF CAPITOL BUSINESS EQUIPMENT, INC.
vs.
DEPARTMENT OF FINANCE & ADMINISTRATION
(No. CC-79-60)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $141.00 for wire hanger clips purchased by
the respondent on or before July 30, 1975. Respondent was billed on September
12, 1975, but made no payment to the claimant.
In its Answer, the respondent admits the validity of the claim and states that
there were sufficient funds on hand at the close of the fiscal year in question
from which the claim could have been paid.
Based on the foregoing, an award in the amount of $141.00 is hereby made to the
claimant.
Award of $141.00.
Opinion issued June 13, 1979
DREMA D. GREENLEE and
STEPHEN E. GREENLEE
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-79-70)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for dam-
W. VA.] REPORTS
STATE COURT OF CLAIMS 339
ages in the sum of $54.00, based upon the following facts: On or about January
15, 1979, claimants were driving across the Shadle Bridge in the vicinity of
Point Pleasant, in Mason County, West Virginia. While claimants were crossing
the bridge, which is owned and maintained by the respondent, a piece of floor
decking punctured claimants? left rear tire. Being of the opinion that the
stipulation establishes legal liability on the part of the respondent, and that
the sum of $54.00 is a fair and equitable estimate of the damage sustained by
the claimants, an award in the above amount is hereby made.
Award of $54.00.
Opinion issued June 13, 1979
HECK?S, INC.
vs.
DIVISION OF VOCATIONAL REHABILITATION
(No. CC-79-36)
No appearance by claimant.
Henry C. Bias, Jr., Deputy
Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $245.56 for unpaid bills representing
small purchases made by the respondent between June, 1974 and April, 1976. In
its Answer, respondent admits the validity of the claim and further states that
there were sufficient funds on hand at the close of the fiscal years in
question from which the claims could have been paid.
Based on the foregoing, an award in the amount of $245.56 is hereby made to the
claimant.
Award of $245.56.
340 REPORTS
STATE COURT OF CLAIMS [W. Va.
Opinion issued June 13, 1979
JAMES C. MACKNIGHT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-144a)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, James C. MacKnight, filed this claim against the respondent for
damages to his 1977 Ford Pinto automobile.
Early in the afternoon of April 23, 1978, the claimant was driving his
automobile on Route 3 south of New Haven, West Virginia, at approximately 35
miles per hour. It was cloudy and the road was wet. As he proceeded over a
small rise in the highway, he came upon a hole in the road. In an attempt to
miss the hole, he veered to the right onto the berm of the highway. The right
front wheel struck the hole, damaging the tire and rim.
In order for negligence on the part of the Department of Highways to be shown,
proof that the respondent had actual or constructive notice of the defect in
the road is required. Light v. Dept. of Highways, 12 Ct. Cl. 61; Lowe
v. Dept. of Highways, 8 Ct. Cl. 216
(1971). There is no evidence in the record of notice to the respondent. The
State is neither an insurer nor a guarantor of the safety of persons travelling
on its highways. Adkins v. Sims, 130 W. Va. 645, 46 S.E. 2d 81 (1947). Accordingly, the
Court disallows this claim.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF? CLAIMS 341
Opinion issued June 13, 1979
JAMES C. MACKNIGHT
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-144b)
Claimant appeared in person.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim, originally filed against the respondent by Frances J. MacKnight,
was amended by the Court substituting James C. MacKnight, husband of Frances J.
MacKnight, as claimant.
On or about May 1, 1978, Frances J. MacKnight was driving her husband?s 1977
Ford Pinto automobile southerly on W.Va. Route 62 in Mason County, West
Virginia, taking her daughter to band practice at the high school. The weather
was clear and the highway was dry. She had stopped at the traffic light located
at the Pomeroy Mason County Bridge, and had started again, proceeding at
approximately 15-20 miles per hour. Just before she reached the high school,
the automobile struck a pothole in the highway, damaging a tire and rim.
Mrs. MacKnight testified that she travelled this road five to six times a week
and that she knew the hole was there.
This Court has held many times that the State is not a guarantor of the safety
of its travellers on its roads and that the user of the highways travels at his
own risk. Adkins v. Sims, 130 W.Va. 645, 64 S.E. 2d 81 (1947); Parsons v. State Road Comm?n., 8 Ct. Cl. 35 (1969). Further, the record does not
establish that the respondent had notice of a defect in the highway. For the
State to be found liable, it must have had either actual or constructive notice
of the defect in the highway. Keith v.
Dept. of Highways, 12 Ct. Cl.
199; Bradshaw v. Dept. of Highways, 12 Ct. Cl. 187.
Accordingly, the Court disallows this claim.
Claim disallowed.
342 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued June 21, 1979
LEWIS DALE METZ, Claimant
vs.
WEST VIRGINIA STATE BOARD OF
PROBATION AND PAROLE; TO WIT:
ITS AGENTS ?
MALCOLM LOUDEN, Chairman-Member,
and LINDA MECKFESSEL, Member-Secretary,
and
WEST VIRGINIA DEPARTMENT OF CORRECTIONS;
TO WIT: ITS AGENTS ?
STEWART WERNER,
Commissioner, and BOB WILLIS,
Parole Officer, Respondents.
(No. CC-77?155)
Ernest M. Douglass, Attorney at Law, for claimant.
Frank M. Ellison, Deputy Attorney General, for the respondents.
PER CURIAM:
This claim is before the Court, at this time, upon the respondents? motion to
dismiss.
The claimant, who initially was not represented by counsel, has filed a claim
in the sum of $5,000.00 for damages allegedly sustained as the result of the
alleged unlawful revocation of his probation on May 17, 1977, and his
subsequent confinement at Huttonsville Correctional Center until August 19,
1977, when he was released upon a writ of habeas corpus issued by the Circuit
Court of Kanawha County.
The basis of the motion to dismiss is that the claimant has an adequate remedy
at law in the federal courts under the Civil Rights Act, 42 U.S.C. ?1983. The
fact that a claimant might possibly have some other remedy or resource never
has been held to be a bar or defense to the prosecution of a claim in this
Court, but, upon occasion, proceedings in this Court have been stayed pending
the outcome of a companion legal action. In addition, while in the Notice of
Claim reference
VA.] REPORTS
STATE COURT OF CLAIMS 343
is made to various constitutional
provisions which might be viewed as indicating the basis for assertion of a
claim under the Civil Rights Act, it also may be viewed as asserting a claim
based upon the common law tort of false imprisonment.
The position of the respondents upon their pending motion to dismiss appears to
be somewhat confused. On the one hand, it is asserted in their behalf that the
claimant has an adequate remedy at law against them and that they are subject
to prosecution in the federal courts under the Civil Rights Act. On the other
hand, it is asserted in respondents? brief that they are immune from
prosecution, such immunity being based on the quasi-judicial nature of their
duties. The confusion arises from the circumstance that they cannot be both
subject to prosecution and immune from prosecution. In any case, examination of
those subjects by this Court appears to be wholly unnecessary because the Civil
Rights Act applies only to ?persons? who, acting under color of law, violate
another?s Constitutional rights, and a superficial examination of authorities
indicates that a state agency, such as those designated as respondents in this
case, is not a ?person? within the meaning of that act. See 42 U.S.C.A. ?1983,
Notes 129, 131 and 135.
For the foregoing reasons, the motion to dismiss is denied as to the
respondents, the West Virginia Board of Probation and Parole and the Department
of Corrections.
Of course, this Court has only such jurisdiction as is conferred upon it by
statute, as delineated by West Virginia Code, ?14-2-13, and limited by
?14-2-14. ?14-2-13 provides:
?14-2-13. Jurisdiction of the Court.
The jurisdiction of the court, except for the claims excluded by section
fourteen [14-2-14], shall extend to the following matters:
1. Claims and demands, liquidated and unliquidated, ex contractu and ex
delicto, against the State or any of its agencies, which the State as a
sovereign commonwealth should in equity and good conscience discharge and pay.
2. Claims and demands, liquidated and unliquidated,
344 REPORTS
STATE COURT OF CLAIMS [W. Va.
ex contractu and ex delicto, which may
be asserted in the nature of setoff or counterclaim on the part of the State or
any state agency.
3. The legal or equitable status, or both, of any claim referred to the court
by the head of a state agency for an advisory determination.?
It is clear from that statute that this Court has no jurisdiction over any
individual person, and the claim must be, and is hereby, dismissed as to the
individual persons named as respondents.
Accordingly, as heretofore stated, the Court grants the motion to dismiss as to
the following individuals: Malcolm Louden, Linda Meckfessel, Stewart Werner,
and Bob Willis, and overrules the motion to dismiss as to the following
agencies: West Virginia State Board of Probation and Parole and West Virginia
Department of Corrections.
Opinion issued June 30, 1979
ARNOLD W. BOLYARD
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-1)
Randy Goodrich, Attorney at Law, for claimant.
Henry Haslebacher, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Arnold W. Bolyard, seeks compensation for the total loss of his
automobile, which occurred when he collided with a large boulder on U.S. Route
119 between Clendenin and Elkview, West Virginia.
The accident happened at approximately 5:00 a.m. on the morning of August 15,
1977. The claimant was driving in the southbound lane of the highway in his
1969 Oldsmobile Delta 88 automobile at about 35 mph. It was dark and moderately
foggy. The road was dry and relatively straight. There was an automobile
approaching from the opposite direction in the northbound lane. The claimant
testified that he switched his
W. VA.]
REPORTS STATE COURT OF CLAIMS 345
headlights from high to low beam, and,
after the automobile passed, he switched back to the high beam, at which time
he saw a boulder immediately ahead in the highway. He applied the brakes,
skidded approximately 30 feet, and crashed into the boulder. The claimant
further testified that he was told by members of a family living next to the
highway that it was the practice of the local substation of the Department of
Highways to supply the family with flares to warn motorists of rock slides.
Mr. Gary Huffman, a foreman employed by the respondent, testified that during
his three-year tenure at the substation, he had no personal knowledge of any
such procedure.
The section of Route 119 at which the accident took place is similar to
stretches of highway throughout the State which are flanked by steep rock
cliffs. Mr. Huffman, in his testimony, admitted that rock slides had occurred
in the area, but there had been no notice of an impending rock fall. There was
a ?Falling Rock? sign posted approximately 100 yards north of the scene of the
accident.
There is no evidence that the respondent knew or should have known of the
existence of an unusually dangerous condition which would render a mere warning
insufficient. Smith
v. Dept. of Highways, 11 Ct. Cl. 221
(1977). It is apparent from the evidence that the boulder had fallen just prior
to the accident. In fact, the claimant testified that he was ?very positive? he
was ?the first car there.?
The law of West Virginia is well established that the State is neither an
insurer nor a guarantor of the safety of persons travelling on its highways. Adkins v. Sims, 130 W.Va. 645, 46 S.E.2d 81 (1947). ?As the State is not an insurer of
the safety of those travelling on the public roads, anyone injured or who
sustains damage must prove that the State has been negligent in order to render
the State liable.? Hanson v. State
Road Comm?n. 8 Ct. Cl. 100 (1970).
The record does not establish negligence on the part of the respondent, and,
accordingly, the Court disallows the claim.
Claim disallowed.
346 REPORTS STATE
COURT OF CLAIMS [W. Va.
Opinion issued June 30, 1979
LAWRENCE CHILDERS
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-63)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
This claim arises out of an automobile accident which occurred at 5:30 a.m. on
February 17, 1978, on U.S. Route 50 west of Clarksburg, West Virginia,
approximately one-half mile east of the junction of Routes 50 and 23. The
claimant, driving his 1969 Cadillac Fleetwood automobile, was proceeding
westerly from his home in Clarksburg to his place of employment at the Willow
Island power station in St. Marys, West Virginia. He was accompanied by two
sleeping coworkers. It was dark, the weather was clear, and the four-lane
highway was dry.
The claimant testified that he was travelling at approximately 55 mph and that,
as he crested a slight knoll on the highway, his headlights shone on what h
perceived to be a brown grocery bag lying approximately 100 feet in front of
his vehicle in the center of the right-hand lane. He was unsure whether any
automobiles were beside him in the passing lane. He slowed to a speed of 40 mph
and chose to straddle the unknown object on the highway. Unfortunately, the
object was a large rock, which, when struck, caused an estimated $649.20 in
damages to the underside of the automobile. The claimant further testified that
he had driven this route every morning of the week prior to the accident and
had not previously encountered any rocks on the highway in the area in
question.
Marshall Bobbitt, a foreman for the respondent, testified that daily during the
entire month of February, 1978, snow patrols were dispatched at regular hourly
intervals to inspect an assigned section of Route 50 for snow and/or debris. No
debris
W. VA.] REPORTS
STATE COURT OF CLAIMS 347
of any kind was reported found in the area of the accident on the morning of
February 17, 1978, prior to the accident. The evidence revealed that the
section in question was not known to be a falling rock area. The claimant was
of the opinion that the rock had just fallen on the highway immediately before
the accident.
This Court repeatedly has adhered to the general principle of the case of Adkins v Sims, 130
W.Va. 645, 46 S.E.2d 81(1947), that the State is not a guarantor of the safety
of travelers and that the user of the highway travels at his own risk. The duty
of the State in the maintenance of highways is one of reasonable care and
diligence under all circumstances. In the case of Hammond v, Department of Highways, 11 Ct. Cl. 234 (1977), this Court held, ?The
unexplained falling of a rock or boulder onto a highway, without a positive
showing that the Department of Highways knew or should have known of a
dangerous condition and should have anticipated injury to person or property,
is insufficient. .
. to justify an award.?
There was no evidence presented showing any negligence on the part of the
respondent. Accordingly, the Court disallows the claim.
Claim disallowed.
Opinion issued June 30, 1979
CLINIC PRIVATE DIVISION. UNIVERSITY OF VIRGINIA
vs.
DIVISION OF VOCATIONAL REHABILITATION
(No. CC-79-22)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
348 REPORTS
STATE COURT OF CLAIMS {W. Va.
Claimant seeks payment of the sum of
$842.00 for unpaid hospital bills representing services performed by the
claimant for one Denny L. Hood, a client of the West Virginia Division of
Vocational Rehabilitation.
In its Answer, the respondent admits the allegations set forth in the Notice of
Claim and joins the claimant in requesting payment.
Based on the foregoing, an award in the amount of $842.00 is hereby made.
Award of $842.00.
Opinion issued June 30, 1979
DILL?S MOUNTAINEER ASSOCIATES, INC.
vs.
DEPARTMENT OF HEALTH
(No. CC-79-94)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent.
PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $2,406.00 for equipment which was ordered,
delivered, and received, but for which no payment was made by the respondent.
In its Answer, the respondent admits the validity of the claim, stating that
payment for said equipment had not been made prior to the close of the fiscal
year, with the result that the funds which had been encumbered for the purchase
expired.
In view of the foregoing, an award in the amount of $2,406.00 is hereby made.
Award of $2,406.00.
W. VA.) REPORTS
STATE COURT OF CLAIMS 349
Opinion issued June 30, 1979
JAMES L. DYKES
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-225)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
RULEY, JUDGE:
The claimant, James L. Dykes, seeks recovery from the respondent in the amount
of $68.86 for damages to his automobile which occurred on September 13, 1978.
On the day of the accident at approximately 2:00 p.m., the claimant was driving
his 1974 Vega station wagon on W. Va. Route 61 between Pratt, W. Va. and East
Bank, W. Va., when he approached a road construction area. The respondent was
grading the sides of Route 61. Flagmen were stationed at each end of the
construction area to control the flow of traffic. After being signaled forward
by a flagman, the claimant proceeded at a speed of 10-15 mph following 6-8 feet
behind a coal truck. While the claimant?s attention was focused on a road
grader adjacent to the highway, his automobile struck a rock on the highway,
approximately 10 inches wide and 8 inches high, causing damage to his
automobile.
If the Court were disposed to hold the respondent guilty of negligence, it is
also clear from the record that the claimant failed to exercise reasonable care
and caution under the circumstances. The presence of flagmen at a construction
site is sufficient to alert the reasonably prudent motorist to the possibility
of a dangerous condition. Notwithstanding this warning, the claimant chose to
follow a coal truck at an extremely close distance, limiting his vision of the
road ahead. While his vision was thus limited and his attention was on the road
grader, the rock was struck.
It is the opinion of this Court that the claimant?s failure to exercise
reasonable care under the circumstances was the
350 REPORTS
STATE COURT OF CLAIMS [W. Va.
proximate cause of the accident and resulting damages. Accordingly, the claim
is hereby disallowed.
Claim disallowed.
Opinion issued June 30, 1979
NATIONWIDE INSURANCE CO.,
AS SUBROGEE OF PHILLIP W. ALEXANDER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-79-150)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent.
PER CURIAM:
This claim was submitted upon a duly executed written stipulation to the effect
that the respondent is liable for damages in the sum of $179.22, based upon the
following facts:
On or about December 6, 1977, claimant?s insured, Phillip W. Alexander, was
operating his vehicle on Route 94 and 17th Street in Huntington, West Virginia.
A toll booth barricade on the entrance ramp on the north side of Route 94 and
17th Street had been negligently affixed by the respondent, and, as a proximate
result of this negligence, the barricade was blown into the side of claimant?s
insured?s vehicle, damaging it in the amount of $179.22.
Based on the foregoing facts, an award in the above amount is hereby made.
Award of $179.22.
W. VA.] REPORTS
STATE COURT OF CLAIMS 351
Opinion issued June 30, 1979
LARRY KEITH SMITH
vs.
DEPARTMENT OF HIGHWAYS
(CC-78?259)
No appearance by claimant.
Nancy J. Aliff, Attorney at Law, for respondent. WALLACE, JUDGE:
This claim was filed by Mary Ann Smith against the respondent, but during the
hearing, it developed that she sought recovery for damage to an automobile
registered to her husband, Larry Keith Smith. The Court, on its own motion,
amended the complaint and named Larry Keith Smith as the proper claimant.
On September 25, 1978, at approximately 2:00 p.m., Mary Ann Smith was driving
her husband?s 1972 Lincoln automobile in an easterly direction on Lake
Washington Road in Wood County, West Virginia, when she struck a deep pothole,
resulting in damages to the automobile in the amount of $296.30.
Lake Washington Road is a narrow, two-lane, blacktop road which connects Route
68 with Dupont Road. Just prior to the accident, Mrs. Smith encountered four or
five large potholes which she avoided by driving in the other lane. Traffic was
heavy in the oncoming lane and behind her. She proceeded slowly at
approximately 10 to 15 mph. Rounding a curve, she struck a large hole estimated
to be 12 inches deep, resulting in the claimed damages.
Mrs. Smith notified the respondent of the accident and was advised that the
respondent had received complaints con cerning the potholes and that repairs
should have been made.
While the respondent is not an insurer of those using its highways, it does owe
a duty of reasonable care and diligence in the maintenance of the highways. Lohan v. Dept. of Highways, 11 Ct. Cl. 39 (1975).. The respondent had notice of the
352 REPORTS
STATE COURT OF CLAIMS [W. Va.
dangerous condition on the narrow,
heavily-travelled road, and the necessary repairs should have been made within
a reasonable time.
The Court is of the opinion that the respondent was negligent in not making the
necessary repairs, and that Mrs. Smith was free from contributory negligence.
Accordingly, an award is made to the claimant in the amount of $296.30 for
damages to the automobile.
Award of $296.30.
Opinion issued June 30, 1979
3M COMPANY
vs.
DEPARTMENT OF MOTOR VEHICLES
(No. CC-79-77)
No appearance by claimant.
Henry C. Bias, Jr., Deputy Attorney General, for respondent. PER CURIAM:
This claim was submitted for decision based on the allegations of the Notice of
Claim and the respondent?s Answer.
Claimant seeks payment of the sum of $3,000.00 for 20,000 decals ordered in
March, 1974, by Governor Arch Moore. The decals were received by the Department
of Motor Vehicles, but were never used. An invoice for said decals remains
unpaid.
In its Answer, the respondent admits the allegations of fact set forth in the
Notice of Claim, but further alleges that sufficient funds were not available
at the close of the fiscal year in question from which the claim could have
been paid.
While we feel that this is a claim which in equity and good conscience should
be paid, we are of further opinion that an award cannot be made, based on our
decision in Airkem Sales
W. VA.]
REPORTS STATE COURT OF CLAIMS 353
and Service, et al. v. Department of Mental
Health, 8 Ct. Cl. 180 (1971).
Claim disallowed.
Opinion issued June 30, 1979
CHRYSTINE WINER
vs.
DEPARTMENT OF HIGHWAYS
(No. CC-78-170)
Claimant appeared in person.
Nancy J. Aliff, Attorney at Law, for respondent.
WALLACE, JUDGE:
The claimant, Chrystine Winer, seeks recovery for alleged damages in the amount
of $171.12 for personal injuries suffered when, as a pedestrian, she fell after
the heel of her shoe became caught in a gap between a sidewalk and curb.
Between 4:00 p.m. and 4:30 p.m. on the clear and dry day of March 31, 1978, the
claimant was walking home after an appointment with her hairdresser. While
crossing the intersection of Chestnut and Walnut Streets in Clarksburg, West
Virginia, the claimant stepped up onto the sidewalk adjacent to the eastbound
ramp to U.S. Route 50. The heel of her shoe caught in a gap, slightly more than
an inch in width, which separated the curb from the sidewalk, causing the
claimant to lose her balance and fall. The claimant testified that she was
carrying only her pocketbook and that, while unaware of the existence of the
gap between the sidewalk and the curb, she had walked the particular route
where the accident occurred since 1948.
Assuming that the respondent was negligent in failing to remedy the alleged
defect, and that the gap did in fact constitute a dangerous condition, the
claimant failed to exercise reasonable care for her own safety. It is well
settled that a pedestrian has the duty to exercise ordinary and prudent care
354 REPORTS STATE
COURT OF CLAIMS [W. Va.
for his own safety and to look for and protect himself from known and visible
dangers. Failure to do so under normal circumstances constitutes contributory
negligence as a matter of law. Jackson
v. Cockl1, 149 W.Va. 78, 138 S.E.2d
710 (1946); Vance v. Department of
Highways, 10 Ct. Cl. 189 (1975).
The injuries suffered by the claimant were proximately caused by her own
negligence, and, accordingly, the Court disallows her claim.
Claim disallowed.
W. VA.] REPORTS
STATE COURT OF CLAIMS 355
REFERENCES
Adjoining Landowners Motor
Vehicles?See also Negli Advisor Opinions gence; Streets and Highways
Annual Leave National Guard
Assumption of Risk Negligence?See also Motor Ve Auction hides; Streets and
Highways
Bailment Notice
Blasting Office Equipment and Supplies
Board of Regents Parks and Playgrounds
Bridges Pedestrians
Building Contracts Personal Services
Closing-Out Sales Physicians and Surgeons?See also
Colleges and Universities?See Hospitals
Board of Regents Prisons and Prisoners
Contracts?See also Building Con- Public Employees Retirement Sy tract stem
Damages Public Institutions
Department of Banking Public Officers
Department of Motor Vehicles Real Estate
Drains and Sewers?See also Relocation Assistance
Waters and Watercourses Scope of Employment
Electricity Sick Leave
Expenditures?See also Office State Agencies
Equipment and Supplies Statutes
Falling Rocks?See also Landslides Stipulation and Agreement
Fires and Fire Protection Streets and Highways?See also
Flooding Falling Rocks; Landslides; Motor
Hospitals Vehicles; Negligence
Independent Contractor Taxation
Insurance Trees and Timber
Interest Wages
Jurisdiction Waters and Watercourses?See al s Drains and Sewers; Flooding
Landlord and Tenant
Wells
Landslides?See also Falling Rocks W. Va. University?See Board of
Limitation of Actions Regents
356 REPORTS STATE
COURT OF CLAIMS [W. Va.
ADJOINING LANDOWNERS
Where the respondent State Agency
failed to maintain the culvert adjacent to claimants? property and the record
established that the flooding did not occur prior to the installation of the
culvert, the Court made an award for the damages to claimants? home. William
J. 4 dkins and Dorothy Marie Adicins
et al. vs. Department of Highways (CC-77-78) 185
Where claimant?s property was damaged as the result of actions by the
respondent in constructing a highwall on Route 19, and the proper measure of
damage is the diminution in market value, the Court made an award in accordance
with the decision in Jarrett v. E. L. Harper and Son, Inc., -? W. Va. ?, 235 S.E.2d.
362 (1977). Eugene Lafferty and Wanda Lafferty
vs. Department of Highways (CC-.76-44) 100
The Court made an award to the claimant for damage to his apartment where mud
and water were washed into the apartment from a land fill constructed by
employees_of the respondent on land adjacent to the claimant?s property. Patrick
West
vs. Department of Highways (CC-77-205) 193
Claimant alleged damage to his property as the result of a stopped-up culvert
which caused excessive water to flow onto his property, causing damage. The
Court held that the damage was the result of a heavy rain where water followed
its natural course down the slope of the hill onto claimant?s property, and
therefore, to hold that the diversion of water from the stopped-up culvert was
the proximate cause of damage, was unwarranted from the evidence. Bliss R
Wotring vs. Depart men of Highways (CC-77-140) 162
ADVISORY OPINIONS
Where claimant?s State agency
underpaid its statutory contribution to the claimant, and respondent did not
have sufficient funds available at the end of the pertinent fiscal year with
which to pay the claim, the Court denied the claim. Department of Employment
Security vs. Department of
Health (CC-78-43) 146
The Court denied payment of accrued interest on the underpayment of a statutory
contribution to the claimant by the respondent State agency. Interest awarded
by the Court is restricted by Code ? 14-2-12. Department of Employment Security vs. Department of Health (CC-78-43) 146
Where the respondent?s State agencies requested an advisory determination
respecting a claim based upon a duly executed purchase order between the
Department of Mental Health and the claimant, whereby the claimant became
obligated to construct the first phase of construction upon a Central Mental
Health Complex, but said contract was cancelled several months later when an
administrative decision was made to the effect that the Mental Health Complex
should not be constructed at that particular site, the court advised the
respondent that the claimant contractor should be paid the proposed settlement
in discharge of all obligations under the contract. Edward L. 1?Jezelek,
Inc. vs. Department of Finance and Ad ministratio and Department of
Health (CC-78-2) 74
W. VA.] REPORTS
STATE COURT OF CLAIMS 357
ANNUAL LEAVE
Claimant was granted an award for
annual days leave to which the respondent admitted the claimant was entitled
when he served as an administrative officer for the respondent?s agency.
Richard L. Weekly vs. Office of Emergency
Services
(CC-77-219a&b) 123
ASSUMPTION OF RISK
Where the claimant sustained personal
injuries when she slipped oc ice on the grounds of the Capitol Complex, the
Court held that the claimant was barred from recovery by virtue of the doctrine
of assumption of the risk. Pauline E.
Flaherty vs. Department of Finance & Administration (CC-77-89) 50
AUCTIONS
Claimant crushing company alleged
misrepresentation on the part of the respondent at an auction sale for junk and
junk cars. The Court denied said claim as the evidence clearly revealed that
the bidders understood that they were bidding for the right to clear a site of
the junk located there, and not for any particular number of vehicles. Cavalier Crushing Com pan vs. Dept. of Highways (CC-77-26) 206
BAILMENT
The driver of a vehicle was made an
award for damage sustained by said vehicle even though it did not belong to him
as he had repaired the vehicle, and the Court held that a bailee in possession
may sue for and recover judgment for wrongful damage or destruction by another
of hailed property. Charles H.
Spradling, Jr. vs. Department of Highways (CC 78-68 336
BLASTING
Where the claimant and the respondent
stipulated that blasting operations conducted by the respondent caused damage
to claimant?s electrical equipment, the Court made an award to the claimant for
the amount of the damage. Appalachian
Power Company vs. Department of Highways (CC?76-66) --
-
Claimants were granted an award for damage
to their home which was caused by blasting done by the respondent incident to
the excavation of a cut through a hill, since liability for damage proximately
caused by blasting is absolute. Arnold
G. Heater and Geraldine Heater vs. Dept. of Highways (CC-78-
130) 310
Where blasting activities by employees of the respondent caused damage to
claimants? property, the Court made ?an award for such damage in accordance
with the stipulation filed by the parties. John Tillinghast & Janet Till?nghast Vs.
Department of Highways (CC-77-80) -- -- -- - 159
The Court made an award to claimant contractor for blasting done on a project
where the technique of presplitting was used and the respondent State agency
denied the claimant contractor any tolerance on drilling behind template. The
Court held that the claimant contractor was entitled to a tolerance of 12
inches, Vecellio & Grogan, Ire. vs. Dept. of Highways (D-914,
D-993, D-918, Par. C) 294
358 REPORTS STATE
COURT OF CLAIMS [W. Va.
Where blasting by employees of the respondent resulted in damage tO claimants?
mobile home, the Court made an award to the claimants for the damage in
accordance with the stipulation submitted by the parties. John R. Wilder and Norma J.
Wilder vs. Department of Highways (CC-77-92)
? 24
BOARD OF REGENTS
The decision in Airkem Sales and Service, et al. V. Dept. of Mental Health, 8 Ct. Cl. 180 (1970) was applied to a claim where the
respondent admitted that West Virginia University purchased traverse rods from
the claimant and failed to pay for the same, but there were insufficient funds
remaining in the appropriation for the particular fiscal year. Capitol Busi nes Equipment, Inc. vs. Board of Regents (CC-77-108) 205
Where claimant supplied room air conditioning units to the respondent, and the
respondent admitted the validity of the claim and that there were sufficient
funds remaining in the fiscal year from which claim could have been paid, the
Court made an award to the claimant. Climate
Makers of Charleston,
Inc. vs. Board of Regents (CC-78-90)
166
In a claim for damaged personal possessions stored by the claimant in a
dormitory closet at West Virginia University, the Court determined that the
legal relationship existing between the respondent, Board of Regents, and the
claimant was one of landlord and tenant, and, as it is the duty of the landlord
to maintain the premises used in common by his tenants in a reasonably safe
condition, the Court made an award to the claimant for damage to personal possessions
when a water leak occurred in the dormitory. Lillian Dalessio vs. Board of Re gent (CC-78-88) 242
Where the respondent admitted liability and recommended payment of a claim for
design and art work on brochures for the Southern West Virginia Community
College at Logan, West Virginia, the Court made an award to the claimant, as
the respondent had sufficient funds available during the fiscal year in which
the order was made. Direct Mail Service
Co. vs.
Board of Regents (CC-77-15l) ? 49
Claimant sustained personal injuries when he fell into a large hole adjacent to
a path used by students attending a Fine Arts Camp at West Virginia University.
The general law is that an institution is under a duty of ordinary or
reasonable care with regard to the condition of its grounds to see that they
are maintained in a reasonably safe condition, and, as the respondent failed in
this duty, the Court made an award to the claimant. Jacquclyn B. Eisenberg, parent and next friend of Mark
Harold Eisenberg, an infant vs. Board of Regents (CC-
76-143) 273
Where claimant suffered personal injuries as the result of
a fall when leaving a ladies? restroom at Fairmont State Col lege the Court
held that the absence of a sign in the restroom
was not sufficient to establish liability on the part of the re spondent Mary Jo Hall vs. Board of Regents (D-1025) 232
Where claimant sustained injuries as the result of a fall
when leaving a ladies? restroom at Fairmont State College, the
Court determined that the accident was one which would not
have occurred if the claimant had been exercising ordinary
W. VA.] REPORTS
STATE COURT OF CLAIMS 359
care, and the lack of such care was negligence on her part.
Mary Jo Hall vs. Board of
Regents (D-1025) 232
Where claimant sought compensation for goods furnished and services rendered to
West Virginia University, and the respondent admitted the validity of each
claim and that there were sufficient funds available at the close of the fiscal
year from which the claims could have been paid, the Court made awards to each
of the claimants. Light Gallery and
Supply Co.,
et al. vs. Board of Regents (CC-79-2)
321
Where the claimant installed carpet in offices of the respondent in accordance
with a purchase order, and, after having installed said carpet, the claimant
received a cancellation of the purchase order, the Court made an award for the
carpeting.
Sanders Floor Covering Inc. vs. Board
of Regents (CC-77-74) -- 71
Where claimant delivered a quantity of furniture to the West Virginia University
Medical Center under a contract for the furniture, and the respondent later
cancelled the purchase order, the Court made an award to the claimant. Thompson?s
of Morgantown, Inc. vs. Board of Regents (CC-77-177) 72
Claimant was granted an award for the cost of printed forms shipped by the
claimant to the respondent, but for which the claimant failed to be paid as the
invoice was received by the respondent after the close of the fiscal year. Uarco, Inc. vs.
Board of Regents (CC-78-53)
150
Claimant was granted an award for the balance due on an agreement between the
claimant and Potomac State College to publish a yearbook for the school, as the
respondent admitted the facts and the amount of the claim. Todd W. Ware and
Taylor Publishing Co. vs. Board of Regents (CC-78-204) 269
BRIDGES
Where the claimant had not driven over
the bridge in question in three months, and he knew that other bridges on the
interstate were rough and patched but had negotiated them safely, he had no
reason to expect to encounter the large hole which caused the accident. The
Court cannot therefore conclude that the claimant was guilty of contributory
negligence. Davis vs. Department of
Highways: Hartford Accident & Indemnity Company vs. Department of Highways (D-996a)
(D?996b) ?
? 31
Where the evidence in a case impels the conclusion that the respondent
Department of Highways, in the exercise of ordinary care, should have known of
the existence of a hole in the bridge, which hole was the cause of the accident
resulting in damage to claimants? truck, the Court made an award to the
claimants for said damages. Davis vs.
Deprtment of Highwys:
Hartford Accident & Indemnity Company vs. Department of
Highways, (D-996a) (D-996b) ? 31
Claimant?s automobile sustained damage when his wife was driving the vehicle
across a bridge where a metal plate became loose and struck the undercarriage
of the vehicle. The Court made an award for the damage in accordance with the
stipulation filed by the parties. Rush
Fields vs. Department of
Highways (CC-78-77) 149
Claimants were granted an award for damage to their vehicle when a piece of
floor decking on a bridge punctured a
360 REPORTS STATE
COURT OF CLAIMS [W. Va.
tire on the vehicle. Drema D. Greenlee
and Shep hen E. Green-
lee vs. Department of Highways (CC-79-70)
338
Where claimant?s trucks sustained damage as the result of striking a metal
sheet on a bridge which had been negligently placed by respondent?s employees,
the Court made an award to the claimant for said damage in accordance with the
written stipulation filed by the parties. Timothy J. Grimmett vs. De partmen of Highways (CC-77-l47) 51
Where claimant and respondent stipulated that claimant?s truck was damaged as
the result of a piece of metal protruding from a bridge owned and maintained by
the respondent, the Court made an award to the claimant, as the negligence of
the respondent was the proximate cause of the damage. Halliburton Services vs. Department of Highways (CC-78-264) . - 281
Where claimant and respondent stipulated that claimant?s vehicle was damaged by
a board protruding from a bridge, the Court made an award, as the negligence of
the respondent was the proximate cause of the damage. Linda E. Hamilton vs.
Department of Highways (CC-78-260) 282
Where respondent?s employees negligently left pieces of welding rod material on
a bridge after completing the day?s work, and claimant?s motorcycle tire and
tube were punctured by the pieces of welding rod material, the Court made an award
in accordance with the written stipulation filed by the parties. Michael J. Hart vs. Department of Highways. (CC 77-124 52
Where claimants? vehicle was damaged by a loose plank in a wooden bridge and
the respondent had constructive knowledge of the need of repairs to the bridge,
the Court made an award to the claimants for the damages. Linda Lester and
Leon Lester vs. Department of Highways (CC-77-210)
102
Where a piece of steel on a bridge punctured one of the tires on claimant?s car
beyond repair, the Court made an award to the claimant for the damage in
accordance with a written stipulation filed by the parties. Charles P. Long vs.
Department of Highways (CC-78-115) 173
Where claimant sustained damage to his vehicle on a wooden bridge when a plank
unexpectedly came loose and caused the damage, the Court granted an award to
the claimant as the respondent had notice of the disrepair of the bridge and
failed to either warn the claimant or make repairs. Gerald J. Lynch
vs. Department of Highways (CC-77-175)
103
Where a light from a sign on a bridge fell on claimant?s automobile, the Court
held that the respondent was responsible for the maintenance and control of the
bridge, and made an award to the claimant for the damages. Franklin Ross and
Elsie M. Ross vs. Department of Highways (CC-77-132) 111
An award was made to the claimant for damage to his vehicle when he was forced
to ford a creek in an area where a bridge had been damaged and the respondent
had failed to repair the same or to provide a reasonable alternative route.
Larry Roton vs. Department
of Highways (CC-78-147) 256
Where the parties stipulated that the claimant lawfully drove his dump truck
across a bridge belonging to the respondent, which bridge collapsed, and the
evidence was that an
W. VA.] REPORTS
STATE COURT OF CLAIMS 361
inspection in 1974 had revealed that the bridge had a low limit of zero tons,
but the respondent failed to repair the bridge or post a weight limit on it,
the Court made an award to the claimant for the loss of said truck. Charles
E. Sch.ooley v. De partmen of Highways (CC-76-131) 28
Claimant alleged damage to his automobile when said automobile fell through a
hole in the wooden floor of an old narrow bridge near Milton, West Virginia.
The evidence disclosed that the bridge had been closed and the respondent had
erected barricades at each end of the bridge, but said barricades or timbers
were removed by unknown third persons. The facts failed to establish any
negligence on the part of the respondent, and the Court denied the claim. Roy D.
Smith vs. Department of Highways, (CC-76-129) 29
If the claimant had exercised the reasonable care required of her under the
circumstances, and maintained a proper lookout for a hole in the walkway of a
bridge which she knew to be there, she would have been able to avoid the
injury. Therefore, the Court denied the claim, as the condition of the bridge
was not the proximate cause of the accident. Dema Marie
Welch vs. Department of Highways (CC-77-l7) 136
Where the claimant sustained personal injuries when she fell into a hole on the
sidewalk of a bridge, which hole she had seen prior to crossing the bridge, the
Court held that the claim- and was guilty of contributory negligence as a
matter of law.
Dema Marie Welch vs. Department of Highways (CC-77-17) 136
Where respondent?s employees negligently placed a sheet of metal over a hole in
a bridge, and, as a result of this negligence, claimant?s vehicle sustained
damage, the Court made an award to the claimant for said damage. Marvin Roy
Welch
vs. Department of Highways (CC-77-184) 73
An award was made to claimants for damage to their home from excessive water
run-off which occurred as the result of respondent?s negligent re-surfacing
activities and inadequate drain design and maintenance of a street and bridge
adjacent to claimants? property. Loraine White and Velma White vs.
Dept. of Highways (CC-78-139) 271
BUILDING CONTRACTS
Where the respondent and claimant
contractor agreed that the claimant was entitled to recover from the respondent
for a certain sum of money on a claim involving the presplitting technique of
excavation, the Court made an award in accordance with the previous decision in
Vecellio & Grogan, Inc. vs. Department of Highways, 12 Ct. Cl. 294
(1979). Black Rock
Contracting, Inc. vs. Department of Highways, (CC-76-9) 324
Where claimant was performing a contract and was requested to make additional
changes while doing the work on the representation that a change order would be
issued to cover the cost, and said change order was requested but not approved,
the Court made an award to the claimant in the amount of the requested change
order as the work was performed in a workmanlike manner and the cost was
reasonable for the materials and labor involved. Boone Remodeling Com pan
vs. Department of Corrections (CC-77-130a-e) 89
362 REPORTS STATE
COURT OF CLAIMS [W. Va.
Where the claimant contractor had entered into a contract to conduct extensive
renovations at one of respondent?s institutions, and during the performance of
the contract the contractor and respondent?s supervisor of maintenance entered
into an agreement whereby claimant would provide certain additional electrical
work in exchange for releasing the contractor from performing certain other
provisions under the contract, the Court held that the claimant would be made
an award only for the extra work performed, as the claimant actually received a
credit against the original contract, and the contractor was unable to perform
a specific portion of the contract. Boone Remodeling Company vs. Department
of Cor rection (CC-77-130a-e) 89
Where the respondent?s State agencies requested an advisory determination
respecting a claim based upon a duly executed purchase order between the
Department of Mental Health and the claimant, whereby the claimant became
obligated to construct the first phase of construction upon a Central Mental
Health Complex, but said contract was cancelled several months later when an
administrative decision was made to the effect that the Mental Health Complex
should not be constructed at that particular site, the Court advised the
respondents that the claimant contractor should be paid the proposed settlement
in discharge of all obligations under the contract. Edward L. Nezelelc, Inc.
vs. Department of Finance & Administration & Dept. of Health (CC-78-2)
74
Where the claimant entered into a contract with the respondent to make a
feasibility study for an activity center at Twin Falls State Park, and later
the contract was cancelled by the respondent, the Court held that the
respondent breached the contract and that the claimant was entitled to
compensation for that portion of the work completed under the contract. Henry
Elden and Associates vs. Dept. of Natural Resources
(CC?77-190) 189
Where claimant architect had a contract to design and prepare plans for Welch
Emergency Hospital and the amount of said contract was in dispute but later
settled by arbitration in accordance with the contract, the Court made an award
in the amount of the arbitration finding. Henry Elden and Associates vs.
Dept. of Finance & Administration and Dept. of Health
(CC-78?269) 275
The claimant contractor was granted an award for rock excavation where rock was
unexpectedly encountered in the construction of Canaan Valley State Park and
the parties stipulated the claim. McCloy Construction Company, Inc. vs.
Dept.
of Natural Resources (CC?77?221) 312
Claimant contractor was forced to perform additional engineering and surveying
work due to an apparent mistake in the plans and specifications of the contract
between the contractor and the respondent; therefore, the Court made an award
for the cost overrun which occurred through no fault on the part of the
claimant. Vecelijo & Grogan, Inc. vs. Dept. of Highways
(D-9l4, D?993, D-918 Par. C) 294
Interest will not be charged against the respondent under W. Va. Code 14-3-1
where the claimant contractor receives the tentative final estimate but does
nothing for several months; however, once the claimant contractor responds to
the respon
W. VA.] REPORTS
STATE COURT OF CLAIMS 363
dent on the final estimate, interest begins to run again until the point in
time when the contractor is paid the final estimate. Vecellio & Grogan,
Inc. vs. Department of Highways
(D-914, D-993, D-918, Par. C) 294
The Court denied a claim by a contractor engaged by the respondent to construct
a highway in Nicholas County where the contractor alleged that the price for
explosives should be increased over the bid price quoted in their contract because
of impost charges placed on explosive sales in accordance with Internal Revenue
regulations. The Curt held that a careful reading of the Federal Register
failed to reveal any provision which would authorize the purchaser of
explosives to pass this charge on to the ultimate consumer, in this instance,
the respondent. Vecellio & Grogan, Inc. vs. Dept. of Highways (D 914
D-993, D-9l8, Par. C) 294
The Court made an award for interest to be charged against the respondent under
a construction contract with the claimant in accordance with W. Va. Code
14-3-1, as the project completion date is the date from which the 150 days
contemplated by the Statute commences, resulting in interest charges from the
15 1st day. Vecellio & Grogan, Inc. vs. Dept. of Highways
(D-914, D-993, D-918, Par. C) 294
The Court made an award to claimant contractor for blasting done on a project
where the technique of presplitting was used and the respondent State agency
denied the claimant contractor any tolerance on drilling behind template. The
Court held that the claimant contractor was entitled to a tolerance of 12
inches. Vecellio & Grogan, Inc. vs. Dept. of Highways (D-914,
D-993, D-9l8, Par. C) 294
The Court rejected respondent?s contention that claimant should not recover for
liquidated damages as the Court determined that there was no evidence as to any
actual damage sustained by the respondent due to delay in construction of the
highway. See also Whitmyer Brothers, Inc. vs. Department of Highways,
12 Ct. Cl. 9 (1977). Vecellio & Grogan, Inc. vs.
Department of Highways (D-914, D-993, D-918, Par. C) 294
Where the contract specifications referred to ?in reasonably close conformity?
for the location of the template line where the contractor was constructing a
fill on which to locate the roadbed, the Court held that a tolerance of 12
inches beyond the template lines should be considered as being ?in reasonably
close conformity?; therefore, the Court made an award to the claimant based
upon this permitted tolerance. Veceflio & Grogan, Inc. vs. Department of
Highways (D-914, D-993, D-918,
Par. C) 294
Where the respondent State agency made a large deduction for fat fill on
claimant?s contract job, which was originally bid as a waste job but became a
borrow job, the Court held that the respondent?s action in making the deduction
was extreme, and made an award to the claimant contractor for 30% of the cubic
yards deducted by the respondent. Vecellio & Grogan, Inc. vs. Department
of Highways (D-914, D-993, D-918, Par.
C) 294
Where the contract between claimant and respondent provided for the respondent
to pay for all seeding and mulching within construction limits, but the
claimant filed a claim for
364 REPORTS STATE
COURT OF CLAIMS [W. Va.
seeding and mulching outside the construction limits, the
Court denied the claim. W & H Contracting Co., Inc. and the
Burlce-Parsons-Bowlby Corp. vs. Department of Highways
(D-750) 22
The Court made an award to the claimant for liquidated damages assessed and
imposed by the respondent where there was no evidence as to the amount of
damages, if any, sustained by the repondent as a result of the delay. Whitmyer
Brothers, Inc. vs. Department of Highways (D-57l) 9
Where contract specifications relating to the installation of fence line along
an interstate were inconsistent and ambiguous, the provision must be construed
in light of proven trade practice and custom; therefore, the Court made an
award to the claimant for additional terminal posts as the requirement for
these terminal posts caused the claimant to have excess labor and material
costs and said requirement was arbitrary on the part of the respondent. Whitmyer
Brothers, Inc. vs. Department of Highways (D-571)
CLOSING-OUT SALES
The Court denied a claim by owners of a
business who alleged that the respondent interfered with a closing-out sale
which resulted in a loss of sales. The Court concluded that the claimants did
not comply with the legal requirements for conducting such sale, and there was
no evidence to establish improper conduct toward the claimant on the part of
the employees of the respondent. Robert V. Heverley, Jr. and Kathleen
Heverly, d/b/a Frances Shoppe, Inc. vs. Department of
Labor (CC-77-81) 251
COLLEGES AND UNIVERSITIES?See Board of
Regents CONTRACTS?See also Building Contracts
Where the claimant contractor had
entered into a contract to conduct extensive renovations at one of respondent?s
institutions, and during the performance of the contract the contractor and
respondent?s supervisor of maintenance entered into an agreement whereby
claimant would provide certain additional electrical work in exchange for
releasing the contractor from performing certain other provisions under the
contract, the Court held that the claimant would be made an award only for the
extra work performed, as the claimant actually received a credit against the
original contract, and the contractor was unable to perform a specific portion
of the contract. Boone Remodeling Company vs. Department of Correc tion (CC-77-130a-e)
89
Where claimant was performing a contract and was requested to make additional
changes while doing the work on the representation that a change order would be
issued to cover the cost, and said change order was requested but not approved,
the Court made an award to the claimant in the amount of the requested change
order, as the work was performed in a workmanlike manner and the cost was
reasonable for the materials and labor involved. Boone Remodeling Company
vs. Department of Corrections (CC-77-130a-e) 89
Where the respondent was prohibited by specific regulation from entering into a
contract for improving offices where the
W. VA.] REPORTS
STATE COURT OF CLAIMS 365
offices were leased premises, the claimant withdrew its claim since the Court
would have been unable to make an award in said matter. Boone Remodeling
Company vs. Department of
Corrections (CC-77-130a-e) 89
Where claimant had a contract to supply coal to West Virginia University, but
because of weather conditions, a more expensive coal had to be delivered, the
Court made an award for the difference in the contract price and the actual
price paid for the coal by the contractor in accordance with the pleadings
filed by the respondent. Central States Resources, Inc. vs.
Board of Regents (CC-78-l8) 289
The doctrine set forth in Airkem Sales and Service, et al. vs. Department of
Mental Health, 8 Ct. Cl. 180 (1971), was applied to a claim by Charleston
Area Medical Center, Inc. against the Department of Health where the two had
entered into an agreement for the State agency to reimburse the hospital for
losses incurred in connection with the operation of a specific project at the
hospital, as the agency had insufficient funds remaining in the appropriation
at the close of the fiscal year in question from which the claim could have
been paid. Charleston Area Medical Center, Inc .vs. Department of Health
(CC-78-283) 272
Where the respondent?s State agencies requested an advisory determination
respecting a claim based upon a duly executed purchase order between the
Department of Mental Health and the claimant, whereby the claimant became
obligated to construct the first phase of construction upon a Central Mental
Health Complex, but said contract was cancelled several months later when an
administrative decision was made to the effect that the Mental Health Complex
should not be constructed at that particular site, the Court advised the
respondent that the claimant contractor should be paid the proposed settlement
in discharge of all obligations under the contract. Edward L. Nezelek, Inc.
vs. Department of Finance & Administration and Dept. of Health (CC-78-2)
74
Where claimant had a contract to provide pickup and disposal of trash and
garbage, and the respondent inadvertently failed to pay the claimant for one month?s
service, the Court made an award in that amount in accordance with the figures
in the renewal agreement. Guyan Transfer and Sanitation, Inc. vs. Dept. of
Finance & Administration (CC-78-244) 280
Where the claimant entered into a contract with the respondent to make a
feasibility study for an activity center at Twin Falls State Park, and later
the contract was cancelled by the respondent, the Court held that the
respondent breached the contract and that the claimant was entitled to
compensation for that portion of the work completed under the contract. Henry
Elden and Associates vs. Dept. of Natural Resources
(CC-77-190) 189
Where claimant architect had a contract to design and prepare plans for Welch
Emergency Hospital and the amount of the contract was in dispute but later
settled by arbitration in accordance with the contract, the Court made an award
in the amount of the arbitration finding. Henry Elden and Associates vs.
Dept. of Finance & Administration and Dept. of Health
(CC-78-269) 275
366 REPORTS STATE
COURT OF CLAIMS [W. Va.
A claim for transportation charges related to typewriters contracted for under
a lease agreement between the claimant and respondent will be allowed by the
Court inasmuch as there was a specific provision in the contract relating
thereto. IBM
Corporation vs. Department of Motor Vehicles (CC-77-l) 2
Transportation charges for delivering a copier were denied by the Court where
there was no contractual provision for the claimant to furnish a copier to the
respondent. IBM Corporation vs. Department of Motor Vehicles (CC-77-l) 2
Where employees of the respondent wrongfully delayed claimant? in performing a
contract for printing the West Virginia State Map, and as a result, the
claimant suffered financial loss, the Court made an award to the claimant for
the losses in accordance with the written stipulation filed by the parties. Morrison
Printing Co., Inc. vs. Department of High way (CC-78-36) 142
Claimant was granted an award for parts and labor where claimant?s contract for
electrical work was cancelled after the claimant had ordered parts and
performed certain work in accordance with the contract. Ostrin Electric Co.
vs. Department of Natural Resources (CC-78-169) 293
Claimant was awarded an amount which represented the balance due under a
contract for providing psychological services to the inmates of two
institutions where the respondent failed to terminate the contract by providing
30 days? written notice to the claimant in accordance with the provisions in
the contract. Positive Peer Culture, Inc. vs. Dept. of Corrections
(CC?77-117) 285
Where the respondent, Department of Corrections, had a contract with the
claimant for certain psychological services to be provided to two institutions
of the respondent, and the claimant was orally notified that the contract would
expire and that the claimant would receive no compensation for the last 65 days
of the contract, the Court made an award, because oral notification was not in
compliance with the contract provision of 30 days? written notice. Positive
Peer Culture, Inc.
vs. Dept. of Corrections (CC-77-117) 285
The Court made an award to the claimant for the construction of a fireplace at
Cass Scenic Railroad. The case was submitted upon the pleadings, in which the
respondent admitted liability. Jerry Austin Rexrode vs. Department of
Natural Re source (CC-77-202) 110
Where claimant performed architectural services on a project for the
respondent, but failed to pay for the same as there were insufficient funds
remaining in the account from which the claim could have been paid, the Court
denied the claim in accordance with Airkem Sales and Service, et al. vs.
Department of Mental Health, 8 Ct. Cl. 180 (1970). R. L. Smith, d/b/a
Architectural Associates vs. Department of Public Safety (CC 78-174 218
Claimant contractor was forced to perform additional engineering and surveying
work due to an apparent mistake in the plans and specifications of the contract
between the contractor and the respondent; therefore, the Court made an award
for the cost overrun which occurred through no fault
W. VA.] REPORTS
STATE COURT OF CLAIMS 367
on the part of the claimant. Vecellio
& Grogan, Inc. vs. Dept.
of Highways (D-914, D-993, D-918, Par.
C) 294
An award was made to the claimant for damages resulting from respondent?s
breach of an employment contract with the claimant where the parties agreed to
the amount in a stipulation filed with the Court. John M. Weber vs. Board of Regents
(CC-77-229) 270
DAMAGES
Where a business is well established,
damages may be awarded for the loss of profits; therefore, where claimants?
business sustained a loss as a result of an accident involving their wrecking
truck, the Court did consider loss of profits in making an award for damages. Davis vs. Department of Highways: Hartford Accident
& Indemnity Company vs. Department of Highways (D-996a) (D-996b) 31
Where a coal truck belonging to claimant?s insured was rendered a total loss in
an accident, the Court based the damages upon the fair market value of the coal
truck immediately before the accident less the salvage value. Davis vs. Department of Highways: Hartford Accident
& Indemnity Company vs.
Department of Highways (D-996a)
(D-996b) 31
Where the Court determined liability on the part of the respondent for the loss
of the claimants? wrecker truck, and the evidence disclosed that the difference
in the fair market value of the wrecker truck immediately before and after the
accident was $25,000.00, but the cost of repair was $18,000.00, the Court made an
award to the claimants for the cost of repair plus the towing charge. Davis vs. Department of Highways: Hartford Accident
& Indemnity Company vs. Department of Highways
(D-996a) (D-996b) ? 31
Claimant was granted an award for the fair market value of his trailer where
employees of the respondent destroyed the trailer resulting from a
misunderstanding or failure of communication, at the time of the Williamson
flood, regarding the trailer?s contents (contaminated meat). Hogan Storage & Transfer Company vs. Department of
Agriculture and De partmen of Health (CC-77-134)
96
The standard measure of damages for injury to personal property is the loss of
fair market value plus reasonable and necessary expenses incurred by the owner
in connection with the injury. Where claimant?s bus was totally destroyed by
employees of the respondent who failed to follow statutory procedures, and the
claimant expressed the value of the bus, the Court made an award to the
claimant for said value. Robert H.
Johnson vs. Department of Highways (CC-77-146)
? 98
Where the claimants and the respondents stipulated that a drainage ditch
parallel with the road across from claimants? property became clogged, causing
surface water to drain across the road and onto claimants? properties and
damaging the same, the Court made an award to the claimants based upon
appraisals of the properties indicating the before and after market values. Norman Maynard & Shirley Maynard vs. Department of Highways (CC-76-71a), Arthur
Maynard & Mollie
Maynard vs. Department of Highways (CC-76-71b)
4
368 REPORTS STATE
COURT OF CLAIMS [W. Va.
The proper method of establishing damage to real estate as a result of a
landslide is to determine the difference in the fair market value of the
property before and after the landslide; therefore, the Court used the expert
testimony of the witness who determined the damage to the real estate by this
method. Polly Stevens, Guardian of the
Person and Estate of James Walter Stevens and Timothy Stevens vs. Department of
High way (D-688) 180
The claimants sought recovery of treble damages for the wrongful cutting of
trees on their property under W. Va. Code ?61-3-48a. The Court refused to make
such an award, as such damages are in the nature of penalties, and this Court
was not created for that purpose. The Court made an award for compensatory
damages only. Fred K. Testa &
Claudia I. Testa vs. Department of Highways (D-669a), Saleem A. Shah &
Theresa
A. Shah vs. Department of Highways (D-669b)
115
The Court denied a claim by a contractor engaged by the respondent to construct
a highway in Nicholas County where the contractor alleged that the price for
explosives should be increased over the bid price quoted in their contract
because of impost charges placed on explosive sales in accordance with Internal
Revenue regulations. The Court held that a careful reading of the Federal
Register failed to reveal any provision which would authorize the purchaser of
explosives to pass this charge on to the ultimate consumer, in this instance,
the respondent. Vecellio & Grogan,
Inc. vs. Dept. of Highways (0-
914, 0-993, 0?918, Par. C) 294
The Court made an award for interest to be charged against the respondent under
a construction contract with the claimant in accordance with W. Va. Code
14-3-1, as the project completion date is the date from which the 150 days
contemplated by the Statute commences, resulting in interest charges from the
15 1st day. Vecelilo & Grogan, Inc.
vs. Dept. of Highways
(0?914, D-993, 0-918, Par. C) 294
The Court rejected respondent?s contention that claimant should not recover for
liquidated damages as the Court determined that there was no evidence as to any
actual damage sustained by the respondent due to delay in construction of the
highway. See also Whitmyer Brothers,
Inc. vs. Department of Highways, 12
Ct. Cl. 9 (1977). Vecellio &
Grogan, Inc. vs.
Department of Highways (0-914, 0-993,
0-918, Par. C) 294
The Court made an award to the claimant for liquidated damages assessed and
imposed by the respondent where there was no evidence as to the amount of
damages, if any, sustained by the respondent as a result of the delay. Whitmyer Brothers, Inc. vs. Department of Highways (0-57 1) 9
DEPARTMENT OF BANKING
Where claimants alleged a monetary
loss due to the reorganization of a savings and loan company in which the
claimants converted savings accounts into stock during the reorganization, the
Court held that it did not have jurisdiction over the company, its officers, or
employees. Charles I?. Evans &
Ernestine Evans vs. Department of Banking (CC-77-127) -
-- 168
Where claimant alleged that the Department of Banking unlawfully permitted the
Parkersburg Savings & Loan Company
W. VA.] REPORTS
STATE COURT OF CLAIMS 369
to reorganize, resulting in a monetary loss to the claimants who converted a
savings account into stock, the Court denied the claim as there was no evidence
that the reorganization was unlawful or that the Dept. of Banking acted
unlawfully in permitting the reorganization. Charles R. Evans &
Ernestine
Evans vs. Department of Banking (CC-77-127) 168
Where claimants filed a claim naming individuals including the commissioner of
banking, the receiver of Parkersburg Savings & Loan Company, the Governor,
and the legislature, the Court dismissed the claims as the Court has no
jurisdiction over any individual. Charles R. Evans & Ernestine
Evans vs. Department of Banking (CC-77-127) 168
DEPARTMENT OF MOTOR VEHICLES
Where the claimant requested a refund
of the 5% tax paid to the Department of Motor Vehicles when she purchased a
second-hand automobile, but returned the automobile and was refused the refund
because the tax had already been sent by the dealer to the department, the
Court determined that the sale was nullified by mutual agreement, and the
claimant should be refunded the tax. Sandra S. Clemente vs. Department of
Motor Vehicles (CC-77-167) 48
The claimant was refunded the 5% tax on an automobile purchased, and the
two-dollar title fee, when the Court determined that the parties nullified the
transaction and the Department of Motor Vehicles was unable to make a refund of
the tax. George M. Custer vs. Department of Motor Vehicles,
(CC-77-86) 48
Claimant was granted an award for the refund of the 5% tax paid on the purchase
of an automobile where the sale between the parties was nullified and the sales
price refunded, and the respondent?s State agency was unable to make a refund
of the tax. Anthony R. Rosi vs. Department of Motor
Vehicles (CC-77-138) 110
A claim for decals received by the respondent, Department of Motor Vehicles,
was denied by the Court as sufficient funds were not available at the close of
the particular fiscal year involved. See Airkem Sales and Service, et al.
vs. Department of Mental Health, 8 Ct. Cl. 180 (1971). 3M Company
vs. Department of Motor Vehicles (CC-79-77) 352
Where the claimant sought to recover a premium due from the respondent?s State
agency, but the respondent indicated that it did not have sufficient monies in
the proper account to pay for said premium, the Court disallowed the claim in
accordance with Airkem Sales and Service, et al. vs. Department of Mental
Health, 8 Ct. Cl. 180 (1971). West Virginia Public Employees Insurance
Board vs. Department of Motor
Vehicles (CC-77-172) --
84
Where the respondent State agency negligently issued a new title to a vehicle
in the name of the owner without the claimant?s lien being recorded thereon,
and claimant bank sustained a loss as the result of this negligence, the Court
made an award to the bank for the loss. Wood County Bank vs. Dept. of Motor
Vehicles (CC-78-209) 276
370 REPORTS STATE
COURT OF CLAIMS [W. Va.
DRAINS AND SEWERS?See also Waters and
Watercourses
Where negligence on the part of the
respondent is not shown to have caused the accident, the Court will deny a
claim where the claimant alleged that the driver of his vehicle went into a
drainage ditch adjacent to the road. Arthur Adkins, Jr. vs.
Dept.
of Highways (CC-78-83) 316
Where the respondent State agency failed to maintain the culvert adjacent to
claimants? property and the record established that the flooding did not occur
prior to the installation of the culvert, the Court made an award for the
damage to claimants? home. William J. Adkins and Dorothy Marie Adkins, et
al. vs. Department of Highways (CC-77-78) 185
Where claimant sustained damage to her vehicle when she went through a ditch in
the roadway, the Court held that the respondent was not guilty of negligence
which proximately caused the accident as it had endeavored to check the
condition of the ditch frequently to keep it backfilled and even with the
pavement. Sadie Jean Akers and Thomas E. Akers vs.
Dept. of Highways (CC-78-132) 315
Where the respondent, having knowledge of the condition which caused drainage
onto claimant?s property, failed to take corrective measures, the Court made an
award to the claimant for the damage to the property. Curtis Allison vs.
Depart men of Highways (CC-77-l10) 84
Where claimant alleged damage to his truck as the result of hitting a
water-filled pothole, and the evidence revealed that the respondent had
attempted on several occasions to repair the hole through the use of both hot
mix and cold mix, but due to a drainage problem, water would accumulate and
cause the mix to wash out and re-create the pothole, the Court denied the
claim, as the respondent is under a duty only to use reasonable care to keep
the highways in a reasonably safe condition, and the respondent had discharged
the duty in this particular case. James R. Banhart vs. Department of
Highways
(CC-78-l 19) 236
Where the damage to claimant?s property was due to respondent?s lack of proper
maintenance of its road and the drain pipe under it, the Court made an award to
the claimant for the damages to her property established by appraisals offered
into evidence. Minnie Lee Brown vs. Department of
Highways (D-999) 125
Where the negligence of the respondent in failing to maintain a culvert, which
caused flooding on a roadway resulting in an accident damaging claimant?s
vehicle, the claimant?s own testimony demonstrated that he was guilty of
contributory negligence by failing to cross the double line when there was no
approaching traffic for a distance of some 150 to 175 feet.
William C. Griffing vs. Department of Highways (CC-77-50) 127
Claimant was denied a claim for damage to his vehicle which occurred when the
vehicle struck an embankment as the Court determined that, even though the
respondent was negligent in failing to maintain a culvert causing accumulation
of water on the highway, the claimant was guilty of contributory negligence
which proximately contributed to the accident.
Lloyd Harding Gwinn vs. Dept. of Highways (CC-77-191) 128
W. VA.] REPORTS
STATE COURT OF CLAIMS 371
A claim for personal injuries sustained by the claimant in an accident alleged
to have been caused by a blocked culvert which caused water to flow across a
highway, was denied by the Court, as there was no showing that the respondent
knew or should have known that there was a clogged culvert, nor was there any
showing that respondent was negligent in permitting the partial flooding of the
highway. Karen HaIler vs.
Department of Highways (CC-77-123) ---- 327
Where the claimants and the respondents stipulated that a drainage ditch
parallel with the road across from claimants? property became clogged, causing
surface water to drain across the road and onto claimants? properties and
damaging the same, the Court made an award to the claimants based upon
appraisals of the properties indicating the before and after market values. Norman Maynard & Shirley Maynard vs. Department of Highways (CC-76-71a), Arthur
Maynard & MolIie
Maynard vs. Department of Highways (CC-76-71b)
4
Where claimant alleged that its decedent was killed in an
accident which resulted when the respondent failed to provide
adequate drainage for a backwater pond, thereby causing
water from the pond to overflow and freeze upon the highway,
and the evidence failed to establish any connection whatsoever
between the water in the pond and the ice on the highway, the
Court denied the claim. Meredith K.
Rice, Adm. of the Estate
of Syed Q.
Abbas, Deceased vs. Department of Highways
(D-875) 12
The Department of Highways has a legal duty to use reasonable care to maintain
a ditch line in such condition that it will carry off surface water and prevent
it from passing upon property adjacent to the road. Therefore, the Court made
an award where the claimant proved by a preponderance of the evidence that the
respondent failed to maintain the ditch line properly, and as a result of such
failure, a landslide occurred causing damage to the property of the wards of
the claimant. Polly Stevens, Guardian
of the Person and Estate of James Walter Stevens and Timothy Stevens vs.
Department of High ways (D?688) 180
Where the respondent failed to maintain a ditch adjacent to the front of
claimants? property, and as a result of such failure, the claimants? home and
contents were damaged by water and mud, the Court made an award for such damage
in accordance with the written stipulation filed by the parties. Charles E. and Mary P. Taylor vs. Department of
Highways (CC-78-
206) 261
The failure of the respondent to exercise ordinary care must be established by
a preponderance of the evidence, and, while the claimant testified that there
was mud and water on the road resulting from a clogged drainage ditch, and said
condition caused the claimant?s accident, there was no evidence introduced to
establish notice to the respondent of the condition of the roadway. The Court
therefore denied the claim. Gerald E.
Tinsley and Lois C. Tinsley vs. Department of Highways
(CC-77-165) 134
The Court denied claimant?s claim for damage to her property allegedly sustained
as the result of diversion of a natural drain course by the respondent. The
evidence would have required the Court to engage in pure speculation, which it
can-
372 REPORTS STATE
COURT OF CLAIMS [W. Va.
not do. Ruth Ann Toppings vs. Department of Highways (0-
1007) 261
An award was made to claimants for damage to their home from excessive water
run-off which occurred as the result of respondent?s negligent re-surfacing
activities and inadequate drain design and maintenance of a street and bridge
adjacent to claimants? property. Loraine White and Velma White vs.
Dept. of Highways (CC-78-139) 271
Claimant alleged damage to his property as the result of a stopped-up culvert
which caused excessive water to flow onto his property, causing damage. The Court
held that the damage was the result of a heavy rain where water followed its
natural course down the slope of the hill onto claimant?s property, and
therefore, to hold that the diversion of water from the stopped- up culvert was
the proximate cause of damage, was unwarranted from the evidence. Bliss R.
Wotring vs. Department
of Highways (CC-77-140) 162
ELECTRICITY
Where the claimant and the respondent
stipulated that blasting operations conducted by the respondent caused damage
to claimant?s electrical equipment, the Court made an award to the claimant for
the amount of the damage. Appalachian Power Company vs. Department of Highways
(CC-76-66) -
EXPENDITURES?See also Office Equipment
and Supplies
Where the claimant provided portable
toilets to the respondent in the aftermath of the flood in Williamson, West
Virginia, and several of the toilets were later found to be missing, the Court
advised the respondent to pay for said toilets as the loss was the result of
unlawful conversion by the respondent. Alert Sanitation vs. Office of the
Governor?Emergency Flood
Disaster Relief (CC-77-156) 76
Where claimant physician rendered professional services to a patient at a State
hospital, for which services claimant was not paid because the agency failed to
have sufficient funds in its budget, the Court applied the Airkem decision
and denied the claim. Pedro N. Ambrosio, M.D. vs. Department of
Health, Division of Mental Health (CC-77-90) 15
Where claimant sought payment for merchandise shipped to respondent?s hospital,
and the respondent admitted the validity of the claim and that it had
sufficient funds to pay the same, the Court made an award to the claimant for
the merchandise. American Hospital Supply vs. Department of Health (CC-78-
265) ?
?- 278
Where claimant sought payment for goods and services rendered to the
respondent, and the respondent had sufficient funds to pay for the same, the
Court made an award to the claimant for the merchandise. Bern hardt?s
Clothing, Inc. vs.
Department of Corrections (CC-78-203) 238
Where the claimant delivered merchandise to respondent?s Work/Study Centers and
the respondent admitted receiving the merchandise but did not have sufficient
funds remaining at the close of the fiscal year from which these invoices could
have been paid, the Court applied the decision of Airlcem Sales and Service
vs. Department of Mental Health, 8 Ct. Cl.
W. VA.] REPORTS
STATE COURT OF CLAIMS 373
180 (1971) and disallowed the claim. C. H.
James & Co., Division of James Produce Co.,
Inc. vs. Department of Corrections
(CC-77-l48) 30
The decision in Airkem Sales and
Service, et al. vs. Dept. of Mental Health, 8 Ct. Cl. 180 (1971) was applied to a claim where the respondent
admitted that West Virginia University purchased traverse rods from the
claimant and failed to pay for the same, hut there were insufficient funds
remaining in the appropriation for the particular fiscal year. Capitol Business Equipment, Inc. vs. Board of Regents (CC-77-108) 205
Claimant sought payment for wire hanger clips purchased by the respondent where
the respondent admitted the validity of the claim and that it had sufficient
funds on hand at the close of the fiscal year from which the claim could have
been paid; the Court made an award to the claimant. Capitol Business Interiors, Division of Capitol Business
Equipment, Inc.
vs. Department of Finance & Administration (CC-79-60) 338
Where the claim was submitted upon the pleadings, and the respondent admitted
the validity of the claim and that it had sufficient funds in the budget from
which the claim should have been paid, the Court made an award to the claimant
for the goods sold and delivered to the respondent. Cecil E. Jackson Equipment, Inc. vs. Department of Corrections (CC-
77-97) 58
- Where claimant had a contract to supply coal to West
Virginia University, but because of weather conditions, a more expensive coal
had to be delivered, the Court made an award for the difference in the contract
price and the actual price paid for the coal by the contractor in accordance
with the pleadings filed by the respondent. Central States Resources, Inc. vs. Board of Regents (CC-78-18) 289
The doctrine set forth in Airkem Sales
and Service, et al. vs. Department of Mental Health, 8
Ct. Cl. 180 (1971), was applied to a claim by Charleston Area Medical Center,
Inc. against the Department of Health where the two had entered into an
agreement for the State agency to reimburse the hospital br losses incurred in
connection with the operation of a specific project at the hospital, as the
agency had insufficient funds remaining in the appropriation at the close of
the fiscal year in question from which the claim could have been paid. Charleston Area Medical Center, Inc. vs. Department of Health
(CC-78-283) 272
Where claimant, Circuit Clerk of Kanawha County, filed a claim representing
fees incident to instituting a suit for the respondent, for which the claimant
was not paid, and there were sufficient funds in the budget with which to pay
the claim, the Court made an award to the claimant for these fees. Phyllis J. Rutledge, Circuit Clerk of Kanawha County,
W. Va.
vs. Auditor of the State of West Virginia (CC-77-77)
56
Where claimant furnished floor tile and brush-on adhesive for use at an
institution of the respondent, but claimant was not paid for said supplies as
the invoice was submitted after the close of the fiscal year during which the
supplies were furnished, the Court made an award in the amount of the purchase
order. Clendenin Lumber & Supply
Company vs. Department of Health, Division of Mental Health (CC-78-14) 119
374 REPORTS STATE
COURT OF CLAIMS [W. Va.
Where claimant supplied room air conditioning units to the respondent, and the
respondent admitted the validity of the claim and that there were sufficient funds
remaining in the fiscal year from which the claim could have been paid, the
Court made an award to the claimant. Climate Makers of
Charleston, Inc. vs. Board of Regents (CC-78-90) 166
Where claimant sought payment for unpaid hospital bills representing services
performed for a client of the Division of Vocational Rehabilitation, the Court
made an award for the services, which were admitted by the respondent. Clinic Private
Division, University of Virginia vs. Division of Vocational
Rehabilitation (CC-79-22) 347
Where claimant?s State agency underpaid its statutory contribution to the
claimant, and respondent did not have sufficient funds available at the end of
the pertinent fiscal year with which to pay the claim, the Court denied the
claim. Department of Employment Security vs. Department of Health
(CC-78-43) 146
Where the claimant sold and delivered a quantity of heating oil to respondent?s
Huttonsville Correctional Center and the invoice failed to be paid because
there were no funds remaining in the appropriation for the State agency, the
Court applied the Airkem decision and denied the claim. Department of
Highways vs. Department of Corrections (CC-77-65) 43
Where the Department of Highways sold and delivered heating oil to respondent?s
Huttonsville Correctional Center, and sought an award for the amount of the
invoice and interest, the record failed to disclose the existence of any
contract between the parties specifically providing for the payment of
interest. Therefore, pursuant to W. Va. Code 14-2-12, the Court denied the
interest portion of the claim. Department of Highways vs. Department of
Corrections (CC-77-65) 43
Where the respondent admitted liability and recommended payment of a claim for
design and art work on brochures for the Southern West Virginia Community
College at Logan, West Virginia, the Court made an award to the claimant, as
the respondent had sufficient funds available during the fiscal year in which
the order was made. Direct Mail Service Co. vs.
Board of Regents (CC-77-151) 49
Where the respondent State agency admitted the validity of the claim but stated
that it lacked the necessary funds in the appropriate fiscal year from which
the claim could have been paid, the Court denied the claim where claimant
sought payment of a bill for a renewal equipment performance program for a
Miracode Mjcrofilmer. See Airkem, et al. vs. Department of Mental
Health, 8 Ct. Cl. 180 (1970). Eastman Kodak Co. vs.
Office of the Secretary of State (CC-78-1l2) 167
Where respondent owed claimant the unpaid balance on the lease of a postage
meter, the Court made an award in the amount of the claim. Friden Mailing
Equipment Corporation
vs. Department of Corrections (CC-77-125) 95
Where a State agency has overspent its budget during a particular fiscal year,
a claim for merchandise where the agency had insufficient funds to pay for the
same will be denied in accordance with the previous decision of the Court, Airkem
Sales and Service, et al. vs. Department of Mental Health, 8
W. VA.] REPORTS
STATE COURT OF CLAIMS 375
Ct. Cl. 180 (1971). Graves-Humphreys, Inc. vs. Department of Public
Institutions (CC-77-35)
Where the respondent refused to pay the statement submitted by medical doctors
who rendered professional services to a trooper in the employ of the respondent
because the statement was submitted after the close of the fiscal year, the
Court made an award for said services. H. M. Hills, Jr. & Luis
A. Loimil vs. Department of Public Safety (CC-77-200) 70
An award was made to claimant for radiological services performed for the
respondent where the respondent admitted the validity of the claim and the
amount. Kanawha Valley Radiologists, Inc. vs. Board of Vocational Education,
Division
of Vocational Rehabilitation (CC-77-212 a-k) 100
Claimant hospital was granted an award for services rendered to two inmates of
respondent?s Huttonsville Correctional Center when the respondent failed to pay
for the same during the fiscal year in which the expenses were incurred and
there were sufficient funds in the respondent?s budget. Memorial
General Hospital vs. Dept. of Corrections (CC-79-38) 313
Where respondent issued a purchase order for license plate decals at an agreed
price, and the claimant made an error in the billing, invoicing the respondent
at an incorrect rate, the Court made an award to the claimant for the
difference resulting from claimant?s own error. Moore Business Forms, Inc.
vs.
Department of Motor Vehicles (CC-78-23) 104
The Court made an award to the claimant for ambulance service provided to a
patient at the request of the respondent?s representative, with the respondent
admitting the validity of the claim and the amount. New Martinsville/Wetzel
County Emergency Squad, Inc. vs. Board of Vocational Education, Division
of Vocational Rehabilitation (CC-77-211) 105
Claimant exterminating company was granted an award where the respondent
admitted liability for failure to pay for services rendered to a State
institution. Orkin Exterminating, Inc. vs. Dept. of Health, Division of
Mental Health (CC-78-
96a-c) 215
Where claimant performed routine maintenance services
for which it was not paid and the respondent admitted the
validity of the claim, the Court made an award to the claim ant Otis Elevator
Company vs. Department of Health, Divi sio of Mental Health (CC-77-204) 108
The Court made an award for service performed by claimant?s service shop where
respondent was unable to provide payment as it was not presented with the
original bill. Patrick
Plaza Dodge, Inc. vs Office of the Treasurer (CC-78-211) 255
Where claimants sought awards for overtime compensation while they were
employed as house parents at respondent?s f acility at Institute, West
Virginia, the respondent contended that the decision of Airkem Sales and
Service, et al. vs. Department of Mental Health, 8 Ct. Cl. 180 (1971)
applied, since insufficient funds were expired in the personal services account
from which the overtime compensation claims could have been paid. The Court
denied this contention based upon the case of State ex rel. Crosier
vs. Callaghan, ?W. Va.? 236 S.E.2d 321 (1977), wherein the Supreme Court
held that the
376 REPORTS STATE
COURT OF CLAIMS [W. Va.
liability for unpaid wages is incurred against an employer at the time
liability is determined; therefore, the question of sufficient funds is
immaterial. Elva B. Petts and James M. Preston vs. Division of Vocational
Rehabilitation (D-927d) and
(D-927i) 222
The respondent admitted in its Answer that it ordered, received, and used
certain drugs purchased from the claimant, but due to a mistake in the drug
contract book, the claimant was not paid the full amount for the drugs;
however, the respondent did not have sufficient funds remaining in its
appropriation from which the claim could have been paid, and the Court
disallowed the claim on the basis of Airkem Sales and Service, et al. vs.
Department of Mental Health, 8 Ct. Cl. 180 (1971). Pfizer Corporation,
Roerig Division vs. Department of
Health, Division of Mental Health (CC-77-l04? 45
Claimant, an organization for the handling of bills and collection of charges
for professional services rendered by physicians at the Medical Center at West
Virginia University, filed a claim for such services to a patient of the
resp.ondent. The Court denied the claim, based upon the principles set forth in
Airkem Sales and Service vs. Department of Mental Health, 8 Ct. Cl. 180
(1971), as the respondent failed to expire sufficient funds in the pertinent
fiscal year. Physicians Fee Office vs. Department of Health, Division
of Mental Health (CC 77?76 17
Claimant sought payment for services rendered to an inmate of the Department of
Corrections, but the department lacked the requisite funds in its appropriation
for the fiscal year in question; therefore, the Court disallowed the claim
based upon the decision in Airkem Sales and Service, et at. vs. Department
of Mental Health, 8 Ct. Cl. 180 (1971). Physicians Fee
Office vs. Department of Corrections (CC-78-74) 175
The Court made an award to the claimant for selling and delivering food
supplies to Roney?s Point Center, an institution of the respondent, as
respondent is liable for merchandise delivered to it. Polis Brothers vs.
Department of Health, Division
of Mental Health (CC-77-107) 109
Where the evidence established that, the parties agreed to have a vehicle
belonging to the respondent repaired, but there was a misunderstanding as to a
limitation on the total cost of repairs, and the claimant exceeded the monetary
limit but completely repaired the vehicle, the Court made an award to the
claimant, since the State would be unjustly enriched if any other decision were
made. Raleigh Motor Sales, Inc. vs.
Department of Natural Resources (CC-76-123) 26
Claimant ambulance service was denied a claim for ambulance service calls where
there was no evidence that the claimant complied with the respondent?s
regulation for certification by the attending physician of the transportation
used. Rick?s
Ambulance vs. Department of Welfare (CC-77-2l3) 255
Where the respondent admitted in its Answer that invoices for goods sent by the
claimant to the respondent represented valid claims, and the respondent had
sufficient funds in which to pay these invoices at the end of the fiscal year,
the Court made an award to the claimant for the goods. S. B. Wallace &
Co. vs. Department of Corrections (CC-77-119) 62
W. VA.] REPORTS
STATE COURT OF CLAIMS 377
Where the claimant installed carpet in offices of the respondent in accordance
with a purchase order, and, after having installed said carpet, the claimant
received a cancellation of the purchase order, the Court made an award for the
carpeting. Sanders Floor Covering Inc. vs. Board of Regents (CC
77?74 71
The Court made an award to the claimant for six special tents used by the State
in a bicentennial celebration at Prickett?s Fort even though the respondent
alleged that the person ordering the tents had no authority to do so, and no
purchase order had ever been authorized or issued to the claimant. The Court
determined that the acceptance and use of the tents without payment by the
respondent would constitute unjust enrichment. Sam Siclajr d/b/a Gallon Canvas
Products Company vs. Governor?s Office of Economic and
Community
Development (CC-77-95) 19
Where claimant performed architectural services on a proect for the respondent,
but failed to pay for the same as there were insufficient funds remaining in the
account from which the claim could have been paid, the Court denied the claim
in accordance with Airlcem Sales and Service, et al. vs. Department of Mental
Health, 8 Ct. Cl. 180 (1971). 1?. L. Smith, d/b/a Architectural
Associates vs. Department of Public Safety
(CC-78-174) 218
The Court made an award to the claimant for certain wheels and axles which it
sold to the respondent and which the respondent had in its possession but was
no longer able to pay for, as the fiscal year had expired. A. A. Spagnuolo
vs. Department of Highways (CC-78-134) 180
Where the respondent unilaterally reduced the amount of merchandise which it
ordered from the claimant without renegotiating a price, the Court made an
award to the claimant for the additional compensation due. State Chemical
Manufacturing Co. vs. Department of Highways (CC-77-79) 8
The Court applied the Airkem decision, 8 Ct. Cl. 180 (1971), to a claim
for petroleum purchases made by the respondent where the respondent admitted
the validity and amount of the claim, but had insufficient funds at the close
of the fiscal year in which to pay said claim. Texaco, Inc. vs. Office of
the Sec retar of State (CC-78-l27) 184
Where claimant delivered a quantity of furniture to the West Virginia
University Medical Center under a contract for the furniture, and the
respondent later cancelled the purchase order, the Court made an award to the
claimant. Thompson?s
of Morgantown, Inc. vs. Board of Regents (CC-77-177) 72
A claim for decals received by the respondent, Department of Motor Vehicles,
was denied by the Court as sufficient funds were not available at the close of
the particular fiscal year involved. See Airkem Sales and Service, et al.
vs. Department of Mental Health, 8 Ct. Cl. 180 (1971). 3M Company vs.
Department of Motor Vehicles (CC-79-77) 352
Where the claimant inadvertently paid twice for an order of Uniform Vehicle
Identification Stamps, the Court made an award for the second payment as the
agency involved had no statutory authority to make such refund. Transport
Motor
Express, Inc. vs. Public Service Commission (CC-78-4) 192
378 REPORTS STATE
COURT OF CLAIMS [W. Va.
Where the claimant sold pharmaceutical products to the respondent based upon an
agreement which provided that the prices were subject to change, the Court made
an award to the claimant for the difference in the old price and the new price
in accordance with the agreement between the parties. Trayenol Laboratories,
Inc. vs. Department of Health, Division of
Mental Health (CC-77-91) ---- 64
Claimant was granted an award for the balance due on an agreement between the
claimant and Potomac State College to publish a yearbook for the school, as the
respondent admitted the facts and the amount of the claim. Todd W. Ware and
Taylor Publishing Co. vs. Board of Regents (CC-78-204) 269
Where the claimant sought to recover a premium due from the respondent?s State
agency, but the respondent indicated that it did not have sufficient monies in
the proper account to pay for said premium, the Court disallowed the claim in
accordance with Airkem Sales and Service, et al. vs. Department of Mental
Health, 8 Ct. Cl. 180 (1971). West Virginia Public Employees Insurance
Board vs. Department of Motor Vehicles
(CC-77-172) 84
Where claimant sought payment for salary due him for professional services
performed for the respondent, and the respondent admitted the validity of the
claim, the Court made an award to the claimant. Silas C. Wiersma vs. Dept. of
Health, Division of Mental Health (CC-78-158) 234
FALLING ROCKS?See also Landslides
Claimant alleged damage to his vehicle
when he struck a boulder which had crashed onto the highway. The Court denied
the claim as the boulder had fallen just prior to the accident and there was no
evidence that the respondent knew or should have known of the existence of an
unusually dangerous condition. Arnold W. Bolyard vs. Department of Highways
(CC-78-1) 344
Where claimant?s automobile sustained damage when it struck a rock on the
highway, the Court denied the claim as there was no showing that the respondent
knew or should have known of the dangerous condition, especially since the rock
had fallen on the highway immediately before the accident.
Lawrence Childers vs. Department of Highways (CC-78-63) - 346
Where the claimant struck a rock in a construction area after having been
signaled forward by a flagman, the Court denied the claim as the evidence
disclosed that the claimant failed to exercise reasonable care under the
circumstances, since the presence of a flagman at a construction site is suff
icient to alert a motorist to the possibility of a dangerous condition. James
L. Dykes vs. Department of Highways (CC-78-
225) 349
The Court denied a claim where claimant alleged that while driving his vehicle
along the highway his automobile struck a rock, because claimant testified that
he knew the rocks were there and could have avoided driving over them. John
Thomas
Weddington vs. Department of Highways (CC-77-l6l) 161
FIRES AND FIRE PROTECTION
Where claimant contended that the
period of limitation was tolled due to the incapacity of the decedent?s mother,
and there
W. VA.] REPORTS
STATE COURT OF CLAIMS 379
was a delay in appointing an administrator for decedent?s estate, the Court
held that the period of limitation is not tolled until an administrator is
appointed; therefore, the claim was dismissed based upon the fact that the
claim was not filed within the period of limitation set forth in West Virginia
Code ?55-7-6. Elwood Clark, Admin. of
the Estate of Sharon Marie
Clark, Dec. vs. State Fire Marshal (CC-76-102)
? 77
Where claimant?s decedent was killed
in a fire, and claimant alleged that respondent failed to inspect the hotel
where claimant?s decedent was in residence at the time, the Court dismissed the
claim in accordance with the two-year period of limitation set forth in West
Virginia Code 55-7-6, as the Court is required by statute (? 14-2-21) to apply
the statute of limitations. Elwoocl Clark,
Admin. of the Estate of Sharon Marie
Clark, Dec. vs. State Fire Marshal (CC-76-102)
77
Where claimant?s property was damaged by fire when employees of the respondent
were attempting to start a backfire in order to control a forest fire, the
Court held that the respondent is liable for providing equitable compensation
to the claimant for her loss. Mrs.
Richard L. Cooper vs. Department
of Natural Resources (CC-77-60) 93
Where the claimant sustained damage to her property as a result of a backfire
started on her property by employees of the respondent who were attempting to
control a forest fire, the Court held that Code ?20-3-4 authorizes the
respondent to start backfires and exonerates the fire fighters from criminal
responsibility. However, this does not mean that a property owner?s property
can be destroyed without compensation for the loss. Mrs. Richard L. Cooper vs. Department of Natural
Resources (CC-77-60) 93
FLOODING
Where the respondent State agency
failed to maintain the culvert adjacent to claimants? property and the record
established that the flooding did not occur prior to the installation of the
culvert, the Court made an award for the damages to claimants? home. William J. Adlcins and Dorothy Marie Adkins, et al. vs.
Department of Highways (CC-77-78) 185
Where the claimant provided portable toilets to the respondent in the aftermath
of the flood in Williamson, West Virginia, and several of the toilets were later
found to be missing, the Court advised the respondent to pay for said toilets
as the loss was the result of unlawful conversion by the respondent. Alert Sanitation vs. Office of the Governor?Emergency Flood
Disaster Relief (CC-77-156) 76
Where claimant?s house sustained damage when respondent?s employees began to
demolish the house in the aftermath of the Williamson flood, the Court made an
award to the claimant for the damage caused by the negligence of the
respondent. Gladys Barfield vs. Office
of the Governor?Emergency Flood Dis aste Relief (CC-78-173) 237
The Court denied claimant?s claim for damage to his vehicle sustained when the
claimant drove said vehicle into water on the highway which caused him to lose
control and drive into an embankment, as the Court determined that claimant?s
failure to cross the double line when there was no approaching
380 REPORTS STATE
COURT OF CLAIMS [W. Va.
traffic was negligence. Lloyd Harding Gwinn vs. Dept. of
Highways (CC.-77-191) 128
Where the employees of the Department of Highways blocked a stream, which
caused periodic flooding on claimant?s property and resulted in a slip, the
Court made an award for the corrective work necessary to prevent further damage
to claimant?s property. Herman F. Lilly vs. Department of High way (CC-77-133)
153
Claimant was granted an award for the fair market value of his trailer where
employees of the respondent destroyed the trailer resulting from a
misunderstanding or failure of communication, at the time of the Williamson
flood, regarding the trailer?s contents (contaminated meat). Hogan Storage
& Transfer Company vs. Department of Agriculture a?nd De partmen of Health (CC-77-134)
96
The Court advised the respondent to pay a claim where a contractor employed
by the respondent damaged the residence of the claimant when a piece of
equipment struck the rear of the residence during cleanup operations following
the flood in Williamson, West Virginia. Robert L. Massie & Mae Massie
vs. Office of the Governor?Emergency Flood Disaster Relief
(CC-77-199) 82
Where the respondent engaged the services of a contractor to assist in cleaning
up the debris resulting from the flood in Williamson, West Virginia, and,
during said cleanup, the operator of an endloader destroyed property belonging
to the claimant, the Court advised the respondent to pay said claim. Alex
Ray vs. Office of the Governor?Emergency Flood Dis aste Relief (CC-77-192)
83
Where claimant alleged that its decedent was killed in an accident which resulted
when the respondent failed to provide adequate drainage for a backwater pond,
thereby causing water from the pond to overflow and freeze upon the highway,
and the evidence failed to establish any connection whatsoever between the
water in the pond and the ice on the highway, the Court denied the claim. Meredith
K. Rice, Adm. of the Estate of Syed Q. Abbas, Deceased vs. Department of High way D-875) 12
Where the evidence failed to establish flooding or any connection at all
between the water in a pond adjacent to the highway and the ice on the highway,
which ice was alleged to have caused the accident resulting in the death of
claimant?s decedent, the claimant failed to prove any negligence on the part of
the respondent, and the claim was denied. Meredith K. Rice, Adm. of the
Estate of Syed Q.
Abbas, Deceased vs. De partmen of
Highways (D-875) 12
As the result of construction activities near claimant?s house, water flooded
claimant?s basement and caused damage to personal property; therefore, the
Court made an award to the claimant for the damage in accordance with the
written stipulation filed by the parties. Mae Russell vs. Department of
Highways (CC-78-81) 177
An award was made to the claimant for damage to a rock wall where employees of
the State damaged the same during the cleanup of flood debris in Williamson,
West Virginia.
W. VA.] REPORTS
STATE COURT OF CLAIMS 381
Thelma J. Stone vs. Office of the
Goverror?Emergency Flood
Disaster Relief (CC-78-.11) 202
The Court made an award to claimants for damage to their wall which occurred
when the operator of an endloader engaged in the cleanup operation after the
Williamson flood negligently damaged said wall. Patricia Wilson, George P. Wilson and Gladys V. Wilson
vs. Office of tho Governor?Emergency
Flood Disaster Relief (CC-78-41) 309
HOSPITALS
Where claimant physician rendered
professional services to a patient at a State hospital, for which services
claimant was not paid because the agency failed to have sufficient funds in its
budget, the Court applied the Airkem decision and denied the claim. Pedro N. Ambrosio vs. Department of Health, Division
Of Mental Health (CC-77-90) 15
Where claimant sought payment for merchandise shipped to respondent?s hospital,
and the respondent admitted the validity of the claim and that it had
sufficient funds to pay the same, the Court made an award to the claimant for
the merchandise. American Hospital
Supply vs. Department of Health (CC
78-265 278
The doctrine set forth in Airkem Sales
and Service, et al. vs. Department of Mental Health, 8 Ct. Cl. 180 (1971), was applied to a claim by
Charleston Area Medical Center, Inc. against the Department of Health where the
two had entered into an agreement for the State agency to reimburse the
hospital for losses incurred in connection with the operation of a specific
project at the hospital, as the agency had insufficient funds remaining in the
appropriation at the close of the fiscal year in question from which the claim
could have been paid. Charleston Area
Medical Center, Inc. vs. Department of Health
(CC-78-283) - -- 272
Where claimant sought payment for unpaid hospital bills representing services
performed for a client of the Division of Vocational Rehabilitation, the Court
made an award for the services, which were admitted by the respondent. Clinic Private Division, University of Virginia vs.
Division of Vocational
Rehabilitation (CC-79-22) 347
Where claimant hospital rendered services to three inmates of respondent?s
Huttonsville Correctional Center, and received no payment from respondent, the
Court made an award to claimant for the services. Davis Memorial Hospital vs. Dept.
of Corrections (CC-78-230a-c) - 244
Where claimant architect had a contract to design and prepare plans for Welch
Emergency Hospital and the amount of the contract was in dispute but later
settled by arbitration in accordance with the contract, the Court made an award
in the amount of the arbitration finding. Henry Elden and Associates vs. Dept. of Finance & Administration and
Dept. of Health
(CC-78-269) 275
An award was made to claimant for radiological services performed for the
respondent where the respondent admitted the validity of the claim and the
amount. Kanawha Valley Radiologists,
Inc. vs. Board of Vccational Education, Division
of Vocational Rehabilitation (CC-77-2l2
a-k) --
100
382 REPORTS STATE
COURT OF CLAIMS [W. Va.
Claimant hospital was granted an award for services rendered to two inmates of
respondent?s Huttonsville Correctional Center when the respondent failed to pay
for the same during the fiscal year in which the expenses were incurred and
there were sufficient funds in the respondent?s budget. Memorial
General Hospital vs. Dept. of Corrections (CC-79-38) 313
Where claimant had not received payment for medical expenses incurred by a
patient of the respondent, the Court made an award to the claimant hospital for
the medical expenses. Private Diagnostic Clinic, Surgical Professional Programs
Office vs. Division of Vocational Rehabilitation (CC-77-224) 144
Where claimant?s decedent, while a patient in a State institution, sustained
injuries in a fall and later died, the Court held that the doctrine of res ipsa
loquitur cannot be invoked where existence of negligence is solely a matter of
conjecture or where it may be held that there was no negligence on the part of
the respondent; therefore, the Court denied the claim. Patty Sheets,
Administratrix of the Estate of Ray Samuel Six, Deceased vs. Department of
Health, Division of Mental Health
(CC-76-80) 332
INDEPENDENT CONTRACTOR
The Court made an award to the
claimant for damages to his property when claimant?s fence was struck by snow
plowing equipment used during snow removal operations by an independent
contractor of the Department of Highways. See Hubbs vs. Department of
Highways, 12 Ct. Cl. 39 (1977).
Frank G. Barr vs. Department of Highways (CC-77-141) 65
As the duty of snow removal is the responsibility of the W. Va. Commissioner of
Highways within the meaning of the term ?maintenance? (See W. Va. Code 17-2a-8),
this particular duty cannot be delegated nor assigned; therefore, the
respondent is liable for actions of negligence by an independent contractor
which damaged claimant?s property during the removal of snow from a highway. Kermit
Reed Hubbs vs. Department
of Highways (CC-77-83) 39
Even though the Court agreed that the National Guard occupied the position of
an independent contractor when its members performed snow removal operations on
behalf of the respondent, the rule of non-liability is subject to certain
exceptions, one of which is where the law imposes a special duty; therefore,
the Court made an award to the claimant where members of the National Guard, in
removing snow from a main highway, performed their work in a negligent manner,
causing damage to claimant?s fence line. Kermit Reed Hubbs
vs. Department of Highways (CC-77-83) 39
Where the evidence disclosed that the employee alleged to have caused an
accident was determined to be an employee of an independent contractor, the
Court held that the respondent cannot be held liable for the negligence, if
any, of such employee. R. H. Bowman Distributing Co., Inc. vs. Department
of Highways (CC-77-99) 156
Claimant was granted an award for damage to the vehicle he was driving where it
struck an expansion joint, even though said damage was the result of negligent
acts of an independent contractor of the respondent, as the law is well settled
that
W. VA.] REPORTS
STATE COURT OF CLAIMS 383
the principal must bear the consequences of his agent?s negligence. Charles
H. Spradling, Jr. vs. Department of Highways
(CC-78?68) 336
The claimant was granted an award for damage to an automobile which he was
driving but which did not belong to him where the automobile struck a damaged
expansion joint, because the independent contractor of the respondent, who
damaged the expansion joint, negligently failed to make any effort to notify
the respondent or to warn motorists. Charles
H. Spradling, Jr. vs. Department of Highways (CC-78-68) 336
INSURANCE
Claimant was granted an award for
damage to its insured?s vehicle which occurred when a barricade was blown into
the vehicle and the barricade had been negligently affixed by an employee of
the respondent. Nationwide Insurance Co., as Subrogee of Phillip W.
Alexander vs. Department of High way (CC-79-150) 350
The Court denied a claim for damage to the paint of an automobile where the
evidence revealed that the employees of the respondent had performed no work on
the roadway on the day that claimant alleged the damage was done to his
vehicle. TJ.S.A.A. Insurance Co. & Harold F. May vs. Department of
Highways (CC-77-215 a&b) 159
INTEREST
The Court denied payment of accrued
interest on the underpayment of a statutory contribution to the claimant by the
respondent State agency. Interest awarded by the Court is restricted by Code
?14-2-12. Department of Employment Security vs. Department of Health (CC-78-43)
146
Where the Department of Highways sold and delivered heating oil to respondent?s
Huttonsville Correctional Center, and sought an award for the amount of the
invoice and interest. the record failed to disclose the existence of any
contract between the parties specifically providing for the payment of
interest. Therefore, pursuant to W. Va. Code 14-2-12, the Court denied the
interest portion of the claim. Department of
Highways vs. Department of Corrections (CC-77-65) 43
Interest will not be charged against the respondent under W. Va. Code 14-3-1
where the claimant contractor receives the tentative final estimate but does
nothing for several months; however, once the claimant contractor responds to
the respondent on the final estimate, interest begins to run again until the
point in time when the contractor is paid the final estimate. Vecellio &
Grogan, Inc. vs. Department of Highways (D-9l4,
D-993, D-918, Par. C) 294
The Court made an award for interest to be charged against the respondent under
a construction contract with the claimant in accordance with W. Va. Code
14-3-1, as the project completion date is the date from which the 150 days
contemplated by the Statute commences, resulting in interest charges from the
151st day. Vecellio & Grogan, Inc. vs. Dept. of Highways
(D-914, D-993, D-9l8, Par. C) 294
384 REPORTS STATE
COURT OF CLAIMS [W. Va.
JURISDICTION
Where claimant?s decedent was killed
in a fire, and claimant alleged that respondent failed to inspect the hotel
where claimant?s decedent was in residence at the time, the Court dismissed the
claim in accordance with the two-year period of limitation set forth in West
Virginia Code 55-7-6, as the Court is required by statute (? 14-2-21)
to apply the statute of limitations. Elwood Clark, Admin. of the Estate of
Sharon Marie
Clark, Dec. vs. State Fire Marshal (CC-76-102) 77
Where claimant alleged a monetary loss due to the reorganization of a savings
and loan company in which the claimants converted savings accounts into stock
during the reorganization, the Court held that it did not have jurisdiction
over the company, its officers, or employees. Charles R. Evans &
Ernestine Evans vs. Department of Banking (CC-77-127) 168
Claimant, a former employee of the Department of Welfare, requested the Court
to direct the respondent, Public Employees Retirement System, to pay retirement
benefits to the claimant to which claimant alleged she was legally entitled.
The Court determined that it did not have statutory jurisdiction to direct the
respondent to reward retirement benefits to the claimant, and, therefore, the
motion to dismiss the claim was sustained. Lillian M. Holstein vs. Public
Employees Retirement System
(CC-78-78) 151
The jurisdiction of the Court of Claims is clearly set forth and limited by
Code ? 14-2-13, which specifically excludes an action against the Board of
Education in the definition of a State agency. Therefore, the Court sustained
the respondent?s motion to dismiss as the Court has no jurisdiction over such
claims. Timothy Rakes, by his father and next friend. Andrew Rakes, and
Andrew Rakes vs. Board of Education of the
County of Lincoln (CC-77-55) 147
A claim filed by the claimant against the respondent for compensation for injuries
alleged to have been received while claimant was on duty with the West Virginia
National Guard in 1910 was dismissed, as the application of West Virginia Code
14-2-21, the statute of limitations, excludes the claim from the jurisdiction
of the Court. Arthur Vannort vs. Department
of Veterans? Affairs and Adjutant General (CC-77-218) 267
LANDLORD AND TENANT
Where the respondent was prohibited by
specific regulation from entering into a contract for improving offices where
the offices were leased premises, the claimant withdrew its claim since the
Court would have been unable to make an award. Boone Remodeling Company vs.
Department of Corrections
(CC-77-l3Oa-e) 89
Where the respondent admitted that it was indebted to the claimant for back
rent, and also alleged that there were insufficient funds from which to pay the
rent, the Court denied the claim in accordance with the Airkem decision.
See Airkem Sales & Service, et al. vs. Department of Mental Health, 8
Ct. Cl. 180 (1971). The County Commission of Mason County vs.
Department of Public Safety (CC-77-109) 188
In a claim for damaged personal possessions stored by the claimant in a
dormitory closet at West Virginia University, the
W. VA.] REPORTS
STATE COURT OF CLAIMS 385
Court determined that the legal relationship existing between the respondent,
Board of Regents, and the claimant was one of landlord and tenant, and, as it
is the duty of the landlord t maintain the premises used in common by his
tenants in a reasonably safe condition, the Court made an award to the claimant
for loss of possessions when a water leak occurred in the dormitory. Lillian
Dalessio vs. Board of Regents (CC 78?88 242
LANDSLIDES?See also Falling Rocks
Where respondent?s employees
negligently cut two temporary cables installed by the claimant after a slide
had occurred, the Court made an award to the claimant for the damage to the
cables. C & P Telephone Company of West Virginia vs. Department of
Highways (CC-77-71) 239
Where respondent?s employees, in maintaining a road above the claimants?
property, cut into the hillside and caused a slide to occur on claimants?
property, damaging the same, the Court made an award to the claimants. James
H. Curnutte, Jr. & Deborah L. Curnutte vs. Department of Highways (CC-78
-150) 290
Where the employees of the Department of Highways blocked a stream, which
caused periodic flooding on claimant?s property and resulted in a slip, the
Court made an award for the corrective work necessary to prevent further damage
to claimant?s property. Herman F. Lilly vs. Department of High way (CC-77?133)
153
The Department of Highways has a legal duty to use reasonable care to maintain
a ditch line in such condition that it will carry off surface water and prevent
it from passing upon property adjacent to the road. Therefore, the Court made
an award where the claimant proved by a preponderance of the evidence that the
respondent failed to maintain the ditch line properly, and as a result of such
failure, a landslide occurred causing damage to the property of the wards of
the claimant. Polly Stevens, Guardian of the Person and Estate of James
Walter Stevens and Timothy Stevens vs. Department of High ways (D-688) 180
The proper method of establishing damage to real estate as a result of a
landslide is to determine the difference in the fair market value of the
property before and after the landslide; therefore, the Court used the expert
testimony of the witness who determined the damage to the real estate by this
method. Polly Stevens, Guardian of the Person and Estate of James Walter
Stevens and Timothy Stevens vs. Department of High way (D-688) 180
LIMITATION OF ACTIONS
Where claimant contended that the
period of limitation was tolled due to the incapacity of the decedent?s mother,
and there was a delay in appointing an administrator for decedent?s estate, the
Court held that the period of limitation is not tolled until an administrator
is appointed; therefore, the claim was dismissed based upon the fact that the
claim was not filed within the period of limitation set forth in West Virginia
Code ?55-7-6. Elwood Clark, Admin. of the Estate of Sharon Marie
Clark, Dec. vs. State Fire Marshal (CC-76-102) 77
386 REPORTS STATE
COURT OF CLAIMS [W. Va.
Where claimant?s decedent was killed in a fire, and claimant alleged that
respondent failed to inspect the hotel where claimant?s decedent was in
residence at the time, the Court dismissed the claim in accordance with the
two-year period of limitation set forth in West Virginia Code 55-7-6, as the
Court is required by statute (? 14-2-21) to apply the statute of limitations. Elwood Clark, Admin. of the Estate of Sharon Marie
Clark, Dec. vs. State Fire Marshal (CC-76-102)
77
The failure of the postal service to deliver a Notice of Claim within three
days does not provide legal ground for the Court to deny respondent?s Motion to
Dismiss said claim when the claim was not received by the Clerk and was not
filed until after the two-year period of limitation set forth in West Virginia
Code ?55-7-6. Elwood Clark, Admin. of the Estate
of
Sharon Marie Clark, Dec. vs. State Fire Marshal (CC-76-102) 77
The claimant filed a claim for compensatory time worked
over two years before the filing of the action, and the Court
held that the claim was barred by the statute of limitations
under Code ?21-5c-8. Nathan Haddad, Jr.
vs. Department of
Motor Vehicles and Department of Finance & Administration
(CC-77-2) ? ? 130
Where the claimant filed a claim based upon an invoice
barred by the five-year statute of limitations set forth in West
Virginia Code f 55-2-1, the amount of that invoice was denied.
S. B. Wallace & Co. vs. Department
of Corrections (CC-77-
119) 62
A claim filed by the claimant against the respondent for compensation for
injuries alleged to have been received while claimant was on duty with the West
Virginia National Guard in 1910 was dismissed, as the application of West
Virginia Code 14-2-21, the statute of limitations, excludes the claim from the
jurisdiction of the Court. Arthur Vannort vs. Department of Veterans?
Affairs and Adjutant General (CC-77-218) 267
MOTOR VEHICLES?See also Negligence;
Streets and Highways
Where claimant sustained damage to her
vehicle when she went through a ditch in the roadway, the Court held that the
respondent was not guilty of negligence which proximately caused the accident
as it had endeavored to check the condition of the ditch frequently to keep it
backfilled and even with the pavement. Sadie
Jean Akers and Thomas E. Akers vs.
Dept. of Highways (CC-78-132) 315
Where claimant and respondent stipulated that claimant?s automobile was damaged
when it struck a hole which was full of water and obscured from view, the Court
made an award to the claimant. David E.
Alvis vs. Department of Highways
(CC-77-62) 47
Where claimant?s automobile struck a hole which was full of water and obscured
from view, the Court made an award for damage to the automobile based upon the
stipulation filed by the parties. David
E. Aivis vs. Department of Highways
(CC?77?62) 47
Where claimant alleged that she slid into an approaching dump truck belonging
to respondent when she encountered a Dept. of Highways vehicle parked on the
right side of the
W. VA.] REPORTS
STATE COURT OF CLAIMS 387
road, the Court denied the claim as the claimant did not prove by a
preponderance of the evidence that the accident was caused by the negligence of
the respondent. Jack
D. Bailey &
Betty Louise Bailey vs. Department of Highways (CC-78-49) 317
Where employees of the respondent negligently instructed the claimant to
proceed across a road onto which respondent?s employees had just dumped reddog,
and claimant?s vehicle sustained flat tires as a result thereof, the Court made
an award to the claimant for said damages. Raymond N. Belmont
vs. Department of Highways (CC-77-84) 57 Claimant alleged damage to his
vehicle when he struck a
boulder which had crashed onto the highway. The Court denied the claim as the
boulder had fallen just prior to the accident and there was no evidence that
the respondent knew or should have known of the existence of an unusually
danger-. ous condition. Arnold W. Bolyard vs. Department of High way
(CC-78-l) 344
Where claimant was operating his van and was signaled to proceed onto fresh tar,
and as a result thereof the van was heavily splashed with tar, the Court made
an award to the claimant for the damage to the vehicle because respondent?s
failure to warn the claimant of the presence of this tar constituted
negligence. Charles A. Bowman vs. Department of
Highways (CC-77-137) 66
Where a contractor of the Department of Highways damaged an expansion joint on
an interstate and failed to make any effort to notify the respondent or warn
motorists, the Court made an award to the claimant for damages to his
automobile when he struck said expansion joint. The law is well settled that
the principal must bear the consequences of his agent?s negligence, and
therefore, the respondent is liable to the claimant. Jeffrey D. Bubar vs.
Department of Highways (CC 78-27 204
Where claimants and respondent stipulated that the claimants? vehicle was
damaged when it struck a large hole which was covered with water on the date of
the accident, the Court made an award to the claimant in accordance with the
written stipulation filed by the parties. Darrell E. Buckner &
Betty S. Buckner v. Department of Highways (CC-77-129) 41
Where claimant sustained damage to his automobile when he struck a pothole in a
portion of a road which was otherwise free from defects, the Court denied the
claim. Arnell Church
vs. Department of Highways (CC-78-79) 165
Where the employees of the respondent sprayed portions of a highway with an
anti-spalling compound used for the preservation of concrete and there were no
warning signs or flag- men before, during, or after the job, and as a result
the claimant was involved in an accident where another automobile slid on the
treated portion of the roadway and into the claimant, causing injuries thereto,
the Court made an award to the claimant. Michael H. Coen & Ruth Coen vs.
Department
of Highways (D-1008) 119
Where the parties stipulated that an employee of the respondent negligently
threw a rock against claimant?s vehicle, breaking the windshield, the Court
made an award to the
388 REPORTS STATE
COURT OF CLAIMS [W. Va.
claimant for said damage. Virginia Sue
Cook vs. Department
of Highways (CC-77-144) 58
Where the evidence in a case impels the conclusion that the respondent
Department of Highways, in the exercise of ordinary care, should have known of
the existence of a hole in the bridge, which hole was the cause of the accident
resulting in damage to claimants? truck, the Court made an award to the
claimants for said damages. Davis v.
Department of Highways: Hartford Accident & Indemnity Company vs.
Department of Highways (D-996a)
(D-996b) 31
Claimant was denied recovery for dar.age to his automobile caused when he
struck a hole in the road, as the Court determined that there was no evidence
to the effect that the respondent knew or should have known of the existence of
the hole.
Merton M. Delancey vs. Department of
Highways (CC-.78-9l) 245
Where there was no evidence in the record that the respondent had notice of the
hole in the road prior to the accident, a claim for damages to claimants?
automobile was denied by the Court. Lawrence
& Claudette Ferguson vs. Department of
Highways, (CC-78-100) 326
An award was made for damage to claimants? gas tank which occurred when their
automobile struck a large rock which had been knocked into the road by a grader
and left there, The Court concluded that the accident was caused by negligence
on the part of the respondent. Teresa
K. Gillispie and Johnny Wayne Gillispie vs. Dept. of Highways (CC-78-
153) 248
Where the negligence of the respondent in failing to maintain a culvert, which
caused flooding on a roadway, resulted in an accident damaging claimant?s
vehicle, the claimant?s own testimony demonstrated that he was guilty of
contributory negligence by failing to cross the double line when there was no
approaching traffic for a distance of some 150 to 175 feet.
William C. Griffing vs. Department
of Highways (CC-77-50) 127
Where claimant and respondent stipulated that claimant?s truck was damaged as
the result of a piece of metal protruding from a bridge owned and maintained by
the respondent, the Court made an award to the claimant, as the negligence of
the respondent was the proximate cause of the damage. Halliburton Services vs. Department of Highways (CC-78-264) 281
The simple existence of a pothole in the road does not make the State negligent
per se, as the State must have had actual or constructive notice of the
particular road defect which allegedly caused the accident. Therefore, the
Court denied the claim where claimant?s son, while driving his vehicle, struck
a hole and caused damage to said vehicle. William L. Hanson, Sr. & William L. Hanson, Jr. vs. Dept. of
Highways (CC-78-
82) 197
Where claimant?s automobile sustained damage as the result of striking
construction plates which were not securely fastened down on the highway, the
Court made an award to the claimant for the damages, as the negligence of the
respondent was the proximate cause of the damage. Howard A. Haynes vs.
Department of Highways (CC-78-28l) - 283
Claimant was granted an award for damage to his pickup truck and station wagon
allegedly caused by disrepair of the
W. VA.] REPORTS
STATE COURT OF CLAIMS 389
road over which claimant had to drive in order to reach his home. Claimant
indicated that he had complained of the situation to the respondent but no
repairs were made to the roadway; therefore, the Court made an award for the
damages to said vehicles. R. L. Jarrell
vs. Dept.
of Highways (CC-78-
172) 319
The standard measure of damages for injury to personal property is the loss of
fair market value plus reasonable and necessary expenses incurred by the owner
in connection with the injury. Where claimant?s bus was totally destroyed by
employees of the respondent who failed to follow statutory procedures, and the
claimant expressed the value of the bus, the Court made an award to the
claimant for said value.
Robert H. Johnson vs. Department of
Highways (CC-77-146) 98 Where
claimant?s automobile sustained damage when it
struck a pothole, the Court denied the claim, as it appeared that the State had
no notice at all of said hole. James G.
Keith
vs. Department of Highways (CC-77-188)
--- 199
Claimants were granted awards for personal injuries sustained in a single-vehicle
accident when the vehicle in which they were traveling came upon an area of
highway with three large holes which caused the accident. The respondent was
negligent in its failure to warn motorists of the danger created by the holes. Forest Joe King, et al. vs. Dept. of Highways
(CC?77-37) 208
Even though the claimant demonstrated that there were defects in the highway
which caused the damage to his automobile, to establish negligence on the part
of the respondent there must be proof that the respondent either knew, or, in
the exercise of ordinary care, should have known about the defects. Without
such proof, the Court must disallow the claim.
John Lavender, Jr. vs. Department of
Highways (CC-77-85) 54
An award was made to claimant for paint damage to her automobile when she
encountered a large paint spill on the highway and was unable to avoid going
through it. Debris J.
Lively vs. Department of Highways (CC-77-228)
153
Where claimant sustained damage to his vehicle on a wooden bridge when a plank
unexpectedly came loose and caused the damage, the Court granted an award to
the claimant as the respondent had notice of the disrepair of the bridge and
failed to either warn the claimant or make repairs. Gerald J. Lynch
vs. Department of Highways (CC-77-175) 103
The claimant was denied an award for damage to his automobile which occurred
when his wife, who was driving, struck a hole in the road, damaging a tire and
rim. The Court has held many times that the State is not a guarantor of the
safety of travelers on its roads, and the user of the highways travels at his
own risk. James C. MacKnight vs.
Department
of Highways (CC-78-144b) 341
Claimant was granted an award for damage to his automobile when a ?MEN WORKING?
sign blew over and struck said automobile. Harold Mahaffee vs. Department of Highways
(CC?77?136) 211
Where the claimant left an automobile on the parking lot at Parkersburg
Community College and failed to make arrange-
390 REPORTS STATE
COURT OF CLAIMS [W. Va.
ments to leave the vehicle on the lot with personnel after school, the Court
held that there was no negligence or wrongdoing on the part of the respondent
which would justify recovery by the claimant for loss of the vehicle. David
L. Mayse
vs. Board of Regents (CC-77-173) 191
Where there was no evidence, and the evidence presented was conflicting, as to
the conditions of the roadway, the Court denied a claim where claimant?s
decedent, while driving his automobile, was involved in an accident alleged to
have been caused by a wet road covered with slag and cinders. The Court
concluded that if there were debris on the road, it was not caused by the
negligence of the respondent. Geraldine May McCarthy, Administratrix of the
Estate of Robert Eugene
McCarthy vs. Department of Highways (CC-76-33) 139 As the evidence failed
to establish that the respondent had
breached any legal duty owed to the claimant, the Court denied claimant?s claim
for damage to his automobile where the vehicle struck a pothole. Rodger C.
Melling vs. Depart men of Highways (CC-78-33) 174 Existence of gravel on a
road does not establish negligence
per se, and where there was no evidence in the record of any notice to
respondent that gravel had washed onto the highway during the night, the Court
denied a claim where claimant allegedly slid in the gravel, resulting in the
destruction of her automobile. Connie Lynn Miller vs. Department of Highways
(CC-76-124) 140
Claimant was granted an award for damage to its insured?s
vehicle which occurred when a barricade was blown into the
vehicle and the barricade had been negligently affixed by an
employee of the respondent. Nationwide Insurance Co., as sub roge of Phillip
W. Alexander vs. Department of Highways
(CC?79?150) 350
Where the respondent State agency knows that a road is too narrow for two-lane
traffic, and knowlingly allows the dangerous condition to exist, the respondent
will be held liable for damages sustained by a claimant whose son had an
accident on said road, causing damage to claimant?s automobile. Ari zon M.
Of futt vs. Department of Highways (CC-76-109) 107
The Court denied a claim for property damage to claimant?s vehicle when he
struck a large depression in the road. The law in West Virginia is well settled
that contributory negligence on the part of the claimant, however slight, which
contributes to proximately cause an accident, will preclude the recovery of
damages, and under the facts of this claim, claimant failed to take the
precautions necessary to protect his own safety and property. Charles Edward
Pauley vs. Department of Highways
(CC?78?136) 215
Where the parties stipulated that a flagman employed by the respondent directed
claimant to drive her automobile around a repair site between an asphalt truck
and a barricade, resulting in damage to her automobile when it became stuck
between the two obstacles, the Court made an award f or the damage. Anna
Jane Phillips vs. Department of Highways
(CC-77-131) 62
A claim for damage to an automobile as the result of striking a pothole was denied
as it must be established that,
W. VA.] REPORTS
STATE COURT OF CLAIMS 391
having received notice of a defect in the road, the respondent must also have
sufficient time within which to take remedial
action. Dallas Poe vs. Department of
Highways (CC-78-97) 201
Where the evidence established that the parties agreed to have a vehicle
belonging to the respondent repaired, but there was a misunderstanding as to a
limitation on the total cost of repairs, and the claimant exceeded the monetary
limit but completely repaired the vehicle, the Court made an award to the
claimant, since the State would be unjustly enriched if any other decision were
made. Raleigh Motor Sales, Inc. vs.
Department of Natural Resources (CC-76-123)
26
Where a light from a sign on a bridge fell on claimant?s automobile, the Court
held that the respondent was responsible for the maintenance and control of the
bridge, and made an award to the claimant for the damages. Franklin Ross and
Elsie M. Ross vs. Department of Highways (CC-77-132) ill
The Court has held many times that the respondent, Department of Highways, is
neither an insurer nor a guarantor of the safety of persons travelling on its
highways. Adkins v. Sims, 130 W. Va. 645, 46 S.E. 2d 81 (1947). The Court applied
this principle in denying a claim for damage to an automobile where the
automobile slipped into a ditch and the evidence disclosed that the road was
assigned a low priority as it was difficult to maintain due to its
inaccessibility. Romie
C. Sayre vs. Department of Highways (CC-78-64) - ---- 178
Where claimants sustained personal injuries when their vehicle struck a broken
section of interstate, causing the vehicle to leave the highway and overturn,
the Court made an award to the claimants as the respondent was negligent both
in permitting a dangerous condition to remain on the highway and in failing to
take effective action to warn motorists of the condition. James Ryan & Joyce Ryan vs. Dept. of Highways
(CC-77-l89) 329
Where respondent?s employees negligently dropped hot welding slag on the
windshield of claimant?s automobile, the Court made an award to the claimant
for the damage. Carolyn Crisp
Sherwood vs. Department of Highways (CC-77-214)
104
The Court made an award to the claimant for damage to her vehicle where the
respondent, while spray painting one of its buildings, over-sprayed, resulting
in paint damage to claimant?s automobile. Mary Jo Shreve v. Department of
High way (CC-77-70) 7
Where the parties stipulated that claimant?s automobile was
damaged when a metal plate became dislodged from a hole on
a state highway, the Court made an award to the claimant for
the damage in accordance with the stipulation. Lawrence
Craig
Skaggs v. Department of Highways (CC-77-56) 3
Claimant alleged damage to his automobile when said automobile fell through a
hole in the wooden floor of an old narrow bridge near Milton, West Virginia.
The evidence disclosed that the bridge had been closed and the respondent had
erected barricades at each end of the bridge, but said barricades or timbers
were removed by unknown third persons. The facts failed to establish any
negligence on the part of the respondent, and the Court denied the claim. Roy
D. Smith v. Department of Highways, (CC-76-129)
29
392 REPORTS STATE
COURT OF CLAIMS [W. Va.
The driver of a vehicle was made an award for damage sustained by said vehicle
even though it did not belong to him as he had repaired the vehicle, and the
Court held that a bailee in possession may sue for the recovery judgment for
wrongful damage or destruction by another of bailed property. Charles H.
Spradling, Jr. vs. Department of Highways (CC 78-68 336
Where claimant?s vehicle struck a signpost in the road and
there was no evidence that the post belonged to the respondent
or was knocked from the side of the road onto the highway,
the Court denied the claim. Foster Starcher vs. Department of
Highways (CC-76-l20) 157
When maintenance employees of the respondent operated a mower in such a manner
as to cause rocks and gravel to damage claimant?s insured?s automobile, the
Court made an award for the damage in accordance with the stipulation filed by
the parties. State Farm Mutual Auto Insurance Co., Subrogee of Dana Lee
Selvig vs. Board of Regents (CC-78-162) 288
Claimant was granted an award for damage to her vehicle when she struck a large
hole on Route 119 near Morgantown, West Virginia, as the Court held that the
road was one of the main arteries into the city, and respondent should have
known of the condition of the road and failed to keep it in a reasonably safe
condition. Connie Ann Stone vs. Department of
Highways (CC-78-177) 259
The Court denied a claim for damage to the paint of an automobile where the
evidence revealed that the employees of the respondent had performed no work on
the roadway on the day that claimant alleged the damage was done to his
vehicle. U.S.A.A. Insurance Co. & Harold F. May vs. Department of Highways
(CC-77-215a&b) 159
The Court denied a claim where claimant alleged that while driving his vehicle
along the berm of a highway his automobile struck a rock, because claimant
testified that he knew the rocks were there and could have avoided driving over
them. John Thomas Weddington vs. Department of Highways (CC 77?161 161
Where respondent?s employees negligently placed a sheet of metal over a hole in
a bridge, and, as a result of this negligence, claimant?s vehicle sustained
damage, the Court made an award to the claimant for said damage. Marvin Roy
Welch
vs. Department of Highways (CC-77-184) 73
Where the respondent State agency negligently issued a new title to a vehicle
in the name of the owner without the claimant?s lien being recorded thereon,
and claimant bank sustained a loss as the result of this negligence, the Court
made an award to the bank for the loss. Wood County Bank
vs. Dept. of Motor Vehicles (CC-78-209) 276
NATIONAL GUARD
Even though the Court agreed that the
National Guard occupied the position of an independent contractor when its
members performed snow removal operations on behalf of the respondent, the rule
of non-liability is subject to certain exceptions, one of which is where by
statute a special duty is imposed upon the respondent; therefore, the Court
made an
W. VA.] REPORTS
STATE COURT OF CLAIMS 393
award to the claimant where members of the National Guard, in removing snow
from a main highway, performed their work in a negligent manner, causing damage
to claimant?s fence line. Kermit Reed
Hubbs vs. Department of Highways
(CC-77-83) 39
Where the boom on claimant?s power loader was struck by a bulldozer being
operated by members of the National Guard in snow removal operations, the Court
made an award to the claimant for the damages to the boom in accordance with
the decision in Hubbs vs. Department of Highways, 12 Ct. Cl. 39 (1977). Hugh C. Mayfield vs. Department of Highways
(CC-77-118) 55
A claim filed by the claimant against the respondent for compensation for
injuries alleged to have been received while claimant was on duty with the West
Virginia National Guard in 1910 was dismissed, as the application of West
Virginia Code 14-2-21, the statute of limitations, excludes the claim from the
jurisdiction of the Court. Arthur
Vannort vs. Department of Veterans? Affairs and Adjutant General (CC-77-218) 267
NEGLIGENCE?See also Motor Vehicles;
Streets and Highways
Where negligence on the part of the
respondent is not shown to have caused the accident, the Court will deny a
claim where the claimant alleged that the driver of his vehicle went into a drainage
ditch adjacent to the road. Arthur
Adkins, Jr. vs.
Dept. of Highways (CC-78-83) - - 316
Where claimant alleged that she slid into an approaching dump truck belonging
to respondent when she encountered a Dept. of Highways vehicle parked on the right
side of the road, the Court denied the claim as the claimant did not prove by a
preponderance of the evidence that the accident was caused by the negligence of
the respondent. Jack D. Bailey &
Betty
Louise Bailey vs. Department of Highways (CC-78-49) 317
Where claimant?s house sustained damage when respondent?s employees began to
demolish the house in the aftermath of the Williamson flood, the Court made an
award to the claimant for the damage caused by the negligence of the
respondent. Gladys Barfield vs. Office
of the Governor?Emergency Flood
Disaster Relief (CC-78-173) 237
Where employees of the respondent negligently instructed the claimant to
proceed across a road onto which respondent?s employees had just dumped reddog,
and claimant?s vehicle sustained flat tires as a result thereof, the Court made
an award to the claimant for said damages. Raymond N. Belmont
vs. Department of Highways (CC-77-84) -- - 57
Where claimant was operating his van and was signaled to proceed onto fresh
tar, and as a result thereof the van was heavily splashed with tar, the Court
made an award to the claimant for the damage to the vehicle as respondent?s
failure to warn the claimant of the presence of this tar constituted
negligence. Charles A. Bowman vs.
Department of Highways
(CC-77-137) - - 66
Where a contractor of the Department of Highways damaged an expansion joint on
an interstate and failed to make any
394 REPORTS STATE
COURT OF CLAIMS [W. Va.
effort to notify the respondent or warn motorists, the Court made an award to
the claimant for damages to his automobile when he struck said expansion joint.
The law is well settled that the principal must bear the consequences of his
agent?s negligence, and therefore, the respondent is liable to the claimant. Jeffrey D. Bubar vs. Department of Highways (CC 78-27 204
Where respondent?s employees negligently cut two tempo rar cables installed by
the claimant after a slide had
occurred, the Court made an award to the claimant for the
damage to the cables. C & P Telephone
Company of West
Virginia vs. Department of Highways (CC-77-71)
? 239
Where employees of the respondent State agency negligently supervised students
who were using firearms with the result that bullets damaged claimant?s
telephone cables, the Court made an award to the claimant for the damages. The C & P Teleplwne Co. of W. Va. vs. Department of
Natural Resources
(CC-78-105) 164
Where employees of the respondent negligently damaged cables belonging to the
claimant while digging a trench, the Court made an award for the damages. The C & P Telephone
Company of West Virginia vs. Board of Regents (CC-78-152) 240
Where the negligence of the respondent was the proximate cause of the accident,
as it failed to provide for the safety of the traveling public during and after
the application of an anti-spalling compound to the highway, the Court made an
award to the claimant for injuries received in an accident when an automobile
being driven in the lane opposite the claimant slid in the anti-spalling
compound across the highway and into the claimant, causing the injuries to the
claimant. Michael H. Coen & Ruth
Coen vs. Department of Highways
(D-1008) 119
Where the parties stipulated that an employee of the respondent negligently
threw a rock against claimant?s vehicle, breaking the windshield, the Court
made an award to the claimant for said damage. Virginia Sue Cook vs. Department
of Highways (CC-77-144) ? ? 58
Where the claimants sustained damage to their property due to the negligence of
respondent?s employees in snow removal operations, the Court held that it was
negligence on the part of the operator of the equipment to fail to confine his
activities within the right-of-way of the road. See also Hubbs v. Department of Highways, 12 Ct. Cl. 39 (1977). Clyde W. Cummings & Betty L. Cummings v. Department of Highways
(CC-77-102) 41
Where the evidence in a case impels the conclusion that the respondent
Department of Highways, in the exercise of ordinary care, should have known of
the existence of a hole in the bridge, which hole was the cause of the accident
resulting in damage to claimants? truck, the Court made an award to the
claimants for said damages. Davis v.
Department of Highways:
Hartford Accident & Indemnity Company v. Department of
Highways (D-996a) (D-996b) 31
The respondent Department of Highways may not be held liable for negligent
maintenance of a section of highway until the date of final acceptance of the
highway by the respondent;
W. VA.] REPORTS
STATE COURT OF CLAIMS 395
therefore, in a claim for damage to a tractor-trailer which occurred when the
driver proceeded onto the berm of an entrance ramp to 1-77, and, in so doing,
passed over a metallic post which extended out of the berm, the Court held that
the Department of Highways was not liable since the State had not yet signed
and approved the final acceptance for the highway. Econo-Car International, Inc. vs. Department of High
way (CC-76-32) ? 80
Where claimants? fence was damaged by an employee of the
respondent during road grading operations, the Court made an
award to the claimant for the damage. Albert
D. Fentress &
Hazel S. Fentress vs. Department of Highways (CC-77-162) -.
94
An award was made for damage to claimants? gas tank
which occurred when their automobile struck a large rock
which had been knocked into the road by a grader and left
there. The Court concluded that the accident was caused by
negligence on the part of the respondent. Teresa K. Gillispie
and Johnny Wayne Gillispie vs. Dept. of Highways (CC-78-
153) 248
Where claimant admitted that he was aware of the existence of the hole in the
road, but was forced to drive into it, the Court held that the claimant?s
admission of his knowledge of the existence of the hole was proof that
claimant?s own negligence was the proximate cause of the accident. Larry A.
Giolitto vs. Department of Highways (CC-78-205)
249
Claimant was denied a claim for damage to his vehicle which occurred when the
vehicle struck an embankment as the Court determined that, even though the
respondent was negligent in failing to maintain a culvert causing accumulation
of water on the highway, the claimant was guilty of contributory negligence
which proximately contributed to the accident.
Lloyd Harding Gwinn vs. Dept. of
Highways (CC-77-191) 128
Where claimant sustained injuries as the result of a fall when leaving a
ladies? restroom at Fairmont State College, the Court determined that the
accident was one which would not have occurred if the claimant had been
exercising ordinary care, and the lack of such care was negligence on her part.
Mary Jo Hall vs. Board of Regents (D-1025) 232
The simple existence of a pothole in the road does not make the State negligent
per se, as the State must have had actual or constructive notice of the
particular road defect which allegedly caused the accident. Therefore, the
Court denied the claim where claimant?s son, while driving his vehicle, struck
a hole and caused damage to said vehicle. William L. Hanson, Sr. & William L. Hanson, Jr. vs. Dept. of
Highways (CC-78-
82) 197
Where respondent?s employees negligently left pieces of welding rod material on
a bridge after completing the day?s work, and claimant?s motorcycle tire and
tube were punctured by the pieces of welding rod material, the Court made an
award in accordance with the written stipulation filed by the parties. Michael J. Hart vs. Department of Highways (CC-77-
124) 52
Claimants were made an award for damage to their property during snow removal activities
(See Hubbs vs. Highways, 12
396 REPORTS STATE
COURT OF CLAIMS [W. Va.
Ct. Cl. 39 [19771). Robert M. Hastings & Linda Hastings, d/b/a Hastings
Stables vs. Department of Highways (CC 77-94 ? 44
Where claimant?s automobile sustained
damage as the result of striking construction plates which were not securely
fastened down on the highway, the Court made an award to the claimant for the
damages, as the negligence of the respondent was the proximate cause of the
damage. Howard A.
Haynes vs. Department of Highways (CC-78-281) 283
As the duty of snow removal is the responsibility of the W. Va. Commissioner of
Highways within the meaning of the term ?maintenance? (See W. Va. Code
17-2A-8), this particular duty cannot be delegated nor assigned; therefore, the
respondent is liable for actions of negligence by an independent contractor
which damaged claimant?s property during the removal of snow from a highway. Kermit
Reed Hubbs vs.
Department of Highways (CC-77-83) 39
Where the parties stipulated that the respondent negligently failed to secure a
steel plate covering a large hole in Route 60 in South Charleston, and said
negligence resulted in damage to claimant?s car, the Court made an award to the
claimant for said damages. McHenry Hudnall, Jr. vs. Department of
Highways (CC-77-52) 26
Claimant was granted an award for damage to her automobile when her automobile
ran over a sign belonging to the respondent as the Court held that leaving a
sign upon the traveled portion of the highway constituted negligence. Peggy
Keyser vs. Department of Highways (CC-78-38) 199
Claimants were granted awards for personal injuries sustained in a
single-vehicle accident when the vehicle in which they were traveling came upon
an area of highway with three large holes which caused the accident. The
respondent was negligent in its failure to warn motorists of the danger created
by the holes. Forest Joe King, et al. vs. Dept. of Highways
(CC-77-37) 208
The Court denied a claim for damage to claimant?s type write which occurred
when an involuntarily committed pa tien was issued a pass to seek legal
assistance from the claim ant The Court noted that an institution is not
negligent per se
whenever a temporarily released patient causes damage to
someone?s property. James T. Kratovil vs. Department of
Health, Division of Mental Health (CC-78-54) 200
Even though the claimant demonstrated that there were
defects in the highway which caused the damage to his auto mobile to establish
negligence on the part of the respondent
there must be proof that the respondent either knew, or, in
the exercise of ordinary care, should have known about the
defects. Without such proof, the Court must disallow the claim.
John Lavender, Jr. vs. Department of Highways (CC-77-85) 54
Where the claimant left an automobile on the parking lot at Parkersburg
Community College and failed to make arrangements to leave the vehicle on the
lot with personnel after school, the Court held that there was no negligence or
wrongdoing on the part of the respondent which would justify recovery by the
claimant for loss of the vehicle. David L.
Mayse vs. Board of Regents (CC-77-l73) 191
W. VA,] REPORTS
STATE COURT OF CLAIMS 397
Existence of gravel on a road does not establish negligence per se, and where
there was no evidence in the record of any notice to respondent that gravel had
washed onto the highway during the night, the Court denied a claim where
claimant allegedly slid in the gravel, resulting in the destruction of her
automobile. Connie Lynn Miller vs.
Department of Highways
(CC-76?124) 140
Claimant was granted an award for damage to its insured?s vehicle which
occurred when a barricade was blown into the vehicle and the barricade had been
negligently affixed by an employee of the respondent. Nationwide Insurance Co., as Subrogee of Phillip W.
Alexander vs. Department of Highways
(CC-79-150) 350
Where the respondent knew of dangerous road conditions caused by a tar spill on
State Route 4 in Clay County, and negligently failed to correct the situation,
and the respondent also knew that several accidents had occurred at this point,
resulting in torn-out guardrails, the Court made an award on a stipulated claim
of wrongful death where claimant?s decedent died as a result of coming upon the
tar spill and sliding through the torn-out guardrails into a creek where he
died. Helen L. Norvell, Executrix of
the Estate of Glenn Hartsel
Norvell, Deceased vs. Department of Highways (D-936)
- - 106
Where the respondent State agency knows that a road is too narrow for two-lane
traffic, and knowingly allows the dangerous condition to exist, the respondent
will be held liable for damages sustained by a claimant whose son had an
accident on said road, causing damage to claimant?s automobile.
Arizona M. Offutt vs. Department of
Highways (CC-76-109) -- 107
Where the record established that claimant was driving in a construction area
over an avenue closed to traffic, the Court held that the claimant?s negligence
was the cause of the accident. Charles
C. Quigley vs. Department of Highways (CC-76-
47) 5
Where the evidence disclosed that the State had erected ?Street Closed? or
?Road Closed? signs in a construction area which also provided a small amount
of open space as a means of ingress and egress for local residents, the Court
found no negligence on the part of the respondent when the claimant drove
through said area and was struck by an automobile coming from another
direction. Charles C. Quigley vs.
Depart men of Highways (CC-76-47)
5
Where claimant alleged that an accident occured due to the negligent design of
the highway which narrowed to the left at the place of the accident, the Court
held that since no proof of negligence was presented by the claimant and there
were no defects in the pavement, the respondent met the required standard of
care, and the claim was denied. Marie
T. Sadd vs.
Department of Highways (CC-77-36) 63
Where respondent?s employees negligently dropped hot welding slag on the
windshield of claimant?s automobile, the Court made an award to the claimant
for the damage. Carolyn
Crisp Sherwood vs. Department of Highways (CC-77-214)
104
Where one of the claimants testified that she and her husband were familiar
with the highway, traveling it several times a week, and candidly admitted that
she was aware of the
398 REPORTS STATE
COURT OF CLAIMS [W. Va.
existence and location of the pothole, the Court held that even if the
respondent were guilty of negligence in failing to repair the hole, the
claimants were guilty of contributory negligence in failing to exercise a
proper lookout in order to avoid striking the hole. Joseph and Marie Sowers vs. Depart men of Highways (CC-77-51) 21
Claimant was granted an award for damage to her property and a black walnut
tree, which damage occurred when respondents were repairing a road in front of
claimant?s property. Barbara H. Spitzer
vs. Department of Highways
(CC-78-164) 314
Claimant was granted an award for damage to the vehicle he was driving where it
struck an expansion joint, even though said damage was the result of negligent
acts of an independent contractor of the respondent, as the law is well settled
that the principal must bear the consequences of his agent?s negligence. Charles H. Spradling, Jr. vs. Department of
Highways (CC-78-68) ? 336
Where respondent?s agent damaged a steel expansion joint incident to snow
removal and left it protruding above the surface of the highway so as to create
a hazard to vehicular traffic, respondent was negligent and was liable for
damage thereby done to the undercarriage of claimant?s vehicle. Charles H. Spradling, Jr. vs. Department of Highways (CC 78?68 336
Even though respondent was negligent in failing to repair
a large hole in a tunnel, claimant was contributorily negligent
when he, knowing of the large hole, drove through the unlit
tunnel at a speed of 35 mph and struck the hole, causing him
to drive off the roadway. Hayes Stanley
vs. Dept. of Highways
(CC-77-145) 258
When maintenance employees of the respondent operated a mower in such a manner
as to cause rocks and gravel to damage claimant?s insured?s automobile, the
Court made an award for the damage in accordance with the stipulation filed by
the parties. State Farm Mutual Auto
Insurance Co., Subrogee of Dana Lee Selvig vs. Board of Regents (CC-78-162) 288
Where the respondent negligently caused snow to be piled on claimant?s
property, killing certain trees, the Court made an award to the claimant for
the damage sustained. Willard P. Teets,
Attorney in Fact for Percy E. Teets vs. Department
of Highways (CC-77-158) ? 203
Where employees of the respondent wrongfully cut down trees on property
belonging to the claimants, even though the employees believed that they had a
right to do so, the respondent is liable to the claimants for the damages. Fred K. Testa and Claudia I. Testa vs. Department of
Highways (D-669a), Saleem A. Shah & Teresa A. Shah vs. Department
of Highways (D-669b) 115
Claimant was granted an award for personal injuries sustained at a State forest
when a large limb fell from a dead tree near a picnic table at which the
claimant was sitting, as the respondent was negligent for failing to remove the
dead tree. Edith Ann Thompson &
Roger Dale Thompson vs.
Department of Natural Resources (CC-77-7)
132
W. VA.] REPORTS
STATE COURT OF CLAIMS 399
Where claimants filed a claim for personal injuries sustained in an accident at
a railway underpass where a train derailment resulted in holes in the road
which allegedly caused the accident, the Court denied the claim as the evidence
indicated that there was a ?ROUGH ROAD? sign placed by the respondent and that
frequent repairs were made to the surface of the highway; therefore, the
respondent was not guilty of negligence which proximately caused the accident. Billy Joe Vinson
and Paul F. Vinson vs. Department of Highways (CC-77-l57) 219
Where the claimant sustained personal injuries when she fell into a hole on the
sidewalk of a bridge, which hole she had seen prior to crossing the bridge, the
Court held that the claimant was guilty of contributory negligence as a matter
of law. Dema Marie Welch vs. Department
of Highways
(CC?77?17) ? ? 136
Claimant alleged personal injuries suffered when she fell after the heel of her
shoe became caught in a gap between a sidewalk and curb. The Court denied the
claim as the claimant failed to exercise reasonable care for her own safety,
for the law is well settled that a pedestrian has the duty to exercise ordinary
and prudent care for his own safety and to look for and protect himself from
known and visible dangers, and failure to do so constitutes contributory
negligence as a matter of law. See Vance vs. Dept. of Highways, 10 Ct. Cl. 189
(1975).
Chrystine Winer vs. Dept. of Highways (CC-78-170) 353
NOTICE
Where the respondent, having knowledge
of the condition which caused drainage onto claimant?s property, failed to take
corrective measures, the Court made an award to the claimant for the damage to
the property. Curtis Allison vs.
Department
of Highways (CC-77-11Q) ? 84
Where the respondent had actual notice of claimants? claim for relocation
expense, the fact that the notice was not written in the form required by
respondent did not bar the claim, because the memorandum did not have the force
and effect of law; therefore, the Court made an award to the claimants for said
relocation expense. Olie G. Bastin and
Priscilla Bastin vs.
Department of Highways (CC-76-24)
86
Claimant alleged damage to his vehicle when he struck a boulder which had
crashed onto the highway. The Court denied the claim as the boulder had fallen
just prior to the accident and there was no evidence that the respondent knew
or should have known of the existence of an unusually dangerous condition. Arnold W. Bolyard vs. Department of Highways (CC-78-l) ? 344
Where claimant?s automobile sustained damage when she struck a pothole, the
Court determined that there was no notice of the dangerous condition of the
highway, nor was there such a neglect of duty as to create liability on the
part of the respondent, and the claim was disallowed. Cynth.in
Lou Bradshaw vs. Department of Highways (CC-78-30)
187
Where claimant?s automobile sustained damage when it struck a rock on the
highway, the Court denied the claim as there was no showing that the respondent
knew or should have known of the dangerous condition, especially since the rock
400 REPORTS STATE
COURT OF CLAIMS [W. Va.
had fallen on the highway immediately before the accident.
Lawrence Childers vs. Department of
Highways (CC-78-63) 346
Claimant was denied a claim for damages to her automobile when she struck a
hole in the road as there was no evidence that the respondent had either actual
or constructive notice of said hole. Ilene
Clark Cooksey vs. Department of Highways
(CC-77-114) 195
Where a hole in the road appeared suddenly and without warning, proof of actual
or constructive notice is a prerequisite to establishing negligence; therefore,
the Court denied the claim since respondent did not have notice of the
particular hole in this claim in time to prevent the accident. (See Hoskins vs. Department of Highways, 12 Ct. Cl. 60 [19771).
John F. Cummings vs. Department of
Highways (CC-76-77) 59
Claimant was denied recovery for damage to his automobile caused when he struck
a hole in the road, as the Court determined that there was no evidence to the
effect that the respondent knew or should have known of the existence of the
hole.
Merton M. Delancey vs. Department of
Highways (CC-78-91) 245
A claim for damage to an automobile as a result of striking a pothole was
denied as the Court held that for the State to be found liable for
pothole-caused damages, the claimants must first establish that the State had
actual or constructive notice of the particular hazard which caused the
accident.
Aileen W. Dodrill vs. Department of Highways
(CC-78-67) - 196
Where there was no evidence in the record that the respondent had notice of the
hole in the road prior to the accident, a claim for damages to claimants?
automobile was denied by the Court. Lawrence
& Claudette Ferguson vs. Department of
Highways (CC-78-lOO) 326
Where there was no evidence on record of prior notice to the respondent, there
is insufficient evidence to establish negligence on the part of the respondent;
therefore, claimant?s claim for damages to his automobile when he struck a hole
in the road was denied. William C. Griffing vs.
Department of High way (CC-77?50) 127
The simple existence of a pothole in the road does not make the State negligent
per se, as the State must have had actual or constructive notice of the particular
road defect which allegedly caused the accident. Therefore, the Court denied
the claim where claimant?s son, while driving his vehicle, struck a hole and
caused damage to said vehicle. William
L. Hanson, Sr. &
William L. Hanson, Jr. vs. Dept. of Highways (CC-78-82) 197
Where the claimant struck a large hole in the inside eastbound lane of 1-70
just beyond the Wheeling Tunnel, and the evidence disclosed that the hole
apparently came into existence within an hour of the accident, the Court denied
the claim since proof of actual or constructive notice is required. Patricia
S. Hoskins vs. Department of Highways (CC-76-79)
60
Where claimant?s automobile sustained damage when it struck a pothole, the
Court denied the claim, as it appeared that the State had no notice at all of
said hole. James G. Keith
vs. Department of Higiways (CC-77-188)
199
Claimants were granted awards for personal injuries sustained in a
single-vehicle accident when the vehicle struck
W. Va.] REPORTS
STATE COURT OF CLAIMS 401
three large potholes. The evidence indicated that the holes had been there for
a substantial period of time, creating a dangerous condition of which the
respondent either knew, or, in the exercise of ordinary care, should have
known. Forest
Joe King, et al vs. Dept. of Highways (CC-77-37)
-- 208
Where claimants? vehicle was damaged by a loose plank in a wooden bridge and
the respondent had constructive knowledge of the need of repairs to the bridge,
the Court made an award to the claimants for the damages. Linda Lester and Leon Lester vs. Department of Highways
(CC-77-
210) 102
Where there was no evidence in the record of any notice to the respondent of
the defect in the road, the simple existence of such a defect does not
establish negligence per se; therefore, the Court denied a claim for damage to
claimant?s vehicle, which had struck a pothole. Daniel Lewis Light vs.
Department of Highways (CC-77-53) 61
A claim for damage to claimant?s automobile, which occurred when it struck a
hole in the road, was denied because there was no evidence in the record of any
notice to the respondent of the defect. James
C. MacKnight vs. Dept. of
Highways (CC-78-144a) 340
The claimant was granted an award for injuries received when she fell while
entering an outhouse at a State park, for the record established that the
respondent knew, or, with reasonable effort should have known, of the condition
of the outhouses, and the failure to properly maintain the facilities
constituted negligence. Alice Marcum
vs. Department of Na tura Resources (CC-76-65)
211
A claim for damage to an automobile as the result of striking a pothole was
denied as it must be established that, having received notice of a defect in
the road, the respondent must also have sufficient time within which to take
remedial action.
Dallas Poe vs. Department of Highways (CC-78-97) 201
Where claimant sustained injuries to her leg when she stepped into a large hole
in the roadway, the Court made an award for the injuries sustained, as the
Court determined that the respondent had constructive knowledge of said hole
and was negligent in failing to take remedial measures or to warn the public of
the presence of the hole. Rhoda Raynett
Mcintyre vs. Dept. of Highways (D-737)
213
Where the respondent knew of dangerous road conditions caused by a tar spill on
State Route 4 in Clay County, and negligently failed to correct the situation,
and the respondent also knew that several accidents had occurred at this point,
resulting in torn-out guardrails, the Court made an award on a stipulated claim
of wrongful death where claimant?s decedent died as a result of coming upon the
tar spill and sliding through the torn-out guardrails into a creek where he
died. Helen L. Norvell, Executrix of
the Estate of Glenn Hartsel
Norvell, Deceased vs. Dpartment of Highways (D-936) 106
Where the respondent State agency knows that a road is too narrow for two-lane
traffic, and knowingly allows the dangerous condition to exist, the respondent
will be held liable for damages sustained by a claimant whose son had an
accident on said road, causing damage to claimant?s automo
402 REPORTS STATE
COURT OF CLAIMS [W. Va.
bile. Arizona M. Of futt vs. Department
of Highways (CC-76-
109) 107
Where the respondent, Department of Corrections, had a contract with the
claimant for certain psychological services to be provided to two institutions
of the respondent, and the claimant was orally notified that the contract would
expire and that the claimant would receive no compensation for the last 65 days
of the contract, the Court made an award, because oral notification was not in
compliance with the contract provision of 30 days? written notice. Positive Peer Culture, Inc.
vs. Dept. of Corrections (CC-77-117)
285
The Court denied a claim where claimant?s son, while operating claimant?s
automobile, struck a pothole which was filled with water as there was
insufficient evidence to establish notice or constructive notice to the
respondent of the pothole, and the simple existence of a pothole does not
establish negligence per se. Robert M.
Pratt vs. Department
of Highways (CC-78-122) 176
It is well established that the State is neither an insurer nor a guarantor of
the safety of persons traveling on its highways, and such law is applicable to
pedestrians crossing the highway. Therefore, where the claimant who suffered
injuries as a result of falling in a hole in the pavement of a road, the Court
held that there must be proof that the respondent had actual or constructive
notice of the defect in the road in order to establish negligence. Jeanne Robinson vs. Department of
Highways (CC-77-33) 145
Where a live tree fell across the highway and claimant?s van collided with the
tree, resulting in damages to the van and injuries to the claimant, the Court
concluded that there was no evidence that the respondent knew or in exercise of
ordinary care should have known that the tree posed a hazard to traffic on the
highways; therefore, the Court denied the
claim. Randall I. Samples vs. Dept. of
Highways (CC-77-82) 217
The Court made an award to claimant for damage to an automobile when claimant?s
wife, while driving said vehicle, struck a hole in the road. The Court held
that the respondent owes a duty of reasonable care and diligence in the
maintenance of highways, especially where the respondent had notice of the
dangerous condition and the repairs should have been made within a reasonable
time. Larry Keith Smith vs.
Dept. of Highways (CC-78-259) 351
The failure of the respondent to exercise ordinary care must be established by
a preponderance of the evidence, and, while the claimant testified that there
was mud and water on the road resulting from a clogged drainage ditch, and the
condition caused the claimant?s accident, there was no evidence introduced to
establish notice to the respondent of the condition of the roadway. The Court
denied the claim. Gerald E. Tinsley and
Lois C. Tinsley vs. Department of Highways
(CC-77-165) 134
OFFICE EQUIPMENT AND SUPPLIES
Claimant?s claim for payment of
merchandise which was ordered, shipped, and received by the respondent, but for
which the respondent was not able to pay as there were in-
W. Va.] REPORTS
STATE COURT OF CLAIMS 403
sufficient funds remaining in its appropriation for the specific fiscal year, the
Court denied the claim in accordance with the Airkem decision. AIling and Cory
vs. Dept. of Corrections
(CC-78-232) 235
Where the respondent State agency admitted the validity of
the claim but stated that it lacked the necessary funds in the
appropriate fiscal year from which the claim could have been
paid, the Court denied the claim where claimant sought pay men of a bill for a
renewal equipment performance program
for a Miracode Microfilmer. See Airicem, et al. vs. Department
of Mental Health, 8 Ct. Cl. 180
(1971). Eastman Kodak Co. vs.
Office of the Secretary of State (CC-78-112)
167
Where the respondent admitted the validity of the claim and stated that payment
for the equipment delivered by the claimant had not been made prior to the
close of the particular fiscal year in which the equipment was received, the
Court made an award to the claimant for the equipment. Dill?s Mountaineer Associates, Inc. vs. Department of
Health (CC-
79-94) 348
Claimant was granted an award for small purchases made by the respondent as the
respondent admitted the validity of the claim and that it had sufficient funds
with which to pay for the purchases in the fiscal years in question. Heck?s Inc.
vs. Division of Vocational Rehabilitation (CC-79-36) 339
A claim for transportation charges related to typewriters contracted for under
a lease agreement between the claimant and respondent will be allowed by the
Court inasmuch as there was a specific provision in the contract relating
thereto. IBM
Corporation vs. Department of Motor Vehicles (CC-77-1) 2
The Court disallowed a claim for a service and lease agreement for copying
equipment and typewriters as the respondent State agency had no funds remaining
for the fiscal year in which the obligation could have been paid; the claim was
barred by Airkem Sales and Service, et
al. v. Department of Mental Health, 8
Ct. Cl. 180 (1971). IBM Corporation vs.
Department of Corrections (CC-78-277)
284
Where claimant performed printing service for the respondent and the respondent
admitted the validity of the claim and the amount due, the Court made an award
to the claimant. Jones Printing
Company, Inc. vs. Governor?s Office of Economic and Community Development (CC-77-207) 99
Where claimant sought compensation for goods furnished and services rendered to
West Virginia University, and the respondent admitted the validity of each
claim and that there were sufficient funds available at the close of the fiscal
year from which the claims could have been paid, the Court made awards to each
of the claimants. Light Gallery and
Supply
Co., et al. vs. Board of Regents (CC-79-2)
321
Claimant was granted an award for business forms where the respondent had
received and accepted the same, even though the forms were in excess of the
amount of the original order. Moore
Business Forms, Inc. vs. Department of Health,
Division of Mental Health (CC-78-46)
214
The Court made an award to the claimant for unpaid invoices admitted by the
respondent. 3M Business Products
Sales, Inc. vs. Department of Motor Vehicles (CC-77-194) 118
404 REPORTS STATE
COURT OF CLAIMS [W. Va.
Claimant was granted an award for the cost of printed forms shipped by the
claimant to the respondent, but for which the claimant failed to be paid as the
invoice was received by the respondent after the close of the fiscal year. Uarco,
Inc. vs. Board of Regents (CC-78-53) 150
PARKS AND PLAYGROUNDS
Where claimant?s automobile was
damaged when a limb from a live tree fell onto her car while she was visiting a
State park, the Court disallowed the claim as there was no explanation of why
the limb fell, nor any proof that it fell as a result of negligence on the part
of the respondent. Harold Hersom and Eleanore Hersom vs. Dept. of Natural
Resources (CC-77-
170) 312
Claimants filed a claim for injuries received when a limb from a dead tree fell
while claimants were fishing at North Bend State Park. The Court denied the
claim as this was not an area of the park designated for fishing, nor was it
patrolled or maintained by the respondent for use by the public; therefore, the
respondent was not negligent in its maintenance of the area. Frances J.
Larch and William E. Larch vs. Dept. of
Natural Resources (CC-77-120) 291
The claimant was granted an award for injuries received when she fell while
entering an outhouse at a State park, for the record established that the
respondent knew, or, with reasonable effort should have known, of the condition
of the outhouses, and the failure to properly maintain the facilities
constituted negligence. Alice Marcum vs. Department of
Natural Resources (CC-76-65) 211
Claimant was granted an award for personal injuries sustained at a State forest
when a large limb fell from a dead tree near a picnic table at which the
claimant was sitting, as the
- respondent was negligent for failing to remove the dead
tree. Edith Ann Thompson & Roger Dale Thompson vs. Department of Natural
Resources (CC-77-7) 132
PEDESTRIANS
Claimant sustained personal injuries
when he fell into a large hole adjacent to a path used by students attending a
Fine Arts Camp at West Virginia University. The general law is that an
institution is under a duty of ordinary or reasonable care with regard to the
condition of its grounds to see that they are maintained in a reasonably safe
condition, and, as the respondent failed in this duty, the Court made an award
to the claimant. Jacquelyn B. Eisenberg, parent and next friend of Mark
Harold Eisenberg, an infant vs. Board of Regents
(CC-76-143) 273
Where claimant sustained injuries to her leg when she stepped into a large hole
in the roadway, the Court made an award for the injuries sustained, as the
Court determined that the respondent had constructive knowledge of said hole
and was negligent in failing to take remedial measures or to warn the public of
the presence of the hole. Rhoda Raynett McIntyre vs. Dept. of Highways (D-737)
-- 213
Where the claimant sustained personal injuries when she fell into a hole on the
sidewalk of a bridge, which hole she
W. Va.] REPORTS
STATE COURT OF CLAIMS 405
had seen prior to crossing the bridge, the Court held that the claimant was
guilty of contributory negligence as a matter of law. Dema Marie Welch, vs.
Department of Highways
(CC?77?17) 136
If the claimant had exercised the reasonable care required of her under the
circumstances, and maintained a proper lookout for a hole in the walkway of a
bridge which she knew to be there, she would have been able to avoid the
injury. Therefore, the Court denied the claim, as the condition of the bridge
was not the proximate cause of the accident. Dema
Marie Welch vs. Department of Highways (CC-77-l7) 136
It is well established that the State is neither an insurer nor a guarantor of
the safety of persons traveling on its highways, and such law is applicable to
pedestrians crossing the highway. Therefore, where the claimant who suffered injuries
as a result of falling in a hole in the pavement of a road, the Court held that
there must be proof that the respondent had actual or constructive notice of
the defect in the road in order to establish negligence. Jeanne Robinson vs.
Department of
Highways (CC-77-33) 145
Claimant alleged personal injuries suffered when she fell after the heel of her
shoe became caught in a gap between a sidewalk and curb. The Court denied the
claim as the claimant failed to exercise reasonable care for her own safety,
for the law is well settled that a pedestrian has the duty to exercise ordinary
and prudent care for his own safety and to look for and protect himself from
known and visible dangers, and failure to do so constitutes contributory
negligence as a matter of law. See Vance vs. Dept. of Highways, 10 Ct.
Cl. 189 (1975).
Chrystine Winer vs. Dept. of Highways (CC-78-170) --- 353
PERSONAL SERVICES
A claim for personal services rendered
by the claimant as a consultant to the Tax Department was admitted by the
respondent State agency, which requested payment of the claim, and the Court
made an award to the claimant for said services.
Donald M. Bondurant vs. State Tax Department (CC-77-142) 24
PHYSICIANS AND SURGEONS?See also
Hospitals
Where claimant physician rendered
professional services to a patient at a State hospital, for which services
claimant was not paid because the agency failed to have sufficient funds in its
budget, the Court applied the Airicem decision and denied the claim. Pedro
N. Amhrosio vs. Department of Health, Division of Mental Health (CC-77-90)
15
Where the respondent refused to pay the statement submitted by medical doctors
who rendered professional services to a trooper in the employ of the respondent
because the statement was submitted after the close of the fiscal year, the
Court made an award for said services. H. M. Hills, Jr. & Luis A.
Loimil vs. Department of Public Safety (CC-77-200) 70
Claimant sought payment for services rendered to an inmate of the Department of
Corrections, but the Department lacked the requisite funds in its appropriation
for the fiscal year in question; therefore, the Court disallowed the claim
based upon the decision in Airkem Sales and Service, et al. vs. Depart-
406 REPORTS STATE
COURT OF CLAIMS [W. Va.
ment of Mental Health, 8 Ct. Cl. 180 (1971). Physicians Fee
Office vs. Department of Corrections (CC-78-74)
175
Claimant, an organization for the handling of bills and collection of charges
for professional services rendered by physicians at the Medical Center at West
Virginia University, filed a claim for such services to a patient of the
respondent. The Court denied the claim, based upon the principles set forth in Airkem Sales and Service vs. Department of Mental
Health, 8 Ct. Cl. 180 (1971), as the
respondent failed to expire sufficient funds in the pertinent fiscal year. Physicians Fee Office vs. Department of Health,
Division of Mental Health (CC-77-
76) 17
Claimant ambulance service was denied a claim for ambulance service calls where
there was no evidence that the claimant complied with the respondent?s
regulation for certification by the attending physician of the transportation
used. Rick?s
Ambulance vs. Department of Welfare (CC-77-2l3)
255
Where claimant sought payment for salary due him for professional services
performed for the respondent, and the respondent admitted the validity of the
claim, the Court made an award to the claimant. Silas C. Wiersma vs. Dept.
of
Health, Division of Mental Health (CC-78-l58) 234
PRISONS AND PRISONERS
The claimant was granted an award for
a towing fee which she had to pay after her vehicle, which had been stolen by
an inmate from Huttonsville Correctional Center, was later towed to another
city by the West Virginia State Police. Ora
T. Herron vs. Dept. of Public Safety and Dept. of Corrections
(CC-76-108) 284
The Claimant filed a claim for damages allegedly sustained as the result of the
alleged unlawful revocation of his probation and subsequent confinement at
Huttonsville Correctional Center when he was released upon a writ of habeas
corpus. The respondent made a motion to dismiss the claim based upon the theory
that claimant had an adequate remedy at law in the federal courts under the
Civil Rights Act, 42 U.S.C. ? 1983. The Court sustained the motion to dismiss
as to specific individuals named in the claim in accordance with W. Va. Code
14-2-13, since under that provision, the Court has no jurisdiction over any
individual person. Lewis Dale Metz vs.
State Board of
Probation and Parole and Dept. of Corrections (CC-77-l55) 342
Where the claimant filed a claim alleging damages sustained as the result of an
alleged unlawful revocation of his probation and subsequent confinement at
Huttonsville Correctional Center, the Court overruled respondent?s motion to
dismiss based upon the theory that the claimant had an adequate remedy at law
in the federal courts under the Civil Rights Act, 42 U.S.C. ? 1983. The Court
held that the agencies, West Virginia Board of Probation and Parole and West
Virginia Department of Corrections, named in the complaint as respondents, are
not considered ?persons? within the meaning of the Civil Rights Act. Lewis Dale Metz vs. State Board of
Probation and Parole and Dept. of Corrections (CC-79-l55) 342
Claimant was granted an award for damage to his vehicle when two inmates from
Huttonsville Correctional Center
W. Va.1 REPORTS
STATE COURT OF CLAIMS 407
walked away from the institution, stole the vehicle, and damaged it. To deny
the claim would amount to imposing a
penalty upon a citizen of the State for living near a correc tiona institution.
Albert K. Tyre vs. Dept. of Corrections
(CC 78-178 263
The Court made an award to the claimant for damage to his
vehicle caused by inmates who had walked away from Hut tonsvill Correctional
Center and stolen the vehicle. A review
of the law by the Court regarding acts of escapees from
institutions made it apparent that each claim must be decided
on its own particular facts. Albert K.
Tyre vs. Dept. of Cor?
rections (CC-78-178) ?
263
PUBLIC EMPLOYEES RETIREMENT SYSTEM
Claimant, a former employee of the
Department of Welfare, requested the Court to direct the respondent, Public
Employees Retirement System, to pay claimant for retirement benefits which
claimant alleged she was legally entitled to receive. The Court determined that
the claimant failed to establish that she was entitled to the claimed
retirement benefits, and, therefore, refused to make an award. Lillian M. Holstein vs.
Public Employees Retirement System (CC-78-78)
151
Claimant, a former employee of the Department of Welfare, requested the Court
to direct the respondent, Public Employees Retirement System, to pay retirement
benefits to the claimant to which claimant alleged she was legally entitled.
The Court determined that it did not have statutory jurisdiction to direct the
respondent to reward retirement benefits to the claimant, and, therefore, the
motion to dismiss the claim was sustained. Lillian M. Holstein vs. Public Employees Retirement System
(CC-78?78) 151
PUBLIC INSTITUTIONS
Where claimant?s decedent sustained
injuries as the result of a fall while under the care of respondent?s
institution, the Court held that to conclude that the respondent was guilty of
negligence that proximately caused the death of the decedent, the Court would
be speculating, which the Court cannot do. Therefore, the Court denied the
claim. Ervin Arthur, Administrator of
the Estate of Cecil C. Brumfield, deceased vs.
Department of Health, Division of Mental Health (CC-76-56) 124
Claimant sustained personal injuries when he fell into a large hole adjacent to
a path used by students attending a Fine Arts Camp at West Virginia University.
The general law is that an institution is under a duty of ordinary or
reasonable care with regard to the condition of its grounds to see that they
are maintained in a reasonably safe condition, and, as the respondent failed in
this duty, the Court made an award to the claimant. Jacquelyn B. Eisenberg, parent and next friend of Mark
Harold Eisenbreg, an infant vs. Board of Regents
(CC-76-143) -. 273
The claimant was granted an award for a towing fee which she had to pay after
her vehicle, which had been stolen by an inmate from Huttonsville Correctional
Center, was later towed to another city by the West Virginia State Police. Ora T. Herron vs. Dept. of Public Safety and Dept. of
Corrections
(CC-76-108) 284
408 REPORTS STATE
COURT OF CLAIMS [W. Va.
The Court denied a claim for damage to claimant?s typewriter which occurred
when an involuntarily committed patient was issued a pass to seek legal
assistance from the claimant. The Court noted that an institution is not
negligent per se whenever a temporarily released patient causes damage to
someone?s property. James T. Kratovil
vs. Department of
Health, Division of Mental Health (CC-78-54)
200
Where the claimant filed a claim alleging damages sustained as the result of an
alleged unlawful revocation of his probation and subsequent confinement at
Huttonsville Correctional Center, the Court overruled respondent?s motion to
dismiss based upon the theory that the claimant had an adequate remedy at law
in the federal courts under the Civil Rights Act, 42 U.S.C. 11983. The Court
held that the agencies, West Virginia Board of Probation and Parole and West
Virginia Department of Corrections, named in the complaint as respondents, are
not considered ?persons? within the meaning of the Civil Rights Act. Lewis Dale Metz vs. State Board of Probation
and Parole and Dept. of Corrections (CC-79-155)
342
Claimant was awarded an amount which represented the balance due under a
contract for providing psychological services to the inmates of two
institutions where the respondent failed to terminate the contract by providing
30 days? written notice to the claimant in accordance with the provisions in
the contract. Positive Peer Culture,
Inc. vs. Dept. of Correc tion (CC-77-117)
285
Where the respondent, Department of Corrections, had a contract with the
claimant for certain psychological services to be provided to two institutions
of the respondent, and the claimant was orally notified that the contract would
expire and that the claimant would receive no compensation for the last 65 days
of the contract, the Court made an award, because oral notification was not in
compliance with the contract provision of 30 days? written notice. Positive Peer Culture, Inc.
vs. Dept. of Corrections (CC-77-1l7)
205
Where claimant?s decedent, while a patient in a State institution, sustained
injuries in a fall and later died, the Court held that the doctrine of res ipsa
loquitur cannot be invoked where existence of negligence is solely a matter of
conjecture or where it may be held that there was no negligence on the part of
the respondent; therefore, the Court denied the claim. Patty Sheets, Administratrix of the Estate
of Ray Samuel Six, deceased vs. Department of Health, Division of Mental
Health
(CC-76-80) - 332
Claimant was granted an award for damage to his vehicle when two inmates from
Huttonsville Correctional Center walked away from the institution, stole the
vehicle, and damaged it. To deny the claim would amount to imposing a penalty
upon a citizen of the State for living near a correctional institution. Albert K. Tyre vs. Dept. of Corrections (CC 78-178 263
The Court made an award to the claimant for damage to his vehicle caused by
inmates who had walked away from Huttonsville Correctional Center and stolen
the vehicle. A review of the law by the Court regarding acts of escapees from
institutions made it apparent that each claim must be
W. Va.] REPORTS
STATE COURT OF CLAIMS 409
decided on its own particular facts. Albert
K. Tyre vs. Dept.
of Corrections (CC-78-178) 263
PUBLIC OFFICERS
Where claimants filed a claim naming
individuals including the commissioner of banking, the receiver of Parkersburg
Savings & Loan Company, the Governor, and the legislature, the Court
dismissed the claims as the Court has no jurisdiction over any individual. Charles R. Evans & Ernestine
Evans vs. Department of Banking (CC-77-127)
168
REAL ESTATE
Where claimant?s house sustained
damage when respondent?s employees began to demolish the house in the aftermath
of the Williamson flood, the Court made an award to the claimant for the damage
caused by the negligence of the respondent. Gladys Barfield vs. Office of the Governor ? Emergency Flood Disaster Relief (CC-78-173) 237
The Court made an award to the claimant for damage to his property when
claimant?s fence was struck by snow plowing equipment used during snow removal
operations by an independent contractor of the Department of Highways. See Hubbs
v. Department of Highways, 12 Ct. Cl.
39 (1977). Frank G.
Barr vs. Department of Highways (CC-77-l41)
65
Where employees of the respondent tore down a damaged building on property belonging
to the claimant, the Court made an award for the damages to the building in
accordance with the stipulation entered into by the parties. Boone Sales,
Inc. vs. Department of Highways (CC-76-119)
92
Where the damage to claimant?s property was due to respondent?s lack of proper
maintenance of its road and the drain pipe under it, the Court made an award to
the claimant for the damages to her property established by appraisals offered
into evidence. Minnie Lee Brown vs.
Department of Highways
(D-999) 125
Where claimant?s property sustained damage during snow removal operations, the
Court made an award for the damage in accordance with the prior decision of Hubbs. v. Dept. of Highways, 12 Ct. Cl. 39 (1977). Eleanor F. Charbeneau & Eleanor B. Charbeneau vs. Department of
Highways (CC-
77-73) 67
Where claimant?s property was damaged by fire when em ployee of the respondent
were attempting to start a backfire
in order to control a forest fire, the Court held that the respon den is liable
for providing equitable compensation to the
claimant for her loss. Mrs. Richard L.
Cooper vs. Department
of Natural ResotLrces (CC-77?60) 93
The Court made an award to the claimant in accordance
with the stipulation filed by the parties which indicated that
in the performance of stone quarry operations a degree of
damage was caused to claimant?s property. B. H. Cottle and
B. H. Cottle, Executor of the Estate of Lucy M. Cottle, de cease vs. Department
of Highways (CC-77-49) 167
Where claimant?s fencing was damaged during snow removal operations being
performed by the respondent, the Court held the respondent liable for the
damage, Stanley N. Cosner vs.
Department of Highways (CC-78-182) 240
410 REPORTS STATE
COURT OF CLAIMS [W. Va.
Where claimants? fence was damaged by an employee of the
respondent during road grading operations, the Court made an
award to the claimant for the damage. Albert
D. Fentress &
Hazel S. Fentress vs. Department of Highways (CC-77-162) --
94
Where a portion of claimant?s fence was damaged by the respondent during snow
removal operations, the Court made an award to the claimant for the damages. Douglas Haney vs.
Dept. of Highways (CC-78-226) 250
Claimants were made an award for damage to their property
during snow removal activities. (See Hubbs
vs. Highways, 12
Ct. Cl. 39, 1977). Robert M. Hastings
& Linda Hastings, d/b/a
Hastings Stables vs. Department of
Highways (CC-77-94) 44
Claimants were granted an award for damage to their home which was caused by
blasting done by the respondent incident to the excavation of a cut through a
hill, since liability for damage proximately caused by blasting is absolute. Arnold G. Heater and Geraldine Heater vs. Dept. of
Highways (CC-78-l30) 310
Even though the Court agreed that the National Guard occupied the position of
an independent contractor when its members performed snow removal operations on
behalf of the respondent, the rule of non-liability is subject to certain
exceptions, one of which is where by statute a special duty is imposed upon the
respondent; therefore, the Court made an award to the claimant where members of
the National Guard, in removing snow from a main highway, performed their work
in a negligent manner, causing damage to claimant?s fence line. Kermit Reed Hubbs vs. Department of Highways
(CC-77-83) 39
Where respondent?s employees sprayed a weed killer adjacent to claimants?
property, and said weed killer caused damage to trees and shrubs on claimants?
property, the Court made an award to the claimants in accordance with the
written stipulation filed by the parties. Theodore Korthals &
Emile Korthals vs. Department of Highwfzys (D-1041) 59
Where the employees of the Department of Highways blocked a stream, which
caused periodic flooding on claimant?s property and resulted in a slip, the
Court made an award for the corrective work necessary to prevent further damage
to claimant?s property. Herman F. Lilly vs.
Department of High way (CC-77-133) 153
The Department of Highways has a legal duty to use reasonable care to maintain
a ditch line in such condition that it will carry off surface water and prevent
it from passing upon property adjacent to the road. Therefore, the Court made
an award where the claimant proved by a preponderance of the evidence that the
respondent failed to maintain the ditch line properly, and as a result of such
failure, a landslide occurred causing damage to the property of the wards of
the claimant. Polly Stevens, Guardian
of the Person and Estate of James Walter Stevens and Timothy Stevens vs.
Department of
Highways (D-688) ? 180
The proper method of establishing damage to real estate is to determine the
difference in the fair market value of the property before and after the
landslide; therefore, the Court used the expert testimony of the witness who
determined the
W. Va.] REPORTS
STATE COURT OF CLAIMS 411
damage to the real estate via this method. Polly Stevens, Guardian of the Person and Estate of James Walter Stevens
and Timothy Stevens vs. Department of Highways (D-688) 180
An award was made to the claimant for damage to a rock wall where employees of
the State damaged the same during the cleanup of flood debris in Williamson,
West Virginia. Thelma J. Stone vs. Office of the
Governor ?
Emergency
Flood Disaster Relief (CC-78-1l) 202
Where the respondent failed to maintain a ditch adjacent to the front of
claimants? property, and as a result of such failure, the claimants? home and
contents were damaged by water and mud, the Court made an award for such damage
in accordance with the written stipulation filed by the parties. Charles E. and Mary P. Taylor vs. Department of
Highways
(CC-78-206) 261
The Court denied claimant?s claim for damage to her property allegedly
sustained as the result of diversion of a natural drain course by the
respondent. The evidence would have required the Court to engage in pure
speculation, which it cannot do. Ruth
Ann Toppings vs. Department of Highways (D
1007 ?
261
An award was made to claimants for damage to their home from excessive water
run-off which occurred as the result of respondent?s negligent re-surfacing
activities and inadequate drain design and maintenance of a street and bridge
adjacent to claimants? property. Loraine
White and Velma White vs.
Dept. of Highways (CC-78-139) 271
RELOCATION ASSISTANCE
Where the respondent had actual notice
of claimants? claim for relocation expense, the fact that the notice was not
written in the form required by respondent did not bar the claim, because the
memorandum did not have the force and effect of law; therefore, the Court made
an award to the claimants for said relocation expense. Olie G. Bastin and Priscilla
Ba.stin vs. Department of Highways (CC-76-24)
86
SCOPE OF EMPLOYMENT
Where the actions of the claimant as
an employee of the respondent were not within the scope of his employment, and
were not the type of actions reasonably expected of an employee in the type of
work he was performing, the Court denied claimant?s claim for attorney fees and
a settlement in the civil action wherein the employee of the respondent was
involved in an altercation with the employee of a contractor of the respondent.
Robert A. Heater vs. Department of
Highways
(CC?77?179) 137
SICK LEAVE
Where the respondent State agency
improperly deducted a period of absences from claimant?s pay and the claimant
had accumulated sufficient sick leave to cover that period, the Court made an
award for the wage deduction made by the respondent. A. M. Fredlock, II vs. Dept. of Highways (CC 78-3 197
STATE AGENCIES
Where respondent?s agent damaged a
steel expansion joint incident to snow removal and left it protruding above the
sur
412 REPORTS STATE
COURT OF CLAIMS [W. Va.
face of the highway so as to create a hazard to vehicular traffic, respondent
was negligent and was liable for damage thereby done to the undercarriage of
claimant?s vehicle. Charles H.
Spradling, Jr. vs. Department of Highways (CC 78-68 -
336
STATUTES
The failure of the postal service to
deliver a Notice of Claim within three days does not provide legal ground for
the Court to deny respondent?s Motion to Dismiss said claim when the claim was
not received by the Clerk and was not filed until after the two-year period of
limitation set forth in West Virginia Code ?55-7-6. Elwood Clark, Admin. of the Estate of
Sharon Marie Clark, dec. vs. State Fire Marshal (CC-76-l02) 77
Where claimant contended that the period of limitation was tolled due to the
incapacity of the decedent?s mother, and there was a delay in appointing an
administrator for decedent?s estate, the Court held that the period of
limitation is not tolled until an administrator is appointed; therefore, the
claim was dismissed based upon the fact that the claim was not filed within the
period of limitation set forth in West Virginia Code ?55-7-6. Elwood Clark, Admin. of the Estate of Sharon
Marie Clark, dec. vs. State Fire Marshal (CC-76-102) 77
Where the claimant sustained damage to her property as a result of a backfire
started on her property by employees of the respondent who were attempting to
control a forest fire, the Court held that Code ?20-3-4 authorizes the
respondent to start backfires and exonerates the fire fighters from criminal
responsibility. However, this does not mean that a property owner?s property
can be destroyed without compensation for the loss. Mrs. Richard L. Cooper vs. Department of Natural
Resources (CC-77-60) 93
The Court denied a claim by owners of a business who alleged that the
respondent interfered with a closing-out sale which resulted in a loss of
sales. The Court concluded that the claimants did not comply with the legal
requirements for conducting such sale, and there was no evidence to establish
improper conduct toward the claimant on the part of the employees of the
respondent. Robert V. Heverley, Jr. and
Kathleen Heverley, d/b/a Frances Shoppe, Inc. vs. Department of
Labor (CC-77-8l) 251
Where the claimant filed a claim alleging damages sustained as the result of an
alleged unlawful revocation of his probation and subsequent confinement at
Huttonsville Correctional Center, the Court overruled respondent?s motion to
dismiss based upon the theory that the claimant had an adequate remedy at law
in the federal courts under the Civil Rights Act, 42 U.S.C. ? 1983. The Court
held that the agencies, West Virginia Board of Probation and Parole and West
Virginia Department of Corrections, named in the complaint as respondents, are
not considered ?persons? within the meaning of the Civil Rights Act. Lewis Dale Metz vs. State Board of Probation and Parole
and Dept. of Corrections (CC-79-155)
342 The Claimant filed a claim for damages allegedly sustained
as the result of the alleged unlawful revocation of his probation and subsequent
confinement at Huttonsville Correctional Center when he was released upon a
writ of habeas corpus.
W. Va.] REPORTS
STATE COURT OF CLAIMS 413
The respondent made a motion to dismiss the claim based upon the theory that
claimant had an adequate remedy at law in the federal courts under the Civil
Rights Act, 42 U.S.C. ? 1983. The Court sustained the motion to dismiss as to
specific individuals named in the claim in accordance with W. Va. Code 14-2-13,
since under the provision, the Court has no jurisdiction over any individual
person. Lewis Dale Metz us. State Board of Probation and Parole and Dept. of
Corrections
(CC-77-155) 342
The jurisdiction of the Court of Claims is clearly set forth and limited by
Code ? 14-2-13, which specifically excludes an action against the Board of
Education in the definition of a State agency. Therefore, the Court sustained
the respondent?s motion to dismiss as the Court has no jurisdiction over such
claims. Timothy Rakes, by his father and next friend, Andrew Rakes, and Andrew
Rakes vs. Board of Education of the
County of Lincoln (CC-77-55) 147
The claimants sought recovery of treble damages for the wrongful cutting of
trees on their property under W. Va. Code ?61-3-48a. The Court refused to make
such an award, as such damages are in the nature of penalties, and this Court
was not created for that purpose. The Court made an award for compensatory
damages only. Fred K. Testa & Claudia I. Testa vs. Department of
Highways (D-669a), Saleem A. Shah &
Theresa A. Shah vs. Department of Highways (D-669b) 115
Where the claimant inadvertently paid twice for an order of Uniform Vehicle
Identification Stamps, the Court made an award for the second payment as the
agency involved had no statutory authority to make such refund. Transport
Motor
Express, Inc. vs. Public Service Commission (CC-78-4) 192
Interest will not be charged against the respondent under W. Va. Code 14-3-1
where the claimant contractor receives the tentative final estimate but does
nothing for several months; however, once the claimant contractor responds to
the respondent on the final estimate, interest begins to run again until the
point in time when the contractor is paid the final estimate. Vecellio &
Grogan, Inc. vs. Department of Highways
(D-914, D-993, D-9l8, Par. C) 294
STIPULATION AND AGREEMENT
Where claimant and respondent
stipulated that claimant?s automobile was damaged when it struck a hole which
was full of water and obscured from view, the Court made an award to the
claimant. David E. Alvis vs Department of High way (CC-77-62) 47
Where claimant?s automobile struck a hole which was full of water and obscured
from view, the Court made an award for damage to the automobile based upon the
stipulation filed by the parties. David E. Alvis v. Department of Highways
(CC-77?62) 47
An award was made to claimant for services rendered when the claim was
submitted to the Court upon pleadings which indicated that the services were
received and the amount was reasonable. Arthritis Care Associates vs.
Division of Vocational
Rehabilitation (CC-77-220) 85
414 REPORTS STATE
COURT OF CLAIMS [W. Va.
Where claimant and respondent stipulated that the claimant?s truck sustained
damage due to a plate and bolts protruding from the highway, the Court made an
award to the c]aimant, as the negligence on the part of the respondent was the
proximate cause of the damage. Wayne Bayliss vs. Dept.
of Highways (CC-78-276) 279
Where employees of the respondent tore down a damaged building on property
belonging to the claimant, the Court made an award for the damages to the
building in accordance with the stipulation entered into by the parties. Boone Sales,
Inc.
vs. Department of Highways (CC-76-119) 92
Where claimants and respondent stipulated that the claimants? vehicle was
damaged when it struck a large hole which was covered with water on the date of
the accident, the Court made an award to the claimant in accordance with the
written stipulation filed by the parties. Darrell E. Buckner & Betty
S.
Buckner vs. Department of Highways (CC-77-129) 41
Where employees of the respondent negligently damaged telephone cables
belonging to the claimant, the Court made an award for the damage in accordance
with the stipulation filed by the parties. The C & P Telephone Company
of W. Va. vs.
Department of Highways (CC-76-l32) 194
Where employees of the respondent State agency negligently supervised students
who were using firearms with the result that bullets damaged claimant?s
telephone cables, the Court made an award to the claimant for the damages. The
C & P Telephone Co. of W. Va. vs. Department of Natural
Resources
(CC-78-105) 164
Where respondent?s sign crew damaged claimant?s water main while installing a
stop sign, the Court made an award for the damage in accordance with the
stipulation filed by the parties. Claywood Park Public Service District vs.
Dept. of
Highways (CC-78-87) 192
Where the parties stipulated that an employee of the respondent negligently
threw a rock against claimant?s vehicle, breaking the windshield, the Court
made an award to the claimant for said damage. Virginia Sue Cook vs.
Department of
Highways (CC-77-144) 58
The Court made an award to the claimant in accordance with the stipulation
filed by the parties which indicated that in the performance of stone quarry
operations a degree of damage was caused to claimant?s property. B. H.
Cottle and B. H. Cottle, Executor of the Estate of Lucy M.
Cottle, deceased vs. Department of Highways (CC-77-49) 167
Claimant?s automobile sustained damage when his wife was driving the vehicle
across a bridge where a metal plate became loose and struck the undercarriage
of the vehicle. The Court made an award for the damage in accordance with the
stipulation filed by the parties. Rush Fields vs. Department of
Highways (CC-78-77) 149
Where the parties stipulated that the respondent had knowledge of a large hole
on a ramp of Interstate 64, but had made no repairs and failed to erect any
warning signs, the Court made an award to the claimant in the amount stipulated
for the damage sustained by the vehicle after striking the hole.
W. Va.] REPORTS
STATE COURT OF CLAIMS 415
Bradford G. Frazier vs. Department of
Highways (CC-77-
201) ?
69
An award was made to the claimant, in
accordance with the stipulation filed by the parties, where claimant?s vehicle
struck a fallen limb on a West Virginia highway, which limb was from a dead
tree located near the highway. Charles
R.
Gore vs. Department of Highways (CC-77-l97)
172
Where claimant?s trucks sustained damage as the result of striking a metal
sheet on a bridge which had been negligently placed by respondent?s employees,
the Court made an award to the claimant for said damage in accordance with the
written stipulation filed by the parties. Timothy J. Grimmett vs.
Department of Highways (CC-77-147) 51
Where claimant and respondent stipulated that claimant?s vehicle was damaged by
a board protruding from a bridge, the Court made an award, as the negligence of
the respondent was the proximate cause of the damage. Linda E. Hamilton vs.
Department of Highways (CC-78-260) 282
Where the parties stipulated that the respondent negligently failed to secure a
steel plate covering a large hole in Route 60 in South Charleston, and said
negligence resulted in damage to claimant?s car, the Court made an award to the
claimant for said damages. McHenry
Hudnall, Jr. v. Department of High way (CC-77-52)
26
Where respondent?s employees sprayed a weed killer adjacent to claimants?
property, and said weed killer caused damage to trees and shrubs on claimants?
property, the Court made an award to the claimants in accordance with the
written stipulation filed by the parties. Theodore Korthais
& Emile Korthals vs. Department of Highways (D-1041) 53
Where a piece of steel on a bridge punctured one of the
tires on claimant?s car beyond repair, the Court made an
award to the claimant for the damage in accordance with a
written stipulation filed by the parties. Charles P. Long vs.
Department of Highways (CC-78-115) 173
Claimant was granted an award for damage to his automo bil when a ?MEN WORKING?
sign blew over and struck said
automobile. Harold Mahaffee vs.
Department of Highways
(CC?77?136) 211
The claimant contractor was granted an award for rock
excavation where rock was unexpectedly encountered in the
construction of Canaan Valley State Park and the parties
stipulated the claim. MeCloy
Construction Company, Inc. vs.
Dept. of Natural Resources (CC-77-221)
312
Where employees of the respondent wrongfully delayed claimant in performing a
contract for printing the West Virginia State Map, and as a result, the
claimant suffered financial loss, the Court made an award to the claimant for
the losses in accordance with the written stipulation filed by the parties. Morrison Printing Co., Inc. vs. Department of High way (CC-78-36) 142
Where the respondent knew of dangerous road conditions caused by a tar spill on
State Route 4 in Clay County, and negligently failed to correct the
situation, and the respondent also knew that several accidents had occurred at
this point,
416 REPORTS STATE
COURT OF CLAIMS [W. Va.
resulting in torn-out guardrails, the Court made an award on a stipulated claim
of wrongful death where claimant?s decedent died as a result of coming upon the
tar spill and sliding through the torn-out guardraiis into a creek where he
died. Helen L. Norvell, Executrix of the Estate of Glenn Hartsel
Norvell, deceased vs. Department of Highways (D-936) 106
The Court made an award to the claimant for the construction of a fireplace at
Cass Scenic Railroad. The case was submitted upon the pleadings, in which the
respondent admitted liability. Jerry Austin Rexrode vs. Department of
Na tura Resources (CC-77-202) 110
As the result of construction activities near claimant?s house, water flooded
claimant?s basement and caused damage to personal property; the Court made an
award to the claimant for the damage in accordance with the written stipulation
filed by the parties. Mae Russell vs. Department of Highways
(CC?78?81) 177
Where the parties stipulated that the claimant lawfully drove his dump truck
across a bridge belonging to the respondent, which bridge collapsed, and the
evidence was that an inspection in 1974 had revealed that the bridge had a low
limit of zero tons, but the respondent failed to repair the bridge or post a
weight limit on it, the Court made an award to the claimant for the loss of
said truck. Charles E. Schooley vs.
Department of Highways (CC-76-131) 28
Where the parties stipulated that claimant?s automobile was damaged when a
metal plate became dislodged from a hole on a state highway, the Court made an
award to the claimant for the damage in accordance with the stipulation. Lawrence
Craig Skaggs vs. Department of Highways (CC-77-56) - - 3
Where the respondent failed to maintain a ditch adjacent to the front of
claimants? property, and as a result of such failure, the claimants? home and
contents were damaged by water and mud, the Court made an award for such damage
in accordance with the written stipulation filed by the parties. Charles E.
and Mary P. Taylor vs. Department of Highways
(CC?78-206) 261
Where blasting activities by employees of the respondent caused damage to
claimants? property, the Court made an award for such damage in accordance with
the stipulation filed by the parties. John Tillinghast & Janet
Tillinghast vs.
Department of Highways (CC-77-80) 159
Where damage to the foundation of claimant?s dwelling was caused by water
run-off from a nearby road right-of-way maintained by the respondent, the Court
made an award for the damage as it was stipulated that negligence on the part
of the respondent was the proximate cause of the damages.
W. F. Webb vs. Department of Highways (CC-78-191) 204
An award was made to the claimant for damages resulting from respondent?s
breach of an employment contract with the claimant where the parties agreed to
the amount in a stipulation filed with the Court. John M. Weber vs. Board of
Regents
(CC-77-229) --
-- 270
W. Va.] REPORTS
STATE COURT OF CLAIMS 417
STREETS AND HIGHWAYS?See also Falling
Rocks; Landslides; Motor Vehicles; Negligence
The Court made an award to the
claimant for personal injuries and damages to his automobile where the
stipulation filed by the parties indicated that the claimant struck a water-
filled hole in the surface of the highway approximately 7? inches deep and two
to three feet wide, which hole had existed for some time prior to the accident.
Elvin S. Alford vs. De partmen of
Highways (D-990) 14
Where claimant alleged damage to his truck as the result of hitting a
water-filled pothole, and the evidence revealed that the respondent had
attempted on several occasions to repair the hole through the use of both hot
mix and cold mix, but due to a drainage problem, water would accumulate and
cause the mix to wash out and re-create the pothole, the Court denied the
claim, as the respondent is under a duty only to use reasonable care to keep
the highways in a reasonably safe condition, and the respondent had discharged
the duty in this particular case. James
R. Ban hart vs. Department of Highways
(CC-78?119) ? 236
Where claimant and respondent stipulated that the claimant?s truck sustained
damage due to a plate and bolts protruding from the highway, the Court made an
award to the claimant, as the negligence on the part of the respondent was the
proximate cause of the damage. Wayne
BayUss vs. Dept. of
Highways (CC-78-276) ? 279
Where claimant?s automobile sustained damage when she struck a pothole, the
Court determined that there was no notice of the dangerous condition of the
highway, nor was there such a neglect of duty that would create liability on
the part of the respondent, and the claim was disallowed. Cynthia
Lou Bradshaw vs. Department of Highways (CC-78-30)
187
Where a contractor of the Department of Highways damaged
an expansion joint on an interstate and failed to make any
effort to notify the respondent or warn motorists, the Court
made an award to the claimant for damages to his automobile
when he struck said expansion joint. The law is well settled
that the principal must bear the consequences of his agent?s
negligence, and therefore, the respondent is liable to the
claimant. Jeffrey D. Bubar vs.
Department of Highways (CC
78-27 204
Where claimant sustained damage to his automobile when he struck a pothole in a
portion of a road which was otherwise free from defects, the Court denied the
claim. Arnefl Church
vs. Department of Highways (CC-78-79) - 165
Where the employees of the respondent sprayed portions of a highway with an
anti-spalling compound used for the preservation of concrete and there were no
warning signs or flagmen before, during, or after the job, and as a result, the
claimant was involved in an accident where another automobile slid on the treated
portion of the roadway and into the claimant, causing injuries thereto, the
Court made an award to the claimant. Michael
H. Coen & Ruth Coen vs. Department of
Highways (D-1008) 119
Where the negligence of the respondent was the proximate cause of the accident,
as it failed to provide for the safety of
418 REPORTS STATE
COURT OF CLAIMS [W. Va.
the traveling public during and after the application of an anti-spalling
compound to the highway, the Court made an award to the claimant for injuries
received in an accident when an automobile being driven in the lane opposite
the claimant slid in the anti-spalling compound across the highway and into the
claimant, causing the injuries to the claimant. Michael H. Coen & Ruth Coen vs. Department of High
way (D-l008) ? 119
Where claimant?s fencing was damaged during snow removal operations being
performed by the respondent, the Court held the respondent liable for the
damage. Stanley N. Cosner vs.
Department of Highways (CC-78-182) 240
Where the claimants sustained damage to their property due to the negligence of
respondent?s employees in snow removal operations, the Court held that it was
negligence on the part of the operator of the equipment to fail to confine his
activities within the right-of-way of the road. See also Hubbs vs. Department of Highways, 12 Ct. Cl. 39 (1977). Clyde W. Cummings & Betty L. Cummings vs. Department of Highways,
(CC-77-102) 41
Where a hole in the road appeared suddenly and without
warning, proof of actual or constructive notice is a prerequisite
to establishing negligence; therefore, the Court denied the
claim since respondent did not have notice of the particular
hole in this claim in time to prevent the accident. (See Hoslcins
vs. Department of Highways, 12 Ct. Cl.
60, 1977). John F.
Cummings vs. Department of Highways (CC-76-77)
59
Where the claimant struck a rock in a construction area
after having been signaled forward by a flagman, the Court
denied the claim as the evidence disclosed that the claimant
failed to exercise reasonable care under the circumstances,
since the presence of a flagman at a construction site is suf ficien to alert a
motorist to the possibility of a dangerous
condition. James L. Dykes vs.
Department of Highways (CC-
78-225) 349
The respondent Department of Highways may not be held
liable for negligent maintenance of a section of highway until
the date of final acceptance of the highway by the respondent;
therefore, in a claim for damage to a tractor-trailer which
occurred when the driver proceeded onto the berm of an
entrance ramp to 1-77 and, in so doing, passed over a metallic
post which extended out of the berm, the Court held that the
Department of Highways was not liable since the State had
not yet signed and approved the final acceptance for the high way Econo-Car International, Inc. vs. Department of High way (CC-76-32) 80
Due to a lack of evidence presented in the claim, the Court
denied a claim against the respondent for the cost of gas lost
by reason of a break in a private gas line alleged to have been
caused by respondent?s snowplow. Evans
Lumber Company vs.
Department of Highways (CC-78-109) 246
Where the parties stipulated that the respondent had knowledge of a large hole
on a ramp of Interstate 64, but had made no repairs and failed to erect any
warning signs, the Court made an award to the claimant in the amount stipulated
for the damage sustained by the vehicle after striking the hole.
Bradford G. Frazier vs. Department of
Highways (CC-77-201) 69
W. Va.] REPORTS
STATE COURT OF CLAIMS 419
Where claimant?s automobile was damaged when it struck a loose piece of
blacktop, and the claimant failed to establish that the respondent either knew,
or in the exercise of cdinary care, should have known about the defect in the
road, the Court denied the claim. Charles W. Grose vs. Department of
Highways (CC-77-75) 25
Claimant was denied a claim for damage to his vehicle which occurred when the
vehicle struck an embankment as the Court determined that, even though the
respondent was negligent in failing to maintain a culvert causing accumulation
of water on the highway, the claimant was guilty of contributory negligence
which proximately contributed to the accident.
Lloyd Harding Gwinn vs. Dept. of Highways (CC-77-191) 128
The Court denied claimant?s claim for damage to his vehicle sustained when the
claimant drove his vehicle into water on the highway which caused him to loose
control and drive into an embankment, as the Court determined that claimant?s
failure to cross the double line when there was no approaching traffic was
negligence. Lloyd Harding Gwinn vs. Dept. of
Highways (CC-77-191) 128
A claim for personal injuries sustained by the claimant in an accident alleged
to have been caused by a blocked culvert, which caused water to flow across a
highway, was denied by the Court as there was no showing that the respondent
knew or should have known that there was a clogged culvert, nor was there any
showing that respondent was negligent in permitting the partial flooding of the
highway. Karen Halter vs.
Department of Highways (CC-77-123) 327
Where a portion of claimant?s fence was damaged by the respondent during snow
removal operations, the Court made an award to the claimant for the damages. Douglas
Haney vs.
Dept. of Highways (CC-78-226) 250
Where claimant?s automobile sustained damage as the result of striking
construction plates which were not securely fastened down on the highway, the
Court made an award to the claimant for the damages as the negligence of the
respondent was the proximate cause of the damage. Howard A.
Haynes vs. Department of Highways (CC-78-281) 283
Where the claimant struck a large hole in the inside eastbound lane of 1-70
just beyond the Wheeling Tunnel, and the evidence disclosed that the hole
apparently came into existence within an hour of the accident, the Court denied
the claim since proof of actual or constructive notice is required. Patricia
S. Hoskins vs. Department of Highways (CC-76-79) 60
Where the evidence indicated that a dangerous condition appeared suddenly and
that the respondent moved promptly to take safety precautions as soon as it
became aware of the problem, the Court denied a claim where the claimant struck
a large hole which had appeared within an hour of the accident, because
negligence on the part of the respondent was not proved. Patricia S. Hoskins
vs. Department of High way (CC-76-79) 60
Where the parties stipulated that the respondent negligently failed to secure a
steel plate covering a large hole in Route 60 in South Charleston, and said negligence
resulted in damage to claimant?s car, the Court made an award to the
420 REPORTS STATE
COURT OF CLAIMS [W. Va.
claimant for said damages. McHenry
Hudnall, Jr. vs. Depart men of Highways (CC-77-52)
? 26
The claimant was granted an award for damage to his automobile when a portion
of ceiling tile fell from the Wheeling Tunnel onto the automobile, because the
respondent, Department of Highways, is responsible for the maintenance of the
Wheeling Tunnel. Alvin 0. Hunter vs. Dept. of Highways
(CC-77-68) 198
Claimant was granted an award for damage to her automo bil when her automobile
ran over a sign belonging to the
respondent as the Court held that leaving a sign upon the
traveled portion of the highway constituted negligence. Peggy
Keyser vs. Department of Highways (CC-78-38)
199
Claimants were granted awards for personal injuries sust.ained in a
single-vehicle accident when the vehicle struck three large potholes. The
evidence indicated that the holes had been there for a substantial period of
time, creating a dangerous condition of which the respondent either knew, or,
in the exercise of ordinary care, should have known. Forest Joe King,
et al. vs. Dept. of Highways (CC-77-37)
208
Even though the claimant demonstrated that there were defects in the highway
which caused the damage to his automobile, to establish negligence on the part
of the respondent there must be proof that the respondent either knew, or, in
the exercise of ordinary care, should have known about the defects. Without such
proof, the Court must disallow the claim.
John Lavender, Jr. vs. Department of
Highways (CC-77-85) 54
A claim for damage to the tire and rim of claimant?s automobile was denied
where there was no showing that the respondent had knowledge of the hole in the
road which was alleged to have caused the damage as the claimant failed to
prove a positive neglect of duty on the part of the respondent.
Gregory D. Lavinder vs. Department of
Highways (CC-77-19) 16
Where there was no evidence in the record of any notice to the respondent of
the defect in the road, the simple existence of such a defect does not
establish negligence per Se; therefore, the Court denied a claim for damage to
claimant?s vehicle, which had struck a pothole. Daniel Lewis Light vs. Depart men of Highways (CC-77-53) 61
The Court denied a claim for damage to claimant?s vehicle when said vehicle
slid upon ice on the highway into a median strip. There was no showing that the
respondent knew or should have known of the existence of ice on the highway,
and the law is well established that the State is neither an insurer nor a
guarantor of the safety of persons traveling on its highways. See Adkins vs. Sims, 130 W. Va. 645, 46 S.E. 2d 81 (1974). Gregory K. Lipscomb vs. Dept. of
Highways (CC-78-
48) 322
An award was made to claimant for paint damage to her automobile when she
encountered a large paint spill on the highway and was unable to avoid going
through it. Debris J.
Lively vs. Department of Highways (CC-77-228)
153
The claimant was denied an award for damage to his automobile which occurred
when his wife, who was driving, struck a hole in the road, damaging a tire and
rim. The Court has
W. Va.] REPORTS
STATE COURT OF CLAIMS 421
held many times that the State is not a guarantor of the safety of travelers on
its roads, and the user of the highways travels at his own risk. James C. MacKnight vs. Dept. of Highways
(CC-78-144b) ? ? 341
Where there was no evidence, and the evidence presented was conflicting, as to
the conditions of the roadway, the Court denied a claim where claimant?s
decedent, while driving his automobile, was involved in an accident alleged to
have been caused by a wet road covered with slag and cinders. The Court
concluded that if there were debris on the road, it was not caused by the
negligence of the respondent. Geraldine
May McCarthy, Administratrix of the Estate of Robert Eugene
McCarthy vs. Department of Highways (CC-76-33)
139
Where claimant sustained injuries to her leg when she stepped into a large hole
in the roadway, the Court made an award for the injuries sustained, as the
Court determined that the respondent had constructive knoweldge of said hole
and was negligent in failing to take remedial measures or to warn the public of
the presence of the hole. Rhoda Raynett
McIn tyr vs. Dept. of Highways (D-737)
213
As the evidence failed to establish that the respondent had
breached any legal duty owed to the claimant, the Court
denied claimant?s claim for damage to his automobile where
the vehicle struck a pothole. Rodger C.
Melling vs. Depart men of Highways (CC-78-33)
174
Where the respondent knew of dangerous road conditions caused by a tar spill on
State Route 4 in Clay County, and negligently failed to correct the situation,
and the respondent also knew that several accidents had occurred at this point,
resulting in torn-out guardrails, the Court made an award on a stipulated claim
of wrongful death where claimant?s decedent died as a result of coming upon the
tar spill and sliding through the torn-out guardrails into a creek where he
died. Helen L. Norvell, Executrix of
the Estate of Glenn Hartsel
Norvell, deceased vs. Department of Highways (D-936)
106
The Court denied a claim for property damage to claimant?s vehicle when he
struck a large depression in the road. The law in West Virginia is well settled
that contributory negligence on the part of the claimant, however slight, which
contributes to proximately cause an accident, will preclude the recovery of
damages, and under the facts of this claim, claimant failed to take the
precautions necessary to protect his own safety and property. Charles Edward Pauley vs.
Department of Highways (CC-78-l36) ? 215
Where an accident occurred in a manhole on property not owned nor maintained by
the respondent, the Court denied the claim. Maxine V. Pauley vs. Department of Highways (CC-77-
208) 143
A claim for damage to an automobile as the result of strik in a pothole was
denied as it must be established that, having
received notice of a defect in the road, the respondent must
also have sufficient time within which to take remedial action.
Dallas Poe vs. Department of Highways (CC-78-97) 201
The Court denied a claim where claimant?s son, while operating claimant?s
automobile, struck a pothole which was filled with water as there was
insufficient evidence to establish
422 REPORTS STATE
COURT OF CLAIMS [W. Va.
notice or constructive notice to the respondent of the pothole, and the simple
existence of a pothole does not establish negligence per se. Robert M. Pratt vs. Department of High way (CC-78-122) 176
Where the claimant admitted knowledge of the existence of the condition of the
road and of the particular pothole which caused damage to her automobile when
she was forced by oncoming traffic to go into said hole, the Court denied the
claim because of the lack of due care on her part. Tom Pro ff it
and Myrna Prof f it vs. Department of Highways (CC-77-69) 18
Where claimant alleged that its decedent was killed in an accident which
resulted when the respondent failed to provide adequate drainage for a
backwater pond, thereby causing water from the pond to overflow and freeze upon
the highway, and the evidence failed to establish any connection whatsoever
between the water in the pond and the ice on the highway, the Court denied the
claim. Meredith K. Rice, Adm. of the
Estate of Sped Q. Abbas, deceased vs. Department of Highways
(D-875) ? 12
Where the evidence failed to establish flooding or any connection at all
between the water in a pond adjacent to the highway and the ice on the highway,
which ice was alleged to have caused the accident resulting in the death of
claimant?s decedent, the claimant failed to prove any negligence on the part of
the respondent, and the claim was denied. Meredith K. Rice, Adm. of the Estate of Syed Q. Abbas, deceased vs.
Department of Highways (D-875) 12
It is well established that the State is neither an insurer nor a guarantor of
the safety of persons traveling on its highways, and such law is applicable to
pedestrians crossing the highway. Therefore, where the claimant suffered
injuries as a result of falling in a hole in the pavement of a road, the Court
held that there must be proof that the respondent had actual or constructive
notice of the defect in the road in order to establish negligence. Jeanne Robinson vs. Department of Highways
(CC-77?33) 145
Where claimants sustained personal injuries when their vehicle struck a broken
section of interstate, causing the vehicle to leave the highway and overturn,
the Court made an award to the claimants as the respondent was negligent both
in permitting a dangerous condition to remain on the highway and in failing to
take effective action to warn motorists of the condition. James Ryan & Joyce Ryan vs. Dept. of Highways
(CC?77-189) 329
Where claimant alleged that an accident occured due to the negligent design of
the highway which narrowed to the left at the place of the accident, the Court
held that since no proof of negligence was presented by the claimant and there
were no defects in the pavement, the respondent met the required standard of
care, and the claim was denied. Marie
T. Sadd vs.
Department of Highways (CC-77-36) 63
The Court has held many times that the respondent, Department of Highways, is
neither an insurer nor a guarantor of the safety of persons travelling on its
highways. Adkins vs. Sims, 130 W. Va. 645, 46 S.E. 2d 81 (1947). The Court applied
this principle in denying a claim for damage to an automobile
W. Va.] REPORTS
STATE COURT OF CLAIMS 423
where the automobile slipped into a ditch and the evidence disclosed that the
road was assigned a low priority as it was difficult to maintain due to its
inaccessibility. Romie C. Sayre
vs. Department of Highways (CC-78-64)
178
The Court made an award to claimant for damage to an automobile when claimant?s
wife, while driving the vehicle, struck a hole in the road. The Court held that
the respondent, which owes a duty of reasonable care and diligence in the
maintenance of highways, had notice of the dangerous condition, and repairs
should have been made within a reasonable time. Larry Keith Smith vs. Dept. of Highways (CC-78-
259) 351
Where one of the claimants testified that she and her husband were familiar
with the highway, traveling it several times a week, and candidly admitted that
she was aware of the existence and location of the pothole, the Court held that
even if the respondent were guilty of ngligence in failing to repair the hole,
the claimants were guilty of contributory negligence in failing to exercise a
proper lookout in order to avoid striking the hole. Joseph and Marie Sowers vs. Department of
Highways (CC-77-51) 21
The claimant was granted an award for damage to an automobile which he was
driving but which did not belong to him where the automobile struck a damaged
expansion joint, because the independent contractor of the respondent, who
damaged the expansion joint, negligently failed to make any effort to notify
the respondent or to warn motorists. Charles
H. Spradling, Jr. vs. Department of Highways (CC 78-68 ?
336
Where claimant?s vehicle struck a signpost in the road and there was no
evidence that the post belonged to the respondent or was knocked from the side
of the road onto the highway, the Court denied the claim. Foster Starcher vs. Department of
Highways (CC-76-l20) 157
Claimant was granted an award for damage to her vehicle when she struck a large
hole on Route 119 near Morgantown, West Virginia, when the Court held that the
road was one of the main arteries into the city, and respondent should have
known of the condition of the road and failed to keep it in a reasonably safe
condition. Connie Ann Stone vs.
Department
of Highways (CC?78?l77) 259
Where claimants filed a claim for personal injuries sustained in an accident at
a railway underpass where a train derailment resulted in holes in the road
which allegedly caused the accident, the Court denied the claim as the evidence
indicated that there was a ?ROUGH ROAD? sign placed by the respondent and that
frequent repairs were made to the surface of the highway; therefore, the
respondent was not guilty of negligence which proximately caused the accident. Billy Joe Vinson and Paul F. Vinson vs. Department
of Highways (CC-77-l57) 219
Claimant alleged personal injuries suffered when she fell after the heel of her
shoe became caught in a gap between a sidewalk and curb. The Court denied the
claim as the claimant failed to exercise reasonable care for her own safety,
for the law is well settled that a pedestrian has the duty to
424 REPORTS STATE
COURT OF CLAIMS [W. Va.
exercise ordinary and prudent care for his own safety and to
look for and protect himself from known and visible dangers,
and failure to do so constitutes contributory negligence as a
matter of law. See Vance vs. Dept. of
Highways, 10 Ct. Cl. 189
(1975). Chrystine Winer vs. Dept. of
Highways (CC-78-170) -- 353
TAXATION
Where the claimant requested a refund
of the 5% tax paid to the Department of Motor Vehicles when she purchased a
second-hand automobile, but returned the automobile and was refused the refund
because the tax had already been sent by the dealer to the department, the
Court determined that the sale was nullified by mutual agreement, and the
claimant should be refunded the tax. Sandra
S. Ciemente vs. Department of Motor Vehicles (CC-77-167) 48
The claimant was refunded the 5% tax on an automobile purchased, and the
two-dollar title fee, when the Court determined that the parties nullified the
transaction and the Department of Motor Vehicles was unable to make a refund of
the tax. George M. Custer vs.
Department of Motor Vehicles
(CC-77-86) 48
Claimant was granted an award for the refund of the 5% tax paid on the purchase
of an automobile where the sale between the parties was nullified and the sales
price refunded, and the respondent?s State agency was unable to make a refund
of the tax. Anthony R. Rosi vs.
Department of Motor Vehicles (CC-
77-138) 110
TREES AND TIMBER
An award was made to the claimant, in
accordance with the stipulation filed by the parties, where claimant?s vehicle
struck a fallen limb on a West Virginia highway, which limb was from a dead
tree located near the highway. Charles
R.
Gore vs. Department of Highways (CC-77-197)
172
Where claimant?s automobile was damaged when a limb from a live tree fell onto
her car while she was visiting a State park, the Court disallowed the claim as
there was no explanation of why the limb fell, nor any proof it fell as a
result of negligence on the part of the respondent. Harold Hersom and
Eleanore Hersom vs. Dept. of Natural Resources (CC-77-170) 312
Claimants filed a claim for injuries received when a limb from a dead tree fell
while claimants were fishing at North Bend State Park. The Court denied the
claim as this was not an area of the park designated for fishing, nor was it
patrolled or maintained by the respondent for use by the public; therefore, the
respondent was not negligent in its maintenance of the area. Frances J. Larch and William E. Larch vs.
Dept. of Natural Resources (CC-77-l20)
291
Where a live tree fell across the highway and claimant?s van collided with the
tree, resulting in damages to the van and injuries to the claimant, the Court
concluded that there was no evidence that the respondent knew or in exercise of
ordinary care should have known that the tree posed a hazard to traffic on the
highways; therefore, the Court denied the
claim. Randall I. Samples vs. Dept. of
Highways (CC-77-82) -- 217
W. Va.] REPORTS
STATE COURT OF CLAIMS 425
Claimant was granted an award for damage to her property and a black walnut
tree, which damage occurred when respondents were repairing a road in front of
claimant?s property. Barbara H. Spitzer vs. Department of Highways
(CC-78?164) 314
Where the respondent negligently caused snow to he piled on claimant?s
property, killing certain trees, the Court made an award to the claimant for
the damage sustained. Willard P. Teets, Attorney in fact for Percy E.
Teets vs. Department
of Highways (CC-77-158) 203
The claimants sought recovery of treble damages for the wrongful cutting of
trees on their property under W. Va. Code ?61-3-48a. The Court refused to make
such an award, as such damages are in the nature of penalties, and this Court
was not created for that purpose. The Court made an award for compensatory
damages only. Fred K. Testa & Claudia I. Testa, vs. Department of
Highways (D-669a) Saleem A. Shah
& Theresa A. Shah, vs. Department of Highways (D-669b) 115
Where employees of the respondent wrongfully cut down trees on property
belonging to the claimants, even though the employees believed that they had a
right to do so, the respondent is liable to the claimants for the damages. Fred
K. Testa and Claudia I. Testa vs. Department of Highways (D-669a), Saleem
A. Shah & Theresa A. Shah vs. Department
of Highways (D-669b) 115
Where employees of the respondent wrongfully cut down trees on property
belonging to the claimants, even though the employees believed that they had a
right to do so. the respondent is liable to the claimants for the damages. Fred
K. Testa and Claudia I. Testa vs. Department of Highways (D-669a), Saleem
A. Shah & Theresa A. Shah vs. Department of High way (D-669b) 115
Claimant was granted an award for personal injuries sustained at a State forest
when a large limb fell from a dead tree near a picnic table at which the
claimant was sitting, as the respondent was negligent for failing to remove the
dead tree. Edith Ann Thompson & Roger Dale Thompson vs. Department of
Natural Resources (CC-77-7) 132
WAGES
Where an employee of the respondent
worked overtime but was not paid for the same, as the request for overtime was
not presented to the respondent in that particular fiscal year, the Court made
an award for the services rendered. Richard
L. Cunningham vs. Dept. of Public Safety (CC-78-258) 241
The Court made an award for overtime compensation to three employees of the
Department of Health where the overtime was certified by the West Virginia
Department of Labor. Jack L. Rader vs. Department of Health (CC-78-223),
Carl L. Baker, Jr. vs. Department of Health (CC-78-224), and H.
M.
Curry vs. Department of Health (CC-78-251) 277
Where the respondent State agency improperly deducted a period of absences from
claimant?s pay and the claimant had accumulated sufficient sick leave to cover
that period, the Court made an award for the wage deduction made by the
respondent. A. M. Fredlock, II vs. Dept. of Highways (CC 78?3 197
426 REPORTS STATE
COURT OF CLAIMS [W. Va.
The Court made an award to the claimant for overtime services rendered to the
respondent State agency. Joseph
Larry Garrett vs. Department of Public Safety (CC-78-237) 247
The Court made an award to the claimant for the difference between an
agreed-upon salary and a salary actually paid the claimant after she went to
work for the respondent State agency, as the respondent admitted the validity
of the claim and the amount due her. Peggy S. Gott vs. Department of
Health, Division of Mental Health (CC-77?153) 95
The claimant filed a claim for compensatory time worked over two years before
the filing of the action, and the Court held that the claim was barred by the
statute of limitations under Code ?21-5C-8. Nathan Haddad, Jr. vs.
Department of Motor Vehicles & Department of Finance & Administration
(CC?77-2) 130
The Court made an award to an employee of the respondent who was dismissed but
later reinstated, where the amount of the claim was for wages for the period of
the suspension.
Thomas F. Lambert vs. Department of Welfare (CC-77-193) 101
An award for overtime was made to the claimant where
his request for overtime had not been honored because it was
not presented for payment within the fiscal year in which the
services were rendered. Harry Glenn Lucas, Jr. vs. Depar-.
tment of Public Safety (CC-78-253) 253
An award for overtime was made to the claimant where the
request for payment had not been made within the fiscal year
in which the services were rendered. Lowell J. Maxey vs.
Dept. of Public Safety (CC-78-238) 254
Where claimants sought awards for overtime compensation while they were
employed as houseparents at respondent?s facility at Institute, West Virginia,
the respondent contended that the decision of Airkem Sales and Service, et
al. v. Department of Mental Health, 8 Ct. Cl. 180 (1971), applied, since
insufficient funds were expired in the personal service account from which the
overtime compensation claims could have been paid. The Court denied this
contention based upon the case of State ex ret. Crosier vs. Callaghan, 236
S.E. 2d 321 (1977), wherein the Supreme Court held that the liability for
unpaid wages is incurred against an employer at the time liability is
determined; therefore, the question of sufficient funds is immaterial. Elva
B. Petts and James M. Preston vs. Division
of Vocational Rehabilitation (D-927d) and (D-927i) 222
Where the record was entirely sii?nt on the question of whether or not an
express or an implied agreement that sleeping hours and lunch periods were to
be considered hours worked, the Court held that the time would be considered
hours worked in accordance with regulations of the West Virginia Department of
Labor, specifically, Section 3.11 of Regulation 3. The Court considered these
hours in determining awards to claimants who sought awards for overtime
compensation while employed as houseparents at respondent?s faciltity at
Institute, West Virginia. Eiva B. Petts and James M. Preston vs. Division of
Vocational Rehabilitation (D-927d)
and (D-927i) 222
Due to a clerical error, the claimant was not paid in his specific
classification under Civil Service, and the Court made
A
W. Va.] REPORTS
STATE COURT OF CLAIMS 427
an award to the claimant for the additional pay in accordance with Code
?14-2-19. Odlund Haney Spangler, Jr. vs. Department of Employment
Security (CC-78-86) 148
Claimant received an award for the difference in her total pay where she worked
full time but received pay for working only part-time due to a misunderstanding
between the head of the institution where claimant was employed and an
administrator of the agency, who instructed the claimant to work full time. Mary
Jo Sharp vs. Department of Health, Division
of Mental Health (CC-77-66) 112
The Court made an award to claimant for overtime compensation in accordance
with the prior decision rendered in
Jack L. Rader et al. vs. Department of Health, 12 Ct. Cl. 277
(1979). Harold L. Weber, Jr. v. Department of Health (CC 78-270 323
Claimant was granted an award for the difference between his salary as acting
director of an agency and administrative officer of that agency as the evidence
indicated that the Civil Service System had formally approved and appointed the
claimant as Acting Director at a salary above what claimant was actually paid. Richard
L. Weekly vs. Office of Emergency
Services (CC-77-219a&b) 123
Where claimant sought payment for salary due him for professional services
perftrnied for the respondent, and the respondent admitted the validity of the
claim, the Court made an award to the claimant. Silas C. Wiersma vs. Dept.
of
Health, Division of Mental Health (CC-78-158) 234
WATERS AND WATERCOURSES?See also
Drains and Sewers; Flooding
Where claimant?s property was damaged
as the result of actions by the respondent in constructing a highwall on Route
19, and the proper measure of damage is the diminution in market value, the
Court made an award in accordance with the decision in Jarrett vs. E. L.
Harper and Son, Inc. --
W. Va.
235 S.E.2d 362 (1977). Eugene Lafferty and Wanda Lafferty
vs. Department of Highways (CC-76-44) 100
Claimants were granted an award for damage to their personal property when mud
and water washed into their apartment due to negligent construction activities
on the part of the respondent. See also West vs. Department of Highways, CC-77-205,
12 Ct. Cl. 193 (1979). Robert Smith and Elizabeth
Smith vs. Department of Highways (CC-78-290) 287
Where damage to the foundation of claimant?s dwelling was caused by water
run-off from a nearby road right-of-way maintained by the respondent, the Court
made an award for the damage as it was stipulated that negligence on the part
of the respondent was the proximate cause of the damages.
W. F. Webb vs. Department of Highways (CC-78-19l) 204
W. VA. UNIVERSITY?See Board of Regents