H. B. 4697
(By Delegate Klempa)
[Introduced February 18, 2008; referred to the
Committee on Finance.]
A BILL to amend the Code of West Virginia, 1931, as amended, by
adding thereto a new article, designated §5-22B-1, §5-22B-2,
§5-22B-3, §5-22B-4, §5-22B-5, §5-22B-6 and §5-22B-7; all
relating to prompt payment for public construction contracts;
enacting the West Virginia Fairness in Public Construction
Contract Act.
Be it enacted by the Legislature of West Virginia:
That the Code of West Virginia, 1931, as amended, be amended
by adding thereto a new article, designated §5-22B-1, §5-22B-2,
§5-22B-3, §5-22B-4, §5-22B-5, §5-22B-6 and §5-22B-7, all to read as
follows:
ARTICLE 22B. FAIRNESS IN PUBLIC CONSTRUCTION CONTRACT ACT.
§5-22B-1. Short title; applicability of article.
This article shall be known and may be cited as the "West
Virginia Fairness in Public Construction Contract Act". The rights
and duties prescribed by this article are not waivable or variable
under the terms of a contract. The terms of any contract waiving the rights and duties prescribed by this article is unenforceable.
§5-22B-2. Definitions.
For the purpose of this article:
(1) "Construction" means furnishing labor, equipment, material
or supplies used or consumed for the design, construction,
alteration, renovation, repair or maintenance of a building, water
or waste water treatment facility, oil line, gas line, appurtenance
or other improvement to real property, including any moving,
demolition or excavation of a building. "Construction" does not
mean the design, construction, alteration, renovation, repair or
maintenance of a road, highway or bridge.
(2) "Contract" means a contract or agreement concerning
construction made and entered into by and between an owner and a
contractor, a contractor and a subcontractor or a subcontractor and
another subcontractor.
(3) "Contractor" means a person performing construction and
having a contract with an owner of the real property or with a
trustee or agent of an owner.
(4) "Owner" means a public entity that holds an ownership
interest in real property.
(5) "Public entity" means the State of West Virginia,
political subdivisions, cities, counties, state universities or
colleges, school districts, all special districts, joint agreement
entities, public authorities, public trusts, nonprofit corporations
and other organizations which are operated with public money for
the public good.
(6) "Retainage" means money earned by a contractor or
subcontractor but withheld to ensure timely performance by the
contractor or subcontractor.
(7) "Subcontractor" means any person performing construction
covered by a contract between an owner and a contractor but not
having a contract with the owner.
(8) "Substantial completion" means the stage of a construction
project where the project, or a designated portion thereof, is
sufficiently complete in accordance with the contract, so that the
owner can occupy or utilize the constructed project for its
intended use.
(9) "Undisputed payment" means payments which all parties to
the contract agree are owed to the contractor.
§5-22B-3. Contract payments; provisions against public policy.
(a) Subject to the provisions of subsections (b), (c), (d),
(e), (f), (g) and (h) of this section, and sections four and five
of this article, and any amendments thereto, all owners,
contractors and subcontractors, who enter into a contract for
public construction after the effective date of this article, shall
make all payments pursuant to the terms of the contract.
(b) The following provisions in a contract for public
construction are against public policy and are void and
unenforceable:
(1) A provision that purports to waive, release or extinguish
the right to resolve disputes through litigation in court or
substantive or procedural rights in connection with such litigation except that a contract may require nonbinding alternative dispute
resolution as a prerequisite to litigation;
(2) A provision that purports to waive, release or extinguish
rights to file a claim against a payment or performance bond,
except that a contract may require a contractor or subcontractor to
provide a waiver or release of such rights as a condition for
payment, but only to the extent of the amount of payment received;
and
(3) A provision that purports to waive, release or extinguish
rights of subrogation for losses or claims covered or paid by
liability or workers compensation insurance except that a contract
may require waiver of subrogation for losses or claims paid by a
consolidated or wrap-up insurance program, owners and contractors
protective liability insurance, or project management protective
liability insurance or a builder's risk policy.
(c) All contracts for public construction shall provide that
payment of amounts due a contractor from an owner, except
retainage, shall be made within thirty days after the owner
receives a timely, properly completed, undisputed request for
payment according to terms of the contract, unless extenuating
circumstances exist which would preclude approval of payment within
thirty days. If such extenuating circumstances exist, then payment
shall be made within forty-five days after the owner receives such
payment request.
(d) The architect or engineer of record or agent of the owner
shall review, approve and forward undisputed requests for payment to the owner within seven business days of receipt from the
contractor.
(e) If the owner fails to pay a contractor within the time
period set forth in subsection (c), the owner shall pay interest
computed at the rate of eighteen percent per annum on the
undisputed amount to the contractor beginning on the day following
the end of the time period set forth in subsection (d).
(f) A contractor shall pay its subcontractors any amounts due
within seven business days of receipt of payment from the owner,
including payment of retainage, if retainage is released by the
owner, if the subcontractor has provided a timely, properly
completed and undisputed request for payment to the contractor.
(g) If the contractor fails to pay a subcontractor within
seven business days, the contractor shall pay interest to the
subcontractor beginning on the eighth business day after receipt of
payment by the contractor, computed at the rate of eighteen percent
per annum on the undisputed amount.
(h) The provisions of subsection (g) shall also apply to all
payments from subcontractors to their subcontractors.
§5-22B-4. Retainage and withholding.
(a) An owner, contractor or subcontractor may withhold no more
than ten percent retainage from the amount of any undisputed
payment due.
(b) An owner must release the retainage on any undisputed
payment due on a construction project within thirty days after
substantial completion of the project; however, if any subcontractor is still performing work on the project under its
subcontract, an owner may withhold that portion of the retainage
attributable to such subcontract until thirty days after such work
is completed.
(c) If an owner, contractor or subcontractor fails to pay
retainage, if any, pursuant to the terms of a contract for public
construction or as required by this article, the owner, contractor
or subcontractor shall pay interest to the contractor or
subcontractor to whom payment was due, beginning on the first
business day after the payment was due, at a rate of eighteen
percent per annum.
(d) Nothing in this section prevents early release of
retainage if it is determined by the owner, the contractor and the
project architect or engineer, that a subcontractor has completed
performance satisfactorily and that the subcontractor can be
released prior to substantial completion of the entire project
without risk or additional cost to the owner or contractor. Once
so determined, the contractor shall request such adjustment in
retainage, if any, from the owner as necessary to enable the
contractor to pay the subcontractor in full, and the owner shall,
as part of the next contractual payment cycle, release the
subcontractor's retainage to the contractor, who shall, as part of
the next contractual payment cycle, release such retainage as is
due to the subcontractor.
§5-22B-5. Undisputed payments.
If any undisputed payment is not made within seven business days after the payment date established in a contract for public
construction or in this article, the contractor and any
subcontractors, regardless of tier, upon seven additional business
days' written notice to the owner and, in the case of a
subcontractor, written notice to the contractor, shall, without
prejudice to any other available remedy, be entitled to suspend
further performance until payment, including applicable interest,
is made. The contract time for each contract affected by the
suspension shall be extended appropriately and the contract sum for
each affected contract shall be increased by the suspending party's
reasonable costs of demobilization, delay and remobilization.
§5-22B-6. Actions under this article.
In any action to enforce section three, four or five of this
article and any amendments thereto, including arbitration, between
a contractor and subcontractors or subcontractors and
subcontractors, the court or arbitrator shall award costs and
reasonable attorney fees to the prevailing party. Venue of such an
action shall be in the county where the real property is located
and under West Virginia law. The hearing in such an arbitration
shall be held in the county where the real property is located.
§5-22B-7. Waiver of rights to collect damages ineffectual.
Any provision in a contract that purports to waive the rights
of a party to the contract to collect damages for delays caused by
another party to the contract is void, unenforceable and against
public policy. This provision is not intended to create a contract
between parties where a contract did not otherwise exist.
NOTE: The purpose of this bill is to enact a comprehensive
prompt payment law which requires public owners to pay contractors
undisputed amounts due within thirty days of receiving a proper
invoice - and contractors to pay subcontractors within seven days
of receiving payment from owners.
Strike-throughs indicate language that would be stricken from
the present law, and underscoring indicates new language that would
be added.